Division of Administrative Hearings, Florida
Latest Update: Oct. 05, 1977
Whether the Petitioner is entitled to an extension of time of 565 days for the completion of the project which is the subject of this proceeding, as opposed to the 367 days time extension which was granted for completion, and thereby is free from liquidated damages in the amount of $31,680.Liquidated damages should not be granted, but money due on completion should be reduced in part, paid in part.