UNITED STATES COURT OF APPEALS
                          For the Fifth Circuit



                              No. 97-20281



                      CENTURY MARINE INCORPORATED,

                                                       Plaintiff-Appellant;


                                   VERSUS


                       UNITED STATES OF AMERICA,

                                                        Defendant-Appellee.




           Appeal from the United States District Court
                For the Southern District of Texas
                            August 27, 1998


Before BARKSDALE, BENAVIDES and DENNIS, Circuit Judges.

DENNIS, Circuit Judge:

     Appellant   Century    Marine,      Inc.     (“Century”),      appeals the

district   court’s     dismissal    of      its    claims     for   additional

compensation under a fixed-price vessel repair contract with the

Maritime   Administration    of    the    United     States    Department   of

Transportation (“MARAD”). MARAD terminated the contract because of

Century’s default in failing to complete the work within the time

specified by the contract.     Century filed suit against the United

States seeking to have the termination for default converted to a

termination for the Government’s convenience; and for payments in

addition to the amount MARAD had paid Century under the terminated
contract.    After   a   bench    trial,      the   district     court   rejected

Century’s demands and dismissed its suit with prejudice.                       We

affirm.     On appeal Century does not contest the trial court’s

determination   that     its    contract      was   properly     terminated   for

default.    Despite its default, Century argues that it is entitled

to recover an amount equal to the unpaid balance of the full fixed

price of the contract less the cost of completion of the unfinished

work under the contract.         Century’s argument is contrary to well

established law and federal regulations.              Under the Government’s

termination of a fixed-price contract because of the contractor’s

default, the    Government       is   not   liable   to    the   contractor   for

unperformed or undelivered work.            Anticipated but unearned profits

are   not   recoverable    by     the   contractor        when   the   Government

terminates the contract for the contractor’s default or for the

convenience of the Government.              Century’s additional contention

that it should be compensated for extra work is also without merit.

There is warrant in the record and an applicable basis in law for

the district court’s rejection of this claim after a trial on the

merits.

                I. FACTUAL AND PROCEDURAL BACKGROUND

      In September 1992, Century and MARAD entered into a fixed-

price contract for the repair and renovation of cargo and ballast

tanks of the S.S. MOUNT WASHINGTON, a public vessel of the United

States.     Thereafter, MARAD issued three contract modifications

(“Mods”) that increased the contract value by $1,050,000.000, for

a total contract amount of $8,521,910.000.                   When Century fell


                                        2
behind schedule on the original completion date of May 3, 1993,

MARAD issued three additional Mods that extended the completion

date until September 15, 1993.       Despite these extensions, Century

continued to fall behind its work schedule. When it became evident

that Century could not complete the contract timely, by letter

dated September 8, 1993, MARAD terminated Century for default.1           At

the time of termination, MARAD had made progress payments to

Century of $5,903,135.50.      On September 22, 1993, the Government

issued Modification     No.   0009   (“Mod   9")   to   the   contract   that

adjusted the contract price for the value of the unfinished work,

and calculated the final progress payment to Century based on its

completed work.     MARAD eventually retained another contractor to

finish Century’s work.2

        Mod 9, admitted as a Government exhibit at trial, sets forth

the percentage of completion of each work item, and adjusts the

total contract price by deducting the contract value of Century’s

          1
          Pursuant to the Federal Acquisition Regulations, the
Government may, by written notice of default to the contractor,
terminate the contract in whole or in part if the contractor fails
to perform the services within the time specified in the contract
or any extension.     48 C.F.R. § 52.249.8(a)(1)(i).      “Federal
regulations which are based upon a grant of authority ‘have the
force and effect of law, and, if they are applicable, they must be
deemed terms of the contract even if not specifically set out
therein, knowledge of which is charged to the contractor.’”
General Eng’g & Mach. Works v. O’Keefe, 

, 780 (Fed.
Cir. 1993).
    2
      Under the Federal Acquisition Regulations, when the services
to be provided by the terminated contractor are still required
after default, the contracting officer shall repurchase the same
services against the contractor’s account as soon as practicable,
48 C.F.R. § 49.402-6(a), and the contractor is liable to the
Government for any excess costs incurred in acquiring services
similar to those terminated for default. 48 C.F.R. § 49.402-2(e).

                                     3
uncompleted work, estimated at $1,260,861.00.                 In Mod 9, MARAD

based the percentage of completion in part on Century’s own percent

completion figure provided in its last progress payment request

submitted to MARAD one week prior to termination, with this figure

adjusted for work accomplished by Century during the final week of

the terminated contract. The Government’s estimate in Mod 9 of the

contract value of Century’s uncompleted work also was based on a

thorough inspection and videotaping of each item of unfinished work

by    Richard    Volkmann,   the     contracting       officer’s         technical

representative, who testified at trial.

      Based on the Government’s calculations in Mod 9, MARAD made a

final payment to Century of $409,023.56, representing compensation

for all work performed after the latest progress payment but before

Century was terminated for default.            According to the contracting

officer’s decision denying Century’s administrative claims for

additional compensation, this final payment to Century represented:

(1) payment for the progress made by Century between the time of

its   last    progress   payment    and      termination     of    the   contract

($51,532.00); (2) payment of the balance of retainage owed to

Century      after   deducting     the       excess   cost    of    procurement

($285,539.06)3; and (3) payment of funds withheld at the direction

of the Government‘s legal department until a separate claim on

another contract was settled ($71,952.50).

      3
       Under the Federal Acquisition Regulations, “the contracting
officer shall use all retained percentages of progress payments
previously made to the contractor and any progress payments due for
work completed before the termination to liquidate the contractor’s
liability to the Government.” 48 C.F.R. § 49.406.

                                         4
     In July 1994, Century submitted a “Request For Equitable

Adjustment and For Conversion of a Termination For Default to a

Termination For Convenience.”                Century’s Request For Equitable

Adjustment      presented     an     administrative     claim    for    additional

payments of almost $1.3 million under the contract, based on

Century’s allegations that MARAD had underestimated the percentage

of completion of finished work items in Mod 9, and that MARAD was

not entitled to retain excess costs of reprocurement from the

retainage withheld from the final payment to Century because

Century was wrongfully terminated.              Century also asserted a claim

for $21,254 in extra work performed pursuant to Century’s Request

For Delivery Orders (RDOs).               Finally, Century requested that its

termination      for   default       be    converted   to   a   termination   for

convenience.

     In December 1994, the Government’s contracting officer issued

a final administrative decision on Century’s claims, denying any

further payments to Century.              This 48-page decision, with attached

supporting exhibits, rebuts in detail each allegation in Century’s

Request   For     Equitable        Adjustment,    concluding     that   Century’s

“termination for default is valid,” and that Century “is not

entitled to a further equitable adjustment.”

     In September 1994, pursuant to the Contract Disputes Act, 41

U.S.C. § 603, and the Suits in Admiralty Act, 46 U.S.C. § 741 et

seq., Century sued the United States in the Court of Federal

Claims, which transferred the case to the Southern District of




                                            5
Texas.4   The United States elected not to file a counterclaim

against Century for liquidated damages, which are recoverable

against a contractor terminated for default.             See 48 C.F.R. §§

49.402-6(c), 49.402-7, 49.402-2(e). Century’s claims were tried to

a judge in December 1996.

     In   the    district   court,    Century      presented   no   evidence

supporting the claim in its administrative level Request For

Equitable Adjustment that it was entitled to recover the excess

costs of reprocurement that the Government had deducted from

Century’s retainage.        Exhibit K of the Contracting Officer’s

decision, which was the only evidence of the Government’s excess

reprocurement    costs   and   the   amount   of   retainage   withheld   at

termination, was withdrawn at trial after Century objected to its

admissibility.

     On January 3, 1997, the district court issued findings of fact

and conclusions of law rejecting Century’s claims, finding that the

United States’ termination of Century for default was justified by

Century’s breach of the contract, and that Century had no valid

claim for an equitable adjustment to the contract.         Also on January

3, 1997, the district court rendered a final judgment dismissing

Century’s claims against the United States with prejudice.


      4
        Under § 603 of the Contract Disputes Act, subject matter
jurisdiction in appeals of administrative decisions involving
federal maritime contracts vests in the federal district courts,
rather than in the Court of Claims (now the Court of Federal
Claims) or the Court of Appeals for the Federal Circuit. Bethlehem
Steel Corp. v. Avondale Shipyards, Inc., 

, 93, 94 (5th
Cir. 1992). Government maritime contracts are otherwise governed
by the Contract Disputes Act. 

                                      6
     On January 10, 1997 Century filed a Motion to Amend or Make

Additional Findings of Fact, asserting that Century had made a

prima facie case on two claims that had not been rebutted by the

United States: (1) a claim for extra work performed on seven RDOs

in the amount of $20,583; and (2) a claim for the “contract

balance”   due    of    $1,293,218.54           resulting   from   the   following

computation:

           Modified Contract Amount                    $8,521,910.00
           Less-Payments and Deducts                   $6,492,159.46
           Less-Work not performed                     $ 714,187.00
           Less-Tow credit and Item 058                $   22,345.00
           Contract Balance Due                        $1,293,218.54


On March 4, 1997 the district court entered an order denying

Century’s Motion to Amend or Make Additional Findings of Fact.

Century appealed.

                         II.    STANDARD OF REVIEW

     The district court’s findings of fact must be reviewed under

the “clearly erroneous” standard of Fed R. Civ. P. 52(a).                       A

finding    of    fact   is     said    to       be   “clearly   erroneous”   when,

notwithstanding there is evidence to support it, the reviewing

court upon examination of the entire evidence is left with the

definite and firm conviction that a mistake has been committed.

Justiss Oil Co. v. Kerr-McGee Refining Corp., 

, 1062

(5th Cir. 1996) (citing United States v. United States Gypsum Co.,

, 395 (1948)).            With respect to the legal conclusions

reached by the trial court on the basis of the facts so found, this

court will conduct a de novo review.                 Reich v. Lancaster, 

1034, 1045 (5th Cir. 1995).

                                III. DISCUSSION

     On appeal, Century does not contest the district court’s

determination that MARAD properly terminated the contract for

Century’s default.       Nor does Century reurge its administrative

level   claim   that    MARAD    had   withheld    an   excessive   amount   of

retainage from the final payment to Century.             Century argues only

that the district court’s judgment denying its claims for the

“contract balance” and extra work was clearly erroneous and must be

reversed because: (1) Century made a prima facie case at trial for

its contract balance and extra work claims; (2) MARAD failed to

rebut Century’s proof on these claims; (3) the district court made

no express findings on each of these claims; and (4) no such

findings can be implied because an implied finding is not supported

by the evidence.

                A.    Century’s “Contract Balance” Claim

     Century contends that it made out a prima facie case for

recovery   of   a    “contract   balance”     of   either   $1,293,218.54    or

$768,889.54.    It is undisputed that the total amount of the fixed-

price contract, including all modifications, was $8,521,910.00, and

that MARAD had paid Century $6,492,159.46 for work completed prior

to Century’s termination for default, leaving an unpaid balance of

$2,029,750.54 under the contract at that time. MARAD and Century

presented conflicting technical expert evidence as to the estimated

cost of completing the contract: Century’s estimate was $736,532.00

and MARAD’s was $1,260,861.00.              Consequently, Century asserts,


                                        8
after subtracting the estimated cost of completing the work under

the contract from the unpaid balance, Century is entitled to the

difference, viz., either $1,293,218.54 or $768,889.54, depending on

whether the Century or the MARAD estimate is used.

       Century’s argument lacks a sound basis in law.               Termination

for    default   is    generally   the    exercise      of    the   Government’s

contractual right to completely or partially terminate a contract

because of the contractor’s actual or anticipated failure to

perform its contractual obligations.            48 C.F.R. § 49.401(a).       The

Government has the right to terminate a fixed-price contract for

default if the contractor fails to deliver the supplies or to

perform the services within the time specified in the contract. 48

C.F.R. § 49.402-1. Under a termination for default, the Government

is not liable for the contractor’s costs on undelivered work. 48

C.F.R. § 49.402-2(a).       In contrast, under a fixed-price contract

terminated for the convenience of the Government, a settlement

should compensate the contractor fairly for the work actually done

and for the preparations made for the terminated portions of the

contract, including a reasonable allowance for profit applicable to

that   work   and     preparations.       48   C.F.R.    §§    49.201,   49.202.

Anticipatory profits and consequential damages shall not be allowed

under either a termination for convenience or a termination for

default of a fixed-price contract.             48 C.F.R. §§ 49.201, 49.202,

49.402-2;     See Mega Constr. Co. v. United States, 

,

475 (1993); G.L. Christian & Assocs. v. United States, 

, 426 (Ct. Cl.), cert. denied, 

(1963).


                                      9
     Consequently, as a contractor terminated for default, Century

cannot, as a matter of law, recover the “unpaid balance” of the

contract less the “cost of completion” of the work under the

contract.      To allow such recovery would permit Century to do

indirectly what it could not do directly, viz., recover anticipated

but unearned profits after the contract has been terminated because

of its default.     A contractor’s right to recover for anticipated

profits arises only if the termination of the contract by the

Government is wrongful and constitutes a breach.                G.L. 

(citing United States v. Behan, 

, 346

(1884); United     States    v.   Spearin,     

,    138   (1918);

Broadbent Portable Laundry Corp. v. United States, 

,

132 (1921)).    Any recovery of profits by a contractor on a contract

terminated because of its own default is limited to earned profit

on work actually performed prior to the termination. Mega 

.

                         B. Century’s Claim For Extra Work

     Century    argues     that   the    district     court’s      findings   and

conclusions are legally insufficient because the court made no

express finding addressing its extra work claim, and that any

implied finding by the court on the extra work issue is not

supported by the evidence.

     Rule 52(a) of the Federal Rules of Civil Procedure provides

that “[i]n all actions tried upon the facts without a jury. . .,

the court shall find the facts specially and state separately its

conclusions of law thereon. . . .”           The articulation of findings of


                                        10
fact and conclusions of law allows this court to ascertain the

factual and legal bases for the district court’s decision, thereby

providing a sufficiently definite predicate for appellate review.

Chandler v. City of Dallas, 

, 90 (5th Cir. 1992).            But

Rule 52(a) “exacts neither punctilious detail nor slavish tracing

of the claims issue by issue and witness by witness.”                 Burma

Navigation Corp. v. Reliant Seahorse M/V, 

, 656 (5th

Cir. 1996) (quoting Schlesinger v. Herzog, 

, 139 (5th

Cir. 1993)); see also United States v. Northside Realty Assocs.,

Inc., 

, 1170 n.5 (5th Cir. 1973) (“‘Courts need not

indulge in exegetics, or parse or declaim every fact and each

nuance and hypothesis.’”) (quoting Gulf King Shrimp Co. v. Wirtz,

, 516 (5th Cir. 1969)).       The rule is satisfied if the

district   court’s    findings   give   the   reviewing   court   a   clear

understanding of the basis for the decision.       Burma 

.

     If a trial judge fails to make a specific finding on a

particular fact, the reviewing court may assume that the court

impliedly made a finding consistent with its general holding so

long as the implied finding is supported by the evidence.             In re

Texas Mortgage Servs. Corp., 

, 1075 n.12 (5th Cir.

1985); Gilbert v. Sterrett, 

, 1393 (5th Cir.), cert.

denied, 

(1975).

     According   to   the   district    court’s   factual   findings    and

conclusions of law, Century had been compensated for the ten valid

delivery orders under which it performed “extra work” to repair


                                   11
weld fractures.    The     court also reached the legal conclusion that

“there is no valid basis for an equitable adjustment to the

contract.”     In rejecting Century’s general claim for equitable

adjustment, which encompassed the extra work claim, the district

court impliedly found that Century was not entitled to compensation

for any other extra work.

     The district court’s 12-page findings of fact and conclusions

of law are sufficiently detailed to adequately state the factual

and legal bases for the district court’s denial of Century’s claim

for extra work, thereby providing a sufficiently definite predicate

for proper     appellate    review.      The    court’s    implied   denial    of

Century’s extra work claim is fully supported by the evidence,

particularly Mod 9, which sets forth the percentage of completion

for unfinished delivery orders; the contracting officer’s decision,

which provides detailed reasons for MARAD’s denial of Century’s

claims   for   extra   work;     and   the     testimony   of   Volkmann,     the

contracting officer’s technical representative, who testified that

he personally inspected and videotaped Century’s unfinished work

and that he researched and drafted 90% of the contracting officer’s

decision with the assistance of Billy Greer, another MARAD employee

who testified at trial.

     In so doing, we reject Century’s argument that the contracting

officer’s decision is a “pleading” and therefore cannot be used as

evidentiary    support     for   the   trial    court’s    implied   denial    of

Century’s claim for extra work.          Under the Contract Disputes Act,

contracting officers are not required to make specific findings of


                                       12
fact, but, if made, they “shall not be binding in any subsequent

proceeding.”          41 U.S.C. § 605(a).     However, there is nothing in the

Contract Disputes Act that prohibits the use of the contracting

officer’s findings and conclusions as evidence in a subsequent de

novo proceeding.5         Cupey Bajo Nursing Home, Inc. v. United States,

, 130 (1996) (“[T]his court reviews the facts and

law decided by a contracting officer similar to other evidence

before it[.]”).           Accord Lathan Co. v. United States, 

, 125 (1990) (“This court may weigh the [contracting officer’s]

findings and conclusions as it would any other evidence.”).                   See

Wilner v. United States, 

, 1403-04 (Fed. Cir. 1993) (en

banc) (expressly overruling pre-Contracts Dispute Act precedent

holding that a contracting officer’s decision “constitutes a strong

presumption or an evidentiary admission. . . albeit subject to

rebuttal,” but cautioning that its opinion does not “suggest[] that

a contracting officer’s final decision has no place in . . .

litigation in the Court of Federal Claims”).                Therefore, in its

role       as   the    finder-of-fact,   a    district   court   may   give   the

contracting officer’s administrative determinations weight, not

deference.       Mega 

.       Cf. Universal Camera

Corp. v. National Labor Relations Bd., 

, 493-94 (1951)

(holding that the nonbinding findings of an NLRB “trial examiner”


       5
      The Contract Disputes Act provides that, after a contracting
officer renders a decision on a claim, a contractor may bring an
action directly on the claim in the United States Court of Federal
Claims (formerly the United States Claims Court), 41 U.S.C. §
609(a)(1), where the action “shall proceed de novo in accordance
with the rules of the appropriate court.” 41 U.S.C. § 609(a)(3).

                                         13
may be considered in a subsequent appeal to establish whether an

employee’s removal was supported by substantial evidence); Chandler

v. Roudebush, 

, 864 n.39 (1976) (holding that prior

administrative findings can be used as evidence of the ultimate

matters at issue in a subsequent de novo proceeding).

     Accordingly, we conclude that the Contract Disputes Act does

not preclude the use of the contracting officer’s decision as

evidence of the ultimate matters at issue in a subsequent de novo

proceeding, provided that it is not given deference or a rebuttable

presumption of correctness.

                           IV.    CONCLUSION

     Having reviewed the record and considered all of Century’s

arguments, we conclude that the district court did not commit any

error of law or clear error of fact in finding Century in default

and in rejecting Century’s claims with prejudice. As for Century’s

“contract balance” argument, we conclude that there is no basis in

law for a defaulted contractor to recover the difference between

the unpaid balance of the contract and the cost of completing the

unfinished work under the contract.         It is well settled that a

defaulted   contractor   cannot   recover   anticipated   but   unearned

profits.    Accordingly, the judgment of the district court is

AFFIRMED.




                                   14
RHESA HAWKINS BARKSDALE, Circuit Judge, specially concurring:



     I concur in the judgment being AFFIRMED, but would do so on

the basis that, pursuant to the district court’s findings of fact

and conclusions of law, and the underlying evidence upon which they

are based (especially, modification No. 009 and the Government

contacting officer’s written response to the request for equitable

adjustment), Century Marine’s claims presented in this court fail,

to include its primary claim that it was not paid for work which it

performed.

     Concerning that primary claim, the references in the majority

opinion concerning anticipated but unearned profits seem wide of

the mark.    Such a “lost-profit” claim is not raised by Century

Marine; and, contrary to the approach taken by the majority, I

would not assume that this is the indirect or implied thrust of the

position asserted here.   To do as the majority has done results, in

my view, in this court reaching outside the record—something we

should not, indeed cannot, do.




                                 15