Filed: May 12, 2020
Latest Update: May 12, 2020
Summary: Case: 19-1478 Document: 47 Page: 1 Filed: 05/12/2020 NOTE: This disposition is nonprecedential. United States Court of Appeals for the Federal Circuit _ AHMED HALIM, Plaintiff-Appellant v. UNITED STATES, Defendant-Appellee _ 2019-1478 _ Appeal from the United States Court of Federal Claims in No. 1:12-cv-00005-EDK, Judge Elaine Kaplan. _ Decided: May 12, 2020 _ CARL COAN, III, Coan & Lyons, Washington, DC, for plaintiff-appellant. TANYA KOENIG, Commercial Litigation Branch, Civil Division, Unite
Summary: Case: 19-1478 Document: 47 Page: 1 Filed: 05/12/2020 NOTE: This disposition is nonprecedential. United States Court of Appeals for the Federal Circuit _ AHMED HALIM, Plaintiff-Appellant v. UNITED STATES, Defendant-Appellee _ 2019-1478 _ Appeal from the United States Court of Federal Claims in No. 1:12-cv-00005-EDK, Judge Elaine Kaplan. _ Decided: May 12, 2020 _ CARL COAN, III, Coan & Lyons, Washington, DC, for plaintiff-appellant. TANYA KOENIG, Commercial Litigation Branch, Civil Division, United..
More
Case: 19-1478 Document: 47 Page: 1 Filed: 05/12/2020
NOTE: This disposition is nonprecedential.
United States Court of Appeals
for the Federal Circuit
______________________
AHMED HALIM,
Plaintiff-Appellant
v.
UNITED STATES,
Defendant-Appellee
______________________
2019-1478
______________________
Appeal from the United States Court of Federal Claims
in No. 1:12-cv-00005-EDK, Judge Elaine Kaplan.
______________________
Decided: May 12, 2020
______________________
CARL COAN, III, Coan & Lyons, Washington, DC, for
plaintiff-appellant.
TANYA KOENIG, Commercial Litigation Branch, Civil
Division, United States Department of Justice, Washing-
ton, DC, for defendant-appellee. Also represented by
JOSEPH H. HUNT, KENNETH DINTZER, ROBERT EDWARD
KIRSCHMAN, JR.
______________________
Case: 19-1478 Document: 47 Page: 2 Filed: 05/12/2020
2 HALIM v. UNITED STATES
Before O’MALLEY, BRYSON, and CHEN, Circuit Judges.
BRYSON, Circuit Judge.
In 2006 and 2007, plaintiff Ahmed Halim purchased
several apartment complexes from the Department of
Housing and Urban Affairs (“HUD”) at foreclosure sales in
various cities. Mr. Halim entered into a series of contracts
with HUD relating to his purchase and operation of the
properties. Disputes arose with regard to Mr. Halim’s pro-
posal to self-manage one of the properties and his failure to
complete repairs at the other three properties and to main-
tain the housing units at those properties in habitable con-
dition. Based on its determination that Mr. Halim had
breached his contractual obligations regarding the repair
and maintenance of three of the properties and his failure
to make satisfactory arrangements for the management of
the fourth property, HUD retained funds that Mr. Halim
had deposited pursuant to the contracts. Mr. Halim filed
this action in the United States Court of Federal Claims
(“the Claims Court”) challenging HUD’s retention of those
funds. The Claims Court granted summary judgment to
the government with respect to Mr. Halim’s claims relating
to all four properties. We affirm.
I
The first of the four properties addressed by the Claims
Court was a 24-unit apartment complex in Flushing, Ohio,
called the Nichols Townehomes Apartments. HUD held a
foreclosure sale for the property in 2006. HUD advertised
the foreclosure sale through a “bid kit.”
The bid documents provided that the successful bidder
would be required to submit a $50,000 earnest money de-
posit immediately after the foreclosure sale. The bid docu-
ments also provided that the successful bidder would be
required to submit certain forms relating to the bidder’s
ability to manage the property appropriately. If HUD
Case: 19-1478 Document: 47 Page: 3 Filed: 05/12/2020
HALIM v. UNITED STATES 3
determined that the bidder/owner was unqualified to self-
manage the property, HUD could require the bidder/owner
to obtain the services of a qualified property management
firm. If the bidder/owner failed to retain those services,
HUD was entitled to reject the bid and retain the bidder’s
earnest money deposit. The successful bidder was required
to sign a copy of an agreement entitled “Terms and Re-
quirements of Foreclosure Sale—Acknowledgement by
Bidder” that mirrored those requirements described in the
bid documents.
Mr. Halim was the high bidder on the property. He
signed the “Terms and Requirements of Foreclosure Sale—
Acknowledgement by Bidder” agreement and submitted
the $50,000 earnest money deposit.
Mr. Halim advised HUD that he intended to self-man-
age the property, and he submitted various forms in sup-
port of his request to be permitted to manage the property
without an independent management firm. After receiving
the forms, HUD advised Mr. Halim that he had failed to
demonstrate that he or his management company had the
experience required to manage the property. Among other
problems, HUD advised Mr. Halim that several of the
forms were “incomplete or . . . in need of correction/clarifi-
cation.” In addition, HUD noted that Mr. Halim’s state-
ment in support of his intention to self-manage the
property “does not indicate any previous experience in Pro-
ject Based Section 8 [federally subsidized] housing, nor did
you include any experience of company staff.” HUD there-
fore advised Mr. Halim that he needed to retain a property
management firm and that if he did not, HUD would reject
his bid and retain his earnest money deposit.
Mr. Halim did not retain a property management firm
as directed. Instead, he submitted revised forms to HUD
in support of his request to self-manage the property. HUD
concluded that the submitted documents, even as revised,
failed to demonstrate that he was qualified to manage the
Case: 19-1478 Document: 47 Page: 4 Filed: 05/12/2020
4 HALIM v. UNITED STATES
property. HUD therefore rejected his bid and retained his
earnest money deposit.
The parties filed cross-motions for summary judgment.
Mr. Halim argued that HUD acted in bad faith when it re-
fused to permit him to self-manage the Nichols
Townehomes property and canceled the sale. For that rea-
son, he argued, HUD breached the contract’s implied cove-
nant of good faith and fair dealing.
The Claims Court rejected that argument. It noted
that in order to demonstrate bad faith, Mr. Halim was re-
quired to show by clear and convincing evidence that HUD
had the specific intent to injure Mr. Halim. The court held
that Mr. Halim had not pointed to any evidence of bad faith
on HUD’s part. In addition, the court noted that Mr. Halim
offered no evidence in support of his “bald assertion” that
the forms he submitted in support of his request to self-
manage the Nichols Townehomes property were “essen-
tially the same” as the forms he had submitted in connec-
tion with other properties that he had been permitted to
self-manage. The court added that Mr. Halim had offered
no evidence that the contexts in which the forms were sub-
mitted in connection with the other properties were com-
parable to the Nichols Townehomes. The court therefore
denied Mr. Halim’s summary judgment motion and
granted summary judgment to the government with re-
spect to that property.
Before this court, Mr. Halim has not pressed his “bad
faith” claim. Instead, he argues that HUD’s rejection of his
request to self-manage the property was arbitrary and ca-
pricious because HUD had allowed him to self-manage
other properties. Before the Claims Court, however, Mr.
Halim did not advance his current argument that HUD’s
actions were arbitrary and capricious. To be sure, at one
point in his opposition Mr. Halim stated that HUD’s ac-
tions were “arbitrary and made in bad faith.” But the “ar-
bitrary and capricious” argument was wholly undeveloped.
Case: 19-1478 Document: 47 Page: 5 Filed: 05/12/2020
HALIM v. UNITED STATES 5
And Mr. Halim has not addressed the government’s con-
tention that in the trial court he argued that HUD had
acted in “bad faith,” while on appeal he argues that HUD
acted “arbitrarily and capriciously.” As such, we deem that
argument waived. See Fresenius USA, Inc. v Baxter Int’l,
Inc., 582 F.3d 1288, 1296 (Fed. Cir. 2009) (“If a party fails
to raise an argument before the trial court, or presents only
a skeletal or undeveloped argument to the trial court, we
may deem that argument waived on appeal.”).
We also reject the “arbitrary and capricious” argument
on the merits. Mr. Halim’s entire argument is based on a
short declaration created in connection with the litigation.
In that declaration, Mr. Halim stated that HUD had ap-
proved him to self-manage five other properties, and that
he was managing two of those properties at the time he
submitted his bid on the Nichols Townehomes Apartments.
He also stated that at least two of the forms he submitted
to HUD to demonstrate his qualifications to self-manage
the other properties were “essentially the same” as the ver-
sion of those forms he submitted for the Nichols
Townehomes Apartments.
Mr. Halim contends that because HUD allowed him to
self-manage other HUD properties, it was required to per-
mit him to self-manage this one. We disagree. The picture
Mr. Halim paints, even viewed in the light most favorable
to him, is not one of unfair conduct of the sort necessary to
make out his claim of breach of an implied covenant. Mr.
Halim does not address the merits of HUD’s decision not to
permit him to self-manage the Nichols Townehomes, ex-
cept to argue that HUD’s action in the case of the Nichols
property was inconsistent with its actions in the case of
other properties that he was allowed to self-manage. Yet
the contract made clear that the decision whether to allow
an owner to self-manage a property was within HUD’s dis-
cretion. Rather than proving improperly restrictive con-
duct on HUD’s part, Mr. Halim’s declaration may simply
Case: 19-1478 Document: 47 Page: 6 Filed: 05/12/2020
6 HALIM v. UNITED STATES
show that HUD treated him more leniently than it was re-
quired to with respect to those other properties.
Contrary to Mr. Halim’s argument, HUD’s decisions
with respect to each property must be assessed based on
the circumstances relating to that particular property. Mr.
Halim has not provided any evidence that the circum-
stances relating to the Nichols property are comparable to
the circumstances relating to any of the other properties.
Moreover, the fact that HUD may have permitted an
owner to self-manage in one case cannot, in effect, estop the
agency from concluding in another case that the owner
should not be permitted to self-manage the property, where
there is no evidence of affirmative misconduct on the part
of the agency. See, e.g., United States v. Ford Motor Co.,
463 F.3d 1267, 1278–79 (Fed. Cir. 2006); Dantran, Inc. v.
U.S. Dep’t of Labor,
171 F.3d 58, 66–67 (1st Cir. 1999).
In short, Mr. Halim failed to demonstrate that HUD’s
decision with respect to this particular property was an im-
permissible exercise of its discretion. The Claims Court
correctly ruled that the government was entitled to sum-
mary judgment that the government did not breach its
agreement with Mr. Halim when it exercised its right to
insist that he designate a management firm to manage the
property rather than allowing him to manage the property
himself. 1
1 In passing, Mr. Halim says that because he did not
submit one of his forms on time, his bid should have been
rejected and his earnest money deposit refunded. Accord-
ing to Mr. Halim, that is another example of how HUD
acted arbitrarily and breached its contract with him. It is
not clear to us that Mr. Halim preserved that argument be-
cause it directly contradicts his allegations in the com-
plaint. See Fourth Amended Complaint at 5, Halim v.
United States, Case No.1:12-cv-00005 (Fed. Cl. Jan. 9,
2015) (“Plaintiff timely submitted all of the documents he
Case: 19-1478 Document: 47 Page: 7 Filed: 05/12/2020
HALIM v. UNITED STATES 7
II
The second property addressed by the Claims Court
was a 40-unit apartment complex in Schenectady, New
York, known as the Schenectady 40 Apartments. HUD
held a foreclosure sale for the property on May 31, 2006.
The bid documents explained that the successful bidder
would have to make certain specified repairs to the prop-
erty to HUD’s satisfaction within 24 months after closing.
The attachment detailing the required repairs explained
that the repairs would be considered completed only after
(1) the purchaser provided written certification that the re-
pairs were complete; (2) the purchaser requested a final in-
spection by HUD; and (3) HUD verified in writing that
completion and compliance had been achieved. HUD esti-
mated that the repairs would cost $1,614,336 and required
the purchaser to deposit $403,584 in escrow as security for
the repairs. In addition to requiring that certain enumer-
ated repairs be completed, the bid documents separately
said the purchaser would be responsible for making any
other repairs necessary to meet applicable state and local
codes.
Mr. Halim was the high bidder on the property at the
HUD foreclosure sale. After the award, Mr. Halim entered
into a Foreclosure Sale Use Agreement with HUD in July
2006. He agreed to complete the required repairs by July
2008 and secured a letter of credit for $403,584 to cover the
repair escrow deposit. The agreement stated that “HUD
may cash the [letter of credit] and apply the funds to cor-
rect latent defects in the completed repairs if the purchaser
is unable or unwilling to make such repairs” within the re-
quired timeframe.
was required to submit to HUD . . . .”). In any event, Mr.
Halim has not identified any authority requiring HUD to
refund his deposit under those conditions.
Case: 19-1478 Document: 47 Page: 8 Filed: 05/12/2020
8 HALIM v. UNITED STATES
In addition, Mr. Halim entered into a Housing Assis-
tance Payment (“HAP”) contract with HUD. As part of that
arrangement, Mr. Halim agreed to bring all the units into
compliance with HUD’s Uniform Physical Condition
Standards (“UPCS”). Unlike the other repairs Mr. Halim
agreed to make, any UPCS repairs needed to be completed
within 180 days. The parties’ agreement, however, re-
quired that after the initial 180-day grace period all the
units had to be maintained “in good and tenantable condi-
tion, and in accordance with the UPCS” at all times during
the HAP contract. Once the UPCS repairs were completed,
Mr. Halim could begin billing HUD for HAP payments,
which are subsidies that cover a portion of the tenants’
rent. HUD could inspect the units whenever it deemed it
necessary to assure itself that the units were being main-
tained in compliance with the UPCS. If HUD determined
that a single unit was not in compliance with the require-
ments of the UPCS, HUD could exercise any of its remedies
under the parties’ agreement for “all or any” units subject
to the HAP agreement. Those remedies included termina-
tion of the HAP agreement and recovery of any overpay-
ments.
An inspector designated by HUD conducted several in-
spections of the property to determine whether the post-
closing repairs had been completed and whether the units
complied with the UPCS. 2 By March 2008, only 32 percent
of the required post-closing repairs had been done.
2 HUD’s inspector created two types of reports. In
his “post-closing inspection” reports, he detailed how many
of the repairs specified in the Foreclosure Sale Use Agree-
ment had been completed. In his “UPCS inspection” re-
ports, he detailed the extent of compliance with the UPCS,
as required by the HAP agreement. We will likewise refer
to “post-closing” repairs and UPCS inspection results sep-
arately.
Case: 19-1478 Document: 47 Page: 9 Filed: 05/12/2020
HALIM v. UNITED STATES 9
In November 2008, HUD issued a formal notice that
Mr. Halim was in breach of the Foreclosure Sale Use
Agreement. HUD gave him an additional 12 months to
perform the necessary repairs, but it added a condition to
obtaining that extension. HUD required Mr. Halim to sub-
mit within 10 days of the letter a schedule for the satisfac-
tory completion of all required repairs. HUD said that if it
did not receive a response and/or schedule that was ac-
ceptable to the department within 10 days, HUD would
take legal action, including retention of the cash held in the
repair escrow.
In response to the notice, Mr. Halim offered to schedule
a follow-up inspection, but he apparently did not offer a
proposed schedule of repairs. HUD’s inspector completed
a two-day follow-up inspection on April 1, 2009. Only one
of the 40 apartments passed the UPCS inspection. With
respect to the post-closing repairs, the inspector noted that
there had not been any substantial improvements since the
previous inspection that had occurred more than a year
earlier.
On June 22, 2009, HUD sent Mr. Halim a notice of de-
fault on the HAP agreement that directed him to correct all
deficiencies within 30 days. A follow-up inspection in Au-
gust 2009 determined that none of the 40 apartments
passed the UPCS inspection. Only 38 percent of the post-
closing repairs had been completed by that time.
HUD subsequently terminated the HAP contract with
Mr. Halim. HUD also retained $248,856 from the repair
escrow, based on HUD’s estimate that Mr. Halim had com-
pleted only 38 percent of the required post-closing repairs.
In his complaint before the Claims Court, Mr. Halim al-
leged that HUD’s retention of those funds breached the
Foreclosure Sale Use Agreement. The complaint also al-
leged that Mr. Halim had maintained the Schenectady 40
property in accordance with UPCS, and that HUD had
therefore improperly terminated the HAP agreement.
Case: 19-1478 Document: 47 Page: 10 Filed: 05/12/2020
10 HALIM v. UNITED STATES
The government moved for summary judgment based
on Mr. Halim’s failure to complete the contractually re-
quired repairs by the specified deadline and his failure to
maintain the units in compliance with the UPCS. Mr.
Halim’s opposition again rested almost entirely on the
short declaration that he filed in connection with this liti-
gation. In that declaration, Mr. Halim asserted, without
any corroborating evidence, that he “completed all of the
required repairs [at the Schenectady 40 property] by Octo-
ber 2009.” He also stated that all the Schenectady 40 units
had passed a UPCS inspection and that HUD was sending
him subsidy payments for all 40 units. Mr. Halim also
pointed to an October 2009 letter from the City of Schenec-
tady’s Bureau of Code Enforcement that stated that the
units comprising the Schenectady 40 property had passed
the city’s inspection and had no outstanding code viola-
tions.
The Claims Court granted the government’s motion,
ruling that Mr. Halim’s declaration was insufficient to
avoid summary judgment as to the Foreclosure Sale Use
Agreement, because his declaration was “conclusory and
uncorroborated by any supporting documentation.” Even
if the declaration were credited, the court added, it would
not be enough to avoid summary judgment. Mr. Halim
stated in the declaration that he completed the repairs by
October 2009. The Claims Court found that assertion to be
immaterial because the deadline for completing post-clos-
ing repairs was in July 2008.
The court also granted the government’s motion for
summary judgment as to Mr. Halim’s claim under the HAP
contract, which required that each of the units be main-
tained in accordance with the UPCS at all times. Because
the facts were not in dispute that the property was not in
compliance with the UPCS as of the final deadline set by
HUD in July 2009, the court held that HUD was entitled
to terminate the HAP contract at that time.
Case: 19-1478 Document: 47 Page: 11 Filed: 05/12/2020
HALIM v. UNITED STATES 11
1
We first address Mr. Halim’s argument regarding the
post-closing repairs. He contends that the Claims Court
erred in granting summary judgment for the government,
because his declaration that he had completed all the re-
pairs by October 2009 created a genuine issue of material
fact. In addition, he relies on the letter from the city Bu-
reau of Code Enforcement, which stated that as of October
9, 2009, the Schenectady 40 properties had “no outstanding
violations” and that “every property has passed inspec-
tions.”
Neither of those documents creates a disputed issue of
material fact as to whether Mr. Halim timely completed
the post-closing repairs. First, we agree with the trial court
that Mr. Halim’s conclusory assertion in his declaration
that he completed the work by October 2009 is not suffi-
cient to create a genuine issue of material fact, in light of
the substantial evidentiary showing to the contrary made
by the government. See Barmag Barmer Maschinenfabrik
AG v. Murata Machinery, Ltd., 731 F.2d 831, 836 (Fed. Cir.
1984). Second, Mr. Halim was required to complete certain
enumerated post-closure repairs to HUD’s satisfaction, and
he was separately required to make any repairs necessary
to meet applicable state and local codes. The fact that the
property may have complied with particular unspecified lo-
cal code requirements does not speak to whether Mr. Halim
had completed the repairs enumerated in the Foreclosure
Sale Use Agreement to HUD’s satisfaction.
Even if Mr. Halim had completed the post-closing re-
pairs by October 2009, that fact was not material. The
Foreclosure Sale Use Agreement required Mr. Halim to
complete the post-closing repairs by July 2008. Mr.
Halim’s assertions in his declaration provide no basis for
denying summary judgment to the government, because it
contains no representation that the post-closing repairs
were completed before October 2009, long after the July
Case: 19-1478 Document: 47 Page: 12 Filed: 05/12/2020
12 HALIM v. UNITED STATES
2008 contractual deadline for those repairs to be com-
pleted.
We agree with the trial court that the July 2008 dead-
line was not extended. Although HUD’s November 2008
notice of default on the Foreclosure Sale Use Agreement
provided Mr. Halim with the opportunity to obtain a 12-
month extension, that extension was conditioned on the re-
ceipt of a satisfactory plan for the schedule of the remain-
ing repairs. Mr. Halim did not present any evidence that
he ever submitted a proposed schedule of repairs. 3
Mr. Halim argues that the fact that HUD conducted
inspections after July 2008 “raised an inference that the
deadline was extended.” That argument is a non sequitur.
HUD set a deadline to correct certain deficiencies. The fact
that HUD inspected the property after the deadline to see
if Mr. Halim had complied with the contractual require-
ments does not raise an inference that the deadline was
extended.
In sum, HUD was within its rights to retain funds from
the repair escrow because Mr. Halim did not timely com-
plete the required post-closing repairs. The government
was therefore entitled to summary judgment that Mr.
Halim breached the Schenectady 40 Foreclosure Sale Use
Agreement.
2
We also agree with the Claims Court that there was no
disputed issue of material fact regarding Mr. Halim’s as-
serted failure to maintain the Schenectady 40 property in
accordance with HUD’s Uniform Physical Condition
3 Even if the deadline were assumed to run from the
notice of default on the HAP contract, Mr. Halim’s alleged
post-closing repairs would still be untimely. The letter de-
claring a default on the HAP contract set a deadline of July
2009.
Case: 19-1478 Document: 47 Page: 13 Filed: 05/12/2020
HALIM v. UNITED STATES 13
Standards. The government points to numerous inspec-
tions that revealed a failure to comply with those standards
throughout the entire period from the closing in 2006 until
late 2009, in violation of the HAP agreement. In response,
Mr. Halim relies on the letter from the City of Schenec-
tady’s Bureau of Code Enforcement regarding the absence
of city code violations as of October 2009.
That document does not address the question whether
the property was in compliance with HUD’s Uniform Phys-
ical Condition Standards during the three-year period
leading up to that date. As the trial court explained, HUD’s
Uniform Physical Condition Standards differ from local
housing codes; even if the property complied with some un-
specified city housing code requirements as of October
2009, that does not establish that the property was in com-
pliance with the UPCS as of that date or throughout the
period between 2006 and 2009. Furthermore, the date of
the letter is October 9, 2009, well after the thirty-day dead-
line set by the June 22, 2009 notice of default on the HAP
agreement. 4
Moreover, Mr. Halim’s allegation that all units had
passed “an inspection” and that HUD was making HAP
subsidy payments on all 40 units before HUD terminated
the HAP agreement does not give rise to a genuine issue of
material fact. HUD’s remedies under the HAP agreement
included the “recovery of overpayments.” Thus, even if
HAP did pay a subsidy for a unit, that does not lead to the
conclusion that the unit was in compliance with the UPCS.
We also agree with the government that Mr. Halim’s con-
clusory assertions in his declaration that all units had
4 Mr. Halim also contends that HUD breached the
implied covenant of good faith and fair dealing by not con-
ducting another investigation after the city’s letter in Oc-
tober 2009. We disagree. HUD had no obligation to
reinspect the premises after it determined that Mr. Halim
had failed to comply by the relevant deadline.
Case: 19-1478 Document: 47 Page: 14 Filed: 05/12/2020
14 HALIM v. UNITED STATES
passed “an inspection” and that he was receiving subsidy
payments are not sufficient to create a genuine issue of ma-
terial fact, in light of the substantial evidentiary showing
to the contrary made by the government. Barmag, 731
F.2d at 836.
Mr. Halim asserts in passing that HUD was not enti-
tled to terminate the HAP agreement “until HUD provided
the tenants at Schenectady 40 an opportunity to comment
on the proposed termination of the HAP contract,” which
HUD allegedly has not done. Mr. Halim waived that ar-
gument by not raising it below, Fresenius, 582 F.3d at 1296,
and in any event, any violation of the tenants’ rights does
not somehow negate the effect of his breach.
We therefore uphold the trial court’s ruling that the
government was entitled to summary judgment that
HUD’s termination of the HAP contract on the Schenec-
tady 40 property was not a breach of Mr. Halim’s rights
under that contract.
III
The third property addressed by the trial court was the
Meadowbrook Apartments, a 51-unit apartment complex
in Meridian, Mississippi. Mr. Halim was the successful
bidder on that property at a HUD foreclosure sale. The
parties closed on the property in January 2007. The Fore-
closure Sale Use Agreement that the parties executed re-
quired Mr. Halim to complete certain repairs to HUD’s
satisfaction within 24 months of closing. HUD estimated
the cost of repairs to be $2,003,276. Mr. Halim obtained a
letter of credit in the amount of $513,967 as security for his
performance of the repair requirements. In addition, the
parties entered into a HAP contract that required Mr.
Halim to keep all units for which he would be receiving
housing assistance payments in “good and tenantable con-
dition” and in compliance with the UPCS requirements at
all times. The HAP contract also provided that if HUD de-
termined that any unit was not in accordance with the
Case: 19-1478 Document: 47 Page: 15 Filed: 05/12/2020
HALIM v. UNITED STATES 15
UPCS, HUD could exercise its remedies under the contract
for all or any of the units, including terminating the con-
tract and the HAP payments.
The HUD-designated inspector conducted more than
two dozen inspections of the property over the course of
several years following Mr. Halim’s purchase of the prop-
erty in January 2007. The inspections included post-clos-
ing repair inspections and UPCS inspections. No more
than 24 of the 51 units ever passed the UPCS inspections,
and none of the inspection reports reflected that Mr. Halim
completed all the required post-closing repairs.
In early 2009, HUD served Mr. Halim with a notice of
violation of the Foreclosure Sale Use Agreement for failing
to meet the 24-month repair deadline. In the notice, HUD
stated that it was aware that the City of Meridian had de-
clared Meadowbrook unfit for habitation and that the city
intended to demolish the apartment complex if Mr. Halim
did not show an “earnest intent to correct the property” to
meet the minimum requirements of the city’s housing code.
On May 4, 2009, HUD issued a notice of default and stated
that it was prepared to cash Mr. Halim’s letter of credit.
In response, Mr. Halim requested a one-year extension,
stating that he had retained a new contractor and promis-
ing to complete the work within that period. The Chief Ad-
ministrative Officer of the City of Meridian contacted HUD
to support the one-year extension request. Based on that
endorsement and Mr. Halim’s response, HUD agreed to
grant an extension until January 31, 2010. HUD con-
ducted regular inspections of the property during that one-
year period. It determined that while some progress was
made, much remained undone. Based on a final inspection
six days before the expiration of the one-year extension,
HUD determined that only 38 percent of the required post-
closing repairs had been completed. At no point did all the
units pass a UPCS inspection.
Case: 19-1478 Document: 47 Page: 16 Filed: 05/12/2020
16 HALIM v. UNITED STATES
In March 2010, Mr. Halim requested, and HUD
granted, a second one-year extension, until January 15,
2011, to complete the repairs. HUD granted that second
extension in part based on the fact that the City of Merid-
ian had granted Mr. Halim until that date to bring the
property into compliance with the city’s housing codes.
Both the city and HUD told Mr. Halim that no further ex-
tensions would be granted.
During that year, Mr. Halim made some progress on
the repairs, and HUD released a substantial portion of the
funds it held in the repair escrow on account of that pro-
gress. An inspection on December 20, 2010, however,
showed that while some progress had been made, a sub-
stantial amount of the required post-closing repairs re-
mained undone. And only 24 of the 52 units passed the
UPCS inspection at that time. A city official and Mr. Halim
were present at that inspection, and the city official re-
minded Mr. Halim that he had to complete work by Janu-
ary 15, 2011, because the city would not grant Mr. Halim
any further extensions.
Following the expiration of the second one-year exten-
sion, the City of Meridian issued a stop-work order on the
property. HUD subsequently notified Mr. Halim that he
violated the Foreclosure Sale Use Agreement and the HAP
contract. Shortly thereafter, HUD terminated the HAP
contract and retained the remaining portion of the es-
crowed funds.
In his complaint, Mr. Halim alleged that he had com-
pleted the post-closing repairs and that he had maintained
the property in full compliance with HUD’s Uniform Phys-
ical Condition Standards. In response to the government’s
motion for summary judgment, Mr. Halim abandoned his
contention that he had completed the required repairs and
argued, instead, that the stop-work order by the City of Me-
ridian had rendered his performance impossible.
Case: 19-1478 Document: 47 Page: 17 Filed: 05/12/2020
HALIM v. UNITED STATES 17
The parties filed cross-motions for summary judgment.
The Claims Court granted the government’s motion and
denied Mr. Halim’s motion. The court rejected Mr. Halim’s
impossibility argument on the ground that he had failed to
show that it was objectively impossible to complete the re-
pairs during the four-year period that he was given by
HUD, including the two one-year extensions. In addition,
the court explained that the defense of impossibility re-
quires a demonstration of lack of fault on the part of the
party asserting it. The court concluded that the unrebut-
ted evidence showed that the stop-work order that Mr.
Halim claims made it impossible for him to complete the
repairs “was issued as a consequence of his own failure to
meet the contractually imposed deadlines even after they
were twice extended by a year.”
On appeal, Mr. Halim continues to press his impossi-
bility theory. He contends that because HUD did not issue
its final notice of violation until December 2, 2011, he had
until January 2, 2012, to complete the repair work. Be-
cause the stop-work order was in effect throughout much
of the year leading up to that date, Mr. Halim argues that
he was prevented, by causes beyond his control, from com-
plying with his contractual obligations and therefore can-
not be found to have been in breach of those obligations.
We disagree. The trial court was correct to conclude
that Mr. Halim was directly responsible for the event that
he claims rendered his performance impossible. That is,
Mr. Halim’s failure to complete the repairs at the property
in a timely manner was what precipitated the city’s stop-
work order. His plea of impossibility is therefore not a vi-
able defense to liability on the contracts. See Seaboard
Lumber Co. v. United States, 308 F.3d 1283, 1294 (Fed. Cir.
2002).
Mr. Halim makes a further argument that there was a
disputed issue of material fact as to whether he maintained
the Meadowbrook property in accordance with HUD’s
Case: 19-1478 Document: 47 Page: 18 Filed: 05/12/2020
18 HALIM v. UNITED STATES
Uniform Physical Condition Standards. Mr. Halim’s only
evidence in support of that contention is that the Meadow-
brook buildings received a certificate of occupancy from the
city in early 2012. Whatever significance that fact may
have had as to the property’s compliance with city housing
codes, it did not create a disputed issue of material fact as
to whether all the units on the property complied with the
separate requirements of the UPCS by the January dead-
line.
The trial court therefore properly granted summary
judgment with regard to the Meadowbrook property.
IV
The fourth of the properties as to which Mr. Halim has
appealed was the Beacon Light—Goodwill Baxter Apart-
ments (“Beacon Light”), a 108-unit apartment complex lo-
cated in Henderson, North Carolina. HUD held a
foreclosure sale for that property in June 2007. At the time
of the sale, the property was vacant and in distressed con-
dition. The bid documents warned bidders of the poor
physical condition of the property, noting that it had been
damaged by fire and vandalism. Although the bid docu-
ments identified numerous issues with the physical condi-
tion of the property, the documents warned that bidders
were expected to arrive at their own conclusions as to the
physical condition of the property as well as “any other fac-
tors bearing upon valuation of the property.” HUD advised
prospective bidders that the condition of the property and
the need to repair it should be factored into the bid price.
Mr. Halim was the high bidder on the Beacon Light
property and completed the purchase in August 2007. He
entered into a Foreclosure Sale Use Agreement with HUD
at that time. The agreement required Mr. Halim to make
certain repairs on the property within 24 months of closing,
to convert the property from rental units into home owner-
ship, and to sell the repaired homes to income-eligible pur-
chasers.
Case: 19-1478 Document: 47 Page: 19 Filed: 05/12/2020
HALIM v. UNITED STATES 19
Following the sale, city officials in Henderson com-
plained to HUD that Mr. Halim had not done any signifi-
cant work on the property and that there had been several
fires at the site. HUD subsequently contacted Mr. Halim
in March 2009 and threatened to declare him in default of
the Foreclosure Sale Use Agreement if the required repairs
were not completed by the August 2009 deadline. Mr.
Halim requested an extension to complete the required re-
pairs. HUD informed Mr. Halim that it would consider a
request for an extension only if he submitted a work plan
indicating the date by which the repairs would be com-
pleted. The record does not reflect that Mr. Halim submit-
ted such a plan.
Immediately before the expiration of the 24-month pe-
riod for making the required repairs, the city’s mayor con-
tacted HUD again to complain that the property had been
allowed to deteriorate significantly during the previous two
years. The mayor explained that no plans had been sub-
mitted to bring the property into compliance with the city’s
housing code and that no work had begun on repairing the
property. The city notified HUD that it had adopted an
ordinance to condemn the property and would begin demo-
lition unless the property could be brought into compliance
with the housing code requirements.
After the 24-month deadline for repairs had passed,
Mr. Halim applied to the city for a special use permit and
a zoning variance. The Beacon Light buildings were set
back 18 feet from the street, in violation of the applicable
local code requiring that they be set back at least 35 feet.
The city denied his requests. In so doing, the city zoning
board noted that the setback requirement was “reasonably
discernible at the time that the applicant purchased the
property” and that “the Applicant has done nothing to re-
move the burned out buildings or attempted to remedy or
repair the buildings since the fires . . . thus making the
conditions worse.”
Case: 19-1478 Document: 47 Page: 20 Filed: 05/12/2020
20 HALIM v. UNITED STATES
Shortly before the city denied Mr. Halim’s zoning re-
quests, Mr. Halim sought to return the property to HUD
and requested that his escrow deposit be returned to him.
HUD, however, declined his request and instead notified
him that he was in default of the Foreclosure Sale Use
Agreement. HUD advised him that it intended to exercise
its rights under the contract and to retain the deposited
funds. HUD subsequently released approximately
$400,000 from the escrowed funds to the city for the pur-
pose of demolishing the property.
In his complaint, Mr. Halim alleged he was entitled to
a refund of the purchase price of the property and the re-
turn of the repair escrow. He asserted that in light of the
city’s zoning ordinance regarding the setback require-
ments, he should be relieved of his contractual obligations
under the doctrine of mutual mistake of fact.
The parties filed cross-motions for summary judgment.
The Claims Court granted the government’s motion and
denied Mr. Halim’s motion, rejecting Mr. Halim’s mutual
mistake argument. First, the court ruled that Mr. Halim’s
lack of due diligence made the doctrine of mutual mistake
unavailable to him. Due diligence, the court concluded,
would have led Mr. Halim to discover the setback ordi-
nance and adjust his expectations, or decline to enter into
the contract, particularly in light of Mr. Halim’s experience
in purchasing apartment complexes from HUD in foreclo-
sure sales. Second, the court ruled that in connection with
the Beacon Light purchase, the risk of encountering imped-
iments such as zoning restrictions was placed on the pur-
chaser. In particular, the court pointed out, the bid
documents provided that prospective purchasers were “ex-
pected to acquaint themselves with the property, and to ar-
rive at their own conclusions as to; physical conditions . . .
and any other factors bearing upon the valuation of the
property.”
Case: 19-1478 Document: 47 Page: 21 Filed: 05/12/2020
HALIM v. UNITED STATES 21
In his opposition to the government’s summary judg-
ment motion, Mr. Halim also argued that he was excused
from the requirement of performance of his contractual ob-
ligations by the doctrine of impossibility. His performance
under the contract was impossible, he contended, because
the city’s denial of a variance precluded him from perform-
ing. The Claims Court rejected that contention on two
grounds. First, the court noted that Mr. Halim had not
even applied for a variance until after the deadline for his
performance had expired. Second, the court ruled that un-
der his contractual arrangement with HUD, Mr. Halim
“bore the risk that Beacon Light might not be in compliance
with local zoning ordinances.”
On appeal, Mr. Halim reprises his mutual mistake and
impossibility arguments. As to mutual mistake, we agree
with the trial court that with the exercise of due diligence
Mr. Halim would have become aware of the zoning regula-
tions. See ConocoPhillips v. United States, 501 F.3d 1374,
1380 (Fed. Cir. 2007) (citing Restatement (Second) of Con-
tracts § 154 (1981)) (“a party bears the risk of a mistake
when the party is aware, at the time the contract is made,
that the party has only limited knowledge with respect to
the facts to which the mistake relates but treats that lim-
ited knowledge as sufficient”); Griffin & Griffin Explora-
tion, LLC v. United States,
116 Fed. Cl. 163, 175 (2014)
(“[A] party cannot rely upon a mutual mistake of fact to
avoid enforcement of a contract where, as here, the ‘mis-
take’ is a result of that party’s failure to exercise due dili-
gence.”); see also Collins v. United States,
532 F.2d 1344,
1348 (Ct. Cl. 1976) (“Ignorance is never sufficient to consti-
tute a ground of relief if it appears that the requisite
knowledge might have been obtained by reasonable dili-
gence.”).
Moreover, the risk of unknown factors such as zoning
regulations was expressly allocated to the purchaser. Zon-
ing restrictions such as Henderson’s fall within the cate-
gory of “any other factors bearing upon the valuation of the
Case: 19-1478 Document: 47 Page: 22 Filed: 05/12/2020
22 HALIM v. UNITED STATES
property.” Where the parties have allocated the risk of mis-
take to one of the parties, that party may not invoke the
doctrine of mutual mistake to avoid its contractual obliga-
tions. See Dairyland Power Co-op v. United States, 16 F.3d
1197, 1202 (Fed. Cir. 1994). Mr. Halim’s impossibility ar-
gument fails on the same ground.
Seaboard, 308 F.3d at
1295 (citations omitted) (“[N]o impossibility defense will lie
where the ‘language or the circumstances’ indicate alloca-
tion of the risk to the party seeking discharge.”).
The Claims Court therefore properly granted summary
judgment to the government with regard to the Beacon
Light property.
AFFIRMED
