GREENE, J.

This case arises from a written contract dispute between Beka Industries, Inc. ("BEKA") and the Board of Education of Worcester County ("the County Board").1 Between 2004 and 2006, BEKA was one of twenty trade contractors to be awarded a lump sum contract to contribute to the construction of a new public school, Ocean City Elementary School, in Worcester County. Dissatisfied with the method and amounts of the County Board's payment for its work, BEKA filed suit in the Circuit Court for Worcester County and obtained a judgment against the County Board. The County Board appealed that judgment to the Court of Special Appeals and succeeded in obtaining a reversal of the judgment and an order for a new trial. BEKA has appealed the intermediate appellate court's judgment and before us contends that the trial court's judgment should be fully reinstated. We affirm the Court of Special Appeals's judgment that a new trial is warranted because the County Board was precluded from presenting evidence on its recoupment claim and BEKA may have been awarded impermissible "delay damages" under the contract. But, we reverse the intermediate appellate court's holding that the County Board's governmental immunity is not waived unless and until BEKA proves that there is a funding mechanism to satisfy a judgment for money damages rendered against the Board. Accordingly, we affirm in part, reverse in part, and remand the case to the intermediate appellate court with direction to remand to the Circuit Court for a new trial.

FACTUAL AND PROCEDURAL BACKGROUND

On June 8, 2004, the County Board executed a written contract with BEKA to perform site clearing, excavation, grading, site utilities, curb and gutter work, and paying for a new elementary school. The "lump sum bid" proposed for the work by BEKA and accepted by the County Board was $1,856,000. Subsequent to execution of the contract, the parties agreed to three approved change orders, totaling $105,913, that increased the total contract price to $1,961,913. BEKA's work on the contract began in June 2004 and was completed by May 2006. During that time, there were numerous disputes regarding BEKA's responsibilities under the original contract as well as the monetary consequences of modifications made by the County Board. To date, the Board has paid BEKA a total of $1,421,852.

Alluded by resolution to their dispute, BEKA filed a Complaint for Money Damages and Other Relief in the Circuit Court for Worcester County. BEKA's original complaint sought damages in the amount of $1,157,053.75, as well as pre-judgment interest, post-judgment interest, costs and attorney's fees. BEKA tabulated that figure alleging that the County Board owed it $361,991.47 under the original contract and an additional $795,062.28 for alterations made to the scope of BEKA's work under the contract. The County Board generally denied liability, raising 12 affirmative defenses in its first Answer; a recoupment claim for "credits, backcharges, and/or setoffs" in the amount of $531,979.52 in its Amended Answer and Counter-Complaint; combining the recoupment claim and the 12 affirmative defenses in its Second Amended Answer; and adding four more defenses to its Third, and final, Amended Answer.2 The County Board conceded at trial that it owes at least $361,991.47 on the balance of the original contract. Numerous motions were filed during the course of the litigation and are discussed with particularity infra.

Following a four day bench trial, the Circuit Court for Worcester County "compromised the claim" between what the trial judge viewed to be BEKA's final claim for $1,215,035,80 (exclusive of prejudgment interest) and the County Board's claim for $505,487 and entered a judgment in favor of BEKA for $1,100,000, excluding prejudgment interest and not awarding attorney's fees or post-judgment interest.3 The County Board appealed the judgment and filed a "Motion to Stay Enforcement of the Judgment," which was denied by the trial judge, but granted on appeal on the condition that a supersedeas bond be filed in the Circuit Court for Worcester County. The County Commissioners of Worcester County fulfilled the bond requirement and the intermediate appellate court heard the case.

The Court of Special Appeals reversed the judgment of the trial court and remanded the case to the Circuit Court for purposes of a new trial. Board of Ed. v. BEKA, 190 Md.App. 668, 989 A.2d 1181 (2010). BEKA petitioned for certiorari and the County Board filed a conditional cross-petition, both of which were granted, BEKA v. Worcester County Bd. of Educ., 415 Md. 38, 997 A.2d 789 (2010), to address the following questions, rephrased for clarity:

As Cross-Petitioner, the County Board has asked:

We answer each question above in the negative. We affirm the Court of Special Appeals's judgment that sovereign immunity is legislatively waived in the action against the County Board based on a written contract for the construction of a public school. We reverse, however, that part of the Court of Special Appeals's holding that requires BEKA to prove a source of funding in order to obtain a judgment at a new trial. Additionally, as discussed infra, we affirm the intermediate appellate court's judgment concerning the treatment of the County Board's recoupment claim and concerning procedural defects in the trial court's judgment.

I. Public School Construction in Maryland

We have recognized there exists "a carefully conceived legislative structure in which the respective powers and limitations of local school boards, the State Board of Education and county governments are delineated and balanced." Bd. of Ed. v. Montgomery County, 237 Md. 191, 197, 205 A.2d 202, 205 (1964). The construction of public schools exemplifies those interwoven roles; State and local governments provide funding, and, along with the county boards of education, they provide oversight for the construction of public schools in Maryland.

The Maryland State Board of Education ("MSBE") establishes standards and planning guidance for construction projects and the State Superintendent must approve of all plans for new construction and the remodeling of school buildings exceeding $350,000. Md.Code (2008 Repl.Vol.), §§ 2-205(l), 2-303(f) of the Education Article ("E.D."). Annually, the MSBE must submit a public school budget to the Governor including appropriations for the Department itself and for aid to "counties ... for the construction of school buildings." E.D. § 2-205(j); see also E.D. § 5-101 (requiring county boards to submit an annual budget including "estimated receipts" and "requested appropriations" for local school construction that has been approved by the local government). The Interagency Committee on School Construction, established by the Board of Public Works pursuant to E.D. § 5-302, provides a recommendation to the Board of Public Works on which submitted, locally approved construction projects should be funded through the Public School Construction Program. The General State School Fund, established by E.D. § 5-201, is a source of funding for school building construction aid described in E.D. § 5-301(c), which requires the State to pay the excess costs above available federal funds for approved school construction projects or improvements.

County boards of education may undertake the construction of public school buildings as long as the plans conform to the "bylaws, rules and regulations of the State Board" and to the regulations of the Board of Public Works related to alternative financing, when applicable. See E.D. §§ 4-115(b), 4-126. The procurement of bids from contractors for school construction contracts, which is addressed in § 5-112 of the Education Article, is administered by county boards. The local county governments meet the requirements of the county board's approved annual budgets by levying and collecting taxes in their jurisdictions and appropriating revenues from other sources. See E.D. §§ 5-104, 5-107; see generally Montgomery County, 237 Md. 191, 205 A.2d 202 (1964). Once appropriated, county boards must keep school construction funding isolated in a separate and independent account. See E.D. § 5-305.

The State, the State Superintendent, the county governments, and the county boards of education are all subject to school construction-related regulations promulgated by the Board of Public Works found in COMAR Title 23.03.02, et seq. (2011) ("Administration of the Public School Construction Program"). See E.D. § 5-301(g)(1). Clearly, in light of the aforementioned statutory provisions, "[s]tate law provides for close supervision of county boards with regard to construction of school buildings." Patterson v. Ramsey, 413 F.Supp. 523, 530 (D.Md. 1976), aff'd, 552 F.2d 117 (4th Cir.1977).

II. Sovereign Immunity

Here, the County Board has been sued for breach of contract, and lacking money (or the ability to raise money on its own) to pay a judgment, the Board contends that the doctrine of sovereign immunity bars the suit. The doctrine of sovereign immunity "prohibits suits against the State or its entities absent its consent." Magnetti v. University of Md., 402 Md. 548, 557, 937 A.2d 219, 224 (2007) (citing Dep't of Natural Resources v. Welsh, 308 Md. 54, 58-59, 521 A.2d 313, 315 (1986)); see also Proctor v. WMATA, 412 Md. 691, 709, 990 A.2d 1048, 1058 (2010) (stating that sovereign immunity is applicable to the State, and its agencies and instrumentalities); Stern v. Board of Regents, 380 Md. 691, 700, 846 A.2d 996, 1001 (2004) ("The doctrine of sovereign immunity has long been recognized as applicable in actions against the State of Maryland and its official representatives.").

In order to determine if the doctrine of sovereign immunity applies to the County Board in the underlying contract suit, we ask: "(1) whether the entity asserting immunity qualifies for the protection; and if so, (2) whether the legislature has waived immunity either directly or by necessary implication, in a manner that would render the defense of immunity unavailable." Magnetti, 402 Md. at 557, 937 A.2d at 224 (quoting ARA Health v. Dept. of Public Safety, 344 Md. 85, 92, 685 A.2d 435, 438 (1996)); see also Austin v. City of Baltimore, 286 Md. 51, 69-71, 405 A.2d 255, 264-66 (1979) (Eldridge, J., concurring in part, dissenting in part) (describing the legislative origins of sovereign immunity and the resulting deference to that body regarding waivers of the doctrine). A legislative waiver of sovereign immunity, notably, is ineffective unless "there are `funds available for the satisfaction of the judgment' or the agency has been given the power `for the raising of funds necessary to satisfy recovery against it.'" Stern, 380 Md. at 701, 846 A.2d at 1001-02 (quoting University of Maryland v. Maas, 173 Md. 554, 559, 197 A. 123, 126 (1938)).5

BEKA asserts that even if the County Board is entitled to sovereign immunity, that doctrine has been legislatively waived for its contract claim pursuant to Md.Code (2009 Repl.Vol.), §§ 12-201 et seq. of the State Government Article ("S.G.").6 Conversely, the County Board, as Cross-Petitioner, asserts that BEKA may obtain only a limited judgment because sovereign immunity applies and has only been legislatively waived for claims of $100,000 or less, or the limits of an insurance policy, pursuant to Md.Code (2006 Repl.Vol.), § 5-518 of the Courts and Judicial Proceedings Article.7 The County Board contends that when C.J.P. § 5-518 is read together with § 4-105 of the Education Article,8 there is "little room for the applicability of any other sovereign immunity waiver provision found in State law, including S.G. § 12-201 et seq."

The Court of Special Appeals held that S.G. § 12-201 applies; however, it also determined that S.G. § 12-2039 does not provide a funding mechanism for a contract judgment; therefore, according to the intermediate appellate court, because no proof was offered on the County Board's ability to pay a judgment the waiver of sovereign immunity was "ineffective." BEKA, 190 Md.App. at 712, 989 A.2d at 1207. Consequently, the intermediate appellate court held that "in the event that there is a new trial, and a judgment is entered against the Board on the contract claims, there will need to be evidence presented, and a factual finding by the Circuit Court, regarding whether there are funds available to satisfy the judgment." BEKA, 190 Md.App. at 715, 989 A.2d at 1208.

We shall hold that the legislative waiver of sovereign immunity in S.G. § 12-201(a) is applicable to the Board of Education of Worcester County. Additionally, we hold that S.G. § 12-203 provides a funding mechanism for judgments rendered against the County Board following a waiver of sovereign immunity under S.G. 12-201(a). Thus, suit on a written contract for construction of a public school may be brought against the County Board. Moreover, the limited waiver of sovereign immunity contained in C.J.P. § 5-518 does not apply.

A. S.G. § 12-201 Waives Sovereign Immunity for the County Board of Education Arising out of a School Construction Contract

BEKA advances the contention, which was adopted by the intermediate appellate court, that "in the context of this case, the Board is a "unit" of the State pursuant to S.G. § 12-201, and this statute waives [the County Board's] right to the defense of sovereign immunity in contract actions." BEKA, 190 Md.App. at 709, 989 A.2d at 1205 (footnote omitted). Conversely, the County Board asserts that "S.G. § 12-201 et seq., . . . applies only to contract claims against the State, its officers, and its units" and that local boards of education, the County Board contends, are not "units" of the State.10 We reject the County Board's position and affirm the intermediate appellate court's conclusion.

First, we must determine "whether the entity asserting immunity qualifies for its protection." Stern, 380 Md. at 700, 846 A.2d at 1001-02 (citation omitted). We affirm that a county board of education, is "a State agency entitled to governmental immunity." BEKA, 190 Md.App. at 694, 989 A.2d at 1196 (citing Board of Ed. v. Zimmer-Rubert, 409 Md. 200, 205-06, 973 A.2d 233, 236-37 (2009)) (noting numerous cases in support of the proposition that the Court of Appeals has "long considered" county school boards to be State agencies); see also Chesapeake Charter v. Board of Ed., 358 Md. 129, 135-36, 747 A.2d 625, 628-29 (2000) (holding that county school boards are `creatures' of the General Assembly and principally governed by state policies, although not "units" for the purposes of the State's General Procurement Law).

If a county board of education may benefit from the sovereign immunity enjoyed by State agencies, then, necessarily, it is also subject to statutory restraint on that defense by operation of a legislative waiver. See State v. Sharafeldin, 382 Md. 129, 140, 854 A.2d 1208, 1214 (2004) ("We have held, consistently, that immunity from suit is `one of the highest attributes of sovereignty,' and that any waiver of that immunity must come from the Legislature."); see also E.D. § 3-104(b)(2) (allowing a county board of education to "sue or be sued"); see also C.J.P. § 5-518 (discussed infra). "Title 12 of the State Government Article addresses the liability of state agencies and the scope of the doctrine of sovereign immunity ... contain[ing] separate statutory provisions regarding tort and contract actions." BEKA, 190 Md. App. at 695, 989 A.2d at 1197. Alluding briefly to the legislative history of S.G. § 12-201, the Court of Special Appeals concluded that because the Board of Education of Worcester County is a State agency, a "unit" of the State in the parlance of the statute, then the waiver of sovereign liability in contract actions set forth in S.G. § 12-201 was expressly applicable.11 BEKA, 190 Md.App. at 708, 989 A.2d at 1204-05. We agree. Moreover, as required by the statute and cases interpreting the provision, the contract between the County Board and BEKA, irrefutably "was [ (1) ] reduced to writing; and (2) the State employee or official [the County Superintendent on behalf of the Board] acted within the scope of his, her, [or its] authority in executing the contract," therefore, the contract was duly executed and falls within the waiver of sovereign immunity provided by S.G. § 12-201(a). See ARA Health, 344 Md. at 92, 685 A.2d at 440 (holding that immunity was not waived where a claim did not satisfy the formal requirements of a written contract under S.G. § 12-201(a)).

The County Board contends that the legislative waiver of sovereign immunity contained in S.G. § 12-201 does not apply because a county board of education is neither a State "unit," nor a local government entity,12 drawing on the distinction made in Chesapeake Charter in which Judge Wilner discussed the "hybrid nature" of county boards of education, stating that:

Chesapeake Charter, 358 Md. at 139-40, 747 A.2d at 630-31. The proposition that Chesapeake Charter stands for is that a local school board is not a "unit" of State Government for purposes of the General Procurement Law because the "procurement of supplies and services by the county boards of education" in contrast to school construction, has never been subject to the general authority of the Board of Public Works, or the Department of General Services.13

We held in Chesapeake Charter that "a county school board is not a "unit" within the meaning of [the General Procurement Law], and accordingly, that [the Maryland State] Board of Contract Appeals ha[d] no jurisdiction over disputes arising from procurement decisions made by those boards." Chesapeake Charter, 358 Md. at 145-46, 747 A.2d at 634 (noting that the Education Article retained, despite numerous revisions, distinct statutory procurement requirements for county boards related to the solicitation of school construction contracts); see also E.D. § 5-112 (governing the bid process for school construction). Thus, the fine distinction drawn in Chesapeake Charter for the purposes of determining whether a school bus contract (a local, operational expense) was governed by the State's General Procurement Law, as highlighted by the County Board and the Maryland Association of Boards of Education as amicus curiae, in this case, does not proscribe the application of S.G. § 12-201(a)'s waiver of sovereign immunity to the County Board in the present contract action.14

B. Funding the Judgment

Before this Court, the parties contest the applicability of S.G. § 12-203 as a funding mechanism to satisfy BEKA's judgment, as well as the status of the supersedeas bond filed in the Circuit Court for Worcester County as a stay of execution pending this appeal. Because S.G. § 12-201(a) waives the County Board's sovereign immunity in an action based on a written contract for public school construction, we must ascertain whether the General Assembly intended for a judgment awarded thereunder to be satisfied by funding requested by the Governor as part of a "budget bill" pursuant to S.G. § 12-203. Thus, the issue before us is whether § 12-203 applies to all judgments, or only certain judgments, as it appears the intermediate appellate court concluded. In the later case, it would be necessary to have some intelligible way of discerning which judgments would be the responsibility of the State and which would not.

The Court of Special Appeals held that, pursuant to this Court's decision in Stern, and notwithstanding the waiver of sovereign immunity, "the burden of proving the availability of funds to satisfy the judgment is on the party seeking to show a waiver of the defense of sovereign immunity, in this case, BEKA[,]" because "SG § 12-203 does not provide a mechanism for appropriation of State funds to satisfy a judgment against a county board of education." BEKA, 190 Md.App. at 710, 712, 989 A.2d at 1205, 1207. The Court of Special Appeals reviewed the record to ascertain if facts were alleged to indicate that the County Board had the means to satisfy the judgment, through taxation or appropriation. See BEKA, 190 Md.App. at 712-13, 989 A.2d at 1207. Finding none and concluding that several allegations of sources of funding made by BEKA on appeal had not been made at trial, the intermediate appellate court determined that a new trial would require fact-finding on the issue of availability of funding. BEKA, 190 Md.App. at 715, 989 A.2d at 1208. In our view, additional fact-finding is unnecessary because funding is provided by statute.

The Court of Special Appeals concluded that S.G. § 12-203 could not be used to satisfy a judgment, stating:

BEKA, 190 Md.App. at 710-11, 989 A.2d at 1206. The Court of Special Appeals determined that S.G. § 12-203 did not apply to the present dispute relying largely upon Chesapeake Charter. In that case, we did not consider the sections of the State Government Article, at issue in the present case, because there the parties brought their procurement contract to the Maryland State Board of Contract Appeals ("MSBCA") pursuant to § 15-205 of the State Finance and Procurement Article ("S.F.P."). Consequently, sovereign immunity was not an issue in the case.

In Chesapeake Charter, we held that a county board of education's school bus contracts were not subject to the General Procurement Law, because the board was not a "unit" of the Executive Branch of the State Government within the meaning of the pertinent statutory provision, S.F.P. § 11-101(x), and therefore the MSBCA had no jurisdiction over the dispute between the county board and a school bus contractor. Chesapeake Charter, 358 Md. at 145-46, 747 A.2d at 634. Determining that the language of the pertinent statute was ambiguous, we considered the legislative history and concluded that, other than school construction, the State Board of Public Works and the Department of General Services had never "exercised any authority over the procurement of supplies and services by the county boards of education." Chesapeake Charter, 358 Md. at 140, 747 A.2d at 631 (footnote omitted, quoted supra).

Accordingly, our holding in Chesapeake Charter was a narrow one. We determined that "most of [the county board of education's] operational funding comes from the county, not the State, government" and that "[t]hey are subject to the county, not the State budget process" therefore the school bus contract was a local, and not a State concern. Chesapeake Charter, 358 Md. at 139, 747 A.2d at 631. The Court of Special Appeals relied on this reasoning to conclude that, "[b]ecause county boards of education are subject to the county budget process, it does not appear that the State would be responsible for paying a judgment against a county board of education. . . . Accordingly, S.G. § 12-203 does not provide a mechanism for appropriation of State funds to satisfy a judgment against a county board of education." BEKA, 190 Md.App. at 712, 989 A.2d at 1207. While we do not disagree that the county board of education must submit a budget to the local government for approval, the funding that is appropriated to fulfill the budget emanates from local, State, and federal sources. This "local budgetary character," therefore, appears insufficient to overcome the overwhelming support in our case law for the notion that county boards of education are "legally State agencies." See Chesapeake Charter, 358 Md. at 137, 747 A.2d at 629.

Here, the issue is one of statutory construction because we must determine whether S.G. § 12-203, by its terms, is applicable to the underlying action. We construe S.G. § 12-203 "recogniz[ing] that `the cardinal rule of statutory interpretation is to ascertain and effectuate the intention of the legislature[,]'" Stern, 380 Md. at 720, 846 A.2d at 1013, beginning with a plain meaning analysis in order to "give effect to the statute as it is written[,]" Pak v. Hoang, 378 Md. 315, 323, 835 A.2d 1185, 1189 (2003). "[B]ut if the true legislative intent cannot readily be determined from the statutory language alone, we look to other indicia of that intent, including the title to the bill, the structure of the statute, the inter-relationship of its various provisions, its legislative history, its general purpose, and the relative rationality and legal effect of various competing constructions." Baltimore County v. RTKL Assoc., 380 Md. 670, 678, 846 A.2d 433, 437-38 (2004). We also "avoid a construction of the statute that is unreasonable, illogical, or inconsistent with common sense." Zimmer-Rubert, 409 Md. at 215, 973 A.2d at 243 (quoting Walzer v. Osborne, 395 Md. 563, 573, 911 A.2d 427, 432 (2006)). "We have also stated that this Court must read and `construe legislative dilution of governmental immunity narrowly in order to avoid weakening the doctrine of sovereign immunity by judicial fiat.'" Magnetti, 402 Md. at 565, 937 A.2d at 229 (quoting Stern, 380 Md. at 720, 846 A.2d at 1012-13).

Section 12-203 of the State Government Article requires that "adequate" funds to satisfy a final judgment "rendered against the State or any of its officers or units" be made available through a "budget bill"15 after all appellate issues have been resolved. S.G. § 12-203. The provision is intended to "carry out this subtitle," which, as stated, addresses "Actions in Contract." S.G. 12-203. According to the plain language of the statute, and its surrounding provisions relating to governmental immunity in contract suits, there is no indication that § 12-203 differentiates between those judgments that the State must pay and those it must not as long as the legislative waiver of sovereign immunity enshrined in S.G. § 12-201(a) is applicable to the dispute.16 See e.g., Coastal Holding & Leas. v. Maryland Environmental, 420 F.Supp.2d 441, 444-46 (2006) (holding that the Maryland Environmental Service was immune from suit in federal court based on the "state treasury" factor of the Fourth Circuit's sovereign immunity analysis because the agency successfully argued that S.G. § 12-203 means that the "State of Maryland is ultimately liable for any judgments entered against it in a contract" and likewise for a tort action).

The amount of money that the Governor would be required to include in the budget bill "to satisfy a final judgment" is a factual inquiry and must be determined at trial by reference to the contract provisions and an accounting of payments and reimbursements between the parties. Thus, there is no other burden on BEKA in the instant case to prove the availability of funds, as there was in Ruff, and the Court of Special Appeals erred in concluding that BEKA bore that burden.

Moreover, we have previously noted that S.G. § 12-203 was enacted by the General Assembly for the particular purpose of addressing the funding requirement that must precede a waiver of sovereign immunity under S.G. § 12-201(a). In Stern, we concluded that the General Assembly enacted S.G. § 12-203 upon an acknowledgment of our reasoning in Maas, 173 Md. at 558-60, 197 A. at 125-26 and Ruff, 278 Md. at 590-91, 366 A.2d at 366, that sovereign immunity is a valid defense unless funds have been appropriated to pay a judgment or funds may be raised for that purpose, stating:

Stern, 380 Md. at 715, 846 A.2d at 1010. Therefore, in Stern, we considered S.G. § 12-203 to be an explicit funding mechanism for judgments based upon written contracts against the State, its officers, or units. Judge Wilner, dissenting in Stern with respect to the majority's analysis of S.G. § 12-201 and concluding that the Board of Regents had in fact breached written contracts with the students by executing a mid-year tuition increase, nevertheless echoed the majority's view of the function and purpose of S.G. § 12-203 stating:

Stern, 380 Md. at 732, 846 A.2d at 1019 (Wilner, J., dissenting). Judge Wilner noted that "§ 12-203 requires the Governor to include in the budget bill money that is adequate to satisfy final judgments," citing § 52(4) and (12) of Article III of the Maryland Constitution. Stern, 380 Md. at 732, 846 A.2d at 1019, fn. 4.17

Section 12-203 applies to the instant case because this Court has determined, supra, that its statutory companion, S.G. § 12-201(a), waives the County Board's governmental immunity and the language of S.G. § 12-203 requires that all judgments rendered against the State, its officers or units, upon breach of a written contract shall be requested by the Governor as part of a budget bill. Furthermore, the application of S.G. § 12-203 to written contract disputes between a State entity and a private party is consistent with the purpose of providing a waiver to immunity in contract actions involving written agreements. It gives effect to "the moral obligation on the part of any contracting party, including the State or its political subdivisions, to fulfill the obligations of a contract." Magnetti, 402 Md. at 560, 937 A.2d at 227, fn. 6 (quoting 1976 Md. Laws, Ch. 450).18

C. Section 5-518(b) of the Courts and Judicial Proceedings Article does not apply

The County Board has asserted that the only applicable legislative waiver of its sovereign immunity is exclusively found in C.J.P. § 5-518 because § 4-105 of the Education Article states "a county board of education shall have the immunity from liability described under § 5-518" and this is the only provision in the Education Article that addresses sovereign immunity for county boards of education. E.D. § 4-105(d). Therefore, the Board contends in its cross-petition that it is insulated from paying damages to BEKA over $100,000 (or the amount of its insurance policy) pursuant to C.J.P. § 5-518(b) and pursuant to this Court's opinion in Zimmer-Rubert, 409 Md. 200, 973 A.2d 233 (2009).

In Zimmer-Rubert, in the context of what we perceived to be a claim for personal injury resulting from an alleged age discrimination violation, we commented that the term "`any claim' [under § 5-518(c)] cannot reasonably be read to exclude certain categories of claims." Zimmer-Rubert, 409 Md. at 215, 973 A.2d at 242 (quoting Zimmer-Rubert v. Board of Ed., 179 Md.App. 589, 612, 947 A.2d 135, 149 (2008)). Our interpretation of § 5-518(c) was clearly in the context of a tort or insurable claim, such as "those for personal injury," and for claims arising from "alleged employment law violations." Zimmer-Rubert, 409 Md. at 216, 973 A.2d at 242. We did not imply in that case that C.J.P. § 5-518(c) applies to contract claims, nor did we address, by association, the meaning of C.J.P. § 5-518(b), to which Respondent looks in the present case. Thus, Respondent's contention that Zimmer-Rubert interpreted C.J.P. § 5-518 to be applicable to contract claims is incorrect. Moreover, we have found no cases to support the contention that C.J.P. § 5-518(b) applies to contract claims filed against a county board of education. Therefore, we affirm, without the need for further discussion, the Court of Special Appeals's conclusion that C.J.P. § 5-518 does not place limitations on the waiver of sovereign immunity under S.G. § 12-201(a). See BEKA, 190 Md.App. at 707, 989 A.2d at 1204 (holding "[t]hus, the language of § 5-518, limiting the liability of a self-insured board of education to $100,000, does not apply to BEKA's contract claims.").

III. The Propriety of the Trial Court's Treatment of the County Board's Recoupment Claim

At trial, the County Board sought to reduce the amount of money damages awarded to BEKA by asserting its entitlement to "credits, backcharges, and/or set-offs" totaling $531,079.52 arising from PCOs (proposed change orders) numbering 1, 2, 3, 4, 14, 15, 17, 18, 19, 40.19 The County Board alleged in pleadings, discussed infra, that BEKA "refused or failed to perform certain work in accordance with the [Contract], and [the County Board] had to have that work performed by other contractors[,]" and that BEKA "had certain work removed from its scope of work by the construction manager in accordance with the Contract."

The County Board's claim is a "recoupment" claim because it seeks to adjust the amount awarded to BEKA in light of its own losses arising out of the same transaction from which BEKA seeks a legal remedy. BEKA, 190 Md.App. at 727, 989 A.2d at 1215-16 (citing Imbesi v. Carpenter Realty, 357 Md. 375, 380, 744 A.2d 549, 552 (2000) (where recoupment was described as "a diminution or a complete counterbalancing of the adversary's claim based upon circumstances arising out of the same transaction on which the adversary's claim is based")); see The Impervious Products Co. v. Gray, 127 Md. 64, 68, 96 A. 1, 2 (1915) ("In recoupment a defendant may show damages equal to some part of the whole of the plaintiff's claim and have it deducted from that claim, but can recover no affirmative judgment."). The Court of Special Appeals highlighted the equitable nature of a recoupment claim stating, "[r]ecoupment exists in equity as well as at common law, and has been said to be equitable in nature. It reduces the claim affirmatively urged so far as in reason and conscience it ought." BEKA, 190 Md. App. at 727, 989 A.2d at 1216 (quoting Smith v. Smith, 79 Md.App. 650, 662, 558 A.2d 798, 804 (1989) (quoting 20 Am.Jr.2d Counterclaim, Recoupment and Setoff § 6 (1965))).

On appeal before this Court, BEKA poses three questions relating to the treatment of the County Board's recoupment claim at trial and before the Court of Special Appeals. Because the questions are factually and procedurally intertwined, we address them together. BEKA first contends that the intermediate appellate court erred by not affirming the portion of the trial court's ruling on BEKA's Motion for Partial Summary Judgment, by which the trial court barred the County Board from "raising the issue." Secondly, BEKA contends that the County Board's use of the defense of recoupment is barred as a matter of law. Finally, BEKA asserts that the intermediate appellate court applied incorrectly the abuse of discretion standard of review to ultimately reverse the trial court's grant of BEKA's "Motion in Limine to Exclude Evidence of Backcharges."

BEKA's three questions arise in response to the intermediate appellate court's consideration of a single question posed to it by the County Board, which asked "[d]id the trial court err in prohibiting the County Board from submitting evidence regarding its [$531,079.52] recoupment claim[.]" In finding that the trial judge abused his discretion, the Court of Special Appeals analyzed this question wholly in the context of the trial judge's ruling on BEKA's Motion in Limine concluding that it was "unable to determine the basis for the court's ruling excluding the Board's evidence of recoupment[,]" and that "[t]he inherent contradictions in the trial court's statements indicate that there was not a sound exercise of discretion in excluding this evidence." BEKA, 190 Md. App. at 729, 989 A.2d at 1216. The Court of Special Appeals held that in its view of the record the trial court's ruling may have been based on a finding that the recoupment issue was not timely asserted and, to that extent, the decision was erroneous because the Board's "initial answer preserved the defense." BEKA, 190 Md. App. at 729-30, 989 A.2d at 1216-17. We shall affirm the Court of Special Appeals's resolution of the issues regarding the trial court's treatment of the County Board's recoupment claim issue because the Board should have been permitted to present evidence of the claim at trial.

A. Procedural History

The County Board first pleaded its "entitlement" to recoup money owed to BEKA under the contract by way of a Counter-Complaint and Amended Answer filed July 14, 2008. The same "entitlement" claim was presented in four subsequent pleadings: (1) the Second Amended Answer filed July 18, 2008; (2) the response to BEKA's "Motion in Limine to Exclude Evidence of Backcharges" filed August 5, 2008; (3) the Third Amended Answer filed August 12, 2008; and (4) the Board's "Response to BEKA's Motion for Partial Summary" Judgment filed August 18, 2008, wherein the Board maintained that no judgment should be entered until the court received evidence concerning certain proposed "amounts, credits, backcharges and setoffs totaling $531,080."

At a motions hearing on September 18, 2008, less than a month before trial, the trial judge struck the County Board's Counter-Complaint and Amended Answer as untimely, stating: "The fact that discovery closed just four days before the County Board's filing of its Countercomplaint unfairly prejudiced BEKA, and the County Board's Countercomplaint and Amended Answer are stricken."20

Secondly, the trial judge barred the defense of recoupment by granting that portion of BEKA's Motion for Partial Summary Judgment, in which BEKA argued that the County Board "did not comply with the contract provisions governing changes to BEKA's work under the contract." BEKA asserted that there was no dispute of material fact about the failure of the County Board's claim for back-charges, credits or setoffs because: (1) § 4.7.1 of the contract defined a "claim," which BEKA argued clearly included the County Board's recoupment claim; (2) claims must be filed within 7 days and must be substantiated; and (3) claims must be submitted to the Architect for resolution. Therefore, BEKA contended, because the County Board did not submit its "back-charges, credits or setoffs" through this process, it waived its claim. The County Board asserted that there were genuine disputes of the facts related to its claims for recoupment and that the trial court should not enter a money judgment without receiving evidence on the recoupment amounts. The trial judge ruled in BEKA's favor, stating: "As to Beka's Request for Summary Judgment on the issue of credits, back-charges and setoffs, the County Board failed to address Beka's argument that it did not adhere to the contract provisions for asserting a claim and the County Board should be precluded from raising the issue at this time."

Prior to commencement of trial, on October 6, 2008, the trial judge struck the County Board's Second and Third Amended Answers, which each raised recoupment, and the court ruled explicitly on BEKA's Motion in Limine, stating that: "I'm going to bar any evidence of recoupment as an affirmative answer."

B. Summary Judgment

BEKA asks us to determine whether it was error for the Court of Special Appeals to, in effect, reverse the trial court's grant of BEKA's Motion for Partial Summary Judgment. Because the Court of Special Appeals did not consider expressly the trial court's ruling on BEKA's Motion for Partial Summary Judgment, but rather limited its discussion of the County Board's recoupment claim to the context of the trial court's ruling on BEKA's Motion in Limine, BEKA, 190 Md.App. at 727, 989 A.2d at 1216, there is no analysis stated in the intermediate appellate court's opinion regarding the trial court's ruling on summary judgment for this Court to review.

The intermediate appellate court did not engage in de novo review, which would have inquired into whether the trial judge's ruling pertaining to the recoupment claim was legally correct. See e.g., Dashiell v. Meeks, 396 Md. 149, 163, 913 A.2d 10, 18 (2006) ("With respect to the trial court's grant of a motion for summary judgment, the standard of review is de novo.") (citing Rockwood Cas. Ins. Co. v. Uninsured Employers' Fund, 385 Md. 99, 106, 867 A.2d 1026, 1030 (2005)). Upon our review of the grant of the summary judgment motion, however, we conclude that the trial judge was legally incorrect to have granted BEKA's motion as to the County Board's recoupment claim. "Prior to determining whether the trial court was legally correct, an appellate court must first determine whether there is any genuine dispute of material facts.... Any factual dispute is resolved in favor of the nonmoving party.... Only when there is an absence of a genuine dispute of material fact will the appellate court determine whether the trial court was correct as a matter of law." Dashiell, 396 Md. at 163, 913 A.2d at 18 (citations omitted).

The facts relevant to the recoupment claim were disputed and therefore the issue should not have been resolved by summary judgment. The County Board claimed it was owed back-charges for ten proposed change orders ("PCOs"), presented to the trial court as Exhibit 2 in BEKA's Motion for Partial Summary Judgment, restated in the County Board's "Response to Motion for Partial Summary Judgment," and in its "Supplement to Defendant's Response to Motion for Partial Summary Judgment." BEKA asserted that the contract required certain claims procedures, namely provisions 4.7.1, 4.7.2 and 4.7.3, to be followed to pursue such credits, but that the County Board did not follow those procedures. The County Board claimed that it was not required to submit the credits through the claims procedure in the contract. Moreover, it argued that the two contract provisions, 4.7.4 and 5.7.1. permitted the withholding of payment on uncontested amounts until all unsettled claims were determined. The trial judge ruled that because "the Board failed to address Beka's argument that it did not adhere to the contract provisions for asserting a claim ... the Board should be precluded from raising the issue at this time." In our view, the trial court erred in arriving at this legal conclusion despite several disputed, material facts concerning legal requirements of the contract; the impact of contract modifications made by the parties; the timeliness of submissions of claims to the architect prior to litigation; and the precise monetary amounts owed to BEKA because of changes to its scope of work or credits for nonperformance owed to the County Board.

Even if there were no disputed material facts the trial judge's conclusion that the County Board "failed to address Beka's argument that it did not adhere to the contract provisions for asserting a claim," is not supported by the record.21 The record indicates that the County Board did in fact address the issue of compliance with the contract procedures in at least two pleadings, the "Response to Motion for Partial Summary Judgment" and the "Supplement to Defendant's Response to Motion for Partial Summary Judgment."

C. Recoupment Claim Not Barred as a Matter of Law

The Court of Special Appeals suggested that on remand

As BEKA notes, the intermediate appellate court did not address this issue directly because it only considered the propriety of the trial judge's ruling on BEKA's motion in limine. The Court of Special Appeals indirectly indicated, however, that the trial judge's ruling to strike the Counter-Complaint (and the later exclusion by granting BEKA's Motion in Limine) had no impact on the recoupment claim because it was implied and preserved by the County Board's initial answer. BEKA, 190 Md.App. at 729-30, 989 A.2d at 1217 (holding that recoupment need not be specifically pled under Md. Rule 2-323(d) and therefore it was timely raised and preserved for appellate review by the County Board's initial answer).

BEKA relies on Imbesi to support this assertion; however, that case did not address recoupment, but rather a set-off claim23 in an unrelated transaction that was statutorily barred by a provision of the Estates and Trusts Article of the Maryland Code. Imbesi, 357 Md. at 392, 744 A.2d. at 558 ("Whether the result is the same if the estate's debtor raises recoupment is an issue that need not presently be decided."). Thus, Imbesi does not assist with the resolution of the treatment of the County Board's recoupment claim in the instant case. BEKA also calls our attention to Cohen v. Karp, 143 Md. 208, 122 A. 524 (1923), where this Court noted that a set-off to a judgment was a defense that could be raised if the defendant had "a right to receive the amount due him from the plaintiff, [and] his claim ... [is] of such a nature that he can sue for and recover it in a court of law." Cohen, 143 Md. at 211, 122 A. at 525 (noting that "[t]he defense of set-off, technically, means a cross-claim"). Finally, BEKA relies upon Telmark, Inc. v. C & R Farms, Inc. et al., 115 A.D.2d 966, 966-67, 497 N.Y.S.2d 536 (1985) in which a New York intermediate appellate court held that because of the express terms of a lease agreement "`under no circumstances' ... [could] the defendants have a cause of action against plaintiff for consequential damages, [therefore] they cannot assert such claim in recoupment."

In Telmark, unlike the instant case, a lease agreement between the parties contractually precluded the defendants from suing the plaintiff for consequential damages and so recoupment could not be used as a "back-door" mechanism for raising the issue. Telmark, 115 A.D.2d at 966-67, 497 N.Y.S.2d 536. Similarly, in Imbesi the preclusive effect of a statutory bar to a set-off claim (not a recoupment claim) was dispositive. Imbesi, 357 Md. at 392, 744 A.2d at 558. In Cohen, again a case about set-offs and not recoupment, this Court held that the trial judge erred in not granting a motion to arrest a judgment because the plaintiff had been ordered erroneously to pay co-defendants the excess of their set-off claim against him. Cohen, 143 Md. at 212-13, 122 A. at 525. Cohen, therefore, does not apply here.

Here, there was no factual conclusion on the record about whether the contract would apply to the County Board's recoupment defense for "back-charges, credits and/or set-offs," as the Court of Special Appeals correctly pointed out. BEKA, 190 Md.App. at 729, 989 A.2d at 1217. Because we hold that the trial judge's rulings precluding the County Board from presenting its evidence on recoupment were in error, and the question of whether the contract precludes a claim by the County Board for "back-charges, credits and/or set-offs" remains unresolved, we hold that the recoupment issue, whether a "defense" or "affirmative claim," is not barred and in fact must be addressed in a new trial.

D. Motion in Limine

To address BEKA's third argument, we consider whether the Court of Special Appeals erred by holding that the trial judge abused his discretion when he granted BEKA's "Motion in Limine to Exclude Evidence of Defendant's Backcharges." As the Court of Special Appeals noted, we have said also that

BEKA, 190 Md.App. at 727-28, 989 A.2d at 1216. BEKA asserts that there was no abuse of discretion because the trial judge had already barred the recoupment defense in his grant of its Motion for Partial Summary Judgment, the trial judge had granted all motions striking the County Board's amended pleadings that raised recoupment, the County Board had committed discovery violations warranting exclusion of the evidence, and even if BEKA had the recoupment information it did not know that the County Board was going to use the credits as an affirmative claim or affirmative defense. Conversely, the County Board asserts that the Court of Special Appeals was correct to find abuse of discretion because the trial judge excluded the evidence without commenting or engaging in any fact finding on the disagreement between opposing counsel on the allegation of discovery violations, the County Board's responses to BEKA's motion identified sources of information substantiating the recoupment claim dating back to February 2008 (well before the commencement of trial), and that the trial judge should have taken a more conservative approach in responding to the discovery dispute under Md. Rule 2-433 ("Sanctions.").

BEKA's motion in limine was based entirely on allegations that the County Board violated unspecified discovery rules. Recently, we have stated:

Williams v. State, 416 Md. 670, 698-99, 7 A.3d 1038, 1054 (2010). We have not required that statements addressing each of these factors be part of the record. The Court of Special Appeals held, in the present case, that the trial judge's ruling was an abuse of discretion because it concluded that the trial judge's statements leading up to the ruling contained "inherent contradictions" and that there was an erroneous "basis" for the ruling. BEKA, 190 Md. App. at 729, 989 A.2d at 1216.

BEKA's motion alleged that the County Board had failed to produce information substantiating its recoupment claim totaling $531,079.52 and that it was severely prejudiced by this withholding because it could not prepare a defense without the ability to determine the reasonableness of the pricing of material and labor in the discrete claims. During argument on the motion, BEKA claimed that it wanted the trial judge to strike two particular pieces of evidence that it alleged were filed untimely by the County Board, namely the August 20, 2008 filing of a Supplement to Answers to Interrogatories and a Supplement to Document Production. BEKA claimed that the documents did not substantiate the claim for back-charges because the documents did not contain the specificity required by the claims procedure under the contract. The County Board alleged, however, that BEKA had been in possession of the same information since commencement of litigation in February 2008 and therefore there was no prejudice. The County Board also noted that BEKA had not made any formal allegations of violation of the discovery rules, therefore, pursuant to Food Lion v. McNeill, 393 Md. 715, 904 A.2d 464 (2006), it should not be granted the extreme relief of exclusion of the evidence.

What is clear from the record is that the trial judge had issued three rulings to bar evidence of the County Board's recoupment claim prior to his ruling on the motion in limine and each time the ruling had favored BEKA. In granting BEKA's motion in limine to exclude the County Board's evidence of recoupment, the trial judge simply stated: "Well, I'll enter my ruling ... I'm going to bar any evidence of recoupment as an affirmative answer." No other evidence or rationale exists in the record explaining or elaborating on the trial judge's determination of the validity of BEKA's allegations regarding the discovery violations, prejudice, or waiver because of violation of the contract terms.

Based upon our review of the record, we conclude that there is scant commentary from the trial judge regarding his deliberation on BEKA's motion in limine, except to indicate his belief that he had already ruled on the substantive issue of presentation of the recoupment claim by striking the Counter-Complaint and Amended Answer and that the County Board's counsel apparently annoyed the court with its circular presentation of its recoupment claim. The particular phrasing of the ruling, barring evidence of recoupment as "an affirmative answer," indicates that the trial judge may have been persuaded by BEKA's argument that it was prejudiced by failing to appreciate that information provided on "backcharges, credits and/or set-offs" at the beginning of litigation would be used as an "affirmative answer" or "affirmative defense."

Notwithstanding the alleged prejudice, there is no legal reasoning stated on the record supporting the trial judge's grant of this motion. The trial judge should have engaged in some factual and legal analysis regarding treatment of the recoupment claim pursuant to, or outside, of the contract. We agree with the Court of Special Appeals that, in spite of the trial judge's apparent fatigue with the issue, the Board should have been permitted to present evidence to support its recoupment claim because the record indicates that the Board put BEKA on notice of its claims during discovery. Moreover, BEKA never formally alleged that discovery was insufficient.

IV. Interpretation of the Contract: "Delay Damages"

The Court of Special Appeals held that the trial court's final judgment must be reversed because of a failure to comply with Md. Rule 2-522(a)24 and because it was impossible to know whether "delay damages" had been awarded in the judgment, when as a legal matter, delay damages were expressly precluded by the terms of the Contract. BEKA contends that the Court of Special Appeals erred in determining that the contract contained a broad "no-damages-for-delay" clause. There is no evidence in the record that the trial judge engaged in any legal analysis of the issue of delay damages under the contract, ostensibly because BEKA did not present its claim for damages under Counts 23, 40, 42, 44 and 45 as "delay damages" even though in closing argument the County Board asserted that characterization.25 Having been asked by the County Board on appeal, however, to determine if BEKA was entitled to "delay damages" under the contract, the intermediate appellate court reviewed the contract.

The interpretation of written contracts presents a question of law for the trial court, which an appellate court reviews de novo. United Services v. Riley, 393 Md. 55, 79, 899 A.2d 819, 833 (2006) (quoting Towson University v. Conte, 384 Md. 68, 78, 862 A.2d 941, 946 (2004)). "Courts in Maryland follow the law of objective interpretation of contracts, `giving effect to the clear terms of the contract regardless of what the parties to the contract may have believed those terms to mean.'" Riley, 393 Md. at 79, 899 A.2d at 833 (quoting Towson University, 384 Md. at 78, 862 A.2d at 946-47).

The Court of Special Appeals held that § 8.3.1 of the Contract precluded BEKA from recovering "delay damages" from the County Board because the express language provided that "[e]xtension of time shall be Contractor's sole remedy for delay." BEKA, 190 Md.App. at 734, 989 A.2d at 1219 (quoting § 8.3.1. of the disputed contract). BEKA asserted that even if § 8.3.1 barred delay damages, other provisions in the Contract modified the plain language of § 8.3.1 thereby expressing the parties mutual assent to accommodate delay damages. On that point, the intermediate appellate court held that "the parties nullified other provisions in the contract that may have allowed damages for costs incurred due to delay. Thus, the contract here clearly precluded BEKA from recovering damages for delay." BEKA, 190 Md.App. at 734, 989 A.2d at 1219-20. The Court of Special Appeals did not identify which "other provisions" had been nullified by the parties or how.

In response to BEKA's alternative assertions that its claims on Counts 23, 40, 42, 44 and 45, totaling $448,349, were not "delay damages" but "direct costs" recoverable under the contract, or that they were delay damages but the clause was unenforceable because of nefarious actions by the County Board, the intermediate appellate court determined that both were determinations appropriately made by the trier of fact, but that "the trial court made no factual findings" on the issues. BEKA, 190 Md.App. at 735, 989 A.2d at 1220. Specifically, the Court of Special Appeals held that:

BEKA, 190 Md.App. at 736, 989 A.2d at 1220. Therefore, lacking factual and legal conclusions upon which to assess whether it would be appropriate to affirm the trial court's judgment, the intermediate appellate court reversed the judgment and ordered a new trial. See e.g., Della Ratta v. Dyas, 414 Md. 556, 565, 996 A.2d 382, 387 (2010) ("Pursuant to Maryland Rule 8-131(c), where, as here, an action has been tried without a jury, the appellate court will review the case on both the law and the evidence. We will not set aside the judgment of the trial court on the evidence unless clearly erroneous.") (citing Md. Rule 8-131(c)). We concur.

V. Judgment

The trial judge announced the judgment of the court on the record as follows:

The parties contest the specificity with which the trial court must address the discrete claims pursuant to Md. Rule 2-522, which requires that the trial judge must "prepare and file or dictate into the record a brief statement of the reasons for the decision and the basis of determining any damages." Md. Rule 2-522(a). Before this Court, BEKA contends that the Court of Special Appeals has erred because the trial judge "is presumed to know, and properly apply, the law" and "the record is replete with competent and largely unrebutted evidence," so that the trial judge "properly used the jury verdict approach in determining the amount of damages to award to BEKA." Moreover, BEKA asserts that the trial judge's statement complies with Md. Rule 2-522(a) because the judge's "decision indicates that he took all of the claims and counterclaims into consideration and determined that Beka was entitled to recover $1.1 million." To the contrary, the County Board has urged us to uphold the Court of Special Appeals's application of Md. Rule 2-522 in the instant case because "[s]eparate claims [49 counts in Beka's original complaint] for damages with specific evidence for each were presented[,]" and the "trial court did not state which of the 49 counts of Plaintiff's Complaint had been proven, nor did the court address the myriad of issues presented to it[.]"

The Court of Special Appeals held that the trial judge did not comply with Md. Rule 2-522(a), and it is apparent from the record that the trial judge entered the "compromise verdict" without any correlation between the grounds for BEKA's various claims for damages and the amount of damages ultimately awarded. BEKA, 190 Md.App. at 735, 989 A.2d at 1219-20. Because of the lack of documentation on how the trial judge resolved the issue of damages owed under the contract, the Court of Special Appeals reversed and remanded for a new trial. BEKA, 190 Md.App. at 735-36, 989 A.2d at 1220. Notwithstanding the Court of Special Appeals's rationale for its judgment, we conclude that the judgment with respect to recoupment and "delay damages" cannot stand because the County Board should have been permitted to introduce evidence on its "back-charges, credits, and set-offs" and the issue pertaining to an improper award of "delay damages" must be fully aired.

JUDGMENT OF THE COURT OF SPECIAL APPEALS AFFIRMED IN PART AND REVERSED IN PART; CASE REMANDED TO THAT COURT WITH DIRECTIONS TO REMAND THE CASE TO THE CIRCUIT COURT FOR WORCESTER COUNTY FOR FURTHER PROCEEDINGS CONSISTENT WITH THIS OPINION. PETITIONER TO PAY 50% AND RESPONDENT TO PAY 50% OF THE COSTS IN THIS COURT AND IN THE COURT OF SPECIAL APPEALS.