Findings Of Fact At all times pertinent to these proceedings, Hamilton held registered residential contractors license number RR0015037. Hamilton agreed to construct a house in Clearmont, Florida, with a completion date no later than May 1, 1977, for Robert J. and Margaret M. Phlepsen. The construction price was $75,000.00. After construction of the house it was discovered that there existed two violations of the Southern Building Code. First, the "step-down" from the kitchen to the garage was an eleven inch riser contrary to the code requirement that the height of a riser shall not exceed seven and three quarters inches. The second violation occurred through the use of 2 X 8 joists where the code would require 2 X 10 joists. The extra high riser between the kitchen and the garage was apparently caused by an oversight. Hamilton merely failed to install an intermediate step at that location. The second violation occurred because the owner and Hamilton agreed to use the smaller joists in order to save money on the contract price. In neither case is there sufficient evidence to establish that Hamilton's violations were willful or deliberate as alleged in the Administrative Complaint. On June 6, 1978, the Lake County Board of Examiners suspended Hamilton's Lake County Certificate of Competency because of violations of building code requirements in the construction of Phlepsen's house.
Findings Of Fact At all times relevant hereto, respondent, George E. Feld, held certified general contractor license number CG C021801 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. Feld has been a licensed contractor in Florida since June 1982. He has qualified George E. Feld and Associates, Inc. under his license and operates the business at 2131 Northeast 205th Street, North Miami Beach, Florida. After submitting the low bid, on or about March 1, 1985 George Feld and Associates, Inc. entered into a contract with the City of Tamarac to construct a 5,500 square foot recreation building for the City. The negotiated contract price was $195,950. The contract called for commencement of the project within ten days after the contract was signed and completion by July 27, 1985. Sometime prior to March 20, 1985, Feld met one David P. McCall and Marvin Weiss at a motel in North Miami. McCall was interested in doing work on the Tamarac project. He gave Feld a business card with the name "Arrow Head Development Corporation, Inc." printed on it, and which stated the firm was "state certified" and "licensed" as a general contractor. Feld also noted that Weiss held a general contractor's license, and he assumed that McCall and Weiss were working together. Relying on McCall's card, and later representations by McCall, but without checking with petitioner's office to verify if McCall or Arrow Head were licensed or qualified, Feld agreed to subcontract out the shell and sewer work on the Tamarac project to Arrow Head. To this end, Feld and Arrow Head entered into two contracts on March 20, 1985, for Arrow Head to perform the shell and sewer work. On June 21, 1985 McCall submitted a written "proposal" to Feld for the shell work on the job. The proposal had the following words and numbers typed on its face: "State License Number: #CGC 05961." It was not disclosed whose license number this was. Although McCall denied typing this document (because he does not personally know how to type), he did not deny that it was placed on the document at his direction or with his knowledge. It was not until sometime later that Feld learned that Arrow Head was not qualified by any licensee. Because of his mistaken belief that Arrow Head was qualified, Feld had never qualified that firm. Even so, there was no evidence that Feld intended to allow an unqualified firm to perform the work. Work proceeded on a timely basis as required by the contract. Feld visited the job site daily, and supervised all activities, including those performed by McCall. He routinely inspected the work, verified that it was being done according to specifications, and made corrections where needed. The job specifications called for trusses that were over forty feet in length. Because of this, and pursuant to the South Florida Building Code (Code), it was necessary for the City to hire an engineer to oversee their installation. The City hired one George Fink as engineer to supervise this phase of the project. However, Fink's responsibility was limited to just that, and once the installation was completed, Feld resumed responsibility for the remainder of the job. Trusses are a manufactured roof member and may vary in length, height and pitch. In this case, they were designed in the form of a cathedral roof, and were in excess of forty-seven feet in length. Further, because of the building's design, there were a number of trusses to be installed. The installation of the trusses was begun around 9:00 a.m. on Friday, June 27, 1985 and finished by 2:00 p.m. that same day. As required by the Code, Fink was present and supervised the installation of the trusses on the top of the shell. He confirmed at hearing that they were properly installed. The problem herein arose early that day when Fink had noticed that the building plans did not provide for lateral bracing of the trusses. However, according to Fink, this was not unusual since plans do not normally provide for lateral bracing. Even so, Fink told an unnamed person who "appeared to be the fellow running the erection crew" that lateral bracing should be added to the center and two side core members and that the four trusses on each end needed additional bracing. Fink also suggested to this unnamed individual that sheathing be added "as soon as possible" to the top and outside of the trusses to give added stability and protect them from wind damage and the like. In this regard, at hearing Fink conceded that it was "reasonable" for a contractor to erect trusses one day, and to place sheathing on them the following work day. Fink thought sheathing to be particularly necessary on this job since the trusses were high pitched," "long in length," and there were "no gables or anything in between to ... add any other support." By the end of the work day, the crew had placed the proper bracing on the trusses. However, no sheathing was applied. According to Fink, who was accepted as an expert in this proceeding, a prudent and competent contractor would be aware of the need for sheathing and added bracing because of the potential hazard of high winds caused by late afternoon thunderstorms in South Florida. By failing to place sheathing on the roof, Fink opined that Feld was grossly negligent and incompetent in the practice of construction on the Tamarac project. Sometime on late Sunday night or early Monday morning, most of the trusses on the roof collapsed. Some fell on an electrical wire running to the building. However, no injuries occurred. Only five trusses on the north side of the building remained in place. The City of Tamarac then filed a complaint with petitioner against Feld. The cause of the collapse was not disclosed, and even Fink was unable to state that the lack of sheathing was the cause of the accident. There was no evidence that strong winds or thunderstorms occurred on the night the trusses fell, or that bad weather was predicted when the work day ended on Friday afternoon. Feld acknowledged that no sheathing was placed on the trusses. He attributed this to the fact that the construction crew stopped work at 3:30 on Friday afternoon, and did not return to the job site until the following Monday morning. He intended to install the sheathing the following Monday but by then it was too late. This was in accord with the standard enunciated by Fink that it was not unreasonable for a contractor to erect trusses one day, and to place sheathing on them the following work day. Feld also stated that he was well aware of the need for bracing and sheathing on trusses by virtue of his long experience in the construction business. Feld hinted, but did not prove, that McCall may have been responsible for the accident because of bad blood between the two. In any event, he doubted that wind would have caused the trusses in question to fall. Finally, Feld pointed out that, even though city inspectors were present, no one had come to him on Friday afternoon and said the trusses might collapse over the weekend without sheathing. Feld is a graduate of the University of Buenos Aires with a degree in architecture, and has been engaged in the construction/architecture business for twenty-two years. He presently is an instructor of construction at Miami-Dade Community College. There is no evidence he has ever been the subject of a disciplinary action by the Board on any other occasion.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that the administrative complaint against George E. Feld be DISMISSED, with prejudice. DONE AND ORDERED this 9th day of April, 1987, in Tallahassee, Leon County, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 9th day of April, 1987.
The Issue The Florida Construction Industry Licensing Board, Petitioner, seeks to revoke the registered contractor's license of Stephen J. Borovina, Respondent, based on allegations, which will be set forth in detail hereafter, that he engaged in conduct violative of Chapter 468, Florida Statutes. The issue presented is whether or not the Respondent aided or abetted and/or knowingly combined or conspired with Mr. Howard North, an uncertified or unregistered contractor, to evade the provisions of Chapter 468.112(2)(b), and (c), Florida Statutes, by allowing North to use his certificate of registration without having any active participation in the operations, management, or control of North's operations. Based on the testimony adduced during the hearing and the exhibits received into evidence, I make the following:
Findings Of Fact The Respondent is a certified general contractor who holds license no. CGC007016, which is current and active. On or about July 25, 1976, Mr. and Mrs. Julius Csobor entered into a contract with Mr. and Mrs. Howard North for the construction of a home in Martin County, Florida, for a total price of $35,990. Neither Mr. or Mrs. North are certified or registered contractors in the State of Florida. (Petitioner's Composite Exhibit #2). Respondent applied for and was issued a permit by the Martin County Building Department to construct a residence for the Csobors at the same address stipulated in the contract between the Csobors and the Norths, i.e., Northwest 16th Street, Palm Lake Park, Florida. (Petitioner's Composite Exhibit #1). Howard North, a licensed masonry contractor for approximately nine (9) years was contacted by the Csobors through a sales representative from a local real estate firm. It appears from the evidence that North had previously constructed a "spec" house which the local realtor had sold and thus put the Csobors in contact with Mr. North when they were shown the "spec" house built by North. Evidence reveals that North contacted Borovina who agreed to pull the permit "if he could get some work from the job and could supervise the project". Having reached an agreement on this point, North purchased the lot to build the home for the Csobors and he orally contracted with the Respondent to, among other things, pull the permit, supervise construction, layout the home and do trim and carpentry work. North paid Respondent approximately $200 to layout the home for the Csobors. By the time that North had poured the slab and erected the subfloor, the Csobors became dissatisfied with his (North's) work and demanded that he leave the project. According to North, Respondent checked the progress of construction periodically. Prior to this hearing, the Csobors had never dealt with Respondent in any manner whatsoever. According to Csobor, North held himself out as a reputable building contractor. A contractor is defined in relevant part as any person who, for compensation, undertakes to, or submits a bid to, or does himself or by others, construct, repair, etc. . . . real estate for others. . . Chapter 468.102(1), Florida Statutes. Applying this definition to the facts herein, it appears that the Respondent, at least in a literal sense, satisfied the requirements and obligations of a contractor, as defined in Chapter 468.102, Florida Statutes. Thus, he contracted with North to oversee and/or supervise the project for the Csobors which he fulfilled, according to the testimony of North. Said testimony was not refuted and thus I find that no effort was made by Respondent to evade any provision of Chapter 468, Florida Statutes. Accordingly, I shall recommend that the complaint filed herein be dismissed in its entirety.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby recommended that the complaint filed herein be dismissed in its entirety. RECOMMENDED this 4th day of November, 1977, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings 530 Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Stephen J. Borovina 2347 Southeast Monroe Street Stuart, Florida 33494 J. Hoskinson, Jr. Chief Investigator Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1442 STEPHEN J. BOROVINA, CG C007016, 2347 S. E. Monroe Street, Stuart, Florida 33494, Respondent. / This cause came before the FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD at its regular meeting on February 10, 1978. Respondent was sent the Hearing Officer's findings and recommendations and was given at least 10 days to submit written exceptions to the recommended order. Respondent was notified of the meeting so that respondent or counsel might appear before the Board. Respondent did not appear The FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD on February 10, 1978, after reviewing a complete transcript of the Administrative Hearing, by motion duly made and seconded voted to revoke the certified general contractor's license of STEPHEN J. BOROVINA. It is therefore, ORDERED that the certification of respondent STEPHEN J. BOROVINA, Number CG C007016, be and is hereby revoked. Respondent is hereby notified that he has 30 days after the date of this final order to appeal pursuant to Chapter 120, Florida Statutes, and the Florida Appellate Rules. DATED this 13th day of February, 1978. FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD BY: JOHN HENRY JONES, President ================================================================= SECOND AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD STEPHEN J. BOROVINA, CG C007016, Respondent/Appellant, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1442 FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner/Appellee. / This cause came before the Florida Construction Industry Licensing Board at its regular meeting on August 3, 1979. The respondent was sent the Hearing Officer's findings and recommendations and was given at least 10 days to submit written exceptions to the recommended order. Respondent was notified of the meeting so that respondent or counsel might appear before the Board. Respondent did appear. The Florida Construction Industry Licensing Board, on August 3, 1979, after reviewing a complete transcript of the Administrative Hearing, by motion duly made and seconded, voted to revoke the certified general contractor's license of Stephen J. Borovina, No. CG C007016. On February 13, 1978, the certification of respondent, Stephen J. Borovina, No. CG C007016, was revoked by order of the Florida Construction Industry Licensing Board. On April 25, 1979, the District Court of Appeal of the State of Florida, Fourth District, in Case Number: 78-527, reversed the final order of the Florida Construction Industry Licensing Board. That Court remanded the above captioned case to the Board to further consider the matter and enter such order as it may be advised in conformity with Section 120.57(1)(b)(9), Florida Statutes (1977). In accordance with the decision of the Florida District Court of Appeal, Fourth District, the Board has reconsidered the above captioned matter and finds as follows: The Board rejects the recommended order as the agency's final order. The Board adopts the first paragraph of the hearing officer's finding of fact. The Board, however, rejects the findings of fact found in the second paragraph of the hearing officer's findings. The second paragraph states as follows: A contractor is defined in relevent(sic) part as any person who, for compensation, undertakes to, or submits a bid to, or does himself or by others, construct, repair, etc. real estate for others...Chapter 468.102(1), Florida Statutes. Applying this definition to the facts herein, it appears that the Respondent, at least in a literal sense, satisfied the requirements and obligations of a contractor, as defined in Chapter 468.102, Florida Statutes. Thus, he contracted with North to oversee and/or supervise the project for the Csobors which he fulfilled, according to the testimony of North. Said testimony was not refuted and thus I find that no effort was made by Respondent to evade any provision of Chapter 468, Florida Statutes. Accordingly, I shall recommend that the complaint filed herein be dismissed in its entirety. The findings of fact found in the above-quoted paragraph were not based upon competent substantial evidence. The competent substantial evidence supports a finding that the respondent, Stephen J. Borovina, did not supervise the project and that Borovina evaded the provisions of Chapter 468, Florida Statutes. The following evidence supports the Board's position: There was no written agreement entered into between Howard North and the respondent which indicated that the respondent was to supervise the construction of the Csobors' house (T- 14); It was conceded at the hearing that the only subcontractors or draftmen who worked on the Csobors' house were contracted solely by Howard North and they had no contract whatsoever with the respondent (T-19, 25); The respondent never advised or informed Mr. and Mrs. Csobor that he was the contractor on the job. (T-51); At all times during the act of construction of the house, Mr. and Mrs. Csobor were under the impression that Howard North was the contractor (T-44-51). It is, therefore, ORDERED: That the certification of respondent, Stephen J. Borovina, Number CG 0007016, be and is hereby revoked. Respondent is hereby notified that he has thirty (30) days after the date of the Final Order to appeal pursuant to Chapter 120, Florida Statutes, and the Florida Appellate Rules. Dated this 3rd day of August, 1979. FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD BY: JOHN HENRY JONES, President
The Issue Whether the Respondent was validly disciplined by a local government, which causes the Respondent to be in violation of Section 489.129(1)(i), Florida Statutes (1985). Whether the Respondent failed to perform the contracting job alleged in the Administrative Complaint in a reasonably timely manner, or abandoned the job, in violation of Section 489.129(1)(m), (k), Florida Statutes (1985). Whether the Respondent exhibited financial mismanagement, misconduct or diversion, in violation of Section 489.129(1)(h), (m), Florida Statutes (1985). Whether the Respondent committed gross negligence, incompetence or misconduct in connection with the job alleged in the Administrative Complaint, in violation of Section 489.129(1)(m), Florida Statutes (1985).
Findings Of Fact At all times material to these proceedings, the Respondent, Charles R. Schelah was licensed as a certified general contractor in Florida, and held license number CG C016841. Mr. Schelah was the qualifying agent for Schelah Construction, Inc. On March 11, 1986, Schelah Construction, Inc., entered into a contract with Moner F. Green and Karen L. Green to construct a residence in Prairie Creek Park, Charlotte County, Florida A copy of the contract is Petitioner's Exhibit Pursuant to the written agreement, construction would occur as per the signed construction drawings. The total contract price was to be $102,775.00. This quote was contingent upon a construction start on or before March 15, 1986. After that date, increases in supply and labor costs would be borne by the owners, Mr. and Mrs. Green. The contract further stated that there is no specific completion date, that an expected completion date was August 30, 1986. Construction began on the residence on April 4, 1986. Three revisions of the drawings were completed by the owner before a building permit was requested by the Respondent Schelah. Throughout the progress of construction, major and minor revisions were made by the owners. Many of these revisions delayed construction as the Respondent was required to obtain new special order materials and retrofit many of the changes into the existing construction phase. The Respondent recollected that thirty-five revisions were made to the construction plans by the owners during various phases of construction. In September 1986, the owners began to frequently telephone the Respondent in order to urge him to quickly complete the project as the owners were now required to pay the savings and loan association mortgage installments. The Respondent did not return the telephone calls. A letter was sent to the Respondent by the owners' attorney on November 3, 1986, notifying him that he needed to resume his responsibilities at the construction site. The Respondent did not reply to this letter. On November 7, 1986, the Respondent was removed as contractor of record by the owners. All but the final draw from the savings and loan had been given to the Respondent before his removal. After the Respondent was removed from the project, the owners were given notice of the following liens: $2,750.55 to Pre-Hung Doors of Florida for supplies delivered in August 1986; $700.00 to Paul Hartt Plastering and Stucco, Inc. for work completed in September 1986. The work completed by both subcontractors was performed during the Respondent's term as the prime contractor on the project. These two contractors were never paid by the Respondent out of draws received by him for that purpose through October 1986. These subcontractors, as well as others, testified that they were unable to communicate with Respondent after September 1986. The final draw from the savings and loan in the amount of $19,618.97, was used by the owners to complete the project themselves. The proof of payment submitted by the owner, Mr. Green, at hearing for completion under the direct contract was $6,149.14, in Respondent's Exhibit 14. The residence was completed by the owners in December 1986. Mr. Green, the owner, filed a complaint with the Charlotte County Building Board on October 29, 1986, alleging that the Respondent refused to call him, and was dragging completion of the job for unknown reasons hearing was held on February 19, 1987. At the conclusion of the hearing, the Charlotte County Building board suspended the permitting privileges of Schelah Construction, Inc., until such time as all jobs in progress were finished. During the administrative hearing, the Respondent admitted that a twenty-one day delay on the Green project occurred when he was unable to acquire a sheetrock hanger who would go to the hinterlands (Prairie Creek Park) where the residence was being built. He contends however, that the additional time delays were a result of changes in supply orders due to the changes made by the owners, and the requirement that subcontractors be rescheduled to accommodate these changes. Petitioner's experts in construction practices within Florida, Mr. Bernard Verse and Mr. Stanley Ink, were unable to render an opinion that the Green Construction project had been abandoned by Respondent Schelah, or that there had been a diversion of funds. However, Mr. Ink did render an opinion that the project was not completed in a reasonably timely manner, that the Respondent is guilty of financial mismanagement, and that the Respondent committed gross negligence, incompetence or misconduct on the job in that the Respondent did not use due diligence in completing the job, staying on the job, and paying the subcontractors as the contractor should. Mr. Verse opined that the Respondent committed financial mismanagement and gross negligence in the practice of contracting. It was gross negligence not to maintain contact with clients. The Respondent's own expert in construction practices in the Punta Gorda area, Mr. Larry Deirmeyer, noted that it is difficult to acquire unscheduled building supplies in the Punta Gorda area if a contractor runs a small construction company because the supply houses are in Fort Myers, where rapid growth is occurring. In addition, it is difficult to get subcontractors to work on construction in areas like Prairie Creek Park, which is remote from the developed areas of Charlotte County. After Mr. Deirmeyer was admitted as an expert in construction practices, the Hearing Officer learned that he had built a custom home for the owner Moner Frank Green in 1980. Mr. Green's removal of Mr. Deirmeyer's company from the construction project during the last draw of that project, and his continuous changes in those plans were not considered by the Hearing Officer in this case except for the purpose of weighing Mr. Deirmeyer's independence as an expert witness. Another expert witness in construction practices presented by the Respondent was James Anderson, a state certified contractor from the Port Charlotte area. Mr. Anderson acknowledged the local builder supply problem and rendered the opinion that nine months was a reasonable period of time in which to complete the Green project, based upon the construction plans, the change orders, and the travel required to the project, which is not in the immediate Port Charlotte area. The Respondent Schelah did not maintain communication with the owners regarding the progress of the project, even though he was telephoned repeatedly and received written communication from the Green's attorney. This failure to maintain communication resulted in the Respondent's dismissal from the project. The County's Building Director's requests for communication were also refused by the Respondent.
Recommendation Based upon the foregoing, it is RECOMMENDED: That the Respondent be found not guilty of having violated Section 489.129(1)(i), Florida Statutes, as alleged in paragraph five of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(m) and (k), Florida Statutes, as alleged in paragraph six of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(h) and (m), Florida Statutes, as alleged in paragraph seven of the administrative complaint. That the Respondent be found guilty of having violated Section 489.129(1)(m), Florida Statutes, as alleged in paragraph ten of the administrative complaint in regard to misconduct by the Respondent on the Green project. That the penalties assessed against the Respondent not include an aggravation of penalties under Rule 21E-17.002, Florida Administrative Code, and that the Respondent pay a fine of $750.00, as set forth in Rule 21E-17.001(5), Florida Administrative Code. DONE and ENTERED this 9th day of June, 1989, in Tallahassee, Leon County, Florida. VERONICA E. DONNELLY Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 9th day of June, 1989. APPENDIX TO RECOMMENDED ORDER CASE NO. 88-3442 Petitioner's proposed findings of fact are addressed as follows: Accepted. Accepted. See HO #1. Accepted. See HO #1. Rejected as to location of project. The rest is accepted. See HO #2. Accepted. Accepted. See HO #2. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #6. Accepted. Accepted. See HO #9. Accepted. See HO #9 and #10. Accepted. See HO #10. Accepted. Accepted. See HO #13. Accepted. Accepted. Rejected. See HO #13 and #11. Rejected. See HO #11. Accepted. See HO #11. Accepted. Accepted. Accepted. See HO #14. Accepted. See HO #3 and #8. Accepted. See HO #7. Respondent's proposed findings of fact are addressed as follows: Accepted. See HO #1. Accepted. See HO #2. Accepted. See HO #3 and #4. Accepted. See HO #13. Accepted. See HO #5. Accepted. See HO #6. Accepted. See HO #6. Accepted. See HO #7. 9. Accepted. See HO #9, #10, #11, #12 and #13. 10. Rejected. Irrelevant to this proceeding. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 John Charles Heekin, Esquire 21202 Olean Boulevard, Suite C-2 Port Charlotte, Florida 33952 Kenneth E. Easley, Esquire General Counsel Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 Fred Seely, Executive Director Florida Construction Industry Licensing Board 111 East Coastline Drive Post Office Box 2 Jacksonville, Florida 32202
The Issue Whether Respondent's license as a certified residential contractor should he suspended or revoked, or the licensee otherwise disciplined, for alleged violations of Chapter 489, Florida Statutes, as set forth in Administrative Complaint, dated July 12, 1982. This case was consolidated for hearing with Department of Professional Regulation, Electrical Contractors' Licensing Board v. Raymon E. Johnson, DOAH Case No. 82-2394, pursuant to Rule 28-5.106, Florida Administrative Code. Respondent appeared at the hearing without legal counsel and, after being advised by the Hearing Officer as to his rights to counsel and as to procedures involved in an administrative proceeding, acknowledged that he understood such rights and elected to represent himself. At the commencement of the hearing, Petitioner moved to amend paragraphs 6, 11, 16 and 19 of the Administrative Complaint to correct a typographical error by changing the statutory provision allegedly violated from Section 489.129(1)(c) to 409.129(1)(d) , Florida Statutes. Respondent did not object to the amendment and it was therefore granted. This proceeding involves allegations by Petitioner that Respondent constructed several residences in Sarasota, Florida from 1979 to 1981 without subcontracting electrical, mechanical, and plumbing portions of the buildings in violation of pertinent pro- visions of Chapter 489, Florida Statutes, and that he further practiced electrical contracting with an inactive license and in a county where he was not properly registered, also in violation of Chapter 489, F.S. Petitioner presented the testimony of four witnesses at the hearing, and submitted nine exhibits in evidence. Respondent testified in his own behalf and submitted three exhibits.
Findings Of Fact Respondent Raymon E. Johnson is a certified residential contractor and was so licensed at all times material to the matters alleged in the Administrative Complaint. He was also registered by the Electrical Contractors' Licensing Board as an electrical contractor on April 9, 1979, but such license was not renewed and became delinquent on July 1, 1980. During the valid licensing period, he was registered to perform contracting in Gainesville, Florida and Alachua County. (Stipulation, Petitioner's Exhibit 1) At an undisclosed date, Respondent, a resident of Gainesville, Florida, purchased a lot at 505 South Shore Drive, Sarasota, Florida. On November 30, 1979, Respondent applied to the Building Construction Department of Sarasota County for an owner's building permit to construct a residence on the lot, and the permit was issued on December 14, 1979. The application and permit form provided that if the applicant did not possess a contractor's license and was constructing a single family residence on his land, such structure could not be offered for sale or sold during the valid existence of the current building permit, and that all contracted services must be with licensed contractors. Respondent completed construction of a residence on the property in the spring of 1980, and sold it on or about May 10, 1980. During construction of the house, Respondent had placed a sign on the property which stated "Custom Homes by Ray Johnson." Respondent constructed the home himself and did not subcontract any of the work. (Testimony of Respondent, Petitioner's Exhibits 2, 4, 8) In 1980, Respondent purchased a lot at 3625 Beneva Oaks Boulevard, Sarasota, Florida, and obtained an owner's building permit from Sarasota County on August 7, 1980, to construct a residence there. During construction, Respondent had a "For Sale" sign on the premises. Officials of the Sarasota County Building Construction Department informed him that he would have to take the sign down, and he did, until receiving the certificate of occupancy in early 1981 when he again placed the sign on the property. Respondent sold the house on August 8; 1981. The permit issued for construction contained the same prohibition against offering the property for sale or selling it during the existence of the building permit. Respondent constructed the house himself and did not utilize subcontractors. (Testimony of Respondent, Hayek, Taylor, Petitioner's Exhibits 2-3, 6, 9) On February 2, 1981, Harry W. Mathley obtained an owner's building permit from the Sarasota County Building Construction Department to construct a residence at 3759 Beneva Oaks Boulevard, Sarasota, Florida. Mathley entered into an oral contract with Respondent to perform the framing, electrical and plumbing work on the house. At the time, Respondent told Mathley that he was not licensed in Sarasota County to perform electrical and plumbing work. Mathley paid Respondent a lump sum for the electrical materials and work. Mathley paid for a portion of the plumbing fixtures himself, and paid Respondent a lump sum for the remainder of the fixtures and for the plumbing work. Mathley indicated on a county Subcontractors Verification Form1 prior to issuance of the building permit, that he would perform the electrical and plumbing subcontracting himself. During the course of construction, Mathley permitted Respondent to place a sign "Custom Homes by Ray Johnson" on the property to help him get business. Officials of the County Building Department placed a stop order on the premises on May 11, 1981, which recited that the reason for such notice was that subcontractors were not licensed. Respondent went to the Building Department where the supervisor of licensing explained to him that his sign did not correspond to the owner's building permit taken out by Mathley. Respondent performed the electrical and plumbing work as provided in the oral contract. (Testimony of Hayek, Mathley, Respondent, Petitioner's Exhibits 2, 6, Respondent's Exhibit 1.) On March 6, 1981, Robert L. Rogers obtained an owner's building permit from the Sarasota County Building Construction Department to construct a residence at 3735 Beneva Oaks Boulevard, Sarasota, Florida. On the Subcontractors Verification Form which was completed prior to obtaining the building permit, Rogers stated that the electrical and plumbing work was to be performed by himself as owner. He entered into an oral contract with Respondent to do the framing, electrical and plumbing portions of the house and paid him in a lump sum for this work. Respondent advised him that he was not licensed to perform electrical and plumbing contracting in Sarasota, but was qualified in another county. Respondent performed the electrical and plumbing work as provided in the oral contract. (Testimony of Rogers, Respondent, Petitioner's Exhibit 2, Respondent's Exhibit 2) Section 113.1 of Sarasota County Ordinance No. 80-90 makes it unlawful for any person to do any construction work in the various trades, including electrical and plumbing, unless he holds an active Sarasota County Operating Certificate, in addition to an applicable Sarasota County Certificate of Competency and State of Florida Registration, or a valid certification by the Florida Construction Industry Licensing Board. The ordinance further provides in that section that no person who is to perform all construction work on his own building is required to hold an operating certificate, provided that the building is for his own single family residence and the required permit is issued. It further provides that the hiring out by "day labor" in order to avoid operating certificate requirements shall be deemed a violation of the ordinance. Section 106.3(c) of the ordinance provides that all work contracted for under a construction permit shall be performed by contractors holding operating certificates for the particular trade involved. Respondent did not hold an operating permit or certificate of competency from Sarasota County at the time he did the work on the residences of Mathley and Rogers. (Testimony of Hayek, Petitioner's Exhibit 5) Respondent testified at the hearing that he had originally intended to build the residences at 505 South Shore Drive and at 3625 Beneva Oaks Boulevard as personal residences and to move his family from Gainesville to Sarasota when his daughter completed high school in the spring of 1981, but that he was unable to do so because of financial difficulties involving unsold houses in Gainesville. However, he conceded that "Well, I am a builder. Any house that I build is for sale." He further testified chat he had resided for several days a week in the residence at 3625 Beneva Oaks Boulevard from the period after it was completed until it was sold. (Testimony of Respondent, Respondent's Composite Exhibit 3)
Recommendation That the Construction Industry Licensing Board suspend he license of Respondent Raymon E. Johnson as a certified residential contractor for a period of three (3) months. DONE AND ENTERED this 2nd day of December, 1982, in Tallahassee, Florida. THOMAS C. OLDHAM Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of December, 1982. COPIES FURNISHED: John O. Williams, Esquire Department of Professional Regulation 547 North Monroe Street, Suite 204 Tallahassee, Florida 32301 Raymon E. Johnson P. O. Box 13981 Gainesville, Florida 32604 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Samuel Shorstein, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 ================================================================= AGENCY FINAL ORDER ================================================================= STATE OF FLORIDA DEPARTMENT OF PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD DEPARTMENT OF PROFESSIONAL REGULATION Petitioner, vs. CASE NO. 0015275 DOAH CASE NO. 82-2393 RAYMON E. JOHNSON CR C004461 612 101ST Street Gainesville, Florida 32604 Respondent. /
The Issue DOAH Case No. 89-3902, the Barona and Carrow Complaints Whether Respondent violated Florida Statutes Section 489.129(1)(d), by willfully or deliberately disregarding and violating the applicable building codes or laws of the state or of any municipalities or counties thereof. Whether Respondent violated Florida Statutes Section 489.129(1)(m), by being guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 90-1900, the Grantz, Victor, Beckett, Maffetonne, and Wolfe Complaints Whether Respondent violated Sections 489.129(1)(m), (j), and 489.105(4), and 489.119, Florida Statutes, by being guilty of gross negligence, incompetence, and/or misconduct. Whether Respondent violated Sections 489.129(1)(h), (m), (j), and 489.119, and 489.105(4), Florida Statutes, by being guilty of financial mismanagement or misconduct. Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilful or deliberate violation or disregard of applicable local building codes and laws. Whether Respondent violated Sections 489.129(1)(m), (j), 489.119, and 489.105(4), Florida Statutes, by failing to properly supervise contracting activities he was responsible for as qualifying agent, which supervisory deficiency also reflected gross negligence, incompetence, or misconduct Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Sections 489.129(1)(m), and (j), Florida Statutes, by giving a guarantee on a job to a consumer and thereafter failing to reasonably honor said guarantee in violation of Florida Statutes. DOAH Case No. 90-1901, the Klokow Complaint Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilfully or deliberately disregarding and violating the applicable building codes or laws of the state or any municipalities or counties thereof. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being guilty of fraud or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 90-1902, the Meister Complaint Whether the Respondent violated Section 489.129(1)(n), Florida Statutes, by failure to obtain a permit. DOAH Case No. 91-7493, the Antonelli Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 91-7951, the Insurance, Palomba, Romanello and Marin Complaints The Insurance Complaint Whether Respondent violated Section 489.129(1)(c), Florida Statutes, by violating Section 455.227(1)(a), Florida Statutes, by making misleading, deceptive, untrue, or fraudulent representations in the practice of his profession. Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilfully or deliberately disregarding and violating the applicable building codes or laws of the state or any municipalities or counties thereof. Whether Respondent violated Section 489.129(1)(c), Florida Statutes, by violating Section 455.227(1)(b), Florida Statutes, by intentionally violating a Board rule. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Palomba Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Romanello Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Marin Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 92-0370, the Pappadoulis Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing financial misconduct. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by committing gross negligence, incompetence and misconduct in the practice of contracting.
Findings Of Fact Pre-Hearing Admissions 3/ Admissions Applicable to All Cases Respondent is currently licensed as a contractor by the Florida Construction Industry Licensing Board. Respondent's current license number from the Florida Construction Industry Licensing Board is CG C040139. Respondent is licensed by the Florida Construction Industry Licensing Board as a certified general contractor. Respondent holds Florida Certified Roofing License No. CC-042792. Respondent is the qualifying agent for Tropical Home Industries, Inc. As qualifying agent for Tropical Home Industries, Inc., Respondent is responsible for all work performed. DOAH Case No. 89-3902 Respondent was licensed as set forth in items 1, 2, 3 and 4 above at the time of the job alleged in the Administrative Complaint. Exhibit "A", attached to the Request for Admissions 4/ is a true and correct copy of the contract between Sarah S. Carrow and the firm Respondent qualified at the time the contract was executed. As a qualifier for Tropical Home Industries, Inc., Respondent was responsible in his capacity as a certified general and roofing contractor for all work performed by Tropical Home Industries, Inc., pursuant to its contract with Sarah S. Carrow. Pursuant to the contract between Sarah S. Carrow and Tropical Home Industries, Inc., all work under said contract was to be completed in three (3) to six (6) weeks. Respondent, acting through Tropical Home Industries, Inc., failed to complete all work under the contract with Sarah S. Carrow within six (6) weeks after work was commenced. Respondent, acting through Tropical Home Industries, Inc., failed to obtain a final inspection of the work under the contract with Sarah S. Carrow prior to the building permit's expiration date. Broward County, Florida, has adopted the South Florida Building Code as its local ordinance governing residential construction. Respondent's failure to obtain a timely final inspection of the work performed pursuant to the contract between Tropical Home Industries, Inc., and Sarah S. Carrow is a violation of Section 305.2 of the South Florida Building Code. Section 1405.1 of the South Florida Building Code requires installation of either a window or vent fan in each bathroom. Section 3407.9(a) of the South Florida Building Code requires that flashing be installed on plumbing vent pipes which are installed through the roof. Any problems or deficiencies in the work performed by Tropical Home Industries, Inc., pursuant to its contract with Sarah S. Carrow were caused by employees and/or subcontractors of Tropical Home Industries, Inc. DOAH Case Nos. 89-3902, 90-1900, 90-1901, and 90-1902 DOAH Case No. 89-3902 The Baronas' house is located at 1251 Westchester Drive East, West Palm Beach, Florida 33417. Respondent contracted with the Baronas as the qualifying agent of Tropical Home Industries, Inc. The Baronas' house is located within Palm Beach County. Palm Beach County is the appropriate Building Department under which all inspections were to have been performed. DOAH Case No. 90-1901 On or about December 5, 1988, Respondent contracted with Mel Klokow, acting for Linda Klokow ("Klokow"), for the renovation of a screen porch with a roof to her home. Respondent contracted with Klokow as a qualifying agent of Tropical Home Industries, Inc. Permit No. 88-8085 was issued by the local building department. The work at the Klokow residence did not pass final inspection. DOAH Case No. 90-1902 In December of 1987, Respondent contracted to close in a screen porch for Janet Meister ("Meister"). Respondent contracted with Meister as the qualifying agent for Tropical Home Industries, Inc. Respondent failed to obtain a permit for the work performed at the Meister's. Respondent's failure to obtain a permit for the Meister job violated local building codes and Section 489.129(1)(n), Florida Statutes. DOAH Case No. 90-1900 The Grantz home is located at 10878 Granite Street, Boca Raton, Florida. The approximate amount of the contract price with the Grantz was $1,890.00. Respondent contracted for the Grantz job as a qualifying agent of Tropical Home Industries, Inc. Respondent began work at the Grantz residence on or about May 10, 1989. The work at the Grantz residence failed final inspection on July 12, 1989. Respondent wilfully violated applicable local building codes and laws on the Grantz project. Respondent wilfully disregarded local building codes and laws in connection with the Grantz project. Respondent deliberately violated applicable local building codes and laws in connection with the Grantz project. Respondent deliberately disregarded applicable local building codes and laws in connection with the Grantz project. On or about April 12, 1989, and April 17, 1989, Respondent contracted with Stephen Victor ("Victor") to install sliding glass doors at his home. The Victor residence is located at 9768 Majorca Place, Boca Raton, Florida. The contract price with Victor was $3,293.00. Respondent contracted with Victor as a qualifying agent of Tropical Home Industries, Inc. Victor paid a total deposit of $670.00 to Respondent. Respondent never began work at the Victor residence. On or about April 17, 1989, Respondent contracted with Vinton Beckett ("Beckett") to install windows at her home. The Beckett residence is located at 2501 N.W. 41st Avenue, Unit 302, Lauderhill, Florida. The contract price with Beckett was $1,684.00. Respondent contracted with Beckett as a qualifying agent of Tropical Home Industries, Inc. On or about October 29, 1988, Respondent contracted with Thomas and Sherry Maffetonne (the "Maffetonnes") to construct a patio enclosure at their home. The Maffetonne's residence is located at 22980 Old Inlet Bridge Drive, Boca Raton, Florida. The contract price for the work to be performed at the Maffetonnes was $4,350.00. Respondent contracted with the Maffetonnes as a qualifying agent for Tropical Home Industries, Inc. A five-year warranty on materials was given by Respondent for the work to be performed at the Maffetonne's. A one-year warranty on labor was given by Respondent for the work performed at the Maffetonne's. On or about June 6, 1989, Respondent contracted with Mr. and Mrs. Morton Wolfe (the "Wolfes") to install windows at their home. The Wolfe's residence is located at 7267 Huntington Lane, #204, Delray Beach, Florida. Respondent contracted with the Wolfes as the qualifying agent of Tropical Home Industries, Inc. Respondent failed to obtain a timely permit or call for required inspections at the Wolfe residence. DOAH Case No. 91-7951 On June 21, 1990, Tropical's general liability insurance coverage (policy number 891006GL327), produced by Steven Adams and Associates, Inc., (hereinafter "Adams and Associates") and afforded by Guardian P & C Insurance Company, expired. On July 17, 1990, Tropical issued a check to Adams and Associates in the amount of $2,475.00 to obtain general liability and workers' compensation insurance. Upon receipt of the check, Adams and Associates issued a Certificate of Insurance to the Davie (Florida) Building Department indicating that Tropical had general liability (policy number GL 235810) and workers' compensation insurance in force through July 17, 1991. After said Certificate of Insurance was issued, Tropical stopped payment on the check issued to Adams and Associates. Tropical failed to issue an additional check or remit payment of any kind, resulting in both the general liability and workers' compensation insurance being canceled, effective July17, 1990. In September of 1990, a Certificate of Insurance was submitted to the Davie Building Department indicating that Tropical had general liability insurance in effect from September21, 1990, until September 21, 1991. Said certificate had been altered in that the issue, effective, and expiration dates had been updated to reflect that the policy coverage was current and in force. The policy listed on the certificate (number 891006GL327, produced by Adams and Associates with coverage being afforded by Guardian P & C Insurance Company) expired on June21,1990, and was never renewed or kept in force after that date. The Davie Building Department had no other certificates or records indicating that Tropical had insurance coverage. Between July 17, 1990, and April 8, 1991, Tropical obtained five (5) building permits from the Davie Building Department. At no time during the aforementioned period did Tropical have general liability insurance, thereby violating Section 302.1(b) of the South Florida Building Code which requires that building permit applicants be qualified in accordance with PartI of Chapter 489, Florida Statutes. Licensees are required to maintain public liability insurance at all times as provided by rules promulgated pursuant to Part I of Chapter 489, Florida Statutes. Construction Industry Licensing Board records indicate that Tropical has general liability insurance coverage through Equity Insurance (hereinafter "Equity") of Hollywood, Florida. Effective June 8, 1988, Tropical's insurance with Equity was canceled. On February 20, 1991, Tropical entered into an agreement with Michael and Margaret Palomba (hereinafter "Palombas") to perform enclosure and remodeling work at the Palombas' residence located at 130 North East 5th Court, Ft. Lauderdale, Florida 33334. The approximate contract price was $11,978.00. On March 13, 1991, Tropical received a $2,994.50 deposit from the Palombas. On March 25, 1991, Tropical obtained a permit for the project from the Broward County Building Department. Subsequent to receiving the permit, Tropical removed an interior closet from the area that was to be remodeled. Subsequent to receiving the permit, Tropical removed interior plaster from the area that was to be remodeled. Subsequent to receiving the permit, Tropical removed exterior doors from the area that was to be remodeled. Tropical then stopped work stating that rotten wood had been discovered, and requested an additional $2,800.00 to continue with and complete the project. Tropical refused to perform any additional work without the Palombas agreeing to the added cost. Tropical failed to continue with the project pursuant to the original agreement. Tropical refused to continue with the project pursuant to the original agreement. Tropical failed to return any monies to the Palombas. In May 1991, the Palombas hired a second contractor, Dan Sturgeon, to complete the project for $13,830.00. On or about July 11, 1990, Tropical entered into an agreement with Don Romanello (hereinafter "Romanello") to construct a screen room on an existing slab at Romanello's residence located in Boca Raton, Florida. The contract price was $9,500.00. Tropical received $4,800.00 in payments from Romanello, but failed to obtain a permit or perform any work pursuant to the agreement. Tropical has failed to return any portion of Romanello's payments. Tropical refused to communicate with Romanello. Based on the preceding, Tropical committed misconduct in the practice of contracting. On or about June 23, 1990, Tropical entered into an agreement with Marcelina Marin (hereinafter "Marin") to construct a screen room at Marin's residence located in Broward County, Florida, for $4,021.00. Tropical received a $2,000.00 deposit from Marin at the time the agreement was entered into. Tropical failed to perform any work under the terms of the agreement. Tropical has failed to return Marin's deposit. Tropical has refused to return Marin's deposit. Based on the preceding, Tropical committed misconduct in the practice of contracting. DOAH Case No. 91-7493 On July 2, 1988, Respondent contracted with Anthony Antonelli ("Antonelli") to construct an aluminum roof over the patio and gutters of his residence at 9303 Laurel Green Drive, Boynton Beach, Florida. The price of the contract was $2,016.00. Antonelli paid a deposit of $500.00 to Tropical Home Industries. Respondent informed Antonelli that he would not be able to perform the work at the contracted price. Respondent never performed any work at the Antonelli's home. Respondent canceled the contract with Antonelli. Respondent failed to return the deposit paid by Antonelli to Tropical Home Industries. Testimony at Final Hearing Facts Applicable to All Cases Respondent is, and has been at all times hereto, a certified general and roofing contractor in the State of Florida, having been issued license number CG C040139 and CC 2042792. For all contracts and jobs referenced in all of the administrative complaints in these consolidated cases, Respondent acted through the contracting business with which he was associated and for which he was responsible in his capacity as a licensed contractor. DOAH Case No. 89-3902, The Barona and Carrow Complaints Respondent contracted with Rhonda Barona to build an addition to her home at 1251 Westchester Dr. East., West Palm Beach, Florida, for approximately $5,124. The work performed at the Barona residence took an unreasonable amount of time to complete. The permit issued to perform the work at the Barona residence was canceled and Respondent failed to obtain a final inspection. Respondent contracted with Sarah Carrow to build an addition at her home located at 1421 N. 70th Avenue, Hollywood, Florida, for approximately $14,460.60. Respondent allowed the permit to expire and failed to obtain required inspections at the Carrow residence. Respondent failed to fully comply with applicable local codes by failing to install a window or vent fan in the bathroom. DOAH Case No. 90-1900, The Grantz, Victor, Beckett, Maffetonne and Wolfe Complaints On or about March 31, 1989, Respondent contracted with John and Lori Grantz to install windows at 10878 Granite Street, Boca Raton, Florida, for the amount of $1,890.00. Work at the Grantz residence began on or about May 10, 1989. At the time work began, no permit had been obtained. A late permit was obtained on June 15, 1989, in violation of local codes. The work performed by Respondent at the Grantz residence failed final inspection on July 12, 1989, because the structure was not constructed as for the intended use. The windows which were installed were designed as a temporary structure, removable in cases of severe weather and not as a permanent enclosure. On or about April 12, 1989, and April 17, 1989, Respondent contracted with Stephen Victor ("Victor") to install sliding glass doors and windows at 9768 Majorca Place, Boca Raton, Florida, for the total amount of $3,293.00. Victor paid Tropical a total deposit of $670.00, but work never began. On or about April 17, 1989, Respondent contracted with Vinton Beckett ("Beckett") to install windows at 2501 N.W. 41st St., Unit 808, Lauderhill, Florida, in the amount of $1,684. A five-year warranty on materials and a one-year warranty on labor were provided to Beckett by Tropical. Respondent failed to obtain a timely permit or call for required inspections in violation of local law. Respondent failed to correct defects and deficiencies in the work performed at the Beckett residence in a reasonable amount of time. On or about October 29, 1988, Respondent contracted with Thomas and Sharee Maffetonne to construct a patio enclosure at 22980 Old Inlet Bridge Drive, Boca Raton, Florida, for the amount of $4,350.00. A five-year warranty on materials and a one-year warranty on labor were given. Respondent failed to correct defects and deficiencies in the work on the Maffetonne residence in a reasonable amount of time. On or about June 6, 1989, Respondent contracted with Morton Wolfe to install windows at 7267 Huntington Lane, #204, Delray Beach, Florida, for the amount of $1,668.13. Respondent failed to obtain a timely permit or call for required inspections at the Wolfe residence in violation of local codes. DOAH Case No. 90-1901 The Klokow Complaint On or about December 5, 1989, Respondent contracted with Mel Klokow, acting for Linda Klokow, for the construction of a screen porch with a roof to her home at 5292 N.E. 10th Terr., Ft. Lauderdale, Florida, for the sum of $4,473.00. Permit number 88-8085 was issued by the local building department. The work performed at the Klokow residence initially failed to pass the final inspection, and the Respondent failed to return to correct the code violations in a reasonable amount of time. DOAH Case Number 90-1902 The Meister Complaint In December of 1987, Respondent contracted to close in a screen porch for Janet Meister. Respondent failed to obtain a permit for the work performed, which is a violation of local building codes. DOAH Case Number 91-7493 The Antonelli Complaint On July 2, 1988, Respondent contracted with Anthony Antonelli ("Antonelli") to construct an aluminum roof over the patio and gutters at his residence at 9303 Laurel Green Drive, Boynton Beach, Florida. The price of the contract for the work to be performed at the Antonelli residence was $2,016.00. Antonelli remitted a deposit of $500 to the Respondent. Respondent informed Antonelli that he would not be able to perform said job for the contracted price and no work ever began. Respondent canceled the contract with Antonelli and failed to return the deposit to Antonelli. DOAH Case Number 91-7951 The Insurance, Palomba, Romanello and Marin Complaints On June 21, 1990, Tropical's general liability insurance coverage, policy number (891006GL327), produced by Stephen Adams & Associates, Inc., ("Adams & Associates") and afforded by Guardian Property & Casualty Company, expired. On July 17, 1990, Tropical issued a check to Adams & Associates in the amount of $2,475.00 to obtain and/or renew general liability and workers' compensation insurance. Upon receipt of the check, Adams & Associates issued a certificate of insurance to the Davie Building Department in Davie, Florida, indicating that Tropical had general liability (policy number 235810) and workers compensation insurance in force through July 17, 1991. After said certificate of insurance was issued, Tropical stopped payment on the check issued to Adams & Associates. Tropical failed to issue an additional check or remit payment of any kind resulting in the general liability and workers compensation insurance being canceled, effective July 17, 1990. In about September 1990, a certificate of insurance was submitted to the Davie Building Department indicating that Tropical had general liability insurance in effect from September 21, 1990, until September 21, 1991. Said certificate had been altered in that the issue, effective and expiration dates had been updated to reflect that the policy coverage was current and in force. The policy listed on the certificate (number 891006GL327), produced by Adams & Associates and afforded by Guardian Property & Casualty Company, expired on June 21, 1990, and was never renewed or kept in force after that date. The Davie Building Department has no other certificates or records indicating that Tropical has insurance coverage. Between July 17, 1990, and April 8, 1991, Tropical obtained five (5) building permits from the Davie Building Department. At no time during the aforementioned period did Tropical have general liability insurance thereby violating Section 302.1(b) of the South Florida Building Code which requires that building permit applicants be qualified in accordance with Part I of Chapter 489, Florida Statutes. Licensees are required to maintain public liability insurance at all times as provided by rules promulgated pursuant to Part I of Chapter 489, Florida Statutes. Construction Industry Licensing Board ("CILB") records indicate that Tropical has general liability insurance coverage through Equity Insurance Company ("Equity") of Hollywood, Florida. Effective June 8, 1988, Tropical's insurance with Equity was canceled. On February 20, 1991, Tropical entered into an agreement with Michael and Margaret Palomba (the "Palombas") to perform enclosure and remodeling work at the Palomba's residence located at 130 N.E. 5th Ct., Ft. Lauderdale, Florida 33334. The approximate contract price was $11,978.00. On March 13, 1991, Tropical received a $2,994.50 deposit from the Palombas. On March 25, 1991, Tropical obtained a permit for the project from the Broward County Building Department. Subsequent to receiving the permit, Tropical removed an interior closet and exterior doors from the area that was to be remodeled. Tropical then stopped work stating that rotten wood had been discovered, and requested an additional $2,800.00 to continue with and complete the project. Tropical refused to perform any additional work without the Palombas agreeing to the added cost. Tropical failed or refused to continue with the project pursuant to the original agreement and failed to return any monies to the Palombas. In May, 1991, the Palombas hired a second contractor, Dan Sturgeon, to complete the project for $13,000.00. 156. Based on the foregoing, Tropical committed misconduct in the practice of contracting. On or about July 11, 1990, Tropical entered into an agreement with Don and Norma Romanello (the "Romanellos") to construct a screened room on an existing slab at the Romanello's residence located in Boca Raton, Florida. The contract price was $9,500. Tropical received a $4,800.00 payment from the Romanellos but failed to perform any work pursuant to the agreement. Tropical has failed or refused to return any portion of the Romanellos payments and has refused to communicate with the Romanellos. Based on the preceding, Tropical committed misconduct in the practice of contracting. On or about June 23, 1990, Tropical entered into an agreement with Marcelina Marin to construct a screened room at Marin's residence located in Broward County, Florida for $4,021.00 Tropical received a $2,000.00 deposit at the time the agreement was entered into. Tropical failed to perform any work under the terms of the agreement, and has failed or refused to return Marin's deposit. Based on the preceding, Tropical committed misconduct in the practice of contracting. DOAH Case Number 92-0370 The Pappadoulis Complaint On or about February 11, 1990, the Respondent contracted with John Pappadoulis ("Pappadoulis") to remodel a Florida room for the agreed upon amount of $11,448.00 at his residence located at 983 Southwest 31st Street, Fort Lauderdale, Florida. Respondent received a deposit of $648.00, but never obtained a permit nor began work. The Respondent failed or refused to return Pappadoulis' deposit. John Pappadoulis has since passed away. Aggravating and Mitigating Circumstances Monetary Damages Several of the customers in these cases suffered monetary damages. The Baronas had to hire an attorney to deal with the Respondent. The Baronas also incurred additional costs in the work they performed to complete the contract. John and Lori Grantz also suffered monetary damages due to their dealings with the Respondent. The work at the Grantz residence was never completed by the Respondent. The Respondent filed a lien on the Grantz property and also filed a lawsuit to receive the full amount of the contract price. The Grantz had to hire an attorney to obtain legal advice and to defend the lawsuit. The Grantz prevailed in that lawsuit and a judgment was entered requiring the Respondent to refund the $500.00 cash deposit. The Grantz also spent at least $150.00 on attorney fees. The deposit money was never returned and none of their costs were ever reimbursed by the Respondent. Steven Victor also sustained monetary damages in his dealings with the Respondent. Victor paid the Respondent $670.00 as a deposit. No work was ever performed. After requesting the return of his deposit money and failing to receive it, Victor filed a civil action against the Respondent. Judgment was entered in favor of Victor, but the judgment was never paid. The Maffetonnes also sustained monetary damages in their dealings with the Respondent. The Respondent agreed to refund a portion of the contract money to the Maffetonnes due to a problem with the carpet he installed incorrectly, but failed to ever refund any money. The Maffetonnes therefore paid for goods which were defective, and never received a compensatory credit. Klokow also sustained monetary damages in his dealings with the Respondent Because of continuing roof problems, Klokow had to hire an independent roofing expert to inspect the roof and prepare a report. Mr. and Mrs. Palomba also sustained monetary damage due to their dealings with the Respondent. When the Respondent abandoned the Palomba job, the Palombas were forced to hire a second contractor at a higher contract price. The Respondent's actions also caused monetary damages to Antonelli, Pappadoulis, Marin, and Romanello. In each case, the homeowner paid a deposit to the Respondent, and the Respondent failed to ever perform work or return any of the deposit money. The Antonellis paid $500.00, Pappadoulis paid $648.00, Marin paid $2,000.00, and Romanello paid $4,800.00. Actual Job-Site Violations of Building Codes or Conditions Exhibiting Gross Negligence, Incompetence, or Misconduct by the Licensee Several of the jobs involved in these cases had actual job site violations of building codes or conditions which exhibited gross negligence, incompetence, or misconduct by the Respondent which had not been resolved as of the date of the formal hearing. At the Barona residence, the framing inspection failed twice before finally being passed a third time; the lath inspection failed three times before finally passing on the fourth time; and the final inspection failed and was never satisfactorily completed by the Respondent. At the Carrow residence, the Respondent failed to install a window or vent fan in the bathroom of the room addition which he installed. In addition to the building code violation, the work performed was incompetent as the structure installed leaked for many months. Further, the original permit expired prior to a final inspection ever being obtained. At the Grantz residence, the Respondent exhibited incompetence and misconduct by installing windows that he knew or should have known were unsuitable for the purposes specified by the customer. Severity of the Offense The large number of violations established in these cases indicates that the Respondent is a serious threat to the public. These violations establish that the Respondent had a pattern of failing to conduct any meaningful supervision of work in progress. And perhaps most serious of all is his frequent act of soliciting deposits for projects he apparently had no intention of even beginning, much less finishing. This latter practice borders on constituting some form of larceny. Danger to the Public The Respondent is a danger to the public in two ways. First, he is a financial threat to the public, most significantly by his practice of taking deposits for jobs he apparently did not intend to perform. Second, he is a threat to public safety, because the work he performs is often done in a haphazard, careless manner. The Number of Repetitions of Offenses As is obvious from the findings of fact and conclusions of law in this Recommended Order, the Respondent is guilty of numerous repeated offenses which occurred over a period of approximately three years. The Respondent's numerous offenses are indicative of an attitude of contempt or disregard for the requirements of the applicable rules and statutes. Number of Complaints Against Respondent The charges in these cases are based on fifteen separate customer complaints to the Department of Professional Regulation regarding the Respondent. Further, the Palm Beach County Construction Industry Licensing Board received four complaints from homeowners regarding the Respondent 5/ and the Broward County Consumer Affairs Department received twenty-nine complaints regarding the Respondent. 6/ Such a large number of complaints indicates that the Respondent's shortcomings were not isolated events, but represent a recurring problem. The Length of Time the Licensee Has Practiced The Respondent was first licensed as a state general contractor in 1987. He obtained his roofing contractor license shortly thereafter. The Respondent's licenses were placed under emergency suspension in August of 1991. Damage to the Customers The damages, monetary and otherwise, suffered by the Respondent's customers has already been addressed. In addition, all of the Respondent's customers mentioned in the findings of fact suffered a great deal of aggravation, stress, and frustration in dealing with the Respondent. Penalty and Deterrent Effect In these cases, the proof submitted demonstrates that no penalties short of revocation of the Respondent's licenses and imposition of the maximum amount of fines will act as a deterrent to the Respondent and others and as appropriate punishment for the many violations established by the record in these cases. Efforts at Rehabilitation There is no persuasive evidence in the record of these cases that the Respondent has become, or is likely to become, rehabilitated. To the contrary, the greater weight of the evidence is to the effect that the Respondent is unwilling or unable to conform his conduct to the requirements of the statutes and rules governing the practice of contracting.
Recommendation Based upon the foregoing findings of fact and conclusions of law, IT IS RECOMMENDED: That the Respondent be found guilty of all of the violations charged in each Administrative Complaint and Amended Administrative Complaint as noted in the conclusions of law, and that the Respondent be disciplined as follows: The Respondent be required to pay an administrative fine in the amount of $5,000.00 for each of the twenty-nine counts of violations charged and proved, for a grand total of $145,000.00 in administrative fines; The Respondent's license numbers CG C040139 and CC C042792 be revoked; and The Respondent be required to pay restitution to the following Complainants in the following amounts: Steven Victor - $670.00; John Grantz - $650.00; Don Romanello - $4,800.00; Marcelina Marin - $2,000.00; Anthony Antonelli - $500.00; John Pappadoulis' next of kin - $648.00. All restitution shall earn 12% interest per annum from the date the Complainants paid their deposit to Respondent. DONE AND ENTERED at Tallahassee, Leon County, Florida, this 21st day of October, 1992. MICHAEL M. PARRISH, Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 904/488-9675 Filed with the Clerk of the Division of Administrative Hearings this 21st day of October, 1992.
The Issue Whether Respondent's license as a registered electrical contractor should be suspended or revoked, or the licensee otherwise disciplined, for alleged violations of Chapter 489, Florida Statutes, as set forth in Administrative Complaint, dated July 6, 1982 This case was consolidated for hearing with Department of Professional Regulation, Construction Industry Licensing Board v. Raymon E. Johnson, DOAH Case No. 82-2393, pursuant to Rule 28-5.106, Florida Administrative Code. Respondent appeared at the hearing without legal counsel and, after being advised by the Hearing Officer as to his rights to counsel and as to procedures involved in an administrative proceeding, acknowledged that he understood such rights and elected to represent himself. At the commencement of the hearing, Petitioner moved to amend paragraph 1 of the Administrative Complaint to correct a scrivener's error to delete the words "certified residential contractor" and substitute therefor "registered electrical contractor." Respondent did not object to the amendment and it was therefore granted. This proceeding involves allegations by Petitioner that Respondent constructed several residences in Sarasota, Florida from 1979 to 1981 without subcontracting electrical work on the said residences, as required by Sarasota, Florida, in violation of pertinent provisions of Chapter 489, Florida Statutes, and that he further practiced contracting in a county where he was not properly registered, and on an inactive registration, also in violation of Chapter 489, Florida Statutes. Petitioner presented the testimony of four witnesses at the hearing, and submitted nine exhibits in evidence. Respondent testified in his own behalf and submitted three exhibits.
Findings Of Fact Respondent Raymon E. Johnson is a certified residential contractor and was so licensed at all times material to the matters alleged in the Administrative Complaint. He was also registered by the Electrical Contractors' Licensing Board as an electrical contractor on April 9, 1979, but such license was not renewed and became delinquent on July 1, 1980. During the valid licensing period, he was registered to perform contracting in Gainesville, Florida and Alachua County. (Stipulation, Petitioner's Exhibit 1). At an undisclosed date, Respondent, a resident of Gainesville, Florida, purchased a lot at 505 South Shore Drive, Sarasota, Florida. On November 30, 1979, Respondent applied to the Building Construction Department of Sarasota County for an owner's building permit to construct a residence on the lot, and the permit was issued on December 14, 1979. The application and permit form provided that if the applicant did not possess a contractor's license and was constructing a single family residence on his land, such structure could not be offered for sale or sold during the valid existence of the current building permit, and that all contracted services must be with licensed contractors. Respondent completed construction of a residence on the property in the spring of 1980, and sold it on or about May 10, 1980. During construction of the house, Respondent had placed a sign on the property which stated "Custom Homes by Ray Johnson." Respondent constructed the home himself and did not subcontract any of the work. (Testimony of Respondent, Petitioner's Exhibits 2, 4, 8) In 1980, Respondent purchased a lot at 3625 Beneva Oaks Boulevard, Sarasota, Florida, and obtained an owner's building permit from Sarasota County on August 7, 1980, to construct a residence there. During construction, Respondent had a "For Sale" sign on the premises. Officials of the Sarasota County Building Construction Department informed him that he would have to take the sign down, and he did, until receiving the certificate of occupancy in early 1981 when he again placed the sign on the property. Respondent sold the house on August 8, 1981. The permit issued for construction contained the same prohibition against offering the property for sale or selling it during the existence of the building permit. Respondent constructed the house himself and did not utilize subcontractors. (Testimony of Respondent, Hayek, Taylor, Petitioner's Exhibits 2-3, 6, 9) On February 2, 1981, Harry W. Mathley obtained an owner's building permit from the Sarasota County Building Construction Department to construct a residence at 3759 Beneva Oaks Boulevard, Sarasota, Florida. Mathley entered into an oral contract with Respondent to perform the framing, electrical and plumbing work on the house. At the time, Respondent told Mathley that he was not licensed in Sarasota County to perform electrical and plumbing work. Mathley paid Respondent a lump sum for the electrical materials and work. Mathley paid for a portion of the plumbing fixtures himself, and paid Respondent a lump sum for the remainder of the fixtures and for the plumbing work. Mathley indicated on a county Subcontractors Verification Form, prior to issuance of the building permit, that he would perform the electrical and plumbing subcontracting himself. During the course of construction, Mathley permitted Respondent to place a sign "Custom Homes by Ray Johnson" on the property to help him get business. Officials of the County Building Department placed a stop order on the premises on May 11, 1981, which recited that the reason for such notice was that subcontractors were not licensed. Respondent went to the Building Department where the supervisor of licensing explained to him that his sign did not correspond to the owner's building permit taken out by Mathley. Respondent performed the electrical and plumbing work as provided in the oral contract. (Testimony of Hayek, Mathley, Respondent, Petitioner's Exhibits 2, 6, Respondent's Exhibit l.) On March 6, 1981, Robert L. Rogers obtained an owner building permit from the Sarasota County Building Construction Department to construct a residence at 3735 Beneva Oaks Boulevard, Sarasota, Florida. On the Subcontractors Verification Form which was completed prior to obtaining the building permit, Rogers stated that the electrical and plumbing work was to be performed by himself as owner. He entered into an oral contract with Respondent to do the framing, electrical and plumbing portions of the house and paid him in a lump sum for this work. Respondent advised him that he was not licensed to perform electrical and plumbing contracting in Sarasota, but was qualified in another county. Respondent performed the electrical and plumbing work as provided in the oral contract. (Testimony of Rogers, Respondent, Petitioner's Exhibit 2, Respondent's Exhibit 2) Section 113.1 of Sarasota County Ordinance No. 80-90 makes it unlawful for any person to do any construction work in the various trades, including electrical and plumbing, unless he holds an active Sarasota County Operating Certificate, in addition to an applicable Sarasota County Certificate of Competency and State of Florida Registration, or a valid certification by the Florida Construction Industry Licensing Board. The ordinance further provides in that section that no person who is to perform all construction work on his own building is required to hold an operating certificate, provided that the building is for his own single family residence and the required permit is issued. It further provides that the hiring out by "day labor" in order to avoid operating certificate requirements shall be deemed a violation of the ordinance. Section 106.3(c) of the ordinance provides that all work contracted for under a construction permit shall be performed by contractors holding operating certificates for the particular trade involved. Respondent did not hold an operating permit or certificate of competency from Sarasota County at the time he did the work on the residences of Mathley and Rogers. (Testimony of Hayek, Petitioner's Exhibit 5) Respondent testified at the hearing that he had originally intended to build the residences at 505 South Shore Drive and at 3625 Beneva Oaks Boulevard as personal residences and to move his family from Gainesville to Sarasota when his daughter completed high school in the spring of 1981, but that he was unable to do so because of financial difficulties involving unsold houses in Gainesville. However, he conceded that "Well, I am a builder. Any house that I build is for sale." He further testified that he has resided for several days a week in the residence at 3625 Beneva Oaks Boulevard from the period after it was completed until it was sold. (Testimony of Respondent, Respondent's Composite Exhibit 3)
Recommendation That the Electrical Contractors' Licensing Board impose an administrative fine of $500.00 on Respondent Raymon E. Johnson. DONE AND ENTERED this 2nd day of December, 1982, in Tallahassee, Florida. THOMAS C. OLDHAM Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of December, 1982. COPIES FURNISHED: John O. Williams, Esquire Allen R. Smith, Jr. Department of Professional Executive Director Regulation Board of Electrical Contractors 547 North Monroe Street 130 North Monroe Street Suite 204 Tallahassee, Florida 32301 Tallahassee, Florida 32301 Samuel R. Shorstein, Secretary Raymon E. Johnson Department of Professional Post Office Box 13981 Regulation Gainesville, Florida 32604 130 North Monroe Street Tallahassee, Florida 32301
The Issue Whether Petitioners' claim for monies from the Florida Homeowners' Construction Recovery Fund is subject to adjudication pursuant to Section 120.57(1), Florida Statutes, and, if so, how much should Petitioners be awarded.
Findings Of Fact Based on the evidence adduced at hearing, and the record as a whole, the following findings of fact are made: On or about October 1, 1997, Petitioners entered into a contract in which they agreed to pay Respondent Norman Levinsky's company, Broward Roofing, Inc., $3,700.00 to place a "new shingle roof" on Petitioners' residence and perform other related roofing work. The contract provided Petitioners with a ten-year "labor warranty" and a 30-year shingle warranty. After the contracted work was completed and Petitioners paid Broward Roofing, Inc., the $3,700.00 called for by the contract, the newly-installed roof started leaking. Broward Roofing, Inc., refused to make the necessary repairs. Petitioners paid other contractors to perform the repair work. On November 17, 1998, Petitioner filed an application seeking to recover from the Florida Construction Industries Recovery Fund (which has since been renamed the Florida Homeowners' Construction Recovery Fund) $1,025.00 that they had paid for repairs to the "new shingle roof" Broward Roofing, Inc., had recently installed, contending that they were deserving of such an award inasmuch as "[t]he roofer [Broward Roofing, Inc.] [had] refused to fix [their] new roof that was leaking and [had] totally ignored [their] 10 year warranty." Their application was filed on a Board-produced Construction Industries Recovery Fund Claim Form (Form), at the end of which was printed the following: In addition to your complete written statement, we are requesting documentation of your contractual relationship with the contractor and evidence supporting your claim. Certified copies of the following list of documents are required to assist us in determining your eligibility for recovery. I have attached the following: (these documents are required for proper processing of your claim. Failure to provide required documentation will delay processing and could result in your claim being denied due to incompleteness.) Court certified copy of the Civil Judgment, and/or Final Order of the Construction Industry Licensing Board directing restitution be paid. Copy of contract between you and the contractor. Copies of applicable bonds, sureties, guarantees, warranties, letters of credit and/or policies of insurance. Court certified copies of levy and execution documents. Proof of all efforts/inability to collect restitution judgment. No claims will be processed until 45 days after the date of entry of the Civil Judgment and/or Final Restitution Order. On the completed Form that Petitioners filed, only the spaces next to "Copy of contract between you and the contractor" and "Copies of applicable bonds, sureties, guarantees, warranties, letters of credit and/or policies of insurance" were checked. On May 4, 1999, the Broward County Central Examining Board of Construction Trades filed an Administrative Complaint against "Norman Levinsky d/b/a Broward Roofing, Inc.," which read as follows: Count I At all times material hereto RESPONDENT was a roofing contractor holding Broward County Certificate of Competency #95-7726-R- R. On or about September 16, 1997, RESPONDENT entered into a contract to re- roof Complainant's home located at 10551 N.W. 21st Court, Sunrise, Florida. RESPONDENT obtained a building permit. The work was completed on March 10, 1998 and the roof began to leak on June 1, 1998. RESPONDENT failed to properly supervise to ensure that the tie in with flat roof was properly completed. His failure to ensure such a proper tie in resulted in leaks. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(11) of the Broward County Code of Ordinances by failing to properly supervise a project commenced pursuant to a building permit. Count II Paragraphs 1 and 2 are included as if restated herein. Complainant paid RESPONDENT the total contract price of $3,700.00. RESPONDENT completed the work. RESPONDENT gave Complainant a 10 year labor warranty. RESPONDENT failed and refused to honor his warranty. Complainant had to pay additional amount of $1,025.00 for a new contractor to repair the work of RESPONDENT. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(5)c of the Broward County Code of Ordinances by committing mismanagement which causes financial harm to a customer because the customer had to pay more for the contracted job than the original contract price. Count III Above paragraphs are included as if restated herein. RESPONDENT failed to honor the warranty and complete the project in a workmanlike manner for a period in excess of 90 consecutive days. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(8) of the Broward County Code of Ordinances by abandoning a construction project in which RESPONDENT was under contract as a contractor. It is determined that the above stated charges are grounds for disciplinary action pursuant to Chapter 9, Sections 9-14, 9-28 and 9-46, Broward County Code of Ordinances and Section 6.11, Broward County Charter. Broward County has the authority to certify and discipline local contractors pursuant to Section 489.131, Florida Statutes. Following a hearing on the Administrative Complaint held May 25, 1999, the Broward County Central Examining Board of Building Construction Trades, on June 16, 1999, issued an Order, which read as follows: A Disciplinary Proceeding was held on May 25, 1999, before the Broward County Central Examining Board of Building Construction Trades (the "Board"), in accordance with Section 9-14, Broward County Code of Ordinances (the "Code"). Service of the Administrative Complaint filed against the Respondent was made by certified mail. The Respondent being duly advised was not present at the hearing. The Board heard the sworn testimony of William Grubb and Marlene Grubb. Upon consideration, it is ORDERED: The allegations of fact as set forth in the Administrative Complaint are found to be true and adopted and incorporated herein by reference as findings of fact. The conclusions of law alleged and set forth in the Administrative Complaint are approved and adopted and incorporated herein. Upon these findings, it is therefore ORDERED: That Respondent's Certificate of Competency is hereby revoked. That the Respondent make restitution to the Complainants in the amount of $3,700.00. Prior to the RESPONDENT being allowed to reinstate his certificate of competency or being allowed to sit for any exam administered by a Broward County Central Examining Board, or receiving any license from a Broward County Central Examining Board, RESPONDENT must appear before the Board and prove that the restitution amount has been paid in full. The board's order may be appealed by Petition for Writ of Certiorari to the Seventeenth Judicial Circuit within thirty (30) days of the date of rendition of the order of the board as provided by the Florida Rules of Appellate Procedure. FURTHER, the Broward County Central Examining Board of Construction Trades makes RECOMMENDATION to the Florida Construction Industry Licensing Board to impose on the state registration, the following penalty: 1. Revoke state registration and require the RESPONDENT to make restitution to the Complainants in the amount of $3,700.00. In accordance with Florida Statutes, Chapter 489.131(7)(c) and (d), the disciplined contractor, the complainant, or the Department of Business and Professional Regulation may challenge the local jurisdiction enforcement body's recommended penalty for Board action to the State Construction Industry Licensing Board. A challenge shall be filed within sixty (60) days of the issuance of the recommended penalty to the State Construction Industry Licensing Board in Jacksonville, Florida. If challenged, there is a presumptive finding of probable cause and the case may proceed before the State Board without the need for a probable cause hearing. Failure of the disciplined contractor, the complainant, or the Department of Business and Professional Regulation to challenge the local jurisdiction's recommended penalty within the time period set forth in this subsection shall constitute a waiver of the right to a hearing before the State Construction Industry Licensing Board. A waiver of the right to a hearing before the State Board shall be deemed an admission of the violation, and the penalty recommended shall become a final order according to procedures developed by State Board rule without further State Board action. Pursuant to Section 120.569, Florida Statutes, the Parties are hereby notified that they may appeal the Final Order of the State Board by filing one copy of a Notice of Appeal with the Clerk of the Department of Business and Professional Regulation, Northwood Centre, 1940 North Monroe Street, Tallahassee, Florida 32399-0792, and by filing the filing fee and one copy of the Notice of Appeal with the District Court of Appeal within thirty (30) days of the effective date of said Order. On or sometime after September 1, 1999, Petitioners filed an affidavit prepared by Petitioner Marlene Grubb, which read as follows: I, Marlene A. Grubb, hereby certify that I have completed a reasonable search and inquiry in accordance with the instructions provided by the Construction Industry Licensing Board and have not found property or assets to satisfy my Board Order[1] in whole or part. Legal Names The Department of State revealed that the company Broward Roofing Inc. was administratively dissolved on 9/10/98. The C[IL]B verified the contractor[']s name and license number as: Norman Levinsky d/b/a Broward Roofing Inc. RC0047656. Real Property My search included property in the names: Norman Levinsky and Broward Roofing Inc. in Broward County, Florida. Norman Levinsky had no real property and Broward Roofing Inc. is delinquent on property taxes for over two years. Boats and Motor Vehicles There were no vehicles or boats in the motor vehicle data bank registered to Norman Levinsky or Broward Roofing Inc. Aircraft The FAA in Oklahoma City, Ms. Jeannie Vannest stated that there is no registration listed for Norman Levinsky or Broward Roofing Inc. On March 25, 2004, the Board rendered a Final Order Approving Recommended Order of Disciplinary Action by Local Enforcement Body, which approved the Broward County Central Examining Board of Building Construction Trades' June 16, 1999, Order and read as follows: THIS MATTER came before the Construction Industry Licensing Board (hereinafter referred to as the "Board") pursuant to Section 489.131(7), Florida Statutes, for a determination of whether to accept the proposed recommended penalty by the Broward County Central Examining Board of Building Construction Trades (a copy of which is attached and incorporated herein by reference). Neither the Petitioner, the Respondent nor the Complainant filed a challenge to the local enforcement body's recommended penalty to the Board. Upon consideration of the local enforcement body's Administrative Complaint, the minutes from the meetings on January 21, 1999, and May 25, 1999, and the Final Order of Disciplinary Action and its proposed recommended penalty to the Board in this matter and being otherwise fully advised in the premises it is hereby ORDERED AND ADJUDGED: The proposed recommended penalty is hereby approved and adopted in its entirety and incorporated herein by reference. In accordance with the recommended penalty, Respondent's state registration (RC 0047656) is hereby REVOKED. Respondent shall pay restitution in the amount of $3,700 to William and Marlene Grubb. Respondent will adhere to and abide by all of the terms and conditions of the recommended penalty. Failure to abide by the terms of this Order may result in further action by the Board. This Order shall be placed in and become a part of Respondent's official records. A change in the Respondent's licensure status, including the suspension, revocation, voluntary relinquishment, or delinquency of license, does not relieve the Respondent of his obligation to pay any fines, costs, interest or restitution imposed in this and previous orders. Pursuant to Section 120.68, Florida Statutes, the Parties are hereby notified that they may appeal this Final Order by filing a Notice of Appeal with the Clerk of the Department of Business and Professional Regulation, Northwood Centre, 1940 North Monroe Street, Tallahassee, Florida 32399- 0792, and by filing the filing fee and one copy of the Notice of Appeal with the District Court of Appeal within thirty (30) days of the effective date of this Order. This Order shall become effective upon filing with the Clerk of Department of Business and Professional Regulation. This was the "Final Order of the Construction Industry Licensing Board directing restitution be paid," that, according to the Form Petitioners used to submit their claim for monies from the Florida Construction Industries Recovery Fund, was "required for proper processing of [their] claim." On June 10, 2004, more than five and a half years after Petitioners had filed their claim application, the Board met to determine the merits of their claim pursuant to Section 120.57(2), Florida Statutes. Although given due notice of the Board meeting, neither Petitioners, nor Mr. Levinsky, made an appearance, either in person or through a representative, at the meeting. "[U]pon consideration of the documentation and testimony submitted," the Board determined that Petitioners' claim for $1,025.00 should be "approved." On July 29, 2004, the Board rendered (that is, filed with the agency clerk) a written order to this effect, which read as follows: THIS MATTER came before the Construction Industries Recovery Fund Committee and Construction Industry Licensing Board (the "Board") pursuant to sections 120.57(2) and 489.143, Florida Statutes (2003) as well as rule 61G4-21.004, Florida Administrative Code, on June 10, 2004, in Coral Gables, Florida, for consideration of a claim for restitution from the Construction Industries Recovery Fund (the "Recovery Fund"). William [a]nd Marlene Grubb ("Claimants") and Norman Levinsky ("Licensee") were duly notified of the proceedings. At the proceedings before the committee and the Board, Claimants were not present, and were not represented by counsel. Licensee was not present, and was not represented by counsel. Upon consideration of the documentation and testimony submitted, it is ORDERED: Claimants satisfied all requirements for payment from the Recovery Fund. The Recovery Fund Claim was filed on November 17, 1998. The application was timely filed. The contractor was paid $3,700.00. Claimants were awarded restitution from the Construction Industry Licensing Board on March 24, 2004, in the amount of $3,700.00, pursuant to a Final Order Approving Recommended Order of Disciplinary Action by Local Enforcement Body. The Board adopted and approved the Broward County Central Examining Board of Building Construction Trades recommendation, which found: Contractor held a current and active license at all times material to the transaction; The construction contract is dated September 18, 1997; The work was completed on March 10, 1998, and the roof began leaking June 1, 1998; Contractor failed to honor the warranty on the roof; As a result, Claimants paid an additional $1,025.00 for repair work; Contractor violated subsection 9- 14(b)(5)c of the Broward County Ordinances by committing mismanagement, which caused financial harm to a consumer because the consumer had to pay more for the contractual job than the original contract price. The contractor engaged in activity that appears [to] violate section 489.129(1)(g)2, Florida Statutes (2003). There is an asset search in the file that shows no assets are available from which claimant can satisfy the judgment. Pursuant to section 489.143, Florida Statutes (2003), the maximum amount that the Recovery Fund can pay on a single claim is $25,000.00. Thus, the claim for restitution from the Recovery Fund is APPROVED in the amount of $1,025.00. In accordance with rule 61G4-21.005, Florida Administrative Code, the Secretary of the Florida Department of Business and Professional Regulation is directed to pay the claim from the Recovery Fund after forty-five days from the date upon which the Final Order is filed with the Agency Clerk. Pursuant to section 489.143(6), Florida Statutes (2003), upon payment of the claim from the Recovery Fund, Licensee's licensure to practice contracting is AUTOMATICALLY SUSPENDED without any further administrative action. Pursuant to section 489.143(2), Florida Statutes (2003), upon receipt by Claimant under section 489.143(1), Florida Statutes (2003) of payment from the Recovery Fund, Claimant shall assign his or her additional right, title, and interest in the judgment or restitution order, to the extent of such payment, to the Board, and thereupon the Board shall be subrogated to the right, title, and interest of the Claimant; and any amount subsequently recovered on the award, judgment or restitution order by the Board, to the extent of the right, title, and interest of the Board therein, shall be for the purpose of reimbursing the Recovery Fund. This Order shall become effective upon filing with the Clerk of the Department of Business and Professional Regulation. DONE AND ORDERED this 21st day of June, 2004. Appended to the order was the following Notice of Right of Appeal: You are hereby notified that mediation is not available in this matter. Pursuant to Section 120.569, Florida Statutes, you may seek review of the above by filing a request for hearing with the Executive Director of the Board at 1940 North Monroe Street, Tallahassee, Florida 32399-2202 within twenty-one (21) days of the filing of this Order. Upon request, you will receive an informal hearing pursuant to section 120.57(2), Florida Statutes. In the alternative, you may request a formal hearing pursuant to Section 120.57(1), Florida Statutes, if there are material facts in dispute; if you request a formal hearing, the petition must contain the information required by Rule 28-106.201, Florida Administrative Code, including specification of the facts which are in dispute. If you request a hearing, you have the right to be represented by an attorney or other qualified representative to take testimony. On August 12, 2004, Petitioners filed a Request for Hearing, complaining that they "should be awarded at least $3,475.00" to be adequately compensated for all of the repairs they had to make to their roof as a result of Broward Roofing, Inc.'s failure to meet its responsibilities. On August 30, 2004, the Board referred the matter to DOAH "for the assignment of an Administrative Law Judge to conduct a formal hearing" pursuant to Section 120.57(1), Florida Statutes.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Board issue an order dismissing Petitioners' Request for Hearing challenging the Board's order, rendered July 29, 2004, disposing of their claim for monies from the Fund, but allowing them, if they so desire, to request that that order be vacated and re-rendered so that they will have the opportunity to file a timely appeal in accordance with Section 120.68, Florida Statutes. DONE AND ENTERED this 28th day of December, 2004, in Tallahassee, Leon County, Florida. S __ STUART M. LERNER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 28th day of December, 2004.
The Issue The issue presented is whether Respondent committed the offenses alleged in the administrative complaint, and, if so, what penalty should be imposed.
Findings Of Fact At all times material hereto, Respondent, John Arena, was a certified residential contractor, the qualifying agent for Classic Industries, Inc. and held license number CR C021139 from the Florida Construction Industry Licensing Board. The President and sole owner of Classic was Anthony Manganelli. Mr. Manganelli was also the manager of Classic and the principal from whom Mr. Arena received his information about the contracts entered into by Classic. On or about July 30, 1988, someone contacted Ms. Solange Gaston of Hollywood, Florida, by telephone, and asked her if her roof needed repair. The solicitor represented himself as an associate of Classic and offered to come out and inspect her roof. Ms. Gaston, believing her roof was in disrepair, agreed to have the inspection completed and entered into a contract with Mr. Carlo Mangano, representing himself as an agent of Classic, to do the repair. With Ms. Gaston's agreement, the tile on her roof was replaced with shingle roofing and certain other repairs were attempted. A letter to Petitioner from the Chief Permit Processor of the City of Hollywood, Florida indicates that no roofing permit was issued for Ms. Gaston's address. The roof was leaking prior to the repair and continues to leak. Ms. Gaston paid the complete contract price of $3,500 to Classic, but has been unable to locate Mr. Mangano or to have her roof repair completed. In her attempts to achieve satisfaction, Ms. Gaston contacted Classic and asked to speak with someone in charge. She was under the impression that she was speaking with Mr. Arena; however, she never spoke to Mr. Arena. In fact, Mr. Arena was not aware of the contract with Ms. Gaston until the instant complaint was filed against him. Mr. Arena does not know Mr. Mangano. When Mr. Arena became aware of the problem, he attempted to contact Mr. Manganelli, but was told that Mr. Manganelli had moved. Ultimately, Mr. Arena located Mr. Manganelli at a new address. According to Mr. Arena, Mr. Manganelli produced a copy of what appeared to be a contract with Ms. Gaston which has the signature of Carlo Mangano on it, but it is marked indicating that Ms. Gaston's credit was turned down. Mr. Manganelli told Mr. Arena that Classic had not undertaken the job due to the refusal of credit. With that representation, Mr. Arena was under the impression that the work had not been done, as was the custom of dealing for Classic when credit was denied. The two papers purporting to be contracts, one which Ms. Gaston acknowledged as being the one which she signed and the other being the one which Mr. Arena obtained from Mr. Manganelli as the actual contract between Ms. Gaston and Classic through Mr. Mangano, appear to be altered. Although both documents contain the same information, including the date, parties, addresses, work to be completed and price quoted, the portion of the copy indicating the price is written in Arabic numerals on Mr. Arena's copy and by words on Ms. Gaston's copy. Mr. Arena's copy also has the indication that credit was turned down on it, although the cancelled checks paid to Classic by Ms. Gaston were received into evidence. It was Mr. Arena's arrangement with Mr. Manganelli that Mr. Arena was to be informed of every contract into which Classic entered. In this way, Mr. Arena knew which sites he was to supervise. Since he was not advised about the roofing job for Ms. Gaston, he made no attempt to supervise it and after he became aware that the credit for the job had been disallowed, he was under the reasonable impression that the job was not done by Classic. Further, he did not know Mr. Mangano, nor did he believe that Mr. Mangano had the authority to bind Classic. Mr. Arena believes that Mr. Mangano may have obtained a blank contract form of Classic and misrepresented himself to Ms. Gaston as an agent for Classic. Petitioner asserted, however, that Mr. Arena, nevertheless, was responsible for the job and that Classic did perform the job. Neither Mr. Manganelli nor Mr. Mangano were present or testified at the hearing. Given Mr. Arena's demeanor at the hearing and the conflicting and altered state of the alleged contract forms, Mr. Arena's testimony is deemed credible, and the proof failed to demonstrate clearly that Classic actually attempted to repair Ms. Gaston's roof or that Mr. Arena was responsible for the attempted repair.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is: RECOMMENDED that the Florida Construction Industry Licensing Board issue a Final Order dismissing the administrative complaint filed in this case against Respondent, John Arena. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 20th day of June, 1990. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of June, 1990. COPIES FURNISHED: Robert G. Harris Department of Professional Regulation 1940 North Monroe Street Suite 341 Tallahassee, Florida 32399-0792 John D. Arena 5961 Southwest 13th Street Plantation, Florida 33317 Fred Seely Executive Director Department of Professional Regulation Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 Kenneth D. Easley General Counsel Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792 =================================================================
