Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, the following relevant facts are found. Jesse Bruce, Respondent herein, is a registered roofing contractor and has been issued license No. RC0022948. On September 2, 1981, Respondent entered into a contract to repair a roof at 3684 NW 29th Street, Lauderdale Lakes, Florida, for Ms. Beryl Babb for the sum of $485.00. Respondent admits that he commenced construction under the above-referenced contract without first having obtained a building permit. Respondent was paid in full under the contract by Ms. Babb on September 4, 1981. Pursuant to the terms of the construction contract, Respondent provided for a two-year warranty on the roof repairs. Within an approximate two-month period following the repairs by Respondent, Ms. Babb made repeated phone calls to Respondent's construction company to report complaints that she was having in that the roof and garage appeared to "leak more than it had leaked prior to the repairs." Ms. Babb made at least six telephone calls to Respondent's construction company to no avail. During November, 1981, Ms. Babb filed a civil complaint in small claims court and during January, 1982, Ms. Babb received a judgment against the Respondent for $300.00. 1/ Respondent ahs been a licensed and registered roofing contractor since October, 1974. Respondent acknowledged that he received complaints from Ms. Babb as was testified herein; however, he states that he was busy during the times in which the complaints were made, an further that he did not want to make repairs inasmuch as Ms. Babb had elected to file a civil complaint against him in small claims court. Finally, Respondent acknowledged that he was obliged to return tot he Babb residence to make the repairs inasmuch as the complaints from Ms. Babb came during the two-year period in which the warranty for the roof repairs was in effect.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Respondent be placed on probation for a period of six (6) months. 3/ RECOMMENDED this 3rd day of February, 1983, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of February, 1983. COPIES FURNISHED: Michael J. Cohen, Esquire Suite 101, Kristin Building 2715 E. Oakland Park Blvd. Ft. Lauderdale, Florida 33306 Jesse Bruce 721 NW 20th Ave. Ft. Lauderdale, Florida 33311 Mr. James Linnan Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact At all times material hereto, Respondent was licensed by the Construction Industry Licensing Board as a registered roofing contractor (RC- 0034055), building contractor (CB-C033206), and certified roofing contractor (CC-C035625). At the time of hearing, license RC-0034055 had expired and was no longer in effect. Although Petitioner introduced a "certification of licensure", executed by its custodian of records which purports to establish prior disciplinary action by the Construction Industry Licensing Board against Respondent, said certification references license number CG-C024378. There is no documentation in the record to establish that Respondent has license number CG-C024378, and in any event if this is, in fact, his license, this case does not involve license number CG-C024378. The records' custodian was not present to testify or to be cross-examined, and therefore this apparent discrepancy in the certification is unexplained. Further, the only documentation introduced to support prior disciplinary action by the Board against one of Respondent's licenses, is a certified copy of an order dated August 7, 1985 (Case No. 0051210), but this case involves license RC-0034055, which expired in July 1987 and is no longer in effect. Therefore, it has not been established by evidence in this record that Respondent has previously been subject to disciplinary action by the Construction Industry Licensing Board concerning his current valid licenses, CB- C033206 and CC-C035625. Respondent was the qualifying agent at all times material hereto, of Unique Construction, Inc., 1302 North Clearview Avenue, Tampa, Florida. On February 25, 1986, George Katsarelis entered into a sales contract with Unique Construction, Inc., to reroof his entire house at 6 Venetian Court, Tarpon Springs, Florida. Respondent was not present when the contract was executed, and had not met Katsarelis at the time work commenced on the job. Katsarelis specified to the salesman representing Unique Construction, Inc., that he wanted to be sure all required local permits were pulled for this job. Work on the Katsarelis roof began within only a few days of the execution of the sales contact. Crews from Unique Construction tore off approximately 80% of the Katsarelis roof before a City of Tarpon Springs building inspector stopped work on the job because no permit had been obtained. Thereafter, it took two days for Unique to put a temporary cover over Katsarelis' uncovered roof while a permit was being obtained. A permit was finally obtained on March 19, 1986, and the work was completed. Katsarelis paid Unique Construction, Inc., $7,000, the full contract amount, for reroofing of his home. Between February 25, 1986, and December 1987, Katsarelis had to repeatedly call Unique Construction since his roof leaked every time it rained. A ten foot ceiling section in his Florida room eventually caved in due to these leaks. In December 1987, Respondent came to Katsarelis' home for the first time and decided to reroof the whole house for a second time. No additional payment was required or made by Katsarelis for this second reroofing job. After a hard rain in April 1988 his roof again leaked, and within a week prior to hearing, Respondent made a third attempt to correct Katsarelis' leak problem. According to expert testimony and evidence offered at hearing by Owen Baynard, who was accepted as an expert in roofing, work performed by Unique Construction on the Katsarelis roof was incompetent and the result of a lack of proper supervision of the work crews by the qualifying agent, Respondent. The job fails to meet the standards of local building practices. There was improper and insufficient preparation of the roof surface, a lack of adequate adhesive, nailing, and mopping to meet Sections 101, 107, 109 and 113 of the Southern Standard Building Code Roof Coverings standards, applicable in this case. The only way to remedy Katsarelis' continuing leak problem is to completely redo all work done by Unique Construction on his roof, and completely reroof his house in a workmanlike manner. As qualifying agent for Unique, Respondent was responsible for beginning work on Katsarelis' roof without obtaining or assuring that someone else had obtained a local permit for the job. A permit was not posted on the site when this work began, in violation of local building code requirements. Respondent failed to obtain required local building department inspections on the job. Respondent's actions on the Katsarelis job, as qualifying agent and in actions taken personally on two occasions to correct continued leakage, were incompetent and of substandard quality. On December 17, 1986, Lawrence E. Burkett entered into a sales contract with Unique Construction, Inc., to reroof his home on 62nd Avenue, N.E., in St. Petersburg, Florida. Work commenced shortly after this contract was executed, and upon completion Burkett paid Unique $3,657, the contract amount. Respondent admits that leaks continued to exist in Burkett's roof for nine or ten months after Unique's crews worked on his roof. Finally, on September 16, 1986, Unique's crew replaced a section of roof and this corrected the leaking. In an attempt to correct or prevent damage from leakage, Unique's crews installed pans between Burkett's drop ceiling and the roof to catch water which was leaking into his Florida room. A permit was not posted on the Burkett job, but the record does not establish whether a local permit for this job was required to be posted. On or about February 23, 1987, Respondent was issued a letter of reprimand by the United Construction Trades Board of the City of Tampa. However, no action was taken against his local certificate. This reprimand resulted from a roofing job performed by Respondent on the home of Gerald T. Minnick in late 1986. Repeated attempts by Respondent to correct leakage in the Minnick roof failed.
Recommendation Based upon the foregoing, it is recommended that the Construction Industry Licensing Board enter a Final Order suspending Respondent's licenses numbered CB-C033206 and CC-C035625 for a period of six (6) months and imposing an administrative fine of $2,500; provided that after the expiration of thirty (30) days from the issuance of the Final Order if Respondent pays said fine in full, his license shall be immediately reinstated. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 5th day of August, 1988. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1050 Filed with the Clerk of the Division of Administrative Hearings this 5th day of August, 1988. COPIES FURNISHED: David Bryant, Esquire 220 East Madison Street Tampa, Florida 33602 William E. Whitlock, III, Esquire 116 East 3rd Avenue Tallahassee, Florida 32303 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 =================================================================
The Issue The issues in this case are whether Respondent, Linda Ratliff, d/b/a Suncoast Roofing of Polk County, Inc. (Respondent), violated provisions of Chapter 489, Florida Statutes (2009),1 as alleged in the Administrative Complaint dated June 21, 2010, issued by Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board (Petitioner or Department), and, if so, what penalties should be imposed.
Findings Of Fact Petitioner is the state agency charged with regulating the practice of contracting, pursuant to Section 20.165, Florida Statutes, and Chapters 455 and 489, Florida Statutes. Respondent is, and has been at all times material to the allegations of this case, a certified roofing contractor, license number CCC 058307. Respondent’s license is currently in “probation, active” status. Respondent’s address of record is 2023 Shoreland Drive, Auburndale, Florida 33823. Linda Ratliff, individually, is the licensed, primary qualifying agent for Suncoast Roofing of Polk County, Inc. (Suncoast). J. Ratliff works in the family business, and has done so for approximately 17 years. As the primary qualifying agent for Suncoast, Linda Ratliff is responsible for the supervision of all operations of the business. Such operations include, but are not limited to, field work at contract sites, financial responsibility for the entity, and all contractual obligations of the company. In this case, the only contractual obligation in dispute is in relation to a contract between Respondent and Ray and Loretta Noble. On or about February 25, 2009, Respondent entered into a contract (the contract) with Ray and Loretta Noble. The contract described the work to be performed. The address for the property was identified as 1021 and 1023 Brunell Road, Lakeland, Florida. The Noble property was a duplex, and the contract required the owner to pay $6,800.00 “when finish with work.” The terms of the contract specified that Respondent would: remove the old, flat roofing; replace felt with glass base; fix any rotten wood; recover the roof with 1.5 Iso Board installation and Rubber Bitumen; replace roof stacks with new stacks; obtain the permit; torch down Bitumen; install 12-year manufacturer warranty on shingles, 12 years on Rubber Bitumen, 15 TPO; provide a five-year warranty on labor; clean-up and haul off all trash from roof; roll yard with magnetic roller; provide professional job supervision, and re-shingle the front of the apartment. Respondent applied for and received a building permit for the Noble contract on or about February 27, 2009. Thereafter, Respondent proceeded with work on the property. On or about March 3, 2009, Respondent requested payment from Mr. Noble regarding completion of the roof. J. Ratliff, acting in his capacity as an agent for Respondent, represented to Mr. Noble that the job was finished and that payment was due and owing. Based upon Mr. Ratliff’s representations, Mr. Noble believed that the roof had passed inspection, and that the roof had been installed as presented in the contract. Accordingly, Mr. Noble paid Respondent the full contract price for the job. Unbeknownst to Mr. Noble, the new roof did not pass inspection. In fact, the roof never passed inspection. Initially, Respondent failed to perform minor work to ensure that the roof was water tight. For each deficiency identified by a city inspector, Respondent returned to the job site and made minor repairs. Ultimately, the job could not pass inspection due to the placement of air-conditioning units on the roof of the structure. Respondent did not remove the units prior to installing the new roofing system. In order to assure a water- tight roof, the units would have needed to be removed so that roofing materials could be place underneath. Afterward, the units would have to be re-positioned on the roof. Instead, Respondent sealed around the existing air conditioners as best as could be done, but Respondent’s work did not prevent water from intruding below. After a series of failed inspections, on or about July 7, 2009, city officials, Respondent, and the property owner met at the job site to determine what could be done to cure the roof problems. City officials advised the property owner that the air-conditioning units would need to be moved to allow the installation of roofing material and re-set afterwards. Mr. Noble did not want to incur the cost of the additional project. Respondent also refused to correct the job so that it could pass inspection. Respondent advised Mr. Noble that it would cost an additional $800.00 to have a licensed person remove the units and re-set them. Respondent and Mr. Noble reached an impasse and neither would compromise. Respondent never returned to the job site, and did not obtain an acceptable inspection for the work performed. Eventually, Mr. Noble had another company re-roof the structure and incurred an additional $7,400.00 in roofing expenses. Respondent did not refund any of Mr. Noble’s money, nor did Respondent honor the terms of the contract. The roof failed not fewer than seven inspections and several of the failures were unrelated to the issue associated with the air- conditioning units. The investigative costs for this case totaled $325.90. Respondent has prior disciplinary action against the license, as noted in Petitioner’s Exhibit C. Respondent’s claim that an additional licensee would have been required to remove the air-conditioning units and re- set them, is not mitigation of the circumstances of this case. Respondent had the option of not undertaking a project that required the removal of the air-conditioning units, in order to assure a water-tight result. As the licensed party, Respondent knew or should have known how to install a water-tight roofing system.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding Respondent guilty of violating the provisions of law found in Counts I, II, III, IV, VI, and VII. Based upon the guidelines, past disciplinary actions against the Respondent, and a totality of the circumstances, it is further recommended that an administrative fine in the amount of $5000.00 be imposed for the violations noted above. Also, it is recommended that Respondent’s license be suspended for six months. Finally, it is recommended that Respondent be required to reimburse Petitioner for the investigative and other costs incurred in this case to the full extent allowed by law. DONE AND ENTERED this 30th day of December, 2010, in Tallahassee, Leon County, Florida. S J. D. PARRISH Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 30th day of December, 2010.
Findings Of Fact At all times relevant hereto, respondent, James S. Stroz, held registered roofing contractor license number RC 0034849 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He was first licensed in November, 1979, and at that time qualified under the name of Stroz Roofing. A change in status application was later filed to qualify Stroz Roofing, Inc., 13696 Exotica Lane, West Palm Beach, Florida. Although licensed as a roofing contractor, respondent's firm only performs work on wood shakes or shingles. He does not do hot roofs or flat roofs, which is another speciality in the roofing business. While working for a roofing firm in1979, Stroz became acquainted with Lacy Davis, an unlicensed individual who specialized in flat roof work. When Stroz started his own roofing company in 1983, he began contracting out the flat roof work to other licensed roofing contractors. Lacy Davis learned of this and approached Stroz offering his services on the flat roof work. Stroz knew Davis was unlicensed and would not initially hire him, but Davis gave him a business card of Henry Haywood, a licensed roofing contractor in Palm Beach County and explained he and Haywood were partners and that the work and permitting would be done under Haywood's license. In actuality, Haywood had not authorized Davis to use his business cards, or topull permits under his name. Indeed, Haywood had no knowledge of Davis' activities. Without verifying the truth of Davis' representations, and accepting them instead at face value, Stroz agreed to hire Davis to perform his flat roof work. Between January 20, 1983 and September 30, 1984, Stroz performed some twenty-one jobs using Davis for the flat roof work. At all times, Stroz was under the impression that the work was being done under Haywood's license and that his activities were lawful. Stroz made all checks for the work payable to Lacy Davis or Lacy Davis Roofing. He did this because Davis told him he frequently had difficulty reaching Haywood to cash the checks, and because the business bank account was in Davis' own name. A few of the checks carried a notation at the bottom that payment was for work by Haywood Roofing, but most made no reference to Haywood. Stroz pulled all permits on their jobs reflecting that Haywood Roofing was the licensed contractor. Of the twenty invoices given by Davis to Stroz for the twenty-one jobs, only four were on invoices printed with Haywood's name. The remainder had various other names including "Lacy Davis Roofing," "Lacy Davis" and "Lacy Davis and Benny Guy Roofing Contractors." None of these were licensed as roofing contractors by petitioner. In June, 1984, a member of Davis' crew was injured and it was discovered Davis had no insurance. Stroz's insurance paid the claim, but an investigation ultimately determined that Davis was unlicensed and had no authority to act on Haywood's behalf. This led to the issuance of the administrative complaint herein. Respondent has fully cooperated with petitioner, and in fact voluntarily disclosed one job with Davis that petitioner's investigation had failed to uncover. He admits he was negligent in not checking out the representations of Davis, but he never intended to violate the law. No consumer was harmed in any way by Davis' work, and there are no complaints concerning the quality of the jobs in question.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that Respondent be found guilty as charged in the administrative complaint, and that he be fined $500 to be paid within thirty days from date of the final order rendered in this proceeding. DONE and ORDERED this 2nd day of July, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of July, 1985.
The Issue The issues in Case No. 07-4376PL are whether Respondent violated Subsections 489.129(1)(i), 489.119(2), 489.126(2)(a), and 489.129(1)(j), (m), and (o), Florida Statutes (2004),1 and, if so, what discipline should be imposed. The issues in Case No. 07-4377PL are whether Respondent violated Subsections 489.1425(1), and 489.129(1)(i) and (o), Florida Statutes, and, if so, what discipline should be imposed.
Findings Of Fact Petitioner is the state agency charged with regulating the practice of contracting pursuant to Section 20.165 and Chapters 455 and 489, Florida Statutes. Mr. Roach is, and was at all times material to this action, a certified roofing contractor in the State of Florida having been issued License No. CCC1326005. Mr. Roach's Certified Roofing Contractor License No. CCC1326005 is current and active. Mr. Roach's current addresses of record are Post Office Box 345, Orange Springs, Florida, and 22204 U.S. Highway 301, Hawthorne, Florida. At all times material to this action, Mr. Roach was a licensed qualifier for All Florida Roofing Contractors, Inc. (All Florida). There is evidence in the record sufficient to establish that Mr. Roach has been previously disciplined for a violation under Chapter 489, Florida Statutes. Notably, Mr. Roach has been previously disciplined for, among other things, violations of Subsections 489.129(1)(m) and (o), Florida Statutes. Case No. 07-4376PL Mr. Roach failed to obtain a Certificate of Authority for All Florida, as required by Subsection 489.119(2), Florida Statutes. On or about August 23, 2004, Mr. Pang contracted with Mr. Roach, to remove and replace the hurricane-damaged roof of his hotel property located at 1620 West Vine Street, Kissimmee, Florida. The contract price for the aforementioned project was $40,000.00. Mr. Pang made an initial payment of $2,250.00 on August 22, 2004, and another payment of $20,000.00 on August 23, 2004. As part of the contract, All Florida was required to pull the building permits for the project, and Mr. Roach failed to do this. Mr. Roach commenced work on the project on or about September 7, 2004. On or about late September 2004, he ceased work on the project, and the project remained unfinished. Mr. Pang paid All Florida an additional $10,000.00 on September 16, 2004. On October 1, 2004, the City of Kissimmee issued a Notice of Violation against Mr. Pang for failure to have a building permit for the work that had been performed by Mr. Roach on the roof. Mr. Roach scheduled repairs on the project, but did not return to the project. Mr. Roach did not have any inspections performed on the roof. Later, another contractor hired by Mr. Pang finished the roofing project at a cost of an additional $32,975.00. Case No. 07-4377PL On or about September 15, 2004, Ms. Perez contracted with Mr. Roach to repair roof damage to her residence at 1502 Golden Poppy Court, Orlando, Florida. The contract price for the aforementioned project was $7,268.32, of which Mr. Roach was paid $3,634.16 on September 18, 2004. The contract entered into between Ms. Perez and Mr. Roach failed to inform the homeowner of the Construction Industry Recovery Fund. On or about October 27, 2004, the Orange County Building Department issued Mr. Roach a permit for the aforementioned project (Permit No. T04018050). Mr. Roach did not have any inspections performed on the roof. On September 25, 2004, Ms. Perez paid $3,614.16 to All Florida, which was the remaining amount of the contract. Another contractor was hired by Ms Perez to correct deficient aspects of Mr. Roach's work on the roof at a cost of $900.00.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered whose outcome is the following: That in Case No. 07-4376PL Respondent violated Subsections 489.129(1)(i), (j), (m) and (o), Florida Statutes; Dismiss Count II of the Administrative Complaint in Case No. 07-4376PL; In Case No. 07-4376PL, imposing an administrative fine of $1,000.00 for the violation of Subsection 489.129(1)(i), Florida Statutes; imposing an administrative fine of $5,000.00 for the violation of Subsection 489.129(1)(j), Florida Statutes; imposing an administrative fine of $2,500 for the violation of Subsection 489.129(1)(o), Florida Statutes; no administrative fine is recommended for the violation of 489.129(1)(m), Florida Statutes, because the violation is included in the violations of Subsections 489.129(1)(j) and (o), Florida Statutes; That in Case No. 07-4377PL, Respondent violated Subsections 489.129(1)(i) and (o), Florida Statutes; In Case No. 07-4377PL, imposing an administrative fine of $1,000 for the violation of Subsection 489.129(1)(i), Florida Statutes; imposing an administrative fine of $2,500 for the violation of Subsection 489.129(1)(o), Florida Statutes; Requiring Respondent to make Restitution to Mr. and Mrs. Pang in the amount of $25,000; Requiring Respondent to make Restitution to Ms. Perez in the amount of $900; and Revoking Respondent's contractor license. DONE AND ENTERED this 31st day of March, 2008, in Tallahassee, Leon County, Florida. S SUSAN B. HARRELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 31st day of March, 2008.
The Issue The issue for determination is whether Respondent, licensed as a registered roofing contractor, certified roofing contractor, and certified building contractor, committed various violations of Chapter 489, Florida Statutes, sufficient to justify the imposition of disciplinary sanctions against his licenses.
Findings Of Fact Respondent is Joseph H. Rayl, holder, at all times pertinent to these proceedings, of registered roofing contractor license no. RC 0034055; certified roofing contractor license no. CC C035625; and certified building contractor license no. CB C033206. Petitioner previously disciplined Respondent's license RC 0034055 through the imposition of a $250 fine by order dated July 11, 1985; and Respondent's license CB C033206 by suspension of license for six months and imposition of a fine of $2,500. Petitioner also found probable cause for three cases in 1987 that were closed with letters of guidance to Respondent. Petitioner is the Department of Professional Regulation, Construction Industry Licensing Board, the state agency charged with the regulation of contractors in the State of Florida. Respondent was the qualifying agent for Unique Construction, Inc., (Unique) at all times pertinent to these proceedings. Further, Respondent has been the qualifying agent for Superior Roofing & Construction Inc., (Superior) since February, 1988. On June 19, 1984, Mary Lois Brining, owner of a day care center for children known as Town and Country Schools of Bradenton in Manatee County, Florida, entered into a contract with Respondent to reroof the day care center. Respondent's personnel arrived at the school and removed the roof. Heavy rainfall then caused extensive damage to the interior of the facility and Brining complained to Unique. A representative of the company assured her that the situation would be resolved. Brining later paid Unique $623 to paint the school's interior, in addition to the cost of the roof replacement. While Respondent was never present during the construction, his workmen finished the roofing project on June 26, 1984. When leaks to the roof developed after completion of the job, Brining advised Unique of the leakage on numerous occasions. No action was taken by Respondent or Unique in response to Brining's telephone calls about the roof's leakage. Water leakage also damaged the carpet in Brining's facility, which she replaced at a cost of $2,000. In 1988, Brining finally hired another roofing company to correct the roof leakage. Helen M. Hayes, a resident of Gulfport, Florida, contracted with Unique to reroof the flat portion of the roof to her home on April 12, 1984, for a sum of $2,890. The job was finished on April 15, 1984. Two days later, the roof leaked. Hayes advised Unique and a representative came to the house and attempted to stop the leaks. After every rain, the roof leaked and Hayes would advise Unique. She never saw or spoke with Respondent. Finally, after 22 contacts with the company over a period of two and a half years, Hayes contacted local government building authorities. The building inspector for the City of Gulfport inspected the roof and told the company to replace it. Unique's workmen removed the roof in July, 1986, and left the house uncovered. That same day 10 inches of rain fell in the area of the residence, resulting in extensive damage to the home's interior and clothing which Hayes had stored in the home. Hayes called the police. The police called the building inspector who, in turn, called the roofing company. On July 28, 1986, Unique completed replacing the roof on Hayes' house. That new roof still leaks, the floor to the house is cracked from the leakage, the carpet has been saturated with water, plaster from the ceiling is falling to the floor, and there are water stains on the ceiling and walls throughout the residence. The proof further establishes that the City of Gulfport, located in Pinellas County, Florida, retained a private contractor to conduct an inspection of Hayes' roofing job in July of 1986. That inspection established that the roof should be replaced with a roof complying with building code requirements. Notably, while Unique obtained permits for the job, no final inspection of the project was ever obtained by Respondent's company in accordance with the Southern Building Code adopted as an ordinance by the City of Gulfport. James Oliver Prince is a resident of Lake Hthchineha, a settlement located in Polk County, Florida. He has never met Respondent. Prince entered into a contract with Unique in September of 1985. The reroofing job was completed on or about September 26, 1985. Leaks developed with the onset of the first rain after the completion of the job. Prince notified Unique and a representative came out to the residence to attempt to repair the roof and stop the leaks. This procedure continued on numerous occasions until November of 1987 when Prince attempted to contact Unique regarding the roof's leakage only to be informed that the telephone had been disconnected. Prince tried to locate Unique at the various offices listed on his contract, but received no answer. Eventually, due to the seriousness of the leaks and his inability to contact Unique, Prince hired a carpenter and replaced the roof at a cost of approximately $6,000. As established by testimony of Charles Fant, fire chief and building official for the City of Treasure Island, Florida, Unique obtained a construction permit for a reroofing job for the home of Vincent Ferraro located at 62 North Dolphin Drive in that city. The city has adopted the Southern Building Code as a city ordinance. However, the company never obtained the required final inspection for that job as required by the building code. On August 13, 1986, Carl and Ludie Buice of Bellview, Florida entered into a contract with Unique for a reroofing job on their home. Carl Buice passed away in November of 1986 Later, their son assisted Ms. Buice when leaks developed in the roof by attempting to contact the roofing company. The son, Alfred Buice, was unable to contact Unique. He then contacted the local offices of the Better Business Bureau; thereafter a representative of Superior, Respondent's successor company to Unique, came to the Buice residence on or about May 25, 1988, and gave Alfred Buice a check for $200 in connection with money previously spent by Buice to repair leaks to the roof. Even after repairs, the roof continued to leak to the point that it began to cave in around the roof's edges. Eventually, Alfred Buice had his mother's residence reroofed by another contractor on March 21, 1989, for $5,800. Testimony of Petitioner's expert witness establishes that Respondent was grossly negligent in meeting his qualifying agent responsibilities to supervise financial activities and construction practices of Unique. Further, Respondent's subordinates, who actually carried out roofing activities, performed those tasks incompetently. Respondent failed to comply with existing construction industry practices to inspect jobs where successive complaints were lodged by customers.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that a Final Order be entered revoking Respondent's licenses as a registered roofing contractor, certified roofing contractor, and certified building contractor. DONE AND ENTERED this 7th day of July, 1989, in Tallahassee, Leon County. Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 7th day of July, 1989. APPENDIX The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by the parties. Petitioner's Proposed Findings. 1.-42. Addressed. Respondent's Proposed Findings. None submitted. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, Florida 32399-0750 William E. Whitlock, III, Esquire 320 West Park Avenue Tallahassee, Florida 32301 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Kenneth E. Easley, Esquire Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, Florida 32399-0750
The Issue Whether Respondent committed the offenses alleged in the Administrative Complaint and the penalties, if any, that should be imposed.
Findings Of Fact Petitioner is a licensing and regulatory agency of the State of Florida charged with the responsibility and duty to prosecute administrative complaints pursuant to Chapters 455 and 489, Florida Statutes. At all times pertinent to this proceeding, Respondent was licensed as a certified building contractor and a certified roofing contractor, having been issued license numbers CC C027427 and CB C023123. At all times pertinent to this proceeding, MCI was a corporation engaged in roofing contracting, and Respondent was its qualifying agent. A re-roofing job by MCI on the shared roof of two townhouses located at 105 and 106 Woodland Road, the Village of Palm Springs, Florida (the Village), is at issue in this proceeding. These two townhouses are part of a building consisting of four townhouses. All four townhouses have a shared roof. Essentially, the work by MCI was to re-roof half of the entire roof. At the times material to this proceeding Lawrence Gauer owned the townhouse at 105 Woodland Road (Gauer townhouse) and RCM owned the townhouse at 106 Woodland Road (RCM townhouse). Both townhouses are within the permitting jurisdiction of the Village. Mr. Malt, Respondent's brother, owns RCM. Mr. Malt is a certified general contractor, developer, and real estate broker. Mr. Malt has extensive experience building townhouses, having built over 4,000 dwelling units, including the townhouses where the work at issue in this proceeding occurred. Mr. Malt also owns the company that manufactured the engineered pre-stressed concrete structural members that served as the foundation for the roof at issue in this proceeding. Mr. Malt is not a licensed roofing contractor, and his general contractor’s license does not authorize him to perform roofing work. In the fall of 1998, Mr. Malt determined that the RCM townhouse should be re-roofed. Mr. Malt contacted the owners of the other three townhouses to determine whether they wanted to re-roof their portions of the shared roof. Mr. Gauer decided to have his part of the shared roof re-roofed with Mr. Malt, but the owners of the other two townhouses declined. At all times material to this proceeding, Respondent authorized Mr. Malt to act as an agent for MCI. On January 7, 1999, MCI contracted with Mr. Gauer and with RCM to perform the work at issue in this proceeding. Mr. Gauer signed the contract in his capacity as owner of his townhouse. Mr. Malt signed the contract on behalf of RCM as owner of its townhouse. Mr. Malt also signed the contract on behalf of MCI in his capacity as its agent. The total amount of the contract was $5,000, with each owner (Mr. Gauer and RCM) being responsible for payment of $2,500. The contract required each owner to pay $1,250 upon execution of the contract with the balance due within five days ". . . of completion (inspection by the Village . . .)". On or about January 7, 1999, Mr. Gauer paid $1,850 to MCI. There was no explanation as to why Mr. Gauer paid more than the contract required on that date. Respondent's license number did not appear in the contract, and the contract did not contain a written statement explaining the rights of consumers under the Construction Industries Recovery Fund. On January 13, 1999, Mr. Malt, as agent for MCI, applied to the Village for the requisite building permits for the subject work. On January 13, 1999, the Village issued two separate permits, one for each townhouse, authorizing the re- roofing work contemplated by the subject contract. Each permit reflected that the valuation of the work was $2,500. Consistent with the applicable building code, the Village's building department issued a notice with each permit that because the roof was flat, the roof had to provide positive drainage to prevent the ponding of water or the roof had to be constructed of specific water retaining material. Mr. Malt, as agent for MCI, hired the crew that performed the roofing work at issue in this proceeding. At all times material to this proceeding, Mr. Malt supervised the roofing crew that worked on the two townhouses. Prior to beginning work on the roof, Mr. Malt checked weather forecasts for the area. On January 13, 1999, the roofing crew removed the existing roofing material from the roof. At the end of the workday, the crew covered the exposed roof with plastic sheeting commonly referred to as Visqueen. For a flat roof, the accepted standard in the roofing industry is to remove only as much roofing material as can be replaced with finished roofing material the same day. A plastic sheeting such as Visqueen is inadequate to protect an exposed flat roof from a heavy rainfall. The failure to adequately protect the exposed roof on January 13, 1999, constituted negligence. On the night of January 13, 1999, an unexpected heavy rainfall event occurred. As a consequence of the rainfall and the inadequately protected roof, substantial amounts of rainfall intruded in both townhouses, causing extensive damage. The work crew spent most of January 14, 1999, cleaning up following the rain event the previous day. As of Friday, January 15, 1999, the roof was still exposed. On that date, MCI installed a base coat of hot asphalt and insulation, which was inadequate to waterproof the flat roof. At the end of the workday, the roofing crew covered the roof with Visqueen and left for the weekend. On January 16, 1999, additional heavy rains occurred. Again, as a consequence of the rainfall and the inadequately protected roof, substantial amounts of rainfall intruded in both townhouses, causing additional damage to both townhouses. The failure to adequately protect the exposed roof constituted negligence. Mr. Gauer's homeowner's insurance company paid his policy limits for emergency services and repairs to his townhouse. The repairs were completed on or about February 19, 1999. Mr. Gauer subrogated his rights against MCI to his insurance company. There was a civil action pending by the insurance company against MCI at the time of the final hearing based on the subrogation rights. Mr. Gauer's homeowner's insurance did not cover damages to his or Mr. Poitivent's personal property. The value of those losses was not established. During the week beginning January 18, 1999, MCI installed new roofing material on the roof. In doing so, the roofing crew covered the clothes dryer vent for each townhouse with roofing material. As a result, Mr. Gauer's clothes dryer did not vent properly, and he paid an independent contractor $250.00 to inspect and clean out the dryer vent. MCI promptly corrected the deficient work after Mr. Gauer told Mr. Malt that his dryer vent had been covered during the re-roofing. The accepted standard in the roofing industry is that roof vents are not to be covered over without some specific instruction to do so. MCI's failure to adhere to that standard constituted negligence. MCI asserted that it completed the roofing work in 1999. At the times pertinent to this proceeding, Craig Johns was a building inspector for the Village. Mr. Johns inspected the subject roof on the following dates in 1999: June 15, July 15, August 12, and August 30. Following each inspection, Mr. Johns found that the roof did not pass inspection. Among other deficiencies, Mr. Johns found that the roof did not provide positive drainage, which was required for a flat roof covered in asphalt. 2/ As of the final hearing, MCI had not obtained a passing final inspection from the Village's building department. Mr. Malt established that Respondent had just cause to believe that MCI had completed all work on the project in 1999. Consequently, Respondent is not guilty of abandoning the work within the meaning of Section 489.129(1)(k), Florida Statutes (1997). As of June 15, 2001, Petitioner's costs of investigation and prosecution in this case, excluding costs associated with attorney's time, totaled $794.23. 3/
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner enter a final order finding Respondent guilty of the violations alleged in Counts I, II, V, and VI of the Administrative Complaint. The recommended penalty for the violation alleged in Count I is an administrative fine in the amount of $100. The recommended penalty for the violation alleged in Count II is an administrative fine in the amount of $100. The recommended penalty for the violation alleged in Count V is an administrative fine in the amount of $500. The recommended penalty for the violation alleged in Count VI is an administrative fine in the amount of $500. It is further recommended that the final order require Respondent to pay Mr. Gauer restitution in the amount of $250. It is further recommended that the final order require Respondent to pay investigative costs in the amount of $794.23. DONE AND ENTERED this 5th day of November, 2001, in Tallahassee, Leon County, Florida. CLAUDE B. ARRINGTON Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 5th day of November, 2001.
Findings Of Fact At all times relevant thereto, Respondent, Ronald E. Lotz, held registered roofing contractor license number RC0031773 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He has been a licensed roofing contractor since February, 1978. His present address is 1650 Palm Avenue, Winter Park, Florida. In April, 1979 Lotz and Allen Hartwell entered into a contract whereby Lotz agreed to install a "new truss, and shingle roof" on Hartwell's house located at 4005 Northwest 19th Avenue, Ocala, Florida. The agreed upon price for the job was $1,225. As is relevant here, Lotz agreed, inter alia, that a "(n)ew exterior siding (would) be used on all gables". According to their agreement, Lotz was to purchase the plywood necessary to complete the work while Hartwell agreed to buy all their necessary materials. Section 6 of Marion County Ordinance 78-5, adopted on January 24, requires that a roofing permit be obtained on all jobs where the value of the work exceeds $100.00. Lotz did not obtain such a permit even though he conceded at the hearing that such a permit was required. Although the contract called for a new exterior side on all gables, Lotz did not install the same. Instead, he installed tongue and groove 3/4 inch boards which he felt were an adequate substitute. He discussed this with Hartwell at the time the job was performed and Hartwell did net object to this change in the contract. Hartwell, who filed a complaint against Lotz, was primarily dissatisfied with a wavy roof. However, that aspect of the job is not a part of this proceeding. The contract itself was modified by the parties a number of times. As a result, Lotz omitted certain requirements therein but added others without additional charge. In all, he was paid $1,125 for the project.
Recommendation Based on the foregoing findings of fact and conclusions of law it is, RECOMMENDED that respondent be found guilty of failing to obtain a roofing permit in violation of Subsection 489.129(I)(d) Florida Statutes, and that he be given a public reprimand and fined $250. It is further RECOMMENDED that all other charges against respondent be DISMISSED. DONE and ENTERED this 27th day of September, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of September, 1983 COPIES FURNISHED: Charles P. Tunnicliff, Esquire Deaptment of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Ron Lotz 1650 Palm Avenue Winter Park, Florida 32789 Mr. J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box Jacksonville, Florida 32201
The Issue The issues are based upon an administrative complaint brought by the State of Florida, Department of Professional Regulation against Phillip E. Sheffield, Respondent. In particular, Respondent is said to have violated the building code of the City of Jacksonville, Florida by failing to obtain a building permit before commencing construction work related to a roofing project and building the roof to a slope that was contrary to that local building code. For violations of the City of Jacksonville building code, Respondent is said to have violated Section 489.129(1)(d), Florida Statutes, by willful or deliberate violation and disregard for the applicable building code of the municipality. Finally, Respondent is said to have violated Section 489.113(3), Florida Statutes by failing to subcontract roofing work.
