The Issue The issue for determination is whether Arthur Signore committed the offenses set forth in the administrative complaints and, if so, what action should be taken.
Findings Of Fact At all times material hereto, Arthur Signore (Respondent) was licensed by the Department of Business and Professional Regulation, Construction Industry Licensing Board (Petitioner) as a certified general contractor. He received his license in 1969, qualifying Deluccia Construction. Respondent was issued license number CG CA01004. Subsequently, in 1976, Respondent qualified Construction By Scott (CBS). He was issued license number CG CB01004. At all times material hereto, Respondent has been the qualifier of CBS, and the sole owner and president of CBS. At all times material hereto, Respondent's belief was that Petitioner permitted a general contractor to use his/her license to obtain building permits for construction projects for which the general contractor had no contracts through the business that he/she qualified. Respondent practiced his belief frequently by applying for and obtaining building permits for construction projects for which companies or individuals other than CBS had contracts. Collins Job (Case No. 97-1436) Sometime after Hurricane Andrew in 1992, Respondent made an oral agreement with Harold Bader to go into partnership with Bader and form a construction company, with Respondent qualifying the company. Respondent provided his name, his company's name (CBS), and his license number to Bader in order for the qualifying documents to be completed and submitted to the Petitioner. However, the company was not formed and the qualifying documents were never submitted. At no time material hereto was Bader licensed by the Petitioner to engage in the practice of contracting. Respondent knew or should have known that Bader was not licensed by the Petitioner. In March 1994, Thomas Sherry of American Building Industries, Inc. (ABI), began negotiating with Maria and Wayne Collins, husband and wife, for the remodeling of their home, located at 7417 SW 140th Court, Miami, Florida. On March 24, 1994, the Collins entered into a contract with ABI for the remodeling of their home at a cost of $12,500. Bader was the owner of ABI. Sherry was a salesperson for Bader. Sherry provided the Collins with a business card which showed, among other things, ABI's name, address and telephone number, and license number. The license number on the business card was Respondent's license number. All business cards were provided to Sherry by Bader. At no time material hereto, did Sherry talk with or meet Respondent. The records of the Metropolitan Dade County, Building and Zoning Department reflect, among other things, Respondent's name, his company's name (CBS) and license number on the building permit application for the construction to the Collins' home. However, the address listed for Respondent and his company was the address for ABI. Further, the said records reflect, among other things, that aforementioned information provided, as to Respondent, was used to obtain the building permit. Respondent did not complete the permit application for the building permit to remodel the Collins' home. The Collins paid $6,875 to ABI. Any and all checks were made payable to ABI. No money for the construction on the Collins' home was paid to or received by Respondent. In May 1994, problems developed on the job site between the Collins and ABI. The work performed by ABI failed numerous inspections. Mr. Collins wanted to talk with Respondent who was listed as the contractor on the permit and requested Bader to contact Respondent. Bader refused, indicating to Mr. Collins that all communication should be with him (Bader). Finally, in August 1994 the Collins fired ABI after more problems had developed. At that time ABI had completed some of the work. On August 29, 1994, Mr. Collins met with Respondent at Respondent's place of business. Prior to the meeting, Mr. Collins had called Respondent numerous times regarding his problems with ABI and Bader and requesting assistance from Respondent. Each time Respondent denied having any knowledge of the work being performed. When Mr. Collins met with Respondent, Mr. Collins discussed the problems that he had experienced with ABI and Bader. Respondent continued to deny knowing anything about the construction project but agreed to send his employees to examine the job and determine what could be done, if anything. The following day two of Respondent's workers came to the Collins' home and examined the work completed and the work remaining. Subsequently, Respondent contacted Mr. Collins. Respondent indicated to Mr. Collins that he could complete the job for $5,000. Mr. Collins refused to pay the additional monies since it would extend the remodeling cost beyond the contracted cost and since he was now directly paying the subcontractors. At no time did Respondent or his business (CBS) have a contract with the Collins. Until being contacted by the Collins, Respondent had no knowledge that Bader used his name, business name and license number to contract with the Collins and to obtain the building permit for the remodeling of their home. However, prior to being contacted by the Collins, Respondent had been contacted by other persons who had contracts with ABI, who had been informed by Bader that Respondent was the contractor for their jobs, who had problems with ABI, and who wanted assistance from Respondent. Furthermore, the building permits for the construction jobs of those persons reflected Respondent and Respondent's company as the contractor. At no time material hereto was Bader or ABI licensed by the Petitioner to engage in the practice of contracting. Respondent knew or should have known that neither Bader nor ABI was licensed by the Petitioner to engage in the practice of contracting. Respondent was placed on notice of their unlicensed activity after the contacts by the homeowners prior to the contact by the Collins. Even with the knowledge of the homeowners' complaints prior to the Collins' complaints, at no time did Respondent notify Bader to stop using his (Respondent's) name, company's name and license number. Further, at no time did Respondent notify the Metropolitan Dade County, Building and Zoning Department of Bader's misuse of his (Respondent's) name, company's name, and license number or to no longer issue permits to ABI under his (Respondent's) name, company and license. Walsh Job (Case No. 97-1435) In the Fall of 1995, Patrick and Susan Walsh entered into an oral agreement with John Petracelli for an addition to and the remodeling of their home, located at 761 Glen Ridge Road, Key Biscayne, Florida. On October 16, 1995, the Walshes entered into a verbal agreement with Petracelli for an engineer to produce a set of plans at a cost of $2,250 for the construction to their home. The Walshes paid Petracelli the $2,250 on October 16, 1995. On December 7, 1995, the Walshes entered into a written agreement with Petracelli for the construction work on their home at a cost of $84,000. Pursuant to this written agreement, the Walshes paid Petracelli $16,800 on December 7, 1995. Petracelli contacted Respondent and requested Respondent to be the contractor for the construction work on the Walshes' home. Respondent and Petracelli had met one another previously when Petracelli was a salesperson for Bader. Petracelli informed Respondent that he (Petracelli) had already told the Walshes that Respondent was the contractor. To the contrary, Petracelli had not informed the Walshes that Respondent was involved in the construction to their home. Respondent agreed to be the contractor but informed Petracelli that, until a set of plans was approved by the Village of Key Biscayne Building Division (Building Division), he could not provide Petracelli with a cost figure for the construction work. Petracelli informed Respondent that the plans were being prepared, but did not inform Respondent that the Walshes had paid for the preparation of the plans. Respondent agreed further to submit the completed plans to the Building Division for a "dry run" only. After the dry run, Respondent would provide a cost figure for the construction work. A dry run is a process in which a contractor, who has a complicated job which requires an engineer, submits a set of plans, together with an application for a building permit, to the Building Division for approval. The plans may be subject to several modifications requested by the Building Division before they are approved. As a result, the contractor does not know the estimated cost of a job until the plans have gone through the requested modifications, if any, and approved by the Building Division. After the plans are approved by the Building Division, the contractor is notified to come to the Building Division and sign for and obtain the building permit. Pursuant to the agreement between Respondent and Petracelli, on or about December 11, 1995, Respondent completed an application for a building permit for the addition to and the remodeling of the Walshes' home and gave it to Petracelli. The application reflected, among other things, CBS (Respondent's company) as the contractor, and Respondent as the qualifier. Respondent provided the application to Petracelli for the dry run process only. Further, Respondent reiterated to Petracelli that, once the plans were approved by the Building Division, he (Respondent) would meet with the Walshes and agree on a cost for the construction work on their home and that, after agreeing on the cost he (Respondent) would sign for and obtain the building permit for the construction to begin. Respondent was not aware that Petracelli and the Walshes had a signed agreement for the construction work. Petracelli submitted the plans, along with the permit application, to the Building Division for approval. The plans were modified several times to meet the approval of the Building Division, but were never approved. The Building Division considered the plans submitted to be substandard. Since no plans were approved, no building permit was issued. On or about January 3, 1996, the Walshes met at the Building Division with some of the Building Division's officials, Petracelli, and the engineer who prepared the plans. As a result of the meeting, among other things, the Walshes were able to review the permit application and discovered that Respondent, not Petracelli, was licensed and the contractor for the construction work; concluded that the engineer's work was considered so substandard by the Building Division that any modification produced by the engineer would not be approved by the Building Division; and determined that they no longer wanted Petracelli to perform the construction work on their home. Within 24 hours of the meeting, the Walshes telephoned Petracelli and terminated his services. Also, the Walshes requested the return of all of the monies paid to Petracelli by them; however, Petracelli did not return any of their money. At no time material hereto was Petracelli licensed by the Petitioner to engage in the practice of contracting. Respondent knew or should have known that Petracelli was not licensed by the Petitioner. At no time material hereto did Respondent or his company (CBS) have a contract with the Walshes. At no time material hereto did Respondent have any communication or contact with the Walshes. Biscayne Kennel Club Job (Case No. 97-2998) The Biscayne Kennel Club (BKC), located at 320 NW 115th Street, Miami Shores, Florida, was a track for greyhound racing. On October 30, 1995, the last race was run at BKC. In February 1996, the BKC sold its Pari-Mutuel license. On or about December 11, 1996, the BKC, by and through its representative, Carl Spitzer, entered into a written contract with Cuyahoga Wrecking Corporation (CWC), by and through its representative, Thomas Schwab, for, among other things, the removal of asbestos and the demolition and removal of BKC's grandstand structure and viewing area. The contract was prepared by Schwab, who had 25 years of experience in the demolition business, with 20 years of that experience in the State of Florida. All contract negotiations were between Schwab and Spitzer. At no time was the President and CEO of BKC, Kay Spitzer, involved in the contract negotiations. As to cost, the contract provided at Article 4 that the cost was $37,500 and that the $37,500 was "dedicated to the removal of the described ACM." Further, Article 4 provided that the "balance of the work to be paid for by the sale of the ferrous and non-ferrous metals by the contractor." In addition, the contract provided in Article 7 that, among other things, all permits were included in the contract price and that BKC and the "contractor" would share "equally all the proceeds of the non-ferrous metals minus whatever costs are incurred bringing it to market." The contract did not restrict or prohibit CWC from engaging the services of any individual or subcontractor to perform the work required in the contract. The grandstand structure and viewing area were one structure. Attached to the roof of the structure was a small building which was used by BKC personnel for viewing the races. The roof was the highest part of the structure, except for the small building. The distance from ground level to the top of the roof was 69 feet and 10 inches; and the top of the small building was approximately 15 feet higher than the top of the roof. CWC contracted with Sal's Abatement to perform the asbestos removal. Schwab was licensed by Dade County, Florida, as a specialty contractor. He was notified that the work for the BKC job was outside the scope of his license and that a contractor, licensed by the Petitioner, was required for the BKC job. Schwab contacted Respondent to be the general contractor. Schwab had worked with Respondent before on other, but smaller, jobs. Respondent agreed to be the general contractor in return for a percentage of the contract. Per the agreement, Respondent would obtain the necessary permits, provide the equipment necessary for the demolition, and supervise the workers on the job. On March 6, 1997, Respondent completed an application for a building permit with Miami Shores Village, Florida, for the demolition of the BKC grandstand. The application reflected Respondent's company (CBS) as the contracting company and Respondent as the qualifier. Carl Spitzer signed the permit application on behalf of BKC. On March 17, 1997, a building permit (permit number 41084) was issued by the Village of Miami Shores for the demolition of BKC's grandstand. On April 29, 1997, the cost of the permit, $566.50, was paid. At no time material hereto was Schwab or CWC licensed by Petitioner to engage in the practice of contracting. Respondent knew or should have known that neither Schwab nor CWC were licensed by Petitioner. At no time did a contract exist between Respondent or his company with BKC for the demolition job. Respondent supervised CWC's preparation of the grandstand for demolition. In preparing the grandstand for demolition, Respondent and Schwab met at the site at least 3 times to discuss the demolition and its progress. On May 16, 1997, the grandstand was scheduled to be demolished. On the morning of May 16th, as Schwab was leaving BKC, Respondent arrived. Shortly thereafter, the grandstand accidentally collapsed--the beams supporting the roof of the grandstand failed, and the roof collapsed. Two of CWC's workers were killed and three were seriously injured. After the collapse, BKC contracted with another company, Omega Contracting, to complete the demolition job. The Petitioner submitted documents reflecting that its costs of investigation and prosecution of the complaints against Respondent, excluding costs associated with attorney's time, to be $1,017.25. On May 22, 1997, pursuant to an Emergency Suspension Order, on May 22, 1997, the Petitioner suspended Respondent's license. Respondent has no prior disciplinary action taken against him by the Petitioner.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Construction Industry Licensing Board enter a final order: Dismissing all counts in Case Nos. 97-1435 and 97-1436. Finding that Arthur Signore violated Subsections 489.129(1)(c), (e), and (j), 489.1265(3), and 455.227(1)(a), Florida Statutes (1995). Revoking Arthur Signore's certified general contractor's license. Requiring Arthur Signore to pay all reasonable costs of investigation and prosecution associated with the Department of Business and Professional Regulation's investigation and prosecution of the charges set forth in the Administrative Complaint of Case No. 97-2998.3 DONE AND ENTERED this 13th day of January, 1998, in Tallahassee, Leon County, Florida. ERROL H. POWELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 13th day of January, 1998.
The Issue Whether the Respondent committed the violations alleged in the Administrative Complaint, and, if so, the penalty that should be imposed.
Findings Of Fact Based on the oral and documentary evidence presented at the final hearing and on the entire record of this proceeding, the following findings of fact are made: The Department of Business and Professional Regulation is the state agency responsible for investigating and prosecuting complaints involving violations of the requirements of Chapter 489, Part I, Florida Statutes. Sections 489.131(7)(e) and 455.225, Florida Statutes. Pursuant to Section 489.129(1), the Construction Industry Licensing Board ("Board") is the entity responsible for imposing discipline for any of the violations set out in that section. At all times material to this case, Mr. Vega was a certified general contractor operating under a license issued by the Construction Industry Licensing Board, numbered CG C046448. Mr. Vega has been a licensed general contractor in Florida since 1989, and since 1994, he has been the licensed qualifying agent for Group Construction South Florida, Inc. The residence of David M. Hudson, located at 19801 Southwest 84th Avenue, Miami, Dade County, Florida, was severely damaged in August, 1992, by Hurricane Andrew. In a letter dated October 13, 1992, Mr. Hudson, who holds a doctorate in biology and is the laboratory manager for the University of Miami Chemistry Department, proposed to Mr. Vega that he prepare plans for reconstructing the Hudson residence. On December 23, 1992, Mr. Hudson and Mr. Vega executed a contract for construction work to be performed on the Hudson residence. The parties contemplated that Mr. Vega would complete the work in accordance with the drawings and original blueprints prepared by Jose A. Sanchez, a structural engineer, at Mr. Vega's direction and based on preliminary plans approved by Mr. Hudson. Specifically, Mr. Hudson understood that the major elements of construction included in the December 23 contract were elevation of the house from one story to two stories, construction of a new living area on the second floor, and construction of a basement on the first floor to serve as a "bare bones storage area." The contract price specified in the December 23 contract was $146,338.33, with ten percent due upon acceptance of the proposal, ten percent due at completion of each of eight items of construction specified in the contract, and ten percent due upon completion of the project. The eight items of construction specified in the contract were "demolition work, rising work, tie beams, roof, doors & windows, plaster & tile, pool & fence, finish work and paint." On February 1, 1993, Metropolitan Dade County Building and Zoning Information Department issued Permit Number 93119957 to Mr. Vega for the Hudson project. The building permit was based on the original plans for the project submitted by Mr. Vega on January 19, 1993, together with some items that were added to the plans at the county's request. Mr. Vega began work on the project on February 1, 1993, the day the permit was issued. Mr. Vega hired Ruben Armas to act as foreman for the project, and his duties included hiring and supervising day laborers and procuring materials needed for construction. At the time, Mr. Armas was not licensed, registered, or certified by either Dade County or the State of Florida. Mr. Vega had an arrangement with Mr. Armas whereby he paid Mr. Armas periodic advances on a lump sum payment that Mr. Armas was to receive when the Hudson project was complete. Mr. Vega did not deduct FICA or withholding tax from the payments made to Mr. Armas under this arrangement. Mr. Vega dealt directly with Mr. and/or Mrs. Hudson regarding the project, although they would occasionally leave messages for him with Mr. Armas. Mr. Vega directly supervised Mr. Armas and gave him instructions on the work that was to be performed and the way it was to be done. Mr. Vega was routinely at the job site at least two or three times a day to inspect the work that had been done. Mr. Vega was present at the site during the entire time that cement was poured for footings or other structural elements. Mr. Vega arranged for various subcontractors to work on the project, including electricians, plumbers, air conditioning workers, roofers, carpenters, and drywall hangers. On April 14, 1993, a Department investigator conducted an inspection of the Hudson project during a "hurricane task force sweep." When she and the other members of the task force arrived on the job site, she observed Mr. Armas and two other men "inside working," but she did not observe them working or see the type of work they were doing. Mr. Armas walked out to meet the inspector and gave her a card that contained his name and phone numbers and the words "General construction & roof repair." Mr. Armas told the Department investigator that, when she arrived, he was "working on the footing for the elevation of the house." On April 21, 1993, Mr. Vega signed a Cease and Desist Agreement in which he acknowledged that the Department was investigating allegations that he had "engaged in the practice of aiding and abetting unlicensed contractor Ruben Armas." By signing the agreement, Mr. Vega agreed to cease "engaging in this activity," but he did not admit that the Department's allegations were true. The Department investigator was at the Hudson job site on April 14, 1993, for thirty minutes to an hour, during which time Mr. Vega did not appear at the site. This was the only time she was at the job site while work was being done. As the work progressed on the project, everything appeared to be going well, and Mr. Vega felt that he enjoyed a very good working relationship with Mr. and Mrs. Hudson. Mr. Hudson paid Mr. Vega a total of $116,400.00, or eighty percent, of the original contract price of $146,338.33, in ten percent increments as provided in the contract. By check dated December 23, 1992, Mr. Hudson paid the down payment of $14,633.38. By check dated February 5, 1993, Mr. Hudson paid $14,600.00 upon completion of the demolition work. By check dated March 5, 1993, Mr. Hudson paid $14,633.00 upon completion of raising the structure to two stories. By check dated March 24, 1993, Mr. Hudson paid $14,633.00 upon completion of the tie beams. By check dated April 19, 1997, Mr. Hudson paid $14,633.00 upon completion of the roof. By check dated May 13, 1993, Mr. Hudson paid $14,633.00 which should have been paid upon completion of the doors and windows but which he paid even though the installation of the doors and windows was not complete. By check dated June 23,1993, Mr. Hudson paid $12,000.00 of the $14,633.00 draw because, in his opinion, the project was not being completed on schedule. Finally, by check dated July 2, 1993, Mr. Hudson paid $17,000.00 to bring the payments up to the amount consistent with the contract schedule for completion of the pool and fence. In a letter to Mr. Vega dated June 7, 1993, Mr. Hudson stated that he wanted to make "a major change" in the plans. Specifically, Mr. Hudson wanted to eliminate the swimming pool, which he estimated would save $20,000.00 of the $146,633.00 contract price, and use the money saved "to completely finish the downstairs to be a nice guest area," to "install the better quality carpet we want, complete wooden fence, air conditioning in 1st floor, plumbing ~ electric in 1st floor, [and] indoor wooden shutters for all windows." Mr. Hudson went on to state that he wanted certain enumerated appliances, which would cost $4,108.00, and new furniture, which he estimated would cost $6,000.00, for a total of $10,108.00. According to Mr. Hudson's proposal, Mr. Vega should be able to "finish off the 1st floor the way we want it, install the nice carpet and tile, and do all the other jobs previously listed (fence, plumbing, etc., for 1st floor) for about $10,000.00." The basement area which Mr. Hudson wanted to finish as a "nice" living area consisted of approximately 2,000 square feet and had originally been designed as a storage area, with concrete floor and walls. Mr. Vega and Mr. Hudson discussed the proposal and the costs of the changes, but they did not reach an agreement on the cost of the additional work. 3/ Mr. Hudson asked Mr. Vega to leave the job site and cease work on the project on or about July 3, 1993, and Mr. Vega did not perform any work on the Hudson residence after this time. Mr. Hudson terminated Mr. Vega from the project solely because of the dispute with Mr. Vega over the cost of the changes he had requested in his June 7 letter. Mr. Hudson did not complain to Mr. Vega about the quality of the work that had been completed, and, although he thought that the project was getting behind schedule, Mr. Hudson issued a check dated July 2, 1993, which brought the total payments to eighty percent of the original contract price. When Mr. Vega stopped work on the project, the structure contained deviations from the original plans. 4/ Some of the deviations were items shown in the original blueprints which had not been incorporated into the structure; some were items that were not shown in the original blueprints but were incorporated into the structure at the request of, or with the approval of, Mr. and/or Mrs. Hudson; some were deviations in the size of openings to accommodate doors and in the location and size of windows; most were minor deviations in the placement of electrical switches and receptacles or other similar deviations. The construction was, however, generally consistent with the original plans. 5/ There were three items that were significant deviations from the original plans. The most serious deviation concerned the changes made in the dimensions of the structural slab that formed the floor of the second floor balcony off the family room, kitchen, and dining room and the roof of the first floor terrace. The original plans included a second floor balcony with a width of six feet. The Hudsons asked Mr. Vega to increase the width of the balcony, and Mr. Vega called Mr. Sanchez, the structural engineer who had prepared the original plans, and asked if the width of the slab could be increased. Mr. Sanchez approved an extension from the original six feet to eight feet, eight inches, and he advised Mr. Vega of the additional reinforcement that would be needed to accommodate the increased width. On the basis of Mr. Sanchez's approval, Mr. Vega incorporated the additional reinforcement specified by Mr. Sanchez and poured the slab to the requested width of eight feet, eight inches. Even though Mr. Vega consulted a structural engineer, he did not submit revised blueprints to the building department and obtain approval for the structural change before doing the alteration. He was aware that the building code required approval before such a change could be incorporated into a structure and that his actions violated the code. 6/ The second significant deviation from the original plans was Mr. Vega's failure to construct the fireplace shown in the original plans. According to the plans, a fireplace was to be constructed in the living room, on the second floor. Although the roof was completed and the drywall installed, no accommodation had been made for the fireplace in either the wall or the roof. Mr. Vega intended to construct the fireplace and would have done so had he not been told to cease work on the project. The third significant deviation from the original plans concerns the windows installed in the structure. No window permits or product approvals were contained in the permit file for the Hudson project. In addition, some of the windows were not the size specified in the original plans, some were too deep, and some were placed lower than the thirty inch sill height specified in the original plans. Many of the items identified as "deviations" were actually items not shown on the original plans but incorporated into the structure at the request of, or with the approval of, Mr. and/or Mrs. Hudson. Neither the requests for the additional items nor the costs of the items were reduced to writing by Mr. Hudson or Mr. Vega. At the time Mr. Hudson directed him to cease work on the project, Mr. Vega had contracts with subcontractors to provide the labor and materials specified in the original contract. He was prepared to complete the project in accordance with the original plans and for the original contract amount, with adjustments for the extras that had already been incorporated into the project at the request of, or with the approval of, Mr. and/or Mrs. Hudson. He was also prepared to correct all deficiencies and code violations in the structure. After he was terminated from the project, Mr. Vega continued to negotiate with Mr. Hudson's attorney to arrive at an agreement for completion of the project that would be satisfactory to Mr. Hudson. In a proposal submitted to Mr. Hudson's attorney in the fall of 1993, Mr. Vega offered to complete the project in seven weeks in accordance with the original plans, as modified to incorporate the changes and upgrades Mr. Hudson had requested in the June 7 letter and the changes and upgrades that had already been incorporated into the project at the request of, or with the approval of, Mr. and/or Mrs. Hudson. The total price for completion proposed by Mr. Vega was $56,750.00, which included the cost of the upgrades and extras and the $29,572.00 balance owing under the original contract. Mr. Hudson did not accept this proposal. Instead, he eventually hired a contractor named Robert Krieff, who did some work on the project. In February, 1994, Mr. Hudson took over the building permit himself and hired various subcontractors to work on the project. According to Mr. Hudson, in addition to the $116,400.00 he paid Mr. Vega, he has paid approximately $50,000.00 for work done after he terminated Mr. Vega, and he anticipates spending another $35,000.00 before a Certificate of Occupancy is issued. Mr. Hudson paid off a lien on his property for work done pursuant to his contract with Mr. Vega. A Claim of Lien in the amount of $4,712.00 was filed by Luis A. Roman on October 5, 1993, for drywall hung and finished at the Hudson residence under an arrangement with Mr. Vega. Summary of the evidence. The evidence presented by the Department is sufficient to establish that Mr. Vega willfully violated the building code with respect to the alteration of the width of the second floor balcony. Mr. Vega admitted that he knew he was violating the building code when he extended the width of the second floor balcony beyond the width specified in the original blueprints before submitting revised engineering plans to the county and receiving approval to make the alteration. This violation is one of procedure only, however, and there was no competent evidence presented to establish that Mr. Vega failed to include adequate reinforcement to compensate for the additional width prior to pouring the slab or that there were structural problems with the slab. 7/ The evidence presented by the Department is sufficient to establish that Mr. Vega violated the building code because the work completed by Mr. Vega on the Hudson project contained deviations from the original approved plans. 8/ On the other hand, the evidence presented by the Department is sufficient to establish that this violation is a minor one. The Department's experts testified that the construction done on the Hudson residence by Mr. Vega was generally consistent with the approved plans and that it was commonplace for contractors in Dade County to deviate from the approved plans and later submit revised plans for approval. The evidence presented by the Department is sufficient to establish that Mr. Vega did not file product approvals or obtain window permits prior to windows being installed in the Hudson project. The evidence presented by the Department is not sufficient, however, to establish that these omissions on Mr. Vega's part constituted a violation of section 204.2 of the South Florida Building Code, as alleged in the Administrative Complaint. Although there was some testimony that the building code requires that product approvals be filed and window permits obtained before windows are installed, the applicable code and section were not identified by the Department's witnesses or otherwise made a part of the record. Thus, there is no evidence of the precise obligations imposed on Mr. Vega by the code that was applicable at the time of the Hudson project. As a result, it is not possible to determine whether Mr. Vega fulfilled his obligations under the code. The evidence presented by the Department is not sufficient to establish that Mr. Vega assisted Mr. Armas in engaging in the unregistered or uncertified practice of contracting. There is no evidence in the record that Mr. Armas performed any work on the Hudson project that could be performed only by a licensed contractor. 9/ Notwithstanding the opinions stated by the Department's experts, the evidence presented by the Department is not sufficient to establish that Mr. Vega is guilty of incompetence or misconduct in the practice of contracting as a result of the work done on the Hudson project. The evidence presented by the Department is sufficient to establish that Mr. Hudson suffered financial loss in the amount of $4,712.00, which is the amount Mr. Hudson paid to clear the lien placed on his property by Luis A. Roman. Although this loss is attributable to Mr. Vega's failure to pay Mr. Roman for hanging and finishing drywall in the Hudson residence, the evidence presented by the Department is not sufficient to establish that Mr. Hudson suffered financial loss as a result of the violation with which Mr. Vega was charged and of which he was proven guilty.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Construction Industry Licensing Board issue a Final Order dismissing Counts I and III of its Administrative Complaint, finding that Gonzalo Vega is guilty of violating section 489.129(1)(d), Florida Statutes (1993), and imposing an administrative fine in the amount of $1,000.00. DONE AND ENTERED this 3rd day of July, 1997, in Tallahassee, Leon County, Florida. PATRICIA HART MALONO Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (904) 488-9675 SUNCOM 278-9675 Fax Filing (904) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of July, 1997.
Findings Of Fact At all times material hereto, Respondent has been a registered residential contractor having been issued license number RR 0040275. In approximately 1980, Respondent entered into a contract to erect a screen room for a Mr. Lewis. Under the terms of the contract, Respondent was to obtain the necessary building permit. After the contract had been signed, Respondent's grandfather died, and Respondent therefore went to New Jersey. He left the permit application with his qualifying agent to sign and process through the building department. When Respondent returned from New Jersey approximately 30 to 35 days later, he went to the Lewis job site and found the project almost completed. Respondent did not check to ascertain if the permit had been obtained, but rather completed the screen room himself. Lewis subsequently contacted Respondent to say that he had received a notice of violation from the building department for erecting a screen room without a permit. Respondent contacted the building department and advised that it was not Lewis's fault, but rather that it was Respondent's responsibility to pull the permit. Respondent was charged with unlawfully erecting a screen room without a permit; he appeared in court and pled guilty; and he paid a $250 fine pursuant to the adjudication of guilt entered on April 20, 1981, in the County Court in and for Dade County, Florida, in Case No. 81-50438. On June 24, 1981, Respondent submitted to the Construction Industry Licensing Board a Contractor's Registration application. On that application, Respondent answered in the negative the following question: "Has any person named in (i) below ever been convicted of any offense in this state or elsewhere other than traffic violations?" At the time Respondent gave that answer, he believed it to be true. He understood the question to call for information on criminal acts and did not comprehend the "screen room" charge to have been criminal conduct. Since Respondent answered that question in the negative, his application for registration was processed in accordance with normal procedures. Had Respondent answered that question in the affirmative, his application would not have gone through normal processing but rather would have been presented to the Construction Industry Licensing Board for the Board's determination of whether to approve the application based upon a consideration of the facts. On November 22, 1982, Respondent contracted with Naomi Blanton to construct an addition to Blanton's home located in the City of Miami, in Dade County, Florida, for a contract price of $11,250. When Respondent had first met with Blanton several months earlier, he had told her he could guarantee completion of the project within 45 days. No contract was entered into at that time, however, since Blanton had not obtained the financing she needed in order to construct an addition. When the contract was signed on November 22, Respondent told Blanton he would start the job when he finished the Chamber of Commerce building he was con structing but that he was starting a 12-unit duplex project around Christmas and would not be able to guarantee any 45-day completion deadline. Accordingly, when the contract was signed, no completion date was included in the terms of that written contract, since Respondent did not know when he could guarantee completion. The Blanton contract written by Respondent specifically provided that Respondent would obtain the building permit. On December 22 and 23, 1982, two of Respondent's employees arrived at the Blanton job site, dug a trench, knocked down the utility room, and moved Mrs. Blanton's washing machine. No further work was done until January 1983. Since Respondent knew that he was required to obtain the building permit before commencing any construction work, Respondent submitted his plans and permit application to the City of Miami Building Department. After the plans had been there about a week, he was advised that his plans would not be accepted unless they were drawn by an architect, although that is not required by the South Florida Building Code. After attempting several more times to obtain approval from the City of Miami Building Department, Respondent hired an architect to redraw the plans and secure the building permit. By this time, Respondent found himself unable to concentrate on operating his business efficiently, since he was preoccupied with spending time with his father who was dying of cancer. Also by this time, Blanton had commenced telephone calls to Respondent on an almost daily basis as late as 11:00 p.m. at his office, at his home, at his mother's home, and at his father's home. Respondent offered to return Blanton's deposit, but she refused to cancel the contract and threatened Respondent that she would sue him if he did not comply with that contract. Respondent commenced working on the Blanton job, although no permit had yet been obtained. The contract on the Blanton job called for payments at certain stages of the construction. By January 27, 1983, Respondent had completed a sufficient amount of the work under the contract so that Blanton had paid him a total of $8,270 in accordance with the draw schedule contained in the contract. Respondent ceased working on January 27, 1983, and advised Blanton and her attorney that he would do no further work until he could obtain the building permit, which he had still not been able to obtain. Although he told them his work stoppage was due to his continued inability to obtain the permit, he also stopped work due to his father's illness and his continued inability to get along with Mrs. Blanton. A delay occurred with the plans being redrawn by the architect Respondent hired to obtain the Blanton building permit, since the architect needed information from Blanton and she was out of town. After Blanton returned, the architect made unsuccessful attempts to obtain the building permit. Respondent and his architect were finally able to speak to one of the top personnel in the City of Miami Building Department about the problems they were experiencing in obtaining a building permit, and, at about the same time, Blanton contacted that same individual to complain that Respondent had no permit. On May 4, 1983, the building department finally accepted the second permit application together with the plans drawn by the architect, and the building permit was issued on May 4, 1983. No work was performed on the Blanton job between January 27, 1983, when Blanton paid Respondent the draw to which he was entitled by that date, and May 4, 1983, when the building permit was finally issued by the City of Miami. Respondent immediately resumed work and quickly completed the next stage of construction called for under the Blanton contract. Upon completing that next stage, he requested his next draw payment; however, Blanton decided not to pay Respondent for the work completed and had her attorney advise Respondent not to return to the job site. Blanton then had a friend of her son come to Miami from Wisconsin to complete the addition to her home. At all times material hereto, Respondent held a certificate of competency issued by Metropolitan Dade County.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of violating Section 489.129(1)(d), Florida Statutes, by willfully and deliberately violating Section 301(a) of the South Florida Building Code; imposing an administrative fine against Respondent in the amount of $2,000 to be paid by a date certain; and dismissing the remaining charges contained in the Administrative Complaint, as amended, against Respondent. DONE and RECOMMENDED this 13th day of April, 1984, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of April, 1984. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Joseph F. Scioli, Jr. 246 North Krome Avenue Florida City, Florida 33034 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
The Issue The issue is whether Respondent's license as a registered building contractor should be disciplined for the acts alleged in the Administrative Complaint, as amended?
Findings Of Fact Respondent, Robert Tucker, is a registered building contractor holding State of Florida license number RB 0033063 (Ex. 7). Respondent was licensed as a building contractor by the State of Florida in September 1978, and has remained licensed at all times material hereto (Ex. 7). Since September 20, 1978, Respondent has held a local Building Contractor's License issued by the Leon County Contractor Licensing and Examination Board (Ex. 7). Respondent's license with the Department has been delinquent since July 1, 1985 (Ex. 7). In July 1983, Respondent made an oral agreement with Violet Gladieux to erect a carport for her at a cost of $1,350 (Ex. 3). Ms. Gladieux's residence is located at 2321 Belle Vue Way, within the city limits of Tallahassee. Jay Gladieux, Jr. became acquainted with Mr. Tucker from his position as an employee of Mr. Tucker on a prior construction project. Mr. Gladieux introduced his mother, Ms. Gladieux, to Mr. Tucker for the carport construction. It was orally agreed that Ms. Gladieux would pay Mr. Tucker for supplies as they were needed. Mr. Tucker began erection of the carport approximately one week after July 11, 1983, when he received the first payment of $300. On July 29, 1983, Mr. Tucker received final payment of $350 so that he could complete the carport (Ex. 3). Approximately two weeks after July 29, 1983, Respondent completed the carport. A permit for the erection of the carport was required by Section 7-63, Buildings and Construction Regulations (The Building Code) of the City of Tallahassee. The language of that ordinance has not changed since 1957 (Ex. 1). No building permit was ever obtained by Mr. Tucker for erection of the carport. Approximately two weeks after completion of the carport, it collapsed after a heavy rainfall (Ex. 4 and 5). Mr. Tucker returned to repair the damaged carport. He erected center studs and was to return later to complete the damage repair. Mr. Tucker has failed to return to complete the damage repair after requested to do so by Jay Gladieux. When an administrative complaint has been filed against a contractor, personal service of the complaint is attempted upon the contractor at his last address of record. If personal service cannot be effectuated at the contractor's last address of record, further attempts are made to locate the contractor. The building departments, both City and County, the telephone company, utility company and post office are contacted. The building departments are contacted to determine if the contractor has obtained any permits, for the permits would list the contractor's address. The telephone company is contacted for prior and new telephone listing(s) with address(es). The post office is contacted for forwarding address(es). The utility company is contacted for new utility service which would contain a new address (es). If the contractor cannot be located after using these avenues, a diligent search affidavit is executed by the investigator who is attempting to serve the contractor. In September 1978 and at all times pertaining to the construction of the carport, Respondent's address of record with the Department was 1515-21 Paul Russell Road and P.O. Box 20234, Tallahassee, Florida. Respondent had not notified the Department of Professional Regulation, Construction Industry Licensing Board of any change in his address (Ex. 7), other than by the new address revealed on the Election of Rights form he filed in response to the administrative complaint. The Department attempted to personally serve Mr. Tucker at his listed address and could not locate him there. On May 21, 1984, Robert E. Connell, an investigator for the Department of Professional Regulation, executed a diligent search affidavit concerning service of the Administrative Complaint upon Mr. Tucker in this proceeding (Ex. 8).
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is recommended that Respondent be found guilty of the charges in count one of the Administrative Complaint, as amended; that counts two and three be dismissed; and that he be fined $250.00. DONE AND ORDERED this 4th day of April 1986 in Tallahassee, Leon County, Florida. WILLIAM R. DORSEY,JR., Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 4th day of April 1986. COPIES FURNISHED: Mr. James Linnan Executive Director Construction Industry Licensing Board P.O. Box 2 Jacksonville, Florida 32202 Mr. Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Salvatore A. Carpino, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Errol H. Powell, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Robert Tucker P.O. Box 10218 Tallahassee, Florida 32302
