The Issue Whether Respondent violated provisions of Chapter 75-489, Laws of Florida, as amended, as more specifically alleged in Administrative Complaint dated February 10, 1992.
Findings Of Fact At all times relevant hereto Respondent was licensed by Petitioner as a certified building contractor having been issued license C-608, and was qualifying agent for Bay City Builders, Inc. Bay City Builders, Inc., entered into a contract to add four bedrooms and two baths to a residence in Dunedin, Florida, being used as an Adult Congregate Living Facility (ACLF) (Exhibits 1 and 2), at a price of $32,000. The contract provided, inter alia, that the contractor would provide all permits and fees directly associated with the project. Upon signing the original contract on September 26, 1991, the owner paid Bay City Builders $3200 (Exhibit 3). On October 8, 1991, the owner paid Bay City Builders an additional $7200 (Exhibit 3) when the plans were presented to the owner. Prior to the issuance of the permit for this project, Bay City Builders poured the footing for the building addition. The permit application was signed by Respondent. After entering into the contract, Bay City Builders found there was an impact fee involved, the project was never completed and was subsequently abandoned. Bay City Builders prepared a second contract for this project which increased the price to $41,789 (Exhibit 5) and presented this to the owner who did not accept the new contract. Respondent admits that he was the qualifying contractor for Bay City Builders, and the permit was pulled under his license, but contends he had nothing to do with the financial arrangements between Bay City Builders and the owner. Respondent was paid a flat fee by Bay City Builders for obtaining permits under his license for work Bay City Builders contracted to perform. He occasionally visited the sites where work was being performed by Bay City Builders. Bay City Builders is not licensed. The permit for the ACLF addition was applied for on November 1, 1991, but was not issued by the City of Dunedin until February 13, 1992 (Exhibit 6). It could have been picked up any time after November 30, 1991. On September 5, 1991, Bay City Builders entered into a contract with an owner living in Seminole, Florida, to replace the roof over a rear porch of this residence for a total price of $900. (Exhibit 8) This was a flat roof, and the initial intent was to replace the tar and gravel roof with tar and gravel. At the time construction started on September 11, 1991, the person doing the installation used a rubberized roof, which was satisfactory to the owner and gave the owner a 5 year unconditional warranty. Respondent's license does not authorize him to reroof an existing building, and no permit was applied for to perform this job. No certified roofer was engaged to do this reroofing, the rubberized compound applied to the roof was improperly applied and the roof started leaking when the first rain came. Workers from Bay City Builders came to the residence several times to attempt to patch the leaks, but the leaks persisted. Ultimately, the owner had to employ a qualified roofing contractor to redo the roof. While Bay City Builders was attempting to stop the leaks, the ceiling over the porch was also ruined and had to be replaced. In his testimony, Respondent admitted that he was the sole qualifying contractor for Bay City Builders, that his function was to give Bay City Builders a price estimate for the work intended, including the ACLF addition, but the owner of Bay City Builders entered into a contract for $5000 less than Respondent's estimate for the ACLF. Respondent also acknowledged that Bay City Builders, acting under Respondent's license, entered into contracts for some 150 jobs, but that Respondent was told or learned of only 60 of these projects. Respondent was paid a fixed fee by Bay City Builders for each permit obtained, and he prepared estimates of cost.
The Issue Whether Respondent's contractor license should be disciplined for alleged violations of Chapters 489 and 455, Florida Statutes.
Findings Of Fact Respondent, James Cooper, was at all times material to this action licensed by the State of Florida as a registered roofing contractor, having been issued license number RC0066905. Mr. Cooper's license is currently classified "Inactive, Issued (09/05/97)." Around March 1, 1996, Marshall Moran was contacted by Julia Jones regarding repairs to the leaky roof on her home located at 209 Cresent Drive, DeFuniak Springs Walton County, Florida. Ms. Jones' home was over one hundred years old with a steep metal roof. The roof she wished repaired was over the enclosed sleeping porch of her house. Over the last ten years, she had various contractors attempt to fix the leak in the sleeping porch roof. These attempts occurred, on average, more than one time per year. The leak always returned. Marshall Moran is an unlicensed and unregistered roofing contractor. Mr. Moran has been a roofing contractor since before the licensure requirements for contractors became law. He elected not to become licensed under those statutes. However, he did have the experience and skills necessary to repair Ms. Jones' roof. Marshall Moran discussed the job with Ms. Jones. Mr. Moran recommended the entire section of the roof be rebuilt and described the anticipated repairs. Ms. Jones would not allow the entire section of roof to be repaired. She thought only the small section where the leak was apparent needed repair. Unknown to Ms. Jones and prior to beginning the work, Mr. Moran contacted Respondent to tell him of Ms. Jones' job and to see if Respondent wanted to do the job. Respondent couldn't do the job with his crew but offered to allow Mr. Moran to "work under his license." Respondent was pursuing a large commercial roofing contract around the same time as the events at issue here. He wanted to keep Moran's crew together in order to be able to complete the large commercial job. He held the crew together by enabling Moran to do the construction at Julia Jones' residence in consideration for taking legal responsibility for the Jones' job. Respondent did not hire Mr. Moran as his employee. Respondent knew Mr. Moran was not registered or certified to practice contracting. He also knew Mr. Moran was well qualified to perform the work on the Jones' job. Respondent admits that he knew that he should not pull permits for anyone, but that he did it just this one time in order to keep the crew together. On March 15, 1996, Respondent obtained City of DeFuniak Springs, Florida, building permit number 1379 for the roof repairs to Ms. Jones' residence. On the application for said building permit, Respondent represented himself (doing business as Cooper Roofing and Repair) as the contractor of record on the aforesaid project. Respondent intended to and did eventually take legal responsibility for the Jones' job. However, he did not supervise Mr. Moran or his crew. Additionally, Ms. Jones was never informed of Respondent's involvement. More importantly, Ms. Jones never contracted with Respondent for either Respondent or his company to perform roof repairs on her home. On March 21, 1996, Mr. Moran provided an estimate for repair of the portion of Ms. Jones' roof she felt needed repair. The estimate bears the name of "AAA Metal Works" and "Marshall Moran." AAA Metal Works was Mr. Moran's company. The estimate does not reference either Respondent or his company. The estimated cost to repair Ms. Jones roof was $2,785. Based on the estimate, Ms. Jones entered into a contract with Mr. Moran and AAA Metal Works to perform the repairs to her roof discussed above. Moran and his crew substantially completed the repairs to Ms. Jones' roof in a few days. However, the roof continued to leak after Moran and his crew ended their work. The continuing leak was not due to any incompetence on the part of Respondent or Moran. Ms. Jones paid for the repairs with two checks made out to AAA Metal Works. The checks were in the amounts of $3,500 and $4,350. Respondent did not receive any of the money for the Jones' job. His only expense was the fee for the building permit. All other expenses were paid for by Mr. Moran. At no time during the formation or performance of the contract with Marshall Moran did Julia Jones have any contact with or knowledge of involvement by Respondent. In fact, Respondent only drove by the job site one time. As indicated, the roof continued to leak. Ms. Jones contacted Mr. Moran on approximately 5-6 occasions notifying him of the continued leaks. Mr. Moran would return to Ms. Jones' home and inspect the problems, but was unable to stop the leaks to Jones' satisfaction. It is not clear whether Mr. Moran kept Respondent informed of these continued service calls. Approximately one year after completion of the initial repairs on Ms. Jones' roof, Respondent received a call from Ms. Jones' tenant and friend, Sharon Jenks, who called posing as a potential new client. Ms. Jenks had gotten Respondent's name from the building permit. Ms. Jenks called Respondent because the house was still leaking approximately one year after the repair was done and intervening visits by Marshall Moran had not fixed the problem. Ms. Jenks arranged for Respondent to visit Ms. Jones' home. Respondent did not recognize the house when he arrived and drove past it. When Ms. Jenks showed Respondent the building permit bearing his name, Respondent showed surprise. He returned the next day with Mr. Moran. Respondent, Mr. Moran, Ms. Jenks and Ms. Jones all met regarding the continued leaking. Respondent and Mr. Moran told Ms. Jones that the metal on the roof was "bad" and needed to be replaced to stop the leaks on the "sleeping porch." Understandably, Ms. Jones did not want to deal any further with Mr. Moran or Respondent and would not permit them to make the recommended necessary repairs. Ms. Jones sued both Respondent and Mr. Moran in a civil action styled: Julia R. Jones v. James K. Cooper and Marshall Moran, Case Number 97-0040-CC, in the County Court of the First Judicial Circuit in and for Walton County, Florida. Following a judge trial, a Final Judgment was entered in favor of Respondent and Mr. Moran on December 9, 1997. Mr. Moran was charged with contracting without a license in violation of Section 489.127, Florida Statutes (1995), in State of Florida v. Marshall Moran, Case Number 97-0549-CF, in the Circuit Court of the First Judicial Circuit in and for Walton County, Florida. That charge was dismissed by Circuit Judge Lewis Lindsey on February 3, 1998.
Recommendation Based upon the findings of fact and conclusions of law, it is, RECOMMENDED: That the Board should find Respondent guilty of violating Chapters 489 and 455, Florida Statutes, and impose an administrative fine of $500.00 on Respondent DONE AND ENTERED this 3rd day of August, 1998, in Tallahassee, Leon County, Florida. DIANE CLEAVINGER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of August, 1998. COPIES FURNISHED: John O. Williams, Esquire Maureen L. Holz, Esquire Willams and Holz, P.A. 458 West Tennessee Street Tallahassee, Florida 32301 J. LaDon Dewrell, Esquire 207 Florida Place, Southeast Ft. Walton Beach, Florida 32549 Rodney Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
The Issue The issue presented is whether Respondent is guilty of the allegations contained in the Administrative Complaint filed against him, and, if so, what disciplinary action should be taken against him, if any.
Findings Of Fact At all times material hereto, Respondent has been a certified roofing contractor in the State of Florida, having been issued license numbered CC C050454 by the Florida Construction Industry Licensing Board. At all times material hereto, Respondent has been the licensed qualifying agent for Hi-Tech Roofing, USA, Inc. In order to repair hurricane damage to her roof, Alice Young asked a friend to recommend someone to do the work. Her friend recommended Roy West who had done work for her and for a friend of hers. In early March 1993 Young contacted West. Young entered into a contract with West for West to repair the damage, including removal of tile, replacement of bad decking, and reinstallation of roofing felt and tile. Since the proposal form used by West was blank as to the name of the company involved, Young asked West the name of his company. West wrote Hi Teck Roofing on the proposal form. The contract price was $11,500, with payment to be made in three increments. West told Young to make her checks payable to him personally. He also told her he was from Arkansas and that he would be going back and forth between Arkansas and Miami. West began the work on or about March 17, 1993. Young gave him a check on that date for $3,833 and a second check in the same amount on March 23. He also received a partial payment of $1200 toward the balance on April 23, 1993. All three checks were made payable to Roy West and reflect that they were cashed by him using an Arkansas driver's license as identification. On March 17, 1993, Young signed a partially-completed application for a permit from the Metropolitan Dade County Building & Zoning Department for the contracted work. The application as filed with Metropolitan Dade County lists Hi-Tech Roofing USA as the contractor and Respondent as the qualifier. The application as filed purports to bear the signature of Respondent as qualifier for Hi-Tech Roofing, USA, Inc., and is dated April 1, 1993. His signature was purportedly witnessed and notarized by Eyder C. Macaya, his former secretary. Metropolitan Dade County issued the permit through Respondent's licensure for the contracted work. When the job neared completion, West requested payment in full. However, Young refused to make the final payment, alleging that the peak in the roof line was uneven, and dismissed him from the job. Before West left, Young demanded to see the permit for the work, and he showed it to her. Young contacted her attorney, who informed her that West was not licensed and advised her to file a complaint with Dade County. In 1995, two years later, Young filed her complaint with Dade County. She was contacted by an enforcement officer for the County and provided him with her documentation. The County contacted Respondent, and Respondent contacted Young. Respondent inquired about her problem with West and about the project. Respondent offered to renew the original permit and complete the roof, including repairing a leak and the peak in the roof, for the balance of the price contracted between Young and West. Respondent and Young executed a contract on May 7, 1996, and Respondent commenced his repairs on the roof. After Respondent had completed his work, Young still complained about the peak in the roof. One portion of the roof over the patio continued to leak. Respondent hired at a cost of $250 a special inspector to verify that the work was completed according to Code. Young refused to pay Respondent any money pursuant to the contract she had with him or for any of the work he performed because she still was not satisfied with the roof peak. Although Respondent filed a lien against her property for $2,634 (the balance of Young's contract with West and the full price of the contract between Young and Respondent), Respondent never enforced that lien. At no time material hereto was West licensed, registered, or otherwise qualified to perform contracting in the State of Florida. At no time material hereto was West an employee of Hi-Tech Roofing, USA. Respondent did not sign the permit application used by West to obtain the permit to perform Young's roof repairs. Further, Respondent did not authorize West to perform roof repairs to Young's residence on behalf of Respondent or on behalf of Hi-Tech Roofing, USA, Inc. Respondent did not have a business relationship with West at any time material hereto.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding Respondent not guilty and dismissing the Administrative Complaint filed against him in this cause. DONE AND ENTERED this 3rd day of March, 1998, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of March, 1998. COPIES FURNISHED: Gail Hoge, Esquire Department of Business and Professional Regulation Northwood Centre, Suite 60 1940 North Monroe Street Tallahassee, Florida 32399-0792 Lawrence A. Mizne, pro se 801 South 21st Avenue Hollywood, Florida 33020 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Rodney Hurst, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467
The Issue The issues that were presented for disposition in the above-styled cases were whether Respondent committed certain alleged violations of Chapter 489, F.S. and if so what discipline is appropriate. As stated below, the parties stipulated to the violations, leaving only the issue of discipline to be resolved.
Findings Of Fact Gordon Lee Cederberg is, and has been at all times material hereto, a licensed registered roofing contractor, having been issued license number RC 0051346, by the State of Florida. At all times material Respondent was the licensed qualifier for Allied American Roofing Company and was responsible in such capacity for supervising its contracting activities. Allied American Roofing Company was dissolved on November 4, 1988. Stipulated Violations By stipulation, Respondent has admitted the following allegations of the amended administrative complaint in DOAH #91-8319: 3. CASE NO. 0106373 COUNT THREE Respondent d/b/a Allied American Roofing contracted with Michael Roberts on April 4, 1988 to reroof a home located at 530 Mason Street, Apopka, Florida. The contract price was $942.80 and was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the City of Apopka Building Department. By the reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a municipality, to wit, Apopka, Florida, by failing to obtain a permit and inspection is as required by that municipality. 4. CASE NO. 0107766 COUNT FOUR Respondent's license was under suspension by the Florida Construction Industry Licensing Board between August 10, 1988, and March 3, 1989. Respondent d/b/a Allied American Roofing contracted with Nancy Wiegner on September 22, 1988, to reroof a home located at 15 Kentucky Street, St. Cloud, Florida. The contract price was $1,600.00 and it was paid in full. Respondent commenced work under the contract but failed to obtain a permit prior to commencing such work from the City of St. Cloud, Florida, and the municipality issued a stop order on the job. Respondent further engaged in contracting in a municipality where he had not registered. By reason of the foregoing allegation, Respondent has violated Section 489.129(1)(j), F.S., in that he failed in a material respect to comply with the provisions of Section 489.117(2), F.S., in that he engaged in contracting in a municipality, to wit, St. Cloud, Florida, where he had failed to comply with the local licensing requirements for the type of work covered by his registration. COUNT FIVE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that Respondent willfully deliberately disregarded and violated the applicable building code of a municipality, to wit, St. Cloud, Florida by failing to secure a permit as required by that municipality. COUNT SIX By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT SEVEN By reason of the foregoing allegations, Respondent has violated 489.129(1)(m), F.S., by committing gross negligence, misconduct, and/or incompetency in the practice of contracting. 8. CASE NO. 0112740 COUNT EIGHT Respondent d/b/a Allied American Roofing contracted with Emma Smith on October 3, 1988 to reroof a home at 1911 Mullet Lake Park Road, Geneva, Seminole County, Florida. The contract price was $4,100.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to properly construct a watertight roof which continued to leak and caused damage to the home. Respondent has failed to honor the five (5) year labor and twenty (20) year material warranty that was part of the said contract, although he was requested to do so. By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(n), F.S., in that the Respondent proceeded on a job without obtaining an applicable local building department permit and inspections. COUNT NINE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT TEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act of gross negligence, incompetency and/or misconduct in the practice of contracting by failing to honor the written warranty described in paragraph twenty-six above. COUNT ELEVEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 12. CASE NO. 89-001674 COUNT TWELVE Respondent d/b/a Allied American Roofing Company contracted with Thelma Beck to reroof a home at 3910 Pineland Ridge Road, Orlando, Orange County, Florida on January 26, 1989 for a price of $2,270.00. Respondent accepted a $100.00 deposit for said job; the work was not begun and the $100.00 deposit was returned to Mrs. Beck. By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT THIRTEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. COUNT FOURTEEN Respondent d/b/a Allied American Roofing contracted with Morris Remmers to reroof a home at 8719 Butternut Boulevard, Orlando, Orange County, Florida, on or about February 23, 1989. The contract price was $2,870.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Orange County Building Department. By reason of the foregoing allegation, Respondent is guilty of violating Section 489.129(1)(n), F.S., in that Respondent proceeded in a job without obtaining an applicable local building department permit and inspections. COUNT FIFTEEN By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT SIXTEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 17. CASE NO. 89-008737 COUNT SEVENTEEN Respondent d/b/a Allied American Roofing contracted with Robert Speirs to reroof a dwelling at 2467 Fieldingwood Road, Maitland, Seminole County, Florida on or about October 14, 1988. The contract price was $3,600.00. Respondent proceeded to work the job but failed to obtain a permit and secure required inspections from the Seminole County Building Department. Respondent failed to properly construct a water tight roof which continued to leak. Respondent failed to honor the three (3) year labor and twenty (20) year material warranty that was part of the contract although he was requested to do so. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(n), F.S., in that Respondent proceeded on a job without obtaining an applicable local building department permit and inspections. COUNT EIGHTEEN By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while license was suspended. COUNT NINETEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act of gross negligence, incompetency and/or misconduct in the practice of contracting by failing to honor his written warranty described in paragraphs forty-seven above. COUNTY TWENTY By reason of the aforesaid allegations, Respondent is guilty of violating 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 21. CASE NO. 109636 COUNT TWENTY-ONE Respondent d/b/a Allied American Roofing Company contracted with Daniel J. Doherty to reroof a home at 225 Dover Wood Road, Fern Park, Seminole County, Florida on October 2, 1988, for the contract price of $3,590.00 which was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to construct a watertight roof, which contributed to water damage to the interior of Mr. Doherty's home. Respondent failed to honor the five (5) year labor and twenty (20) year material warranty that was part of the contract, although he was requested to do so. By the reason of the foregoing allegations, Respondent has violated Section 489.129(1)(n), F.S., by proceeding on the job without obtaining a local building department permit and inspections. COUNT TWENTY-TWO By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S. by engaging in contracting while his license was suspended. COUNT TWENTY-THREE By reason of the foregoing allegations, Respondent has violated 489.129(1)(m), F.S., by committing gross negligence, misconduct, and/or incompetency in the practice of contracting by failing to honor his warranty as described in paragraph fifty-six above. COUNT TWENTY-FOUR By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. COUNT TWENTY-SEVEN Respondent d/b/a Allied American Roofing contracted with Gloria Viruet to reroof a home at 3010 (renumbered to 3007) Northwood Blvd., Orlando, Orange County, Florida on June 7, 1988. The contract price was $3,500.00. Respondent proceeded to complete the job without receiving a permit and securing required inspections from the Orange County Building Department. The Respondent failed to properly construct a watertight roof and a leak developed after construction. Respondent failed to honor the five (5) year labor and twenty (20) material warranty that was part of the said contract, although he has been requested to do so. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(d), F.S., in that Respondent willfully and deliberately disregarded and violated the applicable building code of a County, to wit, Orange County, Florida by failing to obtain a permit and inspections as required by that County. COUNT TWENTY-EIGHT By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting, by failing to honor his written warranty described in paragraphs seventy. COUNTY TWENTY-NINE By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 28. CASE NO. 0108263 COUNT THIRTY Respondent d/b/a Allied American Roofing Company contracted with John E. Hultin to reroof a home located at 3610 Lakeview, Apopka, Florida on November 7, 1987. The contract price was $2,900.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to properly install a roof covering, violating Section 103 of the Standard Building Code, 1985 Standard of Installation of Roofing Coverings adopted by Seminole County and Seminole County Ordinance Section 40.51. The contract provided for a five (5) year labor warranty and a twenty (20) year material warranty. Respondent made several attempts to correct defects but has not fulfilled his warranty as the roof continued to leak. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a county, to wit, Seminole County, Florida by failing to obtain a permit and inspections as required by that county. COUNT THIRTY-ONE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a county, to wit, Seminole County, Florida by installing the above described roof in a grossly negligent manner and in a manner which violated Section 103 of the Standard Building Code, 1985 Standard of Installation of Roof Covering, adopted by Seminole County and Seminole Ordinances Section 40.51. COUNT THIRTY-TWO By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practices of contracting by failing to honor his written warranty described above. COUNT THIRTY-THREE By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. FACTS RELATED TO RESPONDENT'S PROPOSED MITIGATION Respondent has been engaged in the practice of roofing contracting for over twenty years. Prior to moving to Florida in 1983 his company worked in Michigan, Ohio and Indiana on large commercial jobs. In 1983 he was employed by the Disney company to do commercial roofing work. After licensure in Florida, Cederberg continued with large public works and commercial jobs in Florida. Sometime around 1988, after a disastrous reversal of fortune, the company filed for bankruptcy. Although he was utterly unfamiliar with the practice of residential roof contracting, particularly the demanding supervision involved, Gordon Cederberg began doing residential work. Around this same time Cederberg's wife left him and he was given custody of three children, ages three, six, and nine. He was emotionally distraught and obtained counseling and financial and other support from his church group. Cederberg's roofing contractor's license was suspended by the Construction Industry Licensing Board from August 1, 1988 to March 1, 1989, during which time he continued to work, due to financial pressures. Warranty work was not done due to his financial and emotional straits. According to Cederberg and his witnesses, he is in the process now of turning his life around. He operates on a smaller scale and is able to handle the work. He has one employee and has been able to avoid new complaints. He is still financially unable to provide restitution to the customers previously harmed.
Recommendation Based on the foregoing it is hereby, RECOMMENDED: that the parties' stipulation with regard to dismissals and admissions described above be accepted by the Board and that the following penalty be imposed: a) 1000.00 fine; one year suspension, with this penalty suspended during, and removed upon successful completion of, probation with an appropriate timetable for restitution and the requirement that appropriate continuing education courses are completed; and payment of costs of investigation and prosecution. DONE and ENTERED this 31st day of December, 1992, at Tallahassee, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of December, 1992. COPIES FURNISHED: Jack McRay, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Daniel O'Brien, Executive Director Construction Industry Licensing Board P.O. Box 2 Jacksonville, FL 32202 William S. Cummins, Esquire Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Jack Snow, Esquire 407 Wekiva Spings Road, Suite 229 Longwood, FL 32779
Findings Of Fact At all times material hereto, Respondent has been registered as a specialty contractor in Florida, having been issued license number RX-00492l2. He has also been, and continues to be, the qualifying agent for Stretch and Seal, Inc. On July 10, 1986, Emmanuel E. Cabral entered into a contract with Stretch and Seal, Inc., for cleaning of the roof on his residence in Inverness, Florida, application of a base coat and finishing coat of Stretch and Seal on the entire roof (approximately 1,518 square feet), coating of all vents and roof edges, and coating where his flat roof meets the shingle portion of his roof. The total contract price was $1,600. Richard J. Cummings executed this contract on behalf of Stretch and Seal, as "authorized signature." Cummings is not licensed by the Construction Industry Licensing Board. The Cabral contract provided a ten year warranty, and specified that, "All material is guaranteed. . . . All work to be completed in a workmanlike manner according to standard practices." The warranty was signed by Respondent, as President of Stretch and Seal, Inc. Cabral made three payments in July and August, 1986 in the total amount of $1,600 for work performed on his roof pursuant to his contract with Stretch and Seal, Inc. These payments were by checks payable to "John P. Terranova." Cummings had instructed the Cabrals to make the payments directly to Respondent. At hearing, Respondent admitted receiving and cashing these checks. On August 12, 1986, Emmanuel Cabral executed a Customer Work Acceptance and Job Rating Form which indicates he considered the work performed on his roof to be "satisfactory." This is the lowest rating shown on the form other than a general category marked "other." The Cabrals responded to a newspaper ad about Stretch and Seal which featured Respondent, and which stated the product "protects roofs" and "stops most annoying leaks." The toll free phone number in the ad is the same one that is printed on the Stretch and Seal contract which Mr. Cabral eventually signed. When Richard Cummings came to their house to explain the product, he presented the Cabrals with a flyer describing Stretch and Seal as a "new roof sealer" that "stops leaks and protects your roof." At the time they contracted with Stretch and Seal, Inc., the Cabrals' roof did not leak. Mrs. Anna Cabral testified that they were interested in insulating their roof to help the house stay cooler. The newspaper advertisement and flyer that Cummings gave them represented that the product reduces energy costs, reflects the sun's rays and insulates, plus reduces noise from wind and rain, and Mr. Cabral contracted with Stretch and Seal, Inc., based upon these representations. The Cabrals' roof began to leak in October, 1986 and additional leaks continued to appear throughout their house through November, 1986. Mrs. Cabral made repeated efforts to contact Respondent or Cummings, and although workmen did appear at their house on one occasion, the Cabrals were not home, and therefore no repair work was done. Respondent failed to honor the warranty given on this job in any way. Eventually, the Cabrals had to have their roof entirely redone by another roofing company, at a cost of $2,300. No local permit was obtained for the work performed on the Cabrals' roof, although a permit is required by the applicable local building code for any improvements to property valued at more than $300, except painting. Respondent presented two defenses. First, he maintained that the product applied to the Cabral roof is simply a paint, and not a sealant, insulator, or weatherproofing agent. Representations about the product made by Respondent in newspaper ads and by his authorized agent to customers do not support Respondent's assertion at hearing. Competent substantial evidence was not presented at hearing by Respondent to rebut the clear and convincing evidence presented by Petitioner that the product applied to the Cabral roof was represented to be a sealant, insulator and weatherproofing agent. Second, Respondent maintained that he had sold the Stretch and Seal "area distributorship" to Cummings prior to this job with the Cabrals. Therefore, he argued he was not responsible for the work that Cummings performed. While Cummings did the actual work on the Cabral roof, and signed the contract with Mr. Cabral, Respondent was, and still is the qualifying agent of Stretch and Seal, Inc. It was Respondent who signed the Cabrals' warranty, and received and cashed their checks in payment for this job. The distributorship agreement between Respondent and Cummings, executed in December, 1985, specifically recites and acknowledges Cummings' responsibilities under the agreement in consideration for Respondent "using his licenses." Thus, it is clear that Stretch and Seal, Inc., continued to do business and to operate under Respondent's license, with him as qualifying agent, even after the distributorship agreement was executed.
Recommendation Based upon the foregoing, it is recommended that the Construction Industry Licensing Board enter a Final Order revoking Respondent's specialty contractor registration for violating Sections 489.105(4), 489.115(1)(b), 489.117(2), 489.119, and 489.129(1)(d),(j) and (m), Florida Statutes. DONE AND ENTERED this 5th day of February, 1988, in Tallahassee, Florida. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 5th day of February, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-4010 Rulings on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact 1. Rejected as unnecessary. Adopted in Findings of Fact 2-4. 4-5. Adopted in Finding of Fact 6. 6. Adopted in Finding of Fact 7. 7-8. Adopted in Findings of Fact 3, 8. Acted in part in Finding of Fact 9, but otherwise Rejected as not based upon competent substantial evidence. Adopted in part in Finding of Fact 8, but otherwise Rejected as not based upon competent substantial evidence. COPIES FURNISHED: Lee Sims, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 John P. Terranova 3 Birdie Lane Palm Harbour, Florida 33528 Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 William O'Neil General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue Whether Respondent, Glenn V. Curry, committed the offenses alleged in the Administrative Complaint and, if so, what discipline should be imposed against Respondent's roofing contractor's license.
Findings Of Fact At all times pertinent to this proceeding, Respondent, Glenn V. Curry, was a certified roofing contractor having been issued license C-3810. During times material hereto, Respondent was the qualifying contractor for Economic Roofing Company, 2538 Surinam Court, Holiday, Florida. On or about December 27, 1995, Connie Socash, an investigator with the Pinellas County Construction Licensing Board, observed two individuals performing roofing work on the structure located at 2024 Cleveland Street in Pinellas County, Florida. Adjacent to the Cleveland Street property was a truck from which the individuals were working. Affixed to the truck was a magnetic sign with the words "Economic Roofing" printed on it. When approached by Ms. Socash, the two people performing the roofing work stated that they were subcontractors for Economic Roofing. One of the individuals performing the roofing work identified herself as Bonnie Sargent. However, neither of the individuals provided Investigator Socash with a roofing contractor's license or license number. After determining that Petitioner had not issued a roofing contractor's license to Bonnie Sargent, Investigator Socash issued a citation to the person identifying herself as Bonnie Sargent. The citation was issued to Ms. Sargent for subcontracting and performing "roofing work without a competency license as required by law." The citation, which was signed by Ms. Sargent, listed the following two options that were available to her: (1) pay a fine of $125.00 within a specified time period; or (2) appear at the Pinellas County Misdemeanor Courthouse on January 19,1996. Ms. Sargent chose the first option and paid the fine of $125.00 on or about January 9, 1996. After issuing the citation to Bonnie Sargent, Investigator Socash contacted Respondent regarding the Cleveland Street roofing project. Respondent refused to cooperate with Investigator Socash and failed to provide her with any information regarding the relationship of Bonnie Sargent to Economic Roofing. Prior to this case, Respondent has not been the subject of any disciplinary action by the Pinellas County Construction Licensing Board.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is recommended that the Pinellas County Construction Licensing Board enter a Final Order: Finding Respondent, Glenn V. Curry, guilty of violating Section 489.129 (1) (e), Florida Statutes, and Chapter 89-504, Section 24 (2) (d), (e), (j), and (m), Laws of Florida as alleged in the Administrative Complaint. Imposing an administrative fine of $750.00. Suspending Respondent's roofing contractor's certificate for one year. Such suspension may be stayed subject to terms and conditions prescribed by the Pinellas County Construction Licensing Board. DONE and ENTERED this 27th day of August 1996, in Tallahassee, Florida. CAROLYN S. HOLIFIELD Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of August, 1996. COPIES FURNISHED: William J. Owens Executive Director Pinellas County Construction Licensing Board 11701 Ulmerton Road Largo, Florida 34643-5116 Glenn V. Curry 2538 Surinam Court Holiday, Florida 34691 Howard Bernstein, Esquire County Attorney's Office 315 Court Street Clearwater, Florida 34616-5165
The Issue The issue presented is whether Respondent is guilty of the allegations contained in the Administrative Complaints filed against him, and, if so, what disciplinary action should be taken against him, if any.
Findings Of Fact At all times material hereto, Respondent was licensed as a certified general contractor in the State of Florida, having been issued license number CG C000942. At all times material hereto, Respondent was the licensed qualifying agent for Twenty First Century Construction Management, Inc. On September 5, 1992, Willie Janes, doing business as Janes Roofing Contractor, entered into a contract with Debourah Benjamin to replace the roof at her residence located in Margate, Florida. The contract price was $6,748, but Janes later agreed to do the work for $6,248, which was all Benjamin's insurance company would pay. On November 26, 1992, Benjamin gave Janes a check in the amount of $2,200 as a down payment on the work. The check was payable to Willie Janes. At the time Janes entered into his contract with Benjamin, his local roofing license had expired, and he was not licensed as a roofing contractor by the State of Florida. Respondent applied for the roofing permit for the Benjamin job. The City of Margate Building Department issued permit number 11525-R by and through Respondent's licensure on December 3, 1992. Janes commenced work on the Benjamin project on November 26, 1992. On December 8, 1992, the City of Margate Building Department performed a tin tag inspection of the work done by Janes. The work failed the inspection that day but passed two days later. On January 11, 1993, Benjamin issued a second check, in the amount of $2,300, payable to Willie Janes, for the purchase of roof tile. Janes did not order and did not pay for the roof tile until approximately June 25, 1993. The tile was delivered to Benjamin's residence a few days later and placed on the roof for installation but Janes did not return to the project site. The amount of tile delivered to Benjamin's residence was not sufficient to cover the entire roof. On approximately June 25, 1993, Benjamin noticed for the first time that the name of the company on the permit posted at her residence was Twenty First Century Construction. Neither the Respondent nor Twenty First Century Construction Management, Inc., had any involvement in Benjamin's project other than obtaining the building permit. Benjamin contacted the building department which issued the permit and was referred to Petitioner. An employee of Petitioner advised her that the qualifier for Twenty First Century Construction was Respondent. Benjamin had never heard of Respondent at the time. Benjamin contacted Respondent by telephone several times about completing the work commenced by Janes. Respondent repeatedly promised to finish the roof but never did. Benjamin next contacted the Margate Police Department to report the activities of Respondent and Janes. On September 3, 1993, Officer Liberatori of the Margate Police Department spoke to Respondent by telephone, and Respondent promised to complete the work within 30 days. However, Respondent did nothing to complete the work. The last inspection performed on the Benjamin project under permit number 11525-R was the dry-in inspection performed on February 8, 1993. Permit number 11525-R expired on July 8, 1993. In December 1993 Benjamin had the project completed by another contractor. On November 16, 1992, Delos and Barbara Johnson entered into a written contract with Respondent to remodel a porch enclosure at the Johnson residence in Coral Springs, Florida, for a contract price of $10,250. The Johnsons made three payments to Respondent: $1,000 on September 28, 1992; $5,000 on November 17, 1992; and $3,000 on December 2, 1992. On October 12, 1992, Respondent applied for a building permit from the City of Coral Springs for the Johnson remodeling. The City of Coral Springs issued permit number 920004472 by and through Respondent's licensure on November 30, 1992. When the City of Coral Springs issues a building permit, it provides with the permit a list of the required inspections. Respondent proceeded with the construction until December 2, 1992, when he received the third payment. Thereafter, Respondent ceased all construction activities on the Johnson project. Shortly thereafter, the Johnsons learned from the Coral Springs Building Department that their remodeling project had failed to pass the required inspections. When they confronted Respondent regarding his failure to obtain the required inspections, he represented to them that he had made a videotape of all the work he performed, that he himself was a building inspector and could inspect his work, and that he could get a special inspector to inspect the project from the videotape. At no time material hereto was Respondent a certified building inspector. Videotaping a construction project in lieu of obtaining required inspections is not permitted under the South Florida Building Code nor is it permitted by the City of Coral Springs Building Department. Of the required nine inspections for the project, Respondent only obtained three inspections. Of those three, he only passed two. Respondent's failure to obtain the required inspections constitutes a violation of the South Florida Building Code, the minimum standard required for any type of building construction in South Florida. A contractor's failure to adhere to that minimum standard causes harm to the public from deteriorating construction. The Johnsons and the City of Coral Springs Building Department gave Respondent an opportunity to obtain and pass the required inspections and complete the construction project. When Respondent declined to do so, the attorney hired by the Johnsons discharged Respondent. The Johnsons had paid approximately 90 percent of the money they had saved for the porch enclosure to Respondent, and they could not afford to continue with the construction project using the services of another contractor until November 1994. Rick Hugins of Hugins Construction Corp., the remedial contractor, needed to pass the required inspections that Respondent had neglected in order to be permitted by the City of Coral Springs Building Department to complete the project. Work that needed to be inspected was concealed by subsequently- installed construction materials which had to be removed in order that the required inspections could be performed. Numerous code violations were discovered in the concealed work. The work performed by Respondent was below industry standards. The Johnsons paid Hugins Construction Corp. $10,000 to correct the code violations, to pass the required inspections Respondent had missed, and to complete the project. Hugins completed the project by January 23, 1995. Respondent has been previously disciplined by Petitioner on charges of assisting unlicensed activity and of failing to notify Petitioner of his current mailing address and telephone number. That discipline included the payment of an administrative fine and an assessment of costs associated with that investigation and prosecution.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding Respondent guilty of the allegations contained in Counts I and III of the Administrative Complaint filed against him in DOAH Case No. 97- 1365, finding Respondent guilty of the allegations contained in Counts I and II of the Administrative Complaint filed against him in DOAH Case No. 97-1368, requiring Respondent to pay restitution to the Johnsons, assessing against Respondent the costs of investigation and prosecution through the time the final order is entered, and revoking Respondent's certification as a general contractor in the State of Florida. DONE AND ENTERED this 10th day of July, 1998, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 10th day of July, 1998. COPIES FURNISHED: Dorota Trzeciecka, Esquire Department of Business and Professional Regulation 401 Northwest Second Avenue, No. N-607 Miami, Florida 33128 Edward Conrad Sawyer, Esquire 1413 North 58th Avenue Hollywood, Florida 33021 Rodney Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
The Issue Whether Respondent's registered roofing contractor's license should he revoked, suspended or otherwise disciplined based on charges that he violated Ch. 455, Florida Statutes (1979), by (1) abandoning a construction project; making a misleading, deceptive or untrue representation in the practice of his profession; (3) violating local building codes in two instances; and (4) engaging in the business of contracting in a county or municipality without first complying with local licensing requirements.
Findings Of Fact At all times material hereto, respondent held registered roofing contractor's license, number RC 0033215, issued by the State of Florida. The license has been in a delinquent status since July 1, 1981. (Petitioner's Exhibit 1). Between October 1, 1979, and September 30, 1980, respondent held an occupational license issued by the County of Indian River, Florida, which enabled him to engage in the business of roofing contracting in that county. However, this occupational license expired on September 30, 1980. (Petitioner's Composite Exhibit 9). In February, 1981, respondent entered into a verbal agreement with Ezra Grant to repair, for compensation, all leaks in the front and rear sections of the roof on Grant's home, which was located in Sebastian, Florida. (Testimony of Grant). When respondent and Grant entered into this verbal agreement, respondent gave Grant one of his calling cards. On the face of the calling card, in the lower right corner, was written "licensed and insured." (Petitioner's Exhibit 4; Testimony of Grant). At all time material hereto, respondent was not licensed to engage in the business of roofing contracting in the City of Sebastian, Florida. (Petitioner's Exhibit 5). Pursuant to the agreement, respondent performed roof repairs on Grant's home. (Testimony of Grant). Respondent failed to obtain a permit to perform such roof repairs in violation of Section 105.1, Standard Building Code, as adopted by the City of Sebastian, Florida in Section 7-16, Article II, Sebastian Code of Ordinances. (Petitioner's Exhibits 6 and 8a and b). On February 19, 1981, respondent submitted a bill in the amount of $800.00 to Grant for the roof repairs. The bill described the work performed and stated that the "work is guaranteed for 1 year." (Petitioner's Exhibit 2; Testimony of Grant). On February 20, 1981, Grant paid respondent, in full, for the described roof repairs. (Petitioner's Exhibit 3). Approximately two weeks after respondent performed the roof repairs, the roof over the rear portion of Grant's home began to leak, again, in the area where it was repaired. (Testimony of Grant). Respondent returned to Grant's home, on two occasions1 after the discovery of continuing leakage in the roof over the rear portion of Grant's home. However, respondent did not perform roof repairs on either occasion. On the first occasion, he merely removed equipment which he had left at Grant's home. (Testimony of Grant). After Grant complained to petitioner Department of Professional Regulation, respondent returned a second time. He inspected the rear portion of Grant's roof, removed two layers of slate from the roof, and tested it by pouring water over it. Although this test revealed that Grant's roof still leaked, Grant made no effort to repair the leakage. (Testimony of Grant). Arthur Mayer, then the Building Official for the City of Sebastian, observed respondent removing the slate from the roof. He instructed respondent that, upon finishing the work, he should go to the Sebastian City Hall and apply for a roofer's license and a permit for the roof repairs already performed on Grant's home. Respondent promised to comply. (Testimony of Mayer). But, despite his promise, he failed to apply for and obtain a license to engage in the business of roofing contracting in the City of Sebastian, Florida. He also failed to apply for and obtain a roof permit, and pay the proper late fees, as required by Section 107.2, Standard Building Code, as adopted by the City of Sebastian, Florida, in Section 7-16, Article II, Sebastian Code of Ordinances. (Testimony of Mayer; Petitioner's Exhibits 6, 8a and c). Grant, eventually, had his roof repaired by another contractor at a cost of $150.00. (Testimony of Grant).
Recommendation Based on the foregoing, it is RECOMMENDED: That respondent's registered roofing contractor's license be revoked. DONE AND ORDERED this 28th day of February, 1983, in Tallahassee, Florida. R. L. CALEEN, JR. Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 28th day of February, 1983. COPIES FURNISHED: Stephanie A. Daniel, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Jerry E. Smith Route 1, Box 111B Fellsmere, Florida 32948 James Linnan, Executive Director Construction Industry Licensing Board P. O. Box 2 Jacksonville, Florida 32202
The Issue The issues in this case are whether Respondent, Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., committed the offenses alleged in a four-count Administrative Complaint filed with Petitioner, the Department of Business and Professional Regulation, on January 4, 2008, and, if so, what penalty should be imposed.
Findings Of Fact Petitioner, the Department of Business and Professional Regulation (hereinafter referred to as the "Department"), is the agency of the State of Florida charged with the responsibility for, among other things, the licensure of individuals who wish to engage in contracting in the State of Florida; and the investigation and prosecution of complaints against individuals who have been so licensed. See Chs. 455 and 489, Fla. Stat. Respondent, Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., is and has been at all times material hereto a certified roofing contractor in Florida, having been issued license number CCC 1326506 by the Construction Industry Licensing Board (hereinafter referred to as the “Board”). At all times material hereto, the status of his license has been "Current, Active." At all times material, Mr. Ringold was certified as doing business as Alpha Restoration, Inc. (hereinafter referred to as "Alpha"), a Florida corporation. At the times material, Mr. Ringold was the qualifying agent for Alpha, which possesses a certificate of authority as a contractor qualified business in Florida, license number QB 40272. Alpha’s license was issued May 5, 2005, and it is scheduled to expire August 31, 2010. On or about November 7, 2005, Alpha, through its employee Harry Youdell, met with Jose Fons at Mr. Fons’ residence located at 9922 Southwest 2nd Terrace, Miami, Florida (hereinafter referred to as the “Residence”), to inspect the roof on the Residence. Mr. Fons had not been successful in obtaining approval from his insurance company for replacement of the hurricane-damaged roof. Alpha represented that it would assist Mr. Fons in negotiating with his insurance company to obtain approval for replacement of the roof, which Mr. Fons authorized, in writing, Alpha to do. On January 15, 2006, Mr. Fons and Alpha entered into a written agreement (hereinafter referred to as the “Contract”) whereby Alpha agreed to install a metal tile roof on the Residence in exchange for payment of $27,187.02, with possible increases for “additional payments & supplements,” from Mr. Fons. The Contract provided for a 50 percent material deposit to be paid to Alpha. By check dated January 15, 2006, Mr. Fons paid the 50 percent deposit totaling $13,600.00 to Alpha. At the time the Contract was entered into, Alpha told Mr. Fons that a permit would be applied for the following week and that construction would commence in February. Although there was unsubstantiated hearsay that Mr. Fons was informed that the metal tile roof Mr. Fons was purchasing had not been approved for use in Miami-Dade County, Mr. Fons credibly denied being so informed. The credible, non-hearsay evidence supports a finding that Mr. Fons was not immediately informed that metal tile roofs were not authorized in Miami-Dade County. Despite not providing written or verbal authorization to Alpha to wait more than 30 days after execution of the Contract to apply for the permit for the roof work, no permit was applied for by Alpha for the Residence roof work within 30 days after January 15, 2006. Nor did Alpha commence work of any kind on the project in January or February 2006. During the first week of March, having heard nothing more from Alpha, Mr. Fons called Alpha and inquired about the status of the project. Mr. Fons was told by Mr. Youdell that the metal tile roof had not been approved by the Miami-Dade Building Department (hereinafter referred to as the “Building Department”). Mr. Youdell told Mr. Fons it would take another 30 days to obtain a permit. As of April 2006, Alpha had not commenced work or contacted Mr. Fons. Therefore, Mr. Fons called and spoke to Mr. Youdell about the status of the project. Mr. Fons was again told that the metal tile roof had not been approved and that testing of the roof would take another 30 days. In fact, Alpha had not made application for any permit for the Residence roof job through April 2006. On May 11, 2006, approximately 114 days after receiving Mr. Fons’ deposit, Alpha finally submitted an application for the permit with the Building Department. The application was designated C2006169450 by the Building Department. In May 2006, Mr. Fons again contacted Alpha to inquire about the project, since no work had been started and he had not heard from Alpha. For the third time, Alpha told Mr. Fons that the roof had not gained approval from the Building Department and that another 30 days was needed. In June 2006, Mr. Fons again contacted Alpha. Work on his roof had not started and he had not heard from Alpha. Not surprisingly, Mr. Fons was told for the fourth time that the roof had not gained approval and there would be another 30-day delay. Mr. Fons, who was becoming frustrated with the delay, visited the Building Department and inquired about the project. He learned that Alpha had not applied for a permit until May 2006 and was told that the Building Department had “denied” it on May 16, 2006. Mr. Fons was not told by the Building Department that, despite the “denial,” the permit application remained open. By July 2006, Alpha had still not commenced work. Therefore, Mr. Fons contacted Alpha and requested a meeting to discuss alternatives to the metal tile roof. Obviously, Mr. Fons was aware that metal tile roofs were not approved for use in Miami-Dade County since entering into the Contract. While no work had commenced from January 15, 2006, when the written agreement was entered into and the deposit was made, through July 2006, Mr. Fons effectively agreed to wait for Alpha to attempt to gain approval for the metal tile roof from the Building Department. Having obtained Mr. Fons’ approval, Alpha could not have commenced work on the project through July 2006. On July 17, 2006, Alpha, through Mr. Youdell, met with Mr. Fons at the Residence. Because of the delays that had been caused by the failure of Alpha to gain approval of the metal tile roof from the Building Department and with assurances that the contract price would be the same, Mr. Fons agreed to accept, and Alpha agreed to provide, a tile roof. Alpha represented to Mr. Fons that the tile roofing material was in-stock, that a permit would be obtained within a week, and that construction would commence by mid-August 2006. Between July 25, 2006, approximately a week after the July 17, 2006, meeting, and August 7, 2006, Mr. Fons monitored the Building Department’s web-site to see if Alpha had applied for a permit for the tile roof. When there was no indication that the permit had been applied for, Mr. Fons called Alpha on August 8, 2006. Mr. Youdell told him that the permit had been applied for and it had not appeared in the computer system because the Building Department was backlogged. Mr. Youdell told Mr. Fons that Alpha would be at the Residence in ten days to at least clean up debris. As of August 18, 2006, no new permit had been applied for and no one from Alpha had been to the Residence. Consequently, Mr. Fons wrote and delivered a letter by facsimile addressed to Mr. Ringold, stating, in part, the following: After months of dealing with you, this is my formal request for a full refund of $13,600 paid to you January 15, 2006, with my personal check #6408. Said amount was a deposit for the contract for the replacement of the roof at my residence located at 922 SW 2 Terrace, Miami, FL. As you are aware of, Florida Statutes 489.126 demands that you apply for the necessary permits within 30 days after the initial payment (my payment to you on 1-15- 06 $13,600). Please do not call me, from now on all communications will be done in written form. If you fail to refund my deposit within 10 days, please be advised that I will file a complaint . . . . Since we are now in August, and you have not commenced work at my residence, this is my demand letter for a check in full refund of my deposit within 10 days of receipt of this letter. On August 24, 2006, after having received Mr. Fons’ August 18, 2006, letter, Alpha submitted an on-line application for a tile roof for the Residence. The matter was designated W2006262830. This permit application was not approved because Alpha failed to complete the application process. When he did not receive a response to his August 18, 2006, letter, Mr. Fons wrote a second letter to Alpha, which was mailed by certified mail on or about September 4, 2006. In the second letter, Mr. Fons indicated that the ten-day deadline set out in his previous letter had passed without response and he again requested the return of his deposit. On September 3, 2006, the original metal tile roof permit application was rejected by the Building Department. On September 8, 2006, the permit application, having been converted from a metal roof to a tile roof, was approved and issued as permit number 2006126043. On September 6, 2006, after Alpha had applied for and obtained a permit, Mr. Fons finally received a written response from Alpha to his August 18, 2006, letter. In the response, Mr. Ringold suggests the following: “At the signing of your contract you were aware that ‘Metro Steel Tile’ did not have Miami Dade approval and you were willing to wait for such to be approved. This made securing a permit in 30 days impossible and you were completely aware of that at the time.” Mr. Ringold’s understanding of Mr. Fons’ “understanding” has not been substantiated by the evidence presented in this case, and is, therefore, rejected. Mr. Ringold goes on to accurately suggest that Mr. Fons and Alpha had modified the agreement in July, when it was agreed that a tile roof would be placed on the Residence. Mr. Ringold then suggests that any delay in applying for a permit after July was due to the need to ensure that the tiles were delivered, facts Mr. Fons was not previously apprised of. Mr. Ringold ends the letter as follows: We have confirmed that your tile is acquired and have applied for your permit. Had we been informed that you were so concerned that your permit be pulled immediately we would have been more than happy to do so. We never worry about getting the permit in Dade County as they are very effective in issuing permits in a timely manner [a fact which Mr. Youdell was apparently not aware of, given his representation to Mr. Fons that the Building Department was back logged]. I do not understand the reason for the letter? We sincerely have always had your best interest at heart, and want to proceed with the install. I am confident that you will be pleased with the finished product. Please if you would contact me directly at . . . to discuss this matter. On September 11, 2006, Mr. Fons found a copy of permit number 2006126043, issued on September 8, 2006, on the door of the Residence. Other than a letter from Mr. Fons to Alpha dated October 23, 2006, requesting a list of subcontractors and suppliers used by Alpha, there was no further correspondence between Alpha and Mr. Fons. Nor did Alpha make any effort to fulfill its obligations under the Contract. Ultimately, permit number 20066126043, issued September 8, 2006, was cancelled based upon a February 7, 2007, request from Alpha. No work took place on the project for more than 90 days after the permit was issued. Based upon the foregoing, more than six months passed after the Contract was entered into without any work being performed by Alpha: January 15, 2006, to July 17, 2006. While the evidence failed to prove that Mr. Fons was fully informed at the time the Contract was entered into that the metal tile roofing he had selected was not approved for use in Miami-Dade County and, therefore, securing a permit would take some time to acquire, he was eventually informed of these facts. Ultimately, Mr. Fons acquiesced to the delay in commencing work between January 15, 2006, and July 17, 2006, when Mr. Fons and Alpha agreed to a modification of the Contract; in particular, to replace the roof on the Residence with a tile roof. There was, therefore, no “abandonment” of the project between January and July 2006. Between July 17, 2006, and February 2007, a period of eight months, no work was performed on the project. In fact, after early September 2006 there was no meaningful communication between Mr. Fons and Alpha. Viewing the evidence most favorably to Alpha, Alpha had informed Mr. Fons in a letter he received on September 6, 2006, that the tiles were available (the evidence failed to substantiate this claim; if the tiles had been “available” they would have been delivered directly to the Residence), the permit had been obtained, Alpha indicated its willingness to fulfill its obligation, and Alpha attempted to place the ball in Mr. Fons’ court by asking that he call to discuss the matter, and Mr. Fons had demanded a return of his deposit. Viewing the evidence most favorably to Mr. Fons, he had been waiting for eight months to have his roof repaired; he had on a monthly basis had to initiate contact with Alpha and every time he did, was told “it will be another 30 days”; Alpha had taken until May 2006 to make its first application for a permit, despite the fact that Alpha had represented to Mr. Fons that the permit would be obtained in January and that work would commence in February, the monthly representations that the permit had been applied for but was being held up by the Building Department. After renegotiating his contract, Mr. Fons was again told that the permit would be pulled within a week and that work would commence within a month. Despite these representations, no permit was applied for until after his August 18, 2006, letter was received and that permit was never approved. When Mr. Fons did finally complain and request the return of his deposit, although it had only been a month since renegotiating the type of roof to be placed on the Residence, Alpha did not respond until September 6, 2006, and only responded after finally obtaining a permit. Given these circumstances, the suggestion of Alpha that “[w]e sincerely have always had your best interest at heart, and want to proceed with the install” must have seemed disingenuous to Mr. Fons. Weighing the foregoing facts, it is ultimately found that simply “offering” to proceed, despite Mr. Fons’ demand for the return of his deposit, was simply too little, too late. Given the total eight-month delay in the project and all the misinformation Mr. Fons had been given by Alpha, and especially in light of the fact that Alpha had $13,600.00 of Mr. Fons’ money for which it had performed no work whatsoever, Alpha should have done more to attempt to fulfill the contract. Failing to do more under these circumstances constitutes an abandonment of the project to the financial detriment of Mr. Fons. On February 21, 2007, Mr. Fons contracted with another company to install a tile roof on the Residence. Work commenced February 23, 2007, and was completed March 5, 2007. Mr. Fons has suffered a loss of $13,600.00 as result of Alpha’s failure to fulfill its obligations under the Contract. The total costs of investigation incurred by the Department in this case, excluding costs associated with any attorney time, was $342.42.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding that Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., violated the provisions of Section 489.129(1)(g)2., (i), (j), and (m), Florida Statutes, as alleged in Counts I, II, III, and IV of the Administrative Complaint; imposing fines of $1,500.00 for Count I, $500.00 for Count II, and $2,500.00 for Count III; requiring that Mr. Ringold make restitution to Mr. Fons in the amount of $13,600.00; requiring that Mr. Ringold pay the costs incurred by the Department in investigating and prosecuting this matter; and placing Mr. Ringold’s license on probation for a period of one year, conditioned upon his payment of the fines, restitution to Mr. Fons, payment of the costs incurred by the Department, and any other conditions determined to be necessary by the Board. DONE AND ENTERED this 10th day of February, 2009, in Tallahassee, Leon County, Florida. LARRY J. SARTIN Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 10th day of February, 2009. COPIES FURNISHED: Brian P. Coats, Esquire Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street, Suite 42 Tallahassee, Florida 32399-2022 Paul Buschmann, Esquire Hinshaw & Culbertson, LLP One East Broward Boulevard, Suite 1010 Fort Lauderdale, Florida 33301 W. Harrell, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Ned Luczynski, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
