The Issue Whether disciplinary action should be taken against Respondent's contracting license based on the violations as charged in the Administrative Complaint in this proceeding.
Findings Of Fact Based on the evidence and testimony of the witnesses presented and the entire record in this proceeding, the following Findings of Fact are made: Respondent is a certified contractor, having been issued License No. CGC 1506923 by the Florida Construction Industry Licensing Board. Respondent's licensure as a certified general contractor is "Current, Active." Respondent is the primary qualifying agent for his company, Transflorida Corporation, which has a Certificate of Authority as a Contractor Qualified Business, License No. QB 29658; that licensure is "Current." On or about July 3, 2006, Peter Cali entered into a written contractual agreement with Respondent, d/b/a Transflorida Corporation, for the construction of an addition to his residence at 2103 Lake Pickett Road, Orlando Florida. The original contract price between Respondent and Mr. Cali was $60,000.00. On July 3, 2006, Mr. Cali paid a total of $30,000.00 to Respondent. Respondent delivered some bricks to the Cali residence and had the septic tank pumped out. With the exception of the foregoing, Respondent failed to accomplish any meaningful work on the project. Respondent abandoned the project. Mr. Cali telephoned Respondent repeatedly requesting that Respondent perform the construction as agreed. Mr. Cali did nothing to inhibit Respondent's performance of the construction contract. Although requested, Respondent did not refund any money to Mr. Cali. Mr. Cali did not benefit as a result of the delivery of the bricks or the pumping of the septic tank. Mr. Cali's "out of pocket" damages are $30,000.00. Petitioner's total investigative cost for the case is $701.63. Respondent has been the subject of seven final orders revoking his professional license and fining him a total $230,000.00.2/
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered as follows: Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(g)2., Florida Statutes, as alleged in Count II of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $5,000.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(j), Florida Statutes, as alleged in Count III of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $5,000.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(m), Florida Statutes, as alleged in Count IV of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $5,000.00; Requiring Respondent to pay financial restitution in the amount of $30,000.00 to Peter Cali; Assessing cumulative cost of investigation and prosecution in the total amount of $701.63, which excludes costs associated with any attorney's fees; and Permanently revoking Respondent's license as a result of the numerous violations and the financial harm sustained by Peter Cali. DONE AND ENTERED this 10th day of June, 2008, in Tallahassee, Leon County, Florida. S JEFF B. CLARK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 10th day of June, 2008.
The Issue At issue is whether Respondent committed the offenses set forth in the Administrative Complaints and, if so, what penalty should be imposed.
Findings Of Fact The parties Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board (Department), is a state agency charged with the duty and responsibility for regulating the practice of contracting pursuant to Section 20.165, Florida Statues, and Chapters 455 and 489, Florida Statutes. Respondent, Richard M. Golfman, was, at all times material hereto, licensed by the Department as a certified general contractor, having been issued license number CG C032860, and authorized to engage in the practice of general contracting as an individual.1 The Feinstein project (DOAH Case No. 00-0599) On or about October 30, 1998, Respondent entered into a written contract with Norman and Sheila Feinstein to furnish the materials and perform the labor necessary to enclose and remodel the screened patio, and to build a rock garden, at their home located at 5468 Northwest 20th Avenue, Boca Raton, Florida, for the sum of $5,000. At the time, the Feinsteins paid Respondent $1,500 as the initial payment (deposit) under the terms of the contract. The contract Respondent presented and the Feinsteins executed on October 30, 1998, did not include Respondent's license number, nor did it contain a statement concerning consumers' rights under the Construction Industries Recovery Fund. Following execution of the contract, Respondent made repeated promises to construct the rock garden; however, it was not until November 10, 1998, that Respondent appeared on-site and constructed the rock garden, albeit not to the Feinsteins' satisfaction. Subsequently, Respondent had some high-hat electrical fixture cans and a bundle of furring strips delivered to the home for the patio project but, thereafter, despite repeated requests, refused to perform any work on the project or refund any money to the Feinsteins. The value of the labor and materials Respondent invested in the rock garden, as well as the cost of the building materials (the high-hat fixtures and furring strips) delivered to the job-site, was $250, a sum considerably less than the $1,500 the Feinsteins had entrusted to Respondent under the terms of their agreement. The Burres/Berger project (DOAH Case No. 00-0600) On or about November 23, 1998, Respondent submitted a written proposal to Tanya Burres to furnish the materials and perform the labor necessary to replace the existing roof on her home located at 7270 Montrico Drive, Boca Raton, Florida, for the sum of $22,125. The proposal was a one-page preprinted form. In the upper left there appeared, printed immediately following Respondent's handwritten name, the following: THE GOLFMAN GROUP, INC. P.O. Box 811926 Boca Raton, Florida 33431 The proposal did not include Respondent's license number, nor did it contain a statement concerning consumers' rights under the Construction Industries Recovery Fund. At the time the proposal was submitted, Tanya Burres was under contract to sell the home to Drs. Glenn Berger and Michelle Fiorillo, husband and wife (the Bergers), and Ms. Burres had agreed to split with the Bergers the cost of a new roof for the home. At the time, Ms. Burres had suggested the Respondent as a contractor to perform the work (because he had previously done satisfactory work for Ms. Burres); however, it was understood that the employment of any contractor was subject to the Bergers' approval. That the Bergers' agreement was required before any such employment would be accepted was clearly conveyed to Respondent. On November 23, 1998, Tanya Burres signed the proposal and gave Respondent a check payable to his order in the sum of $1,106.25, representing her half of the ten percent deposit called for by the proposal. The Bergers, however, declined to accept the proposal, and refused Respondent's request for the balance of the deposit. Rather, the Bergers, having received adverse information from the Department regarding Respondent's record, preferred to employ a different contractor, and Ms. Burres accorded the Bergers a monetary credit at closing (on the purchase of the home) for one-half the cost to re-roof the home. When the Bergers informed Ms. Burres (shortly after she signed the proposal on November 23, 1998) that they would not agree to use Respondent, Ms. Burres attempted to stop payment on her check; however, the check had already been cashed. Thereafter, Ms. Burres attempted on numerous occasions to contact Respondent by telephone and by his pager, but Respondent failed to return any of her calls or messages. To date, Respondent has failed to account for or return Ms. Burres' deposit of $1,106.25. The costs of investigation and prosecution As of February 25, 2000, the Department's costs of investigation and prosecution, excluding costs associated with any attorney's time, totaled $234.85 for DOAH Case No. 00-0599 (the Feinstein project) and $195.65 for DOAH Case No. 00-0600 (the Burres/Berger project.) Previous disciplinary action At hearing, the Department offered proof that, on two prior occasions, Respondent had been subjected to disciplinary action by the Construction Industry Licensing Board (the Board). (Petitioner's Exhibit 2.) The first occasion is reflected in the terms of a Final Order of the Board, dated August 4, 1987, which found Respondent guilty of the violations alleged in the Administrative Complaint (which were not revealed at hearing beyond what may be inferred from the terms of the Final Order), and resolved that Respondent suffer the following penalty: Respondent's licensure is hereby suspended for ten (10) years. Provided, Respondent may obtain termination of said suspension at anytime, without further action by the Board, upon providing the Board's Executive Director with a certified bank check in an amount sufficient to cover and pay a fine of five hundred dollars ($500), and the bad check alleged in the Administrative Complaint, and all service charges in connection therewith, and all other fees accruing as of the date Respondent seeks said termination of supervision. The second occasion Respondent was subjected to disciplinary action is reflected in the terms of a Final Order of the Board, dated July 18, 1997, which approved a stipulated settlement of certain complaints then pending before the Board. That Final Order approved the dismissal of a number of counts contained in five Administrative Complaints then pending before the Board and, as to the remaining counts, agreed (without Respondent admitting or denying the allegations of fact contained in the Administrative Complaints) to the following penalty: 3. FINE AND COSTS: Respondent shall pay a fine of Nine Hundred dollars ($900.00) and costs of Eight Hundred fifty One dollars ($851) to the Board within thirty (30) days of the filing of the Final Order. Said payment shall be in the form of a cashier's or certified check and shall be made payable to the "Construction Industry Licensing Board." To assure payment of the fine and costs, it is further ordered that all of Respondent's licensure to practice contracting shall be suspended with the imposition of the suspension being stayed for thirty (30) days. If the ordered fine and costs are paid in compliance with the terms set forth above, the suspension imposed shall not take effect. However, should payment not be timely made, the stay shall be lifted and Respondent's license shall be immediately suspended. Upon payment of the fine and costs in full, the suspension imposed shall be lifted. Respondent apparently satisfied the fines and costs imposed by the foregoing orders. (Petitioner's Exhibit 2.)
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be rendered adopting the foregoing findings of fact and conclusions of law, and which, as a penalty for the violations found, imposes an administrative fine in the total sum of $13,500.00, revokes Respondent's licensure, orders that Respondent pay restitution to Norman and Sheila Feinstein in the sum of $1,250.00 and to Tanya Burres in the sum of $1,106.25, and assesses costs of investigation and prosecution (through February 25, 2000) in the total sum of $430.50 against Respondent. DONE AND ENTERED this 22nd day of June, 2000, in Tallahassee, Leon County, Florida. WILLIAM J. KENDRICK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 22nd day of June, 2000.
The Issue Whether disciplinary action should be taken against Respondent's license to practice contracting, as charged in the three-count Administrative Complaint filed against Respondent in this proceeding, which alleged that Respondent violated Subsection 489.129(1)(g)2., Florida Statutes (2009),1 by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer; Subsection 489.129(1)(j), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor; and Subsection 489.129(1)(m), Florida Statutes, by committing incompetency or misconduct in the practice of contracting; and, if so, what penalty should be assessed.
Findings Of Fact Petitioner is the state agency charged with regulating the practice of contracting, including roofing contractors, in the State of Florida. At all times material, Respondent was a certified roofing contractor, having been issued License No. CCC 1328032 by the Florida Construction Industry Licensing Board ("CILB"). Respondent was the qualifier of Partnership Remodeling and Roofing Services, Inc. On February 10, 2009, Respondent entered into a contract with William Heston to re-roof Heston's home located at 6002 Cocos Drive, Fort Myers, Florida 33908. The agreed price of the contract was $13,970.00. On or about February 10, 2009, Heston gave Respondent a check in the amount of $7,000.00 as a deposit, payable to Partnership Roofing Services. After being paid the deposit, Respondent did obtain a permit and filed a Notice of Commencement, but Respondent failed to commence work according to the contract. Heston attempted to contact Respondent numerous times to prompt him to start performing the work, to no avail. On March 6, 2009, Heston sent a letter to Respondent asking for the return of his deposit. Although Respondent claims that he had other financial obligations which prevented him from making restitution to the homeowner, Respondent verbally agreed numerous times to return the deposit to Heston, but he failed to do so. The percentage of contracted work completed was zero, while the percentage of the contract price paid to Respondent was 50 percent. The total investigative costs of this case to Petitioner, excluding costs associated with any attorney's time, was $427.00. Respondent has not had a prior disciplinary action filed against his license.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board, issue a final order, as follows: Finding Respondent guilty of having violated Subsection 489.129(1)(g)2., Florida Statutes, as alleged in Count I of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $1,500.00. Finding Respondent guilty of having violated Subsection 489.129(1)(j), Florida Statutes, as alleged in Count II of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $2,500.00. Finding Respondent guilty of having violated Subsection 489.129(1)(m), Florida Statutes, as alleged in Count III of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $1,500.00. Ordering Respondent to pay financial restitution to the consumer, William Heston, in the amount of $7,000.00, representing the deposit paid to Respondent. Requiring Respondent to pay Petitioner's costs of investigation and prosecution, excluding costs associated with an attorney's time, in the amount of $427.12. Suspending Respondent's license to practice contracting (No. CCC 1328032) for a period of one year, followed by probation for two years. DONE AND ENTERED this 19th day of July, 2010, in Tallahassee, Leon County, Florida. S DANIEL M. KILBRIDE Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 19th day of July, 2010.
The Issue The issues in this case are whether Respondent violated Subsections 489.129(1)(j) and (m), Florida Statutes (2004),1/ and, if so, what penalty should be imposed.
Findings Of Fact The Parties At all times relevant to this proceeding, Respondent was a certified general contractor, having been issued License No. CGC 1506043 by the Florida Construction Industry Licensing Board ("Board" or "Construction Industry Licensing Board") and was the primary qualifying agent for Rankor Corporation. The Board is the state agency charged with regulating the practice of contracting in the State of Florida pursuant to Chapters 455 and 489, Florida Statutes. At all times relevant, Rankor Corporation was a contractor-qualified business in the State of Florida, having been issued License No. QB 26667. The officers of the Rankor Corporation were as follows: Tina M. Despin, president; Stephen Despin, Sr., executive vice president; Jerold S. Bakelman, vice president and treasurer; and Eldora Bakelman, secretary. The directors of the Rankor Corporation were Respondent, Mr. Bakelman and Mr. Despin. Jerold Bakelman was licensed as a financially responsible officer by the Board from August 27, 2003, to January 7, 2005. Mr. Bakelman's license number was FRO 711. Transactions Related to Longoria Property In December 2004, Antonia Longoria met with Tina Despin and Stephen Despin, Sr., about replacing the roof and performing other repairs at a house owned by Ms. Longoria located at 4716 Nottingham Drive, Ft. Myers, Florida ("Nottingham Drive house" or "Nottingham Drive property").2/ On or about December 7, 2004, Ms. Longoria entered into a contract with Rankor Corporation to remove and replace the roof and to make the other repairs at the Nottingham Drive house (hereinafter referred to as "Contract No. 1" or "December 7, 2004, Contract"). The cost for the scope of work in Contract No. 1, including the cost of obtaining permits was $32,690.00. Pursuant to the terms of the contract, one-third of the contract amount, $10,896.67, was due when the contract was signed; one-third of the contract amount was due when the trusses were delivered; $8,396.67 was due when the job was completed; and $2,500.00 was due after the final inspection of the job was completed. The December 7, 2004, Contract was signed by Tina Despin on behalf of Rankor Corporation and by Ms. Longoria. On or about December 7, 2004, Ms. Longoria paid Rankor Corporation, by personal check, a payment in the amount of $10,896.67 for the work to be done pursuant to Contract No. 1. Ms. Longoria made the check out to Rankor Corporation and gave it to Ms. Despin. On or about December 17, 2004, about ten days after Contract No. 1 was executed, Ms. Longoria entered into a second contract with Rankor Corporation to do additional work at the Nottingham Drive house (hereinafter referred to as "Contract No. 2" or "December 17, 2004, Contract"). Under the terms of the December 17, 2004, Contract, Rankor Corporation was required to relocate the entrance to the house from the side to the front of the house. The cost for the scope of work under this contract was $10,770.00, with payments to be made in three installments. Pursuant to the terms of Contract No. 2, one-third of the contract amount, $3,590.00, was due when the contract was signed; one-third was due when the trusses were delivered; and the remaining one-third was due upon completion of the project. Contract No. 2 was signed by Tina Despin on behalf of Rankor Corporation and by Ms. Longoria on or about December 17, 2004. Two days later, on or about December 19, 2004, Ms. Longoria paid Mr. Despin, Sr., by personal check, a payment in the amount of $3,590.00 for the project under this contract. The check was made out to "Stephen E. Despin" and not to Rankor Corporation. Ms. Longoria paid the $3,590.00 to Mr. Despin, Sr., as a representative of Rankor Corporation. The scope of work under both Contract No. 1 and Contract No. 2 required permits from the City of Ft. Myers Building Department before work could commence. However, after the two contracts were executed, Rankor Corporation never applied for the permits necessary to commence work under those contracts. At or near the end of January 2005, Ms. Longoria began calling Mr. Despin, Sr., to find out when he would begin the project at the Nottingham Drive house. After several unsuccessful attempts by Ms. Longoria to reach Mr. Despin, Sr., he returned her call in February or March, but Rankor Corporation never performed any of the work required under Contract No. 1 and Contract No. 2. No one from Rankor Corporation ever performed any work on Ms. Longoria's Nottingham Drive house. Notwithstanding its failure to perform any of the work required under the December 7, 2004, Contract and the December 17, 2004, Contract, Rankor Corporation did not return Ms. Longoria's two payments made pursuant to the terms of those contracts. The total of these two payments was $14,486.67. In or about March 2005, the City of Ft. Myers Code Enforcement unit posted a notice on the Nottingham Drive property advising Ms. Longoria that the subject property was in violation of the city code. The notice gave Ms. Longoria, as owner of the property, 30 days to have the repairs done to bring the house into compliance with the code. The violations cited in the notice were related to damages the Nottingham Drive house sustained from Hurricane Charlie. On or about April 19, 2005, Ms. Longoria entered into a contract with Roofmaster of South Florida, Inc. ("Roofmaster") to repair the roof at the Nottingham Drive house in order for the roof to be in compliance with the City of Ft. Myers code. The scope of work under the contract with Roofmaster was smaller than the scope of work under the December 7, 2004, Contract between Ms. Longoria and Rankor Corporation. The contact price for the project with Roofmaster was $9,500.00. In or about May 2005, Roofmaster commenced and completed work under its contract with Ms. Longoria. For this work, Ms. Longoria paid Roofmaster the contract price of $9,500.00. At no point in time until May 2005, the time at which Roofmaster commenced work under the contract with Ms. Longoria, did Ms. Longoria prevent Rankor Corporation from commencing and completing the work projects under the December 7, 2004, Contract and the December 17, 2004, Contract. Respondent's Attempts to be Removed as Qualifying Agent On January 5, 2005, Respondent wrote a letter to Mr. Bakelman memorializing Respondent's and Bakelman's conversation concerning Mr. Bakelman's decision to no longer serve as the financially responsible officer for Rankor Corporation. In the letter, Respondent recounted that during that conversation, he (Respondent) had "executed documents supplied by you [Bakelman] from the State of Florida Construction Industry Licensing Board releasing you [Bakelman] from said position with immediate effect." By letter dated January 5, 2005, Respondent forwarded a copy of his January 5, 2005 letter to Mr. Bakelman to the secretary of the Construction Industry Licensing Board in Tallahassee, Florida. Respondent requested that the letter be recorded and filed with pertinent information maintained by that office for "the business qualified by me [Respondent], known as Rankor Corporation. Apparently concerned about Mr. Bakelman's stepping down as Rankor Corporation's financially responsible officer, Respondent contacted the Department's Customer Service section on January 5, 2005, about the situation. At that time, a person in that section told Respondent that he should inform the company officers that they had an obligation to secure a new financially responsible officer, and if they did not, he was obligated either to act in that position or to terminate his position as qualifying representative. On January 7, 2005, Bakelman was properly removed as the financially responsible officer for Rankor Corporation and, thereby, ceased being the financially responsible officer for Rankor Corporation. Upon Mr. Bakelman's being properly removed as the financially responsible officer, Respondent, as the qualifying agent, became responsible for the duties and obligations related to Rankor Corporation's financial matters. By letter dated February 7, 2005, Respondent advised Stephen and Tina Despin (Stephen and Tina) that he was terminating his position as the primary qualifying agent for Rankor Corporation. In this letter, Respondent recounted a January 5, 2005, letter to the Despins in which he indicated that in light of Mr. Bakelman's resignation, he (Respondent) was requiring them to secure a financially responsible officer within two weeks. According to the letter, the reason Respondent was terminating his position with the company was that the Despins had failed to do so. In addition to advising the Despins that he was terminating his position as qualifying agent for Rankor Corporation, Respondent's letter provided the following: Pursuant to guidelines of CILB [Construction Industry Licensing Board], it is required that no new contracts or construction endeavors requiring the use of my license be undertaken, this includes, but is not limited to, the "pulling" of permits. Furthermore, my license number is to be removed form any signage or advertising immediately, which would serve to give the impression that Rankor is acting as a certified general contractor. The only work you are permitted to perform is to conclude projects already underway, and I was advised by the board [Construction Industry Licensing Board] that you should secure another qualifier as soon as possible. I will advise the local building departments of the change of status as well. Respondent sent the February 7, 2005, letter to the Despins by certified mail. According to the return receipt, Tina Despin signed for and received the letter on February 8, 2005. Respondent also sent a copy of his February 7, 2005, letter to the Despins to the Construction Industry Licensing Board. On February 7, 2005, Respondent sent a letter to the Board informing the Board of Respondent's termination as the primary qualifying agent for Rankor Corporation and requesting the appropriate documents to be removed as the primary qualifying agent for Rankor Corporation. The letter provided, in relevant part, the following: Construction Industry Licensing Board Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Fl [sic] 32399 Re.: Termination of Acting as Qualifier for Rankor Corporation Dear Sirs or Mesdames: As per attached letter I with immediate effect remove myself as qualifier for Rankor Corporation, QB 26667[.] Please provide me with any forms required to effect completion of the same, this should not be considered in any manner a renunciation or modification of my termination as qualifier. This act is irrevocable and immediate. I am a certified General Contractor, [sic] [M]y license number is CGC 1506043. The "attached letter" referred to in Respondent's letter to the Board, quoted in paragraph 30, is Respondent's February 7, 2005, letter to the Despins. Larissa Vaughn has been the administrative assistant for the executive director of the Board since February 2005. As an administrative assistant, Ms. Vaughn is familiar with the licensure process for construction contractors. Ms. Vaughn testified that the Board never received Respondent's February 7, 2005, letter to the Board, which informed the Board of Respondent's termination as the primary qualifying agent for Rankor Corporation and requested that he be sent appropriate documents to be removed as the primary qualifying agent for Rankor Corporation. The reason the Board never received the letter is not clear. However, Ms. Vaughn testified that a letter, such as Respondent's February 7, 2005, letter to the Board, would not have necessarily been received. According to Ms. Vaughn, "[a] lot of letters like this are received and [when] there is a request for forms, it goes to our customer contact center." Ms. Vaughn testified that even if the Board had received Respondent's February 7, 2005, letter, that correspondence would not have been sufficient in itself to remove Respondent as the primary qualifying agent for Rankor Corporation. According to Ms. Vaughn, the Department requires that to be removed as the primary qualifying agent for a contractor-qualified business in the State of Florida, a licensed contractor must submit to the Board a properly completed change of status application. Ms. Vaughn testified that a change of status application can be requested and received from the Department by phone, e-mail, or internet.3/ On September 13, 2005, Respondent submitted a change of status application to the Board. Almost two years later, Respondent's change of status application remains open and has not been approved by the Board. Respondent's efforts to terminate his status as the qualifying agent for Rankor Corporation were unsuccessful for the reasons stated above. In this case, even if Respondent's February 7, 2005, letter had effectively terminated his status as qualifying agent, the fact remains that he was the qualifying agent in December 2004 when Rankor Corporation entered into the two contracts with Mrs. Longoria. Moreover, Respondent became responsible for Rankor Corporation's financial matters after Mr. Bakelman was properly released as the company's financially responsible officer. There is no evidence that Respondent has been previously cited for violations under Chapter 489, Florida Statutes. The total investigative costs of this case to Petitioner, excluding costs associated with any attorney's time, for Department Case No. 2005-028129 was $408.37 (four hundred eight dollars and thirty seven cents).
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner, Department of Business and Professional Regulations, Construction Industry Licensing Board, enter a final order: (1) finding that Respondent, Joseph D. Sloboda, violated Subsections 489.129(1)(j) and (m), Florida Statutes; (2) imposing a $1,000 fine for each violation; (3) requiring Respondent to make restitution to Antonia Longoria in the amount of $14,486.67; and (4) requiring Respondent to pay investigative costs associated with this case of $408.37. DONE AND ENTERED this 30th day of November, 2007, in Tallahassee, Leon County, Florida. S CAROLYN S. HOLIFIELD Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 30th day of November, 2007.
Findings Of Fact Leroy Alvin Colts was qualifier for Berkley Home Service, which held License #RC0029635. Colts held such license from 1977 - 81. In December 28, 1978, Leroy Alvin Colts' local certificate of competency was revoked by the Pinellas County authorities. This action was reviewed by the Florida Construction Industry Licensing Board prior to these charges being filed. On January 4, 1979, Leroy Alvin Colts was adjudged guilty of violating Section 812.021 (Grand Theft) and Section 812.014 (Grand Larceny) and sentenced to 45 years in the State Penitentiary. These offenses arose directly from Colts' activities as a licensed contractor. The court's judgment was affirmed by the appellate court. Notice of this proceeding was provided Colts in the manner prescribed by law, and inquiry of Counsel for the Petitioner Board and representatives of the St. Petersburg Police Department showed that Colts was free on bond and available to attend the hearing.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, the Hearing Officer recommended that the Florida Construction Industry Licensing Board revoke Leroy Alvin Colts' license. DONE and ORDERED this 21st day of September, 1979, in Tallahassee, Leon County, Florida. STEPHEN F. DEAN, Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 COPIES FURNISHED: Michael E. Egan, Esquire 247 South Adams Street Post Office Box 1386 Tallahassee, Florida 32302 Joseph F. McDermott, Esquire 544 First Avenue, North St. Petersburg, Florida 33701 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner,
The Issue Whether the Respondent was validly disciplined by a local government, which causes the Respondent to be in violation of Section 489.129(1)(i), Florida Statutes (1985). Whether the Respondent failed to perform the contracting job alleged in the Administrative Complaint in a reasonably timely manner, or abandoned the job, in violation of Section 489.129(1)(m), (k), Florida Statutes (1985). Whether the Respondent exhibited financial mismanagement, misconduct or diversion, in violation of Section 489.129(1)(h), (m), Florida Statutes (1985). Whether the Respondent committed gross negligence, incompetence or misconduct in connection with the job alleged in the Administrative Complaint, in violation of Section 489.129(1)(m), Florida Statutes (1985).
Findings Of Fact At all times material to these proceedings, the Respondent, Charles R. Schelah was licensed as a certified general contractor in Florida, and held license number CG C016841. Mr. Schelah was the qualifying agent for Schelah Construction, Inc. On March 11, 1986, Schelah Construction, Inc., entered into a contract with Moner F. Green and Karen L. Green to construct a residence in Prairie Creek Park, Charlotte County, Florida A copy of the contract is Petitioner's Exhibit Pursuant to the written agreement, construction would occur as per the signed construction drawings. The total contract price was to be $102,775.00. This quote was contingent upon a construction start on or before March 15, 1986. After that date, increases in supply and labor costs would be borne by the owners, Mr. and Mrs. Green. The contract further stated that there is no specific completion date, that an expected completion date was August 30, 1986. Construction began on the residence on April 4, 1986. Three revisions of the drawings were completed by the owner before a building permit was requested by the Respondent Schelah. Throughout the progress of construction, major and minor revisions were made by the owners. Many of these revisions delayed construction as the Respondent was required to obtain new special order materials and retrofit many of the changes into the existing construction phase. The Respondent recollected that thirty-five revisions were made to the construction plans by the owners during various phases of construction. In September 1986, the owners began to frequently telephone the Respondent in order to urge him to quickly complete the project as the owners were now required to pay the savings and loan association mortgage installments. The Respondent did not return the telephone calls. A letter was sent to the Respondent by the owners' attorney on November 3, 1986, notifying him that he needed to resume his responsibilities at the construction site. The Respondent did not reply to this letter. On November 7, 1986, the Respondent was removed as contractor of record by the owners. All but the final draw from the savings and loan had been given to the Respondent before his removal. After the Respondent was removed from the project, the owners were given notice of the following liens: $2,750.55 to Pre-Hung Doors of Florida for supplies delivered in August 1986; $700.00 to Paul Hartt Plastering and Stucco, Inc. for work completed in September 1986. The work completed by both subcontractors was performed during the Respondent's term as the prime contractor on the project. These two contractors were never paid by the Respondent out of draws received by him for that purpose through October 1986. These subcontractors, as well as others, testified that they were unable to communicate with Respondent after September 1986. The final draw from the savings and loan in the amount of $19,618.97, was used by the owners to complete the project themselves. The proof of payment submitted by the owner, Mr. Green, at hearing for completion under the direct contract was $6,149.14, in Respondent's Exhibit 14. The residence was completed by the owners in December 1986. Mr. Green, the owner, filed a complaint with the Charlotte County Building Board on October 29, 1986, alleging that the Respondent refused to call him, and was dragging completion of the job for unknown reasons hearing was held on February 19, 1987. At the conclusion of the hearing, the Charlotte County Building board suspended the permitting privileges of Schelah Construction, Inc., until such time as all jobs in progress were finished. During the administrative hearing, the Respondent admitted that a twenty-one day delay on the Green project occurred when he was unable to acquire a sheetrock hanger who would go to the hinterlands (Prairie Creek Park) where the residence was being built. He contends however, that the additional time delays were a result of changes in supply orders due to the changes made by the owners, and the requirement that subcontractors be rescheduled to accommodate these changes. Petitioner's experts in construction practices within Florida, Mr. Bernard Verse and Mr. Stanley Ink, were unable to render an opinion that the Green Construction project had been abandoned by Respondent Schelah, or that there had been a diversion of funds. However, Mr. Ink did render an opinion that the project was not completed in a reasonably timely manner, that the Respondent is guilty of financial mismanagement, and that the Respondent committed gross negligence, incompetence or misconduct on the job in that the Respondent did not use due diligence in completing the job, staying on the job, and paying the subcontractors as the contractor should. Mr. Verse opined that the Respondent committed financial mismanagement and gross negligence in the practice of contracting. It was gross negligence not to maintain contact with clients. The Respondent's own expert in construction practices in the Punta Gorda area, Mr. Larry Deirmeyer, noted that it is difficult to acquire unscheduled building supplies in the Punta Gorda area if a contractor runs a small construction company because the supply houses are in Fort Myers, where rapid growth is occurring. In addition, it is difficult to get subcontractors to work on construction in areas like Prairie Creek Park, which is remote from the developed areas of Charlotte County. After Mr. Deirmeyer was admitted as an expert in construction practices, the Hearing Officer learned that he had built a custom home for the owner Moner Frank Green in 1980. Mr. Green's removal of Mr. Deirmeyer's company from the construction project during the last draw of that project, and his continuous changes in those plans were not considered by the Hearing Officer in this case except for the purpose of weighing Mr. Deirmeyer's independence as an expert witness. Another expert witness in construction practices presented by the Respondent was James Anderson, a state certified contractor from the Port Charlotte area. Mr. Anderson acknowledged the local builder supply problem and rendered the opinion that nine months was a reasonable period of time in which to complete the Green project, based upon the construction plans, the change orders, and the travel required to the project, which is not in the immediate Port Charlotte area. The Respondent Schelah did not maintain communication with the owners regarding the progress of the project, even though he was telephoned repeatedly and received written communication from the Green's attorney. This failure to maintain communication resulted in the Respondent's dismissal from the project. The County's Building Director's requests for communication were also refused by the Respondent.
Recommendation Based upon the foregoing, it is RECOMMENDED: That the Respondent be found not guilty of having violated Section 489.129(1)(i), Florida Statutes, as alleged in paragraph five of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(m) and (k), Florida Statutes, as alleged in paragraph six of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(h) and (m), Florida Statutes, as alleged in paragraph seven of the administrative complaint. That the Respondent be found guilty of having violated Section 489.129(1)(m), Florida Statutes, as alleged in paragraph ten of the administrative complaint in regard to misconduct by the Respondent on the Green project. That the penalties assessed against the Respondent not include an aggravation of penalties under Rule 21E-17.002, Florida Administrative Code, and that the Respondent pay a fine of $750.00, as set forth in Rule 21E-17.001(5), Florida Administrative Code. DONE and ENTERED this 9th day of June, 1989, in Tallahassee, Leon County, Florida. VERONICA E. DONNELLY Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 9th day of June, 1989. APPENDIX TO RECOMMENDED ORDER CASE NO. 88-3442 Petitioner's proposed findings of fact are addressed as follows: Accepted. Accepted. See HO #1. Accepted. See HO #1. Rejected as to location of project. The rest is accepted. See HO #2. Accepted. Accepted. See HO #2. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #6. Accepted. Accepted. See HO #9. Accepted. See HO #9 and #10. Accepted. See HO #10. Accepted. Accepted. See HO #13. Accepted. Accepted. Rejected. See HO #13 and #11. Rejected. See HO #11. Accepted. See HO #11. Accepted. Accepted. Accepted. See HO #14. Accepted. See HO #3 and #8. Accepted. See HO #7. Respondent's proposed findings of fact are addressed as follows: Accepted. See HO #1. Accepted. See HO #2. Accepted. See HO #3 and #4. Accepted. See HO #13. Accepted. See HO #5. Accepted. See HO #6. Accepted. See HO #6. Accepted. See HO #7. 9. Accepted. See HO #9, #10, #11, #12 and #13. 10. Rejected. Irrelevant to this proceeding. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 John Charles Heekin, Esquire 21202 Olean Boulevard, Suite C-2 Port Charlotte, Florida 33952 Kenneth E. Easley, Esquire General Counsel Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 Fred Seely, Executive Director Florida Construction Industry Licensing Board 111 East Coastline Drive Post Office Box 2 Jacksonville, Florida 32202
The Issue The issue for determination is whether Respondent committed the offenses set forth in the Administrative Complaint and, if so, what action should be taken.
Findings Of Fact At all times material hereto, Mr. Borek was licensed by the Department as a certified general contractor, having been issued license number CG C 58817. He was licensed on November 18, 1996. At all times material hereto, Mr. Borek was the qualifying agent of Atlantic Coast General Contractors, Inc. (ACGC), a Florida corporation, and has been its president. ACGC was issued a certificate of authority as a contractor qualified business on June 2, 1977, having been issued license number QB 07357. ACGC's license expired on September 1, 2001 and became null and void on September 1, 2003. The State of Florida, Department of State, administratively dissolved ACGC, as a corporation, on October 1, 2004, for its failure to file its annual report, as required by law; and, as a result, ACGC's authority to transact business, as a corporation, in the State of Florida was revoked on the same date. At all times material hereto, Tracey Meredith (Ms. T. Meredith) resided in and owned a home located at 7690 Northwest 16th Court, Pembroke Pines, Florida. Ms. T. Meredith wanted her mother, Jane Meredith1 (Ms. J. Meredith), to live with her so Ms. T. Meredith decided to have an addition built to her home, consisting of a bedroom, bathroom, and closet. Ms. T. Meredith obtained a proposal from ACGC and five other contractors for the addition. Each contractor was aware of the purpose of the addition. Ms. T. Meredith decided to contract with ACGC, which was not the lowest or the highest bidder, but was somewhat in the middle. On June 28, 2002, a Proposal/Contract (Contract) was executed with ACGC for the addition at a cost of $32,925.00. Even though the Contract showed Ms. T. Meredith as the contracting party, it was signed by Ms. J. Meredith because she (Ms. J. Meredith) was actually paying for the addition and signing the checks. Both Mses. T. Meredith and J. Meredith were in agreement with the Contract. The Contract provided, among other things, that the addition was 15 x 21; and that the payments would be as follows: 20% at acceptance of the Contract, 20% at permit issuance, 10% at slab, 20% at wall and roof framing, 10% at roof completion, 10% at finished walls and flooring, and 10% at final completion. No dispute exists that the cost of the Contract was reasonable. No dispute exists that the Contract failed to contain a provision explaining the consumer's rights under the Florida Homeowners' Construction Recovery Fund, formerly known as the Construction Industries Recovery Fund. No dispute exists that the Contract did not provide a date for completion of the addition. Regarding a completion date for the addition, Ms. T. Meredith testified that all the other proposals provided that the addition would be completed within six to eight weeks and that, at the beginning, Mr. Borek orally communicated to her that the addition would be completed by ACGC within six to eight weeks. To the contrary, Mr. Borek testified that, at the beginning, no completion date was given to her, either orally or in writing. None of the other proposals were submitted into evidence, only the Contract with Mr. Borek, which did not provide a completion date. It would not be reasonable for Ms. T. Meredith to accept Mr. Borek's proposal without it’s being within the time period of completion of the other proposals. The undersigned finds Ms. T. Meredith's testimony more credible and makes a finding of fact that, at the time of the signing of the Contract, Mr. Borek made an oral representation that the addition would be completed by ACGC within six to eight weeks. An expert in the field of general contracting, John Yanoviak (Mr. Yanoviak), testified on behalf of the Department. The undersigned finds his testimony credible, except as specifically indicated. A reasonable amount of time to complete the addition was a maximum of three months. Mr. Borek, as the contractor, was responsible for keeping the project timely and for quality control. On June 30, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,585.00. This amount was 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. Paying this amount was in accordance with the Contract. Mr. Borek filed an application for a building permit with the City of Pembroke Pines (CPP) on or about July 3, 2002. The building permit was issued by CPP on or about October 25, 2002. Work on the addition was commenced before the issuance of the building permit. Ms. T. Meredith was aware of the date that the building permit was issued. Prior to the issuance of the building permit, Ms. T. Meredith complained to Mr. Borek regarding the addition’s not being completed. No evidence was presented to show that Ms. T. Meredith indicated to Mr. Borek that, by his failure to complete the addition within a six-to- eight-week period, he was not abiding by the Contract. No evidence was presented to show that she indicated her dissatisfaction to the degree of possibly terminating the Contract with ACGC. On November 12, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,585.00. This amount was paid after Mr. Borek obtained the building permit and was 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. Paying this amount was in accordance with the Contract. On December 11, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,885.00. This amount was $300.00 more than 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. An inference is drawn and a finding is made that this check was written in advancing of the addition. According to the records of the CPP's building department2 (Records), a CPP form for a revision to the addition was submitted on January 6, 2003, providing for an electrical change to the addition. Further, the Records indicate that, on March 20, 2003, an application for an electrical permit was submitted and that, on March 24, 2003, the permit was approved. Also, a revision to the plans of the addition was submitted to the CPP by the architect to the addition, Hernando Acosta, according to the Records. The Records indicate that the revision to the plans was dated January 30, 2003 by Mr. Acosta, that the revision was submitted on February 7, 2003, and that the revision was approved on February 11, 2003 by the CPP. In addition, in February 2003, Ms. T. Meredith received written communication from the CPP regarding a problem with the addition. Ms. T. Meredith received a copy of a letter from the CPP to Mr. Borek, dated February 18, 2003. The letter indicated, among other things, that the CPP had issued a "stop work status" on the addition due to Mr. Borek’s having issued a check, payable to the CPP, in the amount of $135.80, which was dishonored. Another revision, according to the Records, was submitted on March 27, 2003, regarding the trusses. The Records indicate that the revision was approved on April 17, 2003. Ms. T. Meredith became more dissatisfied with the progress toward completion on the addition by Mr. Borek to the point that she filed a complaint with the Department on May 21, 2003. In May 2003, Ms. T. Meredith received written communication from the CPP regarding a problem with the addition. By letter dated May 22, 2003, she received notification from the CPP, as information only, that a code violation had not been corrected within the allowable ten-day period, together with a copy of CPP's letter to Mr. Borek, dated May 22, 2003, of his failure to correct the code violation. The letter to Mr. Borek indicated, among other things, that Mr. Borek had until June 11, 2003 to correct the violation, identifying the inspection date and the violation. By a letter dated May 28, 2003, Ms. T. Meredith advised Mr. Borek, among other things, that he had seven days to continue with the work on the addition in accordance with the Contract or else the Contract would be considered by her to be "null and void"; that, if he did not do so, she would be "forced" to hire another contractor, with Mr. Borek being held financially responsible for completion of the addition; and that the Contract was to be completed within six to eight weeks. On June 12, 2003, Mr. Borek contacted the investigator for the Department regarding the complaint filed by Ms. T. Meredith. Among other things, Mr. Borek informed the investigator that he (Mr. Borek) was willing to complete the addition in 30 days. By his representation, Mr. Borek indicated that he would complete the addition on or about July 12, 2003. By a letter dated June 18, 2003, Mr. Borek notified the investigator, among other things, that he was working "diligently" to complete the addition. Mr. Borek failed to complete the addition within the 30-day period, as he had represented to the Department's investigator. The Records indicate that an application for a building permit, involving the roof to the addition, was submitted on June 25, 2003. The permit was issued, according to the Records, on July 30, 2003. Further, the Records indicate that a revision, regarding the size of a window and the elimination of a door, was submitted on July 8, 2003, and approved on July 9, 2003. In July 2003, Ms. T. Meredith received another written communication from the CPP regarding a problem with the addition. By letter dated July 9, 2003, she received notification from the CPP, as information only, that a code violation had not been corrected within the allowable ten-day period, together with a copy of CPP's letter to Mr. Borek, dated July 9, 2003, of his failure to correct the code violation. The letter to Mr. Borek indicated, among other things, that Mr. Borek had until July 28, 2003, to correct the violation, identifying the inspection date and the violation. In addition, in July 2003, Ms. T. Meredith received written communication from the CPP regarding another problem with the addition. She received a copy of a letter from the CPP to Mr. Borek, dated July 18, 2003, which indicated, among other things, that the CPP had issued a "stop work status" on the addition due to Mr. Borek having issued a check, payable to the CPP, in amount of $76.23, which was dishonored. Even though Mr. Borek failed to complete the addition within the 30-day period that he had represented to the Department's investigator and even though Ms. T. Meredith had received notification of the problems at the jobsite from the CPP, on September 10, 2003, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $4,000.00. No dispute exists that this check was written and presented to Mr. Borek. An inference is drawn and a finding is made that this check was written in furtherance of the addition. ACGC had been paid a total of $24,055.00 of the Contract cost of $32,925.00, which was approximately 73 percent of the Contract cost. The balance of the Contract cost was $8,870.00. Mr. Borek testified that, at the time of the writing of the check for $4,000.00, he and Ms. T. Meredith agreed that he would have until on or about November 15, 2003 to complete the project. Ms. T. Meredith testified that no such agreement was made. At the time of the check for $4,000, ACGC was almost 60 days beyond the completion date represented to the Department's investigator. No testimony was presented as to why the $4,000.00 was paid to ACGC in light of such a considerable delay in completing the job by ACGC and in light of the complaint being filed with the Department. Due to the lack of an explanation for the payment of the $4,000.00 to ACGC in furtherance of the project, Mr. Borek's testimony presents a reasonable explanation. Therefore, Mr. Borek's testimony is found to be credible. Hence, a finding is made that, on or about September 10, 2003, Mr. Borek and Ms. T. Meredith orally agreed that ACGC would have until on or about November 15, 2003, to complete the addition. Ms. T. Meredith continued to be dissatisfied with the progress on the addition by ACGC. Sometime after September 10, 2003, an incident occurred which caused her to reach the conclusion that she could not allow ACGC to continue working on the project. One day when she left for work, one of ACGC's workers was painting the exterior walls. When she returned from work later that same day, the same worker for ACGC was painting the exterior walls. Ms. T. Meredith immediately directed the worker to leave and to take all of his equipment with him; the worker did so. Ms. T. Meredith contacted Mr. Borek and informed him that she would not allow him to continue with the project. Mr. Borek repeatedly requested Ms. T. Meredith to allow him to continue with the project, but she refused. By letter dated October 9, 2003, Ms. T. Meredith terminated the Contract with ACGC. She mailed the letter on the same date and faxed it on October 14, 2003. Her mother was in agreement with terminating the Contract. Ms. T. Meredith indicated, among other things, in her letter to ACGC that its failure to complete the addition as of the date of the letter, when the oral agreement was completion within six to eight weeks, left her no choice but to terminate the Contract. Ms. T. Meredith included in the letter, among other things, what remained to be completed on the project and a cost of $539.55 for damaged items at her home caused by ACGC, with an itemized list. At the time of the termination, the following work remained to be completed: purchase and installation of plumbing fixtures; sewer hookup; molding; tile work in the bathroom; installation of storm panels and flooring; some painting; installation of an air conditioner; some electrical connections; and installation of an electrical panel, electric wall plates, and an electric light fixture. Ms. T. Meredith obtained a homeowner's permit and hired someone, Adam Friedman, to assist her in completing the addition. On December 15, 2003, the CPP issued a certificate of occupancy to her. As to expenditures by Mses. T. and J. Meredith in order to complete the addition, the undersigned finds the testimony of Mr. Yanoviak credible. Mses. T. and J. Meredith expended $19,170.52 to complete the addition. The expenditures for completion were reasonable and necessary. Not included in the expenditures for completion are the following: $3,941.31 for items not included in the Contract--a fence, pavers, wood floor, upgraded bathroom fixtures or accessories, closet woodwork and various Home Depot items (totaling $238.21); $250.00 for mill work associated with chair rails; and $2,400.00 for an exterior concrete slab. Included in the expenditures for completion is the following: $1,360.00 for a split-system air conditioning unit which was not installed by ACGC. Further, included in the cost of expenditures is an adjustment in favor of Ms. T. Meredith in the amount of $1,000.00 for the elimination of a window on the west elevation of the addition, which was orally agreed to by Ms. T. Meredith and Mr. Borek after the signing of the Contract and which would have been subtracted from the cost of the Contract. After Ms. T. Meredith terminated the Contract, she filed a claim under the Construction Industries Recovery Fund. The claim was dated October 10, 2003, one day after she terminated the Contract. Ms. T. Meredith set forth in the claim that she was requesting $12,000.00, which she indicated was the amount to pay another contractor to complete the project. The undersigned places very little weight upon the amount requested because the claim is prior to completing the project and fails to reflect the actual costs involved in completing the project, which were realized only after completion. Damage to items at Ms. T. Meredith's home occurred, during the work being performed by ACGC, for which ACGC was responsible. The following items were affected: damaged a window magnet that was part of the home's security system at $80.00; destroyed, broken, or thrown away one large planter pot, one archway, and two large stepping stones--all at an estimate of $440.34; and broken tiles in the front of the house at $13.57. The damages totaled $533.91. At the time of the hearing, Mr. Borek had not made any payments to Ms. T. Meredith or Ms. J. Meredith for their expenditures to complete the addition or for the damages. At the time of the termination, in accordance with the oral agreement of completion by on or about November 15, 2003, ACGC had a little over 30 days to complete the addition. In light of the finding that an oral agreement had been reached to allow ACGC until on or about November 15, 2003, to complete the addition and in light of the only incident since that agreement, presented by the evidence, was the situation involving ACGC's painter, the undersigned finds that the painting situation was not substantial and that, therefore, the termination on October 9, 2003, prior to the new agreed- upon termination date, was unreasonable. Ms. T. Meredith testified that, sometime during the middle of the year 2003, for a period of "exactly" 60 days, ACGC failed to perform any work at the project. Mr. Borek denies her assertion. Ms. T. Meredith testified that she kept records on everything. When she testified as to an exact 60- day period in the middle of 2003 during which no work was being done at the project, Ms. T. Meredith did not point to any of her records to verify the assertion or provide certain beginning and ending dates. Taking into consideration the standard of proof and the burden of proof, the evidence failed to show clearly and convincingly that no work was done at the jobsite by ACGC for a period of 60 days in the middle of the year 2003. Nothing was done by Ms. T. Meredith, the architect, or CPP to delay the completion of the project. Mr. Borek admits that he had other jobs in progress when he was working on the addition. He further admits that when changes had to be made to the project, whether by the CPP or the architect or Ms. T. Meredith or himself, he had to re- arrange his schedule to accommodate the other jobs, which included re-deploying his workers and subcontractors, which in turn caused delays. Further, Mr. Borek admits that the turnaround time for any changes given to the architect for the plans to the addition was reasonable and that the turnaround time for the CPP to review the changes to the plans submitted by the architect was reasonable. Consequently, no unreasonable or inordinate delays were caused by the architect or the CPP when changes were made to the plans of the addition. Mr. Borek performed some work for Ms. T. Meredith at no cost that was not required by the Contract. The extra work at no cost included the following: the removal of trees; pouring of an exterior concrete slab; and plastering of drywall. The slow progress in completing the Contract was significant and material and resulted in the Contract’s not being performed in a reasonable time. The delays in completion of the addition were significant and were the fault of Mr. Borek. In addition to re-deploying workers for other jobs on which ACGC was working, ACGC failed to properly perform work, which resulted in failed inspections by the CPP, which resulted in numerous delays, and failed to timely obtain an electrical permit. As to the failure to timely obtain an electrical permit, the electrical permit was obtained almost five months subsequent to the issuance of the building permit by the CPP. The electrical permit was applied for on March 20, 2003 and approved on March 24, 2003. CPP's turnaround time in approving the permit was short and inconsequential. As to the failure to properly perform work, the Records indicate construction defects, which were under Mr. Borek's, the contractor's, control and which resulted in failed inspections. Furthermore, the Records indicate prior construction faults, identified in inspections, not being timely corrected, which was under Mr. Borek's control and which resulted in delays until the faults were corrected. Mr. Yanoviak testified that failure to perform the Contract within a reasonable time constituted misconduct. The undersigned finds his testimony credible. A finding of fact is made that the failure to perform the Contract within a reasonable time constituted misconduct. Additionally, Mr. Yanoviak testified that the failure to perform the Contract within a reasonable time constituted a material breach of the Contract. The undersigned finds his testimony credible, and a finding of fact is made that the failure to perform the Contract within a reasonable time constituted a material breach of the Contract. Further, Mr. Yanoviak testified that, such material breach, justified terminating the Contract. The undersigned finds his testimony credible only as to a general application and, therefore, a finding of fact is made that, generally, the failure to perform a construction contract within a reasonable time would justify terminating the construction contract but does not justify terminating the Contract under the circumstances presented in the instant case. Both Mr. Borek and Ms. T. Meredith orally agreed to a new date for completion of the addition, i.e., on or about November 15, 2003. To disregard the new date of completion would be manifestly unjust. Furthermore, at the time of the termination of the Contract by Ms. T. Meredith, i.e., on October 9, 2003, the termination was unreasonable and not for just cause. Hence, a finding of fact is made that termination of the Contract by Ms. T. Meredith, prior to the new completion date, was not justified. Mr. Yanoviak also testified that failure to perform the Contract within a reasonable time constituted abandonment of the project. The undersigned finds his testimony credible only as to general application and, therefore, a finding of fact is made that, generally, the failure to perform a construction contract within a reasonable time would constitute abandonment of a project. However, as found above, a new date for completion of the project was orally agreed upon and the new date had not expired at the time of the termination of the Contract by Ms. T. Meredith. Hence, a finding of fact is made that, under the circumstances of the instant case, abandonment did not exist. The Department presented evidence of costs for the investigation and prosecution of this matter, excluding costs associated with attorney time. As of July 5, 2005, the costs for the investigation and prosecution totaled $880.18. As to prior disciplinary action, on September 9, 2004, the Department filed a Final Order in Department of Business and Professional Regulation vs. Bret Jayson Borek, Case No. 2003-069533, License No. CG Co58817 before the Construction Industry Licensing Board. In that case, an administrative complaint was filed against Mr. Borek for violating Section 489.129(1)(i), Florida Statutes (2001), by failing to comply in a material respect with a provision of Chapter 489, Florida Statutes, through the failure to obtain a certificate of authority for ACGC; and for violating Section 489.129(1)(q), Florida Statutes (2001), by failing to satisfy a civil judgment, related to the practice of construction, within a reasonable time. Mr. Borek waived his rights to an informal hearing, and no material fact was disputed. Among other things, the Final Order imposed an administrative fine of $1,000.00, required restitution of $15,218.94 to a roofing and sheet metal company and required payment of $506.92 for investigative costs.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order: Finding that Bret Jayson Borek committed the violations set forth in Counts I, II, and III; Dismissing Count IV; and Imposing the following penalties: As to Count I, an administrative fine in the amount of $1,000.00 and revocation of the license of Bret Jayson Borek. As to Count II, an administrative fine in the amount of $500.00. As to Count III, an administrative fine in the amount of $5,000.00 and revocation of the license of Bret Jayson Borek. S DONE AND ENTERED this 9th day of January, 2006, in Tallahassee, Leon County, Florida. _______________________________ ERROL H. POWELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 9th day of January, 2006.
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, the arguments of counsel and the entire record compiled herein, the following relevant facts are found. Based on an Administrative Complaint filed on July 6, 1979, the Florida Construction Industry Licensing Board (herein sometimes referred to as the Petitioner or the Board) seeks to take disciplinary action against Licensee Richard E. Ulbricht, d/b/a Ulbricht Construction, Inc., and to impose an administrative fine or $500.00. Respondent is a registered contractor who holds the following licenses: RG 0011921 - Registered General/Active/Issued RGA 0011921 - Registered General/Active/Issued RG OB 11921 - Registered General/Delinquent RM 0014920 - Registered Mechanical/Active/Issued RM 0017586 - Registered Mechanical/Delinquent RS 0019201 - Registered Sheet Metal/Active/Issued RC 0019264 - Registered Roofing/Active/Issued Respondent was first licensed by the Petitioner during February, 1972. On June 14, 1977, Respondent qualified Ulbricht Construction, Inc., as the business entity through which he would conduct his contracting business. The construction activities involved herein took place in the City of Palm Bay, Florida. Palm Bay has no local licensing board. On June 12, 1978, Respondent entered into a contract with Michael D. and Karen K. McCammack to construct a residence for the sum of $39,900.00. Respondent received the full contracted price and the transaction closed on January 4, 1979. Chelsea Title and Guaranty Company closed the transaction for Respondent and the McCammacks on January 4, 1979. Camille Guilbeau is the manager for the Palm Bay branch of Chelsea Title and Guaranty Company. Ms. Guilbeau is in charge of all closing and as such ensures that all outstanding obligations of record are paid. In keeping with Chelsea's policy of protecting itself in the event of outstanding unrecorded claims of liens, Chelsea has a policy of requiring contractors and builders such as Respondent to declare in an affidavit that there is no outstanding work which has been performed, or labor or materials for which a lien could be filed on property in which Chelsea is closing the mortgage transaction. Respondent executed such an affidavit relative to the McCammacks' property, which Chelsea relied on to close the transaction on January 4, 1979 (Petitioner's Exhibit 4). On January 4, 1979, Chelsea Title and Guaranty Company paid Rinker Materials Corporation of Melbourne, Florida, $1,201.02 based on a claim of liens filed December 15, 1978, for materials consisting of concrete block, steel and miscellaneous items which were used on the McCammack property (Petitioner's Exhibit 6). Subsequent to the date of closing, January 4, 1979, liens amounting to approximately $2,761.62 have been filed against the McCammack property based on Respondent's failure to pay bills for labor and/or materials used in connection with the construction of the McCammacks' residence. These lien claims were filed against the McCammacks' property for a drilled well, installation of a pump and tank by Perry and Leighty, Inc., of Melbourne, Florida; two septic tanks, drains and sand supplied by Pence South Brevard Sewer and Septic Tank of Melbourne, Florida (Petitioner's Exhibits 7, 8 and 9). On December 22, 1978, Respondent entered into a contract with Robert J. Greene to construct a residence for $30,500.00 in Palm Bay, Florida. Respondent filed an affidavit of no liens relative to the Greene property on January 10, 1979. Chelsea Title and Guaranty Company relied on this affidavit to close the Greene property transaction on January 10, 1979 (Petitioner's Exhibit 5). Respondent was paid thee entire contract price. On February 12, 1979, Pence South Brevard Sewer and Septic Tank filed a claim of lien in the amount of $1,015.36 for two septic tanks, drains and sand which had been furnished the Respondent for the property of Robert J. and Alice Greene of Palm Bay, Florida, on December 15, 1978 (Petitioner's Exhibits 10 and 11). Approximately $3,496.40 was retained by Chelsea Title and Guaranty Company to satisfy outstanding recorded obligations on the date the Greene transaction closed (Petitioner's Exhibit 13). On February 21, 1979, Respondent caused to be filed in the United States District Court of the Middle District of Florida, a Voluntary Petition for Bankruptcy for Ulbricht Construction, Inc. (Petitioner's Exhibit 2 Composite).
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED: That the Respondent's contractors licenses set forth hereinabove be REVOKED. RECOMMENDED this 6th day of May, 1980, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 6th day of May, 1980.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are made: At all times material to this proceeding, Respondent Wilmon Ray Stevenson was licensed as a registered building contractor in the state of Florida, holding license numbers RB 0035005 and RB A035005. License number RB 0035005 was issued on an active status qualifying an Individual in March 1987 and is still in effect. License number RB 0035005 replaced license number RR 0035005 issued in December, 1980. License number RB A035005 was issued on an active status qualifying Yankee Construction, Inc. d/b/a Olympic Homes of Citrus County (Olympic) in June 1987 and replacing license number RR A035005 issued in August 1981. In October, 1988 Respondent submitted a change of status application which was not acted upon by Petitioner until February, 1989 when it was deleted. However, Petitioner's file (Petitioner's Exhibit 1, page 2) indicates the license was in effect only until October, 1988. The Marion County Building Department was advised of this status change in September, 1988. Findings As To Case No. 90-1637 On April 16, 1988, Frank and Margaret Orkwis entered into a contract with Olympic to construct a home for $37,900 which was later modified, increasing the contract price to $39,363.00. On July 26, 1988 a permit for the Orkwis job was obtained from the Marion County Building Department in accordance with the Respondent's letter dated January 25, 1985 authorizing certain individuals to "pull" permits on his license. There was a total of $27,583.20 paid to Olympic on the Orkwis contract which included $27,483.20 paid by draw schedules and $100.00 as a down payment. Olympic stopped work on the Orkwis home sometime around November 27, 1988 and failed to complete the work under the contract. Olympic gave no notice to Orkwis that it intended to terminate the work on the Orkwis job. In fact, Olympic kept putting Mrs. Orkwis off about completing the job until sometime in late January, 1989 or early February, 1989 when she decided to get a permit and complete construction. Olympic terminated the Orkwis job without just cause. The following liens were recorded against the Orkwis property for the failure of Olympic to timely pay for materials and labor furnished to Olympic for the Orkwis's job in accordance with Orkwis contract: (a) Florida A/C Sales and Services, Inc., filed December 13, 1988 and; (b) Florida Forest Products, Inc. filed December 15, 1988. The labor and materials had been furnished between October 24, 1988 and November 22, 1988. Olympic was contacted by Mrs. Orkwis concerning the liens, with no response. However there was insufficient evidence to establish that the liens had not been removed from the property, by payment or bond, within 30 days after the date of such liens. Sometime in early 1989, Mrs. Orkwis obtained a permit and she and her husband completed the home. Although Mr. Orkwis had obtained an estimate of $27,050.00 from a contractor to complete the home, she and her husband invested 466.5 hours of their time and $10,340.00 for materials to complete the home. In addition to the material, a reasonable amount for labor to complete the home would be $10,000.00. Findings As To Case No. 90-1889 John J. and Josephine Grillo and Madeline Chapman entered into a contract with Olympic for construction of a home on June 11, 1987. A permit was obtained for the Grillo/Chapman home under Respondent's license. The Grillo/Chapman home was completed and a certificate of occupancy issued January 13, 1989. Olympic was paid in full under the contract. Before the expiration of the one-year warranty under the contract, Olympic was advised of certain problems with the construction which Olympic attempted to correct. It is unclear whether the problems were satisfactorily corrected by Olympic but it appears that the only complaint not resolved was a water stain on the carpet that was the result of water seeping in under a door. Respondent was not aware of these problems until after the expiration of the one-year warranty and upon learning of the problems, commented that he was not obligated since the warranty had expired. There was insufficient evidence to establish that the problems were not corrected in accordance with contract. Findings As To Case No. 90-1890 Veronica McPherson entered into a contract with Olympic on March 1, 1989 to construct a home for the contract price of $36,450.00 which was later modified increasing the contract price to $37,775.00. All permits were obtained under the Respondent's license pursuant to a letter dated January 15, 1985 authorizing certain individuals to "pull" permits under Respondent's license. McPherson paid $26,442.50 to Olympic pursuant to a draw schedule in the contract as the home was being constructed. Additionally, McPherson paid a $100.00 down payment. All work performed by Olympic pursuant to the McPherson contract was prior to November 22, 1988. The exact date of termination of work is uncertain. Olympic notified McPherson that it had terminated work and would not complete construction of the home. The exact date of this notification is uncertain. There is no evidence that notice was not given within 90 after termination of work. Olympic terminated work without just cause. McPherson paid a roofing contractor $998.00 to complete the roof on her unfinished home in order to protect the interior. McPherson was financially unable to complete construction of the home. A reasonable estimate to complete construction of the McPherson home at the time work ceased would be $20,000.00. On December 15, 1988 Florida Forest Products, Inc. recorded a lien on December 15, 1988 against the McPherson property for building materials furnished to the McPherson job on order of Olympic on October 24, 1988 for construction of the home pursuant to the McPherson contract in the amount of $1,450.08. There was insufficient evidence to establish that this lien had not been removed from the McPherson property, by payment or bond, within 30 days after the date of such lien. There were three other claims of liens for labor and materials furnished to the McPherson job on order of Olympic between October 19, 1988 and December 2, 1988 for construction for the home pursuant to the McPherson contract as follows: (a) Florida A/C Sales and Services, Inc. dated December 8, 1988 for $1,059.00; (b) Masons Concrete of Crystal River dated December 14, 1988 for $354.97 and (c) Panning Lumber Company, a Division of Wheeler Consolidated, Inc. for $2,284.13. There is no evidence that any of the above liens were ever recorded against the McPherson property. Likewise, there is no evidence to establish that these liens had not been removed from the McPherson property, by payment or bond, within 30 days after the date of such lien, if in fact they were recorded. General Findings Respondent was advised by Larry Vitt in February, 1988 that Olympic was having financial problems. Respondent never supervised the financial aspects of Olympic. Respondent did not participate in the contract process or supervision of the construction of homes contracted to be built by Olympic. More specifically, he did not participate in the contract process or the supervision of the construction of the Orkwis, McPherson or Grillo/Chapman homes. Respondent's main purpose in being involved with Olympic was to use his license to qualify Olympic and to contract all of Olympic's concrete block work. In March, 1989 Respondent advised the Marion County Building Department that no one was authorized to "pull" permits under his license. However, at no time did Respondent withdraw the permits for the Orkwis and McPherson jobs that had been issued under his license. The record is clear that Respondent did not understand his relationship with Olympic nor did he understand the responsibility he incurred when he used his license to qualify Olympic. However, his inexperience or ignorance in this regard does not relieve him of his responsibility to those whose homes were built or not completely built pursuant to a permit issued under his license.
Recommendation Having considered the foregoing Findings of Facts and Conclusions of Law, the evidence of record, the demeanor of the witnesses and the disciplinary guidelines set out in Chapter 21E-17, Florida Administrative Code, it is RECOMMENDED: That the Board enter a final order finding Respondent guilty of violating Section 489.129(1)(k) and (m), Florida Statutes, and for such violations it is Recommended that the Board assess the Respondent with an administrative fine of $2,500.00. It is further Recommended that Counts I and II for the Administrative Complaint in Case Nos. 90-1637, 90-1889, and 90-1890 be Dismissed. DONE and ORDERED this 24th day of October, 1990, in Tallahassee, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 24th day of October, 1990. APPENDIX TO RECOMMENDED ORDER IN CASE NO. 90-1637 The following constitute my specific rulings pursuant to Section 120.59(20, Florida Statutes, on all of the proposed findings of fact submitted by the parties in this case. Rulings of Proposed Findings of Fact Submitted by the Petitioner 1. Covered in Conclusions of Law. 2.-8. Adopted in Findings of Fact 1, 2, and 3. 4.-6. Adopted in Findings of Fact 15, 16, and 17, respectively. 7. Adopted in Findings of Fact 19 and 20, but modified. 8.-12. Adopted in Findings of Fact 18, 4, 5, 6, and 8, respectively. 13.-14. Adopted in Findings of Fact 9 and 10, respectively, but modified. Adopted in Findings of Fact 21 through 25. Restatement of testimony; not stated as a Finding of Fact but see Findings of Fact 10 and 14. Adopted in Findings of Fact 13 through 15. Adopted in Findings of Fact 16, but modified. Rulings of Proposed Findings of Fact Submitted by Respondent 1. Covered in Preliminary Statement. 2.-8. Adopted in Findings of Fact 1, 2, 3, 3, 15, 15, and 16, respectively. 9. Adopted in Findings of Fact 19 and 20. 10.-11. Adopted in Findings of Fact 18 but modified. Adopted in Finding of Fact 4. Adopted in Findings of Fact 4 and 6. Adopted in Finding of Fact 5. Adopted in Findings of Fact 8 and 9. 16.-20. Adopted in Findings of Fact 7, 7, 11, 13 and 14, respectively, but modified. Not material. Adopted in Finding of Fact 3, but modified. Not material. Copies furnished to: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32202 Kenneth E. Easley, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 G. W. Harrell, Esquire Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, FL 32399-0792 Fred A. Ohlinger, Esquire P.O. Box 1007 Beverly Hills, FL 32665
Findings Of Fact At the final hearing the following factual allegations contained in the Administrative Complaint were either stipulated to by the parties or not disputed by the Petitioner: The Respondent John W. Rohrback is a certified general contractor having been issued license numbers CC C002372, CG CA 02372, PM 0015083 and RF 0036563. The last known address of the Respondent Rohrback is 10282 N.W. 31st Street, Coral Springs, Florida 33065. The Respondent Rohrback, while doing business as Statewide Insulation and Solar Systems, Inc., failed to initially obtain building permits which are required by ordinance on the following job sites: Mrs. Blanche Nelson, 454 N.E. 4th Street, Boca Raton. Mrs. Dorothy Menzel, 784 N.E. 71st, Lot 27, Block C, Boca Harbor. Work started May 17, 1980. Permit taken out on May 19, 1980. Mrs. Meinhard, 1230 S.W. 7th Street, Lot 6, Block 29, Boca Raton Square. Work started on May 7, 1980. Permit taken out on May 19, 1980. Ms. Mary Greenhauer, 986 S.W. 14th Street, Lot 20, Block 63, Boca Raton Square. Work started on May 3, 1980. Permit issued on May 19, 1980. Although the Respondent Rohrback eventually received the permits for these projects, he also initially failed to obtain a license to do contracting in the City of Boca Raton as required by ordinance. On or about August 11, 1980, the City of Boca Raton Contractor's Board suspended the Respondent Rohrback indefinitely from doing business in the city for: using alternate materials and methods without clearance; not obtaining building permit; not filing a proper permit; and not filing proper proof of a certificate of competency. At the time of the hearing before the local contractor's board, the Respondent Rohrback had settled and obtained releases with two of the listed individuals. He was told to settle the remaining two cases, obtain releases and appear before the local Board at a later date. The Respondent appeared on the designated date and discovered that the Board had met the previous day and suspended his license. The Respondent Rohrback contacted the Boca Raton city attorney and a representative of the Department to present the signed releases and cancelled checks he eventually obtained from the four listed individuals in order to obtain a reversal of the local Board's action suspending his license. At the time of hearing, the Respondent had been unsuccessful in obtaining a reversal of the Board's decision. Additionally, the Respondent Rohrback acted as qualifying agent for D.R.K. Company from July 1, 1979 through February 1981. During this period of time, D.R.K. utilized deceptive practices in order to obtain contracts from various individuals. By certified letter dated June 12, 1980, the Respondent informed D.R.K. and pertinent licensing boards that he was withdrawing as qualifying agent for D.R.K. and Statewide Insulation and Solar Systems, Inc., and revoking any presigned permits or letters of authorization that may have been signed by John W. Rohrback. However, the Respondent did not actually attempt to revoke his authorization until October 28, 1980, when a letter was sent to Milton Rubin, administrative assistant to the Florida Construction Industry Licensing Board, outlining the problems he had encountered with D.R.K. and Statewide. On or about February 19, 1981, the Lee County Board of County Commissioners suspended the Respondent Rohrback's privilege to pull building permits.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That a Final Order be entered dismissing the Administrative Complaint filed against the Respondent John W. Rohrback in Case No. 82-2616. DONE and ORDERED this 28th day of March, 1983, in Tallahassee, Florida. SHARYN L. SMITH, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 28th day of March, 1983. COPIES FURNISHED: Michael J. Cohen, Esquire Suite 101 Kristin Building 2715 East Oakland Park Blvd. Fort Lauderdale, Florida 33306 John W. Rohrback 10282 Northwest 31st Street Coral Springs, Florida 33065 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
