The Issue Whether Respondent committed the offenses set forth in the administrative complaint and, if so, the penalty which should be imposed.
Findings Of Fact At all times material to this case, the Respondent, Harry Bradshaw, was licensed as a registered roofing contractor in the State of Florida, holding license number RC 0033812. On August 26, 1986, Respondent's license as a registered roofing contractor was suspended by Petitioner. Respondent's license remained suspended at all times material to this case. On December 16, 1987, Respondent contracted with the Moose Lodge located in Hialeah, Florida, to reroof the Moose Lodge building. The proposal submitted by Respondent contained representations that Respondent was licensed as a registered roofing contractor and that he was insured. Respondent knew that his license as a registered roofing contractor was under suspension. Respondent had no insurance. The contract between Respondent and the Moose Lodge provided that Respondent would perform the work and supply the materials for the sum of $6,200.00. The sum of $3,200.00 was paid to Respondent in advance of his beginning the job. Respondent used the sums advanced to purchase materials and supplies. The remaining $3,000.00 was to have been paid upon Respondent's completion of the job. During the negotiations that resulted in the contract between Respondent and the Moose Lodge, Respondent represented that the job should be completed in time for the functions scheduled for New Year's Eve. While Respondent had purchased the materials needed for the job and had done a substantial amount of work on a portion of the roof, he was unable to complete the work by the New Year. Respondent was ordered to stop work on the job on January 26, 1988. Respondent did not abandon the job. Although he was slow in performing the work, a part of Respondent's delay in performance was caused by rain. There was no evidence as to what would have been a reasonable period of time for Respondent to have completed the job. On January 26, 1988, the administrator for the Moose Lodge complained to the Building Inspection Department for the City of Hialeah, Florida, because the administrator was not pleased with the progress that Respondent was making toward completion of the job. The administrator was told by a representative of the Building Inspection Department on January 26, 1988, that Respondent had no license and that the required permit had not been pulled. The administrator was told to prohibit Respondent from working on the roof. Immediately thereafter, the administrator instructed Respondent to do no further work on the roof. The members of the Noose Lodge completed the job started by Respondent for less than $3,000.00, the balance of the amount that would have been owed Respondent if he had finished the job. Respondent knew that a permit was required for this work. Respondent also knew that only a licensed roofing contractor could pull the required permit. Respondent proceeded with the job when he was unable to persuade a licensed roofing contractor to pull the permit for him. Petitioner filed an administrative complaint against Respondent alleging that at the time he contracted with the Moose Lodge, Respondent's license was suspended, thus violating the provisions of Section 489.129(1)(j), Florida Statutes, and the provisions of Section 489.127(1)(e), Florida Statutes. The administrative complaint also alleged that Respondent failed to perform in a reasonably timely manner and/or abandoned the job in violation of Section 489.129(1)(m), Florida Statutes, and Section 489.129(1)(k), Florida Statutes. Respondent denied the allegations of the administrative complaint and timely requested a formal hearing. This proceeding followed. Respondent was previously disciplined by the Construction Industry Licensing Board, and his license remained under suspension at the time of the final hearing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated Section 489.127(1)(e), Florida Statutes, and Section 489.129(1)(j), Florida Statutes. It is further recommended that the final order revoke Harry Bradshaw's license in the State of Florida as a registered roofing contractor. DONE and ENTERED this 31st day of October, 1989, in Tallahassee, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 1989. COPIES FURNISHED: Harry Bradshaw 5590 East Seventh Avenue Hialeah, Florida 33013 David M. Gaspari, Esquire Adams, Coogler, Watson & Merkel, P.A Suite 1600 NCNB Tower 1555 Palm Beach Lakes Boulevard West Palm Beach, Florida 33402-2069 Kenneth E. Easley, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
The Issue The issue for determination is whether Respondent, licensed as a registered roofing contractor, certified roofing contractor, and certified building contractor, committed various violations of Chapter 489, Florida Statutes, sufficient to justify the imposition of disciplinary sanctions against his licenses.
Findings Of Fact Respondent is Joseph H. Rayl, holder, at all times pertinent to these proceedings, of registered roofing contractor license no. RC 0034055; certified roofing contractor license no. CC C035625; and certified building contractor license no. CB C033206. Petitioner previously disciplined Respondent's license RC 0034055 through the imposition of a $250 fine by order dated July 11, 1985; and Respondent's license CB C033206 by suspension of license for six months and imposition of a fine of $2,500. Petitioner also found probable cause for three cases in 1987 that were closed with letters of guidance to Respondent. Petitioner is the Department of Professional Regulation, Construction Industry Licensing Board, the state agency charged with the regulation of contractors in the State of Florida. Respondent was the qualifying agent for Unique Construction, Inc., (Unique) at all times pertinent to these proceedings. Further, Respondent has been the qualifying agent for Superior Roofing & Construction Inc., (Superior) since February, 1988. On June 19, 1984, Mary Lois Brining, owner of a day care center for children known as Town and Country Schools of Bradenton in Manatee County, Florida, entered into a contract with Respondent to reroof the day care center. Respondent's personnel arrived at the school and removed the roof. Heavy rainfall then caused extensive damage to the interior of the facility and Brining complained to Unique. A representative of the company assured her that the situation would be resolved. Brining later paid Unique $623 to paint the school's interior, in addition to the cost of the roof replacement. While Respondent was never present during the construction, his workmen finished the roofing project on June 26, 1984. When leaks to the roof developed after completion of the job, Brining advised Unique of the leakage on numerous occasions. No action was taken by Respondent or Unique in response to Brining's telephone calls about the roof's leakage. Water leakage also damaged the carpet in Brining's facility, which she replaced at a cost of $2,000. In 1988, Brining finally hired another roofing company to correct the roof leakage. Helen M. Hayes, a resident of Gulfport, Florida, contracted with Unique to reroof the flat portion of the roof to her home on April 12, 1984, for a sum of $2,890. The job was finished on April 15, 1984. Two days later, the roof leaked. Hayes advised Unique and a representative came to the house and attempted to stop the leaks. After every rain, the roof leaked and Hayes would advise Unique. She never saw or spoke with Respondent. Finally, after 22 contacts with the company over a period of two and a half years, Hayes contacted local government building authorities. The building inspector for the City of Gulfport inspected the roof and told the company to replace it. Unique's workmen removed the roof in July, 1986, and left the house uncovered. That same day 10 inches of rain fell in the area of the residence, resulting in extensive damage to the home's interior and clothing which Hayes had stored in the home. Hayes called the police. The police called the building inspector who, in turn, called the roofing company. On July 28, 1986, Unique completed replacing the roof on Hayes' house. That new roof still leaks, the floor to the house is cracked from the leakage, the carpet has been saturated with water, plaster from the ceiling is falling to the floor, and there are water stains on the ceiling and walls throughout the residence. The proof further establishes that the City of Gulfport, located in Pinellas County, Florida, retained a private contractor to conduct an inspection of Hayes' roofing job in July of 1986. That inspection established that the roof should be replaced with a roof complying with building code requirements. Notably, while Unique obtained permits for the job, no final inspection of the project was ever obtained by Respondent's company in accordance with the Southern Building Code adopted as an ordinance by the City of Gulfport. James Oliver Prince is a resident of Lake Hthchineha, a settlement located in Polk County, Florida. He has never met Respondent. Prince entered into a contract with Unique in September of 1985. The reroofing job was completed on or about September 26, 1985. Leaks developed with the onset of the first rain after the completion of the job. Prince notified Unique and a representative came out to the residence to attempt to repair the roof and stop the leaks. This procedure continued on numerous occasions until November of 1987 when Prince attempted to contact Unique regarding the roof's leakage only to be informed that the telephone had been disconnected. Prince tried to locate Unique at the various offices listed on his contract, but received no answer. Eventually, due to the seriousness of the leaks and his inability to contact Unique, Prince hired a carpenter and replaced the roof at a cost of approximately $6,000. As established by testimony of Charles Fant, fire chief and building official for the City of Treasure Island, Florida, Unique obtained a construction permit for a reroofing job for the home of Vincent Ferraro located at 62 North Dolphin Drive in that city. The city has adopted the Southern Building Code as a city ordinance. However, the company never obtained the required final inspection for that job as required by the building code. On August 13, 1986, Carl and Ludie Buice of Bellview, Florida entered into a contract with Unique for a reroofing job on their home. Carl Buice passed away in November of 1986 Later, their son assisted Ms. Buice when leaks developed in the roof by attempting to contact the roofing company. The son, Alfred Buice, was unable to contact Unique. He then contacted the local offices of the Better Business Bureau; thereafter a representative of Superior, Respondent's successor company to Unique, came to the Buice residence on or about May 25, 1988, and gave Alfred Buice a check for $200 in connection with money previously spent by Buice to repair leaks to the roof. Even after repairs, the roof continued to leak to the point that it began to cave in around the roof's edges. Eventually, Alfred Buice had his mother's residence reroofed by another contractor on March 21, 1989, for $5,800. Testimony of Petitioner's expert witness establishes that Respondent was grossly negligent in meeting his qualifying agent responsibilities to supervise financial activities and construction practices of Unique. Further, Respondent's subordinates, who actually carried out roofing activities, performed those tasks incompetently. Respondent failed to comply with existing construction industry practices to inspect jobs where successive complaints were lodged by customers.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that a Final Order be entered revoking Respondent's licenses as a registered roofing contractor, certified roofing contractor, and certified building contractor. DONE AND ENTERED this 7th day of July, 1989, in Tallahassee, Leon County. Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 7th day of July, 1989. APPENDIX The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by the parties. Petitioner's Proposed Findings. 1.-42. Addressed. Respondent's Proposed Findings. None submitted. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, Florida 32399-0750 William E. Whitlock, III, Esquire 320 West Park Avenue Tallahassee, Florida 32301 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Kenneth E. Easley, Esquire Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, Florida 32399-0750
The Issue Whether Respondent's registered roofing contractor's license should he revoked, suspended or otherwise disciplined based on charges that he violated Ch. 455, Florida Statutes (1979), by (1) abandoning a construction project; making a misleading, deceptive or untrue representation in the practice of his profession; (3) violating local building codes in two instances; and (4) engaging in the business of contracting in a county or municipality without first complying with local licensing requirements.
Findings Of Fact At all times material hereto, respondent held registered roofing contractor's license, number RC 0033215, issued by the State of Florida. The license has been in a delinquent status since July 1, 1981. (Petitioner's Exhibit 1). Between October 1, 1979, and September 30, 1980, respondent held an occupational license issued by the County of Indian River, Florida, which enabled him to engage in the business of roofing contracting in that county. However, this occupational license expired on September 30, 1980. (Petitioner's Composite Exhibit 9). In February, 1981, respondent entered into a verbal agreement with Ezra Grant to repair, for compensation, all leaks in the front and rear sections of the roof on Grant's home, which was located in Sebastian, Florida. (Testimony of Grant). When respondent and Grant entered into this verbal agreement, respondent gave Grant one of his calling cards. On the face of the calling card, in the lower right corner, was written "licensed and insured." (Petitioner's Exhibit 4; Testimony of Grant). At all time material hereto, respondent was not licensed to engage in the business of roofing contracting in the City of Sebastian, Florida. (Petitioner's Exhibit 5). Pursuant to the agreement, respondent performed roof repairs on Grant's home. (Testimony of Grant). Respondent failed to obtain a permit to perform such roof repairs in violation of Section 105.1, Standard Building Code, as adopted by the City of Sebastian, Florida in Section 7-16, Article II, Sebastian Code of Ordinances. (Petitioner's Exhibits 6 and 8a and b). On February 19, 1981, respondent submitted a bill in the amount of $800.00 to Grant for the roof repairs. The bill described the work performed and stated that the "work is guaranteed for 1 year." (Petitioner's Exhibit 2; Testimony of Grant). On February 20, 1981, Grant paid respondent, in full, for the described roof repairs. (Petitioner's Exhibit 3). Approximately two weeks after respondent performed the roof repairs, the roof over the rear portion of Grant's home began to leak, again, in the area where it was repaired. (Testimony of Grant). Respondent returned to Grant's home, on two occasions1 after the discovery of continuing leakage in the roof over the rear portion of Grant's home. However, respondent did not perform roof repairs on either occasion. On the first occasion, he merely removed equipment which he had left at Grant's home. (Testimony of Grant). After Grant complained to petitioner Department of Professional Regulation, respondent returned a second time. He inspected the rear portion of Grant's roof, removed two layers of slate from the roof, and tested it by pouring water over it. Although this test revealed that Grant's roof still leaked, Grant made no effort to repair the leakage. (Testimony of Grant). Arthur Mayer, then the Building Official for the City of Sebastian, observed respondent removing the slate from the roof. He instructed respondent that, upon finishing the work, he should go to the Sebastian City Hall and apply for a roofer's license and a permit for the roof repairs already performed on Grant's home. Respondent promised to comply. (Testimony of Mayer). But, despite his promise, he failed to apply for and obtain a license to engage in the business of roofing contracting in the City of Sebastian, Florida. He also failed to apply for and obtain a roof permit, and pay the proper late fees, as required by Section 107.2, Standard Building Code, as adopted by the City of Sebastian, Florida, in Section 7-16, Article II, Sebastian Code of Ordinances. (Testimony of Mayer; Petitioner's Exhibits 6, 8a and c). Grant, eventually, had his roof repaired by another contractor at a cost of $150.00. (Testimony of Grant).
Recommendation Based on the foregoing, it is RECOMMENDED: That respondent's registered roofing contractor's license be revoked. DONE AND ORDERED this 28th day of February, 1983, in Tallahassee, Florida. R. L. CALEEN, JR. Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 28th day of February, 1983. COPIES FURNISHED: Stephanie A. Daniel, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Jerry E. Smith Route 1, Box 111B Fellsmere, Florida 32948 James Linnan, Executive Director Construction Industry Licensing Board P. O. Box 2 Jacksonville, Florida 32202
The Issue The issue for consideration in this case is whether Respondent's certification as a roofing contractor in Pinellas County should be disciplined because of the matters alleged in the Administrative Complaint filed herein.
Findings Of Fact At all times pertinent to the issues herein, Petitioner, Pinellas County Construction Licensing Board, was the county agency responsible for certifying the competence of practitioners in the construction trades in Pinellas County, and for the regulation of the construction industry in that county. Respondent was certified as a roofing contractor by Petitioner under certificate number C-7779 (RC0067087). On April 19, 1999, Vivian P. Campbell, representative of the Bay Pines Apartments Unit Four Association (Association), a condominium association which owns the apartment building at 4600 98th Way, North in St. Petersburg, executed a proposal by Respondent to perform roofing services at the facility for a contract price of $39,050.00. The proposal, accepted by the Association, called for Respondent to install insulation board to existing deck after sweeping away all rock and debris; to install other material; to reseal all gutters and install rain diverters; and to install wood nailers for all perimeters of the roof. No completion date was established or stated in the agreement. The contract called for a complete price of $39,050 for the work but no time for completion was mentioned in the document. Within the first 30 days of signing the contract, the Association made two payments to Respondent; one on April 19, 1999, in the amount of $9,000, and another on May 13, 1999, in the amount of $4,000, for a total of $13,000. On May 3, 1999, Respondent removed some gravel from the roof. Respondent also caused some materials to be delivered to the site, erected a sign identifying himself as the contractor, and installed a porta-pottie at the site. However, aside from the initial gravel removal, Respondent did little more roof work than was called for in the contract. On June 20, 1999, he repaired one of several leaks in the building roof, but that repair was a small part of the contract work. All attempts by the Association and the apartment manager to contact Respondent were unsuccessful. As a result, the Association contacted its attorney who wrote to Respondent on July 6, 1999, demanding he commence work within five days of the letter or the contract would be considered terminated. Respondent did not do so. However, on July 26, 1999, he wrote to the building manager, apologizing for being slow in starting the work, and offering to deduct $5,000 from the contract price if he could start work. As a result of this letter, the building manager met with Respondent on August 21, 1999, to re-negotiate the contract. At this meeting, the parties agreed that Respondent would do the work for an additional $11,000 beyond the $13,000 which had already been paid to him. The additional funds were to be paid in two installments; one on August 19, 1999, and one on August 27, 1999. A contract incorporating those terms was drawn up and forwarded to Respondent for his signature but he did not sign the amended contract, did not do any of the work called for in the contract, and did not return any of the funds paid to him under the contract. On October 29, 1999, Ms. Campbell met with Respondent and the consumer protection offices of Pinellas County of the Circuit Court. At this meeting, Respondent volunteered to pay back all sums he had received for the work he had agreed to do. He left the meeting room, promising to return with the money within one hour. The other parties went to lunch, and while they were having their meal, Respondent called the consumer protection officer and related he could not raise the money he had promised. There was no further contact from Respondent from that point until the hearing. Respondent admits that a majority of the complaint of the Association is true. He contends, however, that the delay in starting work was due to the need to obtain the necessary materials for the job and the heavy rains which occurred during the period in question. This was a completely flat roof which had no pitch to it at all and Respondent claims he could not install the new roof if there was any standing water at the site. Respondent also agrees there was a meeting with the building manager during which he indicated his desire to go ahead with the work, but contends he wanted a statement in the supplemental agreement to the effect his license would not be revoked. Any decision on the issue of Respondent's licensure was not within the authority of the Association, which had no authority to bind the licensing officials to any particular disciplinary decision. Respondent also contends he had planned to make the agreed reimbursement payment worked out by the consumer protection officer but could not do so because he was not paid for another job. Then, he contends, before the second payment was due, he was advised of the filing of the disciplinary complaint against his license. When that happened he decided not to pay back any funds as long as discipline was being taken, regardless of what he did. Respondent's defenses are unpersuasive. The amount of work done by Respondent on the contract was far less than the percentage of payment he received under the contract.
Recommendation Based on the foregoing Findings of Facts and Conclusions of Law, it is RECOMMENDED: That the Pinellas County Construction Licensing Board enter a final order in this case directing Respondent to reimburse Bay Pines Apartment Unit Four Association all funds paid by it to him for work not accomplished as called for in the contract between them on April 19, 1999; that it revoke Respondent's certification as a roofing contractor in Pinellas County but suspend the execution of the revocation upon Respondent's full and complete repayment; and that it place his certification on probation for a period of one year. DONE AND ENTERED this 12th day of April, 2000, in Tallahassee, Leon County, Florida. ARNOLD H. POLLOCK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 12th day of April, 2000. COPIES FURNISHED: William J. Owens, Executive Director Pinellas County Construction Licensing Board 11701 Belcher Road, Suite 102 Largo, Florida 33773-5116 Raymond J. Mowery, Jr. Post Office Box 60002 St. Petersburg, Florida 33714
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, the following relevant facts are found. Jesse Bruce, Respondent herein, is a registered roofing contractor and has been issued license No. RC0022948. On September 2, 1981, Respondent entered into a contract to repair a roof at 3684 NW 29th Street, Lauderdale Lakes, Florida, for Ms. Beryl Babb for the sum of $485.00. Respondent admits that he commenced construction under the above-referenced contract without first having obtained a building permit. Respondent was paid in full under the contract by Ms. Babb on September 4, 1981. Pursuant to the terms of the construction contract, Respondent provided for a two-year warranty on the roof repairs. Within an approximate two-month period following the repairs by Respondent, Ms. Babb made repeated phone calls to Respondent's construction company to report complaints that she was having in that the roof and garage appeared to "leak more than it had leaked prior to the repairs." Ms. Babb made at least six telephone calls to Respondent's construction company to no avail. During November, 1981, Ms. Babb filed a civil complaint in small claims court and during January, 1982, Ms. Babb received a judgment against the Respondent for $300.00. 1/ Respondent ahs been a licensed and registered roofing contractor since October, 1974. Respondent acknowledged that he received complaints from Ms. Babb as was testified herein; however, he states that he was busy during the times in which the complaints were made, an further that he did not want to make repairs inasmuch as Ms. Babb had elected to file a civil complaint against him in small claims court. Finally, Respondent acknowledged that he was obliged to return tot he Babb residence to make the repairs inasmuch as the complaints from Ms. Babb came during the two-year period in which the warranty for the roof repairs was in effect.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Respondent be placed on probation for a period of six (6) months. 3/ RECOMMENDED this 3rd day of February, 1983, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of February, 1983. COPIES FURNISHED: Michael J. Cohen, Esquire Suite 101, Kristin Building 2715 E. Oakland Park Blvd. Ft. Lauderdale, Florida 33306 Jesse Bruce 721 NW 20th Ave. Ft. Lauderdale, Florida 33311 Mr. James Linnan Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact At all times relevant thereto, Respondent, Ronald E. Lotz, held registered roofing contractor license number RC0031773 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He has been a licensed roofing contractor since February, 1978. His present address is 1650 Palm Avenue, Winter Park, Florida. In April, 1979 Lotz and Allen Hartwell entered into a contract whereby Lotz agreed to install a "new truss, and shingle roof" on Hartwell's house located at 4005 Northwest 19th Avenue, Ocala, Florida. The agreed upon price for the job was $1,225. As is relevant here, Lotz agreed, inter alia, that a "(n)ew exterior siding (would) be used on all gables". According to their agreement, Lotz was to purchase the plywood necessary to complete the work while Hartwell agreed to buy all their necessary materials. Section 6 of Marion County Ordinance 78-5, adopted on January 24, requires that a roofing permit be obtained on all jobs where the value of the work exceeds $100.00. Lotz did not obtain such a permit even though he conceded at the hearing that such a permit was required. Although the contract called for a new exterior side on all gables, Lotz did not install the same. Instead, he installed tongue and groove 3/4 inch boards which he felt were an adequate substitute. He discussed this with Hartwell at the time the job was performed and Hartwell did net object to this change in the contract. Hartwell, who filed a complaint against Lotz, was primarily dissatisfied with a wavy roof. However, that aspect of the job is not a part of this proceeding. The contract itself was modified by the parties a number of times. As a result, Lotz omitted certain requirements therein but added others without additional charge. In all, he was paid $1,125 for the project.
Recommendation Based on the foregoing findings of fact and conclusions of law it is, RECOMMENDED that respondent be found guilty of failing to obtain a roofing permit in violation of Subsection 489.129(I)(d) Florida Statutes, and that he be given a public reprimand and fined $250. It is further RECOMMENDED that all other charges against respondent be DISMISSED. DONE and ENTERED this 27th day of September, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of September, 1983 COPIES FURNISHED: Charles P. Tunnicliff, Esquire Deaptment of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Ron Lotz 1650 Palm Avenue Winter Park, Florida 32789 Mr. J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box Jacksonville, Florida 32201
Findings Of Fact At all times relevant hereto, respondent, James S. Stroz, held registered roofing contractor license number RC 0034849 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He was first licensed in November, 1979, and at that time qualified under the name of Stroz Roofing. A change in status application was later filed to qualify Stroz Roofing, Inc., 13696 Exotica Lane, West Palm Beach, Florida. Although licensed as a roofing contractor, respondent's firm only performs work on wood shakes or shingles. He does not do hot roofs or flat roofs, which is another speciality in the roofing business. While working for a roofing firm in1979, Stroz became acquainted with Lacy Davis, an unlicensed individual who specialized in flat roof work. When Stroz started his own roofing company in 1983, he began contracting out the flat roof work to other licensed roofing contractors. Lacy Davis learned of this and approached Stroz offering his services on the flat roof work. Stroz knew Davis was unlicensed and would not initially hire him, but Davis gave him a business card of Henry Haywood, a licensed roofing contractor in Palm Beach County and explained he and Haywood were partners and that the work and permitting would be done under Haywood's license. In actuality, Haywood had not authorized Davis to use his business cards, or topull permits under his name. Indeed, Haywood had no knowledge of Davis' activities. Without verifying the truth of Davis' representations, and accepting them instead at face value, Stroz agreed to hire Davis to perform his flat roof work. Between January 20, 1983 and September 30, 1984, Stroz performed some twenty-one jobs using Davis for the flat roof work. At all times, Stroz was under the impression that the work was being done under Haywood's license and that his activities were lawful. Stroz made all checks for the work payable to Lacy Davis or Lacy Davis Roofing. He did this because Davis told him he frequently had difficulty reaching Haywood to cash the checks, and because the business bank account was in Davis' own name. A few of the checks carried a notation at the bottom that payment was for work by Haywood Roofing, but most made no reference to Haywood. Stroz pulled all permits on their jobs reflecting that Haywood Roofing was the licensed contractor. Of the twenty invoices given by Davis to Stroz for the twenty-one jobs, only four were on invoices printed with Haywood's name. The remainder had various other names including "Lacy Davis Roofing," "Lacy Davis" and "Lacy Davis and Benny Guy Roofing Contractors." None of these were licensed as roofing contractors by petitioner. In June, 1984, a member of Davis' crew was injured and it was discovered Davis had no insurance. Stroz's insurance paid the claim, but an investigation ultimately determined that Davis was unlicensed and had no authority to act on Haywood's behalf. This led to the issuance of the administrative complaint herein. Respondent has fully cooperated with petitioner, and in fact voluntarily disclosed one job with Davis that petitioner's investigation had failed to uncover. He admits he was negligent in not checking out the representations of Davis, but he never intended to violate the law. No consumer was harmed in any way by Davis' work, and there are no complaints concerning the quality of the jobs in question.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that Respondent be found guilty as charged in the administrative complaint, and that he be fined $500 to be paid within thirty days from date of the final order rendered in this proceeding. DONE and ORDERED this 2nd day of July, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of July, 1985.
The Issue The central issue in this case is whether Respondent is guilty of the violations alleged in the amended administrative complaints.
Findings Of Fact Based upon the testimony of the witnesses and the documentary evidence received at the hearing, I make the following findings of fact: At all times material to the allegations, Respondent, Ruth Ogen, was a licensed roofing contractor, license no. CC CO27471. A. R. Ogen Construction, Inc. was qualified by the Department as a roofing contractor. Respondent is the sole qualifier and licensee associated with the company, A. R. Ogen Construction, Inc. Respondent is married to Avraham Ogen who presents himself as the president of A. R. Ogen Construction, Inc. On or about November 9, 1986, A. R. Ogen Construction, Inc. doing business as Ogen Roofing & Waterproofing entered into a contract with Ardee Yuran to replace the entire roof of a commercial structure located at 14951 N.E. 6th Avenue, North Miami Beach (6th Avenue). The contract provided, among other things, that the top row of tiles around the parapet wall would be removed and reinstalled upon completion of the roof. In negotiating the contract described in paragraph 4, Mrs. Yuran was mindful of the work Avraham Ogen had performed at her residence. Mr. Ogen had supervised the reroofing of Mrs. Yuran's residence which had been satisfactorily performed. The residential job had required the removal of the tiles along the parapet wall and Mrs. Yuran expected the same process would be utilized in completing the commercial roof. The purpose intended to be accomplished by removing the tiles was to allow the roofers to extend the roofing materials up the sides of the parapet and over the crest. The roofing material is then sealed to the wall and the tiles replaced. This procedure results in a waterproof barrier so that when rain accumulates on the flat roof (and the water level rises) it cannot seep through the sealed perimeter. During the time Mr. Ogen was negotiating and performing the roof work for the 6th Avenue building, he was also retained to paint the structure (which was to be completed after the roof was finished). There came a time when Mrs. Yuran and Mr. Ogen disagreed regarding aspects of the roof work and the painting that was to be done. Eventually, the parties reached an impasse where neither was willing to concede: Mr. Ogen was not willing to perform the work as specified by Mrs. Yuran, Mrs. Yuran was not willing to pay Mr. Ogen any more on the contracts. At this point, Ruth Ogen, Respondent, had not been involved in the daily work progress made at the site. To make matters worse, a leak developed at the 6th Avenue property which resulted in a waterfall pouring down through the overhang of the building. As a result of the disagreement, both parties retained lawyers and, understandably, the issues escalated. Mrs. Yuran retained three individuals to review the work performed by Mr. Ogen. On March 4, 1987, Walter H. Scott, Scott Roofing & Repair, Inc., determined that water accumulating on the 6th Avenue roof was draining behind flashing which had not been properly sealed to the perimeter walls instead of running through the outlets. Mr. Scott recommended that the flashing be resealed along the wall. Had the tiles been removed and the work been performed as stated in the contract, the leak would have been avoided. A second licensed roofing contractor, Gary Carruth, Falcon Roofing Co., inspected the property on June 23, 1987, and recommended reflashing the walls along the perimeter of the 6th Avenue building. Mr. Carruth observed that the tiles had not been removed along the wall and that the roofing materials had not been properly sealed along the perimeter. James Rodgers, a consulting engineer performed a third inspection of the roof at 6th Avenue on June 25, 1987. According to Mr. Rodgers, several items of the contract work completed by Mr. Ogen were inadequately performed. Mr. Rodgers found that the pitch pans were not installed properly around the air conditioning units and that the flashing along the parapet wall was not properly completed nor performed as described in the contract. Respondent also retained a licensed roofer to review the work at 6th Avenue. Bill Mathews, Bill Mathews Roofing, completed a roof inspection report on November 21, 1988. According to Mr. Mathews, the flashing along the parapet wall required repair because it had been improperly sealed. Mr. Mathews noted that the top row of tile should have been removed so that flashing could have been taken up and over the parapet wall. Mr. Mathews also noted that the flat roof had buckles or "fish mouths" which should have been corrected as the roof was being installed. Mr. Mathews recommended that the flashing be resealed and that the buckles be cut and sealed with membrane and roofing cement. Finally, Mr. Mathews determined that the pitch pans under the air conditioning units should be filled with an asphalt cold process to prevent further cracking and potential leaks. A final inspection report was completed by Robert B. Hilson, Bob Hilson & Company, Inc., on August 18, 1988. Mr. Hilson is a consultant for the Department and made the inspection at the request of its attorney. Mr. Hilson's findings and recommendations mirrored those suggested by Mr. Mathews. The work performed by Mr. Ogen on the 6th Avenue property did not meet the terms of the contract and did not meet performance standards acceptable in the roofing industry. Mr. Ogen failed to properly seal all flashing materials along the parapet wall, failed to correct the buckles or "fish mouths," and failed to meet the contractual obligations (removing the tiles and extending the flashing over the crest). Because of the substandard work, Mrs. Yuran incurred additional expenses and inconvenience. Respondent did not view the 6th Avenue structure either before or during the time that her husband supervised the work performed. Respondent's role with the company was as secretary, bookkeeper, and office manager. Mr. Ogen supervised or performed all work at the 6th Avenue job. Respondent did not supervise Mr. Ogen or the workers under his supervision. "Ogen Roofing & Waterproofing" has not been qualified by the Department as a roofing contractor. On or about April 28, 1987, A. R. Ogen Construction, Inc. was requested to perform a roofing inspection at 1180 N.E. 204 Terrace. The subject property was under contract for sale and was ultimately purchased by Rose Zenar. According to the inspection report filed by Mr. Ogen, the roof and roof covering were in satisfactory condition with no evidence of leaks. Mr. Ogen signed the inspection report as president of A. R. Ogen Construction, Inc., state license no. CC CO27471. During the first rain after she had moved into the house, Mrs. Zenar observed water leaking through the ceiling into the kitchen. She immediately called Mr. Ogen who came out, observed the problem, but did not repair the leak. Mr. Ogen did not return Mrs. Zenar's subsequent calls. Ultimately, she contacted James Rodgers to perform a second roof inspection. As a result of Mr. Rodgers' inspection, Mrs. Zenar discovered that the leak was of long duration as it had completely rotted and decayed the roof rafters and sheathing in the area of the leak. Mr. Rodgers took pictures of the area which clearly showed the discolored wood. Evidence of the discoloration was visible from the attic entrance located in the garage adjacent to the kitchen. Mr. Ogen's failure to discover the rotted roof was due to an inadequate inspection of the crawl space between the ceiling and the roof rafters. It is the normal practice of qualified roof inspectors to examine the crawl space between the ceiling and roof supports. Respondent did not perform the roof inspection at Mrs. Zenar's home, did not supervise the inspection performed by Mr. Ogen, and did not have a checklist of items to be reviewed by him in making the inspection. The erroneous inspection performed by Mr. Ogen resulted in expenses and inconvenience to Mrs. Zenar.
Recommendation Based on the foregoing, it is RECOMMENDED: That the Department of Professional Regulation, Construction Industry Licensing Board, enter a final order finding the Respondent guilty of the violations set forth above and, based upon the penalties recommended by rule, impose an administrative fine against the Respondent in the amount of $3000.00 DONE and RECOMMENDED this 20th day of April, 1989, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of April , 1989. APPENDIX RULINGS ON PETITIONER'S PROPOSED FINDINGS OF FACT: Paragraphs 1 through 7 are accepted. With the correction to reflect Mrs. Yuran not Mr. Yuran, paragraph 8 is accepted. Paragraphs 9 through 12 are accepted. Paragraph 13 is accepted. Paragraph 14 is accepted with the correction that the witness' name was Gary Carruth. With the deletion of the last paragraph of paragraph 15 which is rejected as argument or comment, the first five paragraphs of paragraph 15 are accepted. Petitioner is warned not to subparagraph statements of fact or to restate testimony, but to simply set forth the fact deduced from such testimony. Paragraph 16 is rejected as irrelevant or immaterial. Paragraph 17 is accepted to the extent that it finds the reroofing work performed on the 6th Avenue building was a poor quality which was not done under the supervision of a qualified, licensed roofing contractor. Further, it was gross negligence not to properly supervise the job. No conclusion is reached as to whether Respondent is able to supervise a job. Paragraph 18 is accepted. Paragraph 19 is rejected as a recitation of testimony. Paragraphs 20 through 24 are accepted. Paragraphs 25 through 31 are accepted. Paragraph 32 is accepted. Paragraph 33--none submitted. With regard to paragraph 34, the first sentence is accepted. The remainder is rejected as conclusion of law, argument, or comment. Paragraph 35 is rejected as irrelevant. Paragraphs 36-38 are accepted. Paragraph 39 is rejected as comment, irrelevant, or recitation. The first two sentences of paragraph 40 are accepted, the remainder is rejected as comment, conclusion of law, or argument. Paragraph 41 is rejected as irrelevant, conclusion of law, or argument. RULINGS ON RESPONDENT'S PROPOSED FINDINGS OF FACT: Paragraph 1 is accepted. Paragraph 2 is accepted but is irrelevant. Paragraph 3 is accepted. Paragraph 4 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 5 is accepted. Paragraph 6 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 7 is rejected as irrelevant or unsupported by the record. Paragraph 8 is accepted. Paragraph 9 is accepted. Paragraph 10 is rejected as contrary to the weight of the credible evidence presented. Paragraph 11 is rejected as argument, speculation, or unsupported by the record. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument, irrelevant, or unsupported by the weight of credible evidence. Paragraph 14 is rejected as argument, irrelevant, or comment. Paragraph 15 is accepted but is irrelevant. Paragraph 16 is rejected as argument. Paragraph 17 is accepted but is irrelevant. Paragraph 18 is rejected as irrelevant, argument, or unsupported by this record. Paragraph 19 is rejected as irrelevant. The following are rulings on case no. 88-1776 as submitted by Respondent: Paragraph 1 is accepted. Paragraph 2 is rejected as unsupported by the record. Paragraph 3 is rejected as irrelevant. Paragraph 4 is accepted but is irrelevant, immaterial. Paragraph 5 is rejected as unsupported by the record. Paragraph 6 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 7 is rejected as unsupported by the weight of credible evidence. Paragraph 8 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 9 is accepted but is irrelevant. Paragraph 10 is rejected as irrelevant, immaterial or unnecessary. Paragraph 11 is rejected as irrelevant, immaterial or unnecessary. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument or unsupported by the weight of the credible evidence. Paragraph 14 is rejected as contrary to the weight of the credible evidence. Paragraph 15 is accepted but is irrelevant. COPIES FURNISHED: Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Bruce D. Lamb General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Elizabeth R. Alsobrook Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
