Findings Of Fact Respondent is Richard K. Willis, a registered roofing contractor licensed by Petitioner and holding license RC-0041275 at all times pertinent to these proceedings. His address of record is Winter Haven, Florida. Respondent and Jeffrey Smith entered into a contract in July of 1986. Under terms of the agreement, Smith, a chiropractor, agreed to pay Respondent the sum of $2,200 to re-roof the facility which served as Smith's home and office. The agreement signed by the parties contains a written guarantee that materials to be used in the project would meet specifications set forth in the document. Further, the guarantee stated that work would be completed in "a workmanlike manner according to standard practices." The project was completed by Respondent and Smith paid him the agreed upon amount of $2,200 in July of 1986. About three weeks after completion of the job, Smith noticed a leak in the roof and telephoned Respondent. Two or three weeks later and after several more telephone calls from Smith, Respondent returned to the job site. By that time, interior damage to the ceiling tiles had been sustained. The tiles became discolored by leaking water and started to collapse. Respondent proceeded to patch the leaking roof with tar. In June of 1987, Smith's facility developed a second leak in the roof over the back portion of the house. Respondent returned, reviewed the problem and agreed to tear off the leaking section of the roof and replace it. As a result of this action by Respondent, the leakage increased. More extensive damage was caused by water leaking down door frames and across the ceiling of the house. Respondent had also promised that he would put a "tarp" over Smith's roof to temporarily stop the leakage until repairs could be effected, but such covering never materialized. After Respondent's second attempt to fix the roof, Smith advised him that the leakage was continuing. Smith then tried several times without success to communicate with Respondent and get him to return to the job site. Finally, after Smith contacted local government building officials, Respondent returned and stopped the leakage. The repairs came too late to prevent ceiling damage which cost Smith $400 to repair. When a third leak developed in the roof in February of 1989, Smith hired another contractor to fix the leak for the sum of $60. Petitioner provided expert testimony which establishes that Respondent demonstrated incompetence in the practice of roof contracting. Further, the work performed by Respondent did not meet the terms of the guarantee he gave to Smith. These conclusions are based on the fact that workmanship provided by Respondent failed to meet standard practices of the industry. Such failure is demonstrated by the irregularity with which surface material was applied to the roof; the lack of sufficient gravel; the lack of uniform distribution of that gravel; missing metal flashing and lifted or separated flashing at the vertical surfaces of the roof; and improper installation of flashing around the plumbing vent exiting through the roof. Respondent's previous disciplinary history with Petitioner consists of an administrative fine of $250 on June 19, 1985, and letter of guidance issued on August 14, 1986.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent in violation of Subsection 489.129(1)(m), Florida Statutes, (1988) and revoking his license as a roofing contractor in accordance with provisions of Rule 21E-17.001, Florida Administrative Code. DONE AND ENTERED this 6th day of April, 1989, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 6th day of April, 1989. APPENDIX The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by Petitioner. Petitioner's Proposed Findings 1.-17. Addressed in substance. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Richard K. Willis 2106 Winter Lake Road Winter Haven, Florida 33880 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 =================================================================
The Issue Whether Respondent's activity and conduct in the performance of a roofing contract constitutes abandonment of that contract in violation of Section 489.129(1)(k), Florida Statutes (1979), and whether Respondent willfully or deliberately violated the Volusia County Building Code, thereby contravening Section 489.129(1)(d), Florida Statutes (1979), by failing to obtain a building permit prior to commencing construction of the subject project. Based upon my observation of the witnesses and their demeanor while testifying, the arguments of counsel and Respondent, the Petitioner's proposed recommended order and the entire record compiled herein, I hereby make the following:
Findings Of Fact By its Administrative Complaint signed October 21, 1981, Petitioner, Florida Construction Industry Licensing Board, seeks to take disciplinary action against Respondent and against his license as a registered roofing contractor. Respondent, Leonard L. Clark, is a registered roofing contractor who holds License No. RC 0020933 which has been issued by Petitioner. Respondent does business under the entity Clark Roofing. On January 15, 1981, Respondent entered into a contract with one Mae Coogan, to reroof her residence. The contract specifically required Respondent to "replace any bad wood," and provide a ten (10) year workmanship warranty. (Petitioner's Exhibit No. 1.) Additionally, Respondent agreed to install a 1 x 2 inch strip and a brown aluminum facia at an extra cost of $200.00. (Petitioner's Exhibit No. 1 and testimony of John Coogan.) Mrs. Mae Coogan is an elderly woman and is incapacitated. Her son, John Coogan, who lives with her in her residence, advised her during the negotiations of the subject contract, and testified as a witness in the proceedings herein. Respondent and John Coogan's testimony establishes that construction on the subject project commenced on February 10, 1981, and ceased on March 28, 1981. At that time, based upon Respondent's representation that the job was complete, Mr. Coogan paid Respondent the entire $2,500.00 due under the terms of the contract. Shortly thereafter, Mr. Coogan discovered evidence of "bad" or "rotten wood." Mr. Coogan immediately apprised Respondent of this, whereupon Respondent initially told him that he would be back to the job site to take care of any problems that existed with the reroofing project. There is conflicting evidence as to whether or not there was a subsequent telephone conversation between Respondent and Mr. Coogan following a letter which Respondent found offensive. Respondent claims that there was such a conversation and that the parties became angry at each other. At that juncture, the parties were unable to resolve their differences. Efforts by the parties to resolve their differences reached a stalemate, and Respondent did not again visit the project site or otherwise inspect the claimed damaged by Mr. Coogan. Mr. Coogan, to substantiate his claim that there was in fact rotten or bad wood left exposed in the overhang, rafters and beams surrounding the roof, introduced several photographs which depicted the condition of the wood on the roof. (Petitioner's Composite Exhibit No. 3.) Respecting the fact that there was rotten wood, as claimed by Mr. Coogan, in the rafters and overhang, Respondent admitted the existence thereof. There is also a question about the possibility of rotten wood being covered by Respondent's employees and not replaced as required by the contract. The particular area in question is a portion of a flat roof which sagged in several places. Mr. Coogan claims that he had been advised that this was due to rotten wood underneath the shingles in an area in which he specifically claims to have asked Respondent to allow him to inspect the exposed-wood surface prior to the time in which it was covered with asphalt shingles. Respondent's workers covered this area of the roof without permitting Mr. Coogan the opportunity to inspect it. Mr. Coogan testified that the roof continued to sag in the identical places where it sagged prior to the reroofing. In this regard, Respondent admits that he might have agreed to allow Mr. Coogan an opportunity to inspect the exposed roof once the shingles were removed and prior to the time that he recovered (reroofed) the flat roof. Respondent further testified that this was not due to any effort on his part to conceal or otherwise hide rotten wood and, in fact, he claimed to have covered or replaced any bad or rotten wood. In this regard, Mr. Coogan noticed at least four water leaks from his roof prior to the time that Respondent reroofed his mother's house; however, he testified, on cross-examination, that he has not seen any leaks since Respondent has completed the subject project. Bob McConnell, Volusia County Building Inspector for approximately five years, inspected the roofing job completed by Respondent for Mrs. Coogan on July 28, 1981. Mr. McConnell found that the roofing job did not comply with the contract in the following regards: The 1 x 2 inch strip beneath the brown aluminum facia, called for as an extra, was not installed; There was visible rot in the sheathing; A short hip (rafter) was replaced with unsound wood; and A rafter tail had visible rot. In this regard, Mr. McConnell, while also reporting that there were soft spots in the built-up roof, could not testify with certainty that they were the result of wood rot. Respondent testified that he has tried to contact Mr. Coogan on several occasions to correct any claimed deficiency. Respondent stands, at this time, willing to correct any deficiency that exists or to correct any problem which stems from his deviation from the contract. In this regard, Respondent has offered, and no offers, to remove the shingles from the entire roof and allow for it to be inspected by Respondent or any designated roofing contractor whom Coogan or Petitioner selects. Respondent will replace any "bad" or "rotten" wood which he has been claimed to have covered. However, Respondent expects to be paid for reroofing this job in the event that in an inspection reveals that no "bad" or "rotten" wood was covered as Mr. Coogan and Petitioner claim. Inspector McConnell has known Respondent in excess of twenty-five (25) years and is unaware of any claim that Respondent has performed any unworkmanlike or "shoddy" roofing repairs. Finally, in this connection, Respondent introduced letters from three (3) area builders who attested to Respondent's excellent workmanship. (Respondent's Composite Exhibit No. 3.)
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby RECOMMENDED: That the Respondent be placed on probation for a period of two (2) years and that the term of probation be suspended for a period of sixty (60) days, during which time Respondent shall be allowed an opportunity to return to the Coogan residence and replace any existing exposed "rotten" or "bad" wood which should have been replaced pursuant to the terms of the contract. In the event that the Respondent properly completes the replacement of the rotten or damaged wood on this project, following an inspection by one of Petitioner's agents, it is further RECOMMENDED: That the entire term of the probation be suspended. In the event that Respondent fails to properly complete this project, following an inspection by one of Petitioner's agents, it is further RECOMMENDED: That the entire term of probation be instituted without the necessity of further hearing. RECOMMENDED this 11th day of August, 1982, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of August, 1982.
Findings Of Fact In July, 1986, Respondent is and at all material times has been licensed as a certified roofing contractor in the State of Florida. He holds license number CC C026475. He is the qualifying agent for B & P Roofing, Inc. In July, 1986, B & P Roofing, Inc. performed a pre- closing roof inspection of the 1029 McKean residence at the request of the real estate broker handling the sale. The report, dated July 31, 1986, estimated that it would cost $1400 to reroof the flat roof areas and replace the skylights and $300 to replace some cracked tiles on the main, sloped roof. Noting that it was impossible to examine the roof membrane under the tiles, the report concludes that the repairs should be minimal. Chris and Heather Peterson purchased the 1029 McKean residence on August 9, 1986. In late December, 1986, or early January, 1987, the Petersons contacted B & P Roofing, Inc. and requested that they perform the roofing repairs identified in their earlier estimate. The parties agreed that B & P Roofing, Inc. would also replace two skylights for an additional $300. By Final Order filed on April 22, 1983, Petitioner reprimanded Respondent, as qualifying agent for B & P Roofing, Inc., for failing to obtain a permit and inspection in connection with a residential roof installation. By Final Order filed January 23, 1984, Petitioner imposed an administrative fine of $500 against Respondent, as qualifying agent for B & P Roofing, Inc., for failure to obtain building permits on three different roofing jobs. As a result of these disciplinary actions, B & P Roofing, Inc. adopted a procedure by which each job could be readily checked in the office as to whether a permit had been obtained. A chart is posted in the office and each job is marked as to whether it requires a permit and, if so, whether a permit has been issued. After the Peterson job had been obtained but before work had begun, Richard Francis Xavier McFadden, the president of B & P Roofing, Inc. noticed that the Peterson job had been posted in the office, but the "permit" column had not been checked. He asked Patricia McFadden, his wife who was performing clerical work in the office, why no permit was required for the job. She told him that she had been told by someone at the Winter Park Building Department that one was not required. Mr. McFadden immediately telephoned the Winter Park Building Department to confirm that no permit would be required for the job. He spoke with Karen Clayton, who is the secretary of the Winter Park Building and Zoning Department and handles the issuance of permits, which may be ordered by telephone. Using a Roof Work Sheet dated January 7, 1987, Mr. McFadden described the job to Ms. Clayton. Ms. Clayton placed her hand over the telephone, checked with a nearby building inspector, and informed Mr. McFadden that no permit would be necessary. In fact, the scope of the job required the issuance of a building permit. Ms. Clayton testified that she did not understand at the time that she spoke with Mr. McFadden that an existing roof was being torn off. She also testified that she had not previously heard the phrase, ??90 pound reroofing felt,!? which Mr. McFadden used to describe the job. It is apparent that Mr. McFadden accurately described the job, but Ms. Clayton misunderstood the description and gave him the wrong advice. Without a permit, B & P Roofing, Inc. began the work on or about January 17, 1987, and completed the work in late January or early February, 1987. No inspection of the job was performed by the Winter Park Building Department during the job or immediately after its completion. After Petitioner commenced its investigation, B & P Roofing, Inc., at the investigator's suggestion, obtained a permit on June 30, 1987, and the job passed a final inspection performed on that date or shortly thereafter. Respondent was never aware of the Peterson job until after it had been completed.
Recommendation In view of the foregoing, it is hereby RECOMMENDED that a Final Order be entered dismissing the Administrative Complaint. ENTERED this 20th day of May, 1988, in Tallahassee, Florida. ROBERT E. MEALE Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of May, 1988. APPENDIX Treatment Accorded Petitioner's Findings Adopted, except that the last two sentences are rejected as unnecessary. Adopted. Rejected as irrelevant, except that the last sentence is rejected as against the greater weight of the evidence. Poor workmanship or improper materials is generally not probative of the issues whether Respondent deliberately or through improper supervision failed to obtain a permit or inspection. The only situation in which poor workman- ship or improper materials might be relevant would be if the workmanship or material so deviated from the norm that Respondent and the employees of B & P Roofing, Inc. knew that the job could never pass an inspection. The evidence failed to prove such a deviation in this case. The testimony of Julian Garcia, Petitioner's expert witness, tended to prove such a deviation, but ultimately failed because of the inadequate familiarity of the wit- ness with the specifics of the Peterson job, such as the degree of scope present in the flat areas of the roof and the specific roofing material used in these areas. Adopted in substance. Rejected as unnecessary. First sentence is adopted. Second sentence, although strictly speaking is true, is rejected to the extent that it implies that no inspection took place. Such an implication is against the greater weight of the evi- dence. Ms. Clayton's testimony explains the omission from the record. First, the building inspector whom Rich McFadden testified performed the inspection died shortly thereafter. Second, the inspector probably had no opportunity to record it before the file was closed because the inspection likely took place on the same day or within days of the closing of the file. Ms. Clayton's candid testimony in this regard offers little basis for inferring that the absence of a record entry means no inspection took place, especially in view of the positive testimony of Mr. McFadden that he accom- panied the inspector to the house for the final inspection. Adopted, except that two telephone contacts took place before the work began. Rejected as unnecessary and against the greater weight of the evidence. Mr. and Mrs. McFadden testified in detail to the circumstances surrounding why no permit was obtained. Against such detailed testimony, Respondent's questionnaire response is entitled to little weight. Adopted. Rejected as against the greater weight of the evidence. There was an insufficient predicate for much of Mr. Garcia's testimony for the reasons set forth in paragraph 3 above. 11-12. Adopted. COPIES FURNISHED: David L. Swanson, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 John Sunner, Esquire Post Office Box 1717 Casselberry, Florida 32707 Fred Seely Executive Director Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 William O'Neil General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
Findings Of Fact At all times relevant hereto, respondent, James S. Stroz, held registered roofing contractor license number RC 0034849 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He was first licensed in November, 1979, and at that time qualified under the name of Stroz Roofing. A change in status application was later filed to qualify Stroz Roofing, Inc., 13696 Exotica Lane, West Palm Beach, Florida. Although licensed as a roofing contractor, respondent's firm only performs work on wood shakes or shingles. He does not do hot roofs or flat roofs, which is another speciality in the roofing business. While working for a roofing firm in1979, Stroz became acquainted with Lacy Davis, an unlicensed individual who specialized in flat roof work. When Stroz started his own roofing company in 1983, he began contracting out the flat roof work to other licensed roofing contractors. Lacy Davis learned of this and approached Stroz offering his services on the flat roof work. Stroz knew Davis was unlicensed and would not initially hire him, but Davis gave him a business card of Henry Haywood, a licensed roofing contractor in Palm Beach County and explained he and Haywood were partners and that the work and permitting would be done under Haywood's license. In actuality, Haywood had not authorized Davis to use his business cards, or topull permits under his name. Indeed, Haywood had no knowledge of Davis' activities. Without verifying the truth of Davis' representations, and accepting them instead at face value, Stroz agreed to hire Davis to perform his flat roof work. Between January 20, 1983 and September 30, 1984, Stroz performed some twenty-one jobs using Davis for the flat roof work. At all times, Stroz was under the impression that the work was being done under Haywood's license and that his activities were lawful. Stroz made all checks for the work payable to Lacy Davis or Lacy Davis Roofing. He did this because Davis told him he frequently had difficulty reaching Haywood to cash the checks, and because the business bank account was in Davis' own name. A few of the checks carried a notation at the bottom that payment was for work by Haywood Roofing, but most made no reference to Haywood. Stroz pulled all permits on their jobs reflecting that Haywood Roofing was the licensed contractor. Of the twenty invoices given by Davis to Stroz for the twenty-one jobs, only four were on invoices printed with Haywood's name. The remainder had various other names including "Lacy Davis Roofing," "Lacy Davis" and "Lacy Davis and Benny Guy Roofing Contractors." None of these were licensed as roofing contractors by petitioner. In June, 1984, a member of Davis' crew was injured and it was discovered Davis had no insurance. Stroz's insurance paid the claim, but an investigation ultimately determined that Davis was unlicensed and had no authority to act on Haywood's behalf. This led to the issuance of the administrative complaint herein. Respondent has fully cooperated with petitioner, and in fact voluntarily disclosed one job with Davis that petitioner's investigation had failed to uncover. He admits he was negligent in not checking out the representations of Davis, but he never intended to violate the law. No consumer was harmed in any way by Davis' work, and there are no complaints concerning the quality of the jobs in question.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that Respondent be found guilty as charged in the administrative complaint, and that he be fined $500 to be paid within thirty days from date of the final order rendered in this proceeding. DONE and ORDERED this 2nd day of July, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of July, 1985.
The Issue The issues are based upon an administrative complaint brought by the State of Florida, Department of Professional Regulation against Phillip E. Sheffield, Respondent. In particular, Respondent is said to have violated the building code of the City of Jacksonville, Florida by failing to obtain a building permit before commencing construction work related to a roofing project and building the roof to a slope that was contrary to that local building code. For violations of the City of Jacksonville building code, Respondent is said to have violated Section 489.129(1)(d), Florida Statutes, by willful or deliberate violation and disregard for the applicable building code of the municipality. Finally, Respondent is said to have violated Section 489.113(3), Florida Statutes by failing to subcontract roofing work.
Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact At all times material hereto, Respondent has been a registered roofing contractor in Miami, Florida, having been issued license no. RC 0047352. Respondent is the qualifying agent for All Central Roofing, Inc. In May 1986 All Central Roofing, Inc., entered into a contract with Richard Crisonino to perform certain roofing work on Crisonino's residence in Miami, Florida. The contract price was $3,374. All Central Roofing, Inc., thereafter began the roofing work on Crisonino's residence without obtaining a permit for that work from the local building department and without posting a permit on the job site. All Central Roofing, Inc., failed to obtain the required inspections by the local building department. After completing part of the work involved and after receiving substantial payment under the contract, All Central Roofing Company, Inc., ceased work on the Crisonino residence and failed or refused to complete the work, thereby abandoning the job. By her own admissions at the final hearing in this cause, Respondent does not possess a working knowledge of roofing or roofing contracting. She lacks even a basic fundamental understanding of roofing construction to the extent that it is impossible that she is fulfilling any of her responsibilities as a qualifying agent for All Central Roofing, Inc. Further, Respondent does not even know the number of employees working for All Central Roofing, Inc. Respondent has been disciplined by the Dade County Construction Trades Qualifying Board, and Respondent's personal and business certificates have been revoked by that Board.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is, RECOMMENDED that a Final Order be entered finding Respondent guilty of the allegations contained in the Administrative Complaint filed against her and revoking Respondent's registered roofing contractor license. DONE and RECOMMENDED this 14th day of December, 1987, at Tallahassee, Florida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of December, 1987. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 G. Vincent Soto, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Harry E. Geissinger, Esquire 415 West 51st Place, Suite 201 Hialeah, Florida 33012 Tom Gallagher, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue Whether Respondent committed the offenses set forth in Count I of the Administrative Complaint and, if so, the penalties which should be imposed.
Findings Of Fact At all times pertinent to these proceedings, Respondent was licensed by Petitioner as a certified general contractor in the State of Florida and held license number CG- C016730. At all times pertinent to these proceedings, Respondent was the qualifying agent for Bilo Homes, Inc. (Bilo), a corporation engaged in Florida in the business of general contracting with its principal place of business in Miami, Florida. At all times pertinent to these proceedings, Mr. and Mrs. Donald Huston resided at 29843 S.W. 149th court, Leisure City, Florida. On February 24, 1988, the Hustons contracted with Bilo to build an addition to their house for the sum of $20,000 pursuant to plans and specifications that had been prepared by an architect. The Hustons' existing house was valued between $30,000-$40,000. The contract called for a one-story room addition to be built on a concrete slab with stucco exterior and sheet rock interior. The addition was to have a sliding glass door and was to be connected to the existing structure by a tie beam. The roof of the existing house was to be reshingled to match the shingles on the addition. The project also involved electrical work and plumbing work. The contract was signed on Wednesday, February 24, 1988, and work began on Friday, February 26, 1988. The contract did not specify a time for the completion of the project. The following draw schedule was agreed to by the Hustons and Bilo: 20% of the contract price upon the acceptance of the contract by the Hustons; 10% of the contract price upon the pouring of the concrete slab; 10% of the contract price upon ice completion of the tie beam: 20% of the contract price upon the drying in of the roof; 10% of the contract price upon the completion of the rough mechanical work; 10% of the contract price upon ice completion of the shingling of the roof; 10% of the contract price upon the installation of the plumbing fixtures;; 10% of the contract price (the balance) upon completion of the job. The Hustons made payments to Bilo in the total amount of $14,000.00. These payments were broken down as follows: $4,000.00 paid on February 24, 1988, upon acceptance of the contract; $2,000.00 paid on March 22, 1988, upon the pouring of the concrete slab; $2,000.00 paid on April 5, 1988, upon the completion of the tie beam; $4,000.00 paid on April 18, 1988, upon the drying in of the roof; and $2,000.00 paid on June 25, 1988, upon the completion of the shingling of the roof. Before June 25, 1988, Respondent had asked the Hustons for the draw due upon completion of the rough mechanical work in addition to the draw due upon completion of the shingling. The Hustons refused to pay both draws because they were dissatisfied with the quality of Bilo's work. The Hustons engaged the services of a lawyer and, on June 29, 1988, presented Respondent with a list of items they wanted corrected before paying the draw for the rough mechanical work. Respondent and the Hustons disagreed as to when the items on the list should be corrected. Respondent contended that the items could have been corrected as part of the punch list prior to the final payment. The Hustons contended that the items should be corrected before Respondent received any further draws. This dispute is resolved by finding that while several of the items on the list could have been corrected as part of the final punch list, there were items on the list that should have been corrected by Respondent before he proceeded. Considering the very poor quality of work that went into this job, the Hustons were justified in their demand that Respondent make these corrections before receiving an additional draw. Respondent contends that the Hustons did not pay the draw for the rough mechanical work because they ran out of money. This contention is rejected as being contrary to the greater weight of the evidence. After the Hustons presented Respondent with the list and refused to pay the draw for the rough mechanical work, Bilo stopped work on the project. Bilo performed no work on the project after June 29, 1988. Prior to the work stoppage, Respondent hired K & H Plumbing as the subcontractors to the plumbing work on the Huston job. K & H Plumbing's work failed to pass a Metro Dade County tub and water pipe inspection because the work did not meet the South Florida Building Code. K & H never completed its work on the Huston addition and no final inspection of its work was approved. K & H Plumbing filed suit against the Hustons for the unpaid portion of their contract with Bilo. In addition, K & H Plumbing failed to properly replace wood decking which it had pulled up during the course of its work on the Huston job. Respondent had received funds which1 should have been used to pay K & H. Prior to the work stoppage, Respondent hired Tom Mentelos to perform the electrical subcontracting work on the Huston addition. The work performed, by Mentelos was substandard. His work failed to pass inspection by the Metro Dade County Building and Zoning Department on six different occasions. In addition to this substandard work, one of Mentelos' employees cracked the Huston's kitchen ceiling while working in the attic over the existing portion of the house. This crack was never corrected by Mentelos or by Bilo. Mentelos never completed his work on the Huston addition, although he was never fired by the Hustons. Mentelos filed a claim of lien against the Hustons in he amount of $2,000.00. The first claim of lien was released and Mentelos filed a second claim of lien against the Hustons in the amount of $2,623.00. Respondent had received funds which should have been used to pay Mentelos. Respondent obtained the roofing permit to build the new roof on the Huston addition and to reroof the existing roof. The roofing work involved a process commonly referred to as "hot mopping", a process which requires the services of a licensed roofing contractor. Respondent exceeded the scope of his licensure by engaging in hot mopping. Bilo's employees punched two unnecessary vent pipes through the roof and placed a flat piece of PVC material around the vent holes to keep the, roof from leaking. This is an improper and unacceptable construction practice. Bilo's employees damaged the existing screen porch while working on the roof. The metal flashing which connected the existing roof to the aluminum screen porch was taken off but was never replaced. As a result, the screen porch leaked, a problem that had not been corrected as of the time of the final hearing. While Bilo's employees were working on the roof of the existing structure, a rainstorm occurred which resulted in water stains to the ceiling of the Hustons' main structure. The workmen were not supervised by Respondent and were unprepared for the rain. Other than the water stains, no damage was done to the ceiling. To repair the ceiling stains would require a chemical coating, followed by repainting of the ceiling. The cost of the repair would be approximately $75.00. Bilo engaged in poor construction practice in constructing the exterior wall by facing the poorer grade side of the exterior plywood toward the outside as opposed to inside. The better construction practice is to place the poorer grade side toward the inside where it will not be exposed to view. There is a gap in the area where the metal flashing comes down the exterior side of the end gable and meets the top of the roof. In the work performed by Bilo, the piece of sheathing was above the bottom of the sill plate which caused a gap from one inch to five inches over a distance between eight and ten feet. This gap is a source of potential leaks. Bilo attempted to cover the v-notch in the area of the gag with tar pitch in an attempt to correct this deficiency. Both the gap and the attempted repair are unacceptable construction practices. Bilo had not cut vents in the soffits at the time it stopped work on the project. Without vent holes in the soffits, the job would have not passed inspection. Bilo could have, at little expense, cut the soffit vents at a later point in the job. The end member of the frame for the partition wall between the laundry room and the masonry wall is not pressure- treated wood. The South Florida Building Code requires that the wood used for the end member of such construction be pressure treated or that there be a barrier between the end member and the adjoining wall. Here, Bilo failed to exercise either acceptable option, and, consequently performed work that failed to comport with acceptable construction practices and did not meet code. The manner in which Bilo supported the timber girder that supports the roof trusses fails to meet code because the tie beam, into which this girder is pocketed for support, is improperly supported. A hole was knocked in the cement block wall that supported the tie beam when a plumbing vent was redirected. As a result of this hole, the tie beam rests on only approximately two inches of concrete, which is inadequate to support the tie beam and the timber girder. This work fails to comport with acceptable construction practices. Bilo failed to brace the roof trusses as required by the plans and specifications of the architect. This is an unacceptable construction practiced. Bilo cut into the roof truss without authority from the truss manufacturer or from a qualified engineer. Cutting into a truss can impair its structural integrity and is a violation of code. Respondent maintained at hearing that he would have been able to get approval from the truss manufacturer for the modification of the truss caused by the cut. Respondent did not have such approval as of the time of the final hearing, and there was no evidence, other than his unilateral expectation, to support this contention. The facia board on the eaves did not join properly because Bilo's workmen did not take the time to properly cut the boards with the aid of a square. Although this is a matter that could be corrected for approximately $25.00, this work, along with the other deficiencies detailed herein, demonstrates the substandard work that went into this project and establishes that Bilo failed to provide its workmen adequate supervision or adequate training. At hearing, there was a dispute as to how much time Respondent personally spent at the Huston job site. This conflict is resolved by finding that Respondent was personally on the job site for at least 30 minutes on days when work was progressing. When major items were being performed on the job, he spent more time on the job site. When minor work was being done, Respondent did not go to the job site on a daily basis. Regardless of the number of minutes or hours that Respondent spent on the job site, the conclusion is inescapable that Respondent failed to properly supervise his workmen in light of the low level of skill the workmen exhibited throughout the job. Respondent had the responsibility as the general contractor to properly supervise his workmen and his subcontractors. He failed to perform that responsibility. As of the final hearing, the Huston addition remained uncompleted. At the time of the work stoppage, it would have cost the Hustons more than $6,600 to complete the job, the difference between the contract price and the amount that the Hustons had paid Respondent. The evidence was clear that the Hustons had incurred damages as a result of their dealings with Respondent. The amount of those damages were not established with any degree of certainty. On or about July 15, 1988, Respondent filed a claim of lien against the Hustons' property claiming that Bilo was owed $8,350 for the work that had been done. Respondent has been a certified general contractor for fifteen years and has been certified as a general contractor in the State of Florida since 1980. Respondent's licensure had not been disciplined prior to the filing of the Administrative Complaint in this proceeding.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated the provisions of Section 489.129(1)(h), (j), and (m), Florida Statutes, which imposes administrative fines in the amount of total amount of $5,000 for such violations, and which suspends his licensure as a general contractor for a period of six months. DONE AND ENTERED this 20th day of June, 1990, in Tallahassee, Leon County, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of June, 1990. APPENDIX TO THE RECOMMENDED ORDER IN CASE NO. 89-0765 The following rulings are made on the proposed findings of fact submitted by Petitioner: The proposed findings in Section VI (A) are adopted in material part except to the extent that the proposed findings are subordinate to the findings made. (Section VI (A) pertains to facts established through Respondent's failure to respond to Request for Admissions.) The proposed findings in paragraphs 1 2, 3, 4, 14, 15, 16, 17, 18, 21, 22, 23, and 24 are adopted in material part. The proposed findings in paragraphs 5 - 10 are adopted in material part except to the extent that the proposed findings are subordinate to the findings made or are unnecessary to the conclusions reached. The proposed findings of paragraphs 11, 19, and 25 are adopted in material part except to the extent that the proposed findings are unnecessary to the conclusions reached. The proposed findings of paragraph 12, 26, and 27 are rejected to the extent that the proposed findings are conclusions of law. The proposed findings of fact in paragraphs 13 and 20 are rejected as being subordinate to the findings made or as being unnecessary to the conclusions reached. The following rulings are made on the proposed findings of fact submitted by Respondent: The proposed findings of fact in paragraphs 1, 2, 3, 4, 6, 7, 8, 13, 16, 18, 19, 27, and 30 are adopted in material part. The proposed findings of fact in paragraphs 5, 17, 20, 21, 22, 23, 25, 26, 28, 29, 30, and 32, are rejected as being unnecessary to the conclusions reached. The proposed findings of fact in paragraphs 9 and 11 are rejected as being subordinate to the findings made. The proposed findings of fact in paragraph 10 are adopted in part and are rejected in part as being contrary to the findings made. The proposed findings of fact in paragraphs 12, 14, 33, 35, and 37 are rejected as being contrary to the greater weight of the evidence. The proposed findings of fact in paragraph 15 are adopted in part and are rejected in part as being unsubstantiated by the evidence. The proposed findings of fact in paragraph 24 are adopted in part and are rejected in part as being unnecessary to the conclusions reached. The proposed findings of fact in paragraph 34 are rejected as being the recitation of testimony. COPIES FURNISHED: regory A. Victor, Esquire 3225 Aviation Avenue Suite 400 Miami, Florida 33133 Robert S. Cohen, Esquire Post Office Box 10095 Tallahassee, Florida 32302 Fred Seely, Executive Director Construction Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Kenneth E. Easley, Esquire Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792
The Issue Whether disciplinary action should be taken against the Respondent's contractor license number CG C022926, issued by the State of Florida, based upon the violations of Section 489.105(4), 489.113(3), 489.117(2), 489.115(1)(b), 489.119, and 489.129(1)(d), (e), (g), (j) and (m), Florida Statutes (1987), alleged in three administrative complaints filed by the Petitioner.
Findings Of Fact At all times material to this proceeding, the Respondent, Richard Lee Melvin, was a licensed contractor in the State of Florida, having been issued license number CG C022926, by the State of Florida. The Armstrong Job On or about February 26, 1987, Mr. and Mrs. Armstrong entered into a contract with Sunshine State Homes to do certain siding work and roofing work on two mobile homes owned by the Armstrongs located at 4605 and 4607 Orange Drive in Holiday, Florida. The cost of the repairs under the contract was $6,400. Although the Respondent did not sign that contract, his name and license number appeared on it, he applied for and was granted the necessary Pasco County permit for Sunshine State Homes using his licensure. At the time he applied for the permit, the Respondent knew that Sunshine State Homes was not licensed since he was considering qualifying that company. The permit that the Respondent received from Pasco County required, among other things, that all the Respondent's work conform with the requirements of state and county codes and regulations. The Respondent acted in the capacity of a contractor for Sunshine State Homes even though his certificate did not contain the name Sunshine State Homes. After the signing of the contract, work began on both structures. The roof was replaced on the main structure, and the Armstrongs were informed that the Rainbow Roof System contracted for could not be installed. After work began, it rained and because of improper construction techniques, both mobile homes flooded. Representatives of Sunshine State Homes attempted to correct the problems, but when it rained again, there was substantial leaking in both mobile homes. A rug from the main mobile home had to be removed. Another attempt was made to correct the leaks at the rental unit by re-coating the roof with sealant. Again, it rained, and both mobile homes flooded. Both mobile homes had leaks where, prior to construction beginning, they did not have leaks. Insurance covered $1,200 of the damage to the main mobile home. There also was damage that was not covered by insurance. The type of roof put on the main coach resulted in leaks all along the seam between the roof over the main coach and the roof over the addition to the main structure. The water leaked through the walls of the mobile home, causing water damage. On or about April 7, 1987, the roofs supposedly were finished, and the contractor wanted the rest of his money. The Armstrongs refused to give the balance of the money until another heavy rain was experienced. After representatives from Sunshine State Homes made various threats, the owners paid Sunshine State all but $900 of the contract price. The $900 was withheld to cover the water damage sustained as a result of the leaks. The work that was done was required to be inspected by Pasco County. The work had not been inspected because neither the Respondent nor anyone else from Sunshine State had called for inspections. The work that was done deteriorated over the summer months. On October 14, 1987, the homeowners contracted with Holiday Aluminum to replace the two mobile home roofs in accordance with the contract previously entered into between the homeowners and Sunshine State Homes. It cost the homeowners $4,300 to have the two new roofs installed. They have not experienced any problems with the roofs installed by Holiday Aluminum. The work Sunshine State did under the Respondent's licensure was done in a grossly negligent or incompetent manner. The Respondent and Tropical Exteriors The Respondent was contacted by Jeff Gaston, in mid-November, 1986. Gaston wanted the Respondent to qualify Gaston's company, Tropical Exteriors and Services, Inc. The Respondent met with Gaston and Gaston's attorney, and the Respondent understood that it would take time for all of the paperwork to be concluded. Towards the end of March, 1987, the Respondent started having concerns about his business relationship with Gaston and Tropical. However, the Respondent took no action to terminate that relationship or otherwise advise any governmental agencies involved or homeowners that he was not associated with Tropical until May 13, 1987. There was a continuous business relationship between the Respondent and Tropical for the period November, 1986, through May 13, 1987. The Respondent never qualified Tropical. The Respondent knew that Tropical was using his name in connection with its business after November, 1986. He also thought he would be given notice of any contracts Tropical entered into. But Tropical entered into contracts with the Clems and the Warzyboks and began work without telling the Respondent. The homeowners relied on Tropical's representations regarding the Respondent's association with the business. The Clem Job In November, 1986, Mr. and Mrs. Clem knew that they needed a new roof on their residence located 10511 - 53rd Avenue North, St. Petersburg, Florida, because the shingles were curling. However, they did not have any leaks in the roof. In November, 1986, the Clems were contacted by Millie Morris regarding the roof repairs. Morris stated that she worked for Tropical and was representing U.S. Steel. She advised the Clems that she would like to use the Clem home in an advertising campaign. The Clems did not have the cash money to pay for the repairs and needed financing. As part of that financing, Morris stated that she would give the Clems a $300 rebate on contracting resulting from any leads the Clems gave her. The Clems were able to obtain a second mortgage on their home which provided for the financing of the needed improvements. On or about February 9, 1987, the Clems entered into a contract with Tropical. At the time of the signing of the contract, Morris again reaffirmed to the Clems that any leads the Clems gave Morris that resulted in a contract would result in the Clems being paid the sum of $300. The Clems put $1,000 down at the time of signing the contract and were to pay $1,500 during the course of the job and $2,500 on completion of the job. Before entering into the contract, the Clems relied on the information on the contract letterhead which contained the Respondent's name, type of state certificate, license number, number of years of experience and a representation that the Respondent was insured. Additionally, the Clems called the Better Business Bureau and checked on Tropical to see if any complaints had been filed. The contract provided for, among other things, the removal of the old roof, installation of a new roof, the installation of soffit and facia, the installation of doors and windows and a guaranty on all the work. Shortly after the contract was signed and work was started on the roof, the Clems told Morris the people across the street from them needed repairs. Those people signed a contract with Tropical to have their roof replaced. The work was done, but the Clems received nothing for giving Tropical the customer lead. After the work was done, the Clems dealt with Morris and Gaston. Several times after the job was started, the Clems tried to get Gaston on the job site because the roof was leaking, there was no flashing around the drain pipes and vents, the aluminum edging was bent in many places and the siding had fallen on the ground. Several times when a representative of Tropical was on the job site, Mrs. Clem pointed out to them that the aluminum was bent in places, the seams were cut crooked, there were unnecessary splices in the aluminum, there were bad cuts around certain pipes, there was an electric light left hanging, the wrong weather stripping had been installed around the door, other weather stripping was not put up right, the windows were not sealed, the roof leaked, there was unnecessary tar on the shingles and there were aluminum overlaps facing the street, among other things. From that point forward, representatives of Tropical assured the Clems on many occasions that those problems would be corrected by a date certain, but the deadline was missed in every base. During the construction, the Clems agreed to pay Tropical the $1,500 due during the construction and $2,000 of the $2,500 that was due at the end of construction because a representative of Tropical explained to them that the job was near completion, Tropical needed the money to cover expenses and that Tropical would put in a bedroom window in the Clems residence at no charge. After many telephone conversations and on-site inspections by Tropical, all to no avail, Tropical agreed to finish the job if the Clems would pay him the remaining $500 and if the Clems would pay him an additional $150 for the bedroom window Otherwise, Tropical threatened to forfeit the $500 and not complete the job. The Clems agreed because they knew that it would cost them more than $500 to have the job completed by someone else. The job still was not competed, and the complaints were not corrected. The Clems called another siding contractor, who told the Clems that he would charge $750 just to correct the siding problems, that no permits had been pulled for the job and that the Clems should not allow any further work to be done until the permits had been pulled for the siding and the roof. When the building department received the siding contractor's inquiry regarding the permits, it contacted Tropical. The Clems had several conversations with their attorney, who advised the Clems that it would be cheaper to attempt to solve the problem with Tropical than to get a new contractor. Several attempts were made to have Tropical complete the job, but Tropical continuously failed to honor its agreements. The last time anyone from Tropical was on the job site was April 17, 1987. As of the hearing date, the complaints had not been corrected, and the work had not been completed in accordance with the contract. On or about March 13, 1987, the Respondent obtained a building permit from Pinellas County, Florida, for the installation of the aluminum soffit and facia work, only. Later, after the Respondent had terminated his relationship with Tropical, the job was inspected by the Department of Building Inspections of Pinellas County and was cited for violations of the applicable local codes which never were corrected. The work that was done was done in a grossly negligent or incompetent manner. The Warzybok Case On or about January 14, 1987, Mr. and Mrs. Warzybok, entered into a contract with Tropical Exteriors and Services, Inc., for the removal and replacement of the Warzyboks flat roof at their residence located at 6088 - 27th Avenue, St. Petersburg, Florida. Before entering into the contract, the Warzyboks relied on the information on the contract letterhead which contained the Respondent's name, type of state certificate, license number, number of years of experience and the representation that the Respondent was insured. Additionally, the Warzyboks called the Better Business Bureau and checked on Tropical Exteriors and Services, Inc., to see if any complaints had been filed. Before entering into the contract, the Warzyboks' old flat roof was leaking on the outside of an exterior wall but was not leaking inside. Shortly after the contract was signed, Tropical tore off the old roof, mopped one coat of tar over it, and after it started to rain, put some visqueen over the roof and left. Sometime during the following week, representatives of Tropical finished mopping, put some roof paper down and did some other miscellaneous work. Approximately one week later, Warzybok had the tile roof over the main house pressure cleaned (this roof was connected to the flat roof). When the water from the pressure cleaning came off the tile roof onto the flat roof, the water flooded the room underneath the flat roof. The Warzyboks also discovered that there were broken tiles on the roof over the main house. The flat roof was now leaking inside as well as outside. The Warzyboks attempted on numerous occasions to contact Tropical and have Tropical correct the problems and finish the work. Numerous appointments were made to finish the work and correct the problems, most of which were not kept. Whatever work was done by Tropical did not complete the job or correct the problems. At one point, Tropical sent out a new roofer, Bill Vance, who told the Warzyboks that the roof needed to be totally redone. Several months after the job was started, the homeowners called the City to get an inspection and determined that no permit had been obtained for the job. The City of St. Petersburg Building Department went to the Warzybok property and determined that there had been no permit issued and that the persons who were working on the premises were not licensed roofers. The building department placed a stop order on the work and told the Warzyboks that they needed a licensed roofer to complete the job. The job still has not been completed, and the problems have not been corrected. As of the hearing date, the Warzyboks have problem with leaking skylights, skylights covered with tar, a leaking fireplace, plaster being separated from the sheetrock because of water damage, roofing tiles that were not replaced after they were broken by Tropical and tar on the bottom of the roof, among other things. The Warzyboks got an estimate of $275 just to replace one piece of plaster adjacent to the fireplace only. Tropical started the roof as a three-ply roof and then changed the roof to a one-ply roof. There has been leaking at the chimney and at the skylights, which were not properly installed Some of the tile removed from the main roof at the point of tie-in with the flat roof has not been replaced properly and, in some places, has not been replaced at all. The Respondent, under whose license the work was done, did not know of, and did not properly supervise, the installation of the roof. The roof was installed in an incompetent manner.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Construction Industry Licensing Board find the Respondent guilty of violating Section 489.105(4), 489.119, and 489.129(1)(d), (e), (g), (j) and (m) , Florida Statutes, and that, as punishment, impose on the Respondent a fine of $5000, suspend the Respondent's license for three years and place the Respondent on probation for one year after termination of the suspension conditioned on completion of continuing education designated by the Board and on such other terms that the Board deems appropriate. DONE and ENTERED this 20th day of April, 1989 in Tallahassee, Leon County, Florida. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of April, 1989. APPENDIX TO RECOMMENDED ORDER CASE NOS. 88-5197, 88-5198 and 88-5199 To comply with Section 120.59(2), Florida Statutes (1987), the following rulings are made on the parties' proposed findings of fact: Petitioner's Proposed Findings of Fact. 1.-4. Accepted and incorporated. Sixth sentence, rejected because it was additional sealant, not fiberglass, that was put on the rental unit. Otherwise, accepted and incorporated. Accepted and incorporated. Proposed findings regarding the "high ridge" rejected as not supported by the evidence but otherwise accepted and incorporated. Rejected that the owners held back $1,400 (they held back $900) but otherwise accepted and incorporated. Proposed findings regarding the owners' telephone calls to the inspection department and the inspection results rejected as not supported by the evidence. First and penultimate sentences, accepted and incorporated. 10.-11. Accepted and incorporated. 12. Subordinate and unnecessary. 13.-28. Accepted and incorporated. 29. Accepted but subordinate and unnecessary. 30.-33. Accepted and incorporated. 34. Proposed findings that the permit was pulled after the work for purposes of correcting the work rejected as not proven by the evidence. Otherwise, accepted and incorporated. 35.-45. Accepted and incorporated. The estimate was for plaster, not "plastic." Otherwise, accepted and incorporated. Accepted and incorporated. Second sentence, rejected as not supported by the evidence. Otherwise, accepted and incorporated. Accepted and incorporated. Respondent's Proposed Findings of Fact. (These rulings relate to the unnumbered paragraphs in the Respondent's March 23, 1989, letter, starting with the third paragraph. They are assigned consecutive paragraph numbers for purposes of these rulings.) Accepted and incorporated. First sentence, accepted and incorporated; second sentence, rejected as contrary to facts found. Accepted but subordinate to facts found and unnecessary. First and last sentences, accepted and incorporated. Second and third sentences, rejected as contrary to facts found. First sentence, accepted and incorporated. Second sentence, rejected as unclear. Accepted. First sentence, incorporated; second sentence unnecessary. First and third sentences, rejected as contrary to the weight of the evidence; second sentence, accepted but unnecessary. First sentence, accepted and incorporated (although the unlicensed companies using the Respondent's name also did work and assumed responsibility for the jobs over which the Respondent exercised no control at all.) Second sentence, rejected as contrary to facts found. COPIES FURNISHED: Jack M. Larkin, Esquire 806 Jackson Street Tampa, Florida 33602 Richard Lee Melvin 12737 North Florida Avenue Tampa, Florida 33612 Fred Seely, Executive Director Florida Construction Industry Licensing Board 111 East Coastline Drive, Suite 504 Jacksonville, Florida 32202 Kenneth E. Easley, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
