Division of Administrative Hearings, Florida
Filed: Feb. 20, 1995
The issues are whether Petitioner Mitchell Brothers, Inc. is entitled to recover attorneys' fees and costs from Respondent State of Florida, Department of Transportation, under Section 120.57(1)(b)(5), Florida Statutes, and if so, in what amount.No entitlement to attorney's fee and cost. Department of Transportation justified in sending delinquency letter where delay on project contractor's fault.
