Decision will be entered under
PARIS,
The issues for decision are whether petitioner is: (1) eligible to account for two of its contracts using the completed contract method of accounting and (2) liable for accuracy-related penalties.
Some of the facts are stipulated and are so found. The first stipulation of facts and the first supplemental stipulation of facts, and the exhibits attached thereto, are incorporated herein by this reference. Petitioner, Basic Engineering, Inc., was a Texas corporation with its principal place of business in Texas when it timely filed its petition.
Petitioner's primary business is the engineering, designing, procuring, refurbishing, and delivering of crude oil processing and refining systems to customers in the petrochemical industry worldwide.2017 Tax Ct. Memo LEXIS 24">*25 Thomas Balke owned 51% of petitioner and James Smith owned 49%; Mr. Balke and Mr. Smith also owned Basic Equipment, Inc. (Basic Equipment), another Texas corporation, in the same *28 respective percentages. Mr. Balke was the president of both corporations during the years in issue. Mr. Balke has over 30 years of experience in working with oil refineries and refinery equipment; his international oil refinery business experience first occurred in 1977.
This case concerns the accounting treatment for tax purposes of two of petitioner's contracts that were ongoing in 2009 and 2010: (1) petitioner's contract with Petromaxx Energy Group GmbH, later known as Petromaxx Energy Group GmbH & Co KG, and later as Tagore Investments S.A. as universal successor (collectively Petromaxx); and (2) petitioner's contract with Amber Energy S.A. (Amber). Since its incorporation in 2004 petitioner has accounted for its long-term contracts using the completed contract method of accounting. Respondent's determinations that petitioner was ineligible to use the completed contract method of accounting for the Petromaxx and Amber contracts led to the deficiencies at issue.
Petitioner and Basic Equipment maintained relationships with salespersons working outside the United States who searched for potential customers on their behalf. In 2004 a salesman contacted a Basic Equipment representative to inform *29 him that the international entity Petromaxx was interested in building a small oil refinery in Bulgaria with a 10,000 to 15,000 barrel per day (BPD) crude oil topping unit. Mr. Balke, acting on behalf of Basic Equipment, offered to build Petromaxx a new refinery, but Petromaxx wanted a refinery that was readily available and wanted petitioner to find an existing refinery, disassemble it, and refurbish various parts according to Petromaxx's specifications. The newly refurbished parts would then be reconstructed into a new refinery at Petromaxx's preferred international location.
Representatives for Basic Equipment and Petromaxx visited an existing oil refinery in Nixon, Texas (Nixon refinery), that had equipment similar to the equipment Petromaxx had initially described. After visiting the refinery Basic Equipment made a proposal to refurbish the refinery's parts and sell them to Petromaxx, which would then construct an operating refinery. Basic2017 Tax Ct. Memo LEXIS 24">*27 Equipment and Petromaxx ultimately reached an agreement on December 4, 2005 (Nixon equipment agreement).
Under the terms of the Nixon equipment agreement, Basic Equipment agreed to: design and manufacture one new 10,000 BPD atmospheric crude unit and one reconditioned 17,000 BPD crude topping unit; provide Petromaxx with designs and flow diagrams necessary to operate and perform maintenance on the *30 crude units; provide Petromaxx with plant operation manuals; and supervise the commissioning of the crude units once they were assembled. In exchange, Petromaxx agreed to pay Basic Equipment $21.5 million; Petromaxx initially paid Basic Equipment $6,450,000 as a deposit on December 23, 2005.
Early in 2006 Petromaxx determined that it needed to build a larger production capacity refinery than the Nixon refinery could provide and withdrew the previous agreement.
After determining that the Nixon refinery would not meet its production capacity needs, Petromaxx provided Mr. Balke with new scope of work requirements. In an effort to find a refinery that would meet Petromaxx's production capacity requirements, Mr. Balke and a Petromaxx2017 Tax Ct. Memo LEXIS 24">*28 representative visited a larger refinery with a 50,000 to 55,000 BPD capacity in California (Cenco refinery). After examining the Cenco refinery, Mr. Balke offered to refurbish and sell the refinery's parts to Petromaxx, which would then construct an operating refinery. At some point Mr. Balke made the decision to transfer the *31 order from Basic Equipment to petitioner.2 Basic Equipment transferred to petitioner Petromaxx's original $6,450,000 Nixon refinery deposit in installments of $3 million on February 8, 2006, $3 million on March 8, 2006, and $450,000 on March 28, 2006.
On March 22, 2006, petitioner purchased the Cenco refinery from JAS Marketing, Inc. (JAS), for $18.9 million for use in the Petromaxx project. Petitioner agreed to make its first payment to JAS on or before March 22, 2006, with subsequent payments due monthly through August 22, 2007.
Before executing a formal agreement, Petromaxx transferred to petitioner $10,750,000 in addition to the $6,450,000 deposit Petromaxx paid to Basic Equipment, which was subsequently transferred to petitioner. The advanced funds were paid to petitioner in two equal installments of $5,375,000 on May 22 and September2017 Tax Ct. Memo LEXIS 24">*29 1, 2006.
On October 28, 2006, petitioner and Petromaxx executed a "Sale and Purchase Agreement" (Petromaxx SPA) whereby Petromaxx agreed to purchase certain crude oil processing units from petitioner. The Petromaxx SPA required *32 petitioner to refurbish the oil processing units and to provide Petromaxx with engineering specifications that Petromaxx would use to install the newly refurbished units and construct an operating refinery.3 Once the Cenco refinery was broken down and the necessary parts refurbished, petitioner was responsible for delivering the refurbished units to its facility in Houston, Texas, and Petromaxx was responsible for shipping the refurbished units from there to Bulgaria. Petromaxx was also responsible for creating the refinery site in Bulgaria and erecting and installing the newly refurbished units into a refinery. Once Petromaxx had erected and installed the refurbished units, petitioner was required to supervise the commissioning4 of the newly erected units. Upon successful *33 commissioning of the refinery, a qualified engineer would conduct performance tests and issue a "final acceptance report and certificate" upon successful testing. At that point, petitioner2017 Tax Ct. Memo LEXIS 24">*30 would have fulfilled all of its obligations under the Petromaxx SPA and Petromaxx would assume full responsibility for the refinery and its operation. In consideration for a complete, satisfactory, and timely performance by petitioner of all of its obligations under the Petromaxx SPA, Petromaxx agreed to pay petitioner $90.5 million.5
The Hardt Investment Group, headquartered in Vienna, Austria, controlled the underlying funding of Petromaxx, and the parties negotiated the following governing law provision in This Agreement shall be governed by, and construed in accordance with, the laws of the Republic of Austria including the UN Convention on Contracts for the International Sale of Goods of 1980 (CISG). The Parties' rights and obligations with respect to title to and security interests in the Equipment shall be governed by the law of the jurisdiction in which such Equipment is located.
After executing the Petromaxx SPA, Petromaxx once again determined that it wanted to increase the capacity of its refinery. On October 6, 2007, almost one year after the original contract was executed, petitioner and Petromaxx executed an amendment to the Petromaxx SPA whereby2017 Tax Ct. Memo LEXIS 24">*31 petitioner agreed to refurbish additional equipment that would allow Petromaxx to meet its capacity requirements. Petromaxx agreed to pay an additional $31,750,000 to petitioner for the additional equipment, bringing the total contract price to $122,250,000. In October of 2007, at the time the parties executed the amendment to the Petromaxx SPA, Petromaxx had made payments to petitioner totaling $72.4 million.6
For purposes of accounting for the Petromaxx contract, petitioner's estimate of the time the contract would take to complete is important. The Court will look to the terms of the Petromaxx SPA and will consider testimony from Mr. Balke and respondent's expert witness, John Harris.
With respect to the Petromaxx project's expected timeframe, Agreed Project Schedule. BASIC shall commence * * * [its work] in accordance with the project schedule and management plan set forth in Exhibit 3.2.2 (the "Preliminary Project Schedule"). Within one (1) month after signing this Agreement, BASIC shall submit, for BUYER's review and approval, an updated and more detailed schedule (as approved by Qualified Engineer and by BUYER, the "Agreed2017 Tax Ct. Memo LEXIS 24">*32 Project Schedule") amending the Preliminary Project Schedule which sets forth the timing of completing the [Cenco refinery] Units and of all other major elements of * * * [petitioner's obligations] as well as the interrelationship of such elements. Dates included in the Agreed Project Schedule shall be the best estimates available at the time of submission of the Agreed Project Schedule but shall not be guaranteed dates of delivery or achievement of listed milestones or objectives, except that Delivery of the last [Cenco refinery] Unit is guaranteed to occur no later than twelve (12) months after the signing of this Agreement.
Although the Petromaxx SPA did not contain a project schedule, it required petitioner to "use its best efforts" to deliver the last refurbished unit to its facility in Houston, Texas, by April 30, 2007; however, if petitioner failed to deliver the *36 last unit by April2017 Tax Ct. Memo LEXIS 24">*33 30, 2007, the Petromaxx SPA did not provide for penalties. If petitioner failed to deliver the last unit on or before September 12, 2007, petitioner would default under the terms of the Petromaxx SPA.7 These delivery dates are the only performance dates specified in the Petromaxx SPA.8
*37 Importantly, the Petromaxx SPA did not include terms requiring Petromaxx to ship the refurbished units from Houston, Texas, to Bulgaria by a specific date, begin or finish creating the refinery2017 Tax Ct. Memo LEXIS 24">*34 site by a specific date, or begin or finish installing and erecting the newly refurbished units into a refinery by a specific date. Petitioner did not offer into evidence any documentation reflecting dates by which petitioner or Petromaxx expected Petromaxx to begin or finish its obligations.
*38 With respect to the terms of payment, the Petromaxx SPA indicates that2017 Tax Ct. Memo LEXIS 24">*35 the parties anticipated the final payment to become due on the earlier of: (1) 10 months after the "Final Delivery Date", which was September 12, 2007, or (2) the "Final Acceptance Date", which was the date that the qualified engineer issued a completion report.
Because the Petromaxx SPA did not specify dates by which Petromaxx would ship the refurbished units, finish creating the refinery site, or finish installing and erecting the newly refurbished units into a refinery, it is unclear exactly when the parties expected the Petromaxx SPA to be completed.
Mr. Balke testified that 3-D laser scanning technology was introduced to his industry in the early to mid-2000s. This technology allowed existing refineries to be scanned before their deconstruction and produced blueprints and models of the assembled refineries timelier than the traditional method of measurement and modeling. These blueprints and models could then be shipped elsewhere to assist in the preparation of the new site for construction. According to Mr. Balke petitioner was an early adopter of this technology, and he intended petitioner to use it in completion of the Petromaxx SPA.
*39 In theory, by using2017 Tax Ct. Memo LEXIS 24">*36 the increased efficiency of the 3-D scanning, multiple stages of the refurbishing and reconstruction processes could proceed in tandem. Mr. Balke used the phrase "parallel processing" to describe this system of operation. The logistics of this theory operated in the following manner: Each stage of the dismantling project would be scanned and modeled, and the model would be sent to the purchaser; then, simultaneously, petitioner would begin dismantling and refurbishing the scanned sections of the refinery while the purchaser used the models to prepare the new site for the refinery's specific reconstruction requirements. Despite the theory's temporal benefits, Mr. Balke testified that he was aware of only two other companies in petitioner's industry currently using a parallel processing system.
Respondent called John R. Harris, PE, to testify as an expert witness on the process of creating, constructing, and operating refineries. The Court recognized Mr. Harris as such an expert and received into evidence his expert witness report, in which he stated his opinion regarding a reasonable estimate of time it would take to complete the Petromaxx refinery2017 Tax Ct. Memo LEXIS 24">*37 project.
Mr. Harris opined that a three-year timeframe to complete the Petromaxx project was "optimistic but possible." To arrive at his conclusion, Mr. Harris*40 noted that the only performance date specified in the Petromaxx SPA was September 12, 2007, the date by which petitioner was required to deliver the equipment. Because the Petromaxx SPA did not specify dates by which the remaining components of the Petromaxx refinery project would begin and finish, Mr. Harris was required to make assumptions and estimate how long the remaining components would take, which he summarized as follows: One must make an estimate of the reasonable time required to ship the equipment, acquire the balance of the equipment, supplies and services necessary to complete a refinery. Foreign shipping to an inland port in the developing world is difficult to estimate. Six months seems like an optimistic period to have everything in place in Bulgaria, assuming no delays in long lead-time equipment, no local shortages of necessary supplies or scarcity of skilled labor. Following Owner acquisition of the equipment, and presuming finished engineering proceeds timely, final erection of the refinery could hardly be2017 Tax Ct. Memo LEXIS 24">*38 expected in less than one year. If commissioning proceeds promptly and few problems are found, this task should take 6 weeks, followed by another month for a performance run on the refinery.
Mr. Harris did not take petitioner's parallel processing system into consideration in reaching his conclusions with respect to the Petromaxx SPA's timeframe. Instead, Mr. Harris' conclusion was based on traditional industry practices, and Mr. Balke agreed with Mr. Harris' conclusion to the extent he had relied on traditional industry practices. Mr. Balke disagreed with Mr. Harris' overall conclusion that the Petromaxx project would take at least three years to *41 complete because Mr. Harris did not consider how much time 3-D laser imaging or petitioner's parallel processing system would save.
Ultimately, the Petromaxx refinery project was not completed. At some point during the course of the project, Petromaxx lost its financing and was unable to pay petitioner. At the time of trial, the dismantled units from the Cenco refinery were still in petitioner's construction yard in Texas.
While petitioner was working on the Petromaxx refinery project, a2017 Tax Ct. Memo LEXIS 24">*39 representative from the Hardt Investment Group contacted Mr. Balke to inform him that Amber was interested in purchasing a 100,000 BPD refinery and assembling it in Pakistan. Mr. Balke informed the representative that he was aware of a 100,000 BPD refinery in Turkey (Ataş refinery) that would meet Amber's production capacity requirements. Toplam Mühendislik ve Taahhüt İthalat İhracat Limited Şirketi (Toplam), a company incorporated in Turkey, contracted to supply the Ataş refinery units.9
On July 17, 2008, petitioner and Amber executed a "Sale and Purchase Agreement" (Amber SPA). The Amber SPA required petitioner to identify and negotiate purchase orders with third-party vendors to procure oil processing units for use in the Amber project, refurbish those units, and deliver the newly refurbished units to a designated location. To satisfy those obligations, petitioner purchased the Ataş refinery units from Toplam for $18 million via a "Supply Agreement" executed on July 24, 2008 (Toplam supply agreement). Under the terms of the Toplam supply agreement, Toplam agreed to dismantle the Ataş refinery and deliver the dismantled units to a specified2017 Tax Ct. Memo LEXIS 24">*40 location in Turkey in a condition that would allow them to be refurbished on site. Petitioner then subcontracted with third parties to perform the refurbishing work that was specified in the Amber SPA; the refurbishing work would occur while the Ataş units were at the Ataş refinery site in Turkey.10 Upon completion of the work in *43 Turkey, Amber was responsible for transporting the newly refurbished units to a site in Pakistan.11
The Amber SPA required petitioner to obtain a fluid catalytic cracker unit (FCCU)12 for use in the Amber project. Petitioner agreed to acquire, dismantle, and transport the FCCU to its Houston, Texas, facility for refurbishing work. Petitioner purchased an FCCU from a third party in Wichita, Kansas, for use in the Amber project.
The Amber SPA also required petitioner to provide Amber with engineering specifications and drawings that Amber would use to install the newly refurbished units and construct an operating refinery. Amber was responsible for creating and preparing the refinery site and erecting and installing the newly refurbished units if it elected to do so.13 If Amber chose to erect and install the refurbished units, petitioner was required to supervise the2017 Tax Ct. Memo LEXIS 24">*41 commissioning of the newly erected *44 refinery. Upon successful commissioning of the refinery, a qualified engineer would conduct performance tests and issue a "final acceptance report and certificate" upon successful testing. At that point, petitioner's obligations under the Amber SPA would end and Amber would assume full responsibility for the refinery and its operation. In consideration for a complete, satisfactory, and timely performance by petitioner of all of its obligations under the Amber SPA, Amber agreed to pay petitioner $100 million.
The Amber SPA contained the following governing law provision: This Agreement shall be governed by, and construed in accordance with, the laws of the State of Texas, including
For purposes of accounting for the Amber contract, petitioner's estimate of the time the contract would take to complete is important. The Court will look to the terms of the Amber SPA and will consider testimony from Mr. Balke and respondent's2017 Tax Ct. Memo LEXIS 24">*42 expert witness, John Harris.
With respect to the Amber SPA's timeframe, BASIC shall commence * * * [its work] in accordance with the Project Schedule and shall use its best efforts to ensure that * * * [its work is] performed in accordance with the Project Schedule. Dates included in the Project Schedule are the best estimates available on the date of this Agreement but are not guaranteed dates of delivery or achievement of listed milestones or objectives, except that Delivery of all items comprising the * * * [complete package of crude oil processing and refining equipment] is guaranteed to occur no later than the Delivery Deadline [November 15, 2010]. Modifications to the Project Schedule shall only be made with the prior written approval of * * * [Amber].
A project schedule was not attached to the Amber SPA, and petitioner did not offer into evidence a project schedule or any other documentation that would reflect dates by which the parties expected the various components of the project to be completed.
Although the Amber SPA did not contain a project schedule, the agreement required petitioner to deliver the last unit "no later than" November 15, 2010. Petitioner2017 Tax Ct. Memo LEXIS 24">*43 was entitled to bonus payments if the delivery date for the units occurred before November 15, 2010, and subject to penalties if the delivery date occurred after November 15, 2010.
*46 Importantly, just like the Petromaxx SPA the Amber SPA did not include terms requiring Amber to ship the refurbished units by a specific date, begin or finish creating the refinery site by a specific date, or begin or finish installing and erecting the newly refurbished units into a refinery by a specific date. Petitioner did not introduce into evidence any documentation reflecting dates by when petitioner or Amber expected Amber to begin or finish its obligations.
If Amber elected to erect the refinery, petitioner was required to provide at least one field engineer to supervise the commissioning process. After successful commissioning, a qualified engineer would conduct performance tests which "must in any case be completed within sixty (60) days, or such other period as may be agreed in writing by the Parties, from the date on which Commissioning has commenced." Once the qualified engineer was satisfied that the performance tests showed that the newly installed and erected refinery met certain standards,2017 Tax Ct. Memo LEXIS 24">*44 he was to issue a report. At that point, petitioner's obligations under the Amber SPA would end and Amber would assume full responsibility for the refinery and its operation. The Amber SPA did not specify an overall project completion date.
With respect to the terms of payment, the Amber SPA indicated that the parties anticipated the final payment's becoming due on the earlier of: (1) 10 months after the "Delivery Date", which was the date on which petitioner *47 delivered the refurbished units to its facility in Houston, Texas, or (2) the "Final Acceptance Date", which was the date on which the qualified engineer issued a completion report.14
Because the Amber SPA, like the Petromaxx SPA, did not specify dates by when Amber was required to ship the refurbished units, finish creating and preparing the refinery site, or finish installing and erecting the newly refurbished units into a refinery, it is unclear exactly when the parties expected the Amber SPA to be completed.
Mr. Balke testified that the Amber refinery project was simpler from a logistics perspective than the Petromaxx refinery project and was likely to be finished faster than Petromaxx, starting2017 Tax Ct. Memo LEXIS 24">*45 from each respective contract's start date. In addition he pointed to the Amber SPA, which refers to the possibility that petitioner would use 3-D laser scanning and modeling. As with the Petromaxx SPA, Mr. Balke's intent was for petitioner to use parallel processing in fulfilling the contract obligations of the Amber SPA.
Mr. Harris opined that a 4-1/2-year timeframe to complete the Amber refinery contract was "optimistic but possible." In arriving at his conclusion, Mr. Harris noted that the "Amber plant is double the size of the * * * [Petromaxx] plant, involving more work and time." Mr. Harris also noted that the only performance date specified in the Amber SPA was with respect to petitioner's delivery obligations; petitioner was required to deliver the equipment by November 15, 2010, roughly 28 months after the date on which the Amber SPA was executed. Because the Amber refinery project did not specify dates by which the remaining components of the Amber SPA would begin and finish, Mr. Harris was required to make assumptions and estimate the time it would take to complete the remaining tasks, which he summarized as follows: One must make2017 Tax Ct. Memo LEXIS 24">*46 an estimate of the reasonable time required to ship the equipment, acquire the balance of the equipment, supplies, and services necessary to * * * complete the Amber refinery in Pakistan. Foreign shipping in the developing world is difficult to estimate. Seven months seems like an optimistic period to have everything in place in Pakistan, assuming no delays in long lead-time equipment, no local shortages of necessary supplies or scarcity of skilled labor. Following Owner acquisition of the equipment, and presuming finished engineering proceeds timely, final erection of the refinery could hardly be expected in less than 18 months. If commissioning proceeds promptly, and few problems are found, this task should take *49 two months, following by another two months for a performance run on the refinery.15
As with the Petromaxx SPA, Mr. Harris' overall conclusion with respect to the Amber SPA's timeframe did not take petitioner's parallel processing system into consideration.
On the same day that petitioner and Amber executed the Amber SPA they also executed a "Side Letter" to the Amber SPA whereunder the parties agreed that the due date for certain installment payments would2017 Tax Ct. Memo LEXIS 24">*47 be extended because Amber had not yet obtained sufficient financing to effect payment for the installments. After approximately 18 months, on January 18, 2010, the parties agreed to cancel the Amber SPA and release themselves from all responsibilities and liabilities under the SPA's terms. At the time of trial, the FCCU was still in *50 petitioner's construction yard in Texas, and the Ataş refinery units were still in Northern Cyprus.
From 2005 to 2010 petitioner accounted for the Petromaxx and Amber contracts using the completed contract method of accounting; each return was prepared and signed by the same certified public accountant (CPA). A taxpayer using the completed contract method of accounting recognizes all income and expenses associated with a contract only in the contract's completion year.
Before 2007 | $20,395,917 | $122,250,000 | $16,316,738 | $97,800,000 |
2007 | 49,708,361 | 122,250,000 | 39,766,687 | 97,800,000 |
2008 | 31,978,623 | 122,250,000 | 25,582,819 | 97,800,000 |
2009 | 866,631 | 122,250,000 | 709,295 | 97,800,000 |
2010 | 192,707 | 122,250,000 | 154,174 | 97,800,000 |
Total | $103,142,239 | $82,529,713 |
Before 2007 | -- | -- | -- | -- |
2007 | -- | -- | -- | -- |
2008 | $33,252,634 | $101,000,000 | $26,667,954 | $81,000,000 |
2009 | 1,418,775 | 101,000,000 | 1,137,835 | 81,000,000 |
2010 | 31,585 | 101,000,000 | 25,325 | 81,000,000 |
Total | $34,702,994 | $27,831,114 |
Respondent determined that petitioner was ineligible to use the completed contract method of accounting for the Petromaxx and Amber SPAs. The notice of deficiency reflected alternative accounting positions for petitioner's projects.2017 Tax Ct. Memo LEXIS 24">*49
*52 Under either position, respondent determined that petitioner was not eligible to report income under the completed contract method of accounting. Respondent determined that the Petromaxx SPA should have been reported as a manufacturing contract and that petitioner should have accounted for the Petromaxx SPA using the accrual method of accounting.16 As his alternative position, respondent determined that petitioner must account for both contracts using the percentage of completion method because petitioner could not have estimated their completion within the two-year period beginning on the respective contract commencement dates.
As discussed
*53 The percentage of completion method of accounting requires taxpayers to recognize income and expenses throughout the duration of a contract on the basis of the percentage of the2017 Tax Ct. Memo LEXIS 24">*50 contract that is actually completed. Accordingly, respondent's alternative position adjusted petitioner's gross receipts and cost of goods sold figures for the Petromaxx and Amber SPAs on the basis of the percentage that the contracts were completed in 2009 and 2010.
To determine the percentages of the Petromaxx and Amber SPAs that were completed, respondent used the schedule of contracts petitioner had provided; in accordance with
Respondent then multiplied the percentage each contract was completed by the estimated total contract price to arrive at the amounts petitioner should have recognized as income had it accounted for the contracts using the percentage of completion method of accounting. For 2009 respondent adjusted petitioner's gross receipts2017 Tax Ct. Memo LEXIS 24">*51 by $137,644,475.20 Because petitioner did not report any income or expenses from the Petromaxx or Amber contract from 2005 to 2009, the 2009 adjustment accounts for all income that petitioner should have recognized between *55 2005 and
Respondent allowed corresponding adjustments for cost of goods sold and made an adjustment for a
Generally, the Commissioner's determinations set forth in a notice of deficiency are presumed correct, and the taxpayer bears the burden of showing the determinations2017 Tax Ct. Memo LEXIS 24">*52 are in error.
To prevail, the taxpayer must establish that the Commissioner abused his discretion in changing the method of accounting.
Generally, taxpayers who receive income from long-term contracts must account for that income using the percentage of completion method of accounting.
Respondent's primary position is that the Petromaxx SPA is a manufacturing contract and that it fails to meet the
Manufacturing contracts are generally not treated as long-term contracts, meaning the long-term contract accounting rules of
At issue are two contracts--each for the disassembly, transportation, refurbishing, assembly, and certification of a new oil refinery. Petitioner introduced sufficient evidence, corroborated by the testimony of Mr. Balke, showing that the2017 Tax Ct. Memo LEXIS 24">*55 processes involved normally require more than 12 calendar months to complete. Respondent's expert, Mr. Harris, agreed, stating that the *60 assembly process alone "could hardly be expected in less than one year." Assuming without finding that these contracts are for the manufacture of two oil refineries, each would fall under the
The Commissioner may not change a taxpayer's method of accounting from an incorrect method to another incorrect method.
In some instances taxpayers may account for income from certain construction contracts under a method of accounting other than the percentage of completion method, such as the completed contract method.2017 Tax Ct. Memo LEXIS 24">*56
Petitioner accounted for the Petromaxx and Amber SPAs using the completed contract method. Respondent determined that petitioner was ineligible to use the completed contract method. The parties disagree over whether (1) the contracts were "construction contracts" under
To be eligible for the construction contract exception to the percentage of completion method, the taxpayer must estimate, at the time the contract is entered into, that it will be completed within the two-year period beginning on the contract commencement date.
For purposes of
With respect to estimating the length of a contract under A taxpayer must use a reasonable estimate of the time required to complete a contract when necessary to classify the contract (e.g., to determine whether * * * the two-year completion rule for exempt construction contracts * * * is satisfied * * *). To be considered reasonable, an estimate of the time required to complete the contract must include anticipated time for delay, rework, change orders, technology or design problems, or other problems that reasonably can be anticipated considering the nature of the contract and prior experience. A contract term that specifies an expected completion or delivery2017 Tax Ct. Memo LEXIS 24">*59 date may be considered evidence that the taxpayer *64 reasonably expects to complete or deliver the subject matter of the contract on or about the date specified, especially if the contract provides bona fide penalties for failing to meet the specified date. If a taxpayer classifies a contract based on a reasonable estimate of completion time, the contract will not be reclassified based on the actual (or another reasonable estimate of) completion time. A taxpayer's estimate of completion time will not be considered unreasonable if a contract is not completed within the estimated time primarily because of unforeseeable factors not within the taxpayer's control, such as third-party litigation, extreme weather conditions, strikes, or delays in securing permits or licenses.
Often, a written contract objectively manifests the taxpayer's expectations at the time the taxpayer enters into the contract. However, the regulations do not require the Court to make its determination with respect to the two-year rule on the basis of the contract alone, and the dates specified in the contract are not dispositive.
Although petitioner and Petromaxx formally executed the Petromaxx SPA on October 28, 2006, the first date on which petitioner incurred costs2017 Tax Ct. Memo LEXIS 24">*61 allocable to the Petromaxx SPA (other than bidding expenses or expenses incurred in connection with negotiating the contract) was March 22, 2006, when petitioner purchased the Cenco refinery for use in the Petromaxx SPA. Thus, for purposes of
The parties disagree as to whether petitioner reasonably estimated that the Petromaxx SPA could have been completed within two years from the contract commencement date of March 22, 2006. Respondent relies on the terms of the Petromaxx SPA and Mr. Harris' expert testimony that three years is an optimistic estimate of the time required to complete a project similar to the Petromaxx refinery project. Petitioner contends that its 3-D laser scanning and parallel processing system allowed it to reasonably estimate that the Petromaxx SPA would be completed within two years. Further, petitioner argues that Mr. Harris did not consider petitioner's parallel processing system when determining how long it would take the parties to complete the Petromaxx refinery project and that he was altogether unfamiliar with parallel processing.2017 Tax Ct. Memo LEXIS 24">*62
The two-year rule requires the Court to look at petitioner's expectations at the time it entered into the contract.
*67
Petitioner's contractual obligations were not complete upon delivery of the last refurbished unit. The parts then had to be shipped from Texas to Bulgaria and assembled according to petitioner's detailed modeling, and the newly assembled refinery had to be commissioned under petitioner's supervision and a final acceptance report and certificate obtained upon successful testing. Only then would petitioner's contractual obligations be fulfilled. And the Petromaxx *68 SPA did not specify dates by when these remaining obligations were to be complete.
Respondent introduced an expert witness report into evidence. In that report Mr. Harris estimated how long the remaining components of the Petromaxx refinery project would take, i.e., how long it would take to ship the delivered units from Texas to Bulgaria; how long it would take to assemble the refinery once Petromaxx was in possession of all of the equipment; and how long it would take to commission and performance test the newly assembled refinery. Mr. Balke agreed with Mr. Harris' conclusions to the extent they were based2017 Tax Ct. Memo LEXIS 24">*64 on traditional industry practices.
Once petitioner delivered the final unit, Petromaxx had to ship the units to Bulgaria; Mr. Harris opined that six months was an optimistic estimate of only the time required to ship the units to Bulgaria, which did not include the time required to assemble the new refinery. Once Petromaxx acquired all of the equipment, it had to assemble the refinery; Mr. Harris estimated that the assembly process alone "could hardly be expected in less than one year." Once Petromaxx assembled the refinery, petitioner was required to supervise the commissioning process; Mr. Harris estimated that the commissioning process would take six weeks. After the commissioning process was complete, a qualified engineer was to conduct *69 performance tests and issue a final report upon successful testing; Mr. Harris estimated that performance testing would take approximately one month. At that point petitioner would have finally completed all of its obligations under the Petromaxx SPA.
Even if the Court concludes that April 30, 2007 (the best efforts date)--and not September 12, 2007 (the default date)--is the relevant delivery date despite the Petromaxx SPA's not calling for penalties2017 Tax Ct. Memo LEXIS 24">*65 if petitioner did not deliver the units by then, the Petromaxx project still could not have been completed within two years from March 22, 2006, the contract commencement date. The time between the contract commencement date and the best efforts date was 13 months; once the units were delivered, it would take 6 months to ship them from Texas to Bulgaria. Upon receipt of all of the units, it would take Petromaxx 12 months to assemble the refinery; and once the refinery was assembled, it would take approximately 2-1/2 months to commission and conduct performance tests. In total, a project similar to the Petromaxx refinery project would take over 33 months to complete using traditional industry practices.
The Petromaxx SPA indicates that petitioner and Petromaxx anticipated the final payment's becoming due on the earlier of: (1) 10 months after the "Final Delivery Date", which the Petromaxx SPA defined as September 12, 2007, or (2) *70 the "Final Acceptance Date", which was defined as the date on which the qualified engineer issued a completion certificate.25 Assuming traditional industry practices, this provision puts the completion date more than two years after the contract commencement2017 Tax Ct. Memo LEXIS 24">*66 date. The Petromaxx SPA does not require the qualified engineer to issue a completion certificate by a certain date, and 10 months after the September 12, 2007, "Final Delivery Date" is July 12, 2008, which is more than two years after the March 22, 2006, contract commencement date.
Under
Petitioner acknowledges the lack of specificity in the Petromaxx SPA and the lack of formal documentation such as a project schedule but argues that the "parties intended for Petromaxx to begin building the * * * [refinery] *71 infrastructure while Petitioner was refurbishing the refinery" even though the Petromaxx SPA is silent on the matter.262017 Tax Ct. Memo LEXIS 24">*67
The Petromaxx SPA is governed by Austrian law, including the United Nations Convention on Contracts for the International Sale of Goods (CISG), Apr. 11, 1980, 1489 U.N.T.S. 59.27 The CISG embodies a liberal approach to contract *72 interpretation. Under the CISG a contract of sale may be proven by any means, including witnesses; it need not be evidenced by writing and is not subject to any2017 Tax Ct. Memo LEXIS 24">*68 other requirement as to form. (1) For the purposes of this Convention statements made by and other conduct of a party are to be interpreted according to his intent where the other party knew or could not have been unaware what the intent was. (2) If the preceding paragraph is not applicable, statements made by and other conduct of a party are to be interpreted according to the understanding that a reasonable person of the same kind as the other party would have had in the same circumstances. (3) In determining the intent of a party or the understanding a reasonable person would have had, due consideration is to be given to all relevant circumstances of the case including negotiations, any practices which the parties have established between themselves, usages and any subsequent conduct of the parties.
Even if the Court looks outside the terms of the Petromaxx SPA and considers statements and conduct of the parties, petitioner did not introduce any such evidence to support Mr. Balke's self-serving testimony that would allow the Court to conclude that the parties in fact agreed to implement a parallel processing system. Petitioner did not introduce any evidence that Petromaxx "knew or could not have been unaware what the intent was" with respect to the project's time line.
Petitioner did not produce any other witnesses, provide the Court with any documentary evidence that would reflect a meeting of the minds between the parties to use a parallel processing system, or even explain how much time parallel processing would save; instead petitioner relied solely on Mr. Balke's unsupported testimony. Although Mr. Balke has over 30 years of experience in working with oil refineries and refinery equipment, including international dealings, he did not provide a single concrete example of a project similar to the Petromaxx SPA where the parties conducted operations using a parallel processing system and which was complete within two years from its commencement date.28 Petitioner's *75 actions of purchasing the Cenco refinery and beginning the refurbishing process do not prove the intent or knowledge of Petromaxx to equally perform its responsibilities. Petitioner simply has not introduced sufficient evidence to show that its expectations2017 Tax Ct. Memo LEXIS 24">*71 with respect to the Petromaxx refinery project's timeframe differed from those projected by Mr. Harris according to traditional industry practices or objectively manifested in the Petromaxx SPA.
The Commissioner is granted broad discretion in determining whether an accounting method clearly reflects income, and that determination is entitled to more than the usual presumption of correctness.
Respondent's position that petitioner did not reasonably estimate that the Petromaxx refinery project could be completed within two years is supported by the documentation that is available for the Court to review, primarily the *76 Petromaxx SPA and its amendments, and by Mr. Harris' expert testimony. Petitioner attempts to rebut respondent's determination with Mr. Balke's testimony. However, petitioner did not introduce any other evidence to support Mr. Balke's testimony, and the Court is not required to accept self-serving testimony as true. The Court concludes that petitioner did not meet its burden in proving that, at the time it entered into the Petromaxx SPA,2017 Tax Ct. Memo LEXIS 24">*72 it reasonably believed the contract would be completed within two years from its commencement date. Accordingly, petitioner was not eligible to report income from the Petromaxx SPA using the completed contract method of accounting.
Petitioner and Amber executed the Amber SPA on July 17, 2008. The first date on which petitioner incurred costs allocable to the Amber SPA (other than bidding expenses or expenses incurred in connection with negotiating the contract) was July 24, 2008, when petitioner purchased the Ataş refinery from Toplam for use in the Amber SPA. Thus, for purposes of
As was the case with the Petromaxx SPA, the parties disagree whether petitioner reasonably estimated that the Amber SPA could have been completed within two years from the contract commencement date of July 24, 2008. Respondent argues that the terms of the Amber SPA itself show that petitioner did not reasonably expect the SPA to be completed within two years. Respondent also relies on Mr. Harris' expert testimony that 4-1/2 years is an optimistic2017 Tax Ct. Memo LEXIS 24">*73 estimate of the time required to complete a project similar to the Amber refinery project. Petitioner again argues that its 3-D laser scanning and parallel processing system allowed it to reasonably estimate that the Amber SPA would be completed within two years and that Mr. Harris did not consider petitioner's parallel processing system when determining how long it would take the parties to complete the Amber refinery project.
While the dates specified in a contract are not dispositive, the Court will first look to the terms of the Amber SPA to help determine petitioner's expectations at the time it entered into the agreement. The Amber SPA is governed by Texas law, including
Where an unambiguous writing has been entered into between parties, the courts will give effect to the parties' intention as expressed or apparent in2017 Tax Ct. Memo LEXIS 24">*74 the writing.
The terms of the Amber SPA are not ambiguous. While the Amber SPA is silent with respect to many anticipated performance dates, there is a significant legal difference between ambiguous contracts and silent contracts.
Taken together, the delivery date and the potential penalties and bonus payments indicate that the parties intended November 15, 2010, to be the approximate date by which petitioner would deliver the last unit. This delivery date occurred more than two years after the contract commencement date--July 24, 2008--and Amber still had to transport the refurbished parts from Turkey to Pakistan, construct the refinery, and commission and performance test the newly assembled refinery before petitioner would have satisfied its contractual obligations.
*80 Because the dates specified in the Amber SPA are not dispositive with respect to the two-year rule,
Although the terms of the Amber SPA do not reference parallel processing or specific dates by which the refinery had to be assembled, commissioned, and performance tested, petitioner argues that the November 15, 2010, delivery date was an arbitrary date selected by the parties and that the parties intended to implement petitioner's parallel processing system, which would have allowed the Amber SPA to be completed within "about 18 to 24 months."
Petitioner2017 Tax Ct. Memo LEXIS 24">*76 relies only on Mr. Balke's unsupported testimony; petitioner did not produce any other witnesses, provide the Court or respondent with documentary evidence that would reflect the parties' intent to use a parallel processing system,30 produce any evidence to show that the parties' conduct reflected an intent to conduct operations using a parallel processing system, or even explain exactly how much time parallel processing would save. Even if the *81 Court assumes that the parties would be completing their tasks simultaneously, petitioner did not prove that parallel processing would allow the parties to complete the contract within two years.
Although Mr. Balke has over 30 years of experience in working with oil refineries and refinery equipment, including international dealings, he did not provide a single concrete example of a project similar to the Amber refinery project where the parties conducted operations using a parallel processing system and completed it within two years from its commencement date. And there is no indication that Mr. Balke's projections took into account any unanticipated delays.
As with the Petromaxx refinery project, petitioner has not met its burden to prove that respondent's determination regarding the Amber refinery project was arbitrary. Respondent's position that petitioner could not have reasonably estimated that the Amber refinery project would be completed within two years is supported by the terms of the Amber SPA; on its face, the Amber SPA called for a *82 delivery date more than two years after the Amber SPA commencement date. Even if the Court considers Mr. Balke's self-serving testimony, petitioner did not provide any evidence to support his testimony. The Court concludes that petitioner did not meet its burden in proving that, at the time it entered into the Amber SPA, it reasonably expected the contract to be complete within two years from its commencement date. Accordingly, petitioner was not eligible to report income from the Amber project using the completed contract method of accounting.
Petitioner substantially understated its income tax for both 2009 and 2010, reporting zero tax liability for each of those years. And there is no disagreement that under either of respondent's alternative positions, the amount of tax required2017 Tax Ct. Memo LEXIS 24">*79 to be shown exceeds $10,000 for each year. Therefore, the Court will look next to whether petitioner has shown that it is not liable for the penalty because of reasonable cause.
Petitioner argues that it is not liable for the 20% accuracy-related penalty because, in view of the complexity of
In general the accuracy-related penalty does not apply to any portion of an underpayment of tax if it is shown that there was reasonable cause for such portion and that the taxpayer acted in good faith.
Reasonable cause requires that the taxpayer exercised ordinary business care and prudence as to the disputed item. When an accountant or attorney advises a taxpayer on a matter of tax law, such as whether2017 Tax Ct. Memo LEXIS 24">*80 a liability exists, it is reasonable for the taxpayer to rely on that advice. Most taxpayers are not competent to discern error in the substantive advice of an accountant or attorney. To require the taxpayer to challenge the attorney, to seek a "second opinion," or to try to monitor counsel on the provisions of the Code himself would nullify the very purpose of seeking the advice of a presumed expert in the first place. * * *
*85 Petitioner used the services of the same CPA from at least 2005 through 2010. However, the only evidence of petitioner's reliance upon professional advice rendered by its CPA is the fact that its Federal income tax returns were filed. Nothing in the record indicates that petitioner either requested of or received from its CPA advice regarding the application of the long-term contract exception under
Circumstances that may also indicate reasonable cause and good faith include an honest2017 Tax Ct. Memo LEXIS 24">*81 misunderstanding of fact or law that is reasonable in the light of all the facts and circumstances, including the experience, knowledge, and education of the taxpayer.
As discussed at length
Although the regulations state that dates identified in a contract are not dispositive to the Court's analysis,
Although the contracts lacked specific performance dates, petitioner had another opportunity to control completion dates by creating a project schedule. *87 Both SPAs referenced project schedules to be provided by petitioner; but the project schedules were not included in the SPAs, and petitioner did not provide the Court or respondent with any separate project schedule. A reasonably prudent taxpayer would have some documentation to support its position; outside of Mr. Balke's testimony, petitioner did not provide the Court or respondent with any evidence that would support its decision to account for the Petromaxx and Amber2017 Tax Ct. Memo LEXIS 24">*83 SPAs using the completed contract method.
For the aforementioned reasons, the Court concludes that petitioner did not act with reasonable cause and in good faith when it accounted for the Petromaxx and Amber SPAs using the completed contract method of accounting. Accordingly, the Court will sustain respondent's determinations with respect to the accuracy-related penalties for 2009 and 2010.32
The Court has considered all of the arguments made by the parties, and to the extent they are not addressed herein, they are considered unnecessary, moot, irrelevant, or without merit.
*88 To reflect the foregoing and the concessions of the parties,
1. Unless otherwise indicated, all section references are to the Internal Revenue Code in effect for the years at issue, and all Rule references are to the Tax Court Rules of Practice and Procedure.↩
2. The exact date on which Mr. Balke made the decision to transfer the order is not in the record.↩
3. Petitioner subcontracted the engineering work to MM Inženjering LTD. (Montmontaza), a subsidiary of Montmontaža PLC, a Croatian company, via an agreement executed by the parties on January 9, 2007 (Montmontaza agreement). Montmontaza was responsible for providing the information that Petromaxx would need to construct the refinery in Bulgaria. To satisfy its responsibilities, Montmontaza was to produce as-built documentation of the existing Cenco refinery in its standing condition in California and check the then-existing plant configuration against the future Bulgaria refinery site location. Doing so would allow Montmontaza to produce the documentation that would be necessary for Petromaxx to reconstruct the refurbished Cenco refinery in Bulgaria.↩
4. The Petromaxx SPA defined commissioning as "a set of activities that shall be performed by BUYER's personnel as Supervised by BASIC's on site field engineer and witnesses by Qualified Engineer at BUYER's Location in order to determine that the Facility can be properly and safely operated in accordance with the Technical Standards promptly after mechanical completion and pre-commissioning of the Facility".↩
5. The total contract price included the $17.2 million previously paid to petitioner--the $6,450,000 deposit paid to Basic Equipment (and transferred to petitioner) and the two payments of $5,375,000 paid directly to petitioner.↩
6. The parties executed subsequent amendments to the Petromaxx SPA through August 13, 2008, but the subsequent amendments did not adjust the total contract price.↩
7. Specifically, BASIC shall use its best efforts to Deliver the [Cenco refinery] Units listed as Phase One and as Phase Two in the Equipment Ledger within five (5) months after signing of this Agreement. BASIC shall use its best efforts to Deliver all other Units on or prior to the date corresponding to such Unit set forth in the Project Schedule, and in any event on or prior to April 30, 2007. The failure of BASIC to deliver such Units on the foregoing dates shall not constitute a default under this Agreement unless BASIC fails to use its best efforts. Notwithstanding the foregoing, it shall be a default under this Agreement if BASIC fails to Deliver the last Unit on or prior to September 12, 2007 ("Final Delivery Date").
8. The Montmontaza agreement also appears to coincide with the delivery timeline specified in the Petromaxx SPA, as Montmontaza anticipated having all drawings and documents completed by the middle of September 2007.↩
9. Toplam obtained title to the then-existing Ataş refinery units on April 21, 2008. BP, Shell, and Marmara Petrol owned the refinery site and have since converted the location to an oil products terminal and storage facility.↩
10. Although the Toplam supply agreement allowed for the refurbishing work to take place at the Ataş site, the units were ultimately moved to Northern Cyprus and refurbished there.↩
11. The location at which Amber was to construct a refinery was subject to change at Amber's sole discretion. The available documentary evidence does not reflect a final location determination.↩
12. Fluid catalytic cracking, a type of secondary unit operation, is primarily used in producing additional gasoline in the refining process.↩
13. Under the terms of the Amber SPA, Amber was not
14. Although the Amber SPA provided for delivery of all units to Houston, Texas, the parties stipulated that petitioner and Amber never intended for the Ataş refinery units to be shipped from Turkey to Houston.
15. Mr. Harris' opinion was formed, in part, on the basis of moving the Ataş refinery from Turkey and the FCCU from Wichita to petitioner's facility in Houston for cleaning and inspection and then shipping those refurbished parts to Pakistan. While the FCCU unit was to be transported from Wichita to Houston, and then from Houston to Pakistan, the parties stipulated that petitioner and Amber never intended for the dismantled Ataş refinery to be shipped from Turkey to Houston even though delivery to Houston was specified in the Amber SPA. The stipulation was executed by the parties after the filing date of the expert report.↩
16. Although respondent's pretrial memorandum asserts that both the Petromaxx and Amber contracts are manufacturing contracts, the notice of deficiency determines that only the Petromaxx contract is a manufacturing contract. Respondent did not amend his answer to assert otherwise.↩
17. Because the deficiency and penalty amounts reflected on the face of the notice of deficiency are based on respondent's primary position, the adjustments discussed
18. Petitioner had incurred $82,375,539 of actual expenses between 2005 and 2009. Petitioner estimated the total contract costs to amount to $97.8 million. Actual expenses of $82,375,539 divided by an estimated total contract cost of $97.8 million equals 84.23%.↩
19. Petitioner had incurred $27,805,789 of actual expenses between 2005 and 2009. Petitioner estimated the total contract costs to amount to $81 million. Actual expenses of $27,805,789 divided by an estimated total contract cost of $81 million equals 34.33%.↩
20. For the Petromaxx SPA, respondent multiplied the $122,250,000 estimated total contract price by an 84.23% completion percentage to arrive at a $102,971,175 gross receipts adjustment for income from the Petromaxx SPA from 2005 to 2009. For the Amber SPA, respondent multiplied the $101 million estimated total contract price by a 34.33% completion percentage to arrive at a $34,673,300 gross receipts adjustment. In total, these adjustments amount to $137,644,475.↩
21. Following a change of accounting method, the Commissioner may make any necessary adjustments to prevent taxable income from being duplicated or omitted as a result of the change under
22. For the Petromaxx SPA, respondent multiplied the $122,250,000 estimated total contract price by an 84.39% completion percentage to arrive at $103,166,775. After subtracting the gross receipts adjustment for 2009 of $102,971,175 respondent arrived at a total adjustment for the Petromaxx SPA of $195,600 for 2010. For the Amber SPA, respondent multiplied the $101 million estimated total contract price by a 34.36% completion percentage to arrive at $34,703,600. After subtracting the gross receipts adjustment for 2009 of $34,673,300 respondent arrived at a total adjustment for the Amber SPA of $30,300 for 2010. These adjustments total $225,900.↩
23.
24. The contract commencement date is not necessarily the same date as the date that the contract is entered into. The regulations provide separate definitions for the two times.
25. Although this provision of the Petromaxx SPA refers to terms of payment and not performance, i.e., refurbishing, shipping, constructing the refinery, commissioning, or performance testing, the Court will address this terms of payment provision for the sake of completeness.↩
26. Specifically, petitioner's reply brief states: As is apparent from the contracts themselves and the testimony at trial, Petitioner operates in a flexible and informal manner; the lack of formal documentation of a project schedule does not prove that the parties did not have an understanding that the * * * [refinery site] should be completed while the refinery is being refurbished, simultaneously instead of subsequently. Petitioner offered testimony as a fact witness, under oath, which is the best available evidence of its customary business practices. Mr. Balke has established his criteria as an experienced professional in his line of work. His testimony is supported by the efforts taken by Petitioner to provide specifications to Petromaxx using laser imaging at considerable cost to Petitioner. Procuring those images immediately and providing such images at an unusually early stage in the construction process corroborates the testimony that the parties intended for Petromaxx to begin building the * * * [refinery] infrastructure while Petitioner was refurbishing the refinery.
27. CISG art. 1(1) "applies to contracts of sale of goods between parties whose places of business are in different States: (a) when the States are Contracting States; or (b) when the rules of private international law lead to the application of the law of a Contracting State." For purposes of the CISG, a party's place of business is the one having "the closest relationship to the contract and its performance, having regard to the circumstances known to or contemplated by the parties at any time before or at the conclusion of the contract."
28. The increased efficiency vel non of the parallel processing system does not rescue petitioner's expectations here. Assuming without finding that the best efforts date is the relevant date, the two-year clock began running on March 22, 2006; the best efforts date was April 30, 2007; the parts needed to be transported from Texas to Bulgaria, taking six months; and commissioning and testing the refinery required an additional 2-1/2 months--leaving slightly more than two months until the end of the two-year period for Petromaxx to assemble the refinery according to petitioner's detailed models. And respondent's expert found that through the use of traditional industry techniques, reassembly might be attained in 12 months. As discussed
29. The Amber SPA reserved the right to determine the final location of the refinery, but at the time of executing the SPA, a location in Pakistan was the target.↩
30. Unlike the Petromaxx SPA, which did not reference 3-D laser scanning and modeling, the Amber SPA specifically refers to 3-D laser scanning and modeling. However, like the Petromaxx SPA, the Amber SPA does not mention parallel processing or address the purchaser's obligations under such a system.↩
31. The parties canceled the Amber SPA on January 18, 2010.↩
32. Because the Court sustains the