Filed: Sep. 08, 2018
Latest Update: Mar. 03, 2020
Summary: Case: 17-30909 Document: 00514632898 Page: 1 Date Filed: 09/07/2018 IN THE UNITED STATES COURT OF APPEALS FOR THE FIFTH CIRCUIT United States Court of Appeals Fifth Circuit No. 17-30909 FILED Summary Calendar September 7, 2018 Lyle W. Cayce Clerk TRAFFICWARE GROUP, INCORPORATED, Individually and as Successor in Interest to Naztec, Incorporated, Plaintiff, versus SUN INDUSTRIES, L.L.C.; SUN ELECTRICAL & INSTRUMENTATION, L.L.C., Defendants–Appellees Cross–Appellants, versus COMMAND CONSTRUCTION IN
Summary: Case: 17-30909 Document: 00514632898 Page: 1 Date Filed: 09/07/2018 IN THE UNITED STATES COURT OF APPEALS FOR THE FIFTH CIRCUIT United States Court of Appeals Fifth Circuit No. 17-30909 FILED Summary Calendar September 7, 2018 Lyle W. Cayce Clerk TRAFFICWARE GROUP, INCORPORATED, Individually and as Successor in Interest to Naztec, Incorporated, Plaintiff, versus SUN INDUSTRIES, L.L.C.; SUN ELECTRICAL & INSTRUMENTATION, L.L.C., Defendants–Appellees Cross–Appellants, versus COMMAND CONSTRUCTION IND..
More
Case: 17-30909 Document: 00514632898 Page: 1 Date Filed: 09/07/2018
IN THE UNITED STATES COURT OF APPEALS
FOR THE FIFTH CIRCUIT
United States Court of Appeals
Fifth Circuit
No. 17-30909 FILED
Summary Calendar September 7, 2018
Lyle W. Cayce
Clerk
TRAFFICWARE GROUP, INCORPORATED,
Individually and as Successor in Interest to Naztec, Incorporated,
Plaintiff,
versus
SUN INDUSTRIES, L.L.C.;
SUN ELECTRICAL & INSTRUMENTATION, L.L.C.,
Defendants–Appellees
Cross–Appellants,
versus
COMMAND CONSTRUCTION INDUSTRIES, L.L.C.;
OHIO CASUALTY INSURANCE COMPANY,
Third Party Defendants–
Appellants
Cross–Appellees.
Appeals from the United States District Court
for the Middle District of Louisiana
No. 3:15-CV-106
Case: 17-30909 Document: 00514632898 Page: 2 Date Filed: 09/07/2018
No. 17-30909
Before JONES, SMITH, and COSTA, Circuit Judges.
JERRY E. SMITH, Circuit Judge:*
This is a dispute over a construction subcontract. In this appeal from a
jury verdict, Command Construction Industries, L.L.C. (“Command”), chal-
lenges the district court’s ruling on its Federal Rule of Civil Procedure 50(b)
motion, its attorney fees award, and the award of damages. Sun Industries,
L.L.C. (“Sun”), cross-appeals seven of the jury’s findings on sufficiency
grounds, the award of attorney fees to Command, and the grant of Command’s
motion in limine.
I.
Command served as the general contractor to complete a road project for
the Louisiana Department of Transportation and Development (“DOTD”).
Command executed a subcontract with Sun to provide signalization and elec-
trical work, which commenced in the summer of 2013. Several disputes arose,
causing Sun to walk off the job before completion. Sun claims that was because
of nonpayment and Command’s failure to provide a time schedule and to super-
vise. Command asserts the delays were on account of Sun’s leaving the project
and its failure to order materials timely after DOTD had expanded the scope
of the project. Sun eventually returned to complete the subcontract work, but
disagreement continued, leading to a four-day jury trial.
Command prevailed on the contract issues. The jury found that Sun had
defaulted on its contractual obligations and awarded Command $60,936.26,
less than the $247,469.32 requested in Command’s sworn statement of
* Pursuant to 5TH CIR. R. 47.5, the court has determined that this opinion should not
be published and is not precedent except under the limited circumstances set forth in
5TH CIR. R. 47.5.4.
2
Case: 17-30909 Document: 00514632898 Page: 3 Date Filed: 09/07/2018
No. 17-30909
damages. The jury also found that Command had made all required payments
to Sun before Sun demobilized.
There were two findings in favor of Sun. First, the jury found Command
liable in tort for damage caused to a conduit Sun had constructed before leav-
ing the project. The jury awarded only $20,872.18 of the $62,616.55 Sun
claimed it incurred for repairs. Second, the jury found that Command did not
have reasonable cause to withhold payments to Sun after it returned to the job.
The district court made several post-trial rulings. It first denied Com-
mand’s Rules 50(b) and 59(e) motions. It then found Command was the pre-
vailing party for attorney fees, awarded Command seventy-five percent of its
attorney fees, and apportioned costs between both parties. The district court
also awarded Sun prejudgment interest on the net amount Command still
owed Sun under the subcontract.
In this diversity case, 1 we look to Louisiana law for the rule of decision.
In re Katrina Canal Breaches Litig., 495 F.3d 191, 206 (5th Cir. 2007). We
affirm with the exception of the denial of Command’s Rule 50(b) motion regard-
ing the damaged conduit and the reduction of Command’s attorney fee award.
II.
Sun challenges seven of the jury’s findings, claiming there is insufficient
evidence. But because Sun never filed a Rule 50 motion, those issues are raised
for the first time on appeal. “Absent a postverdict 50(b) motion, we are
1 The initial suit was brought by Trafficware Group, Inc. (“Trafficware”), against Sun
and Merchants Bonding Co. (“Merchants”). Complete diversity existed between those parties
under 28 U.S.C. § 1332. After Trafficware sued, Sun filed a third-party demand against
Command. Both Sun and Command are Louisiana citizens for purposes of § 1332. The dis-
trict court exercised ancillary jurisdiction over the third-party demand. That jurisdiction
existed even after Trafficware settled its suit three days before trial. See Molett v. Penrod
Drilling Co., 919 F.2d 1000, 1004 (5th Cir. 1990).
3
Case: 17-30909 Document: 00514632898 Page: 4 Date Filed: 09/07/2018
No. 17-30909
‘powerless’ to compel, on the basis of insufficiency of the evidence, the district
court to enter judgment contrary to the one it allowed to stand or to order a
new trial.” 2 Thus we do not review those evidentiary challenges.
A.
Command challenges two of the jury’s findings and raised a Rule 50(b)
motion for each. In reviewing a motion for judgment as a matter of law in a
case tried to a jury, our review is “especially deferential,” and “we draw all
reasonable inferences and resolve all credibility determinations in the light
most favorable to the nonmoving party.” 3 “A jury verdict must be upheld
unless there is no legally sufficient evidentiary basis for a reasonable jury to
find as the jury did.” 4
1.
Command challenges the amount of damages for Sun’s breach of con-
tract. Under the subcontract, Command’s sworn itemization of damages is
presumptively correct. Because Sun’s only rebuttal of the presumption was
that Command was entitled to no damages, and the jury did not make that
finding, Command claims the jury relied on speculation and conjecture by not
awarding it the full amount of $247,469.32 shown in its itemization. The
evidence is sufficient to support the verdict. The jury was free to give the
degree of credibility to Command’s witnesses and evidence it thought proper.
It was not confined to choosing an all-or-nothing damages calculation.
McLendon v. Big Lots Stores, Inc., 749 F.3d 373, 374 (5th Cir. 2014) (quoting Ortiz
2
v. Jordan, 562 U.S. 180, 190 (2011)).
Carley v. Crest Pumping Techs., L.L.C., 890 F.3d 575, 578 (5th Cir. 2018) (quoting
3
Heck v. Triche, 775 F.3d 265, 272 (5th Cir. 2014)).
4 Heck, 775 F.3d at 273 (quoting Foradori v. Harris,
523 F.3d 477, 485 n.8 (5th Cir.
2008)).
4
Case: 17-30909 Document: 00514632898 Page: 5 Date Filed: 09/07/2018
No. 17-30909
2.
Command questions the jury’s award of partial damages to Sun for the
damaged conduit. The damage occurred sometime between March and May
2014, during which time Sun had walked off the project. Command cites Sec-
tion 6 of the Subcontract, which makes Sun “solely responsible for all materials
. . . until the subcontract work is completed to [DOTD’s] satisfaction.” The
state did not issue acceptance of the work until August 31, 2015, so Command
claims that a straightforward reading of the subcontract placed the risk of loss
squarely on Sun.
Sun counters that DOTD had paid Command for the portion of work
involving the conduit before its damage, and the jury reasonably could have
interpreted that payment to mean that portion of the subcontract work was
completed to DOTD’s satisfaction under the contract. If so, Sun was no longer
responsible for the conduit after its approval.
Under Louisiana law, the contract is “the law between the parties” and
“is read for plain meaning.” 5 “Where a [contract] contains a definition of any
word of phrase, this definition is controlling.” 6
The language of the subcontract precludes the jury’s finding. Section 6
places all risk of loss on Sun “until the subcontract work is completed to
[DOTD’s] satisfaction.” The question is whether “subcontract work” includes
the entire scope of work or each discrete portion for which Command had
received payment.
The subcontract mandates the former interpretation. It defines
5 In re Liljeberg Enters., Inc., 304 F.3d 410, 439 (5th Cir. 2002) (quoting Nat’l Union
Fire Ins. Co. v. Circle, Inc.,
915 F.2d 986, 989 (5th Cir. 1990)).
6Cangelosi v. Allstate Ins. Co., 680 So. 2d 1358, 1362 (La. App. 1st Cir.), writ denied,
692 So. 2d 375 (La. 1996).
5
Case: 17-30909 Document: 00514632898 Page: 6 Date Filed: 09/07/2018
No. 17-30909
“subcontract work” to mean “the work specified in Exhibit A.” That exhibit is
a lengthy list of individual work items, only three of which relate to conduits.
Defining “subcontract work” to mean the whole of the items listed in Exhibit A
encompasses the entire scope of the subcontract work and not its individual
tasks. Because the subcontract, by its own definition, places all risk on Sun
until completion of all the subcontract work, there was insufficient evidence to
support the finding in this regard, so we reverse the award of $20,872.18 to
Sun for damage to the conduit.
III.
Regarding attorney fees and costs, 7 the district court found Command to
be the prevailing party and awarded it seventy-five percent of its fees, dis-
counting the total amount to account for Command’s change in counsel shortly
before trial. Sun appeals the conclusion that Command was the prevailing
party entitled to fees, and Command appeals the failure to award it the full
amount of its costs and fees.
“State law controls both the award of and the reasonableness of fees
awarded where state law supplies the rule of decision.” Mathis v. Exxon Corp.,
302 F.3d 448, 461 (5th Cir. 2002). Under Louisiana law, the grant of attorney
fees must be “authorized by contract or statute” to be recovered. Peyton Place,
Condo. Assocs., Inc. v. Guastella,
18 So. 3d 132, 146 (La. App. 5th Cir. 2009).
The subcontract contained such an authorization.
Because only Command prevailed on its contractual claims, the district
7 Sun makes a related claim that the district court should have given it a credit on the
damages owed to Command for a settlement amount paid by its bonding company, Mer-
chants. The district court properly concluded that the language of the settlement between
Command and Merchants does not allow the payment to be seen as payment on a liability
but, instead, was solely intended to allow Merchants to avoid litigation. The court did not
err in declining to grant such a credit.
6
Case: 17-30909 Document: 00514632898 Page: 7 Date Filed: 09/07/2018
No. 17-30909
court properly found it was the prevailing party. Sun’s tort claim for the dam-
aged conduit was not covered by the subcontract and thus is not subject to its
section regarding fees. Although Command had to pay Sun the amount re-
maining under the subcontract, that amount did not reflect any judgment of
liability for breach of contract against Command and was reduced by the dam-
ages award to Command.
Under Louisiana law, an award of attorney fees and costs is reviewed for
an abuse of discretion. 8 The district court did not abuse its discretion in its
award of costs. Given the language of the subcontract, however, it did abuse
its discretion in reducing Command’s attorney fee award.
Reducing Command’s fees to account for new counsel, regardless of total
hours spent by both sides, was not unreasonable as an independent action. The
question, then, is whether it was an abuse of discretion to reduce the attorney
fees award in light of Section 11 of the subcontract, which states that, “[i]n the
event of a dispute, the prevailing party shall be entitled to the reimbursement
of all attorney fees involved.”
In Louisiana, a contract has “the effect of law between the parties, and
the courts are bound to give effect to all such contracts.” 9 “Where the words of
a contract are clear and explicit and lead to no absurd consequences, no further
8 Conforto v. Toscano, 234 So. 3d 252 (La. App. 5th Cir. 2017) (stating that the award
of costs is reviewed for abuse of discretion); S. Siding Co. v. Raymond,
703 So. 2d 44, 49 (La.
App. 1st Cir. 1997) (stating that an award of attorney fees is reviewed for abuse of discretion),
writ denied,
709 So. 2d 782 (La. 1998). Command asserts that the subcontract bound the
district court to award it all costs because the subcontract specifies that, in the event of a
breach by Sun, Command is entitled to “all reasonable attorneys’ fees and costs.” The word
“reasonable” dooms Command’s demand for costs, because the district court’s allocation was
not unreasonable given the facts.
9Melancon Equip., Inc. v. Nat’l Rental Co., 978 So. 2d 1053, 1056 (La. App. 3d Cir.
2008) (quoting Green v. TACA Int’l Airlines,
304 So. 2d 357, 361 (La. 1974)).
7
Case: 17-30909 Document: 00514632898 Page: 8 Date Filed: 09/07/2018
No. 17-30909
interpretation may be made in search of the parties’ intent.” 10 Louisiana
courts have held to this principle to the extent that they awarded fees as
mandated by the contract even where a party failed to request them at trial,
raising the issue for the first time on appeal. Melancon, 978 So. 2d at 1056.
The language of Section 11 is “clear and explicit.” LA. CIV. CODE ANN.
art. 2046. It also does not lead to an absurd result in this case. As Command
notes, even though Command changed counsel a few months before trial, Sun’s
attorneys spent more hours in preparing for trial than did Command’s new
counsel. Thus, although the ruling would otherwise not be an abuse of discre-
tion, it is reversible error to have departed from the contractual language.
Command is entitled to receive all of its attorney fees. 11
IV.
Command challenges the award of prejudgment interest on the amount
it still owed Sun under the subcontract. “When the object of the performance
is a sum of money, damages for delay in performance are measured by the
interest on that sum from the time it is due.” LA. CIV. CODE ANN. art. 2000.
Command claims that, although payment would have been due Sun at the time
DOTD approved the work, it should not have to pay interest because the
amount was unascertainable in light of the disputes about breach of contract
and other damages.
The district court concluded that the amount did not have to be ascer-
tainable to merit an award of prejudgment interest. We review that conclusion
10Stone Ins., Inc. v. Beyer-Beeson Ins. Agency, Inc., 45 So. 3d 1125, 1126 (La. App. 5th
Cir. 2010) (citing LA. CIV. CODE ANN. art. 2046).
11 The issue of attorney fees incurred on appeal is remanded for the district court to
consider in the first instance. Instone Travel Tech Marine & Offshore v. Int’l Shipping Part-
ners, Inc., 334 F.3d 423, 433 (5th Cir. 2003).
8
Case: 17-30909 Document: 00514632898 Page: 9 Date Filed: 09/07/2018
No. 17-30909
de novo 12 and find no error. Under Louisiana law, prejudgment interest runs
from the time of judicial demand even if the exact amount is not ascertainable
because of the litigation. 13
The case Command cites to the contrary is inapposite. There, the
amount owed under the contract itself was unascertainable for reasons other
than litigation. The contract in question was for fuel, and the cost of the fuel
was dependent on future market prices that were unknown at the time suit
was filed. See City of New Orleans v. United Gas Pipe Line Co., 517 S.2d 145,
164–65 (La. App. 4th Cir. 1987). Here, the amount due under the subcontract
was set. The inability to ascertain how much would be due given any damage
award does not preclude prejudgment interest under Louisiana law.
V.
Sun appeals the grant of Command’s motion in limine to exclude evi-
dence of mobilization and demobilization costs Sun incurred on account of
delays on the job. Sun claims Command is liable because it did not communi-
cate a proper schedule to Sun for the timely completion of its work. That also
caused Sun to incur costs to store materials for which Command neither billed
DOTD nor reimbursed Sun. The district court ruled that, under Section 1.2 of
the subcontract, Sun’s relief is limited to “justifiable time extensions” and does
not include monetary damages. 14
12 Nat’l Hispanic Circus, Inc. v. Rex Trucking, Inc., 414 F.3d 546, 552 (5th Cir 2005).
13See, e.g., Mini Togs Prods., Inc. v. Wallace, 513 So. 2d 867, 875 (La. App. 2d Cir.),
writ denied,
515 So. 2d 447 (La.), and writ denied,
515 So. 2d 451 (La. 1987).
14The district court interpreted other portions of the subcontract to mean that the
amount Sun could claim from Command is capped at the amount Command received from
DOTD for Sun’s work. Sun disputes whether that provision controls because it falls under
the heading of “Claims Relating to Owner” (DOTD) rather than the section titled “Claims
Relating to Contractor” (Command). Because we decide that the court properly interpreted
Section 1.2, we do not consider whether it properly decided this question.
9
Case: 17-30909 Document: 00514632898 Page: 10 Date Filed: 09/07/2018
No. 17-30909
Command is incorrect to assert that we lack jurisdiction to review that
evidentiary decision in light of Sun’s failure to raise a Rule 50(b) motion after
trial. We review evidentiary rulings for abuse of discretion, subject to harmless
error review. United States v. Alaniz, 726 F.3d 587, 606 (5th Cir. 2013). “A
trial court abuses its discretion when its ruling is based on an erroneous view
of the law or a clearly erroneous assessment of the evidence.” United States v.
Ragsdale,
426 F.3d 765, 774 (5th Cir. 2005) (quotation omitted).
A straightforward reading of the subcontract supports the district court’s
conclusion. Thus, it did not erroneously view the law or otherwise abuse its
discretion.
The judgment is AFFIRMED in part, REVERSED in part, and
REMANDED.
10
