The Issue The issues are whether Respondent committed the several violations of Sections 489.129(1)(h)2.,(h)3.,(j),(k), and (n), Florida Statutes (1997), for the reasons stated in the respective Administrative Complaints and, if so, what, if any, penalties should be imposed. (All chapter and section references are to Florida Statutes (1997) unless otherwise stated.)
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a certified general contractor pursuant to license number CG C059414. At all relevant times, Respondent was the qualifying agent for Fred T. Garrett Construction, Inc. ("FTG"). As the qualifying agent, Respondent was responsible for all of FTG's contracting activities in accordance with Section 489.1195, Florida Statutes. Respondent failed to obtain a certificate of authority for Fred T. Garrett Construction, Inc., as required by Section 489.119(2), Florida Statutes. The St. Cyr Case On or about August 21, 1998, Respondent entered into a contract with Louis L. St. Cyr to construct an addition to the residence located at 201 South Bel Air Drive, Plantation, Florida. The contract price was $50,000. Although Mr. St. Cyr paid $2,500 to Respondent, Respondent failed to commence work and canceled the project, thereby abandoning it without just cause and without proper notification to Mr. St. Cyr. The contract did not permit Respondent to keep the $2,500 paid by Mr. St. Cyr, and Respondent failed to refund the payment within 30 days after abandonment. Out of the $2,500 he received from Mr. St. Cyr, however, Respondent paid $1,600.00 to the architect before abandoning the project. Thus, the net amount that Respondent owes to Mr. St. Cyr is $900. Petitioner incurred a total of $1,092.28 in investigative costs relating to the St. Cyr case. The Forney Case On May 22, 1998, Respondent, who was doing business as FTG, entered into a contract with Mr. Warren Forney for the construction of a two-bedroom, one-bath addition to the residence located at 1698 Northeast 33rd Street, Oakland Park, Florida. The contract price was $32,500. The contract with Mr. Forney did not contain a written statement explaining the customer’s rights under the Construction Industries Recovery Fund, as required by Section 489.1425(1), Florida Statutes. On July 7, 1998, Respondent obtained permit number 98-050297 from the Oakland Park Building Department. Construction commenced on or about July 7, 1998, and continued sporadically until October 29, 1998, when Mr. Forney dismissed Respondent for failure to timely complete the project. The Oakland Park Building Department issued notices of violation against the project on August 3, September 11, and October 14, 1998, for various building code violations. Mr. Forney was forced to obtain a homeowner’s permit and subsequently hired a subcontractor to complete the work. Mr. Forney paid Respondent approximately $29,250 before relieving Respondent of his duties. To complete the project, Mr. Forney paid a total of $48,746.52, which was $15,396.52 over and above the original contract price. Petitioner incurred a total of $2,190.78 in investigative costs relating to the Forney case. The Kong Case In or around January 1998, a contractor named Lakeview Concepts hired Respondent to perform demolition work for the Kong dry cleaning store project on the property located at 5171 South University Drive, Davie, Florida. On or about June 17, 1998, permit 98-00002349 was issued to Respondent to perform alterations on commercial property located at 5171 South University Drive, Davie, Florida. Respondent, however, did not yet have a contract with the owner for this work. The next month, on or about July 30, 1998, Respondent, who was doing business as FTG, entered into a contract with Shek Kong to complete the dry cleaning store project at 5171 South University Drive, Davie, Florida, for the contract price of $22,300. Shek Kong made payments to Respondent totaling $16,000. Respondent’s work was of poor quality, however, and on or about November 6, 1998, he ceased work, though the project had not been completed. On or about November 14, 1998, Douglas Frankow, license number CB C052960, gave Mr. Kong an estimate of $20,562 to complete the project. Thereafter, on or about June 30, 1999, Mr. Kong contracted with George Settergren, another licensed contractor, to complete the project for a contract price of $27,956. On December 9, 1999, in Case No. 98-020065 08, the Circuit Court, Seventeenth Judicial Circuit, Broward County, Florida, rendered a Final Judgment against Respondent and in favor of Mr. Kong. This judgment awarded Mr. Kong the total amount of $28,693.30, plus 10 percent interest per annum. Petitioner incurred a total of $2,502.78 in investigative costs relating to the Kong case.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Florida Construction Industry Licensing Board enter a Final Order finding Respondent guilty of violating Sections 489.129(1)(h)2., (h)3., (j), (k), and (n), Florida Statutes, imposing administrative fines in the aggregate amount of $3,700, assessing investigative costs in the aggregate amount of $5,785.84, placing Respondent's license on probation for a period of four years from the date the Final Order is entered by the Board, and awarding payment of restitution to each customer as follows: (1) to Warren Forney, the amount of $15,396.52; (2) to Shek Kong, satisfaction of the unpaid civil judgment in the amount $28,693.30, plus 10 percent interest accrued thereon; and (3) to Louis L. St. Cyr, the amount of $900. DONE AND ENTERED this 15th day of February, 2002, in Tallahassee, Leon County, Florida. _________________________________ JOHN G. VAN LANINGHAM Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 15th day of February, 2002.
The Issue Whether Respondent committed the violations alleged in the Amended Administrative Complaint issued against him and, if so, what disciplinary action should be taken.
Findings Of Fact Based on the evidence adduced at hearing, and the record as a whole, the following findings of fact are made to supplement and clarify the facts to which the parties stipulated at the outset of the final hearing (Parties' Stipulations)2: The contract referenced in the Parties' Stipulations (Building Contract) was signed by Mr. Stasinos (on behalf of ICC) and Mr. Skiera (on behalf of himself and his wife) on June 29, 2000. The home that ICC agreed to build for the Skieras (Skiera Residence) was described in the Building Contract as a "[c]ustom two-story residence with detached garage and riding cor[r]al for a total of 5,370 square feet." It was to be constructed on a tract of land owned by the Skieras in Boynton, Beach, Florida. The Building Contract provided for the following allowances: $20,000.00 for "electrical"; $17,000.00 for "plumbing"; $15,000 for "HVAC"; a "door hardware allowance" of "$50.00 per [interior] door"; $6,000.00 for a "stacked stone veneer" exterior; an "entry door hardware allowance" of "$100.00 per door"; $15,000.00 for "kitchen cabinetry and vanity"; $8,000.00 for "counter tops and vanity tops"; $9,000.00 for "landscaping," including "trees, shrubs, sod, automatic time clock, [and an] operated irrigation system with rain sensor"; and $7,000 for "driveways, walkways, [and] flatwork." There was no written statement in the Building Contract explaining a consumer's rights under the Construction Industries Recovery Fund, as then required by Section 489.1425, Florida Statutes. The Building Contract contained a "[p]ayment [d]raw [s]chedule," which provided as follows: Upon execution of contract: 10%- $36,608.00 Thereafter, progress payments based on schedule of values. This "schedule of values" (referred to in the "[p]ayment [d]raw [s]chedule") contained the following "scheduled values" (excluding change orders): 1. Permits $21,600.00 2. Clearing/Grading/Fill $10,800.00 3. Foot'gs. Undgr Plumb, Soil Treatmt $23,000.00 4. Foundation/Slab poured $32,760.00 5. Exterior Walls/Tie Beam $26,600.00 6. Roof Trusses $26,600.00 7. Roof Sheathing/Felt $19,400.00 8. Interior Framing Complete $14,000.00 9. Windows/Exterior Door Frames Set $14,400.00 10. 2nd Plumbing/Tub Set $7,200.00 11. Wiring Rough-In $14,400.00 12. HVAC Ducts Installed $7,200.00 13. Roof Shingles/Tiles Installed $14,400.00 14. Insulation (wall & ceiling) $4,200.00 15. Exterior Trim/Soffits $11,800.00 16. Drywall Hung $14,400.00 17. Drywall Finish $10,800.00 18. Interior Trim/Interior Doors Installed $13,400.00 19. Interior Paint $8,800.00 20. Siding/Stucco $14,400.00 21. Exterior Paint Complete $8,800.00 22. Exterior Doors & Garage Door Install $6,200.00 23. Cabinets/Countertops Installed $10,000.00 24. Plumbing Finish $3,600.00 25. Electrical Finish $5,600.00 26. HVAC-Compressor/A.H. Installed $10,920.00 27. Driveway/Walks Installed $3,600.00 28. Landscaping/Irrigation $7,200.00 There were six separate change orders. They were dated August 20, 2000 (Change Order No. 001), August 29, 2000 (Change Order No. 002), September 26, 2000 (Change Order No. 003), October 15, 2000 (Change Order No. 004), October 15, 2000 (Change Order No. 005), and November 10, 2000 (Change Order No. 006). As of December 21, 2000, ICC had been paid in full for all six change orders, as well as for items 1 through 8 on the "schedule of values." As of February 27, 2001, ICC had received additional monies from the Skieras: payment in full for items 9 through 12 and 15 on the "schedule of values" and partial (50 percent) payment for items 13 and 20 on the "schedule of values." As of April 10, 2001, ICC had been paid a total of $287,966.20 (all from the proceeds of a mortgage loan the Skieras had obtained from Admiralty Bank) for work done on the Skiera Residence. On May 1, 2001, the Skieras paid ICC an additional $16,800.00 for drywall work, bringing the total amount of payments that ICC had received from (or on behalf of) the Skieras, as of that date, to $304,766.20. The Skieras made no further payments to ICC. The "eight valid claims of lien" referenced in the Parties' Stipulations were filed by eight different subcontractors, all of whom had been hired by ICC to work on the Skiera Residence: Boca Concrete Pumping, Inc.; Gulf Stream Lumber Company; L & W Supply Corp., d/b/a Seacoast Supply; Waste Management of Palm Beach; B.T. Glass & Mirror, Inc.; Boca Raton Decorating Center Company; American Stairs; and Broten Garage Door Sales Inc.3 Boca Concrete Pumping was the "very first" subcontractor to work on the construction of the Skiera Residence. It did the "slab work, the foundation" (referenced in item 4 of "schedule of values"). Its lien was recorded on December 6, 2000. The lien was in the amount of $1,001.25, and it indicated, on its face, that it was for unpaid "concrete pumping" that had been furnished between September 8, 2000, and September 22, 2000. A satisfaction of this lien, dated March 8, 2001, was filed March 24, 2001. Gulf Stream Lumber's original lien was recorded February 15, 2001. It was in the amount of $67,872.59, and it indicated, on its face, that it was for unpaid "building material" that had been furnished between August 15, 2000, and January 24, 2001. An amended claim of lien was recorded May 3, 2001, in the amount of $36,530.59 for unpaid "building material" that, according to the lien, had been furnished between August 25, 2000, and March 27, 2001. A satisfaction of the original lien and amended claim of lien, dated November 30, 2001, was filed December 5, 2001. The liens were satisfied, pursuant to the terms of a Settlement Stipulation, upon the Skieras' payment of $39,579.28 to Gulf Stream Lumber. L & W Supply's lien was recorded April 30, 2001. It was in the amount of $4,536.98, and it indicated, on its face, that it was for unpaid "building materials [and] related items" that had been furnished between December 16, 2000, and January 30, 2001. A satisfaction of this lien, dated October 11, 2001, was filed November 7, 2001. The lien was satisfied by the payment of $10.00 "and other good and valuable consideration" (which was the payment of an additional $2,850.00 by check dated October 11, 2001). Waste Management of Palm Beach's lien was recorded May 31, 2001. It was in the amount of $1,665.89, and it indicated, on its face, that it was for unpaid "[w]aste [r]emoval [s]ervices" that had been furnished between August 30, 2000, and April 5, 2001. A satisfaction of this lien, dated October 19, 2001, was filed November 13, 2001. B.T. Glass & Mirror's lien was recorded June 29, 2001. It was in the amount of $3,560.00, and it indicated, on its face, that it was for an unpaid "glass/mirror package" that had been furnished between May 3, 2001, and May 31, 2001. A satisfaction of this lien, dated October 19, 2001, was filed November 13, 2001. The lien was satisfied by the payment of $1,600.00 (by check dated November 10, 2001), plus an agreement to provide "$2,000.00 in gazebo or arbor products from the Hitching Post," the Skieras' family business. Boca Raton Decorating Center's lien was recorded May 19, 2001. It was in the amount of $1,218.79, and it indicated, on its face, that it was for unpaid "paint, sealers [and] sundries" that had been furnished between May 1, 2001, to May 2, 2001. A satisfaction of this lien, dated October 11, 2001, was filed November 7, 2001. American Stairs' lien was recorded August 16, 2001. It was in the amount of $4,188.00, and it indicated, on its face, that it was for unpaid "[s]tairs and [r]ailings" that had been furnished between June 8, 2001, and June 15, 2001. A satisfaction of this lien was executed on October 15, 2001. Broten Garage Door Sales' lien was recorded September 5, 2001. It was in the amount of $3,214.00, and it indicated, on its face, that it was for the unpaid "sale and installation of garage doors and openers," which took place between June 25, 2001, and July 17, 2001. A satisfaction of this lien, dated January 31, 2002, was filed on February 5, 2002. At a meeting "in the early part of August [2001]" attended by Respondent, Mr. Stasinos, the Skieras, and the president of the bank from which the Skieras had borrowed the money to pay for the construction of their residence, Respondent announced that, on behalf of ICC, "he was filing [for] bankruptcy."4 ICC stopped working on the Skiera Residence after this meeting. At the time, the Skiera Residence was approximately 70 to 80 percent completed (and the Skieras had paid ICC a total of $304,766.20, or approximately 80 percent of the total contract price (including change orders) of $378,286.205). In addition to paying $57,316.62 to satisfy the "eight valid claims of lien" referenced in the Parties' Stipulations, the Skieras paid approximately an additional $57,000.00 to other subcontractors who provided goods and/or services "needed to complete the house." The $10,000.00 check referred to in the Parties' Stipulation 14 (that the Skieras received from Andover Construction, Inc.) did not "represent any kind of final settlement" between the Skieras and ICC. The October 4, 2001, Certificate of Occupancy for the Skiera Residence referred to in the Parties' Stipulations indicated, on its face, that ICC was the contractor, notwithstanding that ICC had abandoned the project "in the early part of August [2001]." Respondent has been a Florida-licensed general contractor since July 29, 1987. In his capacity as ICC's licensed qualifier, he has previously (by Final Order filed in DBPR Case Nos. 2001-03283 and 2001-03284 on December 23, 2003) been found guilty of, and disciplined for, violating (in connection with two residential construction projects undertaken by ICC for A. Richard Nernberg) the same subsections of Section 489.129(1), Florida Statutes (Subsections (1)(g), (i), and (m)) that he is accused of violating in the instant case. In these prior disciplinary proceedings, Respondent's license was suspended for two years, and he was fined $6,000.00 and required to pay $958.30 in investigative costs. Administrative complaints were also filed against Respondent in DBPR Case Nos. 94-15958 and 97-17352. Both of these cases were resolved by settlement stipulations in which Respondent "neither admit[ted] [nor] denie[d] the allegations of fact contained in the [a]dministrative [c]omplaint[s]."
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Board issue a Final Order: finding Respondent guilty of violating Section 489.1425(1), Florida Statutes, as alleged in Count I of the Amended Administrative Complaint, and fining him $1,000.00 for this violation; (2) finding Respondent guilty of the violation of Section 489.129(1)(g)1., Florida Statutes, relating to Boca Concrete Pumping's December 6, 2000, $1,001.25 lien, alleged in Count II of the Amended Administrative Complaint, and taking the following disciplinary action against him for this violation: suspending his license for four years (with such suspension to run consecutively with his current suspension); (b) fining him $5,000.00; (c) requiring him to pay restitution in the amount of $1,001.25 to the Skieras; and (c) ordering him to reimburse the Department for all reasonable investigative and prosecutorial costs (excluding costs related to attorney time) incurred by the Department; and (3) dismissing all other charges in the Amended Administrative Complaint. DONE AND ENTERED this 8th day of May, 2007, in Tallahassee, Leon County, Florida. S STUART M. LERNER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 8th day of May, 2007.
Findings Of Fact At all times material to these proceedings, the Respondent, ROBERT MENSCHING, was a certified residential building contractor in Florida, and held license number CR C020166. Mr. Mensching was the owner and qualifying agent for Robert Mensching Homes. On or about July 10, 1986, a written proposal was submitted by the Respondent to Mr. and Mrs. Mangiardi for the construction of a single family dwelling in Cape Coral, Florida. The construction price was $60,000.00, with an additional $500.00 for the purchase of the house plans. Mr. and Mrs. Mangiardi paid for the plans on the date of the proposal. Revisions to the proposal were submitted to the Mangiardis in September, 1986. The purchase price and the payment schedule remained the same. The proposal was accepted by the Mangiardis, and the down payment of $5,000.00 required by the contract to start construction, was given to the Respondent. Construction commenced in November 1986. By March 26, 1987, the Respondent had been paid $53,750.00 of the total construction contract price. This included the fourth draw on a five draw payment schedule. Only $6,250.00 remained to be paid by the purchasers for the last phase of construction. In April 1987, the Respondent informed Mr. Mangiardi that he would not complete the final phase of construction. The Respondent informed Mr. Mangiardi that he would pay him $5,000.00. An accounting was not given to the purchasers of the monies disbursed by the Respondent pursuant to the construction schedule. After the Respondent left the project, the Mangiardis were given notice of an outstanding lien in the amount of $963.80, which was owed to Kirkland Electric, Inc. Another Notice to Owner was filed by Wallcrafters, another subcontractor, for $5,272.50. The work completed by both subcontractors was performed during the Respondent's term as the prime contractor on the project. These two subcontractors were never paid by the Respondent out of the draws received by him for that purpose. The Respondent did not pay the $5,000.00 he told Mr. Mangiardi he would pay in April of 1987. The evidence is unclear as to whether this amount of money was a payment of liquidated damages for the breach, the balance of funds entrusted to the contractor which had not been disbursed in the preceding construction phases, or the amount of unpaid liens known to the contractor at the time of breach. The Respondent filed for bankruptcy after a judgment was entered against him in a civil action by the Mangiardis for breach of contract. A Notice of Aggravation was not submitted during the formal hearing regarding the actual damage to the licensee's customers as a circumstance to be considered in aggravation of the penalty to be assessed. A copy of the Florida Construction Industry Licensing Board's previous letter of reprimand was not presented at hearing so that the hearing officer and the Board could use the prior violation for aggravation purposes.
The Issue Whether the Respondent was validly disciplined by a local government, which causes the Respondent to be in violation of Section 489.129(1)(i), Florida Statutes (1985). Whether the Respondent failed to perform the contracting job alleged in the Administrative Complaint in a reasonably timely manner, or abandoned the job, in violation of Section 489.129(1)(m), (k), Florida Statutes (1985). Whether the Respondent exhibited financial mismanagement, misconduct or diversion, in violation of Section 489.129(1)(h), (m), Florida Statutes (1985). Whether the Respondent committed gross negligence, incompetence or misconduct in connection with the job alleged in the Administrative Complaint, in violation of Section 489.129(1)(m), Florida Statutes (1985).
Findings Of Fact At all times material to these proceedings, the Respondent, Charles R. Schelah was licensed as a certified general contractor in Florida, and held license number CG C016841. Mr. Schelah was the qualifying agent for Schelah Construction, Inc. On March 11, 1986, Schelah Construction, Inc., entered into a contract with Moner F. Green and Karen L. Green to construct a residence in Prairie Creek Park, Charlotte County, Florida A copy of the contract is Petitioner's Exhibit Pursuant to the written agreement, construction would occur as per the signed construction drawings. The total contract price was to be $102,775.00. This quote was contingent upon a construction start on or before March 15, 1986. After that date, increases in supply and labor costs would be borne by the owners, Mr. and Mrs. Green. The contract further stated that there is no specific completion date, that an expected completion date was August 30, 1986. Construction began on the residence on April 4, 1986. Three revisions of the drawings were completed by the owner before a building permit was requested by the Respondent Schelah. Throughout the progress of construction, major and minor revisions were made by the owners. Many of these revisions delayed construction as the Respondent was required to obtain new special order materials and retrofit many of the changes into the existing construction phase. The Respondent recollected that thirty-five revisions were made to the construction plans by the owners during various phases of construction. In September 1986, the owners began to frequently telephone the Respondent in order to urge him to quickly complete the project as the owners were now required to pay the savings and loan association mortgage installments. The Respondent did not return the telephone calls. A letter was sent to the Respondent by the owners' attorney on November 3, 1986, notifying him that he needed to resume his responsibilities at the construction site. The Respondent did not reply to this letter. On November 7, 1986, the Respondent was removed as contractor of record by the owners. All but the final draw from the savings and loan had been given to the Respondent before his removal. After the Respondent was removed from the project, the owners were given notice of the following liens: $2,750.55 to Pre-Hung Doors of Florida for supplies delivered in August 1986; $700.00 to Paul Hartt Plastering and Stucco, Inc. for work completed in September 1986. The work completed by both subcontractors was performed during the Respondent's term as the prime contractor on the project. These two contractors were never paid by the Respondent out of draws received by him for that purpose through October 1986. These subcontractors, as well as others, testified that they were unable to communicate with Respondent after September 1986. The final draw from the savings and loan in the amount of $19,618.97, was used by the owners to complete the project themselves. The proof of payment submitted by the owner, Mr. Green, at hearing for completion under the direct contract was $6,149.14, in Respondent's Exhibit 14. The residence was completed by the owners in December 1986. Mr. Green, the owner, filed a complaint with the Charlotte County Building Board on October 29, 1986, alleging that the Respondent refused to call him, and was dragging completion of the job for unknown reasons hearing was held on February 19, 1987. At the conclusion of the hearing, the Charlotte County Building board suspended the permitting privileges of Schelah Construction, Inc., until such time as all jobs in progress were finished. During the administrative hearing, the Respondent admitted that a twenty-one day delay on the Green project occurred when he was unable to acquire a sheetrock hanger who would go to the hinterlands (Prairie Creek Park) where the residence was being built. He contends however, that the additional time delays were a result of changes in supply orders due to the changes made by the owners, and the requirement that subcontractors be rescheduled to accommodate these changes. Petitioner's experts in construction practices within Florida, Mr. Bernard Verse and Mr. Stanley Ink, were unable to render an opinion that the Green Construction project had been abandoned by Respondent Schelah, or that there had been a diversion of funds. However, Mr. Ink did render an opinion that the project was not completed in a reasonably timely manner, that the Respondent is guilty of financial mismanagement, and that the Respondent committed gross negligence, incompetence or misconduct on the job in that the Respondent did not use due diligence in completing the job, staying on the job, and paying the subcontractors as the contractor should. Mr. Verse opined that the Respondent committed financial mismanagement and gross negligence in the practice of contracting. It was gross negligence not to maintain contact with clients. The Respondent's own expert in construction practices in the Punta Gorda area, Mr. Larry Deirmeyer, noted that it is difficult to acquire unscheduled building supplies in the Punta Gorda area if a contractor runs a small construction company because the supply houses are in Fort Myers, where rapid growth is occurring. In addition, it is difficult to get subcontractors to work on construction in areas like Prairie Creek Park, which is remote from the developed areas of Charlotte County. After Mr. Deirmeyer was admitted as an expert in construction practices, the Hearing Officer learned that he had built a custom home for the owner Moner Frank Green in 1980. Mr. Green's removal of Mr. Deirmeyer's company from the construction project during the last draw of that project, and his continuous changes in those plans were not considered by the Hearing Officer in this case except for the purpose of weighing Mr. Deirmeyer's independence as an expert witness. Another expert witness in construction practices presented by the Respondent was James Anderson, a state certified contractor from the Port Charlotte area. Mr. Anderson acknowledged the local builder supply problem and rendered the opinion that nine months was a reasonable period of time in which to complete the Green project, based upon the construction plans, the change orders, and the travel required to the project, which is not in the immediate Port Charlotte area. The Respondent Schelah did not maintain communication with the owners regarding the progress of the project, even though he was telephoned repeatedly and received written communication from the Green's attorney. This failure to maintain communication resulted in the Respondent's dismissal from the project. The County's Building Director's requests for communication were also refused by the Respondent.
Recommendation Based upon the foregoing, it is RECOMMENDED: That the Respondent be found not guilty of having violated Section 489.129(1)(i), Florida Statutes, as alleged in paragraph five of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(m) and (k), Florida Statutes, as alleged in paragraph six of the administrative complaint. That the Respondent be found not guilty of having violated Sections 489.129(1)(h) and (m), Florida Statutes, as alleged in paragraph seven of the administrative complaint. That the Respondent be found guilty of having violated Section 489.129(1)(m), Florida Statutes, as alleged in paragraph ten of the administrative complaint in regard to misconduct by the Respondent on the Green project. That the penalties assessed against the Respondent not include an aggravation of penalties under Rule 21E-17.002, Florida Administrative Code, and that the Respondent pay a fine of $750.00, as set forth in Rule 21E-17.001(5), Florida Administrative Code. DONE and ENTERED this 9th day of June, 1989, in Tallahassee, Leon County, Florida. VERONICA E. DONNELLY Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 9th day of June, 1989. APPENDIX TO RECOMMENDED ORDER CASE NO. 88-3442 Petitioner's proposed findings of fact are addressed as follows: Accepted. Accepted. See HO #1. Accepted. See HO #1. Rejected as to location of project. The rest is accepted. See HO #2. Accepted. Accepted. See HO #2. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #4. Accepted. See HO #5. Accepted. See HO #6. Accepted. Accepted. See HO #9. Accepted. See HO #9 and #10. Accepted. See HO #10. Accepted. Accepted. See HO #13. Accepted. Accepted. Rejected. See HO #13 and #11. Rejected. See HO #11. Accepted. See HO #11. Accepted. Accepted. Accepted. See HO #14. Accepted. See HO #3 and #8. Accepted. See HO #7. Respondent's proposed findings of fact are addressed as follows: Accepted. See HO #1. Accepted. See HO #2. Accepted. See HO #3 and #4. Accepted. See HO #13. Accepted. See HO #5. Accepted. See HO #6. Accepted. See HO #6. Accepted. See HO #7. 9. Accepted. See HO #9, #10, #11, #12 and #13. 10. Rejected. Irrelevant to this proceeding. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 John Charles Heekin, Esquire 21202 Olean Boulevard, Suite C-2 Port Charlotte, Florida 33952 Kenneth E. Easley, Esquire General Counsel Department of Professional Regulation 1940 North Monroe, Suite 60 Tallahassee, Florida 32399-0729 Fred Seely, Executive Director Florida Construction Industry Licensing Board 111 East Coastline Drive Post Office Box 2 Jacksonville, Florida 32202
Findings Of Fact Based upon the record evidence, the Hearing Officer makes the following findings of fact: Martin Gold is now, and has been since July, 1986, licensed by Petitioner as a Registered Specialty Contractor authorized to do painting and waterproofing work in Dade County. He holds license number RX 0051718, which expires June 30, 1989. Since receiving his license he has been disciplined twice by the Florida Construction Industry Licensing Board. Gold is the President of Team Leisure Corp., a construction company, and is also its "qualifying agent." On August 14, 1986, Team Leisure Corp. entered into a written contract with Terry Dudley and his wife, Patricia, in which it agreed, for $12,000, to build a two-room, 27-foot by 13- foot addition to the Dudley home located at 15510 Leisure Drive in Dade County and to install new windows in the existing structure. According to the terms of the agreement, Team Leisure was to do "no painting." In his capacity as President of Team Leisure Corp., Gold hired William Sernaker to directly oversee the completion of the construction work specified in the Dudley contract. At the time, Sernaker was licensed as a general contractor in Dade County. As part of his arrangement with Gold, Sernaker assumed responsibility for ensuring that all work permits and inspections necessary to complete the Dudley project were obtained. On September 4, 1986, Sernaker obtained a building permit for the Dudley project. Thereafter, work on the project commenced. The foundation for the addition was laid and, on September 10, 1989, it passed the inspection of James Tucker, a Dade County building inspector. Fifteen days later, Tucker conducted a tie beam inspection. This phase of the project also received his formal approval. Sernaker obtained a roofing permit on October 14, 1986. The exterior of the roof was inspected by Russell Bergsma, another Dade County building inspector, on October 21, 1986. It too passed inspection. An electrical permit was obtained for the Dudley project on November 17, 1986, by Robins Electric, a subcontractor. When the electrical work was initially inspected by Grant Morse, another Dade County building inspector, it was rejected because there were a "few outlets missing." The record is unclear as to the results of any subsequent electrical inspections. Morse also conducted an inspection of the framing work done on the Dudley project. He did so on or around November 21, 1986. In his view, the framing was "not to code." Accordingly, he left a "tag" at the job site on which he gave the following written explanation for his rejection of the framing work: All window bucks must be tight with caulking, no gaps. When the stucco meets the window frame, it should be set back at approximately a 45-degree angle at a width of one quarter to provide a groove to be filled with caulking. Continuous back bed of caulking must be maintained. A follow-up inspection of the framing work was performed by Bergsma on December 1, 1986. In Bergsma's opinion, while some corrections had been made, deficiencies remained. He therefore issued another rejection. A third framing inspection was conducted on December 3, 1986. Tucker was the inspector who performed this inspection. He approved the work that had been done. Prior to this inspection, Gold had paid another contractor $600 to "redo" the framing. This additional expense was not passed on to the Dudleys. Morse attempted to conduct a final building inspection on December 22, 1989. He was unable to do so, however, because "[n]o one was home." From the outset, Gold kept abreast of the progress that was being made on the Dudley project by communicating with Sernaker. He also visited the job site on at least a weekly basis. Gold also heard from the Dudleys concerning the status of the project. The Dudleys closely monitored the work of Sernaker and his crew. If the work was not done to their satisfaction, they expressed their disapproval to Sernaker and, if he did not rectify the matter, they complained to Gold over the telephone. The following were among the complaints made by the Dudleys: the foundation was not level; the roof did not contain any fiberglass material; the window frames did not fit properly; the wood used for the open beam ceilings had cracks in it and was unsightly; the walls in the den were not level and had cracks in them; the linoleum on the Dudleys' screened-in porch was ripped by workers putting up a wall; the outside stucco was cracking and peeling; and trash was left on the property. An effort was made to address the Dudleys' concerns. For instance, in response to the Dudleys' complaints, a "thin cap" was placed over the foundation to make it level. The roof was redone with fiberglass material. The Dudleys were reimbursed for the linoleum they needed to replace on their porch. A contractor was hired to correct the framing problem. Nonetheless, the Dudleys became increasingly dissatisfied with Team Leisure Corp.. Sometime shortly before January 6, 1987, they became so dissatisfied that they ordered Sernaker and his crew off their property and refused to make any additional payments. Following this incident, Gold met with the Dudleys and attempted to mollify them. This was his first face-to-face meeting with them. He offered to send another contractor to the Dudleys' home to perform the work the Dudleys believed needed to be done to satisfactorily complete the project. The Dudleys accepted this offer. On January 6, 1987, Gold sent the Dudleys a letter which read as follows: As per our mutual agreement, these are the items you requested be taken care of. Once taken care of, you agree to sign completion certificate so we can be funded. COMPLETED (please check upon satisfaction) 1.) Touch up outside windows. 2.) Windows to be locked in. 3.) Walls in den to be taken down and leveled out. 4.) Frame around closet door. 5.) Fix two windows; replace concrete in doors and windows. 6.) Clean up. 7.) Replace vinyl, in rear den. 8.) $100.00 dollars to Mrs. Dudley, for clean-up. 9.) 10 year guarantee- roof and release of lien [sic]. 10.) Concrete over build. 11.) Crack under window sill. 12.) Nail in door frame. 13.) Gaps in drywall bedroom. 14.) Stucco cracking outside. 15.) Electrical inspection. (not to be Mike Charles.) Accepted and Approved: x x After receiving this letter, Mr. Dudley checked all but items 2, 5, 6, 8, and 9 on the letter's "completion certificate." Neither he nor his wife, however, signed this "completion certificate." Although the cracks in the outside stucco had been repaired at the time Dudley checked item 14, the stucco subsequently started cracking again. A final building inspection of the Dudley project was conducted by Tucker on January 13, 1989. The project was "turned down" by Inspector Tucker because it was unpainted. Under their contractual agreement, the Dudleys, not Team Leisure Corp., were responsible for the painting of the project. The painting was not done because the Dudleys noticed cracks reappearing in the outside stucco. On or around March 4, 1987, Mr. Dudley telephoned Inspector Bergsma and asked him to conduct an informal field inspection of the project. Bergsma complied with Dudley's request. When he arrived at the Dudley home, Dudley showed him a "gap on the rear of the house ... where the two roofs are at different levels and come together." Bergsma told Dudley that "[i]t didn't belong there" and that it would have to be eliminated if the structure was to pass a final building inspection. As of the date of the hearing, the structure had not passed such an inspection. Team Leisure Corp. received $10,200 for the work done in connection with the Dudley project. The remaining $1,800 of the $12,000 that the Dudleys were to pay pursuant to the contract was held in escrow by a bank. Ultimately, this $1,800, along with approximately an additional $500 from Team Leisure Corp., was given to the Dudleys as part of a settlement between them and Team Leisure Corp.. The money was to be used by the Dudleys to pay another contractor to complete the project to their satisfaction.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Construction Industry Licensing Board enter a final order (1) finding Respondent guilty of contracting outside the scope of his license in violation of Section 489.129(1) (j) , Florida Statutes; (2) imposing a $750 administrative fine upon Respondent for said violation, and (3) dismissing the remaining charges against Respondent set forth in the instant administrative complaint. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 30th day of May, 1989. STUART M. LERNER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of May, 1989. COPIES FURNISHED: Elizabeth Alsobrook, Esquire Northwood Centre 1940 North Monroe Street Suite 60 Tallahassee, Florida 323399-0792 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Carlos Garcia, Esquire 8603 Dixie Highway Suite 400 Miami, Florida 33143 =================================================================
Findings Of Fact At all times material hereto, Respondent has been a registered residential contractor having been issued license number RR 0040275. In approximately 1980, Respondent entered into a contract to erect a screen room for a Mr. Lewis. Under the terms of the contract, Respondent was to obtain the necessary building permit. After the contract had been signed, Respondent's grandfather died, and Respondent therefore went to New Jersey. He left the permit application with his qualifying agent to sign and process through the building department. When Respondent returned from New Jersey approximately 30 to 35 days later, he went to the Lewis job site and found the project almost completed. Respondent did not check to ascertain if the permit had been obtained, but rather completed the screen room himself. Lewis subsequently contacted Respondent to say that he had received a notice of violation from the building department for erecting a screen room without a permit. Respondent contacted the building department and advised that it was not Lewis's fault, but rather that it was Respondent's responsibility to pull the permit. Respondent was charged with unlawfully erecting a screen room without a permit; he appeared in court and pled guilty; and he paid a $250 fine pursuant to the adjudication of guilt entered on April 20, 1981, in the County Court in and for Dade County, Florida, in Case No. 81-50438. On June 24, 1981, Respondent submitted to the Construction Industry Licensing Board a Contractor's Registration application. On that application, Respondent answered in the negative the following question: "Has any person named in (i) below ever been convicted of any offense in this state or elsewhere other than traffic violations?" At the time Respondent gave that answer, he believed it to be true. He understood the question to call for information on criminal acts and did not comprehend the "screen room" charge to have been criminal conduct. Since Respondent answered that question in the negative, his application for registration was processed in accordance with normal procedures. Had Respondent answered that question in the affirmative, his application would not have gone through normal processing but rather would have been presented to the Construction Industry Licensing Board for the Board's determination of whether to approve the application based upon a consideration of the facts. On November 22, 1982, Respondent contracted with Naomi Blanton to construct an addition to Blanton's home located in the City of Miami, in Dade County, Florida, for a contract price of $11,250. When Respondent had first met with Blanton several months earlier, he had told her he could guarantee completion of the project within 45 days. No contract was entered into at that time, however, since Blanton had not obtained the financing she needed in order to construct an addition. When the contract was signed on November 22, Respondent told Blanton he would start the job when he finished the Chamber of Commerce building he was con structing but that he was starting a 12-unit duplex project around Christmas and would not be able to guarantee any 45-day completion deadline. Accordingly, when the contract was signed, no completion date was included in the terms of that written contract, since Respondent did not know when he could guarantee completion. The Blanton contract written by Respondent specifically provided that Respondent would obtain the building permit. On December 22 and 23, 1982, two of Respondent's employees arrived at the Blanton job site, dug a trench, knocked down the utility room, and moved Mrs. Blanton's washing machine. No further work was done until January 1983. Since Respondent knew that he was required to obtain the building permit before commencing any construction work, Respondent submitted his plans and permit application to the City of Miami Building Department. After the plans had been there about a week, he was advised that his plans would not be accepted unless they were drawn by an architect, although that is not required by the South Florida Building Code. After attempting several more times to obtain approval from the City of Miami Building Department, Respondent hired an architect to redraw the plans and secure the building permit. By this time, Respondent found himself unable to concentrate on operating his business efficiently, since he was preoccupied with spending time with his father who was dying of cancer. Also by this time, Blanton had commenced telephone calls to Respondent on an almost daily basis as late as 11:00 p.m. at his office, at his home, at his mother's home, and at his father's home. Respondent offered to return Blanton's deposit, but she refused to cancel the contract and threatened Respondent that she would sue him if he did not comply with that contract. Respondent commenced working on the Blanton job, although no permit had yet been obtained. The contract on the Blanton job called for payments at certain stages of the construction. By January 27, 1983, Respondent had completed a sufficient amount of the work under the contract so that Blanton had paid him a total of $8,270 in accordance with the draw schedule contained in the contract. Respondent ceased working on January 27, 1983, and advised Blanton and her attorney that he would do no further work until he could obtain the building permit, which he had still not been able to obtain. Although he told them his work stoppage was due to his continued inability to obtain the permit, he also stopped work due to his father's illness and his continued inability to get along with Mrs. Blanton. A delay occurred with the plans being redrawn by the architect Respondent hired to obtain the Blanton building permit, since the architect needed information from Blanton and she was out of town. After Blanton returned, the architect made unsuccessful attempts to obtain the building permit. Respondent and his architect were finally able to speak to one of the top personnel in the City of Miami Building Department about the problems they were experiencing in obtaining a building permit, and, at about the same time, Blanton contacted that same individual to complain that Respondent had no permit. On May 4, 1983, the building department finally accepted the second permit application together with the plans drawn by the architect, and the building permit was issued on May 4, 1983. No work was performed on the Blanton job between January 27, 1983, when Blanton paid Respondent the draw to which he was entitled by that date, and May 4, 1983, when the building permit was finally issued by the City of Miami. Respondent immediately resumed work and quickly completed the next stage of construction called for under the Blanton contract. Upon completing that next stage, he requested his next draw payment; however, Blanton decided not to pay Respondent for the work completed and had her attorney advise Respondent not to return to the job site. Blanton then had a friend of her son come to Miami from Wisconsin to complete the addition to her home. At all times material hereto, Respondent held a certificate of competency issued by Metropolitan Dade County.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of violating Section 489.129(1)(d), Florida Statutes, by willfully and deliberately violating Section 301(a) of the South Florida Building Code; imposing an administrative fine against Respondent in the amount of $2,000 to be paid by a date certain; and dismissing the remaining charges contained in the Administrative Complaint, as amended, against Respondent. DONE and RECOMMENDED this 13th day of April, 1984, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of April, 1984. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Joseph F. Scioli, Jr. 246 North Krome Avenue Florida City, Florida 33034 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following facts were found: At all times material to these proceedings, the Respondent, Victor S. Davis, held a registered general contractor's license, numbered RG 0013635 issued by the State of Florida, Department of Professional Regulation, Construction Industry Licensing Board in April, 1973. At all times material to these proceedings, Respondent's general contractor's license, number RG 0013635, was in a delinquent status and had been in a delinquent status since July 1, 1977. Respondent failed to renew his license after June 30, 1975 but in May, 1976 made application to reinstate license number RG 0013635 which was approved and reinstated on an active status by Petitioner in May, 1976 and issued to Respondent, Victor S. Davis, qualifying Conch Construction Corp., of Key West, Florida. There was no evidence that the reinstated license was issued for Monroe County, Florida or that Respondent ever held a certificate of competency for Monroe County, Florida. At all times material to these proceedings, Respondent was an officer (Secretary) of Classic Marketing and Development, Inc. (Classic). On July 28, 1983, the Respondent, as Secretary of Classic, entered into a contract with William Dees to construct a shell home on the Dees' property located at Lot 14, Block 7, Breezeswept Estates, Ramrod Key, Florida for a contract price of $27,000.00. On September 13, 1983, William Dees applied for and obtained building permit No. 10902-A as owner/builder for the construction of the Dees's home. Construction of the Dees home began on or about September 13, 1983. Gregory H. O'Berry, President of Classic had knowledge of, and approved of, Respondent entering into contracts for construction of homes in Monroe County, Florida, including the contract with Dees. O'Berry was aware that Respondent did not hold a certificate of competency in Monroe County, Florida and that Respondent's registered general contractor's license did not cover contracting in Monroe County, Florida. O'Berry understood that Phillip A. Braeunig, a properly licensed general contractor in Monroe County, Florida, was acting as the general contractor for Classic- in the construction of homes by Classic, including the construction of the Dees home. Braeunig did not act as general contractor on the construction of the Dees' home. Respondent supervised the contraction of the Dees' home, until Respondent abandoned the construction of the Dees' home, and in performing these supervisory duties fulfilled the responsibilities of a general contractor. No other officer or authorized agent of Classic had any responsibility for the supervision of, or acted in any manner as a general contractor, in the construction of the Dees' home. Braeunig prepared and submitted to Respondent an application to qualify Classic with Petitioner using Braeunig's license but this application was never filed with Petitioner during- anytime material to these proceedings. Classic was never qualified by anyone, including Respondent or Braeunig, at any time material to these proceedings. Braeunig~acted as general contractor for Classic on the Conti home, which was in the beginning stages of Classic and prior to the Dees' job. Braeunig was brought into Classic for the purpose of acting as general contractor because of the Respondent's invalid license.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the Board enter a final order Dismissing Count I of the Amended Administrative Complaint filed against the Respondent. It is further RECOMMENDED that the Board enter a final order finding Respondent guilty of the violation charged in Count II of the Amended Administrative Complaint and for such violation it is RECOMMENDED that the Board suspend the Respondent's registered general contractor's license for a period of two (2) years and assess the Respondent with an administrative fine of $500.00, stay the suspension and place Respondent on probation for a period of two (2) years, provided the Respondent pays the $500.00 fine within ninety (90) days. Respondent's failure to pay the $500.00 fine within the time specified will result in his registered general contractor's license being suspended for a period of two (2) years with the requirement that when the fine is paid and the suspension lifted, the Respondent must appear before the Board for reinstatement of his license. Respectfully submitted and entered this 3rd of December, 1985, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 3rd day of December, 1985. APPENDIX Department of Professional Regulation, Construction Industry Licensing Board v. Victor S. Davis, Division of Administrative Hearings Case No. 85-1963 Ruling on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact No. 1 except for the statement that "Respondent's license was issued for Okaloosa County only" which is rejected as not being based upon competent substantial evidence. Hearsay alone is not sufficient to support a finding of fact. Adopted in Finding of Fact No. 1 except for statement that "said license has been delinquent since July, 1981" which is rejected as being contrary to the evidence in Petitioner's Exhibit No. 1 which shows delinquent status as of July 1, 1977. Adopted in Finding of Fact No. 3. Rejected as a conclusion of law rather than a proposed finding of fact. Considered as background information and not as a finding of faet. Adopted in Finding of Fact No. 4. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact Nos. 4 and 5. Adopted in Finding of Fact Nos. 5 and 7. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of feet No. 10 Adopted in Finding of Fact No. 10 Rejected as a conclusion of law rather than a proposed finding of fact. Respondent did not submit Proposed Findings of Fact. COPIES FURNISHED: James Linnan, Executive Director Department of Professional Regulation Construction Industry Licensing Board P. O. Box 2 Jacksonville, FL 32202 Nancy M. Snurkowski, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Victor S. Davis 2169 North Hercules Avenue Clearwater, FL 33575 and 6290 Sandcrest Circle Orlando, FL 32819
The Issue The issue to be resolved in this proceeding involves whether the Respondent's certification to practice contracting should be subjected to disciplinary action for alleged violations of Section 489.129(1), Florida Statutes, and, if the violations are proven, what, if any, penalty is warranted.
Findings Of Fact The Petitioner is an agency of the State of Florida charged, as pertinent hereto, with enforcing, administering, and regulating the practice standards and licensure standards for the construction industry in Florida. This authority is embodied in the various provisions of Chapters 489, 455, and 120, Florida Statutes, and rules promulgated pursuant thereto. The Respondent is a licensed general contractor in the State of Florida having been issued license number RG0060516 and is registered to conduct contracting business in his individual capacity. On July 2, 1990, a contractor, Lonnie J. Walker, notified the Building Department of the City of Tallahassee that he had withdrawn as contractor for a job located at 722 Dunn Street, in Tallahassee, Florida. He thereupon withdrew the building permit he had obtained for the work being performed at those premises. On August 8, 1990, the Respondent contracted with Mary N. Spencer, the owner, to make certain repairs at the two-unit apartment building located at 722 Dunn Street, Tallahassee, Leon County, Florida. The contract price agreed upon between the Respondent and Ms. Spencer was $867.00. The Respondent thereupon performed some of the aforementioned contracting work, consisting of repairs of various types. He was not registered to contract in Leon County, Florida, however. The Department of Growth and Environmental Management of Leon County, Florida, is responsible for issuing construction contractor licenses for the County, including for the City of Tallahassee. There was no proper building permit issued for the job and job site when the Respondent entered into the contracting work at those premises. The Respondent failed to obtain a permit for the repairs and this ultimately came to the attention of the City of Tallahassee Building Department. That agency issued a stop work order on September 5, 1990. The Respondent was not performing work pursuant to Mr. Walker's previous permit, which had been withdrawn. The Respondent was not an employee of Lonnie J. Walker, the previous general contractor for the job. The Petitioner agency submitted an affidavit after the hearing and close of the evidence, with its Proposed Recommended Order. That affidavit asserts that the Petitioner accumulated $458.10 in investigative costs and $2,491.30 in legal costs associated with the prosecution of this case, for a total alleged cost of prosecution of $2,949.40. It moves, in its Proposed Recommended Order, that payment of the costs should be made in accordance with Section 61G4-12.008, Florida Administrative Code. The request for costs was first raised as an issue in the Proposed Recommended Order submitted by the Petitioner and is advanced only in the form of a hearsay affidavit. No prior motion for costs served upon the Respondent is of record in this proceeding.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered by the Construction Industry Licensing Board finding the Respondent guilty of the violations charged in the Administrative Complaint and assessing a penalty in the form of a letter of guidance and an aggregate fine of $600.00, as described with more particularity hereinabove. DONE AND ENTERED this 9th day of March, 1994, in Tallahassee, Florida. P. MICHAEL RUFF Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 10th day of March, 1994. APPENDIX TO RECOMMENDED ORDER, CASE NO. 92-591 Petitioner's Proposed Findings of Fact 1-8. Accepted. Respondent's Proposed Findings of Fact Respondent submitted no post-hearing pleading. COPIES FURNISHED: G.W. Harrell, Esquire Department of Business and Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, FL 32399-0792 Julius S. Baker, Sr. Box 253 Morrow, GA 30260 Mr. Richard Hickok Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway Suite 300 Jacksonville, FL 32211-7467 Jack McRay, Esq. General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, FL 32399-0792
The Issue The Florida Construction Industry Licensing Board (Petitioner herein) seeks to revoke Carroll L. Mozingo's (Respondent herein) license to practice as a registered general contractor based on allegations which will be set forth hereinafter in detail that he diverted funds in violation of Chapter 468.112(2)(e), Florida Statutes. Based upon my observation of the witnesses and their demeanor while testifying and the entire record compiled herein, I make the following:
Findings Of Fact The Respondent is a registered general contractor, who holds current license no. RG0015876. On September 7, 1976, Respondent entered into a contract with Robert Johnson and his wife Sandra Johnson for a room addition and patio to their house located at 197 North Roscoe Blvd., Ponte Vedra Beach, Florida. The full amount of the contract plus agreed upon extras amounted to $9,640.00. (Petitioner's Composite Exhibit Number 2) Respondent applied for and obtained a building permit for the construction of the Johnson's addition on or about September 27, 1976, and construction commenced shortly thereafter. (Petitioner's Exhibit Number 1) Donald Jermaine, a St. Johns County field inspector, testified that he conducted inspections on the subject job and noted numerous violations of the St. Johns County Building Code. He coordinated the inspections for this project up until the time it was abandoned by Respondent during mid February, 1977. At the time of abandonment, the owner, Robert Johnson, had paid a total amount of $11,021.96 to Respondent and/or various suppliers. To complete the job as contracted by the parties (Johnson and Mozingo) Messr. Johnson had to pay Proctors Construction Company $2,800.00, an electrical contractor $369.00 and a plumbing contractor $520.00 for a total expenditure over and above the above referenced contract amount of $3,689.00. He testified that no additional work was done to his home. The Respondent testified that he expended $7,458.00 for materials on the Johnson project and was unable to complete it because his mortgage payments were delinquent and he was not receiving any additional monies from Messr. Johnson to fulfill his obligations. He testified that he was unable to work at night and therefore had to seek other employment with another contractor. The above explanation by the Respondent which led to his abandonment of the subject project does not excuse him from his contractual obligations to either fulfill the contract as agreed upon or to seek a renegotiation based on additional costs and/or unexpected circumstances. This was not done nor was any other explanation given as to where the additional monies in excess of $4,000.00 was spent. I therefore conclude that he engaged in a diversion of funds as alleged in the administrative complaint filed by the Petitioner on May 27, 1977. I shall so recommend.
Recommendation Based on the foregoing findings of fact and conclusions of law, I hereby recommend that the Respondent's general contractor's license be suspended for a period of two years. RECOMMENDED this 2nd day of December, 1977, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings 530 Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 C. H. Hoskinson, Chief Investigator Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211 Carroll L. Mozingo 1909 Ed Johnson Drive Jacksonville, Florida 32218 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1095 CARROLL L. MOZINGO dba CARROLL CONSTRUCTION COMPANY, RG 0015876, 1909 Ed Johnson Drive, Jacksonville, Florida 32218, Respondent. /
