The Issue The issue presented for decision herein is whether or not the Respondent, David H. Tinius, unlawfully abandoned a construction project; diverted funds received for completion of a construction project and thereby failed to fulfill his contractual obligations.
Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, the following relevant facts are found. By its administrative complaint filed herein signed October 6, 1982, the Petitioner, Construction Industry Licensing Board, seeks to suspend, revoke or take other disciplinary action against the Respondent's registered building contractor's license. During times material herein, Respondent was a registered building contractor and has been issued license No. RB0024083. On approximately April 20, 1978, Respondent entered into a contract with Jess Marks to build a residence in Tamarac, Florida, for the sum of $46,551. Respondent commenced construction of the Mark's residence but left the site when it was approximately forty percent complete. At that time, Respondent had received approximately $44,000 of the contract sum. Jess Marks completed the construction of his residence by hiring another contractor to complete the project and expended approximately $50,000 over and above the contract price as agreed upon by the Respondent to complete his residence. Respondent never returned any of the monies received from the Marks for completion of the residence. On approximately April 24, 1978, Respondent entered into a contract with Abe Abrahams to construct a residence in Tamarac, Florida, for the sum of $30,473. Respondent left the Abrahams' project after he had received $6,000 and had completed approximately ten percent of the work on the Abrahams' residence. Respondent did not return to the site nor did he return any of the monies received from the Abrahams for the construction of their residence (See Petitioner's Composite Exhibit No. 5). The Abrahams had to pay for supplies and material bought for the project by the Respondent and which reportedly had been paid, according to Respondent. THE RESPONDENT'S POSITION As noted hereinabove, the Respondent did not appear to contest or otherwise refute the allegations contained in the administrative complaint filed herein. However, Respondent, through counsel, filed an answer which admitted the complaint allegations filed herein.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is, hereby RECOMMENDED that the Respondent's registered building contractor's license No. RB0024083 be REVOKED. DONE and RECOMMENDED this 29th day of August, 1983 in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of August, 1983 COPIES FURNISHED: Michael J. Cohen, Esquire 2715 East Oakland Park Boulevard Suite 101 Fort Lauderdale, Florida 33306 David H. Tinius 4420 Northwest 36th Court Lauderdale Lakes, Florida 33309 David H. Tinius Post Office Box 6338 Charlotte Amalil St. Thomas, U.S.V.I. 00801 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred M. Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact These proceedings were set for final hearing by a Notice of Hearing dated July 8, 1983 addressed to the parties, including Respondent at 488 Esther Lane, Altamonte Springs, Florida, 33596. 2/ The Notice of Hearing was not returned to the Division of Administrative Hearings as undelivered. At the time and place noticed for the final hearing the Hearing Officer waited until 9:16 a.m., to commence the proceedings, which concluded at 11:08 a.m. At no time has the Respondent contacted the Hearing Officer concerning a continuance or explained his failure to appear as noticed. At all times material to this proceeding Mr. McIntee has been licensed as a certified building contractor under license number CB C015923. He was also the qualifying agent pursuant to Section 489.119, Florida Statutes, for Delco, Incorporated. At no time has he ever attempted to qualify or otherwise notify the Construction Industry Licensing Board that he intended to affiliate with or do business as Earth Shelter Corporation of Florida, Inc. On July 30, 1980 Earth Shelter Corporation of Florida, Inc. (Earth Shelter) entered into a contract with Mr. and Mrs. William Sweet to construct an earth shelter single family residence in Lake County, Florida. The estimated cost of the project was to be $57,000 and was guaranteed not to exceed $60,000. The contract was negotiated by Respondent acting as president of Earth Shelter. Mr. McIntee was the contractor who pulled the building permit on behalf of Earth Shelter. The project was financed by First Family Federal Savings and Loan Association of Eustis, Florida. In order to obtain payments from the Association, Respondent periodically executed affidavits which stated in part: Affiant says further that all the subcon- tractors, materialmen or any other persons performing labor and furnishing materials used in the construction of the building, or improvements to the premises or appur- tenances thereof, have been fully paid in- cluding all extras. As the result of executing these affidavits Respondent received draws totaling $49,079.26 on the dates of September 30, 1980, October 31, 1980, December 3, 1980, February 4, 1981 and July 10, 1981. These affidavits were false. At the time the affidavits were executed all the subcontractors had not been paid by Respondent. As an example, Frank Wagner Excavating, Inc. performed subcontracting services at the Sweet project on June 4 and 5, 1981 at a cost of $1,451. This was billed to Respondent on June 6, 1981. He sent Wagner Excavating a check dated June 6, 1981, in the amount of the invoice, but the check was returned to Wagner for lack of sufficient funds at Respondent's bank. Before Respondent's check bounced, but subsequent to invoicing the work done on June 4 and 5, 1981, Mr. Wagner performed additional earth moving work at the Sweet project on July 3, 8, 9 and 10, 1981. That work was invoiced on July 10, 1981 for $1,378.75. No attempt was made by Respondent to pay for the second invoice. Eventually Wagner Excavating was paid by Mr. Sweet personally and by an additional payment directly to Wagner Excavating by First Family Federal Savings and Loan Association in order to satisfy Wagner's lien. In order to protect himself, Wagner had filed a lien against the Sweet property on August 17, 1981. Because of structural defects in the construction of Mr. Sweet's home performed by Respondent, Mr. Sweet filed a complaint with the Lake County Board of Examiners against Respondent. Notice of that complaint was given to Respondent on August 18, 1981. He was informed that on September 1, 1981 the Lake County Board of Building Examiners would take testimony concerning the allegations contained in the complaint. Respondent was urged to attend the meeting and to be represented by counsel if he so desired. Mr. McIntee did appear at that meeting. An investigation of the complaint followed. Respondent was subsequently noticed for a second meeting of the Board of Examiners to be held on October 6, 1981 concerning the Sweet complaint, but he failed to appear. At that time the results of the investigation were reviewed and the Lake County Board of Examiners revoked Respondent's license as a contractor in Lake County for abandonment and code violations related to his work on Mr. Sweet's residence. On September 19, 1980 Earth Shelter through Respondent entered into a contract with James V. Migliorato to construct a residence in Seminole County, Florida. The contract price was $48,500. During the course of the work performed by Mr. McIntee, liens in the amount of approximately $9,500 were filed by third parties who provided materials and services under subcontract to Earth Shelter in the construction of Mr. Migliorato's residence. By March of 1981 Respondent had abandoned the project without cause. Mr. Migliorato later met with him at which time Respondent explained that he had run out of money and was not going to finish the job. In August of 1981 Mr. Migliorato and his counsel met with Respondent and his counsel. During their discussions Respondent stated that the money which he had been paid for work on the Migliorato home had been diverted by him for use on the Sweet residence mentioned above. The liens outstanding against Mr. Migliorato's property were never satisfied by Respondent and had to be paid by the homeowner. An example of the outstanding liens was that filed by Superior Distributors, Inc. which supplied and installed a kitchen and bathroom cabinet at the Migliorato residence. The work was completed on June 30, 1981 and invoiced on the same date for $2,128. This invoice has never been paid by Respondent.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Construction Industry Licensing Board enter a Final Order revoking Respondent's license as a certified building contractor in the State of Florida. DONE and RECOMMENDED this 14th day of October, 1983, in Tallahassee, Florida. MICHAEL P. DODSON Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of October, 1983.
Findings Of Fact The Respondent, Paul K. Scapecchi, is a registered general contractor in the State of Florida, holding license number RG 0015926, and a registered roofing contractor, holding license number RC 0031048. The Respondent is the qualifier for Paul's Construction Company, which is the Respondent's firm. Edwin Schmid is a resident of West Germany who vacations in North Florida, and who testified by deposition which was received in evidence as Exhibit 1. He owns six parcels of real estate, or lots adjacent to each other, including Lot 19, Bon Bay Estates, in Santa Rosa County, Florida, which he purchased in approximately February, 1980. Edwin Schmid intended to have a home constructed on Lot 19 to be used as rental property. Subsequently, Edwin Schmid was introduced to the Respondent and the Respondent's father, Walter Scapecchi, by Lee and Carolyn Swigger. The Swiggers had become friendly with Edwin Schmid because Carolyn Swigger speaks German. Thereafter, Edwin Schmid contracted with the Respondent and Walter Scapecchi to have his home built on Lot 19 in Bon Bay Estates. This contract was in written form and dated March 21, 1981. Although Walter Scapecchi signed this contract "doing business as Paul's Construction Company," as contractor, the Respondent admitted that the contract was with himself, and that his father was merely an employee of the firm. The initial contract with Edwin Schmid in which the price was set at $36,000 was participated in by both the Respondent and his father. Edwin Schmid dealt with the Respondent directly on several occasions, but the business card he had been given showed Walter Scapecchi's name written in by hand over the Respondent's name. The deposit check written by Edwin Schmid was made payable to Walter Scapecchi in the amount of $8,000. Walter Scapecchi is not licensed to engage in the business of general contracting, but was so engaged, aided and assisted by his son, the Respondent. The deposit check for $8,000 was to be used to cover the digging of the foundation, the necessary fill, the pouring of the concrete foundation, a culvert for the driveway, and electrical service, which was to have been completed by April 10, 1981, pursuant to the contract. A second payment of $10,000 was to have been made on April 10, 1981. On April 10, 1981, however, no work had yet been done, and none was done until March of 1982, nearly one year later. The work done in March 1982 consisted only of placing foundation markers. The Respondent admitted that the work of placing foundation markers did not cost anything near the $8,000 paid, and that he did not request the second payment of $10,000 because the work done did not exhaust the initial payment. Nevertheless, no part of the $8,000 initial payment was refunded to Edwin Schmid. Throughout the period of time after the contract was executed in March of 1981, Edwin Schmid wanted the Respondent to complete the construction pursuant to the contract. At one point after the first year had elapsed without any substantial work being done, Edwin Schmid attempted to effect a new contract with the Respondent that required the initial work for which he had already paid $8,000 to be completed. The Respondent agreed to this, but did not perform any more work at the construction site. The Respondent admits that he has not performed as required by the contract. He contends this was due to personal financial problems. Other excuses for the Respondent's nonperformance included his underestimation of the amount of fill required, heavy rains which caused delays, and State of Florida requirements. Nevertheless, work was not begun for nearly one year after the contract, contrary to the agreement, and only a minimal amount of work was done as of the date of the hearing. The Respondent moved out of the State of Florida in February of 1982, without notifying Edwin Schmid.
Recommendation Based upon the foregoing findings of fact and conclusions of law, it is RECOMMENDED that the Respondent, Paul K. Scapecchi be found guilty of violating Sections 489.129(1)(e), (f), (h), (j) and (k), Florida Statutes, and that licenses numbered RG 0015926 and RC 0031048 held by Paul K. Scapecchi be REVOKED. THIS RECOMMENDED ORDER entered this 27th day of September, 1983. WILLIAM B. THOMAS Hearing Officer Division of Administrative Hearings Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of September, 1983. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Paul K. Scapecchi 133F 25th Court, N.W. Birmingham, Alabama 35215 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
The Issue The issue for disposition is whether, as alleged in the Administrative Complaint, Respondent committed various violations of Chapter 489, F.S., regulating the practice of contracting, by failing to complete a roofing job which he had agreed to perform.
Findings Of Fact At all times relevant, Michael W. Ballans was licensed by the State of Florida as a certified building contractor, holding License Number CB C036542. He qualified as an individual doing business at 1107 Oregon Avenue, St. Cloud, Florida 32769. On April 6, 1988, H. Earl Fisher signed his acceptance of a written proposal by Michael Ballans for Ballans to install a new roof on Fisher's double-wide trailer at 7650 E. Irlo Bronson Memorial Highway, in St. Cloud, Florida. The price for the job was $1,575.00, for supplies and labor. Fisher made an initial payment of $1,018.00 on June 6, 1988. Materials were delivered to the job site, but Ballans never commenced work. Fisher contacted Ballans four or five times to try to get him to do the job or to get someone else to do it. Ballans never returned the funds and at one point told Fisher that he could not do the work because he lost his insurance. Fisher did not agree to do the work himself and told Ballans he wanted the money back and the materials removed from his property. Stanton Alexander was qualified as an expert in construction industry contracting, including roofing. He has practiced in the profession for approximately thirty years. He served two terms on the construction industry licensing board, including a term as chairman. He has testified in the past as an expert in construction industry practices. A contractor terminates his responsibility under a contract after payment and final inspection and a certificate of occupancy has been issued. Until then, he is responsible for completion of the job. Proper procedure when a contractor becomes unable, to complete a job is to refund the money and remove the materials or to get permission from the building department and owner to bring in another contractor to complete the work. Michael Ballans did neither, and simply abandoned the job. This deviation from the standards of construction industry practice constitutes incompetency or misconduct.
Recommendation Based on the foregoing, it is hereby, RECOMMENDED That a Final Order be entered finding Michael W. Ballans guilty of violations alleged in Counts I, II and IV of the Administrative Complaint, and imposing a fine of $500.00. DONE AND RECOMMENDED this 16th day of April, 1990, in Tallahassee, Leon County, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 16th day of April, 1990. COPIES FURNISHED: Jack L. McRay, Esquire Dept. of Professional Regulation 1940 N. Monroe St., Suite 60 Tallahassee, FL 32399-0792 Michael W. Ballans 2314 Knob Hill Drive, Apt. #12 Okemos, Michigan 48864 Kenneth D. Easley, General Counsel Dept. of Professional Regulation 1940 N. Monroe St., Suite 60 Tallahassee, FL 32399-0792 Fred Seely, Executive Director DPR-Construction Industry Licensing Board P.O. Box 2 Jacksonville, FL 32202
The Issue Did respondent fail to properly supervise, direct and manage the contracting activities of the business of which he is the qualifier, and if so, what disciplinary action should be taken against respondent's contracting license?
Findings Of Fact At all times material to this proceeding the respondent was a certified building contractor licensed by the State of Florida and the qualifying agent for Custom Concrete of Naples, Inc. (Custom Concrete). Rodney Velez was the president of Custom Concrete and licensed only in concrete--concrete forming, placing and finishing. Susan Velez, Rodney Velez's wife, was an officer of Custom Concrete. On April 23, 1983, Custom Concrete, by and through Rodney Velez, entered into a contract with Mark and Penny Paterson to construct a home for $38,550.00. Mrs. Paterson had previously met Rodney Velez in the course of her work, and Velez had told her that he was a builder. Mrs. Paterson had suggested that Velez look at a floor plan that she and her husband had, and after certain negotiations, including a change of floor plan, the contract was entered into. During the course of the negotiations Mrs. Paterson never talked to the respondent and was unaware that the respondent was involved or would be involved in the construction of the home. Mrs. Paterson believed that Rodney Velez was the "builder"; however, the construction of the Paterson home was beyond the scope of Velez's concrete license. The respondent signed the application to secure the building permit for the Paterson residence, although he did not personally appear to procure the building permit. The clerk of the contractor's licensing section of the building code compliance department relied on the signature on the application because it was notarized. The notary was Susan Velez. Respondent did not supervise or direct the construction of the Paterson home. Neal Jackson, president of the company who did the electric work on the home, was unaware that respondent was involved in the project until well after the house was finished. Although it is usual for a supervisor or superintendent to be at the job site some of the time, Jackson never saw the respondent or Velez at the job site. Jeff Allain, the carpenter who did the framing and certain other work, was on the job site five or six days and saw the respondent once during the framing of the structure "just generally looking around." The respondent didn't say anything to Allain. David Isom did drywall work on the house. He had no contact with the respondent and did not see him at the construction site. Mrs. Paterson went by the construction site quite often and realized that the job was not being properly supervised. Velez was rarely there, and Mrs. Paterson never saw the respondent. The workmen on the site would ask the Patersons when Velez would be there because they had questions concerning the work. Neither of the building inspectors saw anyone supervising at the job site, although usually no one is at the job site when an inspection is made. Two days after the Patersons moved into their house, they compiled a "punch list" of the items that needed to be completed or corrected. The list was given to Velez, but the work was not corrected to the Paterson's satisfaction. Although Velez did not give the "punch list" to respondent, Velez discussed the problems with the respondent. Respondent did not take any steps to remedy the problems and said he thought "a lot of it was nonsense." Velez told respondent that he, Velez, would take care of it. Because of the unresolved problems with the house, Mrs. Paterson finally called the licensing board to file a complaint against Rodney Velez. At that time, she was informed that Rodney Velez was not the contractor; the contractor was the respondent. This was the first time that Mrs. Paterson was aware that the respondent was involved with the construction of the house. All of the Patersons dealings had been with Velez, and all checks for construction payments were made out to Velez personally. 2/ Even though the Patersons had not received satisfaction from Custom Concrete for the problems with the house, they signed the closing papers because Velez threatened to evict them. At closing the Patersons received a lien release from Custom Concrete which released all work prior to March 9, 1984. Subsequently, Velez filed a claim of lien against the Paterson property for work completed on February 9, 1984.
Recommendation Based upon the foregoing findings of fact and conclusions of law it is recommended that respondent be found guilty of violating Section 489.129(j), Florida Statutes, that he be fined $1,000.00, and that his license be suspended for 60 days from the date the Construction Industry Licensing Board enters its final order in this case. DONE and ORDERED this 30th day of January, 1985, in Tallahassee, Florida. DIANE A. GRUBBS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of January, 1985.
