Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence and the positions of the parties, I hereby make the following: Thomas G. Walker (herein sometimes called "Licensee" or "Respondent") is a registered residential contractor and is issued license number RR 0009839. Thomas G. Walker was initially licensed by the Board in July of 1969 as an individual and during January, 1975, he changed his registration status as an individual to qualify Insulshield Roofing as the business entity through which he would conduct his business (Petitioner's Exhibit No. 1). An examination of the official records pertaining to the Licensee reveals that he does not now nor has he ever held a roofing license in the State of Florida. On February 16, 1979, the Licensee was apprehended contracting roofing without a State roofing contractor's license by the Board's representative and was issued a Notice of Violation (Petitioner's Exhibit No. 3). On July 26, 1977, the Licensee entered into an agreement with Jan Soderstrom, 501 Orlando Avenue, Indialantic, Florida, to remove the tile from the Florida Room of her residence and hot mop the herein-described roofing area, to replace tile as needed, to clean and coat the entire roof, and to install a cap over Ms. Soderstrom's chimney. He guaranteed the work for a period of five (5) years and charged a contracted price of $800.00. The Licensee was paid the contracted price of $800.00 by check dated August 4, 1977 (Petitioner's Exhibit No. 5). During early February, 1978, Ms. Soderstrom detected a leak in her roof and summoned the Licensee back to her residence to repair same. During February, 1978, Respondent returned to Ms. Soderstrom's residence to repair the leak in her roof. Upon his return, he removed several roof tiles and since February, 1978, to the present, he has not returned to this project. Clyde Pirtle, a field investigator for the Board, investigated the Licensee based on complaints that he received from Ms. Soderstrom and from a Mr. Capitz. On or about February 16, 1977, Mr. Pirtle discussed a Notice of Violation with the Licensee and explained to him the necessity to register as a Roofing Contractor, if he was in the business of acting as a Roofing Contractor. Mr. Charles D. Franklin, a building official of Indian Harbor Beach, Florida, is the custodian of the records in Indian Harbor, Florida. Based on an examination of the records by Mr. Franklin, the Respondent/Licensee is not registered as a Roofing Contractor locally.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby, RECOMMENDED: That the registered residential contractor's license, number 0009839, of the Licensee, Thomas G. Walker, d/b/a Insulshield Roofing, be suspended for a period of one (1) year. RECOMMENDED this 4th day of April, 1979, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 2400 Independent Square Jacksonville, Florida 32202 Thomas G. Walker d/b/a Insulshield Roofing 170 5th Street South Melbourne Beach, Florida 32951 J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
The Issue Whether Respondent committed the offenses alleged in the Administrative Complaint and, if so, the penalties that should be imposed.
Findings Of Fact At all times relevant to this proceeding, Respondent has been licensed by the Petitioner as a roofing contractor, having been issued license number CCC 57995 by the Florida Construction Industry Licensing Board. At all times relevant to this proceeding, Respondent was the qualifier for and did business as “Victor’s Roofing Co., Inc. of the Fla. Keys” (Victor’s Roofing). At all times relevant to this proceeding, Mr. Johnson was an owner of property located at 3214 Harriet Avenue, Key West, Florida (the subject property). Mr. Johnson lives in Hollywood, Florida. The subject property is rental property. Respondent and his company are not licensed to do drywall work in Key West, Florida, and they are not licensed with Petitioner other than as a roofing contractor. ROOFING WORK On November 3, 2008, Respondent, on behalf of Victor’s Roofing, entered into a contract with Mr. Johnson to re-roof the subject property. The proposal submitted by Respondent to Mr. Johnson contained Victor’s Roofing’s full corporate name; its office address in Marathon, Florida; two telephone numbers; and a fax number. The proposal was signed by Respondent. The proposal described in some detail the scope of the work. The price of the work was $7,000.00. Mr. Johnson accepted the proposal. Victor’s Roofing completed the roofing job to Mr. Johnson’s satisfaction. A leak developed after the roof was completed and Victor’s Roofing promptly repaired the leak to Mr. Johnson’s satisfaction. Petitioner’s Administrative Complaint alleged that Victor’s Roofing had failed to obtain a permit for the roofing job on the subject property and that it had failed to obtain required inspections. Those allegations were the result of an error by Petitioner’s investigator. Ms. Del Rio obtained records from the City of Key West Building Department for the wrong address. Instead of obtaining the permit history for the subject property (3214 Harriet Avenue) she requested and obtained the permit history for 3314 Harriet Avenue. Respondent applied for a permit for the roofing job on the subject property on November 11, 2006, and he obtained an inspection of the roof on November 27, 2007 [sic]. There was insufficient evidence to establish that any other permit or any other inspection was required for the roofing work. DRYWALL WORK After the roofing job had been completed (but before the inspection on November 27, 2007),2 Mr. Johnson informed Respondent by telephone that he needed someone to replace drywall that had been damaged during the period of time the subject property’s roof leaked. Mr. Johnson asked Respondent whether he knew anyone who could do the job. Respondent replied in the affirmative and told Mr. Johnson he would have someone contact him about doing the work.3 Thereafter, Respondent’s brother, Early Harris, contacted Mr. Johnson and the two of them verbally agreed on a price of $4,000. At the time Respondent put Early Harris in touch with Mr. Johnson, Respondent knew that Early Harris was not licensed to do drywall work in Key West. After giving Mr. Johnson’s telephone number to Early Harris, Respondent had no further involvement with the drywall work on the subject property. The price of the drywall work escalated to $9,000.00 after the work began. On November 25, 2006, Early Harris and Mr. Johnson signed a written proposal agreeing to the price of $9,000.00.4 This was a form proposal with the following: Victor’s Roofing Co., Inc. 2nd Generation Serving South Florida Licensed & Insured Marathon, Fla. The only telephone number on the proposal other than Mr. Johnson’s, was the number for Early Harris’ cell phone. The contract signed by Respondent on November 3, 2006, for the roofing work was on a different form and utilized a different font than the contract signed by Early Harris on November 25, 2006. The name of the corporation on the proposal for the drywall work, while similar to the name of Respondent’s company, was different. Early Harris has worked for Respondent’s business for several years, but there was no clear and convincing evidence that Early Harris had the authority to contract on behalf of Respondent’s business in November 2006. There was no evidence that Early Harris is a part owner of Respondent’s business or that he is an officer or director of Respondent’s business. Respondent testified, credibly, that Early Harris was not authorized to contract on behalf of Respondent’s business at the times relevant to this proceeding. There was no clear and convincing evidence to refute Respondent’s assertion that Earl Harris had no authority to contract on behalf of Respondent’s business. Early Harris did the drywall work on the subject property. Mr. Johnson paid Early Harris $9,000.00 for the drywall work. Mr. Johnson could not find the check(s) he wrote for the drywall work and, consequently the check(s) were unavailable as an exhibit. His recollection as to the name of the payee of the check(s) was not clear. Respondent testified, credibly, that neither he nor his business received any of the money for the drywall work. The drywall work Early Harris did was not to Mr. Johnson’s satisfaction. Mr. Johnson had to pay $600.00 to a drywall contractor for corrective work. In addition, Mr. Johnson had to pay $600.00 for a permit to have the repair work done.5 The total investigative costs of this case to Petitioner, excluding costs associated with any attorney’s time, was $191.16.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board, enter a final order finding Respondent not guilty of the violations alleged in Counts I, II, and III of the Administrative Complaint. DONE AND ENTERED this 14th day of January, 2010, in Tallahassee, Leon County, Florida. CLAUDE B. ARRINGTON Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 14th day of January, 2010.
Findings Of Fact The Respondent's name is Troy Griffin. The Respondent is now and was at all times relevant to the pending Administrative Complaint, a registered residential contractor in the State of Florida having been issued license number RR 0030688. The Respondent is not now and at no time material to the pending Administrative Complaint was the Respondent a certified or registered roofing contractor in the State of Florida. At all times material to the pending Administrative Complaint, the Respondent's license #RR 0030688 qualified Griffin Remodeling & Repairs, Jacksonville, Florida. In June 1978 the Respondent d/b/a Griffin Remodeling and Repairs contracted to repair the residence of June Moody, Jacksonville, Florida. The contracting work included work upon the Moody's built-up roof, which Respondent re-roofed pursuant to contract. Respondent built up the roof with more than one layer of felt in 1978. These layers were discovered by the city's inspector in 1982. Respondent returned in 1978 and patched the roof he installed. These patches were seen by the city's inspector in 1982. The owner, Moody, did not complain of leaks in 1982. There was no evidence of leaks in 1982. A roof poorly installed without sufficient tar and felt will leak within the time that has passed between 1978 and 1982. See inspector's testimony in response to Hearing Officer's question. Moody's home was a single family, one story residence. No evidence was received regarding whether the City of Jacksonville requires examinations of roofing contractors prior to their certification.
Recommendation Having found that the Respondent did not commit the alleged violations, it is recommended that the Administrative Complaint be dismissed and no action be taken. DONE and ORDERED this 23rd day of August, 1985, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings The Oakland Buildina 2009 Apalachee Parkway Tallahassee, Florida 32301 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of August, 1985. COPIES FURNISHED: W. Douglas Beason, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Troy Griffin 7443 Laura Street Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Direetor Department of Professional -I Regulation. Construction Industry Licensing Board P. O. Box 2 Jacksonville, Florida 32202
Recommendation Based upon the foregoing findings of fact and conclusions of law, it is recommended that the Construction Industry Licensing Board issue a written reprimand to respondent Elias Davis for failure to pull a permit on a roofing job. RECOMMENDED this 5th day of April, 1984, in Tallahassee, Florida. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 5th day of April, 1984.
The Issue Whether Respondent's contractor license should be disciplined for alleged violations of Chapters 489 and 455, Florida Statutes.
Findings Of Fact Respondent, James Cooper, was at all times material to this action licensed by the State of Florida as a registered roofing contractor, having been issued license number RC0066905. Mr. Cooper's license is currently classified "Inactive, Issued (09/05/97)." Around March 1, 1996, Marshall Moran was contacted by Julia Jones regarding repairs to the leaky roof on her home located at 209 Cresent Drive, DeFuniak Springs Walton County, Florida. Ms. Jones' home was over one hundred years old with a steep metal roof. The roof she wished repaired was over the enclosed sleeping porch of her house. Over the last ten years, she had various contractors attempt to fix the leak in the sleeping porch roof. These attempts occurred, on average, more than one time per year. The leak always returned. Marshall Moran is an unlicensed and unregistered roofing contractor. Mr. Moran has been a roofing contractor since before the licensure requirements for contractors became law. He elected not to become licensed under those statutes. However, he did have the experience and skills necessary to repair Ms. Jones' roof. Marshall Moran discussed the job with Ms. Jones. Mr. Moran recommended the entire section of the roof be rebuilt and described the anticipated repairs. Ms. Jones would not allow the entire section of roof to be repaired. She thought only the small section where the leak was apparent needed repair. Unknown to Ms. Jones and prior to beginning the work, Mr. Moran contacted Respondent to tell him of Ms. Jones' job and to see if Respondent wanted to do the job. Respondent couldn't do the job with his crew but offered to allow Mr. Moran to "work under his license." Respondent was pursuing a large commercial roofing contract around the same time as the events at issue here. He wanted to keep Moran's crew together in order to be able to complete the large commercial job. He held the crew together by enabling Moran to do the construction at Julia Jones' residence in consideration for taking legal responsibility for the Jones' job. Respondent did not hire Mr. Moran as his employee. Respondent knew Mr. Moran was not registered or certified to practice contracting. He also knew Mr. Moran was well qualified to perform the work on the Jones' job. Respondent admits that he knew that he should not pull permits for anyone, but that he did it just this one time in order to keep the crew together. On March 15, 1996, Respondent obtained City of DeFuniak Springs, Florida, building permit number 1379 for the roof repairs to Ms. Jones' residence. On the application for said building permit, Respondent represented himself (doing business as Cooper Roofing and Repair) as the contractor of record on the aforesaid project. Respondent intended to and did eventually take legal responsibility for the Jones' job. However, he did not supervise Mr. Moran or his crew. Additionally, Ms. Jones was never informed of Respondent's involvement. More importantly, Ms. Jones never contracted with Respondent for either Respondent or his company to perform roof repairs on her home. On March 21, 1996, Mr. Moran provided an estimate for repair of the portion of Ms. Jones' roof she felt needed repair. The estimate bears the name of "AAA Metal Works" and "Marshall Moran." AAA Metal Works was Mr. Moran's company. The estimate does not reference either Respondent or his company. The estimated cost to repair Ms. Jones roof was $2,785. Based on the estimate, Ms. Jones entered into a contract with Mr. Moran and AAA Metal Works to perform the repairs to her roof discussed above. Moran and his crew substantially completed the repairs to Ms. Jones' roof in a few days. However, the roof continued to leak after Moran and his crew ended their work. The continuing leak was not due to any incompetence on the part of Respondent or Moran. Ms. Jones paid for the repairs with two checks made out to AAA Metal Works. The checks were in the amounts of $3,500 and $4,350. Respondent did not receive any of the money for the Jones' job. His only expense was the fee for the building permit. All other expenses were paid for by Mr. Moran. At no time during the formation or performance of the contract with Marshall Moran did Julia Jones have any contact with or knowledge of involvement by Respondent. In fact, Respondent only drove by the job site one time. As indicated, the roof continued to leak. Ms. Jones contacted Mr. Moran on approximately 5-6 occasions notifying him of the continued leaks. Mr. Moran would return to Ms. Jones' home and inspect the problems, but was unable to stop the leaks to Jones' satisfaction. It is not clear whether Mr. Moran kept Respondent informed of these continued service calls. Approximately one year after completion of the initial repairs on Ms. Jones' roof, Respondent received a call from Ms. Jones' tenant and friend, Sharon Jenks, who called posing as a potential new client. Ms. Jenks had gotten Respondent's name from the building permit. Ms. Jenks called Respondent because the house was still leaking approximately one year after the repair was done and intervening visits by Marshall Moran had not fixed the problem. Ms. Jenks arranged for Respondent to visit Ms. Jones' home. Respondent did not recognize the house when he arrived and drove past it. When Ms. Jenks showed Respondent the building permit bearing his name, Respondent showed surprise. He returned the next day with Mr. Moran. Respondent, Mr. Moran, Ms. Jenks and Ms. Jones all met regarding the continued leaking. Respondent and Mr. Moran told Ms. Jones that the metal on the roof was "bad" and needed to be replaced to stop the leaks on the "sleeping porch." Understandably, Ms. Jones did not want to deal any further with Mr. Moran or Respondent and would not permit them to make the recommended necessary repairs. Ms. Jones sued both Respondent and Mr. Moran in a civil action styled: Julia R. Jones v. James K. Cooper and Marshall Moran, Case Number 97-0040-CC, in the County Court of the First Judicial Circuit in and for Walton County, Florida. Following a judge trial, a Final Judgment was entered in favor of Respondent and Mr. Moran on December 9, 1997. Mr. Moran was charged with contracting without a license in violation of Section 489.127, Florida Statutes (1995), in State of Florida v. Marshall Moran, Case Number 97-0549-CF, in the Circuit Court of the First Judicial Circuit in and for Walton County, Florida. That charge was dismissed by Circuit Judge Lewis Lindsey on February 3, 1998.
Recommendation Based upon the findings of fact and conclusions of law, it is, RECOMMENDED: That the Board should find Respondent guilty of violating Chapters 489 and 455, Florida Statutes, and impose an administrative fine of $500.00 on Respondent DONE AND ENTERED this 3rd day of August, 1998, in Tallahassee, Leon County, Florida. DIANE CLEAVINGER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of August, 1998. COPIES FURNISHED: John O. Williams, Esquire Maureen L. Holz, Esquire Willams and Holz, P.A. 458 West Tennessee Street Tallahassee, Florida 32301 J. LaDon Dewrell, Esquire 207 Florida Place, Southeast Ft. Walton Beach, Florida 32549 Rodney Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
The Issue Whether Respondent committed the violation alleged in the Administrative Complaint? If so, what punitive action should be taken against Respondent?
Findings Of Fact Based upon the evidence adduced at hearing, and the record as a whole, the following findings of fact are made: Respondent is a roofing contractor. He is now, and has been at all times material to the instant case, licensed to engage in the roofing contracting business in the State of Florida. He has held license number CC C049569 since 1989. In the eight years that he has been licensed, he has been disciplined once. On January 28, 1993, Respondent was issued a Uniform Disciplinary Citation alleging that, "on the 8th day of July, 1992, and the 19th day of August, 1992, [he] did violate the following provisions of law: Section 489.129(1)(j), Florida Statutes (1991), by violation of Section 489.119(5)(b), Florida Statutes (1991), by committing the following act(s): failing to include a license number on a contract and failing to include a license number on an advertisement at: 771 S.W. 61st Terrace, Hollywood, Florida 33023." Respondent did not contest these allegations. Instead, he chose to pay a $200.00 fine for having committed the violations alleged in the citation. Respondent is now, and has been since February 21, 1990, the primary qualifying agent for Ray Guy Roofing, Inc., a roofing contracting business owned by Respondent and located in Hollywood, Florida. Respondent's brother, Rodney Guy (Rodney), is also in the roofing business in the South Florida area. At all times material to the instant case, Rodney engaged in such business under the name "Hot Rods Roofing." In addition to having his own business, Rodney also, on occasion, worked for Respondent. In August of 1992, Rodney entered into a written agreement (Contract) with Christopher Klein in which Rodney agreed, for $7,000.00, to replace the damaged roof on Klein's residence in Dade County1 with a new roof with a seven-year warranty (Project). Subsequently, the Contract price was increased $500.00 to $7,500.00 by mutual agreement. Prior to the commencement of work on the Project, Respondent verbally agreed to assume Rodney's obligations under the Contract. Klein paid the Contract price in full, by check, in two installments. Both checks were made out to Hot Rods Roofing (in accordance with the instructions Klein was given) and cashed by Rodney. The second check contained the following handwritten notation made by Klein: "payment in full - roof - includes Ray Guy Roofing, Inc." The Project was completed on or before September 18, 1992. The work was done by Respondent and the employees of Respondent's roofing business, including Rodney. Following the completion of the Project, the roof started to leak. Klein thereafter unsuccessfully attempted to contact Respondent and Rodney by telephone to apprise them of the situation. On or about August 1, 1993, Klein sent a letter to Respondent and Rodney advising them of the leaks in the roof and requesting that they "send someone to fix them." Neither Respondent nor Rodney responded to Klein's letter. Klein therefore hired someone else to fix the leaks. Leaks subsequently redeveloped in the roof. Klein again unsuccessfully attempted to contact Respondent and Rodney by telephone to bring the matter to their attention. On or about March 22, 1994, Klein sent Respondent and Rodney a letter, which read as follows: As you will recall, you acted as partners in the installation of a new roof at my house after Hurricane Andrew. I have developed a leak and I have been attempting to contact both of you for over a month in connection with warranty work related thereto. I am surprised that you have ignored me because, as you will recall, my hiring you resulted in your obtaining at least 3 other jobs on my street. Please contact me within one week to schedule the repair. If I do not receive word from you, I will be forced to hire another roofing company and I will thereafter send you the bill. The bill will be for the roof repairs and to repair interior damage. Neither Respondent nor Rodney responded to Klein's request. Klein made temporary repairs to the roof at his own expense. Klein, who is a member of The Florida Bar, subsequently filed a complaint in Dade County Court (in Dade County Court Case No. 95-7415 CC 02) seeking a judgment for damages, plus interest and costs, against Ray Guy Roofing, Inc., Respondent, and Rodney for breach of contract (Count I), negligence (Count II), and breach of warranty (Count III). Respondent was served with a copy of the complaint on or about May 12, 1995. Shortly thereafter Klein received a telephone call from Respondent, who wanted to speak to Klein about the lawsuit. During their telephone conversation, they agreed to meet at 5:30 p.m. on May 17, 1995, at Klein's residence to discuss the possibility of settling the lawsuit. Respondent did not show up for the meeting, nor did he telephone or otherwise communicate with Klein to explain his absence. Respondent also failed to respond to Klein's complaint.2 On June 30, 1995, pursuant to Klein's written request, a Final Default Judgment was entered against Respondent and Ray Guy Roofing, Inc.,3 in Dade County Court Case No. 95-7415 CC 02. The Final Default Judgment provided as follows: THIS CAUSE came before the Court this date on Plaintiff's Motion for Final Default Judgment against Defendants Raymond Guy, Individually and Ray Guy Roofing, Inc., and the Court having noted that said Defendants were duly served and defaulted herein, and the court being otherwise duly advised in the premises, it is thereupon ORDERED that Plaintiff's Motion is granted and that Plaintiff, Christopher J. Klein, hereby recovers from Defendants, Ray Guy Roofing, Inc., and Raymond Guy, Individually, the principal sum of $5,500.00 plus costs in the sum of $198.00, making a total sum due of $5,698.00, for which sum let execution issue. Klein sent a copy of the Final Default Judgment to Respondent by United States Mail on or about July 21, 1995. The Final Default Judgment was not appealed, and it has not been vacated, set aside, discharged, or satisfied, in whole or in part.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department issue a final order (1) finding Respondent guilty of the violation of Section 489.129(1)(r), Florida Statutes, alleged in the Administrative Complaint, and (2) disciplining Respondent for having committed this violation by requiring him to: (a) pay a fine of $1,000.00; submit proof of satisfaction of the Final Default Judgment entered in Dade County Court Case No. 95-7415 CC 02; and reimburse the Department for all reasonable costs associated with the Department's investigation and prosecution of the charges set forth in the Administrative Complaint. DONE AND ENTERED this 25th day of September, 1997, in Tallahassee, Leon County, Florida. STUART M. LERNER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (904) 488-9675 SUNCOM 278-9675 Fax Filing (904) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 25th day of September, 1997.
The Issue Does the unsatisfied civil judgment in ABC v Millman et al, Case Number 50 2008 CA 006245 XXXX MB relate to practice of Respondent’s profession, thus establishing that Respondent, Harris M. Millman, violated section 489.129(1), Florida Statutes,(2009)? If he committed the violation, what penalty should be imposed?
Findings Of Fact The Construction Industry Licensing Board has certified Millman as a General Contractor and a Roofing Contractor under the authority of Chapter 489, Florida Statutes. In 2009 and 2010, he held license numbers CGC l1522 (General) and CCC 1327057 (Roofing). Millman’s licenses are presently inactive. Millman has actively practiced the licensed professions of general contractor and roofing contractor in Florida since 1977. The Department and its predecessor agencies have never taken any disciplinary action against him. At all times material to this proceeding, Affiliated was a Construction Qualified Business in the State of Florida, certified under Chapter 489, Florida Statutes, holding license number QB45287. Millman was the Primary Qualifying Agent for Affiliated under Chapter 489, Florida Statutes, at all times material to this proceeding. On December 26, 2005, Millman signed a credit application with American Builders and Contractors Supply Company, Inc., d/b/a ABC Supply Co. Inc. (ABC), on behalf of Affiliated. Millman listed his Certified General Contractor’s License (CGC 011522) on the credit application and personal guarantee Although Millman provided his General Contractor’s license number on the application, ABC did not require a license number. The application indicates that the account is related to “low and steep slope roofing.” The account was for the purchase of roofing materials and supplies. On December 29, 2005, Millman signed a personal guarantee of the Affiliated account with ABC. Millman’s personal guarantee made him personally liable for Affiliated’s obligation to pay ABC. ABC granted the application and opened a line of credit for Millman and Affiliated. Millman and Affiliated used the account to purchase roofing supplies on credit. They purchased and paid for over $800,000 worth of supplies from 2006 into 2009. This is separate from the goods and materials that were the subject of the lawsuit described below. Most of the materials and supplies that Affiliated purchased on the ABC account were for specific roofing projects. But some, as Millman acknowledged in his testimony, were to maintain roofing materials in the Affiliated warehouse. He used these on small jobs and to supplement materials purchased for larger, specific jobs. All the goods and materials purchased related to Millman’s practice of the roofing contracting profession. In 2007 Millman and Affiliated started having financial difficulties. Millman’s business began failing. The failure of a lender that took over a construction project it was financing resulted in the lender not paying Millman for approximately $500,000 worth of his company’s work. This contributed to Millman’s business failure. In addition to Millman’s problems paying ABC, his landlord was evicting him. Millman worked hard during these difficulties to meet his obligations to ABC. He liquidated his Individual Retirement Account and his life savings to make sure he paid for all charges for supplies used for specified customers. He did this to protect customers from the risk of liens being placed on their properties. Millman advised ABC that he was being evicted from his warehouse. He told ABC that the warehouse contained materials obtained with his line of credit that had not been paid for. Millman did not have the ability to return the materials to ABC. As eviction neared, he urged ABC to retrieve the materials before eviction. ABC did not act to retrieve the materials. The landlord evicted Millman. What happened to the materials is not known. On March 4, 2008, ABC sued Millman and Affiliated in the Circuit Court of the Fifteenth Judicial Circuit in and for Palm Beach County, Florida. ABC sought payment for goods and materials purchased on the account and delivered to Millman and Affiliated between January 31, 2007, and January 31, 2008. The court assigned the action Case Number 50 2008 CA 006245 XXXX MB. The goods and materials for which ABC sought payment were roofing goods and materials. They included roofing felt, roofing cement, shingles, plywood, lumber, roofing nails, lead sheets, insulation, roof tile cement, lead boots for pipes, roofing paint, asphalt, and galvanized roof edging. Much, although not all, of the material was delivered to roof tops. Many invoices for the material describe the roof for which the material is intended by height and pitch. The goods and materials related to Millman’s profession of roofing contractor. On June 17, 2008, barely three months after ABC filed suit, Millman entered into a Stipulation for Payment with Judgment upon Default with ABC. Millman agreed in the Stipulation for Payment with Judgment upon Default, that both he as an individual and Affiliated are indebted to ABC in the amount of $45,617.02. This amount included interest, attorney’s fees, and costs. The stipulation included a schedule of eight payments starting with a payment of $2,500.00 on May 30, 2008, and ending with a payment of $22,720.02 on December 30, 2008. Millman made payments from January 1, 2007, forward, even during and after the collection litigation. Millman made over $16,000.00 of those payments. But he did not make all of them. As Millman made payments, he took care to designate payments for supplies allocated to a specific customer and job. He did this to protect his customers from liens and to make sure that documents he signed attesting that supplies for specific jobs had been paid for were honest and correct. On August 3, 2009, the court rendered a Final Judgment After Stipulation in ABC’s collection action. The court adjudged that ABC recover $29,617.02 together with interest at the rate of 11 percent per annum accruing from May 31, 2008, from Affiliated and Millman, jointly and severally. The judgment is for debt incurred relating to Millman’s practice of his licensed profession of roofing contracting. It is not related to Millman’s licensed profession of general contracting. ABC continued to actively pursue collecting the judgment. It garnished Millman’s bank account with Bank Atlantic and obtained $662.61. Millman and Affiliated have not fully satisfied the judgment within a reasonable period of time. The Department incurred $216.00 in costs for the investigation and this action.
Recommendation Based on the foregoing Findings of Fact and Conclusion of Law, it is recommended that the Department of Business and Professional Regulation, Construction Industry Licensing Board, enter a final order finding that Respondent, Harris M. Millman, violated Section 489.129(1)(q), Florida Statutes, and imposing the following penalties: Payment of an administrative fine of $500.00 within 180 days of entry of the final order. Payment of costs of investigation and prosecution in the amount of $216.00 within 180 days of entry of the final order. DONE AND ENTERED this 27th day of August, 2010, in Tallahassee, Leon County, Florida. S JOHN D. C. NEWTON, II Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 27th day of August, 2010.
Findings Of Fact At all times pertinent to the issues herein, Graciela Zara was a registered roofing contractor in the State of Florida having license number RC 0035417. Respondent qualified Rolando Lopez Roofing Corp. at all times material to the complaint. Roofing work was done on the building located at 8413 8415 Hardin Avenue; however, the roofing work was not done by Rolando Lopez Roofing, but rather by Chungo, an employee of M. G. Construction Company, the owner of the building. Certain materials for the roofing work were delivered to 8413-8415 Harding Avenue by Tops All Roofing & Building Products, Inc., and those materials were ordered by Rolando Lopez and/or Renee Garcia. Rolando Lopez Roofing performed roofing work at the the bank at Las Americas Shopping Plaza, 8500 N.W. 85th Street; however, there was no evidence presented that Rolando Lopez Roofing failed to obtain a permit for the work it performed. Tropical Roofing entered into a contract for roofing work at the home of Mr. Sosa, 3001 S.W. 96th Avenue, Miami, Florida. 2/ The work was subcontracted to and done by Rolando Lopez Roofing. Although a permit for the work was required, respondent failed to obtain a permit. The respondent was responsible for obtaining the permit because the contractor that performs the work is responsible for obtaining the permit. Leon Gomez entered into a contract with Rene Garcia for roofing work at 309 Pinecrest Drive. Rene Garcia performed the roofing work on the house and was paid for the work by Mr. Gomez. However, the permit for the roofing work was obtained by the respondent. Roofing work was performed at the home of Felipe Acosta, 401 Flagami Boulevard, Miami, Florida. The permit for the roofing work was obtained by respondent. The contract for the work was with Rolando Lopez Roofing. The roofing work was performed by Rene Garcia and other workers that Mr. Acosta did not know. Mr. Acosta does not know Rulando Lopez. The contract negotiations and the payment for the job were handled by Mr. Acosta's brother. Mr. Acosta did not know whether Rene Garcia or Rolando Lopez received payment for she roofing work, but he knows his brother paid one of them. The roofing work was performed pursuant to the contract with Rolando Lopez Roofing. On June 1, 1983, Rolando Lopez Roofing Corp. issued a check for $11,667.86 to Tops All Roofing & Building Products. The check was returned by the bank stamped "Account Closed." On September 16, 1983, Rolando Lopez was adjudicated guilty of issuing a worthless check in violation of Section 832.05. Mr. Lopez paid $5,000 in restitution to Tops All Roofing & Building Products, but he was unable to pay the remaining amount because he has been unable to get any work. There was no evidence that Rolando Lopez Roofing Corp. failed to pay creditors for materials furnished. Although Rolando Lopez failed to make full restitution to Tops All Roofing and Building Products for the $11,667.86 check that was returned, there was no evidence that the check was for building supplies furnished to Rolando Lopez Roofing. Rolando Lopez testified that the check was written for the benefit of his nephew, Rene Garcia, to be used as collateral. Further, there was no evidence that Tops All Roofing & Building Products had furnished any building materials to Rolando Lopez Roofing prior to June 1, 1983, the date of the check. There was no evidence presented that Rene Garcia was not licensed by the State of Florida as a registered or certified roofing contractor
Recommendation Based on the foregoing Findings of Facts and Conclusions of Law, it is RECOMMENDED that the Respondent be placed on probation for a period of six months. DONE and ORDERED this 2nd day of January, 1985, in Tallahassee, Leon County, Florida. DIANE GRUBBS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of January, 1985.
The Issue Whether Respondent committed the offenses set forth in the administrative complaint and, if so, the penalty which should be imposed.
Findings Of Fact At all times material to this case, the Respondent, Harry Bradshaw, was licensed as a registered roofing contractor in the State of Florida, holding license number RC 0033812. On August 26, 1986, Respondent's license as a registered roofing contractor was suspended by Petitioner. Respondent's license remained suspended at all times material to this case. On December 16, 1987, Respondent contracted with the Moose Lodge located in Hialeah, Florida, to reroof the Moose Lodge building. The proposal submitted by Respondent contained representations that Respondent was licensed as a registered roofing contractor and that he was insured. Respondent knew that his license as a registered roofing contractor was under suspension. Respondent had no insurance. The contract between Respondent and the Moose Lodge provided that Respondent would perform the work and supply the materials for the sum of $6,200.00. The sum of $3,200.00 was paid to Respondent in advance of his beginning the job. Respondent used the sums advanced to purchase materials and supplies. The remaining $3,000.00 was to have been paid upon Respondent's completion of the job. During the negotiations that resulted in the contract between Respondent and the Moose Lodge, Respondent represented that the job should be completed in time for the functions scheduled for New Year's Eve. While Respondent had purchased the materials needed for the job and had done a substantial amount of work on a portion of the roof, he was unable to complete the work by the New Year. Respondent was ordered to stop work on the job on January 26, 1988. Respondent did not abandon the job. Although he was slow in performing the work, a part of Respondent's delay in performance was caused by rain. There was no evidence as to what would have been a reasonable period of time for Respondent to have completed the job. On January 26, 1988, the administrator for the Moose Lodge complained to the Building Inspection Department for the City of Hialeah, Florida, because the administrator was not pleased with the progress that Respondent was making toward completion of the job. The administrator was told by a representative of the Building Inspection Department on January 26, 1988, that Respondent had no license and that the required permit had not been pulled. The administrator was told to prohibit Respondent from working on the roof. Immediately thereafter, the administrator instructed Respondent to do no further work on the roof. The members of the Noose Lodge completed the job started by Respondent for less than $3,000.00, the balance of the amount that would have been owed Respondent if he had finished the job. Respondent knew that a permit was required for this work. Respondent also knew that only a licensed roofing contractor could pull the required permit. Respondent proceeded with the job when he was unable to persuade a licensed roofing contractor to pull the permit for him. Petitioner filed an administrative complaint against Respondent alleging that at the time he contracted with the Moose Lodge, Respondent's license was suspended, thus violating the provisions of Section 489.129(1)(j), Florida Statutes, and the provisions of Section 489.127(1)(e), Florida Statutes. The administrative complaint also alleged that Respondent failed to perform in a reasonably timely manner and/or abandoned the job in violation of Section 489.129(1)(m), Florida Statutes, and Section 489.129(1)(k), Florida Statutes. Respondent denied the allegations of the administrative complaint and timely requested a formal hearing. This proceeding followed. Respondent was previously disciplined by the Construction Industry Licensing Board, and his license remained under suspension at the time of the final hearing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated Section 489.127(1)(e), Florida Statutes, and Section 489.129(1)(j), Florida Statutes. It is further recommended that the final order revoke Harry Bradshaw's license in the State of Florida as a registered roofing contractor. DONE and ENTERED this 31st day of October, 1989, in Tallahassee, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 1989. COPIES FURNISHED: Harry Bradshaw 5590 East Seventh Avenue Hialeah, Florida 33013 David M. Gaspari, Esquire Adams, Coogler, Watson & Merkel, P.A Suite 1600 NCNB Tower 1555 Palm Beach Lakes Boulevard West Palm Beach, Florida 33402-2069 Kenneth E. Easley, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
The Issue The issue for determination is whether Respondent committed the offenses set forth in the Administrative Complaints and, if so, what penalty should be imposed.
Findings Of Fact It is undisputed that at all times material hereto, Respondent was licensed by the State of Florida as a Certified General Contractor, having been issued license number CG C58099. Respondent passed the licensing examination in August 1995. Case No. 99-0261 Respondent is not a licensed roofing contractor. Respondent's Certified General Contractor's license did not and does not permit him to obtain roofing permits to perform any type of work on roofs. Respondent's Certified General Contractor's license number was not low enough for him to be grandfathered in by the State to allow him to lawfully perform roofing work with his Certified General Contractor's license. On or about February 23, 1998, Delfina Valdes contracted with Johnny Hatcher, d/b/a Hatcher's Roofing, to repair the roof on her residence located at 18101 Northwest 32 Avenue, Miami, Florida. They contracted for Hatcher to remove Valdes' old roof and install a new roof at a cost of $4,000. Valdes paid Hatcher $2,000 as a down payment toward the cost of the roof's repair. At no time material hereto was Hatcher a licensed roofing contractor. Furthermore, at no time material hereto was Hatcher's Roofing qualified by the State of Florida to perform contracting. Hatcher removed the roof from Valdes' residence. After removing the roof, he did not perform any more work. Respondent met with Valdes and represented to her that Hatcher was working for him. Respondent further represented that he would obtain the permit for the roofing work. Respondent paid Cayetano Alfonso to obtain a roofing permit for the work on Valdes' roof. On or about March 26, 1998, Alfonso made application to Metropolitan Dade County, Department of Planning, Development and Regulation for the roofing permit, which was subsequently issued. Alfonso was a Certified General Contractor who was licensed to perform roofing work. Alfonso's Certified General Contractor's license number was low enough for him to be grandfathered in by the State to allow him to lawfully perform roofing work with his Certified General Contractor's license. Alfonso was not the qualifier for Hatcher's Roofing nor was he Respondent's qualifier. Alfonso did not enter into the contract with Valdes for repairing her roof. Alfonso was not a party to the contract for repairing Valdes' roof. An inference is drawn and a finding of fact is made that Hatcher was not acting on behalf of Alfonso when he entered into the contract with Valdes. An inference is drawn and a finding of fact is made that Respondent was not acting on behalf of Alfonso when he represented to Valdes that he would obtain the permit for the roofing work. When Respondent discovered that Hatcher had received a $2,000 deposit from Valdes, he requested Alfonso to cancel the permit. On or about April 20, 1998, Alfonso cancelled the roofing permit. On or about June 5, 1998, Valdes cancelled the contract between her and Hatcher Roofing. Valdes received a refund of the $2,000 from Hatcher, through a third party, that she had paid him. Case No. 98-4859 On or about April 9, 1995, Respondent entered into a contract with Susan Casper to construct an addition to her residence located at 17350 Northeast 12th Court, North Miami Beach, Florida, at a cost of $38,135. Casper paid Respondent $36,285.00 toward the cost of the addition. Respondent was not licensed at the time that he entered into the contract. On or about March 20, 1996, Respondent obtained a permit from the Metropolitan Dade County, Department of Planning, Development and Regulation for the work on the addition. Several delays were encountered during the performance of the work. Some of the delays resulted from changes by Casper, which changes required approval by Metropolitan Dade County, Department of Planning, Development and Regulation; however, most of the delays were Respondent's own doing. In October 1996, Casper paid $2,588 to Best Truss Company for a claim of lien filed on her residence, associated with the work being performed on her residence. Respondent worked sporadically on Casper's addition through April 1997. He would inform her at times that he was returning but failed to return. At one point, Casper's children constructed a sign in their own handwriting, instructing Respondent to keep out and indicating that there was no trespassing by him. The sign was posted on the door of Casper's residence. Casper informed Respondent that her children constructed the sign. It was obvious that the keep out, no trespassing sign was constructed by children. Respondent's assertion that he was kept away from Casper's residence by the children's sign is not credible. Even after the children's sign was posted on the front door of Casper's residence, Respondent agreed with Casper to resume work, and he did so. However, his work was sporadic. In or around June 1997, Casper sought assistance from the Metropolitan Dade County, Department of Planning, Development and Regulation to get Respondent to complete the work. In July 1997, Respondent obtained a window permit for the work on Casper's residence. After July 1997, Respondent ceased working on Casper's residence. He did not provide Casper with any notice that he was ceasing work. Respondent had no valid reason for ceasing the work. In September 1997, Casper transferred the permit for the work on her residence from Respondent's name to her name. Respondent failed to perform all the work under the contract. Some of the work performed by Respondent or caused to be performed by Respondent contained code violations and needed correcting. Certain work performed by Respondent or caused to be performed by Respondent needed correcting. Wood doors, glass block, electrical work, and a sprinkler were in need of correction. Casper bore the expense of the corrections. The corrective work was completed at a cost of $1,675.00. The value of the work performed by Respondent on Casper's residence was $18,272, minus the cost of the corrective work of $1,675, which equals a total value of the work at $16,597. This cost value includes overhead and profit. Even though the value of the work by Respondent was $16,597, Casper paid Respondent $36,285, a difference of $19,688. Casper hired a new contractor on or about September 17, 1997, to complete the construction on her residence at a cost of $16,350. As to Case No. 98-4859, as of January 26, 1999, Petitioner incurred a cost of $1,108.76 for the investigation and prosecution of Respondent. Petitioner previously disciplined Respondent for violating Chapter 489, Florida Statutes (1995), including violating Subsection 489.127(1)(k), Florida Statutes (1995), abandonment of a construction project.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order and therein: As to Case No. 99-0261, finding that Respondent violated Subsection 489.129(1)(e), Florida Statutes (1997). As to Case No. 98-4859, finding that Respondent violated Subsection 489.129(1)(k), Florida Statutes (1997), in Count I; and dismissing Count II. Revoking Respondent's license. Ordering Respondent to pay restitution to Susan Casper in the amount of $19,688.00. DONE AND ENTERED this 31st day of October, 2000, in Tallahassee, Leon County, Florida. ERROL H. POWELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 2000. COPIES FURNISHED: Diane Snell Perera, Esquire Department of Business and Professional Regulation 401 Northwest 2nd Avenue, Suite N607 Miami, Florida 33128 Richard F. Hayes, Esquire 10300 Sunset Drive, No. 499 Miami, Florida 33173 Rodney L. Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Barbara D. Auger, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
