Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, I hereby make the following Findings of Fact: At all times relevant hereto, the Respondent, Rex Alaniz, held a registered roofing contractors license, Number RC 0042021, issued by the State of Florida, Construction Industry Licensing Board (hereinafter "the Board"). The Respondent's registered address with the Board was initially 1813 Ocean Drive, Jacksonville, Florida, then changed to 23 Seatrout, Ponte Vedra Beach, Florida. The Respondent's license reflected that he was doing business as "Rex Alaniz Roofing and Remodeling Company." During June 1984, the Respondent was doing business as Alaniz & Sons Roofing Company," a name unregistered and unqualified with the Board. Ms. Audrey Kelly met the Respondent through an as placed in the "Westside Shopper," and advertising newspaper in Jacksonville. The ad stated in part as follows: "Raindrops falling on your head? . . . labor guaranteed . . . State Licensed. . . Alaniz & Sons Roofing Company. Rex Alaniz 246-0265 if you have a leak and cannot sleep, check the rest and then get the best for less. . ." Ms. Kelly called the number listed in the advertisement and met with Buddy Clark on June 5, 1984. Mr. Clark stated that he represented Alaniz & Sons Roofing Company. After Mr. Clark looked at Ms. Kelly's roof, Ms. Kelly signed a contract for the repairs to be completed. The contract provided in part that Alaniz and Sons Roofing Company would repair and seal all exposed areas in the roof and that a one year guarantee on workmanship was included. The total contract price was $735. Ms. Kelly paid Clark $200 as an initial payment on the contract. On June 7, 1984, Respondent went to Ms. Kelly's home to repair the roof. After working approximately two and one-half hours, Respondent told Ms. Kelly that he had repaired the roof. Kelly then paid Respondent the balance of $535 which remained on the contract. On June 19, 1984, a light rain fell on Jacksonville and Ms. Kelly's roof leaked again. Ms. Kelly contacted Respondent and Respondent told her that she should wait until it rained harder so that any additional leaks could be repaired at one time. About three weeks later, a heavy rain fell and the roof leaked a lot. After the heavy rain, the Respondent went out and looked at the roof but did not perform any work on it. Respondent told Kelly that the problem was wind damage and suggested that Kelly contact her insurance company. An inspection by Ms. Kelly's insurance company revealed no wind damage to the roof. Therefore, Kelly repeatedly called Respondent, reaching his answering service, but Respondent did not return her calls. The roof continued to leak until Kelly hired another roofer who replaced the entire roof. Ms. Kelly complained to the State Attorney's office about Respondent's failure to honor the warranty on the contract. In April 1984, Mr. Otis McCray, Jr. discovered three leaks in the roof of his home and called Rex Alaniz. The Respondent went out and looked at the roof and informed Mr. McCray that he could fix it. On April 28, 1984, Mr. McCray entered into a contract with Respondent to repair the three leaks in the roof for a price of $500. A one year guarantee was included in the contract. Approximately one week after the contract was signed, Respondent told McCray that the roof had been repaired. McCray then paid Respondent the full contract price of $500. After a rainfall which occurred during the week following the completion of the repair work, McCray noticed that all three of the areas were leaking again. Thereafter, McCray called the Respondent's office approximately 5 or 6 times, leaving messages with either the receptionist or Respondent's answering service concerning the leaks. McCray also had his wife telephone the Respondent, thinking that perhaps the Respondent would respond to "a woman's voice." The Respondent failed to return any of McCray's calls and failed to return to fix the roof. Mr. McCray ultimately hired someone else to put a new roof on his home. In February 1986, the Respondent entered a negotiated plea to the offense of schemes to defraud in the Circuit Court of Duval County, Florida. The failure to properly perform the repairs and honor the promised warranties in the Kelly and McCray projects were included as a part of the offenses charged. The Respondent was ordered to pay restitution to Ms. Kelly and Mr. McCray. As of the date of the hearing, the Respondent had not made restitution to either Mr. McCray or Ms. Kelly. Douglas Vanderbilt, an investigator for the Department of Professional Regulation, attempted to serve papers upon the Respondent in November of 1985. During such attempt to serve the Respondent, Mr. Vanderbilt discovered that Respondent was no longer living at 23 Seatrout Street in Ponte Vedra Beach and had moved from that address approximately two years prior to November of 1985. At no time material hereto, did Respondent report to the Board a change of address from 23 Seatrout Street, Ponte Vedra Beach. The Respondent has been disciplined by the Board for misconduct twice in the recent past. On November 15, 1984 final action was taken by the Board to suspend Respondent's license for one year, effective January 2, 1985. On November 7, 1985, final action was taken by the Board to suspend Respondent's license for ninety days, consecutive to the one year suspension effective January 2, 1985.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law it is, therefore, RECOMMENDED THAT a final order be issued requiring Respondent to pay an administrative fine of $1,000 and suspending Respondent's license for a period of five (5) years from the date of the Final Order in this case. Provided, however, that said suspension will be terminated early without further action by the Board, at any time that Respondent shall both pay said fine and provide written proof satisfactory to the Board's Executive Director of having paid restitution of $500 to Otis C. McCray, Jr. and $735.00 to Audrey L. Kelly. DONE and ORDERED this 6th day of August, 1986 in Tallahassee, Leon County, Florida. W. MATTHEW STEVENSON, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 6th day August, 1986. COPIES FURNISHED: Lagran Saunders, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Rex Alaniz 1612-5th Street, South Jacksonville, Florida 32250 Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation P. O. Box 2 Jacksonville, Florida 32201 Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Salvatore A. Carpino, Esquire General Counsel 130 North Monroe Street Tallahassee, Florida 321301 APPENDIX The following constitutes my specific rulings pursuant to Section 120.59(2), Florida Statutes, on all of the Proposed Findings of Fact submitted by the parties to this case. Rulings on Proposed Findings of Fact Submitted by the Petitioner Adopted in Finding of Fact 1. Adopted in Finding of Fact 3. Adopted in Findings of Fact 9 and 10. Adopted in Finding of Fact 10. Adopted in Finding of Fact 11. Adopted in Finding of Fact 11. Adopted in Finding of Fact 11. Adopted in Finding of Fact 12. Adopted in Finding of Fact 12. 10. Adopted in Finding of Fact 12. 11. Adopted in Finding of Fact 5. 12. Adopted in Finding of Fact 5. 13. Adopted in Finding of Fact 5. 14. Adopted in Finding of Fact 6. 15. Adopted in Finding of Fact 6. 16. Adopted in Finding of Fact 6. 17. Adopted in Finding of Fact 7. 18. Adopted in Finding of Fact 7. 19. Adopted in Finding of Fact 7. 20. Adopted in Finding of Fact 7. 21. Adopted in Finding of Fact 8. 22. Adopted in Finding of Fact 8. 23. Adopted in Finding of Fact 8. 24. Adopted in Finding of Fact 8. 25. Adopted in Finding of Fact 8. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Rulings on Proposed Findings of Fact Submitted by the Respondent (None submitted) ================================================================ =
The Issue The issue for consideration was whether Respondent's license as a registered roofing contractor should be disciplined because of the misconduct alleged in the Administrative Complaint filed herein.
Findings Of Fact At all times pertinent to the issues contained herein, Respondent, Bruce D. Gayton, was licensed as a roofing contractor in Florida under license number RC0030867, but at the time of the misconduct alleged herein, the license was delinquent and invalid. Respondent's license was placed on delinquent status for non-renewal when it expired on June 30, 1987 and was considered invalid until reinstated in April, 1988. The Petitioner, Construction Industry Licensing Board, (Board), is the state agency responsible for the licensing of contractors in this state. On August 27, 1987, John M. Mack and his wife contracted with Respondent, doing business as Roofing Enterprises, to replace the roof on their 70 year old house in Clearwater. The contract called for Respondent to remove the old roof, replace all rotten wood, and install fiberglass shingles as well as all other actions part thereof, including cleanup. For this, the Macks agreed to pay Respondent $2,930.00 to be paid one- third at commencement, one-third when dried in, and the balance due upon completion. The term "dried in" means to cover the roof base with felt and secure it so as to prevent moisture incursion. This constitutes the subsurface for the final roof surface. The contract did not provide a completion date. Respondent guaranteed his work for five years. Respondent started work on September 9, 1989 and was paid the first $1,000.00 by check. He started tearing off the existing roof and five days later, when only one quarter of the existing roof had been removed, requested the second installment of the contract price. Mr. Mack was out of town at the time, but Mrs. Mack gave him a second $1,000.00 check. At that time, far less than one third of the project had been completed. After that second payment was made, Respondent did "minimal work" on the project. He would appear at the job only intermittently and when he did, would leave after only a short while. When Mr. Mack asked about this, Respondent indicated it was too hot to work after 11:00 in the morning. He also complained that because the sub-roof was made of hard, old white pine, it was very difficult to remove the old nails. For several days in early November, 1987, Respondent did not show up for work and Mack's efforts to reach him by phone were unsuccessful. He finally filed a complaint with both the Better Business Bureau and the Department of Professional Regulation. Finally, on November 14, 1987, Respondent came to the work site and left after two hours indicating he had a meeting with other contractors on other jobs. The next day, when Respondent did not show up, Mr. Mack went to his house whereupon Respondent stated he had spent most of the $2,000.00 the Macks had given him on other projects and to pay his workers and did not have enough funds to finish the job. Mr. Archer, the only employee to work on the Mack property has not been paid at all for his work. Nonetheless, Mr. Mack instructed Respondent to do what he could with what was left and when that was gone, he would pay the balance. Though Respondent had previously indicated to Mr. Mack that he had secured all required permits, the day after the above discussion, he stated he had not done so and left the job site to get it without doing any work that day. Over the next 11 days, Respondent spent a total of 20 hours on the job. On November 17, 1987 it rained and because the roof was not secure, water leaked into the house. The following day, Respondent did not arrive for work until 10:00 AM. On November 19, 1987, when Mr. Mack called the lumber yard from which Respondent had ordered the shingles, he was told they were scheduled for delivery COD and were on their way. When they arrived, Mr. Mack refused to accept them and pay for them because he had already paid Respondent $2,000. Respondent, when told of this development, agreed to borrow the money for them from his brother but was unable to do so, and in order to get the job finally done, Mr. Mack agreed to pay approximately $200.00 for them. They were ultimately delivered. The next day, Respondent telephoned Mr. Mack and said he was coming to the site and would stay until the job was done. However, he did not get there until after 10 and left at 3:30 PM with the job incomplete. At 8:00 AM the following morning, Respondent again called Mr. Mack and reported he did not have enough money for the required flashings. He indicated he would come to work and finish up the shingling, but did not show up at all that day. On the day after, Respondent came with his wife who worked with him for a short while. On this occasion, Mack gave Respondent some more money for supplies, but Respondent left again before the job was complete. Respondent neither showed up for work nor called on both the next two days, but on the following day, November 25, 1987, he finally finished up the job except for the gravel roof on the rear house and the front part of the main house. Because the Macks had a tenant in the rear house who they did not want disturbed, they did not permit Respondent to work there, but he did finally finish up the front of the main house roof and the work that was accomplished was done satisfactorily. There was, however, an unused chimney on the main house which Respondent should have removed and roofed over. Instead, he improperly attempted to roof around it and since he was unable to make the area water tight, it resulted in severe leakage into the house which caused damage to several ceilings and some furniture. Throughout the entire course of the work, Respondent applied improper pressure to the Macks. He repeatedly threatened to file for bankruptcy and not complete the work, prompting the Macks to pay him before contractually called for. At the time for final payment, when Mr. Mack indicated he wanted to have the job checked before making that last payment, Respondent became angry and walked off. He has not been seen or heard from since. As a result of Respondent's failure to properly manage his funds and accomplish the job in a timely and professional manner, the Macks have sustained substantial damage to their property and have had to expend additional funds to get the work done properly. Respondent should have identified the unused chimney at the time he bid for the job and provided for its removal. If this would cost more, he should have so indicated. His failure to identify the problem and correct it constitutes negligence since it is impossible to properly roof around such an obstruction without leaks. Based on the information available to him, Mr. Verse, the Department's expert, concluded Respondent was guilty of gross negligence because: He was required to get a permit for this project and failed to do so, He was required to request inspections of the project as it progressed and failed to do so, He took an unreasonable amount of time to complete the job, (roofs are usually replaced in an expedient manner because re-roofing generates exposure of the house and contents to weather conditions), He failed to properly place the felt and thereafter cover it with the final coat in a timely manner (qualified roofers recognize that felt is insufficient roofing to prevent leaking), He diverted funds from this project to others for which they were not intended, He failed to properly supervise his employees, He did not complete the work called for under the contract, He failed to honor his warranty, and He failed to properly remove the old chimney as a part of the re-roofing process. With the exception of the failure to complete the job which was caused by Mr. Mack's refusal to allow Respondent to complete the roofing project on the gravel roof, Respondent's actions as outlined herein constituted gross negligence. In addition, he violated existing local law by failing to get a permit and have the required inspections made; he failed to perform in a timely manner; he diverted funds; he abandoned the job without it being completed; and he failed to honor his warranty.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is, therefore: RECOMMENDED that Respondent, Bruce D. Gayton's, license as a registered roofing contractor be suspended for three years under such provisions for reinstatement as may be deemed appropriate by the Board, and that he be fined $1,000.00. RECOMMENDED this 11th day of August, 1989 at Tallahassee, Florida. ARNOLD H. POLLOCK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of August, 1989. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792 Bruce D. Gayton 15010 113th Avenue #32 Largo, Florida 34644-4305 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Kenneth A. Easley, Esquire General Counsel DPR 1940 North Monroe Street Tallahassee, Florida 32399-0792 =================================================================
Findings Of Fact At all times material hereto, Respondent has been a registered roofing contractor in Miami, Florida, having been issued license no. RC 0047352. Respondent is the qualifying agent for All Central Roofing, Inc. In May 1986 All Central Roofing, Inc., entered into a contract with Richard Crisonino to perform certain roofing work on Crisonino's residence in Miami, Florida. The contract price was $3,374. All Central Roofing, Inc., thereafter began the roofing work on Crisonino's residence without obtaining a permit for that work from the local building department and without posting a permit on the job site. All Central Roofing, Inc., failed to obtain the required inspections by the local building department. After completing part of the work involved and after receiving substantial payment under the contract, All Central Roofing Company, Inc., ceased work on the Crisonino residence and failed or refused to complete the work, thereby abandoning the job. By her own admissions at the final hearing in this cause, Respondent does not possess a working knowledge of roofing or roofing contracting. She lacks even a basic fundamental understanding of roofing construction to the extent that it is impossible that she is fulfilling any of her responsibilities as a qualifying agent for All Central Roofing, Inc. Further, Respondent does not even know the number of employees working for All Central Roofing, Inc. Respondent has been disciplined by the Dade County Construction Trades Qualifying Board, and Respondent's personal and business certificates have been revoked by that Board.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is, RECOMMENDED that a Final Order be entered finding Respondent guilty of the allegations contained in the Administrative Complaint filed against her and revoking Respondent's registered roofing contractor license. DONE and RECOMMENDED this 14th day of December, 1987, at Tallahassee, Florida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of December, 1987. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 G. Vincent Soto, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Harry E. Geissinger, Esquire 415 West 51st Place, Suite 201 Hialeah, Florida 33012 Tom Gallagher, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue Whether respondent's license should be revoked, suspended or restricted, or whether an administrative fine should be levied against him, or whether he should be reprimanded for the reasons alleged in the administrative complaint?
Findings Of Fact James M. McCurley is a registered roofing contractor, holding Florida License No. RC 0042226. Licensed in Florida since 1982, Mr. McCurley has been in the roofing business for 25 years all told. Although he holds a state license, he is registered to do roof projects in Broward County only, 82-3201-R-R. Thomas v. Shoop, a real estate broker, manages the Mayani Biscayne Condominiums in Miami at 5995 Biscayne Boulevard, (Mayan) and the Camelot South Apartments on 17th Street in Fort Lauderdale (Camelot), which consist of three buildings (A, B and C). Above Camelot B's roof, which "is not properly set up for drainage at all," (T. 183), loomed a leaking water tower, which has only recently been fixed. In the summer of 1983, all four buildings' roofs leaked; and the roofer who had given long-term guarantees on Camelot's roofs had gone bankrupt. An associate of Mr. Shoop knew one John Emig, who was a salesman for Mr. McCurley. Messrs. Shoop and Emig visited the roofs and discussed the problems. In order to "mak[e] sure that they got a reputable roofer. . . [Mr. Shoop] did great deal of research with a list . . . [of] people that [Mr. McCurley] had done work for and were satisfied." (T. 16). Through Mr. Emig, Mr. McCurley offered to replace the 8,000-square-foot roof on Camelot B for $25,000. Further conversations eventuated instead in an agreement, reduced to a separate writing with respect to each Camelot building, Petitioner's Exhibit No. 2, that called for Mr. McCurley to repair, clean and paint the root and soffits of the three Camelot buildings. The contract for Camelot A characterized the work both as restoration and as preventive maintenance. Repairs were to be effected "as needed." The contracts recited the roofing contractor's "opinion [that] the following maintenance work should put this roof and mansard in the best possible condition, and that it reasonably can be expected to have up to a five year service life." Petitioner's Exhibit No. 2. The agreements specified installation of a total of 35 vapor pressure release vents and stated that Mr. McCurley was to: Check and reseal where needed all pitch pockets, using 10-year rubberized elastomers. . . . Remove all blistering coating from the roof decks and at all such spots install a repair patch. Repair any bulges or blisters and treat all cracks as needed using elastomeric and waterproofing membrane. Petitioner's Exhibit No. 2 The contracts were typed on printed forms. When Mr. Emig and Mr. Shoop signed the roofing contracts on August 24, 1983, Mr. McCurley was not present. At the time the agreements were signed, "3 was substituted for "1" in the phrase, "The above work . . . carries with it our 1 year Pree Service Guarantee should any leak occur . . ." Petitioner's Exhibit No. 2. Unchanged was a typewritten paragraph on each contract stating: In this particular situation our warranty shall be a one year unconditional one, which is standard procedure in the industry. Petitioner's Exhibit No. 2. Although Mr. Shoop dealt primarily with Mr. Emig in negotiating the contract, Mr. Shoop and Mr. McCurley went up on a roof together at one point before the contracts were signed. On September 20, 1983, an addendum to the contracts, calling for work on the buildings other than roofing, was executed. The contract price for the roofing work was less than 40 cents per square foot. The roofs in the Camelot complex were built-up tar and gravel, coated with a cementitious fill. Ordinarily insulation lies underneath a built-up roof of this kind. The vapor pressure release vents were proposed and contracted for on the assumption that insulation underlay the tar, insulation which permitted lateral movement of water and water vapor trapped by the tar and cementitious fill. Pressure attendant on vaporization of water trapped underneath the tar and fill is the apparent cause of the cracking and blistering that led to the leaks. In installing the first vapor pressure release vent, Mr. McCurley discovered that the tar had been placed directly on the roof sheathing. He explained to Mr. Shoop that there was no good reason to go forward with installation of the other vents because the impermeability of tar and fill precluded lateral movement of moisture and, therefore, its escape in any significant quantity through the vents. Mr. Shoop insisted, however, that all the vents called for by the contract go in, and Mr. McCurley complied. The vents stood useless (T. 99) but firmly affixed to the roof as recently as five or six months before the hearing. (T. 94) Thereafter, many were dislodged by the contraction and expansion of the roof, aggravating the leakage problems. To meet the contract requirement of an "elastomeric and waterproofing membrane," Mr. McCurley employed a coating he had never used before, but one which was advertised by a company listed on the New York Stock Exchange, Rohm & Haas, as capable of withstanding ponding water. At the time he entered into the contract, Mr. McCurley did not know that this claim was false. In the fall of 1983, he applied this coating not only to places where cementitious fill had bulged, blistered, or cracked, but also to unblemished portions of the Camelot roofs, covering them entirely twice, before applying a final coat of high gloss white paint. Before he was paid, Mr. McCurley had done everything called for by the contract. On May 30, 1984, however, Mr. Shoop told Mr. Emig that old leaks had reappeared and that new leaks had sprung open. Mr. Shoop also telephoned and left word for Mr. McCurley to this effect on June 15, 18, and 19. On July 5, 1984, Mr. Shoop wrote Mr. McCurley a letter, Petitioner's Exhibit No. 4, in response to which Mr. McCurley applied another acrylic waterproofing compound and plastic cement. When he finished, "it looked from a laym[a]n's point of view that it was a good job." (T. 31). In November of 1984, the B building roof still looked good but it leaked. In response to complaints, Mr. McCurley returned several times to repair blistered areas with acrylic waterproofing and to apply plastic cement. Typically these repairs prevented leaks the next hard rain but not the one following. Camelot B needs reroofing, which involves taking out the existing roof and building up a new one with tar and gravel, the approach Mr. McCurley originally recommended.) Mr. Hilson, who has spent approximately 30 years in the roofing business, testified that the coatings that Mr. McCurley used were permeable, and inappropriate for use on horizontal surfaces on that account. Specifically, after inspecting Camelot B's roof, Mr. Hilson testified: It has continued to leak from what we was shown and told. I made a note here that it takes a zero perm rating to hold back water, and these coatings apparently have no such perm rating. These coating[s] are breathable. And because they are breathable they allow water to go through them and become trapped, underneath the cementious fill. The only type of coating that we know of that these type of coatings were normally used on vertical surfaces where water can't stand on them, showing these photographs here the water where it does pond on this coating, it deteriorates the coating. It actually eats it. The fungus attacks it. Basically that's it, except where the bottom statement that I made is that these type of coatings cannot hold back water and should not be used to try to hold back water. And anybody with any roofing knowledge should understand or know they can't hold back water. (T. 71, 72). Respondent McCurley testified that he did not know what numerical "perm rating" the material he used had been given, but that he relied on the manufacturer's representations that it would withstand ponding, when he told Mr. Shoop that he thought it would work. He did not dispute that the coating had failed. Mr. Hilson was of the opinion that not even an impermeable coating would have worked, because it would not only have prevented water's penetrating, but would also have trapped moisture already in the cementitious fill. In his view, when the trapped water vaporized, it "would have blown the system off". Petitioner's Exhibit No. 7. Mr. McCurley also contracted with Mr. Shoop to work on the roof of the Mayani apartment building in Miami. For $1200.00, he undertook, among other things, to check and reseal as needed "litch [sic] pans," repair three leaks in the deck, cover "all bald spots with gravel," and install Gravel Lok over the entire gravel roof area. The leak repairs were unconditionally guaranteed for a year. After work was completed, Mr. McCurley received full payment on September 6, 1983. Before he began work, Mr. McCurley telephoned some government office in Dade County and asked whether a permit was "required to put a cement coating over a gravel built-up roof," (T. 9) and was told that none was required. After the present proceedings were instituted he called again and got the same answer. As a practical matter, persons not licensed as roofers, including "the average painter, goes out and does a waterproof of a roof." (T. 103) Repair of the three leaks probably cost Mr. McCurley $30.00. (T. 99) When he began on the Mayani roof Mr. McCurley was aware that Dade County's code is similar to Broward County's, which incorporates the South Florida Building Code, and knew specifically that Dade County required a permit for roofing repairs "after Three Hundred dollars," (T. 98) a permit he was ineligible to obtain. Dade County does indeed require permits for the "application, construction or repair of any roof covering. . .exceeding three hundred dollars (S300.00) in value of labor and materials, . . . or for work exceeding 2 roofing squares in extent," Petitioner's Exhibit No. 6, and the requirement applied to the job Mr. McCurley did at Mayani. (T. 66). When Mr. Shoop reported the Camelot leaks to Mr. Emig on May 30, 1984, he also reported leaks at Mayani that had appeared after heavy rains in Miami. Eventually respondent repaired the Mayani roof, but problems developed again in November of 1984.
The Issue Whether Respondent committed the offenses set forth in the administrative complaint and, if so, the penalty which should be imposed.
Findings Of Fact At all times material to this case, the Respondent, Harry Bradshaw, was licensed as a registered roofing contractor in the State of Florida, holding license number RC 0033812. On August 26, 1986, Respondent's license as a registered roofing contractor was suspended by Petitioner. Respondent's license remained suspended at all times material to this case. On December 16, 1987, Respondent contracted with the Moose Lodge located in Hialeah, Florida, to reroof the Moose Lodge building. The proposal submitted by Respondent contained representations that Respondent was licensed as a registered roofing contractor and that he was insured. Respondent knew that his license as a registered roofing contractor was under suspension. Respondent had no insurance. The contract between Respondent and the Moose Lodge provided that Respondent would perform the work and supply the materials for the sum of $6,200.00. The sum of $3,200.00 was paid to Respondent in advance of his beginning the job. Respondent used the sums advanced to purchase materials and supplies. The remaining $3,000.00 was to have been paid upon Respondent's completion of the job. During the negotiations that resulted in the contract between Respondent and the Moose Lodge, Respondent represented that the job should be completed in time for the functions scheduled for New Year's Eve. While Respondent had purchased the materials needed for the job and had done a substantial amount of work on a portion of the roof, he was unable to complete the work by the New Year. Respondent was ordered to stop work on the job on January 26, 1988. Respondent did not abandon the job. Although he was slow in performing the work, a part of Respondent's delay in performance was caused by rain. There was no evidence as to what would have been a reasonable period of time for Respondent to have completed the job. On January 26, 1988, the administrator for the Moose Lodge complained to the Building Inspection Department for the City of Hialeah, Florida, because the administrator was not pleased with the progress that Respondent was making toward completion of the job. The administrator was told by a representative of the Building Inspection Department on January 26, 1988, that Respondent had no license and that the required permit had not been pulled. The administrator was told to prohibit Respondent from working on the roof. Immediately thereafter, the administrator instructed Respondent to do no further work on the roof. The members of the Noose Lodge completed the job started by Respondent for less than $3,000.00, the balance of the amount that would have been owed Respondent if he had finished the job. Respondent knew that a permit was required for this work. Respondent also knew that only a licensed roofing contractor could pull the required permit. Respondent proceeded with the job when he was unable to persuade a licensed roofing contractor to pull the permit for him. Petitioner filed an administrative complaint against Respondent alleging that at the time he contracted with the Moose Lodge, Respondent's license was suspended, thus violating the provisions of Section 489.129(1)(j), Florida Statutes, and the provisions of Section 489.127(1)(e), Florida Statutes. The administrative complaint also alleged that Respondent failed to perform in a reasonably timely manner and/or abandoned the job in violation of Section 489.129(1)(m), Florida Statutes, and Section 489.129(1)(k), Florida Statutes. Respondent denied the allegations of the administrative complaint and timely requested a formal hearing. This proceeding followed. Respondent was previously disciplined by the Construction Industry Licensing Board, and his license remained under suspension at the time of the final hearing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated Section 489.127(1)(e), Florida Statutes, and Section 489.129(1)(j), Florida Statutes. It is further recommended that the final order revoke Harry Bradshaw's license in the State of Florida as a registered roofing contractor. DONE and ENTERED this 31st day of October, 1989, in Tallahassee, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 1989. COPIES FURNISHED: Harry Bradshaw 5590 East Seventh Avenue Hialeah, Florida 33013 David M. Gaspari, Esquire Adams, Coogler, Watson & Merkel, P.A Suite 1600 NCNB Tower 1555 Palm Beach Lakes Boulevard West Palm Beach, Florida 33402-2069 Kenneth E. Easley, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence and the positions of the parties, I hereby make the following: Thomas G. Walker (herein sometimes called "Licensee" or "Respondent") is a registered residential contractor and is issued license number RR 0009839. Thomas G. Walker was initially licensed by the Board in July of 1969 as an individual and during January, 1975, he changed his registration status as an individual to qualify Insulshield Roofing as the business entity through which he would conduct his business (Petitioner's Exhibit No. 1). An examination of the official records pertaining to the Licensee reveals that he does not now nor has he ever held a roofing license in the State of Florida. On February 16, 1979, the Licensee was apprehended contracting roofing without a State roofing contractor's license by the Board's representative and was issued a Notice of Violation (Petitioner's Exhibit No. 3). On July 26, 1977, the Licensee entered into an agreement with Jan Soderstrom, 501 Orlando Avenue, Indialantic, Florida, to remove the tile from the Florida Room of her residence and hot mop the herein-described roofing area, to replace tile as needed, to clean and coat the entire roof, and to install a cap over Ms. Soderstrom's chimney. He guaranteed the work for a period of five (5) years and charged a contracted price of $800.00. The Licensee was paid the contracted price of $800.00 by check dated August 4, 1977 (Petitioner's Exhibit No. 5). During early February, 1978, Ms. Soderstrom detected a leak in her roof and summoned the Licensee back to her residence to repair same. During February, 1978, Respondent returned to Ms. Soderstrom's residence to repair the leak in her roof. Upon his return, he removed several roof tiles and since February, 1978, to the present, he has not returned to this project. Clyde Pirtle, a field investigator for the Board, investigated the Licensee based on complaints that he received from Ms. Soderstrom and from a Mr. Capitz. On or about February 16, 1977, Mr. Pirtle discussed a Notice of Violation with the Licensee and explained to him the necessity to register as a Roofing Contractor, if he was in the business of acting as a Roofing Contractor. Mr. Charles D. Franklin, a building official of Indian Harbor Beach, Florida, is the custodian of the records in Indian Harbor, Florida. Based on an examination of the records by Mr. Franklin, the Respondent/Licensee is not registered as a Roofing Contractor locally.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby, RECOMMENDED: That the registered residential contractor's license, number 0009839, of the Licensee, Thomas G. Walker, d/b/a Insulshield Roofing, be suspended for a period of one (1) year. RECOMMENDED this 4th day of April, 1979, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 2400 Independent Square Jacksonville, Florida 32202 Thomas G. Walker d/b/a Insulshield Roofing 170 5th Street South Melbourne Beach, Florida 32951 J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
Findings Of Fact Respondent is Richard McDougal, holder, at all times pertinent to these proceedings, of registered roofing contractor license no. RC 0050466. Petitioner is the Department of Professional Regulation, Construction Industry Licensing Board, the state agency charged with the regulation of contractors in the State of Florida. Respondent was the qualifying agent for D & R Roofing Co., at all times pertinent to these proceedings. On July 31, 1989, Arla Jackson signed and accepted Respondent's written proposal to re-roof a house belonging to Jackson, located in Washington County, Florida. Prior to engaging Respondent to re-roof the house, Jackson had only a minimal amount of leakage in a couple of corners inside the house. Under the terms of the written proposal provided by Respondent to Jackson, Respondent agreed to remove the old roof covering from the structure; install a new three ply fiberglass felt covering; install new eave metal around the roof perimeter; extend the roof a short distance at one end; and top coat a utility building on the premises. Further, Respondent agreed to haul away debris resulting from the job. Completion of the roofing project by Respondent and receipt of payment from Jackson in the amount of $3,000 occurred on August 9, 1989. $2,900 of this amount was payment to Respondent for replacing the old roof while the remainder satisfied charges by Respondent for additional work required to extend the roof. Shortly after Respondent's completion of the roof replacement, Jackson began to telephone Respondent, requesting that he come and repair holes in the roof that were leaking water as the result of rain. Respondent came to Jackson's house on at least three occasions to attempt to stop leaks in the roof. He eventually determined that he had stopped the leaks and told Jackson that, as far as he was concerned, there was no roof leakage problem. Jackson's flat roof continued to leak. Eventually, Gus Lee, an unlicensed roofing assistant to H.M. Strickland, a local licensed contractor, agreed to repair her roof and eliminate the leakage problem. Strickland's signature appears with Lee's on written documentation bearing the date of October 1, 1989, and promising a "fine roof with no leaks; and I will stand behind it." Jackson accepted the Strickland offer. Jackson paid approximately $1,925.00 to Lee for work in connection with replacing the roof and painting the interior ceiling of the house. She paid an additional $653.79 for building supplies in connection with the project. Overall, Jackson paid approximately $2,578.79 for labor and materials to re-roof her house and repair the interior ceiling damage resulting from the leakage. This amount was in addition to the amount previously paid to Respondent. On October 20, 1989, Lee, the unlicensed assistant to Strickland and the person who actually undertook the task of re-roofing Jackson's house, removed the previous roofing material placed on Jackson's house by Respondent. Lee observed no fiber glass felt covering material on Jackson's roof at the time he re-roofed the house. Lee's testimony at hearing was credible, candid and direct. Although unlicensed as a contractor, Lee's attested experience supports his testimony regarding what he observed and establishes that Respondent failed to comply with his agreement to Jackson to provide fiber glass felt during the initial roofing of the house and instead used a less expensive material. Lee's testimony, coupled with that of Jackson and Lee's son, also establishs that significant damage had occurred to the interior ceiling of Jackson's house as the result of leakage after completion of work by Respondent. After Lee completed the re-roofing of Jackson's home, inclusive of use of a six ply felt covering on the roof accompanied by pea gravel and sealant, the roof's leakage stopped.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that a Final Order be entered imposing an administrative fine of $1500 upon Respondent's license as a registered roofing contractor. DONE AND ENTERED this 25th day of November, 1991, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Fl 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of November, 1991. APPENDIX TO RECOMMENDED ORDER The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by the parties. Petitioner's Proposed Findings. 1.-4. Adopted, though not verbatim. 5.-8. Subordinate to Hearing Officer's Conclusions. 9.-11. Adopted in substance, though not verbatim. Respondent's Proposed Findings. None submitted. COPIES FURNISHED: Robert B. Jurand, Esq. Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, FL 32399-0792 Richard McDougal Box 10277 Panama City, FL 32404 Daniel O'Brien, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, FL 32201 General Counsel Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, FL 32399-0750
The Issue Whether Respondent committed the offenses alleged in the Administrative Complaint and, if so, the penalties that should be imposed.
Findings Of Fact At all times relevant to this proceeding, Respondent has been licensed by the Petitioner as a roofing contractor, having been issued license number CCC 57995 by the Florida Construction Industry Licensing Board. At all times relevant to this proceeding, Respondent was the qualifier for and did business as “Victor’s Roofing Co., Inc. of the Fla. Keys” (Victor’s Roofing). At all times relevant to this proceeding, Mr. Johnson was an owner of property located at 3214 Harriet Avenue, Key West, Florida (the subject property). Mr. Johnson lives in Hollywood, Florida. The subject property is rental property. Respondent and his company are not licensed to do drywall work in Key West, Florida, and they are not licensed with Petitioner other than as a roofing contractor. ROOFING WORK On November 3, 2008, Respondent, on behalf of Victor’s Roofing, entered into a contract with Mr. Johnson to re-roof the subject property. The proposal submitted by Respondent to Mr. Johnson contained Victor’s Roofing’s full corporate name; its office address in Marathon, Florida; two telephone numbers; and a fax number. The proposal was signed by Respondent. The proposal described in some detail the scope of the work. The price of the work was $7,000.00. Mr. Johnson accepted the proposal. Victor’s Roofing completed the roofing job to Mr. Johnson’s satisfaction. A leak developed after the roof was completed and Victor’s Roofing promptly repaired the leak to Mr. Johnson’s satisfaction. Petitioner’s Administrative Complaint alleged that Victor’s Roofing had failed to obtain a permit for the roofing job on the subject property and that it had failed to obtain required inspections. Those allegations were the result of an error by Petitioner’s investigator. Ms. Del Rio obtained records from the City of Key West Building Department for the wrong address. Instead of obtaining the permit history for the subject property (3214 Harriet Avenue) she requested and obtained the permit history for 3314 Harriet Avenue. Respondent applied for a permit for the roofing job on the subject property on November 11, 2006, and he obtained an inspection of the roof on November 27, 2007 [sic]. There was insufficient evidence to establish that any other permit or any other inspection was required for the roofing work. DRYWALL WORK After the roofing job had been completed (but before the inspection on November 27, 2007),2 Mr. Johnson informed Respondent by telephone that he needed someone to replace drywall that had been damaged during the period of time the subject property’s roof leaked. Mr. Johnson asked Respondent whether he knew anyone who could do the job. Respondent replied in the affirmative and told Mr. Johnson he would have someone contact him about doing the work.3 Thereafter, Respondent’s brother, Early Harris, contacted Mr. Johnson and the two of them verbally agreed on a price of $4,000. At the time Respondent put Early Harris in touch with Mr. Johnson, Respondent knew that Early Harris was not licensed to do drywall work in Key West. After giving Mr. Johnson’s telephone number to Early Harris, Respondent had no further involvement with the drywall work on the subject property. The price of the drywall work escalated to $9,000.00 after the work began. On November 25, 2006, Early Harris and Mr. Johnson signed a written proposal agreeing to the price of $9,000.00.4 This was a form proposal with the following: Victor’s Roofing Co., Inc. 2nd Generation Serving South Florida Licensed & Insured Marathon, Fla. The only telephone number on the proposal other than Mr. Johnson’s, was the number for Early Harris’ cell phone. The contract signed by Respondent on November 3, 2006, for the roofing work was on a different form and utilized a different font than the contract signed by Early Harris on November 25, 2006. The name of the corporation on the proposal for the drywall work, while similar to the name of Respondent’s company, was different. Early Harris has worked for Respondent’s business for several years, but there was no clear and convincing evidence that Early Harris had the authority to contract on behalf of Respondent’s business in November 2006. There was no evidence that Early Harris is a part owner of Respondent’s business or that he is an officer or director of Respondent’s business. Respondent testified, credibly, that Early Harris was not authorized to contract on behalf of Respondent’s business at the times relevant to this proceeding. There was no clear and convincing evidence to refute Respondent’s assertion that Earl Harris had no authority to contract on behalf of Respondent’s business. Early Harris did the drywall work on the subject property. Mr. Johnson paid Early Harris $9,000.00 for the drywall work. Mr. Johnson could not find the check(s) he wrote for the drywall work and, consequently the check(s) were unavailable as an exhibit. His recollection as to the name of the payee of the check(s) was not clear. Respondent testified, credibly, that neither he nor his business received any of the money for the drywall work. The drywall work Early Harris did was not to Mr. Johnson’s satisfaction. Mr. Johnson had to pay $600.00 to a drywall contractor for corrective work. In addition, Mr. Johnson had to pay $600.00 for a permit to have the repair work done.5 The total investigative costs of this case to Petitioner, excluding costs associated with any attorney’s time, was $191.16.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board, enter a final order finding Respondent not guilty of the violations alleged in Counts I, II, and III of the Administrative Complaint. DONE AND ENTERED this 14th day of January, 2010, in Tallahassee, Leon County, Florida. CLAUDE B. ARRINGTON Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 14th day of January, 2010.
The Issue Whether one or more of the following penalties should be imposed on Sylvia Allen: revocation or suspension of Ms., Allen's practice, imposition of an administrative fine and/or any other relief that the Petitioner deems appropriate?
Findings Of Fact The Petitioner is the state agency charged with the responsibility to prosecute administrative complaints against registered roofing contractors in the State of Florida. Sylvia V. Allen is, and has been at all times material hereto, licensed as a registered roofing contractor in the State of Florida. Ms. Allen holds State of Florida license number RC 0046666. Ms. Allen was at all times material hereto the qualifying agent and the President of Lakemont Construction, Inc. of Park 20 West, 1250 Blountstown Highway, 1236-C, Tallahassee, Florida. In early 1987, Ms. Allen submitted a bid to the Department of General Services (hereinafter referred to as the "Department") for the reroofing and waterproofing of the National Guard Armory building (hereinafter referred to as the "Armory") located in Winter Haven, Florida. The bid submitted by Ms. Allen was for $96,536.00. The Department accepted the bid submitted by Ms. Allen and entered into a contract with her on March 31, 1987. Because the contract price was less than $100,000.00, no bond was required to be posted. On April 20, 1987, a notice to proceed/mobilize was issued by the Department to Ms. Allen. On or about April 29, 1987, Ms. Allen mobilized. Work on the project began on May 11, 1987. The first work performed on the project pursuant to the schedule of work to be performed was the removal of the existing roof and the placement of a temporary roof on the Armory. On May 20, 1987, Ms. Allen submitted a pay request to the architect for the project, Mr. Shafer. This request was forwarded to Thomas Berley, a project director for the Department. Mr. Berley received the request on May 26, 1987. Upon receipt of the request, Mr. Berley notified Mr. Shafer that Ms. Allen needed to provide the Department with a bar chart showing work progress on the project before the pay request could be processed. Efforts were then begun to try to locate Ms. Allen to inform her of this requirement. Mr. Berley was informed by Mr. Shafer that Ms. Allen could not be located. Therefore, Mr. Berley telephoned Ms. Allen's place of business in Tallahassee. Her telephone had been disconnected. Mr. Berley instructed another project director of the Department located in Tallahassee to go the Respondent's office. Mr. Berley was advised that no one was at the office. Ms. Allen's subcontractors were contacted in an effort to reach Ms. Allen. Mr. Berley was informed that the subcontractors could not locate Ms. Allen either and that no contact had been made by them with Ms. Allen since May 26, 1987. Mr. Berley received a copy of a June 2, 1987, letter from Mr. Shafer to Ms. Allen requesting that she contact him. On June 4, 1987, Mr. Berley sent a letter to Ms. Allen advising her of obligations and giving her seven days to indicate why she was not on the job. This letter was sent certified mail and was signed for on June 11, 1987. Work on the project stopped during early June, 1987. A third and final letter seeking to contact Ms. Allen was sent to Ms. Allen but was returned unopened. Because of the failure of Ms. Allen to contact the Department or the project's architect and because of concerns about the ability of the temporary roof to prevent water damage, the contract for reroofing the Armory was terminated at midnight, June 14, 1987. The concerns about the ability of the temporary roof to prevent water damage to the Armory were legitimate concerns. A temporary roof is only intended to keep water out for a short period of time. Work on the project should not have been stopped while the temporary roof was on the Armory. Failure to pay the pay request would not justify Ms. Allen's actions. On June 16, 1987, Ms. Allen contacted Mr. Berley by telephone. Mr. Berley notified Ms. Allen that the Armory contract had been terminated. On June 19, 1987, the Department received a proposal to finish the project using Ms. Allen's subcontractors. The cost of completing the project was $8,000.00-$9,000.00 more than Ms. Allen's bid price. Leaving a temporary roof on the Armory for three weeks was excessive. Once work began on this project, the work should have proceeded continuously until the new roof had been completed. While the temporary roof was on the Armory excessive damage could have occurred resulting in structural damage as well as cosmetic damage. Ms. Allen's actions constituted abandonment of the job. Ms. Allen's actions also constituted incompetence in the practice of contracting. Ms. Allen has previously been issued a letter of guidance from the Construction Industry Licensing Board.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Sylvia V. Allen be found guilty of having violated Sections 489.129(1)(k) and (m) , Florida Statutes. It is further RECOMMENDED that Ms. Allen be required to pay an administrative fine of $2,500.00 to the Petitioner. DONE and ENTERED this 1st day of December, 1988, in Tallahassee, Florida. LARRY J. SARTIN Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 1st day of December, 1988. APPENDIX Case Number 88-1997 The Petitioner has submitted proposed findings of fact. It has been noted below which proposed findings of fact have been generally accepted and the paragraph number(s) in the Recommended Order where they have been accepted, if any. Those proposed findings of fact which have been rejected and the reason for their rejection have also been noted. The Petitioner's Proposed Findings of Fact Proposed Finding Paragraph Number in Recommended Order of Fact Number of Acceptance or Reason for Rejection 1 1. 2 2. 3 3. 4 4 and 6-7. 5 8-9. 6 10. 7 11. 8 Hereby accepted. 9 12-13. 10 14. 11 15. 12-13 16. 14 6. 15 17. 16 19. 17-18 20. 19 18. 20 19. 21 21. 22 22. 23-24 23. 25 24. 26 Irrelevant. 27 25. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Belinda H. Miller, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Sylvia V. Allen 110 Dixie Drive, D2 Tallahassee, Florida 32304 Fred Seely Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Bruce D. Lamb General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Lawrence A. Gonzalez Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
