The Issue Whether Respondent's activity and conduct in the performance of a roofing contract constitutes abandonment of that contract in violation of Section 489.129(1)(k), Florida Statutes (1979), and whether Respondent willfully or deliberately violated the Volusia County Building Code, thereby contravening Section 489.129(1)(d), Florida Statutes (1979), by failing to obtain a building permit prior to commencing construction of the subject project. Based upon my observation of the witnesses and their demeanor while testifying, the arguments of counsel and Respondent, the Petitioner's proposed recommended order and the entire record compiled herein, I hereby make the following:
Findings Of Fact By its Administrative Complaint signed October 21, 1981, Petitioner, Florida Construction Industry Licensing Board, seeks to take disciplinary action against Respondent and against his license as a registered roofing contractor. Respondent, Leonard L. Clark, is a registered roofing contractor who holds License No. RC 0020933 which has been issued by Petitioner. Respondent does business under the entity Clark Roofing. On January 15, 1981, Respondent entered into a contract with one Mae Coogan, to reroof her residence. The contract specifically required Respondent to "replace any bad wood," and provide a ten (10) year workmanship warranty. (Petitioner's Exhibit No. 1.) Additionally, Respondent agreed to install a 1 x 2 inch strip and a brown aluminum facia at an extra cost of $200.00. (Petitioner's Exhibit No. 1 and testimony of John Coogan.) Mrs. Mae Coogan is an elderly woman and is incapacitated. Her son, John Coogan, who lives with her in her residence, advised her during the negotiations of the subject contract, and testified as a witness in the proceedings herein. Respondent and John Coogan's testimony establishes that construction on the subject project commenced on February 10, 1981, and ceased on March 28, 1981. At that time, based upon Respondent's representation that the job was complete, Mr. Coogan paid Respondent the entire $2,500.00 due under the terms of the contract. Shortly thereafter, Mr. Coogan discovered evidence of "bad" or "rotten wood." Mr. Coogan immediately apprised Respondent of this, whereupon Respondent initially told him that he would be back to the job site to take care of any problems that existed with the reroofing project. There is conflicting evidence as to whether or not there was a subsequent telephone conversation between Respondent and Mr. Coogan following a letter which Respondent found offensive. Respondent claims that there was such a conversation and that the parties became angry at each other. At that juncture, the parties were unable to resolve their differences. Efforts by the parties to resolve their differences reached a stalemate, and Respondent did not again visit the project site or otherwise inspect the claimed damaged by Mr. Coogan. Mr. Coogan, to substantiate his claim that there was in fact rotten or bad wood left exposed in the overhang, rafters and beams surrounding the roof, introduced several photographs which depicted the condition of the wood on the roof. (Petitioner's Composite Exhibit No. 3.) Respecting the fact that there was rotten wood, as claimed by Mr. Coogan, in the rafters and overhang, Respondent admitted the existence thereof. There is also a question about the possibility of rotten wood being covered by Respondent's employees and not replaced as required by the contract. The particular area in question is a portion of a flat roof which sagged in several places. Mr. Coogan claims that he had been advised that this was due to rotten wood underneath the shingles in an area in which he specifically claims to have asked Respondent to allow him to inspect the exposed-wood surface prior to the time in which it was covered with asphalt shingles. Respondent's workers covered this area of the roof without permitting Mr. Coogan the opportunity to inspect it. Mr. Coogan testified that the roof continued to sag in the identical places where it sagged prior to the reroofing. In this regard, Respondent admits that he might have agreed to allow Mr. Coogan an opportunity to inspect the exposed roof once the shingles were removed and prior to the time that he recovered (reroofed) the flat roof. Respondent further testified that this was not due to any effort on his part to conceal or otherwise hide rotten wood and, in fact, he claimed to have covered or replaced any bad or rotten wood. In this regard, Mr. Coogan noticed at least four water leaks from his roof prior to the time that Respondent reroofed his mother's house; however, he testified, on cross-examination, that he has not seen any leaks since Respondent has completed the subject project. Bob McConnell, Volusia County Building Inspector for approximately five years, inspected the roofing job completed by Respondent for Mrs. Coogan on July 28, 1981. Mr. McConnell found that the roofing job did not comply with the contract in the following regards: The 1 x 2 inch strip beneath the brown aluminum facia, called for as an extra, was not installed; There was visible rot in the sheathing; A short hip (rafter) was replaced with unsound wood; and A rafter tail had visible rot. In this regard, Mr. McConnell, while also reporting that there were soft spots in the built-up roof, could not testify with certainty that they were the result of wood rot. Respondent testified that he has tried to contact Mr. Coogan on several occasions to correct any claimed deficiency. Respondent stands, at this time, willing to correct any deficiency that exists or to correct any problem which stems from his deviation from the contract. In this regard, Respondent has offered, and no offers, to remove the shingles from the entire roof and allow for it to be inspected by Respondent or any designated roofing contractor whom Coogan or Petitioner selects. Respondent will replace any "bad" or "rotten" wood which he has been claimed to have covered. However, Respondent expects to be paid for reroofing this job in the event that in an inspection reveals that no "bad" or "rotten" wood was covered as Mr. Coogan and Petitioner claim. Inspector McConnell has known Respondent in excess of twenty-five (25) years and is unaware of any claim that Respondent has performed any unworkmanlike or "shoddy" roofing repairs. Finally, in this connection, Respondent introduced letters from three (3) area builders who attested to Respondent's excellent workmanship. (Respondent's Composite Exhibit No. 3.)
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby RECOMMENDED: That the Respondent be placed on probation for a period of two (2) years and that the term of probation be suspended for a period of sixty (60) days, during which time Respondent shall be allowed an opportunity to return to the Coogan residence and replace any existing exposed "rotten" or "bad" wood which should have been replaced pursuant to the terms of the contract. In the event that the Respondent properly completes the replacement of the rotten or damaged wood on this project, following an inspection by one of Petitioner's agents, it is further RECOMMENDED: That the entire term of the probation be suspended. In the event that Respondent fails to properly complete this project, following an inspection by one of Petitioner's agents, it is further RECOMMENDED: That the entire term of probation be instituted without the necessity of further hearing. RECOMMENDED this 11th day of August, 1982, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of August, 1982.
Findings Of Fact Respondent is Richard K. Willis, a registered roofing contractor licensed by Petitioner and holding license RC-0041275 at all times pertinent to these proceedings. His address of record is Winter Haven, Florida. Respondent and Jeffrey Smith entered into a contract in July of 1986. Under terms of the agreement, Smith, a chiropractor, agreed to pay Respondent the sum of $2,200 to re-roof the facility which served as Smith's home and office. The agreement signed by the parties contains a written guarantee that materials to be used in the project would meet specifications set forth in the document. Further, the guarantee stated that work would be completed in "a workmanlike manner according to standard practices." The project was completed by Respondent and Smith paid him the agreed upon amount of $2,200 in July of 1986. About three weeks after completion of the job, Smith noticed a leak in the roof and telephoned Respondent. Two or three weeks later and after several more telephone calls from Smith, Respondent returned to the job site. By that time, interior damage to the ceiling tiles had been sustained. The tiles became discolored by leaking water and started to collapse. Respondent proceeded to patch the leaking roof with tar. In June of 1987, Smith's facility developed a second leak in the roof over the back portion of the house. Respondent returned, reviewed the problem and agreed to tear off the leaking section of the roof and replace it. As a result of this action by Respondent, the leakage increased. More extensive damage was caused by water leaking down door frames and across the ceiling of the house. Respondent had also promised that he would put a "tarp" over Smith's roof to temporarily stop the leakage until repairs could be effected, but such covering never materialized. After Respondent's second attempt to fix the roof, Smith advised him that the leakage was continuing. Smith then tried several times without success to communicate with Respondent and get him to return to the job site. Finally, after Smith contacted local government building officials, Respondent returned and stopped the leakage. The repairs came too late to prevent ceiling damage which cost Smith $400 to repair. When a third leak developed in the roof in February of 1989, Smith hired another contractor to fix the leak for the sum of $60. Petitioner provided expert testimony which establishes that Respondent demonstrated incompetence in the practice of roof contracting. Further, the work performed by Respondent did not meet the terms of the guarantee he gave to Smith. These conclusions are based on the fact that workmanship provided by Respondent failed to meet standard practices of the industry. Such failure is demonstrated by the irregularity with which surface material was applied to the roof; the lack of sufficient gravel; the lack of uniform distribution of that gravel; missing metal flashing and lifted or separated flashing at the vertical surfaces of the roof; and improper installation of flashing around the plumbing vent exiting through the roof. Respondent's previous disciplinary history with Petitioner consists of an administrative fine of $250 on June 19, 1985, and letter of guidance issued on August 14, 1986.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent in violation of Subsection 489.129(1)(m), Florida Statutes, (1988) and revoking his license as a roofing contractor in accordance with provisions of Rule 21E-17.001, Florida Administrative Code. DONE AND ENTERED this 6th day of April, 1989, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 6th day of April, 1989. APPENDIX The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by Petitioner. Petitioner's Proposed Findings 1.-17. Addressed in substance. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Richard K. Willis 2106 Winter Lake Road Winter Haven, Florida 33880 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 =================================================================
Findings Of Fact At all times material hereto, Respondent has been a registered roofing contractor in Miami, Florida, having been issued license no. RC 0047352. Respondent is the qualifying agent for All Central Roofing, Inc. In May 1986 All Central Roofing, Inc., entered into a contract with Richard Crisonino to perform certain roofing work on Crisonino's residence in Miami, Florida. The contract price was $3,374. All Central Roofing, Inc., thereafter began the roofing work on Crisonino's residence without obtaining a permit for that work from the local building department and without posting a permit on the job site. All Central Roofing, Inc., failed to obtain the required inspections by the local building department. After completing part of the work involved and after receiving substantial payment under the contract, All Central Roofing Company, Inc., ceased work on the Crisonino residence and failed or refused to complete the work, thereby abandoning the job. By her own admissions at the final hearing in this cause, Respondent does not possess a working knowledge of roofing or roofing contracting. She lacks even a basic fundamental understanding of roofing construction to the extent that it is impossible that she is fulfilling any of her responsibilities as a qualifying agent for All Central Roofing, Inc. Further, Respondent does not even know the number of employees working for All Central Roofing, Inc. Respondent has been disciplined by the Dade County Construction Trades Qualifying Board, and Respondent's personal and business certificates have been revoked by that Board.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is, RECOMMENDED that a Final Order be entered finding Respondent guilty of the allegations contained in the Administrative Complaint filed against her and revoking Respondent's registered roofing contractor license. DONE and RECOMMENDED this 14th day of December, 1987, at Tallahassee, Florida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of December, 1987. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 G. Vincent Soto, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Harry E. Geissinger, Esquire 415 West 51st Place, Suite 201 Hialeah, Florida 33012 Tom Gallagher, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
Findings Of Fact Respondent has been licensed as a registered roofing contractor at all times relevant to this proceeding. His license number is RC0042041. On August 30, 1982, Respondent contracted with the Julien P. Benjamin Equipment Company of Jacksonville, Florida, for the rental of an asphalt kettle. Respondent executed this contract in the name of his roofing and remodeling business. When Respondent failed to return the kettle or make rental payments, the equipment company filed a complaint with the State Attorney. Respondent subsequently entered a plea of guilty to the charge of Grand Theft, second degree, and was placed on 18 months probation, by order of the Duval County Circuit Court dated May 16, 1983. Respondent returned the kettle and paid the rental fees in March 1983.
Recommendation Based on the foregoing, it is RECOMMENDED: That Petitioner enter a Final Order suspending Respondent's roofing contractor's license for a period of one year. DONE AND ENTERED this 24th day of August 1984 in Tallahassee, Florida. R. T. CARPENTER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 24th day of August 1984. COPIES FURNISHED: Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Rex Alaniz 23 Seatrout Street Ponte Verde Beach, Florida 32082 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred M. Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue Whether Respondent's contractor license should be disciplined for alleged violations of Chapters 489 and 455, Florida Statutes.
Findings Of Fact Respondent, James Cooper, was at all times material to this action licensed by the State of Florida as a registered roofing contractor, having been issued license number RC0066905. Mr. Cooper's license is currently classified "Inactive, Issued (09/05/97)." Around March 1, 1996, Marshall Moran was contacted by Julia Jones regarding repairs to the leaky roof on her home located at 209 Cresent Drive, DeFuniak Springs Walton County, Florida. Ms. Jones' home was over one hundred years old with a steep metal roof. The roof she wished repaired was over the enclosed sleeping porch of her house. Over the last ten years, she had various contractors attempt to fix the leak in the sleeping porch roof. These attempts occurred, on average, more than one time per year. The leak always returned. Marshall Moran is an unlicensed and unregistered roofing contractor. Mr. Moran has been a roofing contractor since before the licensure requirements for contractors became law. He elected not to become licensed under those statutes. However, he did have the experience and skills necessary to repair Ms. Jones' roof. Marshall Moran discussed the job with Ms. Jones. Mr. Moran recommended the entire section of the roof be rebuilt and described the anticipated repairs. Ms. Jones would not allow the entire section of roof to be repaired. She thought only the small section where the leak was apparent needed repair. Unknown to Ms. Jones and prior to beginning the work, Mr. Moran contacted Respondent to tell him of Ms. Jones' job and to see if Respondent wanted to do the job. Respondent couldn't do the job with his crew but offered to allow Mr. Moran to "work under his license." Respondent was pursuing a large commercial roofing contract around the same time as the events at issue here. He wanted to keep Moran's crew together in order to be able to complete the large commercial job. He held the crew together by enabling Moran to do the construction at Julia Jones' residence in consideration for taking legal responsibility for the Jones' job. Respondent did not hire Mr. Moran as his employee. Respondent knew Mr. Moran was not registered or certified to practice contracting. He also knew Mr. Moran was well qualified to perform the work on the Jones' job. Respondent admits that he knew that he should not pull permits for anyone, but that he did it just this one time in order to keep the crew together. On March 15, 1996, Respondent obtained City of DeFuniak Springs, Florida, building permit number 1379 for the roof repairs to Ms. Jones' residence. On the application for said building permit, Respondent represented himself (doing business as Cooper Roofing and Repair) as the contractor of record on the aforesaid project. Respondent intended to and did eventually take legal responsibility for the Jones' job. However, he did not supervise Mr. Moran or his crew. Additionally, Ms. Jones was never informed of Respondent's involvement. More importantly, Ms. Jones never contracted with Respondent for either Respondent or his company to perform roof repairs on her home. On March 21, 1996, Mr. Moran provided an estimate for repair of the portion of Ms. Jones' roof she felt needed repair. The estimate bears the name of "AAA Metal Works" and "Marshall Moran." AAA Metal Works was Mr. Moran's company. The estimate does not reference either Respondent or his company. The estimated cost to repair Ms. Jones roof was $2,785. Based on the estimate, Ms. Jones entered into a contract with Mr. Moran and AAA Metal Works to perform the repairs to her roof discussed above. Moran and his crew substantially completed the repairs to Ms. Jones' roof in a few days. However, the roof continued to leak after Moran and his crew ended their work. The continuing leak was not due to any incompetence on the part of Respondent or Moran. Ms. Jones paid for the repairs with two checks made out to AAA Metal Works. The checks were in the amounts of $3,500 and $4,350. Respondent did not receive any of the money for the Jones' job. His only expense was the fee for the building permit. All other expenses were paid for by Mr. Moran. At no time during the formation or performance of the contract with Marshall Moran did Julia Jones have any contact with or knowledge of involvement by Respondent. In fact, Respondent only drove by the job site one time. As indicated, the roof continued to leak. Ms. Jones contacted Mr. Moran on approximately 5-6 occasions notifying him of the continued leaks. Mr. Moran would return to Ms. Jones' home and inspect the problems, but was unable to stop the leaks to Jones' satisfaction. It is not clear whether Mr. Moran kept Respondent informed of these continued service calls. Approximately one year after completion of the initial repairs on Ms. Jones' roof, Respondent received a call from Ms. Jones' tenant and friend, Sharon Jenks, who called posing as a potential new client. Ms. Jenks had gotten Respondent's name from the building permit. Ms. Jenks called Respondent because the house was still leaking approximately one year after the repair was done and intervening visits by Marshall Moran had not fixed the problem. Ms. Jenks arranged for Respondent to visit Ms. Jones' home. Respondent did not recognize the house when he arrived and drove past it. When Ms. Jenks showed Respondent the building permit bearing his name, Respondent showed surprise. He returned the next day with Mr. Moran. Respondent, Mr. Moran, Ms. Jenks and Ms. Jones all met regarding the continued leaking. Respondent and Mr. Moran told Ms. Jones that the metal on the roof was "bad" and needed to be replaced to stop the leaks on the "sleeping porch." Understandably, Ms. Jones did not want to deal any further with Mr. Moran or Respondent and would not permit them to make the recommended necessary repairs. Ms. Jones sued both Respondent and Mr. Moran in a civil action styled: Julia R. Jones v. James K. Cooper and Marshall Moran, Case Number 97-0040-CC, in the County Court of the First Judicial Circuit in and for Walton County, Florida. Following a judge trial, a Final Judgment was entered in favor of Respondent and Mr. Moran on December 9, 1997. Mr. Moran was charged with contracting without a license in violation of Section 489.127, Florida Statutes (1995), in State of Florida v. Marshall Moran, Case Number 97-0549-CF, in the Circuit Court of the First Judicial Circuit in and for Walton County, Florida. That charge was dismissed by Circuit Judge Lewis Lindsey on February 3, 1998.
Recommendation Based upon the findings of fact and conclusions of law, it is, RECOMMENDED: That the Board should find Respondent guilty of violating Chapters 489 and 455, Florida Statutes, and impose an administrative fine of $500.00 on Respondent DONE AND ENTERED this 3rd day of August, 1998, in Tallahassee, Leon County, Florida. DIANE CLEAVINGER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of August, 1998. COPIES FURNISHED: John O. Williams, Esquire Maureen L. Holz, Esquire Willams and Holz, P.A. 458 West Tennessee Street Tallahassee, Florida 32301 J. LaDon Dewrell, Esquire 207 Florida Place, Southeast Ft. Walton Beach, Florida 32549 Rodney Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Joseph Barrass is a registered roofing contractor holding State of Florida license number RC0026890. Respondent was so licensed at all times relevant to this proceeding. Respondent began doing business as a registered roofing contractor through his corporation, J. B. Roofing and Repairs, Inc., about six years ago. This corporation was dissolved and he continued as a roofing contractor through a corporation known as Roofing Services, Inc. He next did business through a third corporation, C. B. Roofing, Inc. Most recently he has done business as C. B. Roofing, a sole proprietorship. Respondent failed to register any of these entities with Petitioner, and is still licensed under his original fictitious name, J. B. Roofing and Repairs. Respondent contracted with Green Glades Construction Co. in early 1979, to install roofs on some 28 new houses. A dispute arose between the parties regarding several unfinished and leaking roofs. Respondent contends he refused to complete the roofs at issue due to nonpayment in accordance with the oral contract. He also argues that he was unable to repair the leaks while the roofs were wet, as demanded by Green Glades. The dispute was settled through civil proceedings. Another matter which culminated in civil action concerned the installation and repair of a patio roof pursuant to an oral contract between Respondent and Marvin Berkowitz, at the latter's Coral Springs residence. Berkowitz complained that Respondent failed to correct a leak in this roof as required by their agreement. Respondent claims the leak was the result of an improperly installed ceiling fan and the flat roof design demanded by Berkowitz. Respondent completed the job and received final payment on October 9, 1979. However, the roof leaked and Berkowitz thereafter contacted Respondent on numerous occasions requesting repairs. It was not until Berkowitz retained counsel and threatened legal action that Respondent made any effort to repair the leak. He returned on February 14, 1980, and did limited repair work. The roof continued to leak and Berkowitz sought damages through civil action. The evidence is conflicting as to whether or not the ceiling fan had been removed when Respondent returned in February, 1980. Berkowitz testified that it had been removed, and Respondent testified that it had not. The evidence is also in conflict with respect to the caveats and/or assurances Respondent gave Berkowitz regarding this installation. The recollections of both witnesses were self-serving and their testimony was generally lacking in credibility. The City of Coral Springs' building code requires a contractor to obtain a permit prior to roof installation. Respondent knew he was required to obtain such a permit for the Berkowitz project, but failed to do so.
Recommendation From the foregoing, it is RECOMMENDED: That Respondent be found guilty of violating Sections 489.119, 489.129(1)(g) and 489.129(1)(j), F.S., in failing to register his business entities and contracting without requisite qualification. It is further RECOMMENDED: That Respondent be found guilty of violating Subsection 489.129(1)(d), F.S., for wilful disregard of the Coral Springs building code pertaining to building permits. It is further RECOMMENDED: That all other charges against Respondent be dismissed. It is further RECOMMENDED: That Petitioner suspend Respondent's roofing contractor's license for a period of six months. DONE AND ENTERED this 17th day of February, 1982, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 17th day of February, 1982.
Findings Of Fact At all times relevant hereto, respondent, James S. Stroz, held registered roofing contractor license number RC 0034849 issued by petitioner, Department of Professional Regulation, Florida Construction Industry Licensing Board. He was first licensed in November, 1979, and at that time qualified under the name of Stroz Roofing. A change in status application was later filed to qualify Stroz Roofing, Inc., 13696 Exotica Lane, West Palm Beach, Florida. Although licensed as a roofing contractor, respondent's firm only performs work on wood shakes or shingles. He does not do hot roofs or flat roofs, which is another speciality in the roofing business. While working for a roofing firm in1979, Stroz became acquainted with Lacy Davis, an unlicensed individual who specialized in flat roof work. When Stroz started his own roofing company in 1983, he began contracting out the flat roof work to other licensed roofing contractors. Lacy Davis learned of this and approached Stroz offering his services on the flat roof work. Stroz knew Davis was unlicensed and would not initially hire him, but Davis gave him a business card of Henry Haywood, a licensed roofing contractor in Palm Beach County and explained he and Haywood were partners and that the work and permitting would be done under Haywood's license. In actuality, Haywood had not authorized Davis to use his business cards, or topull permits under his name. Indeed, Haywood had no knowledge of Davis' activities. Without verifying the truth of Davis' representations, and accepting them instead at face value, Stroz agreed to hire Davis to perform his flat roof work. Between January 20, 1983 and September 30, 1984, Stroz performed some twenty-one jobs using Davis for the flat roof work. At all times, Stroz was under the impression that the work was being done under Haywood's license and that his activities were lawful. Stroz made all checks for the work payable to Lacy Davis or Lacy Davis Roofing. He did this because Davis told him he frequently had difficulty reaching Haywood to cash the checks, and because the business bank account was in Davis' own name. A few of the checks carried a notation at the bottom that payment was for work by Haywood Roofing, but most made no reference to Haywood. Stroz pulled all permits on their jobs reflecting that Haywood Roofing was the licensed contractor. Of the twenty invoices given by Davis to Stroz for the twenty-one jobs, only four were on invoices printed with Haywood's name. The remainder had various other names including "Lacy Davis Roofing," "Lacy Davis" and "Lacy Davis and Benny Guy Roofing Contractors." None of these were licensed as roofing contractors by petitioner. In June, 1984, a member of Davis' crew was injured and it was discovered Davis had no insurance. Stroz's insurance paid the claim, but an investigation ultimately determined that Davis was unlicensed and had no authority to act on Haywood's behalf. This led to the issuance of the administrative complaint herein. Respondent has fully cooperated with petitioner, and in fact voluntarily disclosed one job with Davis that petitioner's investigation had failed to uncover. He admits he was negligent in not checking out the representations of Davis, but he never intended to violate the law. No consumer was harmed in any way by Davis' work, and there are no complaints concerning the quality of the jobs in question.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that Respondent be found guilty as charged in the administrative complaint, and that he be fined $500 to be paid within thirty days from date of the final order rendered in this proceeding. DONE and ORDERED this 2nd day of July, 1985, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of July, 1985.
Findings Of Fact Roger A. Lollis was licensed as a registered roofing contractor at all times material hereto, having been issued license number RC-0030088. His address of record on file with Petitioner has at all times been 912 Tuskawilla Street, Clearwater, Florida, and this is the address to which notice of the hearing was sent. The hearing notice was not returned to the Division of Administrative Hearings by the post office for any reason. Lollis has been the subject of two previous Final Orders imposing disciplinary actions by the Construction Industry Licensing Board. John P. Terranova was first licensed as a registered specialty contractor in August, 1985, having been issued license number RX-0049212 as the qualifying agent for Stretch and Seal Roofing Systems, Inc. Terranova and his wife are the only shareholders of this corporation, and he is the Chairman of its Board of Directors, as well as its President. On November 15, 1984, Mrs. Judith Fugitt executed a contract with Stretch and Seal Roofing Systems, Inc., through its authorized agent, Scott St. John, for work to be performed on her residence at 1636 Bravo Drive, Clearwater, Florida, in order to correct a problem she was having with leaks. The work to be performed was specified in the contract to include: clean and mildewcide roof surface; inspect for water damage beneath tiles that are cracked or broken; replace broken and cracked tiles as necessary; flow coat to seal chimney flashing against leaks; apply 15 year Stretch and Seal coating in color to be specified by home owner; and color to be applied approximately 2 weeks after Stretch and Seal is applied. The contract further stated that the expense of any labor or materials for work not specified in the contract, such as to replace rotten wood, would be the responsibility of the homeowner. The Fugitt contract provided a 15 year warranty and guarantee and stated, "All material is guaranteed to be as specified. All work to be completed in a workmanlike manner according to standard practices." The contract price for the work to be done on the Fugitt's house was $2500, which was to be paid $500 at commencement of the job, $1500 upon completion of the application of Stretch and Seal, and the balance upon completion of painting of the roof tiles. Although Terranova denies meeting with the Fugitts at the time this contract was executed, Mr. Elmer Fugitt testified that Terranova was present and gave his personal guarantee that the work would be done as specified in the contract and would correct the leak problem. Terranova also represented to Elmer Fugitt that he had 30 years experience in the roofing business. It is specifically found, based upon the demeanor of the witnesses, that the testimony of Elmer Fugitt concerning Terranova's personal involvement in this transaction on or about November 15, 1984, is credible, and Terranova's denial thereof is not. Shortly after November 15, 1984, work commenced on the Fugitt roof, and some rotten wood was discovered which needed to be replaced. Tim Egner, another authorized representative of Stretch and Seal Roofing Systems, Inc., then prepared another proposal for repair and replacement of the rotten wood, which Judith Fugitt also accepted. The contract price for this work was $482.50. Both St. John and Egner worked full-time for Terranova's company, with his knowledge and under his control. Terranova referred to Egner as his "operational manager" who handled customer complaints. The Fugitts paid Terranova, through Stretch and Seal Roofing Systems, Inc., a total of $2981.00 between November 27 and December 23, 1984, for work performed on their roof. This was the full amount due under the November 15, 1984 contract and also the subsequent contract for repair and replacement of rotten wood. In late December, 1984, all tiles were in place, the Stretch and Seal coating had been applied, but the tiles had not been painted. In January, 1985, the Fugitt roof continued to leak and Elmer Fugitt therefore contacted Terranova's company. After repeated contacts, Terranova arranged for Roger Lollis to inspect the roof. On March 12, 1985, Lollis obtained a permit from the Pinellas County Department of Building Inspection for roof repair on the Fugitt residence. Lollis never discussed what he was doing with the Fugitts, but was simply assigned to the job by Terranova. Mr. Fugitt saw Lollis on his roof one time. After tearing up a section of tiles and leaving a portion of the Fugitt roof exposed, Lollis walked off the job and never returned. Thereafter, Elmer Fugitt reset the tiles himself after repeated efforts by his attorney to contact Terranova had failed. The Fugitt roof has never been painted although they contracted and paid for this to be done by Terranova's company. At the hearing, Terranova denied his company either contracted for, or performed, roofing work. It was his testimony that he was only obligated to do painting, and it was Lollis' and the Fugitts' responsibility to do the roofing work. Terranova's testimony is not credible because it is contrary to the terms of the contracts the Fugitts executed with his company, and is outweighed by the convincing testimony of Elmer Fugitt. Terranova contracted for and did perform, through his company, roofing work on the Fugitt residence at a time before he was licensed as a roofing contractor. The roofing work performed by Terranova for the Fugitts would be found to be incompetent and would constitute misconduct in the practice of contracting if he had been licensed at the time. He did not repair the leaks, he accepted full payment for a job that was not completed, he avoided or failed to return repeated calls from and on behalf of the Fugitts, and he allowed their roof to be left exposed to the elements after Lollis walked off the job. Terranova failed to honor the guarantee set forth in his contract with the Fugitts. Lollis performed work on the Fugitt roof at the request and direction of Terranova in March, 1985, at a time Terranova was not a licensed roofing contractor. He did obtain a local permit, but did not call for any inspection. In fact, he walked off the job and left the Fugitt roof exposed. Lollis' actions constitute incompetence and misconduct in the practice of contracting, but there is no evidence he knew that Terranova was not licensed at the time. Lollis was not the qualifying agent for Stretch and Seal. Pinellas County building code ordinances require a permit for any roof repair that exceeds $50 and for any general construction that exceeds $500. Terranova failed to obtain any required permits for the Fugitt job. A final inspection on any roofing job for which a permit has been issued is required, but Lollis never called for one after he obtained the permit in March, 1985.
Recommendation Based upon the foregoing, it is recommended that the Construction Industry Licensing Board enter a Final Order: Dismissing the Administrative Complaint filed against John P. Terranova since it has not been shown that the Board has jurisdiction over him under Section 489.129(1)(m), Florida Statutes, for matters occurring prior to his having been licensed. Finding that Roger A. Lollis has violated Sections 489.129(1)(d),(j) and (m), Florida Statutes, and therefore imposing a six month suspension and $1000 administrative fine against him based not only on the facts found herein concerning his actions regarding the Fugitt roof, but also the fact that this is the third disciplinary action taken against his license by the Construction Industry Licensing Board. DONE AND ENTERED this 11th day of December, 1987, in Tallahassee, Florida. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of December, 1987. COPIES FURNISHED: W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 John P. Terranova 3 Birdie Lane Palm Harbour, Florida 33528 Roger A. Lollis 912 Tuskawilla Street Clearwater, Florida 33516 Fred Seely Executive Director Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 William O'Neil General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue Does the unsatisfied civil judgment in ABC v Millman et al, Case Number 50 2008 CA 006245 XXXX MB relate to practice of Respondent’s profession, thus establishing that Respondent, Harris M. Millman, violated section 489.129(1), Florida Statutes,(2009)? If he committed the violation, what penalty should be imposed?
Findings Of Fact The Construction Industry Licensing Board has certified Millman as a General Contractor and a Roofing Contractor under the authority of Chapter 489, Florida Statutes. In 2009 and 2010, he held license numbers CGC l1522 (General) and CCC 1327057 (Roofing). Millman’s licenses are presently inactive. Millman has actively practiced the licensed professions of general contractor and roofing contractor in Florida since 1977. The Department and its predecessor agencies have never taken any disciplinary action against him. At all times material to this proceeding, Affiliated was a Construction Qualified Business in the State of Florida, certified under Chapter 489, Florida Statutes, holding license number QB45287. Millman was the Primary Qualifying Agent for Affiliated under Chapter 489, Florida Statutes, at all times material to this proceeding. On December 26, 2005, Millman signed a credit application with American Builders and Contractors Supply Company, Inc., d/b/a ABC Supply Co. Inc. (ABC), on behalf of Affiliated. Millman listed his Certified General Contractor’s License (CGC 011522) on the credit application and personal guarantee Although Millman provided his General Contractor’s license number on the application, ABC did not require a license number. The application indicates that the account is related to “low and steep slope roofing.” The account was for the purchase of roofing materials and supplies. On December 29, 2005, Millman signed a personal guarantee of the Affiliated account with ABC. Millman’s personal guarantee made him personally liable for Affiliated’s obligation to pay ABC. ABC granted the application and opened a line of credit for Millman and Affiliated. Millman and Affiliated used the account to purchase roofing supplies on credit. They purchased and paid for over $800,000 worth of supplies from 2006 into 2009. This is separate from the goods and materials that were the subject of the lawsuit described below. Most of the materials and supplies that Affiliated purchased on the ABC account were for specific roofing projects. But some, as Millman acknowledged in his testimony, were to maintain roofing materials in the Affiliated warehouse. He used these on small jobs and to supplement materials purchased for larger, specific jobs. All the goods and materials purchased related to Millman’s practice of the roofing contracting profession. In 2007 Millman and Affiliated started having financial difficulties. Millman’s business began failing. The failure of a lender that took over a construction project it was financing resulted in the lender not paying Millman for approximately $500,000 worth of his company’s work. This contributed to Millman’s business failure. In addition to Millman’s problems paying ABC, his landlord was evicting him. Millman worked hard during these difficulties to meet his obligations to ABC. He liquidated his Individual Retirement Account and his life savings to make sure he paid for all charges for supplies used for specified customers. He did this to protect customers from the risk of liens being placed on their properties. Millman advised ABC that he was being evicted from his warehouse. He told ABC that the warehouse contained materials obtained with his line of credit that had not been paid for. Millman did not have the ability to return the materials to ABC. As eviction neared, he urged ABC to retrieve the materials before eviction. ABC did not act to retrieve the materials. The landlord evicted Millman. What happened to the materials is not known. On March 4, 2008, ABC sued Millman and Affiliated in the Circuit Court of the Fifteenth Judicial Circuit in and for Palm Beach County, Florida. ABC sought payment for goods and materials purchased on the account and delivered to Millman and Affiliated between January 31, 2007, and January 31, 2008. The court assigned the action Case Number 50 2008 CA 006245 XXXX MB. The goods and materials for which ABC sought payment were roofing goods and materials. They included roofing felt, roofing cement, shingles, plywood, lumber, roofing nails, lead sheets, insulation, roof tile cement, lead boots for pipes, roofing paint, asphalt, and galvanized roof edging. Much, although not all, of the material was delivered to roof tops. Many invoices for the material describe the roof for which the material is intended by height and pitch. The goods and materials related to Millman’s profession of roofing contractor. On June 17, 2008, barely three months after ABC filed suit, Millman entered into a Stipulation for Payment with Judgment upon Default with ABC. Millman agreed in the Stipulation for Payment with Judgment upon Default, that both he as an individual and Affiliated are indebted to ABC in the amount of $45,617.02. This amount included interest, attorney’s fees, and costs. The stipulation included a schedule of eight payments starting with a payment of $2,500.00 on May 30, 2008, and ending with a payment of $22,720.02 on December 30, 2008. Millman made payments from January 1, 2007, forward, even during and after the collection litigation. Millman made over $16,000.00 of those payments. But he did not make all of them. As Millman made payments, he took care to designate payments for supplies allocated to a specific customer and job. He did this to protect his customers from liens and to make sure that documents he signed attesting that supplies for specific jobs had been paid for were honest and correct. On August 3, 2009, the court rendered a Final Judgment After Stipulation in ABC’s collection action. The court adjudged that ABC recover $29,617.02 together with interest at the rate of 11 percent per annum accruing from May 31, 2008, from Affiliated and Millman, jointly and severally. The judgment is for debt incurred relating to Millman’s practice of his licensed profession of roofing contracting. It is not related to Millman’s licensed profession of general contracting. ABC continued to actively pursue collecting the judgment. It garnished Millman’s bank account with Bank Atlantic and obtained $662.61. Millman and Affiliated have not fully satisfied the judgment within a reasonable period of time. The Department incurred $216.00 in costs for the investigation and this action.
Recommendation Based on the foregoing Findings of Fact and Conclusion of Law, it is recommended that the Department of Business and Professional Regulation, Construction Industry Licensing Board, enter a final order finding that Respondent, Harris M. Millman, violated Section 489.129(1)(q), Florida Statutes, and imposing the following penalties: Payment of an administrative fine of $500.00 within 180 days of entry of the final order. Payment of costs of investigation and prosecution in the amount of $216.00 within 180 days of entry of the final order. DONE AND ENTERED this 27th day of August, 2010, in Tallahassee, Leon County, Florida. S JOHN D. C. NEWTON, II Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 27th day of August, 2010.
The Issue The issues in this case are whether Respondent, Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., committed the offenses alleged in a four-count Administrative Complaint filed with Petitioner, the Department of Business and Professional Regulation, on January 4, 2008, and, if so, what penalty should be imposed.
Findings Of Fact Petitioner, the Department of Business and Professional Regulation (hereinafter referred to as the "Department"), is the agency of the State of Florida charged with the responsibility for, among other things, the licensure of individuals who wish to engage in contracting in the State of Florida; and the investigation and prosecution of complaints against individuals who have been so licensed. See Chs. 455 and 489, Fla. Stat. Respondent, Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., is and has been at all times material hereto a certified roofing contractor in Florida, having been issued license number CCC 1326506 by the Construction Industry Licensing Board (hereinafter referred to as the “Board”). At all times material hereto, the status of his license has been "Current, Active." At all times material, Mr. Ringold was certified as doing business as Alpha Restoration, Inc. (hereinafter referred to as "Alpha"), a Florida corporation. At the times material, Mr. Ringold was the qualifying agent for Alpha, which possesses a certificate of authority as a contractor qualified business in Florida, license number QB 40272. Alpha’s license was issued May 5, 2005, and it is scheduled to expire August 31, 2010. On or about November 7, 2005, Alpha, through its employee Harry Youdell, met with Jose Fons at Mr. Fons’ residence located at 9922 Southwest 2nd Terrace, Miami, Florida (hereinafter referred to as the “Residence”), to inspect the roof on the Residence. Mr. Fons had not been successful in obtaining approval from his insurance company for replacement of the hurricane-damaged roof. Alpha represented that it would assist Mr. Fons in negotiating with his insurance company to obtain approval for replacement of the roof, which Mr. Fons authorized, in writing, Alpha to do. On January 15, 2006, Mr. Fons and Alpha entered into a written agreement (hereinafter referred to as the “Contract”) whereby Alpha agreed to install a metal tile roof on the Residence in exchange for payment of $27,187.02, with possible increases for “additional payments & supplements,” from Mr. Fons. The Contract provided for a 50 percent material deposit to be paid to Alpha. By check dated January 15, 2006, Mr. Fons paid the 50 percent deposit totaling $13,600.00 to Alpha. At the time the Contract was entered into, Alpha told Mr. Fons that a permit would be applied for the following week and that construction would commence in February. Although there was unsubstantiated hearsay that Mr. Fons was informed that the metal tile roof Mr. Fons was purchasing had not been approved for use in Miami-Dade County, Mr. Fons credibly denied being so informed. The credible, non-hearsay evidence supports a finding that Mr. Fons was not immediately informed that metal tile roofs were not authorized in Miami-Dade County. Despite not providing written or verbal authorization to Alpha to wait more than 30 days after execution of the Contract to apply for the permit for the roof work, no permit was applied for by Alpha for the Residence roof work within 30 days after January 15, 2006. Nor did Alpha commence work of any kind on the project in January or February 2006. During the first week of March, having heard nothing more from Alpha, Mr. Fons called Alpha and inquired about the status of the project. Mr. Fons was told by Mr. Youdell that the metal tile roof had not been approved by the Miami-Dade Building Department (hereinafter referred to as the “Building Department”). Mr. Youdell told Mr. Fons it would take another 30 days to obtain a permit. As of April 2006, Alpha had not commenced work or contacted Mr. Fons. Therefore, Mr. Fons called and spoke to Mr. Youdell about the status of the project. Mr. Fons was again told that the metal tile roof had not been approved and that testing of the roof would take another 30 days. In fact, Alpha had not made application for any permit for the Residence roof job through April 2006. On May 11, 2006, approximately 114 days after receiving Mr. Fons’ deposit, Alpha finally submitted an application for the permit with the Building Department. The application was designated C2006169450 by the Building Department. In May 2006, Mr. Fons again contacted Alpha to inquire about the project, since no work had been started and he had not heard from Alpha. For the third time, Alpha told Mr. Fons that the roof had not gained approval from the Building Department and that another 30 days was needed. In June 2006, Mr. Fons again contacted Alpha. Work on his roof had not started and he had not heard from Alpha. Not surprisingly, Mr. Fons was told for the fourth time that the roof had not gained approval and there would be another 30-day delay. Mr. Fons, who was becoming frustrated with the delay, visited the Building Department and inquired about the project. He learned that Alpha had not applied for a permit until May 2006 and was told that the Building Department had “denied” it on May 16, 2006. Mr. Fons was not told by the Building Department that, despite the “denial,” the permit application remained open. By July 2006, Alpha had still not commenced work. Therefore, Mr. Fons contacted Alpha and requested a meeting to discuss alternatives to the metal tile roof. Obviously, Mr. Fons was aware that metal tile roofs were not approved for use in Miami-Dade County since entering into the Contract. While no work had commenced from January 15, 2006, when the written agreement was entered into and the deposit was made, through July 2006, Mr. Fons effectively agreed to wait for Alpha to attempt to gain approval for the metal tile roof from the Building Department. Having obtained Mr. Fons’ approval, Alpha could not have commenced work on the project through July 2006. On July 17, 2006, Alpha, through Mr. Youdell, met with Mr. Fons at the Residence. Because of the delays that had been caused by the failure of Alpha to gain approval of the metal tile roof from the Building Department and with assurances that the contract price would be the same, Mr. Fons agreed to accept, and Alpha agreed to provide, a tile roof. Alpha represented to Mr. Fons that the tile roofing material was in-stock, that a permit would be obtained within a week, and that construction would commence by mid-August 2006. Between July 25, 2006, approximately a week after the July 17, 2006, meeting, and August 7, 2006, Mr. Fons monitored the Building Department’s web-site to see if Alpha had applied for a permit for the tile roof. When there was no indication that the permit had been applied for, Mr. Fons called Alpha on August 8, 2006. Mr. Youdell told him that the permit had been applied for and it had not appeared in the computer system because the Building Department was backlogged. Mr. Youdell told Mr. Fons that Alpha would be at the Residence in ten days to at least clean up debris. As of August 18, 2006, no new permit had been applied for and no one from Alpha had been to the Residence. Consequently, Mr. Fons wrote and delivered a letter by facsimile addressed to Mr. Ringold, stating, in part, the following: After months of dealing with you, this is my formal request for a full refund of $13,600 paid to you January 15, 2006, with my personal check #6408. Said amount was a deposit for the contract for the replacement of the roof at my residence located at 922 SW 2 Terrace, Miami, FL. As you are aware of, Florida Statutes 489.126 demands that you apply for the necessary permits within 30 days after the initial payment (my payment to you on 1-15- 06 $13,600). Please do not call me, from now on all communications will be done in written form. If you fail to refund my deposit within 10 days, please be advised that I will file a complaint . . . . Since we are now in August, and you have not commenced work at my residence, this is my demand letter for a check in full refund of my deposit within 10 days of receipt of this letter. On August 24, 2006, after having received Mr. Fons’ August 18, 2006, letter, Alpha submitted an on-line application for a tile roof for the Residence. The matter was designated W2006262830. This permit application was not approved because Alpha failed to complete the application process. When he did not receive a response to his August 18, 2006, letter, Mr. Fons wrote a second letter to Alpha, which was mailed by certified mail on or about September 4, 2006. In the second letter, Mr. Fons indicated that the ten-day deadline set out in his previous letter had passed without response and he again requested the return of his deposit. On September 3, 2006, the original metal tile roof permit application was rejected by the Building Department. On September 8, 2006, the permit application, having been converted from a metal roof to a tile roof, was approved and issued as permit number 2006126043. On September 6, 2006, after Alpha had applied for and obtained a permit, Mr. Fons finally received a written response from Alpha to his August 18, 2006, letter. In the response, Mr. Ringold suggests the following: “At the signing of your contract you were aware that ‘Metro Steel Tile’ did not have Miami Dade approval and you were willing to wait for such to be approved. This made securing a permit in 30 days impossible and you were completely aware of that at the time.” Mr. Ringold’s understanding of Mr. Fons’ “understanding” has not been substantiated by the evidence presented in this case, and is, therefore, rejected. Mr. Ringold goes on to accurately suggest that Mr. Fons and Alpha had modified the agreement in July, when it was agreed that a tile roof would be placed on the Residence. Mr. Ringold then suggests that any delay in applying for a permit after July was due to the need to ensure that the tiles were delivered, facts Mr. Fons was not previously apprised of. Mr. Ringold ends the letter as follows: We have confirmed that your tile is acquired and have applied for your permit. Had we been informed that you were so concerned that your permit be pulled immediately we would have been more than happy to do so. We never worry about getting the permit in Dade County as they are very effective in issuing permits in a timely manner [a fact which Mr. Youdell was apparently not aware of, given his representation to Mr. Fons that the Building Department was back logged]. I do not understand the reason for the letter? We sincerely have always had your best interest at heart, and want to proceed with the install. I am confident that you will be pleased with the finished product. Please if you would contact me directly at . . . to discuss this matter. On September 11, 2006, Mr. Fons found a copy of permit number 2006126043, issued on September 8, 2006, on the door of the Residence. Other than a letter from Mr. Fons to Alpha dated October 23, 2006, requesting a list of subcontractors and suppliers used by Alpha, there was no further correspondence between Alpha and Mr. Fons. Nor did Alpha make any effort to fulfill its obligations under the Contract. Ultimately, permit number 20066126043, issued September 8, 2006, was cancelled based upon a February 7, 2007, request from Alpha. No work took place on the project for more than 90 days after the permit was issued. Based upon the foregoing, more than six months passed after the Contract was entered into without any work being performed by Alpha: January 15, 2006, to July 17, 2006. While the evidence failed to prove that Mr. Fons was fully informed at the time the Contract was entered into that the metal tile roofing he had selected was not approved for use in Miami-Dade County and, therefore, securing a permit would take some time to acquire, he was eventually informed of these facts. Ultimately, Mr. Fons acquiesced to the delay in commencing work between January 15, 2006, and July 17, 2006, when Mr. Fons and Alpha agreed to a modification of the Contract; in particular, to replace the roof on the Residence with a tile roof. There was, therefore, no “abandonment” of the project between January and July 2006. Between July 17, 2006, and February 2007, a period of eight months, no work was performed on the project. In fact, after early September 2006 there was no meaningful communication between Mr. Fons and Alpha. Viewing the evidence most favorably to Alpha, Alpha had informed Mr. Fons in a letter he received on September 6, 2006, that the tiles were available (the evidence failed to substantiate this claim; if the tiles had been “available” they would have been delivered directly to the Residence), the permit had been obtained, Alpha indicated its willingness to fulfill its obligation, and Alpha attempted to place the ball in Mr. Fons’ court by asking that he call to discuss the matter, and Mr. Fons had demanded a return of his deposit. Viewing the evidence most favorably to Mr. Fons, he had been waiting for eight months to have his roof repaired; he had on a monthly basis had to initiate contact with Alpha and every time he did, was told “it will be another 30 days”; Alpha had taken until May 2006 to make its first application for a permit, despite the fact that Alpha had represented to Mr. Fons that the permit would be obtained in January and that work would commence in February, the monthly representations that the permit had been applied for but was being held up by the Building Department. After renegotiating his contract, Mr. Fons was again told that the permit would be pulled within a week and that work would commence within a month. Despite these representations, no permit was applied for until after his August 18, 2006, letter was received and that permit was never approved. When Mr. Fons did finally complain and request the return of his deposit, although it had only been a month since renegotiating the type of roof to be placed on the Residence, Alpha did not respond until September 6, 2006, and only responded after finally obtaining a permit. Given these circumstances, the suggestion of Alpha that “[w]e sincerely have always had your best interest at heart, and want to proceed with the install” must have seemed disingenuous to Mr. Fons. Weighing the foregoing facts, it is ultimately found that simply “offering” to proceed, despite Mr. Fons’ demand for the return of his deposit, was simply too little, too late. Given the total eight-month delay in the project and all the misinformation Mr. Fons had been given by Alpha, and especially in light of the fact that Alpha had $13,600.00 of Mr. Fons’ money for which it had performed no work whatsoever, Alpha should have done more to attempt to fulfill the contract. Failing to do more under these circumstances constitutes an abandonment of the project to the financial detriment of Mr. Fons. On February 21, 2007, Mr. Fons contracted with another company to install a tile roof on the Residence. Work commenced February 23, 2007, and was completed March 5, 2007. Mr. Fons has suffered a loss of $13,600.00 as result of Alpha’s failure to fulfill its obligations under the Contract. The total costs of investigation incurred by the Department in this case, excluding costs associated with any attorney time, was $342.42.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding that Douglas J. Ringold, Jr., d/b/a Alpha Restoration, Inc., violated the provisions of Section 489.129(1)(g)2., (i), (j), and (m), Florida Statutes, as alleged in Counts I, II, III, and IV of the Administrative Complaint; imposing fines of $1,500.00 for Count I, $500.00 for Count II, and $2,500.00 for Count III; requiring that Mr. Ringold make restitution to Mr. Fons in the amount of $13,600.00; requiring that Mr. Ringold pay the costs incurred by the Department in investigating and prosecuting this matter; and placing Mr. Ringold’s license on probation for a period of one year, conditioned upon his payment of the fines, restitution to Mr. Fons, payment of the costs incurred by the Department, and any other conditions determined to be necessary by the Board. DONE AND ENTERED this 10th day of February, 2009, in Tallahassee, Leon County, Florida. LARRY J. SARTIN Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 10th day of February, 2009. COPIES FURNISHED: Brian P. Coats, Esquire Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street, Suite 42 Tallahassee, Florida 32399-2022 Paul Buschmann, Esquire Hinshaw & Culbertson, LLP One East Broward Boulevard, Suite 1010 Fort Lauderdale, Florida 33301 W. Harrell, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Ned Luczynski, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
