The Issue Whether Respondent committed the offenses described in the administrative complaints filed against him? If so, what discipline should he receive?
Findings Of Fact Based upon the record evidence, the Hearing Officer makes the following findings of fact: General Information Edward Ryan is now, and has been since October, 1973, licensed as a Building Contractor by the State of Florida. He holds license number CB 0006481. Ryan has previously been disciplined by the Florida Construction Industry Licensing Board (Board). In July, 1987, prior to the issuance of the instant administrative complaints, he received a letter of reprimand from the Board. The Department of Professional Regulation has recently received additional complaints concerning Ryan. These complaints are currently under investigation. Ryan has been the qualifying agent for Gulf Chemical Contractors, Inc. (Gulf) since August, 1982. All ten of the instant administrative complaints involve projects undertaken by Gulf in Dade County, Florida. The South Florida Building Code (Code) has been adopted as the building code for both the incorporated and unincorporated areas of Dade County. The Code provides in pertinent part as follows with respect to the requirement of permits: It shall be unlawful to construct, enlarge, alter, repair, move, remove or demolish any building structure, or any part thereof; or any equipment, device or facility therein or thereon; or to change the Occupancy of a building from one use Group to another requiring greater strength, means of egress, fire and sanitary provisions; or to install or alter any equipment for which provision is made or the installation of which is regulated by this Code; without first having filed application and obtained a permit therefor, from the Building Official, validated by payment there for. EXCEPTION: No permit shall be required, in this or any of the following Sections, for general maintenance or repairs which do not change the Occupancy and the value of which does not exceed one hundred dollars ($100.00) in labor and material as determined by the Building Official. The Code further requires that the permit holder or his agent notify the Building Official of the completion of the project and call for an inspection of the work completed. Another requirement of the Code is that products such as air vent systems receive official approval from the appropriate Building Official prior to their installation. An experienced building contractor like Ryan doing business in Dade County should be aware of these requirements and should know that it is the responsibility of the general contractor of a project to make sure that these requirements are met. Case No. 89-2204 On May 2, 1987, Helana Lau and her husband entered into a written contract with Gulf. Gulf agreed to perform work on the Lau residence located at 2400 S.W. 15th Street in Miami, Florida, for which it was to be paid, pursuant to the terms of the contract, $11,450.00 by the Laus. The work that was to be performed on the structure included, among other things, the replacement of the roof and "any rotted wood on facia and soffits" and the installation of a "filter vent system." Gulf installed an aluminum air vent system for the Laus. The product used by Gulf had not received official approval prior to its installation as required by the South Florida Building Code. Furthermore, it posed a potential safety hazard. No official inspection of the contract work performed by Gulf on the Lau residence has ever been requested, notwithstanding that Gulf has long since terminated its work in connection with the project and vacated the jobsite. Case No. 89-2205 On December 29, 1986, Marvin Lichtenstein entered into a written contract with Gulf. Gulf agreed to texture coat Lichtenstein's home located at 2080 N.E. 171st Street in North Miami Beach, Florida. Pursuant to the terms of the contract, Gulf was to be paid $4,000.00 by Lichtenstein for performing this work. The contract contained a handwritten notation that "finances will be appr 10-11%" and that therefore Lichtenstein would have "a monthly payment of appr $71 or less" on the unpaid balance, which was $3,900.00. The contract also contained the following provision, which unlike the aforementioned notation was printed: This is an agreement by the parties mentioned herein to enter into an installment loan contract. The Purchaser requests that the Seller and the Seller's agents make the appropriate inquiries into the Purchaser's credit history and into the condition of the Title of the Property to be encumbered. The purpose of these inquiries is to see if the Seller may be able to arrange financing of the unpaid cash balance and what the terms of that financing may be. The purchaser agrees to accept any Home Improvement Contract presented by or thru the Seller, that has an interest rate less than the maximum current interest mentioned in the Florida Retail Installment & Sales Acts. The Purchaser agrees that all cost incurred by the Seller in connection with the payment plan will be paid by the Purchaser if the Purchaser refuses to accept that Home Improvement Contract. The work was performed by Gulf on the Lichtenstein home during the second week of January, 1987. Although a permit was required under the Code, it was not obtained prior to the commencement of the project or at any time thereafter. Furthermore, no official inspection of the work completed by Gulf has been requested. Following the completion of the work, Lichtenstein received from AmSav Financial, Inc., an Advance Notice of Acceptance and Intent to Purchase an FHA Title I Note. The document, which was dated January 14, 1987, provided Lichtenstein with the following information: We have found your credit to be satisfactory for a loan in the amount of $3,900.00 for a period of 60 months. Interest at a rate of 14.50% will be charged on the unpaid principal balance. Monthly payments will be $92.82. It is our intention to disburse the funds to the above mentioned dealer [Gulf] when all necessary documents, including a completion certificate indicating the work has been satisfactorily completed are received in proper order; but not earlier than six days from this date. It is not our policy to inspect all improvement projects we finance, so we want you to know that the selection of the contractor and the acceptance of workmanship and materials is your responsibility. You should insist on a copy of all instruments you sign and you should not sign the completion certificate until the contract has been fulfilled to your satisfaction. Contractors are not permitted to give cash rebates from the proceeds of this transaction nor are they permitted to make any payments for you nor any other type of incentive to buy. This commitment is good for 60 days only. If you have any questions regarding this transaction, or if we can be helpful in any way, please let us hear from you within six days from this date. Lichtenstein refused to accept this financing arrangement and, because he was dissatisfied with the work Gulf had done, withheld payment. He eventually settled this dispute with Gulf and paid the company $2,500 in accordance with the terms of the settlement agreement. Case No. 89-2206 On or about July 11, 1987, Al Childress, the supervisor of the Code Enforcement Section of the Dade County Building and Zoning Department, received a complaint regarding work purportedly done by Gulf on the Rojas residence located at 18105 N.W. 5th Court in Dade County, Florida. Childress thereafter inspected the premises and discovered that a three-ton air conditioning unit had been installed without a permit first having been obtained. He further ascertained that no formal inspection of the installed unit had been requested. Childress subsequently issued Gulf citations for "unlawfully commencing work on a[n] air conditioning installation without a permit" and "unlawfully contracting for work outside the scope of the certificate of competency." Case No. 89-2207 On January 12, 1987, Bryan Bitner entered into a written contract with Gulf. Gulf agreed to remodel and renovate the kitchen and other parts of the Bitner residence located 571 N.E. 175th Terrace in North Miami Beach, Florida. Pursuant to the terms of the contract, Gulf was to be paid $10,216 by Bitner. Work on the project began on February 14, 1987, and ended on April 20, 1987. Although given the opportunity to do so by Bitner, Gulf failed to finish the work it had agreed to perform and, without justification or notice, abandoned the project after having completed only 70% of the kitchen cabinetry work specified in the contract. Neither before nor after the commencement of work on the project were the required building, electrical and plumbing permits obtained. No official inspections of the work done in connection with the project have been requested. Case No. 89-2208 On December 19, 1985, Anthony and Anna Rabeck entered into a written contract with Gulf. Gulf agreed to perform roofing work on the Rabeck's home located at 447 East 7th Street in Hialeah, Florida, for which it was to be paid, pursuant to the terms of the contract, $2,792.00 by the Rabecks. Gulf thereafter subcontracted with Louis Rusty Gordon of Rusty's Roofing to perform work on the project. Gordon performed the work, but was not paid the $600.00 Gulf had agreed to pay him. He therefore filed a lien on the Rabeck's residence in the amount of $600.00 and filed a complaint against Gulf and the Rabecks in Dade County Circuit Court seeking a $600.00 judgment against them. Gordon was ultimately paid the $600.00 by the Rabecks. A roofing permit was never obtained for the work that was done on the Rabeck residence. Furthermore, no official inspection of the work has ever been requested. Case No. 89-2209 On February 21, 1987, James Cox entered into a written contract with Gulf. Gulf agreed to texture coat and to add a screened porch to the Cox residence located at 11621 S.W. 183rd Street in Dade County, Florida. For this work, Gulf was to be paid, pursuant to the terms of the contract, $5,700.00 by Cox. The texture coating was completed in late March, 1987. The screened porch was finished in early April, 1987. Upon completion of the entire project, Cox paid Gulf in full in accordance with their contractual agreement. Although a permit was necessary to commence the work on the Cox residence, it was never obtained. In addition, no one requested that the completed work be officially inspected. The screened porch was constructed by a subcontractor, Steve Buzzella. Prior to his undertaking this project, Gulf had agreed to pay him $2,200.00 for such work. Although he satisfactorily completed the project, Gulf did not pay him for his work. Consequently, he filed a lien on the Cox residence in the amount of $2,200.00. Buzzella has yet to be paid the money he is owed by Gulf and the lien remains in effect. Cox has retained legal counsel to assist him in connection with this matter and has already paid $175.00 in legal fees. Case No. 89-2210 On June 30, 1986, Adele Spiegel and her husband David entered into a written contract with Gulf. Gulf agreed in the contract to, among other things, texture coat the Spiegels' residence located at 7380 S.W. 116th Terrace in Dade County, Florida. Pursuant to the terms of the contract, Gulf was to be paid $4,500.00 by the Spiegels. The contract further provided that the Spiegels were to receive a "15 year warr[anty] on [the] tex[ture] coat[ing]" work. It also contained the following provision: Contractor guarantees that all materials furnished by it will be of standard quality, type and condition, free from defects, and will be installed, built or applied in a good workmanlike manner; said labor and materials guaranteed against structural and material defects. Gulf completed the project without obtaining the required permit. Furthermore, no official inspection of the completed project was ever requested. The Spiegels paid Gulf in full for the work it had done. The last of their payments was made on July 10, 1986, following the completion of the project. After this final payment was made, "dark stains" appeared on portions of the texture coating that had been applied to the gable end of the Spiegels' roof. In addition, some of the texture coating started to peel and crack. These problems were caused by the improper application of the texture coating. The Spiegels have advised Gulf of these problems. They have made numerous efforts to have Gulf honor its fifteen-year warranty and correct these problems. These efforts have been to no avail. Gulf has yet to take any corrective action, notwithstanding its obligation to do so under the warranty it gave the Spiegels. Case No. 89-2211 On February 18, 1985, Angelo Bertolino entered into a written contract with Gulf. Gulf agreed to texture coat Bertolino's residence located at 11730 S.W. 175th Street in Dade County, Florida. For this work, Gulf was to be paid, pursuant to the terms of the contract, $3,000.00 by Bertolino. Bertolino received from Gulf, as part of their agreement, a fifteen-year warranty on the texture coating similar to the one that the Spiegels were given. Assurances were given to Bertolino that any warranty work that was necessary would be done by Gulf. The Bertolino home was texture coated shortly after the contract was signed. In July, 1987, the texture coating began to crack and peel. Bertolino immediately contacted Gulf to apprise it of the situation and to request that it perform the necessary repairs in accordance with the terms of the warranty it had given him. Receiving no response from Gulf to this initial request, he telephoned the company's offices on almost a daily basis until September, 1987, when a Gulf representative came to his home and did some corrective work. A month later, the area that had purportedly been repaired started to again crack and peel. Bertolino has made Gulf aware of the situation and has sought on numerous occasions to have the company perform the warranty work necessary to correct these problems. Gulf has ignored these requests and failed to honor the warranty it gave Bertolino. Case No. 89-2212 On January 6, 1988, Edward Baum entered into a written contract with Gulf. Gulf agreed to texture coat Baum's residence located at 10921 S.W. 120th Street in Dade County, Florida. For this work, Gulf was to be paid, pursuant to the terms of the contract, $3,200 by Baum. The project was completed on January 13, 1988. Upon completion of the work, Baum paid Gulf in full. Textured Coatings of America, Inc. (TCA) supplied Gulf with $583.28 of materials that were used to complete the project. The materials were supplied on credit. Because it had not received payment for these materials, TCA, on March 4, 1988, after giving due notice to Gulf and Baum, filed a lien on Baum's residence in the amount of $583.28. TCA has yet to be paid for these materials and the lien is still in effect. Case No. 89-2213 On February 17, 1987, James Harris entered into a written contract with Gulf. Gulf agreed to install new windows in Harris' residence located at 9730 S.W. 167th Street in Dade County, Florida, for which it was to be paid, pursuant to the terms of the contract, $2,503.20 by Harris. The windows were installed in one day. Although one was needed, no permit was obtained prior to the completion of the project. Furthermore, no official inspection of the completed work has ever been requested. The windows were not installed properly. As a result, they do not close and lock as they should. Harris must put cement blocks on the outside ledges in front of some of the windows and then tape these windows shut to prevent them from falling open. Harris has unsuccessfully sought to have Gulf repair the windows.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Construction Industry Licensing Board enter a final order (1) finding Respondent guilty of the violations described in paragraph 7, 8, 11, 12, 14, and 16-24 of the foregoing Conclusions of Law; (2) revoking his license as punishment for these violations; and (3) dismissing the charges against Respondent discussed in paragraphs 9, 10, 13, and 15 of the foregoing Conclusions of Law. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 8th day of September, 1989. STUART M. LERNER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 8th day of September, 1989. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 89-2204 THROUGH 89-2213 The following are the Hearing Officer's specific rulings on the Proposed Findings of Fact submitted by the Department: 1-12. Accepted and incorporated in substance, although not necessarily repeated verbatim, in this Recommended Order. First sentence: Accepted and incorporated in substance; second sentence: Rejected as not supported by persuasive competent substantial evidence inasmuch as it suggests that Lichtenstein was obligated to, and did, make monthly payments of $92.82. Rejected for the same reason as 13, second sentence, above. 15-16. Accepted and incorporated in substance. First sentence: Accepted and incorporated in substance; second sentence: Rejected as not supported by persuasive competent substantial evidence to the extent that it asserts that Rojas "had hired Gulf to install an air conditioning unit." Insofar as it describes the complaint received by Childress, it has been accepted and incorporated in substance. Rejected as not supported by persuasive competent substantial evidence inasmuch as it indicates that the work on the Rojas residence was performed by Respondent. First and second sentences: Accepted and incorporated in substance; third sentence: Rejected as more in the nature of argument than a finding of fact. First sentence: Rejected for the same reason as 18 above; second sentence: Accepted and incorporated in substance. Rejected for the same reason as 18 above. 22-28. Accepted and incorporated in substance. Rejected as beyond the scope of the charges to the extent that it addresses the quality of the work that was completed. In all other respects, this proposed finding has been accepted and incorporated in substance. First sentence: Accepted and incorporated in substance; second sentence: Rejected as not supported by persuasive competent substantial evidence. 31-32. Accepted and incorporated in substance. 33-34. Rejected as not supported by persuasive competent substantial evidence inasmuch as both of these proposed findings are based upon the premise that the Rabeck's paid Gulf in full. 36-44. Accepted and incorporated by reference. 45. Rejected as unnecessary, except for the last sentence, which has been accepted and incorporated in substance. 46-62. Accepted and incorporated in substance. 63. Rejected as unnecessary except to the extent it references the lien filed against the Baum residence. Insofar as it addresses said lien, it has been accepted and incorporated in substance. 65-66. Accepted and incorporated in substance. 67. First sentence: Rejected as unnecessary; second and third sentences: Accepted and incorporated in substance. 68-71. Accepted and incorporated in substance. COPIES FURNISHED: Gregory A. Victor, Esquire Jan L. Darlow, Esquire William Burke, Esquire Bayview Executive Plaza 3225 Aviation Avenue, Suite 400 Miami, Florida 33133 Edward Ryan 169 Lincoln Road Miami Beach, Florida 33139 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
The Issue The issue presented is whether Respondent committed the offenses alleged in the administrative complaint, and, if so, what penalty should be imposed.
Findings Of Fact At all times material hereto, Respondent, John Arena, was a certified residential contractor, the qualifying agent for Classic Industries, Inc. and held license number CR C021139 from the Florida Construction Industry Licensing Board. The President and sole owner of Classic was Anthony Manganelli. Mr. Manganelli was also the manager of Classic and the principal from whom Mr. Arena received his information about the contracts entered into by Classic. On or about July 30, 1988, someone contacted Ms. Solange Gaston of Hollywood, Florida, by telephone, and asked her if her roof needed repair. The solicitor represented himself as an associate of Classic and offered to come out and inspect her roof. Ms. Gaston, believing her roof was in disrepair, agreed to have the inspection completed and entered into a contract with Mr. Carlo Mangano, representing himself as an agent of Classic, to do the repair. With Ms. Gaston's agreement, the tile on her roof was replaced with shingle roofing and certain other repairs were attempted. A letter to Petitioner from the Chief Permit Processor of the City of Hollywood, Florida indicates that no roofing permit was issued for Ms. Gaston's address. The roof was leaking prior to the repair and continues to leak. Ms. Gaston paid the complete contract price of $3,500 to Classic, but has been unable to locate Mr. Mangano or to have her roof repair completed. In her attempts to achieve satisfaction, Ms. Gaston contacted Classic and asked to speak with someone in charge. She was under the impression that she was speaking with Mr. Arena; however, she never spoke to Mr. Arena. In fact, Mr. Arena was not aware of the contract with Ms. Gaston until the instant complaint was filed against him. Mr. Arena does not know Mr. Mangano. When Mr. Arena became aware of the problem, he attempted to contact Mr. Manganelli, but was told that Mr. Manganelli had moved. Ultimately, Mr. Arena located Mr. Manganelli at a new address. According to Mr. Arena, Mr. Manganelli produced a copy of what appeared to be a contract with Ms. Gaston which has the signature of Carlo Mangano on it, but it is marked indicating that Ms. Gaston's credit was turned down. Mr. Manganelli told Mr. Arena that Classic had not undertaken the job due to the refusal of credit. With that representation, Mr. Arena was under the impression that the work had not been done, as was the custom of dealing for Classic when credit was denied. The two papers purporting to be contracts, one which Ms. Gaston acknowledged as being the one which she signed and the other being the one which Mr. Arena obtained from Mr. Manganelli as the actual contract between Ms. Gaston and Classic through Mr. Mangano, appear to be altered. Although both documents contain the same information, including the date, parties, addresses, work to be completed and price quoted, the portion of the copy indicating the price is written in Arabic numerals on Mr. Arena's copy and by words on Ms. Gaston's copy. Mr. Arena's copy also has the indication that credit was turned down on it, although the cancelled checks paid to Classic by Ms. Gaston were received into evidence. It was Mr. Arena's arrangement with Mr. Manganelli that Mr. Arena was to be informed of every contract into which Classic entered. In this way, Mr. Arena knew which sites he was to supervise. Since he was not advised about the roofing job for Ms. Gaston, he made no attempt to supervise it and after he became aware that the credit for the job had been disallowed, he was under the reasonable impression that the job was not done by Classic. Further, he did not know Mr. Mangano, nor did he believe that Mr. Mangano had the authority to bind Classic. Mr. Arena believes that Mr. Mangano may have obtained a blank contract form of Classic and misrepresented himself to Ms. Gaston as an agent for Classic. Petitioner asserted, however, that Mr. Arena, nevertheless, was responsible for the job and that Classic did perform the job. Neither Mr. Manganelli nor Mr. Mangano were present or testified at the hearing. Given Mr. Arena's demeanor at the hearing and the conflicting and altered state of the alleged contract forms, Mr. Arena's testimony is deemed credible, and the proof failed to demonstrate clearly that Classic actually attempted to repair Ms. Gaston's roof or that Mr. Arena was responsible for the attempted repair.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is: RECOMMENDED that the Florida Construction Industry Licensing Board issue a Final Order dismissing the administrative complaint filed in this case against Respondent, John Arena. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 20th day of June, 1990. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of June, 1990. COPIES FURNISHED: Robert G. Harris Department of Professional Regulation 1940 North Monroe Street Suite 341 Tallahassee, Florida 32399-0792 John D. Arena 5961 Southwest 13th Street Plantation, Florida 33317 Fred Seely Executive Director Department of Professional Regulation Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 Kenneth D. Easley General Counsel Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792 =================================================================
The Issue Whether the certified general contractor's license of W. Bert Jones should be revoked.
Findings Of Fact By an Administrative Complaint filed October 27, 1976, the Florida Construction Industry Licensing Board sought to revoke the general contractor's license of W. Bert Jones alleging that the Respondent contractor entered into a contract with Mrs. Barbara Loewe to renovate her home and to add a room onto the back of the house; that the Respondent contractor was paid in full the contract price but the job was not completed and there were numerous building code violations. Respondent requested an administrative hearing. Pursuant to written agreements entered into between the Respondent and Mrs. Barbara Loewe of Tampa, Florida, Respondent agreed to renovate Mrs. Loewe's home and to add a room onto the back of the house. Mrs. Loewe, either by paying the Respondent directly or paying material suppliers, paid the full contract price. In June or July of 1975 the Respondent left the job contracted for partially or wholly incompleted as follows: the ceiling of the kitchen and drywall were in complete and the kitchen was not painted; the guest bathroom was not trimmed; two back rooms were incomplete. Inasmuch as the ceiling was left undone, it was not trimmed, the drywall was incomplete, the doorways were left uninstalled, and the paneling was incomplete; the bathroom had no toilet, no sink and no trim on the tub; in the master bedroom the ceiling was left sagging, there was no insulation in ceiling or walls, the door was untrimmed, siding was left partially undone and the windows weren't trimmed; holes were left unrepaired around the pipes in the home. The sum of Five Thousand Dollars ($5,000) was paid by St. Paul Fire and Marine Insurance Company in full settlement of the claims arising under the general contractor's bond. Additional money, approximately Thirty-Five Hundred Dollars ($3,500), was spent by Mrs. Loewe in addition to the Five Thousand Dollars ($5,000.00) received from the bonding company in order to complete the jobs contracted for. Although there were minimum changes In the job as originally contracted for, work is still going on to complete the original work contracted for by the Respondent. The building inspector for the City of Tampa Building Bureau, Tom Burgoyme, inspected the job site on several occasions during the progress on the work contracted for between Mrs. Loewe and the Respondent. He found building code violations and submitted a list of corrections to the Respondent, Mr. Jones, which were not remedied. A number of problems arose during the construction work, some of which was not the fault of the Respondent. Another contractor was involved in the work on the project. Funds in excess of the purchase price were paid to the Respondent and funds in excess of Eighty-Five Hundred Dollars ($8,500) were needed or will be needed to complete the project.
Recommendation Revoke the general contractor's license of Respondent, Number C GC007323. DONE and ORDERED this 7th day of April, 1977, in Tallahassee, Florida. DELPHENE C. STRICKLAND Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: J. K. Linnan Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211 Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 W. Bert Jones 2300 Greenlawn Street Brandon, Florida 33511
Recommendation It is recommended that the Florida Construction Industry Licensing Board dismiss the Respondent from further responsibility to answer to the Administrative Complaint. DONE and ENTERED this 25th day of August, 1976, in Tallahassee, Florida. CHARLES C. ADAMS Hearing Officer Division of Administrative Hearings 530 Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 1010 Blackstone Building 233 East Bay Street Jacksonville, Florida 32202 John W. Tanner, Esquire Suite One. 434 N. Halifax Avenue Daytona Beach, Florida 32018
Findings Of Fact Glen H. Curd is licensed by the Florida Construction Industry Licensing Board as a Building Contractor and holds license number RB 0022003. Following a hearing the Building Board of Appeals and Adjustments, Pasco County, Florida, on 4 September 1979 revoked Glen H. Curd's Certificate of Competency (Exhibit 1). Exhibit 1, the minutes of the September 4, 1979, meeting of the Building Board of Appeals and Adjustments, Pasco County, clearly indicates that this board revoked Curd's certificate on grounds of incompetence.
The Issue Whether Petitioner is entitled to licensure as a Certified Building Contractor or Residential Contractor.
Findings Of Fact Petitioner is a 44-year-old male. He was born and raised in Tallahassee, Florida. He is a high school graduate. Petitioner passed the examination for licensure as a certified building contractor. This is a comprehensive examination that is designed to test knowledge in all aspects of the construction industry. Passing it is a mandatory prerequisite before an application can be considered by the Florida Construction Industry Licensing Board (FCILB). However, passing the examination does not eliminate or modify the statutory or rule experience requirements. Petitioner submitted his application for a certified building contractor license on or about March 24, 2008. By letter of May 2, 2008, the Department of Business and Professional Regulation requested additional information. Petitioner then provided a revised affidavit from Chad Banks, a certified building contractor, and a letter from the Maintenance Construction Chief of the City of Tallahassee’s Gas Utility Department, each containing more detailed information about Petitioner’s experience. These items were received by Respondent on May 23, 2008. It is not clear whether Petitioner requested and was granted a continuance of his appearance with regard to the instant license application at an earlier FCILB meeting, but on January 15, 2009, the full Board considered Petitioner’s application at a duly-noticed public meeting in Altamonte Springs, Florida. At that time, Petitioner was present. During his appearance before the full Board on January 15, 2009, Petitioner was very nervous, but he believes that one of the Board members offered him, or at least asked him if he would accept, a residential contractor’s license in place of a certified building contractor’s license, and that he answered that he would accept such a license, only to have that “offer and acceptance” voted down by the full Board. However, Petitioner does not rule out the possibility that the vote taken at the meeting was actually with regard to denying the certified building contractor license for which he had applied. There is no evidence that Petitioner has ever submitted an application for a residential contractor’s license. By a Notice of Intent to Deny, dated March 16, 2009, and mailed March 24, 2009, the FCILB formally denied Petitioner’s application for a certified building contractor License stating: The applicant failed to demonstrate the required experience, pursuant to Section 489.111, Florida Statutes and Rule 61G4- 15.001, Florida Administrative Code. Petitioner seeks licensure as one who has four years of active experience and who has learned the trade by serving an apprenticeship as a skilled worker or as a foreman, at least one year of which experience is as a foreman. Petitioner has never worked as a full-time employee of a commercial or residential contractor. Petitioner got early experience in construction working around eight rental properties owned by his father. He performed light carpentry, deck construction, general handyman repairs, and some plumbing and roofing when he was approximately 16 to 21 years of age. However, Petitioner essentially relies on a work history that includes working as a plumber for Jim Bennett Plumbing from 1987 to 1993; as a foreman for the City of Tallahassee Gas Department from 1995 to 2005; as a “contractor trainee” for Chad Banks from 1999 to 2002; as having volunteered as superintendent for Gulf Coast Painting from 2003 to 2007; and as a maintenance man for the City of Tallahassee Parks Department from 2006 to 2007. Petitioner’s dates of employment overlap, because his volunteer experience was acquired mostly on weekends, holidays, in hours after he had already completed a full work day for the City of Tallahassee, or on “time off” from his regular employments with the City. Petitioner is a hard worker and wanted to learn the construction trade, but his volunteer construction jobs were intermittent, and he provided no clear assessment of the number of hours per week or month that he put in for any of them. From 1987 to 1993, Petitioner worked for Jim Bennett Plumbing. He started as a plumber’s helper and progressed to greater responsibility. In that position, he acquired a wide range of experience in plumbing for some residential, but mostly commercial, buildings. During this period, he also did some light cosmetic carpentry and tile work to restore building parts damaged by the installation of plumbing apparatus. Much of Petitioner’s construction experience relates to his association with Chad Banks, who testified that at all times material, Petitioner had “hands on” experience, working for him and that Petitioner was a competent worker. Petitioner has never been a “W-2 employee” of Mr. Banks, but there is no specific statutory or rule requirement that the experience necessary to qualify for the certified building contractor or the residential contractor license must be as a “W-2 employee.” Cf. Conclusions of Law. Mr. Banks was not licensed as a certified building contractor until 1999. Petitioner did some work for Mr. Banks when Mr. Banks was working as a sub-contractor on commercial projects (specifically one or more Super-Lube buildings) prior to Mr. Banks obtaining his certified building contractor’s license in 1999. Most of this employment involved pouring concrete slabs. Petitioner claims experience in “elevated slabs,” limited to the construction of a single Super-Lube building, which Petitioner described as laying a slab below ground level for mechanics to stand on and an at-ground level slab for cars to drive onto the lift for an oil change. He described no truly “elevated” slabs or floors above ground level on this project, and Petitioner’s and Mr. Banks’ testimony was vague as to Petitioner’s responsibilities on this project and as to the project’s duration. The general contractor on this project for whom Mr. Banks “subbed” did not testify. From this, and other employments, Petitioner has experience pouring foundation slabs, but he has never worked on a foundation slab in excess of 20,000 square feet. Petitioner also assisted in Mr. Banks’ construction of some rental sheds, but it is unclear if this was before or after Mr. Banks was licensed. Petitioner worked for Mr. Banks d/b/a C. B. Construction, Inc., in a volunteer capacity on exclusively residential construction from 1999 to 2002, and again from February 2004 to March 2008. During these periods, Petitioner and Mr. Banks considered Petitioner a “contractor trainee,” but Petitioner’s work for Mr. Banks was neither exclusive nor continuous; both men described it as “volunteer” work; and some of it seems to have amounted to Petitioner's looking over work done personally by Mr. Banks and having Mr. Banks explain to him, via a plan sheet, what Mr. Banks had already done personally. There is no evidence that during this time frame Petitioner worked for Mr. Banks as a foreman. Petitioner has the ability to “read” many types of construction “plans.” Petitioner has experience with slab footers, but he has not constructed red iron structural steel qualified for framing a building. Petitioner has experience in decorative masonry walls, but he has not constructed structural masonry walls of a type that would support framing members of a building or other vertical construction. Petitioner also worked for the City of Tallahassee as a “W-2” employee, mostly as a foreman overseeing a crew of four workers, from 1995 to 2005. In that capacity, he worked on a church, but the church itself had been constructed several years previously, and Petitioner’s crew’s contribution was tying-in several gas lines during a roadway development project and keeping all the utilities up and running during the project, while a private contractor worked on the church. With regard to the foregoing project and many others for the City Utilities Department, Petitioner directed a crew that built sidewalks and gutters or that tied these features into existing roadways and driveways. In that capacity, he often coordinated activities with residential contractors. Over his ten years’ employment with the City Utilities, Petitioner also directed a crew that exclusively created underground vaults for the housing and shelter of utility apparatus. However, none of his endeavors for the City Utilities involved vertical structural construction for floors above ground. Petitioner has also built new gas stations for the City’s natural gas vehicles, and has erected pre-fab utility buildings, including much slab work, but the nature and duration of these endeavors is not sufficiently clear to categorize them as qualifying him for the certified building contractor license. Most of Petitioner’s experience with the City, as substantiated by the letter of the City Utilities Maintenance Construction Chief, Mr. Lavine, has been in the construction of driveways, roads, gutters, storm drains, sidewalks, culverts, underground utility structures, plumbing and gas lines. While it is accepted that Petitioner has worked on such projects, this type of work more properly falls in the categories of “plumbing contractor” or “underground utility contractor” and Mr. Lavine was not demonstrated to have any certification/licensure in a category appropriate to Petitioner’s application. (See Conclusions of Law.) Sometime after 2005, for approximately a year, Petitioner was employed by the City of Tallahassee Parks and Recreation Department and in that capacity participated in at least one construction of a dugout and a concession stand at one of its playgrounds. He also did repairs on several dugouts and concession stands, but this latter work would not be classified as “structural” construction. Petitioner’s experience in precast concrete structures is limited to his work with gas utility structures, but does not include work on precast tilt walls, which are the type of walls that are constructed off-site, delivered to the job site, placed on the slab foundation, and raised in place as part of an on- going commercial building project. Petitioner has no experience in column erection. “Columns” in this context within the construction trade refers to supports for upper level structural members, which would entail vertical construction. Petitioner’s experience in concrete formwork does not include experience in the structurally reinforced concrete formwork that would be used in vertical buildings, such as all floors above ground level. FCILB’s Chairman testified that the Board interprets the type of experience necessary to comply with the statutes and rules, more particularly Florida Administrative Code Rule 61G4- 15.001(2), to be “structural experience.” There is no affirmative evidence that Petitioner has ever notified the Clerk of the Agency that he was relying on a right to a default license.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Florida Construction Industry Licensing Board enter a Final Order denying Petitioner’s application for licensure as a Certified Building Contractor. DONE AND ENTERED this 24th day of November, 2009, in Tallahassee, Leon County, Florida. S ELLA JANE P. DAVIS Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 24th day of November, 2009.
Findings Of Fact At all times material hereto, Respondent has been a registered residential contractor having been issued license number RR 0040275. In approximately 1980, Respondent entered into a contract to erect a screen room for a Mr. Lewis. Under the terms of the contract, Respondent was to obtain the necessary building permit. After the contract had been signed, Respondent's grandfather died, and Respondent therefore went to New Jersey. He left the permit application with his qualifying agent to sign and process through the building department. When Respondent returned from New Jersey approximately 30 to 35 days later, he went to the Lewis job site and found the project almost completed. Respondent did not check to ascertain if the permit had been obtained, but rather completed the screen room himself. Lewis subsequently contacted Respondent to say that he had received a notice of violation from the building department for erecting a screen room without a permit. Respondent contacted the building department and advised that it was not Lewis's fault, but rather that it was Respondent's responsibility to pull the permit. Respondent was charged with unlawfully erecting a screen room without a permit; he appeared in court and pled guilty; and he paid a $250 fine pursuant to the adjudication of guilt entered on April 20, 1981, in the County Court in and for Dade County, Florida, in Case No. 81-50438. On June 24, 1981, Respondent submitted to the Construction Industry Licensing Board a Contractor's Registration application. On that application, Respondent answered in the negative the following question: "Has any person named in (i) below ever been convicted of any offense in this state or elsewhere other than traffic violations?" At the time Respondent gave that answer, he believed it to be true. He understood the question to call for information on criminal acts and did not comprehend the "screen room" charge to have been criminal conduct. Since Respondent answered that question in the negative, his application for registration was processed in accordance with normal procedures. Had Respondent answered that question in the affirmative, his application would not have gone through normal processing but rather would have been presented to the Construction Industry Licensing Board for the Board's determination of whether to approve the application based upon a consideration of the facts. On November 22, 1982, Respondent contracted with Naomi Blanton to construct an addition to Blanton's home located in the City of Miami, in Dade County, Florida, for a contract price of $11,250. When Respondent had first met with Blanton several months earlier, he had told her he could guarantee completion of the project within 45 days. No contract was entered into at that time, however, since Blanton had not obtained the financing she needed in order to construct an addition. When the contract was signed on November 22, Respondent told Blanton he would start the job when he finished the Chamber of Commerce building he was con structing but that he was starting a 12-unit duplex project around Christmas and would not be able to guarantee any 45-day completion deadline. Accordingly, when the contract was signed, no completion date was included in the terms of that written contract, since Respondent did not know when he could guarantee completion. The Blanton contract written by Respondent specifically provided that Respondent would obtain the building permit. On December 22 and 23, 1982, two of Respondent's employees arrived at the Blanton job site, dug a trench, knocked down the utility room, and moved Mrs. Blanton's washing machine. No further work was done until January 1983. Since Respondent knew that he was required to obtain the building permit before commencing any construction work, Respondent submitted his plans and permit application to the City of Miami Building Department. After the plans had been there about a week, he was advised that his plans would not be accepted unless they were drawn by an architect, although that is not required by the South Florida Building Code. After attempting several more times to obtain approval from the City of Miami Building Department, Respondent hired an architect to redraw the plans and secure the building permit. By this time, Respondent found himself unable to concentrate on operating his business efficiently, since he was preoccupied with spending time with his father who was dying of cancer. Also by this time, Blanton had commenced telephone calls to Respondent on an almost daily basis as late as 11:00 p.m. at his office, at his home, at his mother's home, and at his father's home. Respondent offered to return Blanton's deposit, but she refused to cancel the contract and threatened Respondent that she would sue him if he did not comply with that contract. Respondent commenced working on the Blanton job, although no permit had yet been obtained. The contract on the Blanton job called for payments at certain stages of the construction. By January 27, 1983, Respondent had completed a sufficient amount of the work under the contract so that Blanton had paid him a total of $8,270 in accordance with the draw schedule contained in the contract. Respondent ceased working on January 27, 1983, and advised Blanton and her attorney that he would do no further work until he could obtain the building permit, which he had still not been able to obtain. Although he told them his work stoppage was due to his continued inability to obtain the permit, he also stopped work due to his father's illness and his continued inability to get along with Mrs. Blanton. A delay occurred with the plans being redrawn by the architect Respondent hired to obtain the Blanton building permit, since the architect needed information from Blanton and she was out of town. After Blanton returned, the architect made unsuccessful attempts to obtain the building permit. Respondent and his architect were finally able to speak to one of the top personnel in the City of Miami Building Department about the problems they were experiencing in obtaining a building permit, and, at about the same time, Blanton contacted that same individual to complain that Respondent had no permit. On May 4, 1983, the building department finally accepted the second permit application together with the plans drawn by the architect, and the building permit was issued on May 4, 1983. No work was performed on the Blanton job between January 27, 1983, when Blanton paid Respondent the draw to which he was entitled by that date, and May 4, 1983, when the building permit was finally issued by the City of Miami. Respondent immediately resumed work and quickly completed the next stage of construction called for under the Blanton contract. Upon completing that next stage, he requested his next draw payment; however, Blanton decided not to pay Respondent for the work completed and had her attorney advise Respondent not to return to the job site. Blanton then had a friend of her son come to Miami from Wisconsin to complete the addition to her home. At all times material hereto, Respondent held a certificate of competency issued by Metropolitan Dade County.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of violating Section 489.129(1)(d), Florida Statutes, by willfully and deliberately violating Section 301(a) of the South Florida Building Code; imposing an administrative fine against Respondent in the amount of $2,000 to be paid by a date certain; and dismissing the remaining charges contained in the Administrative Complaint, as amended, against Respondent. DONE and RECOMMENDED this 13th day of April, 1984, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of April, 1984. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Joseph F. Scioli, Jr. 246 North Krome Avenue Florida City, Florida 33034 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
Findings Of Fact Findings of Fact 1-13 are made based upon the Stipulation of the parties filed on July 10, 1987. Respondent is, and was at all times material to the pending amended administrative complaint, a certified building contractor having been issued license number CB CAO9793 by the Florida Construction Industry Licensing Board. At all times material the pending amended administrative complaint Respondent's certified building contractor license (CB CAO9793) qualified "George E. Longino and Associates, Inc." with the Florida Construction Industry Licensing Board. Respondent is, and was at all times material to the pending amended administrative complaint, a certified air conditioning contractor having been issued license number CA CO24348 by the Florida Construction Industry Licensing Board. At all times material to the pending amended administrative complaint, Respondent's certified air conditioning contractor license (CA CO24348) qualified "George E. Longino and Associates, Inc." with the Florida Construction Industry Licensing Board. Respondent is, and was at all times material to the pending administrative complaint, a registered mechanical contractor having been issued license number PM 0031246 by the Florida Construction Industry Licensing Board. At all times material to the pending administrative complaint, Respondent's mechanical contractor license qualified "J. C. and Sons, Inc." with the Florida Construction Industry Licensing Board. At no time material to the pending amended administrative complaint was Respondent the qualifying agent for "First City Contractors, Inc." as defined by Sections 489.105(4) and 489.119, Florida Statutes. At no time material to the pending amended administrative complaint was Charles L. Crowe registered, certified or otherwise licensed by the Florida Construction Industry Licensing Board. At no time material to the pending amended administrative complaint was "First City Contractor's, Inc." registered, certified or otherwise licensed by the Florida Construction Industry Licensing Board. On or about January 23, 1986, Charles L. Crowe d/b/a First City Contractors, Inc., contracted with Steve Bell to construct a room addition at 3110 Carrevero Drive West, Jacksonville, Florida. The contract price was approximately $25,000. On or about March 10, 1986, the City of Jacksonville, Building and Zoning Inspection Division, issued building permit number 6196 to George E. Longino and Associates, Inc. The above referenced building permit was for the construction of a room addition at the residence of Steve Bell, 3110 Carrevero Drive West, Jacksonville, Florida. The following Findings of Fact are based upon the evidence introduced at formal hearing. In December, 1985, or January, 1986, Charles L. Crowe, sole owner of First City Contractors, Inc., approached Longino and asked him to become a partner in the business and to pull permits and be the qualifying agent for First City Contractors, Inc. Longino advised Crowe that he would not be interested in doing that until he had resolved certain pending problems with his licenses. Specifically, the Construction Industry Licensing Board had filed a disciplinary action against Respondent's licenses and that case had been heard and a Recommended Order entered on October 30, 1985. The Recommended Order was scheduled to be considered by the Construction Industry Licensing Board on January 9, 1986. Longino did agree to pull permits for any job on which he would be paid to supervise the construction. Longino did pull the permit and supervise the construction of a garage addition in Arlington, Jacksonville, Florida, for First City Contractors in January or February, 1986. On January 23, 1986, Charles L. Crowe, doing business as First City Contractors, Inc., entered into a contract with Steve Bell to construct a room addition to a residence located at 3110 Carrevero Drive, Jacksonville, Florida. The contract price was $25,000. Based upon the contract, Crowe asked Longino to use his license number to sign a permit application for the Bell job. Longino used a building permit application form which he had in his truck and filled in the pertinent information on the building permit application. Specifically, Longino filled in the name of the licensed contractor as "First City Contractors, Inc." and signed his name as the licensee with license number CB CA09793. Longino signed the building permit application on or about the last week of January, 1986. Financing was not secured for the Bell job until March, 1986. On March 10, 1986, Crowe used the permit application which had been previously signed by Longino and sent an employee of First City Contractors, Inc., Robert Cumpston, to secure a building permit from the City of Jacksonville for the Bell job. Specifically, permit number 6196 was issued based upon the permit application which had been previously signed by Longino. On February 19, 1986, the Construction Industry Licensing Board entered a Final Order suspending Longino's licenses. Longino received notice of the suspension on February 24, 1986, by certified mail. Longino advised Crowe that his licenses had been suspended within a few days following receipt of the Final Order. Despite the knowledge that Longino's licenses had been suspended, Crowe used the presigned building permit application to secure a building permit for the Bell job on March 10, 1986. Building permit number 6196 was issued to Longino's license number doing business as George E. Longino and Associates, Inc. The name of the business was changed from that which was stated on the building permit application because Longino was not a qualifying agent for First City Contractors, Inc. He was only a qualifying agent for George E. Longino and Associates, Inc. A permit could not be issued to First City Contractors, Inc. using Longino's license number. The Bell job was completed using permit number 6196. Longino did supervise that construction and was present at the site on a daily basis. Permit number 6196 was posted at the site. Despite Longino's statements that he did not know that the permit was issued to his license number, it is found that Longino knew or should have known that permit number 6196 was issued to his license number, doing business as George E. Longino and Associates, Inc. Longino did nothing to remedy the problem even though his licenses had been suspended.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department of Professional Regulation, Construction Industry Licensing Board, enter a Final Order suspending the licenses of George E. Longino for a period of one (1) year in addition to the previous suspension. DONE and ENTERED this 11th day of August, 1987, in Leon County, Tallahassee, Florida. DIANE K. KIESLING Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of August, 1987. COPIES FURNISHED: Van Poole, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 William Bruce Muench, Esquire 438 East Monroe Street Jacksonville, Florida 32201 =================================================================
