Findings Of Fact Brian E. Michaels, the Codes Administrator for Putnam County testified that he regulates the building codes in Putnam County and is in charge with the effective administration thereof. He testified that the pertinent regulations and codes relative to the construction of swimming pools in Putnam County are Ordinances 73-6 and 75-4. (See Petitioner's Exhibits number 2, and number 3, received in evidence). Michaels testified that after seeing an advertisement in the Palatka Daily News on august 6, 1975, his office advised Respondent's office on two occasions to apprise him of certain local laws regulating contractors and the business of contracting. When Respondent failed to respond to approximately three phone calls to its office, Michaels advised Respondent by certified letter dated August 28, 1975, that swimming pool contractors desiring to operate in Putnam County must be locally certified even if they hold state registration. He advised Respondent that if he in fact was state certified that he could send a copy of his certificate for Putnam County official files and to discuss with their office procedures for obtaining a certification in Putnam County. He further advised that the county had adopted the standard swimming pool code, 1974 edition, which requires a plot plan as well as a plan approved before a pool permit could be issued. (See Petitioner's Composite Exhibit number 5). Michaels explained the procedures for complying with the County's certification process which included the filing of an application; taking an exam and receiving a score of at least 70 percent; posting of a $5,000.00 bond; payment of a $50.00 fee which should be included with the application which should also have included a recent photo and the issuance of an occupational license. Additionally, he advised that it was necessary to comply with registration and requirements of the Florida Construction Industry Licensing Board under Chapter 468; Florida Statutes, within 90 days. Michaels testified that Respondent received his certified letter dated August 28, 1975, the following day. (See Petitioner's Composite Exhibit number 5). Section 1020 of Ordinance No. 75-6 of the zone ordinances of Putnam County states in pertinent part that building and related permits issued by the chief building official are required in advance of the construction, erection, demolition, moving, destruction, or alteration of any building or structure with a completed evaluation of $1,000.00. (See Petitioner's Exhibit number 6). On May 27, 1975, the Putnam County Board of County Commissioners enacted Putnam County Ordinance no. 75-4, which ordinance adopted by reference the Southern Standard Swimming Pool Code, 1974 edition, which provided for the adoption of a fee schedule and charges for the issuance of permits to "defray the costs of inspections". (See Petitioner's Exhibit number 7). Jerrell Sparks of Crescent City, testified that he contacted Respondent regarding the construction of a swimming pool during the fall of 1975 following his visit to a building show. On October 21, 1975, Sparks entered into a contract with Terry Michaels, a partner of Respondent, Steve Klapach, d/b/a Starfish Pools for a total price of $5,150.00. At the execution of the contract, Sparks paid Respondent $200.00 and agreed to pay an additional $1,300.00 on November 5, 1975. (See Petitioner's Exhibit number 8, received and made a part herein). Sparks testified that Respondent made the financial arrangements with a mortgage broker in Jacksonville and that Respondent was paid $4,650.00. The construction completed by Respondent consisted of the excavation for the pool and delivery of the pool shell. He testified that he obtained a homeowner's permit but that Respondent did not obtain a permit for the installation of the swimming pool. Tom McConnell of Palatka, testified that he contacted the Respondent regarding a $2,000.00 pool kit which he had seen advertised. He testified that Respondent's partner, Tony Michaels, visited his home on October 14, 1975, at which time he executed a contract for the installation of a pool for a total price of $5,714.00. When the contract was executed, McConnell secured it by an advance payment of $500.00 and he thereafter was never able to contact Respondent. (See Petitioner's Exhibit number 9, received in evidence and made a part hereof). Kenneth L. Rue of Ormond Beach contacted the Respondent based on an ad which appeared in the Sunday supplement of the Daytona Beach News Paper. On August 21, 1975, Rue entered into a contract with Respondent's partner, Tony Michaels and a Mr. Charles Van Dent for the construction of a pool for the total price of $5,200.00. He paid Respondent $500.00 when the contract was executed and paid an additional $4,200.00 when the pool was delivered. He testified that Respondent removed shrubbery and palm trees where the pool was to be positioned and thereafter the excavation and the necessary site preparation was readied. Thereafter the pool was positioned and the plumbing and electrical-fixtures were connected. He testified that the pool did not comply with the specifications as called for in the contract which by its term called for a kidney shaped pool with dimensions of 27' X 13' and a depth of a minimum of 3 and a maximum of 5 feet. He testified that the actual dimensions of the pool installed was 25' x 11' and the depth ranged from 26" to 47". He testified that after the pool was installed it began leaking around the "circulation area" and that when he contacted the Respondent, the pool was removed and Respondent agreed to install any size pool that he desired. The pool called for in the contract was a fiberglass pool however Respondent opted for the installation of a vinyl liner pool. On November 11, 1975, Respondent sent two employees out to make forms for the construction of the pool but since that time, he has had no further contact with Respondent despite repeated attempts. He paid Respondent approximately $4,700.00 of the $5,200.00 contract price and paid another contractor an additional $2,300.00 to complete construction of the swimming pool. (See Petitioner's Composite Exhibit number 10) Brian Michaels was recalled and testified that Respondent never was issued building permits for the McConnell or Sparks projects. The Board introduced into evidence documents showing that Respondent, Steve A. Klapach, RP22049 was registered with the Florida Construction Industry Licensing Board as an active swimming pool contractor during 1975 in the period September, 1975 to December, 1975. (See Petitioner's Exhibit number 1).
Findings Of Fact On December 30, 1975, Collier County adopted Ordinance No. 75-57 which required, among other things, swimming pool contractors to be licensed by the county or state after establishing their competency. Prior to this time swimming pool contractors did not need certificates of competency to construct swimming pools. Anthony Schmidt had been engaged in the manufacture and installation of swimming pools for several years before opening a swimming pool business in Collier County. On April 22, 1976 Schmidt entered into a contract (Exhibit 1) to construct a swimming pool for John Dottore in Naples, Florida. Shortly thereafter Schmidt was issued a violation by an investigator of the FCILB for starting a different pool without a license. Schmidt contacted friends to ascertain who he could get to "pull" the permit needed to construct Dottore's pool, and was subsequently introduced to George C. Moyant, Respondent, a resident of Hollywood, Florida. He was introduced to Moyant at Moyant's house at a meeting arranged by mutual friends. The alleged purpose of this meeting was special tutoring of Schmidt by Moyant to prepare Schmidt for the pool contractor's exam and no other subject was discussed at this meeting. No final arrangements for such tutoring were made. Respondent holds Pool Contractor's License # CP C009205 and General Contractor's License #CG C001828 issued by the FCILB. He is president of Allstate Construction College, Inc. and prepares applicants for the various examinations required for registration with the FCILB. Subsequent to the meeting at Moyant's house Schmidt contacted Moyant regarding Moyant pulling a permit for Schmidt to construct Dottore's pool, and on a subsequent visit by Moyant to Naples Moyant, in company with Schmidt, submitted an Application for Building Permit (Exhibit 4) prepared and signed by Schmidt, showing the contractor to be George C. Moyant, License #CP C009205. At the same time Collier County Permit (Exhibit 5) was issued to Moyant as contractor for the construction of a swimming pool for Dottore. Immediately thereafter, at the Collier County Courthouse parking lot Schmidt gave Moyant a check dated May 4, 1976 in the amount of $500. Moyant's testimony that the payment was an advance for tuition is not credible. Moyant admits that Schmidt called him around the first of May for help in getting a permit for the swimming pool for Dottore and that he, Moyant, was "very reluctant" but assented to come to Naples to help Schmidt out and in fact, pulled the permit. Moyant recognized that his actions were in violation of the laws unless "one does things correctly." He advised Schmidt that his brother or the mutual friend, both of whom have general contractor's licenses would act as his, Moyant's, agent "if any problems come up". Before Schmidt completed the pool an investigator for the FCILB became aware of the circumstances surrounding the issuance of the permit and the investigation and administrative complaint followed.
Findings Of Fact At all times pertinent to this proceeding, Respondent, Alfred C. Wicht, has been registered as a pool contractor, license numbers RP 0026439 and RP A026439. At all times material herein, Respondent was the qualifier for Heritage Pools, Inc. On or about August 1, 1978, Heritage Pools, Inc. entered into a contract with Pacesetter Homes, Inc. to install a swimming pool at 3530 North 30th Terrace, Hollywood, Florida, for the sum of $5,350.00. Heritage Pools, Inc. commenced construction and completed the pool through the gunite and tile stage and received draw payments totaling approximately $4,295.00. About April or May, 1979, the pool popped out of the ground through no fault of the Respondent. The Respondent made some effort at repairing the pool and placing it back in the ground from the date it popped out through October, 1979. Respondent conceded that he delayed completing his repairs on the pool by virtue of the expense it was causing to his company and his belief that Pacesetter Homes, Inc. should have provided financial assistance. On or about December 5, 1979, Pacesetter Homes, Inc. learned that the pool could not be repaired and hired Electra Pools, Inc. to take out the pool initially installed by Respondent, and install a new pool in its place.
Recommendation From the foregoing, it is RECOMMENDED: That Petitioner enter its Final Order dismissing the charges contained in the Administrative Complaint. DONE and ENTERED this 27th day of May, 1983, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of May, 1983. COPIES FURNISHED: Michael Cohen, Esquire Suite 101, Kristin Bldg. 2715 E. Oakland Park Blvd. Ft. Lauderdale, Florida 33306 Alfred C. Wicht 6701 Cypress Rd., #108 Plantation, Florida 33317 James Linnan, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: At all times pertinent to this proceeding, respondent Henry C. Hollenbeck was licensed as a swimming pool contractor. In February of 1980, respondent, doing business as Acme Pools, entered into a contract with Loren Bjornson to construct a swimming pool at Bjornson's residence for a total purchase price of $8,300. Construction of this pool was completed on or about June 30, 1980. Respondent did not obtain a building permit for the Bjornson pool until January 5, 1981. Prior to the construction of a swimming pool in Ft. Walton Beach, a building permit is required. No inspections were performed by the City during construction of the Bjornson pool. Many items, such as the plumbing, walls, drain system, etc., cannot be adequately inspected after construction is completed and the pool is filled with water. Almost immediately upon construction of the Bjornson pool, a crack in the wall at the center of the pool appeared. This was repaired by respondent. Then, in July of 1980, the pool started losing one inch of water per day. In August, 1980, the pool started losing two inches of water per day. Mr. Bjornson repeatedly contacted respondent about this problem, but respondent did not respond to the calls because he felt that Mr. Bjornson had not paid his bills. Apparently, the financial dispute concerned work on a neighbor's driveway for which Mr. Bjornson was never billed. On three different occasions, Mr. Bjornson had not paid his bills. Apparently, the financial dispute concerned work on a neighbor's driveway for which Mr. Bjornson was never billed. On three different occasions, Mr. Bjornson retained another pool company to make repairs on his pool to prevent it from leaking. The three repair bills amounted to slightly over $200 and none of the repair jobs could be guaranteed. In order to make a guarantee, the service and sales manager of Aqua Pools estimated that repairs amounting to $11,365 would be necessary. It was his opinion that the repair work would involve a major rebuilding of the pool, including the removal of the pool deck and tiles and the reinforcement of walls. At the time of the hearing, the Bjornson pool was not presently leaking. By contract dated August 10,1979, respondent agreed to install a swimming pool for Mr. and Mrs. Walter Parker. Construction was competed in October of 1979 and leaking problems began almost immediately. Respondent came back on at least four occasions to do the repair work. The corners were patched and other repair work necessitating the complete draining of the pool was performed. Each time, the Parkers were charged for labor and parts. At the time of the hearing, the Parker pool still leaked approximately one inch per day. It was estimated that it would cost about $1,000 to repair the Parker pool adequately so that a one-year warranty against leaking could be given. Respondent testified that he did not respond to Mr. Bjornson's calls for repair work because Mr. Bjornson still owed him money. He believed the Parkers also owed him money. He felt that he could repair both pools adequately for a nominal sum of money.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that petitioner find respondent guilty of violating Sections 489.129(1)(d) and 489.129(1)(m), Florida Statutes, and suspend his pool contractor's license for a period of one (1) year. DONE AND ENTERED this 16th day of December 1981 in Tallahassee, Florida. DIANE D. TREMOR Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 16th day of December 1981. COPIES FURNISHED: John O. Williams, Esquire 547 North Monroe Street Suite 204 Tallahassee, Florida 32301 Henry C. Hollenbeck Rt. 1, Box 196 F-G, Circle Drive Ft. Walton Beach, Florida 32548 Mr. Samuel Shorestein, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact On October 10, 1979, the Respondent entered into a written swimming pool contract with Mr. and Mrs. Stellato, wherein the Respondent agreed to construct a swimming pool for them on their property in accordance with the plans and specifications attached to the contract. Among other things this swimming pool contract provided for the payment of a total purchase price of $11,225.00 to be paid in the following manner: ten percent to be paid at the signing of the contract. fifty percent to be paid upon the installation of the tank. thirty-five percent to be paid upon completion of the base decking and screen enclosure. five percent, or the balance of the purchase price, to be paid when the filter system was put in operation. Further, this contract provided that if the purchasers of the swimming pool failed to pay the purchase price in accordance with the prescribed schedule, the contractor reserved the right to suspend all work on the swimming pool, and to suspend all warranty work due after completion of the pool. During the month of February, 1980, the Respondent, acting through his duly authorized representatives, did all acts necessary to cause the filter system of the subject swimming pool to become operable, and requested that the Stellatos pay the five percent balance due under the contract. The Stellatos failed to make this final payment, claiming that there was a problem with the pool decking. In response to this complaint the Respondent personally met with the Stellatos, and agreed to cover the problem area of the decking with Chattahoochee River Rock at no cost to the Stellatos. In exchange for this agreement the Stellatos agreed to pay the balance due under the contract. Thereupon, the Respondent installed Chattahoochee River Rock over a substantial portion of the decking at his own expense. During the installation of this Chattahoochee River Rock, Mrs. Stellato contacted the Respondent by phone and demanded that he also install, at his own expense, Chattahoochee River Rock over an existing concrete patio area that had not been built by the Respondent. The Respondent refused to incur this additional expense, because it was not in accordance with the agreement of the parties. Thereafter, the Stellatos again failed to pay the balance due under the contract. The subject swimming pool was inspected by an inspector for Palm Bay, and the City issued a certificate of occupancy in June of 1980. The pool was ready for a certificate of occupancy in February of 1980 except for the removal of one pile of dirt that still remained on the premises. All other aspects of the pool construction passed inspection in February of 1980 when the pool filter system was activated. Since February Of 1980, the Stellatos have had full use of the subject swimming pool. Except for alleging that some low spots remain in the pool decking, the Petitioner offered no substantial evidence of any other significant problem with the Respondent's construction. Notwithstanding the failure of the Stellatos to pay the balance of the contract price in a timely manner, the Respondent performed warranty work on the subject swimming pool after February of 1980. During the course of this warranty work the Respondent added chlorine chemicals to the pool because the Stellatos had failed to properly maintain it up to June of 1980. Another claim concerning a leaking pipe on the pool sweep did not manifest itself until April of 1981, after the expiration of the one year warranty period afforded by the Respondent to all customers. The Petitioner offered no evidence to show that the leak in this pipe was caused by the Respondent. Notwithstanding the expiration of the warranty period, and the lack of evidence to show that the leak was caused by the Respondent, he did send an employee to the job site and stopped the water leak, at no cost to the Stellatos. On several occasions when the Respondent or his employees attempted to satisfy the complaints of the Stellatos, they had to leave the job site because of the abusive language and conduct directed toward them by the Stellatos. In one instance Mr. Stellato ordered the Respondent's employees from the job site and prevented performance of any work under the contract.
Recommendation Based upon the foregoing findings of fact and conclusions of law, it is RECOMMENDED that the Administrative Complaint, as amended, against John W. Thornett be dismissed. THIS RECOMMENDED ORDER entered this 9 day of June, 1982, in Tallahassee, Florida. WILLIAM B. THOMAS Hearing Officer Division of Administrative Hearings Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 Filed with the Clerk of the Division of Administrative Hearings this 9th day of June, 1982.
The Issue The administrative complaint filed on September 17, 1987 alleges that in a residential pool contracting job Respondent Martin ". . . exhibited financial mismanagement, misconduct, or diversion, in violation of 489.129(1)(h), (m) . . . [and] failed to perform in a reasonably timely manner, and/or abandoned said job, in violation of 489.129(1)(m), (k)." The issue is whether Martin committed those violations, and if so, what disciplinary action is appropriate.
Findings Of Fact At all times relevant, Kenneth Martin was licensed in the State of Florida as a registered commercial pool contractor, holding license number RP 0021608. His license is currently in inactive status. Martin was President of Adair Pools, Inc., the corporation under which he conducted his pool construction business. In early July 1986, Adair Pools contracted to build a residential pool for Paul and Cynthia Pajak at 8304 Helena Drive in Orange County, Florida. The pool was to be kidney-shaped, approximately 14 feet by 30 feet, with a waterfall and a detached spa. The contract amount of $11,571.00 expressly excluded the deck, electrical work and screening, although the written contract included a sheet describing the specifications for the excluded work, recommended contractors, and estimated costs. This sheet and the pool contract itself clearly indicated that these items were not the responsibility of the pool company and were not included in the contract price. Work commenced in July, shortly after the contract was signed. Although the contract did not specify a completion date, Martin concedes that the pool should have taken no more than four to eight weeks to complete. The Pajaks had planned a Labor Day party and were told by Adair's employees there would be no problem getting their pool finished for the party. The pool was not finished by Labor Day. After the pool was dug, shot with concrete and tiled, someone determined that the spa was supposed to have been raised. In attempting to raise the spa and to change the water jets, the workers cracked the shell of the spa and had to replace it. Until the problems with the spa, the Pajaks felt that the construction progress was reasonable and smooth. At this point, sometime around Labor Day, the problems began. Adair delayed in paying Shotcrete Pools, the subcontractor for the concrete shell, because Adair felt it was Shotcrete's fault that the spa was cracked. Shotcrete notified the Pajaks that a lien would be placed on the property if they were not paid. The notice to owner is dated November 3, 1986. Eventually Adair paid Shotcrete and its other subcontractors for the Pajak work and no lien was filed. The evidence does not reflect a clear sequence of events, but between Labor Day and February or March 1987, little progress was made to finish the pool. Martin's supervisor left and Martin's brother took over. The Pajaks kept calling Martin and were always assured that the job would be completed. Martin admits that the company at this time was in serious financial trouble because it was not being paid for a large commercial job that it had undertaken. On December 10, 1986, Mrs. Pajak's brother-in-law, an attorney, sent Martin a demand letter, giving a 10-day deadline for completion of the work. Martin and his brother met with the attorney and assured him the job would be finished. In spite of the problems, the Pajaks continued working with Martin and paid the full contract price, less the $100.00 that was to be paid when the pool was filled. On March 5, 1987, Martin informed the Pajaks that they should have the deck poured so that Adair could finish the pool. The Pajaks were not satisfied that the pool was ready for the deck as there were leaks in the waterfall, debris was all over the yard and the spa tile work looked messy. In Martin's opinion those items were his company's responsibility, but were part of the finishing to be done after the deck was poured and the pool was lined with marblelite. On March 21, 1987, the Pajaks contracted with another pool company for $4450.00 to finish their pool. Martin denies that Adair abandoned the job, but admits that it took an inordinate amount of time. The Pajaks did not allow him to finish the cleanup, the interior coating and the pool start up because they contracted with someone else. Martin did not contest that the waterfall leaked or that extensive cleanup needed to be done, but disputed that this work should be done before the deck was poured. He contended that the leaks in the waterfall would have been fixed when the finish was done. Martin estimates that between 1974 and 1986, his company completed over fourteen hundred residential pools and approximately five hundred large commercial pools. Martin has been active on various local pool construction industry boards and has no record of prior disciplinary action against his license.
Recommendation Based upon the foregoing, it is, hereby, RECOMMENDED: That Kenneth Martin be found guilty of misconduct, in violation of Section 489.129(1)(m), Florida Statutes, not guilty of the other violations with which he is charged, and that he be required to pay an administrative fine of $500.00. DONE and RECOMMENDED this 2nd day of August, 1988, in Tallahassee, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of August, 1988. COPIES FURNISHED: David E. Bryant, Esquire 220 East Madison Street, Suite 530 Tampa, Florida 33602 Kenneth R. Martin 3225 North Glenn Drive Orlando, Florida 32806 Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 =================================================================
The Issue The issues presented for decision herein are whether or not Respondent failed to properly supervise a pool construction project, willfully violated local laws, is guilty of gross negligence, incompetence, misconduct, fraud or deceit in the practice of contracting and failed to discharge his supervisory duties as a qualifying agent in violation of sections 489.129(1)(d), (m), (j), and sections 489.119 and 489.105 (4), Florida Statutes.
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, documentary evidence received and the entire record compiled herein, I make the following relevant factual findings. At all times material hereto, Respondent was a registered pool contractor in Florida, holding license no. RP0015329 and served as the qualifying agent for Paradise Pools, Inc. (Request for Admission, responses 1- 4). Petitioner is the regulatory agency in Florida charged with the authority to regulate contractors and to determine compliance with applicable state and local building code requirements. On May 31, 1986, Respondent entered into a contract with Alex and Theresa Nitu for the construction of a swimming pool at the Nitu's residence at 9550 Lisa Road in Dade County, Florida. The following day, the Nitus were approached by John Davis, a partner of Paradise Pools, Inc. Davis identified himself as the owner of Paradise Pools and told the Nitus that Respondent was the company salesman. Davis is not a licensed contractor. During construction, Davis supervised the work for the Nitus' pool. Mrs. Nitu was ill and remained at home on the day the workers laid reinforcing steel for the pool shell. Mr. Nitu, an electrical contractor, took off work and was at home during the two days when the gunite work was done for their pool. Respondent was not present on the job site on those days. The day after the concrete deck was poured, the Nitus noticed that it contained several low spots which collected water and that rocks were protruding through the deck's surface. Additionally, a portion of the deck sloped toward the pool rather than away from it. The following day, the Nitus returned home from work to discover that the "whitecoat" for the deck surface was completed and their water hose, weighted down by a rock and a rag, was filling the pool. The pool was filled with water before the Nitus had completed a fence to secure the pool. At Mr. Nitu's request, James Tucker, a Dade County Building Inspector, inspected the pool on August 6, 1986. Tucker issued a notice of violation to Respondent for allowing water to be put in the pool without proper safety barriers in contravention of section 33-12, Dade County Code; for allowing the deck to slope toward the pool in contravention of section 5003.1 of the South Florida Building Code and for using concrete of less than 2500 psi strength in contravention of section 5003.1(a), South Florida Building Code. In an attempt to correct the low spots and improper slope of the patio, Davis poured an additional layer of cement over the pool deck and scored the surface to create the appearance of keystone. Thereafter, the Nitus discovered hollow areas under certain parts of the keystone. Eventually, the keystone began to separate from the original deck exposing large areas of the deck. Ben Sirkus was tendered and accepted as an expert in pool construction. Sirkus inspected the Nitu's pool on September 24, 1987, at Petitioner's request. Sirkus observed low spots in the pool deck which held water and contributed to the growth of algae. He also observed that large areas of the imitation keystone had separated from the original deck; that portions of the deck still drained towards rather than away from, the pool; that coping mortar had been left on the sides of the coping and the pool shell; that areas of the whitecoat were unusually rough and that the pool pump was off level, which in time could cause scoring of the bearings in the pump. Sirkus opined that the deficiencies observed could not have gone unnoticed by a pool contractor of average skill and ability; that deficiencies indicate poor supervision or gross negligence or that Respondent exhibited incompetence in contracting for the Nitu's pool. John Davis, Respondent's partner and the person who was usually on the site during all facets of the construction, credibly testified that when the angles were laid out for the sloping of the decks surrounding the Nitu's pool, Alex Nitu requested that his employees angle the deck toward the pool such that it would mesh with his patio. This required that Respondent's employees reslope the angles in accord with Mr. Nitu's wishes and contrary to the manner in which they originally sloped the deck. Mr. Davis also attempted to correct the problems that had surfaced surrounding the deck in accordance with the concerns expressed by the Nitus. However, the Nitus vehemently refused access to Respondent's employees and the matter therefore, remained unresolved. Respondent Reise was at the construction site on numerous occasions during the major facets of the construction. In addition to being the principal salesman for Paradise Pools, Respondent Reise has extensive experience in the construction of pools and frequently consulted with his partner, John Davis, about the ongoing construction of the Nitu's pool. Respondent Reise also attempted to gain access to the pool to attempt to correct the problems and other concerns expressed by the Nitus, to no avail. In this regard, a meeting was held at the Nitu's residence on January 30, 1987, by Jim Tucker and Robert Denery, employees of the Dade County Building and Zoning Department, a Mr. Wolf, Petitioner's investigator, Respondent and his partner, John Davis. After a lengthy discussion, it was agreed that all problems were to be resolved which included (1), repair and patch the keystone on the east end of the pool and (2), rework the slope on the northside of the pool to pitch away from the pool and (3), submit test results from an engineering test lab as to the structural strength of the patio slab and final approval by the electrical and plumbing departments of Dade County. Respondent agreed to correct the above-referenced items and agreed to do so as quickly as feasible. The Nitus refused to allow Respondent's employees back on the site to correct the problems. (Respondent's Exhibit 1). John Davis and Respondent's other employees denied that they started filling the Nitu's pool prior to the time that the Nitus had completed a fence to secure it. Their denial in this regard is incredible and is not worthy of belief. The Nitus, in this regard, credibly testified that they were at all times concerned about the safety of the pool and would never have started filling it prior to the time that it was secured. Respondent's employees, on the other hand, were in fact interested in completing the job and it is therefore believed that they started the water running into the pool and weighted the hose down with a rock and a rag as the Nitus found it when they returned home from work on the day that the "whitecoat" was completed. In all other respects, based on the Nitus' failure to permit Respondent's employees to return to the site to complete the deficiencies and other concerns noted, the undersigned finds that Respondent should have been afforded an opportunity to correct such deficiencies and cannot be held liable 1/ for the allegations that he improperly sloped the pool deck, used improper concrete or was otherwise negligent, incompetent, engaged in misconduct and other allegations of improper supervision, as alleged. I shall so recommend.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that: Respondent be assessed an administrative fine in the amount of $250.00. Respondent be issued a written reprimand for allowing his employees to fill an unsecured pool in violation of the local building code. DONE and ORDERED this 16th day of September, 1988, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 19th day of September, 1988.
