Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact At all times material to these proceedings, the Respondent LARRY DAVID COMES, was licensed by the State of Florida as a registered specialty contractor and held license number RX00400762. Mr. Comes is the qualifying agent for D & L Enterprises. At all times material to these proceedings, the Respondent CHARLES J. GOREE was licensed by the State of Florida as a certified general contractor and held license number CG C007621. Mr. Goree is the qualifying agent for CJC Incorporated. In the beginning of the year 1985, the Island Village Association decided to reroof all six buildings located in the condominium project. At the time of the decision, all of the roofs were leaking. The existing roofs had been repaired and patched numerous times since the condominiums were built in 1973. On February 27, 1985, the Respondents COMES and GOREE submitted a joint proposal to the association to remove the existing built-up roof, apply a Neoprene/Hypalon roof, and remove and reshingle the mansard roof for $19,865.00. On April 15, 1985, a written contract was entered into between Island Village Condominium Association and David L. Comes, d/b/a D & L Enterprises, as contractor for the reroofing of Building "C." The Contract required the contractor to furnish all materials and labor to remove the existing built-up roof. Rotten wood on the deck was to be replaced on a time and materials basis. Damaged scuppers were to be replaced and other scuppers were to be cleaned out by the contractor. The Neoprene/Hypalon system would then be applied to the flat roof and the parapet walls. The mansard roof was to be removed and reshingled. Although Charles J. Goree, d/b/a CJC Incorporated, was not named in the contract, the omission was an oversight. At all times during the course of the reroofing project, the Respondent GOREE was responsible for the removal of the existing built-up roof and the application of new shingles to the mansard roof. The Respondent COMES was responsible for the application of the Neoprene/Hypalon roofing system. The reroofing project was a joint undertaking in which Respondents GOREE and COMES exercised equal authority, joint control, or right of control. The Respondents had a community of interest in the performance of the contract with the association. Respondents GOREE and COMES were familiar with what was required of each of them under the verbal joint venture agreement as they had conducted business in the same manner over an extended period of time on several projects. On May 10, 1985, Respondent GOREE applied for and received a building permit for the reroofing of Building "C" at Island Condominiums. During the removal of the built-up roof, GOREE observed "an absolute mess and disaster." The roof had been patched in various ways on numerous occasions. GOREE observed a few "T nails" in a piece of metal stripping picked up with shovels on the roof. The "T nails" discovered were the type which are shot into materials from a nail gun. (See GOREE Exhibit #2) They are not used to secure plywood on a deck because of their short length. Another "T nail," such as GOREE's Exhibit 2, was found by GOREE lying on the area of the roof by the air conditioners. This area of the existing roof was not removed or disturbed during the reroofing process. In the application of his common sense and knowledge of good construction practices and in light of the material in which the "T nails' were located, Respondent GOREE was not put on notice that these "T nails" may have been used to fasten the plywood decking. The type of "T nail" which was used upon plywood roof decking a few years ago in Florida was longer, thicker, and shaped like an elongated wedge. (See GOREE Exhibit 4) None of the "T nails" formerly used for plywood decking were observed by GOREE on the roof. Once the built-up roof was removed, Respondent COMES acted within the terms of the joint venture agreement by applying the Neoprene/Hypalon roofing system in full compliance with the specifications as set forth in the contract with Island Village Condominium Association. During the application of the system, COMES and his crew did not observe any conditions on the plywood decking which would alert them to the possibility of any future problems with the system. On May 17, 1985, Mr. Jim Peaks, an Inspector for Brevard County, completed a "dry in" inspection of the roof on Building "C" which had been requested by Respondent GOREE. Mr. Peaks placed a stop order on the project because the Neoprene/Hypalon roofing system was not an approved product under the Southern Building Code which he believed was in effect in Brevard County on May 14, 1985. In actuality, the 1982 Standard Building Code was in effect at the time. Upon receipt of the stop order, Respondents COMES and GOREE went to the building department and met with Murray Schmidt, Mr. Peaks' supervisor. Mr. Schmidt had the authority to override Mr. Peaks' stop order. Mr. Schmidt, who was new to the county and his position, discussed the stop order with the Inspector. Mr. Peaks refused to remove his stop order because of the lack of code compliance. Mr. Schmidt verbally allowed the Respondents GORE and COMES to continue to work on the roof. Mr. Peaks was told to investigate the roofing system with the Southern Building Code Conference in Birmingham, Alabama. The Respondents were not notified again as to the status of the stop order, one way or the other. Because the Respondents had been told to continue the work on the roof by Mr. Schmidt, who had the authority to override stop orders, the Respondents reasonably assumed that a stop order was no longer in effect. In fact, the permit had the notation "See Murray" on it after the stop order notation. Upon completion of the project, Respondent COMES contacted the building department and requested a final inspection. In the usual course of dealing between contractors and the building department in Brevard County, a contractor is notified only if there is a problem with the project which needs correction before final approval. Neither COMES or GOREE received notification of a problem. Another recognized, usual course of dealing between a contractor and the building department is that the department notifies an owner or the contractor if a six month permit has expired and a final inspection has not been completed. GOREE was not notified of any permit expiration in this case. Again, the Respondents were given the impression by the inactivity in the building department that business was being conducted in the usual manner. The Respondents believed, based upon past and ongoing dealings with the department, that all of their obligations had been met on the reroofing project. On May 28, 1985, the final payment was received from Island Village Condominium Association and a limited warranty was issued in both Respondents' company names, pursuant to the contract with the association. Shortly after completing the job on Building "C," Respondent COMES was called to repair leaks in the new roof. COMES responded promptly and courteously, and placed the blame for the leakage on various factors such as: (1) The short "T" fasteners had begun popping through the Neoprene/Hypalon and destroyed its ability to prevent water penetration. (2) The roof had an inadequate drain system. (3) The plywood deck was bowed in a concave fashion due to the years of improper weight and excess water on the roof. During a meeting with the board of directors of the association requested by COMES, COMES offered to put on a new roof if the board would install sump pumps to remove standing water. The board rejected COMES offer and authorized the condominium property manager to seek other solutions. The Respondents were not contacted by the board again concerning alternative solutions to the problem. In June of 1986, Mr. Rex Lahr, the condominium property manager, began a review of the roof situation. After consulting with Mr. Tom Butler of the county building department, Mr. Lahr decided that an architect needed to be retained by the association to determine whether a structural deficiency or the new roofing system caused the leaks in the roof. An architect was not hired by the association. A traditional, built- up roof was applied over the Neoprene/Hypalon roofing system. In the application of the new roof, the drainage system was redone and the flat roof was given pitch, thereby redesigning the roof as well. Mr. Robert B. Hilson, who was tendered as an expert witness in the case, opined that the Respondents COMES and GOREE failed to properly determine whether the roof deck was in a condition to accept the Neoprene/Hypalon system. Mr. Robert H. Adams, who was tendered as an expert witness in the case, opined that the leaks which developed soon after the application of the Neoprene/Hypalon system indicated that the deck was not in a condition to accept the system. Although there is some basis in fact for the opinions rendered by the two experts, their opinions must be rejected for the following reasons: (1) The experts did not personally observe the building, nor was a determination made which would exclude the possibility that the roofing system failed as a result of structural or design defects. (2) There is ample evidence in the case to support a finding that the leaks were caused by structural or design defects, as well as latent defects not readily observable to the Respondents at the time the roofing system was applied, and outside the terms of the reroofing contract. Some examples of evidence which support a finding that the leaks were caused by structural or design defects are: (1) Mrs. Delores Hammels' testimony that all six buildings had to be reroofed as they all leaked periodically throughout their 12 years of existence; (2) the redesign of the drainage system and the placement of a pitch on the roof by Mr. Roush; (3) the testimony and sketch submitted by Respondent GOREE (GOREE Exhibit #5) which shows that an identical building with a pitch on the roof allows the drainage system, including the internal hidden piping system, to work correctly. The effective redesign of the roof by Mr. Roush confirms this theory as much as, or more than, Mr. Robert H. Adams' theory that the deck was not in a condition to accept the Neoprene/Hypalon system.
The Issue The central issue in this case is whether Respondent is guilty of the violations alleged in the amended administrative complaints.
Findings Of Fact Based upon the testimony of the witnesses and the documentary evidence received at the hearing, I make the following findings of fact: At all times material to the allegations, Respondent, Ruth Ogen, was a licensed roofing contractor, license no. CC CO27471. A. R. Ogen Construction, Inc. was qualified by the Department as a roofing contractor. Respondent is the sole qualifier and licensee associated with the company, A. R. Ogen Construction, Inc. Respondent is married to Avraham Ogen who presents himself as the president of A. R. Ogen Construction, Inc. On or about November 9, 1986, A. R. Ogen Construction, Inc. doing business as Ogen Roofing & Waterproofing entered into a contract with Ardee Yuran to replace the entire roof of a commercial structure located at 14951 N.E. 6th Avenue, North Miami Beach (6th Avenue). The contract provided, among other things, that the top row of tiles around the parapet wall would be removed and reinstalled upon completion of the roof. In negotiating the contract described in paragraph 4, Mrs. Yuran was mindful of the work Avraham Ogen had performed at her residence. Mr. Ogen had supervised the reroofing of Mrs. Yuran's residence which had been satisfactorily performed. The residential job had required the removal of the tiles along the parapet wall and Mrs. Yuran expected the same process would be utilized in completing the commercial roof. The purpose intended to be accomplished by removing the tiles was to allow the roofers to extend the roofing materials up the sides of the parapet and over the crest. The roofing material is then sealed to the wall and the tiles replaced. This procedure results in a waterproof barrier so that when rain accumulates on the flat roof (and the water level rises) it cannot seep through the sealed perimeter. During the time Mr. Ogen was negotiating and performing the roof work for the 6th Avenue building, he was also retained to paint the structure (which was to be completed after the roof was finished). There came a time when Mrs. Yuran and Mr. Ogen disagreed regarding aspects of the roof work and the painting that was to be done. Eventually, the parties reached an impasse where neither was willing to concede: Mr. Ogen was not willing to perform the work as specified by Mrs. Yuran, Mrs. Yuran was not willing to pay Mr. Ogen any more on the contracts. At this point, Ruth Ogen, Respondent, had not been involved in the daily work progress made at the site. To make matters worse, a leak developed at the 6th Avenue property which resulted in a waterfall pouring down through the overhang of the building. As a result of the disagreement, both parties retained lawyers and, understandably, the issues escalated. Mrs. Yuran retained three individuals to review the work performed by Mr. Ogen. On March 4, 1987, Walter H. Scott, Scott Roofing & Repair, Inc., determined that water accumulating on the 6th Avenue roof was draining behind flashing which had not been properly sealed to the perimeter walls instead of running through the outlets. Mr. Scott recommended that the flashing be resealed along the wall. Had the tiles been removed and the work been performed as stated in the contract, the leak would have been avoided. A second licensed roofing contractor, Gary Carruth, Falcon Roofing Co., inspected the property on June 23, 1987, and recommended reflashing the walls along the perimeter of the 6th Avenue building. Mr. Carruth observed that the tiles had not been removed along the wall and that the roofing materials had not been properly sealed along the perimeter. James Rodgers, a consulting engineer performed a third inspection of the roof at 6th Avenue on June 25, 1987. According to Mr. Rodgers, several items of the contract work completed by Mr. Ogen were inadequately performed. Mr. Rodgers found that the pitch pans were not installed properly around the air conditioning units and that the flashing along the parapet wall was not properly completed nor performed as described in the contract. Respondent also retained a licensed roofer to review the work at 6th Avenue. Bill Mathews, Bill Mathews Roofing, completed a roof inspection report on November 21, 1988. According to Mr. Mathews, the flashing along the parapet wall required repair because it had been improperly sealed. Mr. Mathews noted that the top row of tile should have been removed so that flashing could have been taken up and over the parapet wall. Mr. Mathews also noted that the flat roof had buckles or "fish mouths" which should have been corrected as the roof was being installed. Mr. Mathews recommended that the flashing be resealed and that the buckles be cut and sealed with membrane and roofing cement. Finally, Mr. Mathews determined that the pitch pans under the air conditioning units should be filled with an asphalt cold process to prevent further cracking and potential leaks. A final inspection report was completed by Robert B. Hilson, Bob Hilson & Company, Inc., on August 18, 1988. Mr. Hilson is a consultant for the Department and made the inspection at the request of its attorney. Mr. Hilson's findings and recommendations mirrored those suggested by Mr. Mathews. The work performed by Mr. Ogen on the 6th Avenue property did not meet the terms of the contract and did not meet performance standards acceptable in the roofing industry. Mr. Ogen failed to properly seal all flashing materials along the parapet wall, failed to correct the buckles or "fish mouths," and failed to meet the contractual obligations (removing the tiles and extending the flashing over the crest). Because of the substandard work, Mrs. Yuran incurred additional expenses and inconvenience. Respondent did not view the 6th Avenue structure either before or during the time that her husband supervised the work performed. Respondent's role with the company was as secretary, bookkeeper, and office manager. Mr. Ogen supervised or performed all work at the 6th Avenue job. Respondent did not supervise Mr. Ogen or the workers under his supervision. "Ogen Roofing & Waterproofing" has not been qualified by the Department as a roofing contractor. On or about April 28, 1987, A. R. Ogen Construction, Inc. was requested to perform a roofing inspection at 1180 N.E. 204 Terrace. The subject property was under contract for sale and was ultimately purchased by Rose Zenar. According to the inspection report filed by Mr. Ogen, the roof and roof covering were in satisfactory condition with no evidence of leaks. Mr. Ogen signed the inspection report as president of A. R. Ogen Construction, Inc., state license no. CC CO27471. During the first rain after she had moved into the house, Mrs. Zenar observed water leaking through the ceiling into the kitchen. She immediately called Mr. Ogen who came out, observed the problem, but did not repair the leak. Mr. Ogen did not return Mrs. Zenar's subsequent calls. Ultimately, she contacted James Rodgers to perform a second roof inspection. As a result of Mr. Rodgers' inspection, Mrs. Zenar discovered that the leak was of long duration as it had completely rotted and decayed the roof rafters and sheathing in the area of the leak. Mr. Rodgers took pictures of the area which clearly showed the discolored wood. Evidence of the discoloration was visible from the attic entrance located in the garage adjacent to the kitchen. Mr. Ogen's failure to discover the rotted roof was due to an inadequate inspection of the crawl space between the ceiling and the roof rafters. It is the normal practice of qualified roof inspectors to examine the crawl space between the ceiling and roof supports. Respondent did not perform the roof inspection at Mrs. Zenar's home, did not supervise the inspection performed by Mr. Ogen, and did not have a checklist of items to be reviewed by him in making the inspection. The erroneous inspection performed by Mr. Ogen resulted in expenses and inconvenience to Mrs. Zenar.
Recommendation Based on the foregoing, it is RECOMMENDED: That the Department of Professional Regulation, Construction Industry Licensing Board, enter a final order finding the Respondent guilty of the violations set forth above and, based upon the penalties recommended by rule, impose an administrative fine against the Respondent in the amount of $3000.00 DONE and RECOMMENDED this 20th day of April, 1989, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of April , 1989. APPENDIX RULINGS ON PETITIONER'S PROPOSED FINDINGS OF FACT: Paragraphs 1 through 7 are accepted. With the correction to reflect Mrs. Yuran not Mr. Yuran, paragraph 8 is accepted. Paragraphs 9 through 12 are accepted. Paragraph 13 is accepted. Paragraph 14 is accepted with the correction that the witness' name was Gary Carruth. With the deletion of the last paragraph of paragraph 15 which is rejected as argument or comment, the first five paragraphs of paragraph 15 are accepted. Petitioner is warned not to subparagraph statements of fact or to restate testimony, but to simply set forth the fact deduced from such testimony. Paragraph 16 is rejected as irrelevant or immaterial. Paragraph 17 is accepted to the extent that it finds the reroofing work performed on the 6th Avenue building was a poor quality which was not done under the supervision of a qualified, licensed roofing contractor. Further, it was gross negligence not to properly supervise the job. No conclusion is reached as to whether Respondent is able to supervise a job. Paragraph 18 is accepted. Paragraph 19 is rejected as a recitation of testimony. Paragraphs 20 through 24 are accepted. Paragraphs 25 through 31 are accepted. Paragraph 32 is accepted. Paragraph 33--none submitted. With regard to paragraph 34, the first sentence is accepted. The remainder is rejected as conclusion of law, argument, or comment. Paragraph 35 is rejected as irrelevant. Paragraphs 36-38 are accepted. Paragraph 39 is rejected as comment, irrelevant, or recitation. The first two sentences of paragraph 40 are accepted, the remainder is rejected as comment, conclusion of law, or argument. Paragraph 41 is rejected as irrelevant, conclusion of law, or argument. RULINGS ON RESPONDENT'S PROPOSED FINDINGS OF FACT: Paragraph 1 is accepted. Paragraph 2 is accepted but is irrelevant. Paragraph 3 is accepted. Paragraph 4 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 5 is accepted. Paragraph 6 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 7 is rejected as irrelevant or unsupported by the record. Paragraph 8 is accepted. Paragraph 9 is accepted. Paragraph 10 is rejected as contrary to the weight of the credible evidence presented. Paragraph 11 is rejected as argument, speculation, or unsupported by the record. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument, irrelevant, or unsupported by the weight of credible evidence. Paragraph 14 is rejected as argument, irrelevant, or comment. Paragraph 15 is accepted but is irrelevant. Paragraph 16 is rejected as argument. Paragraph 17 is accepted but is irrelevant. Paragraph 18 is rejected as irrelevant, argument, or unsupported by this record. Paragraph 19 is rejected as irrelevant. The following are rulings on case no. 88-1776 as submitted by Respondent: Paragraph 1 is accepted. Paragraph 2 is rejected as unsupported by the record. Paragraph 3 is rejected as irrelevant. Paragraph 4 is accepted but is irrelevant, immaterial. Paragraph 5 is rejected as unsupported by the record. Paragraph 6 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 7 is rejected as unsupported by the weight of credible evidence. Paragraph 8 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 9 is accepted but is irrelevant. Paragraph 10 is rejected as irrelevant, immaterial or unnecessary. Paragraph 11 is rejected as irrelevant, immaterial or unnecessary. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument or unsupported by the weight of the credible evidence. Paragraph 14 is rejected as contrary to the weight of the credible evidence. Paragraph 15 is accepted but is irrelevant. COPIES FURNISHED: Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Bruce D. Lamb General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Elizabeth R. Alsobrook Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue The issues to be resolved in this case are those promoted by the second amended administrative complaint brought by the State of Florida, Department of Professional Regulation against the Respondent, David W. Crosby. Briefly, the basic allegations are that the Respondent granted to James Crosby, d/b/a U.S. Seamless Roof Systems, the unlimited opportunity to obtain building permits under the Respondent's contracting license. This arrangement, it is alleged, was in the face of a circumstance in which James Crosby was not registered, certified, or otherwise licensed by the Construction Industry Licensing Board, nor had the Respondent qualified U.S. Seamless Roof Systems with the Construction Industry Licensing Board. It is further alleged that between August 1982 and in or about 1985 James Crosby operated a roofing contracting business in St. Johns County, Florida, and in St. Augustine, Florida, and utilized the Respondent's authorization to obtain certain building permits and that James Crosby then performed roofing work authorized by those permits. By reason of this arrangement Respondent is said to have violated Sections 489.119 and 489.129(1)(e) (f) (g) (j) and (m), Florida Statutes. There are additional allegations of similar nature pertaining to work in Brooksville and Inverness, Florida.
Findings Of Fact Facts found based upon responses to requests for admissions propounded from Petitioner to the Respondent (see Petitioner's Exhibit 1 admitted into evidence) Respondent's name is David W. Crosby. Respondent is a certified roofing contractor in the State of Florida having been issued license number CC CO 15442. At all times material to the pending Administrative Complaint, Respondent was a certified roofing contractor in the State of Florida having been issued license number CC CO 15442. Respondent's license number CC CO 145442 is active for the period expiring June 30, 1987. In or about August 1982, Respondent issued an unlimited authorization, addressed "To whom It May Concern," which authorized all building departments to issue roofing permits to Respondent's brother, James Crosby. Said James Crosby was operating a roofing business in the period 1982 to 1985, in and about the St. Johns County and St. Augustine area. On or about January 13, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems obtained permit number 12102 from the City of St. Augustine. Said permit, number 12102, was obtained to repair a roof for Zorayda Castle of 83 King Street, St. Augustine, Florida. On or about February 3, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12122 from the City of St. Augustine. Said permit, number 12122, was obtained to reroof the residence of Zorayda Castle of 83 Ring Street, St. Augustine, Florida. On or about February 24, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12158 from the City of St. Augustine. Said permit, number 12158, was obtained to reroof the residence of Lillian Perpall of 67 Abbott Street, St. Augustine, Florida. On or about May 17, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12288 from the City of St. Augustine. Said permit, number 12288, was obtained to reroof the residence of Emily M. Alexander of 20 Cuna Street, St. Augustine, Florida. On or about May 2, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, contracted with Lawrence Golden to repair the roof at Golden's residence at 17 Bay View Drive, St. Augustine, Florida, for a contract price of $985. On or about March 28, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, used contractors license number CC CO 15442 to obtain permit number 3781-81 from St. Johns County Florida. Said permit, number 3781-81, was obtained to reroof the residence of Burton Chase of St. Johns County, Florida. On or about March 28, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, used contractors license number CC CO 15442 to obtain permit number 3780-81 from St. Johns County, Florida. Said permit, number 3780-81, was obtained to reroof the residence of Fred Jensen of St. Johns County, Florida. On or about May 7, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, contracted with Ceal Butler to repair Butler's roof on his residence at Rt. 3, Box 56W3, St. Augustine, Florida, for the contract price of $1,335. Said contract referenced in number 20 above, was executed on a printed form bearing contractors license number CC CO 15442. At no time relevant hereto did Respondent qualify the roofing business, American Roof and Waterproofing Company and/or American Roofing and Waterproofing Company. Facts found based upon testimony at final hearing and exhibits admitted at final hearing James Crosby is also known as James A. Crosby, Jr., and Jim Crosby. On May 17, 1982, James A. Crosby, Jr., who held registered roofing contracting license number RC 0029375, voluntarily relinquished that license in Department of Professional Regulation, Construction Industry Licensing Board v. James A. Crosby, Jr., DPR Case No. 006237. On June 30, 1987, the Construction Industry Licensing Board, in accordance with that voluntary relinquishment, entered a final order approving and accepting the relinquishment. See Petitioner's composite Exhibit 3. James Crosby, in those instances described in the fact finding related to roofing contracting activities, was unlicensed and therefore not authorized to practice contracting, to include roofing contracting. See Petitioner's Exhibit 4 admitted into evidence, a February 7, 1986, notice to cease and desist in the case of State of Florida, Department of Professional Regulation vs. James Crosby, DPR Case No. 62490, in which it is indicated that James Crosby does not hold the necessary license to do roofing work or other forms of contracting contemplated by Chapter 489, Florida Statutes. Petitioner's Exhibit 5 is a copy of the general authorization which Respondent directed "To Whom It May Concern" in August 1982 authorizing James Crosby ". . . to pull permits for all roof work done by U.S. Seamless Roof Systems, St. Augustine, Florida." A copy of Respondent's certified roofing contractors license was attached to this authorization. This authorization has never been withdrawn and still remains on file with the City of St. Augustine, Florida, Building Department. At all relevant times related to the second amended administrative complaint, the City of St. Augustine, Florida, by ordinance, had adopted the Southern Building Code, which required building permits to be issued by the City before James Crosby or the companies under whose name he was doing business could undertake the various projects that are contemplated by the second amended administrative complaint. In January 1983, James Crosby entered into a contract with Wallace Mussallem for the roof repair in a tourist attraction in downtown St. Augustine, Florida, known as Zorayda Castle. Price of the repairs was approximately $6500. Petitioner's composite Exhibit 6 admitted into evidence pertains to various building permit applications and for certificate of appropriateness which James Crosby filed related to the Mussallem job. Crosby was operating under the name U.S. Seamless Roofing Co. as depicted in the aforementioned composite exhibit. Crosby completed the job and was paid the full amount of the contract. Crosby warranted his repair work for a period of ten years. During the initial two years, the roof did not leak; however, in 1986 a number of leaks occurred in the roof. Mussallem was unable to locate James Crosby to fix the roof and Mussallem had another roofer effect repairs and spent $3000 to have one section of the roof repaired. As of the time of the hearing, when Mussallem gave his testimony, part of the roof was still leaking and needed to be fixed. Respondent was never involved in the transaction between Mussallem and James Crosby, beyond giving permission to James Crosby to pull building permits from the City of St. Augustine, Florida. On March 4, 1984, Mr. and Mrs. William Blanchard entered into a contract with James Crosby, d/b/a American Roof and Waterproofing Company. James Crosby's associate, Basil R. Boone, was the person who estimated the job; however, the contract was with James Crosby. A copy of that contract can be found as Petitioner's Exhibit 14 admitted into evidence. It calls for the repair of the roof on the Blanchards' residence in St. Augustine, Florida. On April 5, 1985, James Crosby applied for a building permit from the City of St. Augustine to do the roofing work at the Blanchard home, and on April 30, 1985, that building permit was issued. Petitioner's composite Exhibit 8 is a copy of the application for permit and the permit. The price of the contract was $1575. James Crosby was paid for the roofing work. In the course of this transaction, William Blanchard had no occasion to deal with the Respondent. On May 7, 1984, James Crosby, d/b/a U.S. Seamless Roof Systems contracted with Ceal Butler of St. Johns County, Florida, to do roof repair work on a mobile home belonging to Mr. Butler. See Petitioner's Exhibit 15 admitted into evidence. The contract price was $1335 and Crosby guaranteed the work for ten years. May l8, 1984, James Crosby, as referred to in the check written to the Butlers as "Jim Crosby," was paid the contract amount. The contract form that was utilized in the Butler case referred to the Florida certified contracting number which pertains to the Respondent. Notwithstanding this reference, Respondent did not involve himself with this project. The Butlers immediately began to experience problems with the roofing work done by James Crosby. There were leaks in the roof repair work. The Butlers made numerous requests to have James Crosby honor the warranty, but the repairs were not made. Eventually, another roofer other than James Crosby had to make the repairs on the roof. Lillian Perpall owned a home in St. Augustine, Florida, and contracted with James Crosby to do roofing repair work at her residence. A copy of the contract may be found as Petitioner's Exhibit 17 admitted into evidence. James Crosby was doing business in this instance as U.S. Seamless Roof Systems. The contract price was $4875 and the project carried a ten-year guarantee. On February 24, 1983, in furtherance of the conduct of the project, James Crosby applied for a building permit which was granted that same day. A copy of the application and building permit may be found as Petitioner's composite Exhibit James Crosby was paid the full amount of the contract price for concluding the roofing repair work. Within a year after the work had been done, there was a leak in the roof and James Crosby came and put another coat of material on the roof in response to the complaint of Ms. Perpall. In the last eight or ten months, the back porch area where roof repairs had been made began to leak. Ms. Perpall has tried to contact James Crosby about that problem and has been unable to. In particular, she tried to make contact at the telephone number listed on the contract document that was signed. On the evidence presented, it is found that the Respondent did not participate in the roofing repair work at the Perpall residence, On October 14, 1982, James Crosby, d/b/a U.S. Seamless Roof Systems contracted with Edward Carriere to perform room repair work on Carriere's residence in St. Augustine, Florida. The contract amount was $5100 and the contract included a ten-year guarantee. A copy of the contract may be found as Petitioner's Exhibit 18 admitted into evidence. This contract format bears Respondent's Florida certified contractor's number. In furtherance of this work, James Crosby applied for a building permit from the City of St. Augustine on September 28, 1982, and that permit was issued that same day. A copy of the application and permit may be found as Petitioner's composite Exhibit 11 admitted into evidence. A second building permit related to this work was issued on October 27, 1982, from the City of St. Augustine as acknowledged by James Crosby and is found as part of the Petitioner's composite Exhibit 11. From the beginning, following the work, Carriere has experienced problems with the repair work. These problems are leaks in the roof. They have caused damage in the kitchen and living room area of the Carriere home. James Crosby responded to complaints about the room leaking, but did not fix the problem. The roof leaked from 1983 to 1985. By 1985, Carriere was unable to locate James Crosby to fix the leaking roof. Being unsuccessful in locating James Crosby, Carriere hired another roofer to fix the problem in January 1986. This cost an additional amount of approximately $5800. Carriere never dealt with the Respondent in the roof repair project at his home. On May 2, 1983, Lawrence G. Golden contracted with a representative of U.S. Seamless Roof Systems, the company of James Crosby, to have roof repair work done at the Golden residence in St. Augustine, Florida. A copy of the contract entered into with the company be found as Petitioner's Exhibit 19 admitted into evidence. The contract amount was $985 and the work carried a ten-year guarantee. Lawrence Golden paid the man $985 called for by the contract. Mr. Golden had problems with the roof repair work with the advent of heavy rains, in that the roof leaked. After numerous attempts to contact the company, James Crosby came to examine the nature of the complaint. James Crosby did not fix the problems with the leaking roof or cause them to be fixed until Golden had made a complaint to the State of Florida, Department of Professional Regulation. James Crosby did not obtain a building permit for the roof repair work, nor was a building permit obtained by anyone other than James Crosby. Golden did not deal with the Respondent in the transaction involving the roof repair. On July 15, 1982, Wilbur Lane contracted with James Crosby d/b/a U.S. Seamless Roof Systems to perform roof repair work on Lane's residence in St. Johns County, Florida. The roof repair contract carried the certified roofing contractor license number associated with the Respondent. The amount of the contract price was $1300 and the work carried a ten-year guarantee. James Crosby completed the construction work and received the full payment. A copy of the contract may be found as Petitioner's Exhibit 20 admitted into evidence. Although James Crosby was paid the amount contemplated by the contract, the roof repair work was not successful. After the project was undertaken, Lane experienced leaks inside of his home and made numerous attempts to try to contact James Crosby to take care of the problem. Crosby did attempt to fix the leaks, but failed in the attempt. Eventually Mr. Lane was unable to contact Crosby to continue the effort at rectifying the problem and Mr. Lane had to complete his own repair work on the roof to stop the leaks. Lane never had occasion to deal with the Respondent in this project. 35, The Department of Professional Regulation investigator Augostino A. Lucente investigated the complaint that had been filed by Lawrence Golden and spoke with the Respondent. Respondent indicated that he did not know anything about Mr. Golden or his problem or the fact that roofing repair work had been undertaken by U.S. Seamless Roof Systems. Respondent did indicate to Lucente that James Crosby was using Respondent's certified roofing contractor's license to obtain building permits. Respondent stated that he was trying to do his brother a favor by setting up a company for him in the St. Augustine area. In actuality, James Crosby may not be the brother of Respondent and may in fact be Respondent's cousin. Respondent told Lucente that he had issued the authorization letter, Petitioner's Exhibit 5, and that he had intended to open up a business in the St. Augustine area and to put James Crosby in charge. After about six weeks, Respondent said that he determined that he did not want to do anything with the St. Augustine situation and left everything as it was. This decision came about in September 1982. Respondent also denied any knowledge of the Carriere contract. On October 22, 1986, Petitioner took action against the Respondent in DPR Case Nos. 59109 and 59115 by the entry of a final order disciplining the license which is at issue in this proceeding. A copy of that final order and the underlying administrative complaint may be found as Petitioner's Exhibit 2 admitted into evidence.
The Issue Whether Respondent violated Sections 489.129(1)(e),(m), Florida Statutes (Supp. 1988), and Section 489.129(1)(r), Florida Statutes (1993), and if so, what penalty should be imposed.
Findings Of Fact Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board (Department), is the state agency charged with the responsibility to prosecute administrative complaints pursuant to Chapters 489, 455, and 120, Florida Statutes. At all times material to this proceeding, Respondent, Kenneth G. Steeprow (Steeprow), was licensed as a certified roofing contractor in the State of Florida, having been issued license number CC C036974. He is registered to do business individually, and his license is currently inactive. On April 23, 1987, Ken Steeprow Roofing applied for an extension of credit with Gory Associated Industries, Inc. (Gory). The application listed Ken Steeprow as the owner of Ken Steeprow Roofing. A copy of Steeprow's individual roofing contractor certificate was included with the application. Also included with the credit application was a guaranty signed by Steeprow and his wife for credit extended to Ken Steeprow Roofing. On November 15, 1988, Steeprow Enterprises, Inc. was formed as a Florida corporation. The president of the company was Steeprow, and the secretary/treasurer of the company was Steeprow's wife, Tamara Cherry Steeprow. Steeprow did not qualify Steeprow Enterprises, Inc., as required by Sections 489.119 and 489.1195, Florida Statutes. Steeprow admitted at hearing that he operated Steeprow Enterprises, Inc., during 1989. Steeprow also admitted at hearing that it had been his practice to sign building permit applications in blank and that the secretaries for the company would type in the name of Steeprow Enterprises, Inc., on the application forms. These application forms were used to pull building permits for Steeprow Enterprises, Inc. On February 22, 1989, Gory sent a letter to Ken Steeprow Roofing to the attention of Steeprow, requesting that Steeprow review the information from its customer file and verify whether the information was accurate. On March 9, 1989, Gory received a response, advising that the firm's name was Steeprow Enterprises, Inc., and including a completed application for extension of credit for Steeprow Enterprises, Inc. The contractor's license number listed on the credit application was CC C036974. At the time of the application, Tamara Steeprow signed an agreement for extension of credit on behalf of Steeprow Enterprises, Inc. The agreement included the following provisions: We agree to notify Gory Associated Industries, Inc. immediately in the event of a change of ownership or in the form of our business. We further agree that any goods or merchandise purchased from Gory Associated Industries, Inc. shall remain the property of Gory Associated Industries, Inc. until payment is received for said merchandise and goods by Gory. BLANKET CERTIFICATE OF RESALE STATEMENT This is to certify that all material, merchandise, or goods purchased by the undersigned from Gory Associated Industries Inc. is purchased for the purpose of ROOFING CONSTRUCTION and is purchased under certificate number . This certificate shall be considered a part of each order which we shall give provided such order contains our certificate number. This certificate is to continue in force until revoked. Although the certificate number is blank in the agreement, the credit application included a copy of the certificate for Kenneth Steeprow as a roofing contractor, license number CC C036974. On March 9, 1989, Kenneth Steeprow and Tamara Steeprow signed a guaranty for the extension of credit to Steeprow Enterprises, Inc. The guaranty provided: THE UNDERSIGNED, herein jointly and severally referred to as Guarantor, makes this agreement with Gory Associated Industries, Inc., or divisions thereof, herein referred to as Creditor, with respect to credit extended and to be extended to STEEPROW ENTERPRISES INC. herein referred to as Debtor. For valuable consideration Guarantor does hereby unconditionally guarantee to Creditor, its successors and assigns, prompt and punctual payment of the full amount, including accrued interest, of any and all obligation, indebtedness or liability, whether arising before or after the date hereof, and whether primary or secondary, (herein referred to as "liabilities") of Debtor to Creditor from time to time and at all times hereof and hereafter without limitation as to amount, together with interest, and all expenses of collection, costs and reasonable attorney's fees, whether suit be instituted or not. * * * The obligations hereunder shall be continuing and irrevocable except as herein provided. Revocation may be made by thirty (30) days notice in writing signed by Guarantor and delivered to Creditor, in person or by certified mail only. Any notice shall not effect or impair in any manner whatsoever the obligations of this Guaranty as to liabilities of the Debtor to Creditor existing or committed at or before the time such notice becomes effective. On March 18, 1989, Steeprow resigned as President of Steeprow Enterprises, Inc., and was replaced by his wife. The stock in Steeprow Enterprises, Inc., was sold to Erick Holland on or about January 1, 1990. Erick Holland was not licensed as required by Chapter 489, Florida Statutes. In July, 1991, Monier Roofing Tile, Inc. (Monier), acquired Gory and became the assignee of contract rights and accounts receivable of Gory. Steeprow Enterprises, Inc., ordered roofing supplies from Monier from November 1991 through June 1992 and defaulted in making payments for the roofing materials. In November 1992, Monier brought suit in the Circuit Court of Broward County, Florida, Case Number 92-28733(21), against Steeprow Enterprises, Inc., Steeprow, and Tamara Cherry Steeprow for the money owed by Steeprow Enterprises, Inc. A summary judgment in the aggregate amount of $21,548.09 was entered August, 3, 1993, against all defendants, including Steeprow. The defendants appealed the summary judgment. The Fourth District Court of Appeal rendered an opinion on October 26, 1994, affirming the trial court's decision, stating specifically that as to the individual defendants, including Steeprow, their pleadings and affidavits were deficient and even if construed as an attempt to raise affirmative defenses failed to state a viable defense. The case was remanded to the trial court for the assessment of attorney's fees, and on February 14, 1995, a final judgment was entered, awarding Monier attorney's fees in the amount of $6,600 against all defendants. In May or June 1996, Steeprow filed a voluntary petition in bankruptcy in the United States Bankruptcy Court, Southern District of Florida, Case Number 96-32243. The petition was dismissed on Steeprow's motion on January 10, 1997. The judgments remain unpaid. Steeprow stated at the hearing that he does not intend to pay the judgments. A reasonable time within which to satisfy a judgment is ninety days.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered finding that Kenneth G. Steeprow violated Sections 489.129(1)(e), and (m), Florida Statutes (Supp. 1988) and Section 489.129(1)(r), Florida Statutes (1993), imposing an administrative fine of $2,000 for the violation of Section 489.129(e), imposing an administrative fine of $500 for the violation of Section 489.129(1)(m), assessing costs of investigation, and revoking license number CC C036974. DONE AND ENTERED this 28th day of August, 1997, in Tallahassee, Leon County, Florida. SUSAN B. KIRKLAND Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (904) 488-9675 SUNCOM 278-9675 Fax Filing (904) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 28th day of August, 1997. COPIES FURNISHED: William S. Cummins Senior Attorney Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792 Kenneth G. Steeprow 5985 Acme Avenue Port St. John, Florida 32927 Rodney Hurst, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact The Respondent's name is Troy Griffin. The Respondent is now and was at all times relevant to the pending Administrative Complaint, a registered residential contractor in the State of Florida having been issued license number RR 0030688. The Respondent is not now and at no time material to the pending Administrative Complaint was the Respondent a certified or registered roofing contractor in the State of Florida. At all times material to the pending Administrative Complaint, the Respondent's license #RR 0030688 qualified Griffin Remodeling & Repairs, Jacksonville, Florida. In June 1978 the Respondent d/b/a Griffin Remodeling and Repairs contracted to repair the residence of June Moody, Jacksonville, Florida. The contracting work included work upon the Moody's built-up roof, which Respondent re-roofed pursuant to contract. Respondent built up the roof with more than one layer of felt in 1978. These layers were discovered by the city's inspector in 1982. Respondent returned in 1978 and patched the roof he installed. These patches were seen by the city's inspector in 1982. The owner, Moody, did not complain of leaks in 1982. There was no evidence of leaks in 1982. A roof poorly installed without sufficient tar and felt will leak within the time that has passed between 1978 and 1982. See inspector's testimony in response to Hearing Officer's question. Moody's home was a single family, one story residence. No evidence was received regarding whether the City of Jacksonville requires examinations of roofing contractors prior to their certification.
Recommendation Having found that the Respondent did not commit the alleged violations, it is recommended that the Administrative Complaint be dismissed and no action be taken. DONE and ORDERED this 23rd day of August, 1985, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings The Oakland Buildina 2009 Apalachee Parkway Tallahassee, Florida 32301 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of August, 1985. COPIES FURNISHED: W. Douglas Beason, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Troy Griffin 7443 Laura Street Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Direetor Department of Professional -I Regulation. Construction Industry Licensing Board P. O. Box 2 Jacksonville, Florida 32202
The Issue The issue for determination is whether Respondent committed the offenses set forth in the Administrative Complaints and, if so, what penalty should be imposed.
Findings Of Fact It is undisputed that at all times material hereto, Respondent was licensed by the State of Florida as a Certified General Contractor, having been issued license number CG C58099. Respondent passed the licensing examination in August 1995. Case No. 99-0261 Respondent is not a licensed roofing contractor. Respondent's Certified General Contractor's license did not and does not permit him to obtain roofing permits to perform any type of work on roofs. Respondent's Certified General Contractor's license number was not low enough for him to be grandfathered in by the State to allow him to lawfully perform roofing work with his Certified General Contractor's license. On or about February 23, 1998, Delfina Valdes contracted with Johnny Hatcher, d/b/a Hatcher's Roofing, to repair the roof on her residence located at 18101 Northwest 32 Avenue, Miami, Florida. They contracted for Hatcher to remove Valdes' old roof and install a new roof at a cost of $4,000. Valdes paid Hatcher $2,000 as a down payment toward the cost of the roof's repair. At no time material hereto was Hatcher a licensed roofing contractor. Furthermore, at no time material hereto was Hatcher's Roofing qualified by the State of Florida to perform contracting. Hatcher removed the roof from Valdes' residence. After removing the roof, he did not perform any more work. Respondent met with Valdes and represented to her that Hatcher was working for him. Respondent further represented that he would obtain the permit for the roofing work. Respondent paid Cayetano Alfonso to obtain a roofing permit for the work on Valdes' roof. On or about March 26, 1998, Alfonso made application to Metropolitan Dade County, Department of Planning, Development and Regulation for the roofing permit, which was subsequently issued. Alfonso was a Certified General Contractor who was licensed to perform roofing work. Alfonso's Certified General Contractor's license number was low enough for him to be grandfathered in by the State to allow him to lawfully perform roofing work with his Certified General Contractor's license. Alfonso was not the qualifier for Hatcher's Roofing nor was he Respondent's qualifier. Alfonso did not enter into the contract with Valdes for repairing her roof. Alfonso was not a party to the contract for repairing Valdes' roof. An inference is drawn and a finding of fact is made that Hatcher was not acting on behalf of Alfonso when he entered into the contract with Valdes. An inference is drawn and a finding of fact is made that Respondent was not acting on behalf of Alfonso when he represented to Valdes that he would obtain the permit for the roofing work. When Respondent discovered that Hatcher had received a $2,000 deposit from Valdes, he requested Alfonso to cancel the permit. On or about April 20, 1998, Alfonso cancelled the roofing permit. On or about June 5, 1998, Valdes cancelled the contract between her and Hatcher Roofing. Valdes received a refund of the $2,000 from Hatcher, through a third party, that she had paid him. Case No. 98-4859 On or about April 9, 1995, Respondent entered into a contract with Susan Casper to construct an addition to her residence located at 17350 Northeast 12th Court, North Miami Beach, Florida, at a cost of $38,135. Casper paid Respondent $36,285.00 toward the cost of the addition. Respondent was not licensed at the time that he entered into the contract. On or about March 20, 1996, Respondent obtained a permit from the Metropolitan Dade County, Department of Planning, Development and Regulation for the work on the addition. Several delays were encountered during the performance of the work. Some of the delays resulted from changes by Casper, which changes required approval by Metropolitan Dade County, Department of Planning, Development and Regulation; however, most of the delays were Respondent's own doing. In October 1996, Casper paid $2,588 to Best Truss Company for a claim of lien filed on her residence, associated with the work being performed on her residence. Respondent worked sporadically on Casper's addition through April 1997. He would inform her at times that he was returning but failed to return. At one point, Casper's children constructed a sign in their own handwriting, instructing Respondent to keep out and indicating that there was no trespassing by him. The sign was posted on the door of Casper's residence. Casper informed Respondent that her children constructed the sign. It was obvious that the keep out, no trespassing sign was constructed by children. Respondent's assertion that he was kept away from Casper's residence by the children's sign is not credible. Even after the children's sign was posted on the front door of Casper's residence, Respondent agreed with Casper to resume work, and he did so. However, his work was sporadic. In or around June 1997, Casper sought assistance from the Metropolitan Dade County, Department of Planning, Development and Regulation to get Respondent to complete the work. In July 1997, Respondent obtained a window permit for the work on Casper's residence. After July 1997, Respondent ceased working on Casper's residence. He did not provide Casper with any notice that he was ceasing work. Respondent had no valid reason for ceasing the work. In September 1997, Casper transferred the permit for the work on her residence from Respondent's name to her name. Respondent failed to perform all the work under the contract. Some of the work performed by Respondent or caused to be performed by Respondent contained code violations and needed correcting. Certain work performed by Respondent or caused to be performed by Respondent needed correcting. Wood doors, glass block, electrical work, and a sprinkler were in need of correction. Casper bore the expense of the corrections. The corrective work was completed at a cost of $1,675.00. The value of the work performed by Respondent on Casper's residence was $18,272, minus the cost of the corrective work of $1,675, which equals a total value of the work at $16,597. This cost value includes overhead and profit. Even though the value of the work by Respondent was $16,597, Casper paid Respondent $36,285, a difference of $19,688. Casper hired a new contractor on or about September 17, 1997, to complete the construction on her residence at a cost of $16,350. As to Case No. 98-4859, as of January 26, 1999, Petitioner incurred a cost of $1,108.76 for the investigation and prosecution of Respondent. Petitioner previously disciplined Respondent for violating Chapter 489, Florida Statutes (1995), including violating Subsection 489.127(1)(k), Florida Statutes (1995), abandonment of a construction project.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order and therein: As to Case No. 99-0261, finding that Respondent violated Subsection 489.129(1)(e), Florida Statutes (1997). As to Case No. 98-4859, finding that Respondent violated Subsection 489.129(1)(k), Florida Statutes (1997), in Count I; and dismissing Count II. Revoking Respondent's license. Ordering Respondent to pay restitution to Susan Casper in the amount of $19,688.00. DONE AND ENTERED this 31st day of October, 2000, in Tallahassee, Leon County, Florida. ERROL H. POWELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 2000. COPIES FURNISHED: Diane Snell Perera, Esquire Department of Business and Professional Regulation 401 Northwest 2nd Avenue, Suite N607 Miami, Florida 33128 Richard F. Hayes, Esquire 10300 Sunset Drive, No. 499 Miami, Florida 33173 Rodney L. Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Barbara D. Auger, General Counsel Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
The Issue The issues that were presented for disposition in the above-styled cases were whether Respondent committed certain alleged violations of Chapter 489, F.S. and if so what discipline is appropriate. As stated below, the parties stipulated to the violations, leaving only the issue of discipline to be resolved.
Findings Of Fact Gordon Lee Cederberg is, and has been at all times material hereto, a licensed registered roofing contractor, having been issued license number RC 0051346, by the State of Florida. At all times material Respondent was the licensed qualifier for Allied American Roofing Company and was responsible in such capacity for supervising its contracting activities. Allied American Roofing Company was dissolved on November 4, 1988. Stipulated Violations By stipulation, Respondent has admitted the following allegations of the amended administrative complaint in DOAH #91-8319: 3. CASE NO. 0106373 COUNT THREE Respondent d/b/a Allied American Roofing contracted with Michael Roberts on April 4, 1988 to reroof a home located at 530 Mason Street, Apopka, Florida. The contract price was $942.80 and was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the City of Apopka Building Department. By the reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a municipality, to wit, Apopka, Florida, by failing to obtain a permit and inspection is as required by that municipality. 4. CASE NO. 0107766 COUNT FOUR Respondent's license was under suspension by the Florida Construction Industry Licensing Board between August 10, 1988, and March 3, 1989. Respondent d/b/a Allied American Roofing contracted with Nancy Wiegner on September 22, 1988, to reroof a home located at 15 Kentucky Street, St. Cloud, Florida. The contract price was $1,600.00 and it was paid in full. Respondent commenced work under the contract but failed to obtain a permit prior to commencing such work from the City of St. Cloud, Florida, and the municipality issued a stop order on the job. Respondent further engaged in contracting in a municipality where he had not registered. By reason of the foregoing allegation, Respondent has violated Section 489.129(1)(j), F.S., in that he failed in a material respect to comply with the provisions of Section 489.117(2), F.S., in that he engaged in contracting in a municipality, to wit, St. Cloud, Florida, where he had failed to comply with the local licensing requirements for the type of work covered by his registration. COUNT FIVE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that Respondent willfully deliberately disregarded and violated the applicable building code of a municipality, to wit, St. Cloud, Florida by failing to secure a permit as required by that municipality. COUNT SIX By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT SEVEN By reason of the foregoing allegations, Respondent has violated 489.129(1)(m), F.S., by committing gross negligence, misconduct, and/or incompetency in the practice of contracting. 8. CASE NO. 0112740 COUNT EIGHT Respondent d/b/a Allied American Roofing contracted with Emma Smith on October 3, 1988 to reroof a home at 1911 Mullet Lake Park Road, Geneva, Seminole County, Florida. The contract price was $4,100.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to properly construct a watertight roof which continued to leak and caused damage to the home. Respondent has failed to honor the five (5) year labor and twenty (20) year material warranty that was part of the said contract, although he was requested to do so. By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(n), F.S., in that the Respondent proceeded on a job without obtaining an applicable local building department permit and inspections. COUNT NINE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT TEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act of gross negligence, incompetency and/or misconduct in the practice of contracting by failing to honor the written warranty described in paragraph twenty-six above. COUNT ELEVEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 12. CASE NO. 89-001674 COUNT TWELVE Respondent d/b/a Allied American Roofing Company contracted with Thelma Beck to reroof a home at 3910 Pineland Ridge Road, Orlando, Orange County, Florida on January 26, 1989 for a price of $2,270.00. Respondent accepted a $100.00 deposit for said job; the work was not begun and the $100.00 deposit was returned to Mrs. Beck. By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT THIRTEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. COUNT FOURTEEN Respondent d/b/a Allied American Roofing contracted with Morris Remmers to reroof a home at 8719 Butternut Boulevard, Orlando, Orange County, Florida, on or about February 23, 1989. The contract price was $2,870.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Orange County Building Department. By reason of the foregoing allegation, Respondent is guilty of violating Section 489.129(1)(n), F.S., in that Respondent proceeded in a job without obtaining an applicable local building department permit and inspections. COUNT FIFTEEN By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while his license was suspended. COUNT SIXTEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 17. CASE NO. 89-008737 COUNT SEVENTEEN Respondent d/b/a Allied American Roofing contracted with Robert Speirs to reroof a dwelling at 2467 Fieldingwood Road, Maitland, Seminole County, Florida on or about October 14, 1988. The contract price was $3,600.00. Respondent proceeded to work the job but failed to obtain a permit and secure required inspections from the Seminole County Building Department. Respondent failed to properly construct a water tight roof which continued to leak. Respondent failed to honor the three (3) year labor and twenty (20) year material warranty that was part of the contract although he was requested to do so. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(n), F.S., in that Respondent proceeded on a job without obtaining an applicable local building department permit and inspections. COUNT EIGHTEEN By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S., by engaging in contracting while license was suspended. COUNT NINETEEN By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act of gross negligence, incompetency and/or misconduct in the practice of contracting by failing to honor his written warranty described in paragraphs forty-seven above. COUNTY TWENTY By reason of the aforesaid allegations, Respondent is guilty of violating 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 21. CASE NO. 109636 COUNT TWENTY-ONE Respondent d/b/a Allied American Roofing Company contracted with Daniel J. Doherty to reroof a home at 225 Dover Wood Road, Fern Park, Seminole County, Florida on October 2, 1988, for the contract price of $3,590.00 which was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to construct a watertight roof, which contributed to water damage to the interior of Mr. Doherty's home. Respondent failed to honor the five (5) year labor and twenty (20) year material warranty that was part of the contract, although he was requested to do so. By the reason of the foregoing allegations, Respondent has violated Section 489.129(1)(n), F.S., by proceeding on the job without obtaining a local building department permit and inspections. COUNT TWENTY-TWO By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(j), F.S., by failing in a material respect to comply with the provisions of Section 489.127(1)(e), F.S. by engaging in contracting while his license was suspended. COUNT TWENTY-THREE By reason of the foregoing allegations, Respondent has violated 489.129(1)(m), F.S., by committing gross negligence, misconduct, and/or incompetency in the practice of contracting by failing to honor his warranty as described in paragraph fifty-six above. COUNT TWENTY-FOUR By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. COUNT TWENTY-SEVEN Respondent d/b/a Allied American Roofing contracted with Gloria Viruet to reroof a home at 3010 (renumbered to 3007) Northwood Blvd., Orlando, Orange County, Florida on June 7, 1988. The contract price was $3,500.00. Respondent proceeded to complete the job without receiving a permit and securing required inspections from the Orange County Building Department. The Respondent failed to properly construct a watertight roof and a leak developed after construction. Respondent failed to honor the five (5) year labor and twenty (20) material warranty that was part of the said contract, although he has been requested to do so. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(d), F.S., in that Respondent willfully and deliberately disregarded and violated the applicable building code of a County, to wit, Orange County, Florida by failing to obtain a permit and inspections as required by that County. COUNT TWENTY-EIGHT By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting, by failing to honor his written warranty described in paragraphs seventy. COUNTY TWENTY-NINE By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. 28. CASE NO. 0108263 COUNT THIRTY Respondent d/b/a Allied American Roofing Company contracted with John E. Hultin to reroof a home located at 3610 Lakeview, Apopka, Florida on November 7, 1987. The contract price was $2,900.00 and it was paid in full. Respondent proceeded to complete the job without obtaining a permit and securing required inspections from the Seminole County Building Department. Respondent failed to properly install a roof covering, violating Section 103 of the Standard Building Code, 1985 Standard of Installation of Roofing Coverings adopted by Seminole County and Seminole County Ordinance Section 40.51. The contract provided for a five (5) year labor warranty and a twenty (20) year material warranty. Respondent made several attempts to correct defects but has not fulfilled his warranty as the roof continued to leak. By reason of the aforesaid allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a county, to wit, Seminole County, Florida by failing to obtain a permit and inspections as required by that county. COUNT THIRTY-ONE By reason of the foregoing allegations, Respondent has violated Section 489.129(1)(d), F.S., in that the Respondent willfully and deliberately disregarded and violated the applicable building code of a county, to wit, Seminole County, Florida by installing the above described roof in a grossly negligent manner and in a manner which violated Section 103 of the Standard Building Code, 1985 Standard of Installation of Roof Covering, adopted by Seminole County and Seminole Ordinances Section 40.51. COUNT THIRTY-TWO By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practices of contracting by failing to honor his written warranty described above. COUNT THIRTY-THREE By reason of the aforesaid allegations, Respondent is guilty of violating Section 489.129(1)(m), F.S., by committing an act or acts of gross negligence, incompetency and/or misconduct in the practice of contracting. FACTS RELATED TO RESPONDENT'S PROPOSED MITIGATION Respondent has been engaged in the practice of roofing contracting for over twenty years. Prior to moving to Florida in 1983 his company worked in Michigan, Ohio and Indiana on large commercial jobs. In 1983 he was employed by the Disney company to do commercial roofing work. After licensure in Florida, Cederberg continued with large public works and commercial jobs in Florida. Sometime around 1988, after a disastrous reversal of fortune, the company filed for bankruptcy. Although he was utterly unfamiliar with the practice of residential roof contracting, particularly the demanding supervision involved, Gordon Cederberg began doing residential work. Around this same time Cederberg's wife left him and he was given custody of three children, ages three, six, and nine. He was emotionally distraught and obtained counseling and financial and other support from his church group. Cederberg's roofing contractor's license was suspended by the Construction Industry Licensing Board from August 1, 1988 to March 1, 1989, during which time he continued to work, due to financial pressures. Warranty work was not done due to his financial and emotional straits. According to Cederberg and his witnesses, he is in the process now of turning his life around. He operates on a smaller scale and is able to handle the work. He has one employee and has been able to avoid new complaints. He is still financially unable to provide restitution to the customers previously harmed.
Recommendation Based on the foregoing it is hereby, RECOMMENDED: that the parties' stipulation with regard to dismissals and admissions described above be accepted by the Board and that the following penalty be imposed: a) 1000.00 fine; one year suspension, with this penalty suspended during, and removed upon successful completion of, probation with an appropriate timetable for restitution and the requirement that appropriate continuing education courses are completed; and payment of costs of investigation and prosecution. DONE and ENTERED this 31st day of December, 1992, at Tallahassee, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of December, 1992. COPIES FURNISHED: Jack McRay, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Daniel O'Brien, Executive Director Construction Industry Licensing Board P.O. Box 2 Jacksonville, FL 32202 William S. Cummins, Esquire Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Jack Snow, Esquire 407 Wekiva Spings Road, Suite 229 Longwood, FL 32779
The Issue Whether Respondent committed the offenses alleged in the Administrative Complaint and the penalties, if any, that should be imposed.
Findings Of Fact At the times pertinent to this proceeding, Respondent was not registered, certified, or otherwise licensed to engage in contracting in the State of Florida. At the times pertinent to this proceeding, Respondent conducted business through an entity known as C. J. Home Improvement Corporation, which was also not registered, certified, or otherwise licensed to engage in contracting in the State of Florida. In 1995, Joseph Pallant was one of the owners and the manager of a commercial building located at 3700 Biscayne Boulevard, Miami, Florida. In January 1995, Mr. Pallant entered into an agreement to lease the building for a term of ten years to a non-profit organization named PWAC, an acronym for People With Aids Coalition. PWAC had an office in the adjacent block and wanted to operate a thrift shop at the subject premises. The roof on the subject building leaked. The parties agreed that Mr. Pallant would pay to replace the roof and that PWAC would thereafter be responsible for maintenance. The officers of PWAC informed Mr. Pallant that they wanted Respondent to do the roofing work. There was a conflict in the evidence as to whether Mr. Pallant knew that Respondent was unlicensed. It is clear that Mr. Pallant and Respondent knew one another prior to January 1995. Based on Mr. Pallant's testimony, which the undersigned finds credible, it is found that Mr. Pallant knew that Respondent was in the building repair business, but that he did not know Respondent was unlicensed. Respondent's assumption that Mr. Pallant knew he was unlicensed is not as credible as Mr. Pallant's direct, unequivocal testimony that he had no such knowledge. After having several conversations with Mr. Pallant by telephone and at the building, Respondent prepared a written proposal on his business form to do the work necessary to replace the roof. The proposal was submitted to PWAC. The proposal described in detail the work that would be done and the materials that would be furnished, the time frame for the work, and the price. The price was set at $6,183.00 plus $400.00 if certain additional work would have to be done on certain drains. PWAC was provided a copy of the proposal that was dated February 25, 1995. Respondent signed this proposal and affixed the corporate seal of his business entity. Under Respondent's signature was the phrase "personally individually guaranteed." At all times pertinent to this proceeding, Respondent knew that Mr. Pallant was one of the owners of the building and that he would be paying for the roofing work. On February 27, 1995, Respondent and Mr. Pallant met. Respondent gave Mr. Pallant an unsigned copy of the written proposal (dated February 27, 1995, but otherwise identical to the form given PWAC, but dated February 25, 1995). After they discussed the work, Mr. Pallant accepted the proposal and gave Respondent a check made payable to C. J. Home Improvement in the amount of $3,100.00. Respondent accepted this check and deposited the proceeds of the check in his company's bank account. Without the prior knowledge or consent of Mr. Pallant, Respondent attempted to subcontract the roofing job to a licensed roofer named Don Palmier.1 No work was started on the job. In March 1995, Mr. Pallant met with representatives of PWAC and Respondent to discuss the lack of progress. As a result of that meeting, Mr. Palmier refused to proceed with the roofing job2 and Mr. Pallant learned that Respondent was unlicensed and could not do the work. During the course of the meeting PWAC cancelled its lease. Mr. Pallant subsequently filed suit against C. J. Home Improvement for the return of the $3,100.00. Despite obtaining a final judgment for that sum plus costs and fees, the Respondent has not satisfied any portion of the judgment. As of April 23, 1998, the Petitioner's costs of investigation and prosecution in this case, excluding costs associated with an attorney's time, totaled $269.62.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner enter a final order that adopts the findings of fact and conclusions of law contained herein; finds Respondent guilty of violating the provisions of Section 489.127(1)(f), Florida Statutes, as alleged in Count I of the Administrative Complaint; dismisses Count II of the Administrative Complaint; imposed an administrative fine against the Respondent in the amount of $2,500.00; and assesses costs against Respondent in the amount of $269.62. DONE AND ENTERED this 10th day of September, 1998, in Tallahassee, Leon County, Florida. CLAUDE B. ARRINGTON Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 10th day of September, 1998
Findings Of Fact Indus is a state licensed general contractor and has been in the business of construction in Florida at least since 1974 (Exhibit 3). Indus submitted a bid on Sarasota County School Board Project No. 88039 to build an elementary school building. Indus' bid for this project was $6,863,000. The next lowest bid was Barton-Malow Company whose bid was $6,888,000. There were two other higher bidders (Exhibit 2). The specifications on the project call for a pre-engineered metal roof system (Exhibit 9). Under part two of that portion of the specifications the bidder was required to bid on use of a pre-engineering metal roofing system provided by one of the five providers there listed. The specifications further provided that the supplier of the metal roof system must be a firm that is and has been for a minimum period of two years prior to bid date, an authorized and franchised dealer of the pre-engineered roof system's manufacturer; and the pre-engineered building shall be erected by a firm that has not less than three years successfully experience in the erection of pre-engineered metal roof systems similar to those required for this project. Certification for supplier and installer is required by the specifications to be submitted one week prior to bid date. As subcontractor for the installation of the pre-engineered metal roof system, Petitioner inserted Indus Construction Co., Inc. (Exhibit 1). When queried about the above-cited requirements of the specification Indus stated that it proposed to install a metal roof system manufactured by AEP-SPAN. At the hearing Petitioner's witness testified that Petitioner could buy a pre-engineered metal roof system from any one of numerous manufacturers and that all such systems were basically the same with only slight variations in where the roof material is bent or curved. Respondent's witness' testimony to the contrary is deemed more credible. Independent investigation by Respondent's agents revealed that Indus is not an authorized agent or dealer for any of the five pre-engineered metal roof systems listed in the specifications, and none of them would sell their product direct to Indus (Exhibit 14). They also received information from an AEP-SPAN dealer in Tampa that AEP-SPAN sells only through licensed roofing contractors and installers (Exhibit 15). By letter dated November 14, 1988 (Exhibit 5), AEP-SPAN stated Indus is recognized as an approved installer for applications of AEP-SPAN Metal's metal roof system. Indus is not licensed as a roofing contractor. In its recommendation to the School Board to accept the second low bidder, Petitioner's Architect and Construction Services Staff noted that Indus listed themselves as subcontractor for the pre-engineered metal roof system, but had not requested a bid from any out of the five approved suppliers, and is not a certified dealer. Further, the recommendations include "the staff and architect are unable to determine if Indus has three (3) years successful experience in the installation of any type of Metal Roof System as required by the specifications." (Exhibit 2). Although Indus contends that it has more than three years' experience in installation of metal roof systems none of the projects listed on Exhibit 3 involve the use of pre-engineered metal roofs. Petitioner acknowledged that it had failed to submit the dealer certification or installer certification one week prior to the opening of bids as required by Section 13120 of the bid specifications (Exhibit 9). On cross examination, when asked why such certification was not supplied, Mr. Rakha testified that "contractors aren't supposed to do this," and further that it was not the contractor's responsibility to see if the supplier is qualified.
