Findings Of Fact Respondent has been a registered roofing contractor at all times material hereto. His license number is RC-0035594. On or about April 26, 1985 Respondent, doing business as Pinellas Roofing Service, contracted with Bausch and Lomb to reroof their plant in Manatee County, at a contract price of $31,150. Respondent admits that at no time material hereto was he licensed to engage in contracting in Manatee County. Pinellas Roofing thereafter began, and partially performed, this job for which it was paid a total of $28,035. Petitioner alleges, and Respondent denies, that Respondent diverted funds received from this job for other purposes, and was thereafter unable to fulfill the terms of the contract with Bausch and Lomb. Petitioner did not present competent substantial evidence in support of this charge. Respondent never completed this job and took no steps to inform Bausch and Lomb that he would not complete the contract or make other arrangements for its completion. He left several thousand dollars worth of material on the roof, exposed, when he walked off this job, and this resulted in these materials being substantially destroyed. During the job, he did not take precautions to assure that the roof did not leak during heavy rainstorms. In fact, on at least three occasions, leaks caused damage to the interior of the plant and Respondent could not be reached. Therefore, Bausch and Lomb had to have another roofing contractor make emergency repairs on June 25, July 15 and September 3, 1985, at a total additional cost of $4,150. Since Respondent did not complete the contract, and left the roof unfinished, Bausch and Lomb contracted on September 17, 1985 with Bernard J. Lozon, Inc., to complete the job, and make certain additional repairs, at a cost of $24,000. In the opinion of Bernard J. Lozon, who was accepted as an expert in roofing contracting, the actual work that was done by Pinellas Roofing was satisfactory. However, Respondent's actions in walking off the job and leaving the roof unattended without completing the job is an unacceptable practice in roofing contracting, and constitutes incompetence and misconduct. Respondent failed to properly supervise this job. He relied upon his son to hire the necessary crews, pay them, handle financial aspects of the job, and assure its completion. His testimony indicates he fails to understand his own responsibility for supervising and completing the work for which he contracted, and which was performed under his license. At no time material hereto did Respondent qualify Pinellas Roofing Service with Petitioner. Respondent failed to apply for and obtain a Manatee County building permit for the roofing job in question, and also failed to request the county building department to perform inspections of the work performed. The Board of County Commissioners of Manatee County has adopted and follows the 1979 edition of the Standard for Installation of Roof Coverings, Southern Building Code, as amended in 1981. This Code requires all contractors performing work in Manatee County to be registered in Manatee County, and to obtain permits for all roof replacements and repairs in excess of $200, as well as obtain inspections of all such work to insure compliance with the Code. Respondent failed to comply with these requirements of the local building code. When Respondent submitted his proposal on April 16, 1985 for the Bausch and Lomb job, he specifically acknowledged, in writing, that "all work (is) to be done according to owner specifications sheet." (Emphasis supplied). At hearing, Respondent contended that when he submitted his proposal he never saw the project specification sheet which was thereafter attached to his contract with Bausch and Lomb and made a part thereof. Rather, he testified that his proposal referred to certain specifications that appeared on project drawings which he reviewed prior to submitting his proposal. After considering the demeanor of the witnesses and all of the evidence presented, and particularly the fact that Respondent referred to the "specifications sheet" and not "drawings" in his proposal, it is specifically found that Respondent had knowledge of, and did in fact submit his proposal based upon the "specifications sheet" which ultimately became a part of his contract. As such, he was bound thereby in the performance of work under this contract. In pertinent part, the "specifications sheet" requires that the contractor obtain all necessary permits from Manatee County, that notice be given to the owner in advance of work that will produce excessive amounts of dust or tar fumes so proper precautions could be taken, that roofing materials be stored in a manner that protects them from damage or adverse weather conditions during construction, and that the contractor provide a two year written guarantee at the conclusion of the job. Respondent failed to comply with these requirements of the specifications.
Recommendation Based upon the foregoing, it is recommended that Petitioner enter a Final Order suspending Respondent's registration for a period of ninety (90) days and imposing an administrative fine in the amount of $1,500. DONE AND ENTERED this 22nd day of April, 1987 in Tallahassee, Florida. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of April, 1987. APPENDIX TO RECOMMENDED ORDER, CASE NO. 86-3698 Rulings on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact 1. Adopted in Finding of Fact 8. 3,4 Adopted in Finding of Fact 2. 5,6 Adopted in Finding of Fact 3, but otherwise rejected as irrelevant and unnecessary. 7,8 Adopted in Finding of Fact 9. Adopted in Finding of Fact 6. Adopted in Findings of Fact 5, 6. Rulings on Respondent's Proposed Findings of Fact: Adopted in part in Findings of Fact 3, 5. Rejected as not based upon competent substantial evidence. Adopted in part in Finding of Fact 3. Adopted in part in Findings of Fact 2, 3. 5-7 Addressed in Findings of Fact 2, 3 and 5. 8,9 Rejected as irrelevant and unnecessary. 10. Adopted in part in Finding of Fact 5. 11,12 Adopted in part in Finding of Fact 6. Rejected as not based upon competent substantial evidence. Adopted in Findings of Fact 5, 6. Adopted in Finding of Fact 6. COPIES FURNISHED: W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750 Michael Schlesinger, Esquire 655 Ulmerton Road Building 11-A Large, Fl 33541 Fred Seely Construction Industry Licensing Board Post Office Box 2 Jacksonville, Fl 32201 Van Poole Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750 Joseph A. Sole, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750
The Issue Whether Respondent committed the offenses set forth in the administrative complaint and, if so, the penalty which should be imposed.
Findings Of Fact At all times material to this case, the Respondent, Harry Bradshaw, was licensed as a registered roofing contractor in the State of Florida, holding license number RC 0033812. On August 26, 1986, Respondent's license as a registered roofing contractor was suspended by Petitioner. Respondent's license remained suspended at all times material to this case. On December 16, 1987, Respondent contracted with the Moose Lodge located in Hialeah, Florida, to reroof the Moose Lodge building. The proposal submitted by Respondent contained representations that Respondent was licensed as a registered roofing contractor and that he was insured. Respondent knew that his license as a registered roofing contractor was under suspension. Respondent had no insurance. The contract between Respondent and the Moose Lodge provided that Respondent would perform the work and supply the materials for the sum of $6,200.00. The sum of $3,200.00 was paid to Respondent in advance of his beginning the job. Respondent used the sums advanced to purchase materials and supplies. The remaining $3,000.00 was to have been paid upon Respondent's completion of the job. During the negotiations that resulted in the contract between Respondent and the Moose Lodge, Respondent represented that the job should be completed in time for the functions scheduled for New Year's Eve. While Respondent had purchased the materials needed for the job and had done a substantial amount of work on a portion of the roof, he was unable to complete the work by the New Year. Respondent was ordered to stop work on the job on January 26, 1988. Respondent did not abandon the job. Although he was slow in performing the work, a part of Respondent's delay in performance was caused by rain. There was no evidence as to what would have been a reasonable period of time for Respondent to have completed the job. On January 26, 1988, the administrator for the Moose Lodge complained to the Building Inspection Department for the City of Hialeah, Florida, because the administrator was not pleased with the progress that Respondent was making toward completion of the job. The administrator was told by a representative of the Building Inspection Department on January 26, 1988, that Respondent had no license and that the required permit had not been pulled. The administrator was told to prohibit Respondent from working on the roof. Immediately thereafter, the administrator instructed Respondent to do no further work on the roof. The members of the Noose Lodge completed the job started by Respondent for less than $3,000.00, the balance of the amount that would have been owed Respondent if he had finished the job. Respondent knew that a permit was required for this work. Respondent also knew that only a licensed roofing contractor could pull the required permit. Respondent proceeded with the job when he was unable to persuade a licensed roofing contractor to pull the permit for him. Petitioner filed an administrative complaint against Respondent alleging that at the time he contracted with the Moose Lodge, Respondent's license was suspended, thus violating the provisions of Section 489.129(1)(j), Florida Statutes, and the provisions of Section 489.127(1)(e), Florida Statutes. The administrative complaint also alleged that Respondent failed to perform in a reasonably timely manner and/or abandoned the job in violation of Section 489.129(1)(m), Florida Statutes, and Section 489.129(1)(k), Florida Statutes. Respondent denied the allegations of the administrative complaint and timely requested a formal hearing. This proceeding followed. Respondent was previously disciplined by the Construction Industry Licensing Board, and his license remained under suspension at the time of the final hearing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated Section 489.127(1)(e), Florida Statutes, and Section 489.129(1)(j), Florida Statutes. It is further recommended that the final order revoke Harry Bradshaw's license in the State of Florida as a registered roofing contractor. DONE and ENTERED this 31st day of October, 1989, in Tallahassee, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 1989. COPIES FURNISHED: Harry Bradshaw 5590 East Seventh Avenue Hialeah, Florida 33013 David M. Gaspari, Esquire Adams, Coogler, Watson & Merkel, P.A Suite 1600 NCNB Tower 1555 Palm Beach Lakes Boulevard West Palm Beach, Florida 33402-2069 Kenneth E. Easley, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
Findings Of Fact Respondent, Harry Clinton Brackin, is a licensed registered roofing contractor holding license number RC0045880. Respondent was licensed at all times material to this action. Respondent is the owner and licensee for Brackin Roofing Company. Sometime around February 20, 1987, Respondent entered into a contract with Mrs. Arebelle S. Hughes, an elderly woman, to re-roof her house and remodel the front porch of her home located in Vernon, Florida. In addition to the work performed pursuant to the contract, there were verbal construction agreements between Mrs. Hughes and Respondent for the remodeling of the back porch, removing and closing out windows, replacing and framing doors, placing molding in the kitchen and various other carpentry repairs. Ms. Hughes asked Respondent to perform the additional work because she was well satisfied with the roofing job done by Respondent and she was unable to find a licensed contractor willing to come to Vernon and perform the work she wanted done. Respondent, in fact, informed Ms. Hughes he was not a contractor and in his opinion she needed a contractor. However, Ms. Hughes still wanted Respondent to do the additional work for the above reasons. Later, Mrs. Hughes became very dissatisfied with the quality of Respondent's remodeling work and advised the Respondent of her complaints. However, the evidence disclosed that her complaints were not well communicated and Respondent did generally try to meet Ms. Hughes' requests. None of Respondent's work constituted a hazardous condition and no evidence was offered which indicated an actual building code violation. The Respondent has not corrected the work. Mr. Harold Benjamin, an expert in the area of general contracting, reviewed the contract, the job site, the Respondent's license, and the pertinent Florida Statutes. Mr. Benjamin's expert opinion was that the Respondent's contracting job with Mrs. Hughes definitely exceeded the scope of Respondent's roofing license. Mr. Benjamin added that the carpentry work itself demonstrated an unfitness in the area of carpentry contracting and that Respondent's work did not in some respects meet the minimum carpentry standards for the industry. However, Respondent's work was not so bad as to constitute gross negligence in the area of contracting. This is particularly true since Respondent disclosed to Ms. Hughes that he was not a contractor and that the work she wanted done should be performed by one. Respondent's duty was thereby limited to a duty to perform reasonably given his abilities. Respondent did meet that duty. Respondent was disciplined for the same type of violation in 1986.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Department of Professional Regulation, Construction Industry Licensing Board impose an administrative fine of $2,500.00. DONE and ORDERED this 5th day of December, 1988, in Tallahassee, Florida. DIANE CLEAVINGER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 5th day of December, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 88-2721 The facts contained in paragraphs 1, 3, 4, 6, 7 and 9 of Petitioner's Proposed Findings of Fact are adopted in substance, in so far as material. The facts contained in paragraphs 2 and of Petitioner's Proposed Findings of Fact are subordinate. The facts contained in paragraph 8 of Petitioner's Proposed Findings of Fact are adopted except as to the finding pertaining to gross negligence which is rejected. COPIES FURNISHED: Elizabeth R. Alsobrook, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Harry Clinton Brackin Route 1, Box 2470 Chipley, Florida 32428 Bruce D. Lamb, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, I hereby make the following Findings of Fact: At all times relevant hereto, the Respondent, Rex Alaniz, held a registered roofing contractors license, Number RC 0042021, issued by the State of Florida, Construction Industry Licensing Board (hereinafter "the Board"). The Respondent's registered address with the Board was initially 1813 Ocean Drive, Jacksonville, Florida, then changed to 23 Seatrout, Ponte Vedra Beach, Florida. The Respondent's license reflected that he was doing business as "Rex Alaniz Roofing and Remodeling Company." During June 1984, the Respondent was doing business as Alaniz & Sons Roofing Company," a name unregistered and unqualified with the Board. Ms. Audrey Kelly met the Respondent through an as placed in the "Westside Shopper," and advertising newspaper in Jacksonville. The ad stated in part as follows: "Raindrops falling on your head? . . . labor guaranteed . . . State Licensed. . . Alaniz & Sons Roofing Company. Rex Alaniz 246-0265 if you have a leak and cannot sleep, check the rest and then get the best for less. . ." Ms. Kelly called the number listed in the advertisement and met with Buddy Clark on June 5, 1984. Mr. Clark stated that he represented Alaniz & Sons Roofing Company. After Mr. Clark looked at Ms. Kelly's roof, Ms. Kelly signed a contract for the repairs to be completed. The contract provided in part that Alaniz and Sons Roofing Company would repair and seal all exposed areas in the roof and that a one year guarantee on workmanship was included. The total contract price was $735. Ms. Kelly paid Clark $200 as an initial payment on the contract. On June 7, 1984, Respondent went to Ms. Kelly's home to repair the roof. After working approximately two and one-half hours, Respondent told Ms. Kelly that he had repaired the roof. Kelly then paid Respondent the balance of $535 which remained on the contract. On June 19, 1984, a light rain fell on Jacksonville and Ms. Kelly's roof leaked again. Ms. Kelly contacted Respondent and Respondent told her that she should wait until it rained harder so that any additional leaks could be repaired at one time. About three weeks later, a heavy rain fell and the roof leaked a lot. After the heavy rain, the Respondent went out and looked at the roof but did not perform any work on it. Respondent told Kelly that the problem was wind damage and suggested that Kelly contact her insurance company. An inspection by Ms. Kelly's insurance company revealed no wind damage to the roof. Therefore, Kelly repeatedly called Respondent, reaching his answering service, but Respondent did not return her calls. The roof continued to leak until Kelly hired another roofer who replaced the entire roof. Ms. Kelly complained to the State Attorney's office about Respondent's failure to honor the warranty on the contract. In April 1984, Mr. Otis McCray, Jr. discovered three leaks in the roof of his home and called Rex Alaniz. The Respondent went out and looked at the roof and informed Mr. McCray that he could fix it. On April 28, 1984, Mr. McCray entered into a contract with Respondent to repair the three leaks in the roof for a price of $500. A one year guarantee was included in the contract. Approximately one week after the contract was signed, Respondent told McCray that the roof had been repaired. McCray then paid Respondent the full contract price of $500. After a rainfall which occurred during the week following the completion of the repair work, McCray noticed that all three of the areas were leaking again. Thereafter, McCray called the Respondent's office approximately 5 or 6 times, leaving messages with either the receptionist or Respondent's answering service concerning the leaks. McCray also had his wife telephone the Respondent, thinking that perhaps the Respondent would respond to "a woman's voice." The Respondent failed to return any of McCray's calls and failed to return to fix the roof. Mr. McCray ultimately hired someone else to put a new roof on his home. In February 1986, the Respondent entered a negotiated plea to the offense of schemes to defraud in the Circuit Court of Duval County, Florida. The failure to properly perform the repairs and honor the promised warranties in the Kelly and McCray projects were included as a part of the offenses charged. The Respondent was ordered to pay restitution to Ms. Kelly and Mr. McCray. As of the date of the hearing, the Respondent had not made restitution to either Mr. McCray or Ms. Kelly. Douglas Vanderbilt, an investigator for the Department of Professional Regulation, attempted to serve papers upon the Respondent in November of 1985. During such attempt to serve the Respondent, Mr. Vanderbilt discovered that Respondent was no longer living at 23 Seatrout Street in Ponte Vedra Beach and had moved from that address approximately two years prior to November of 1985. At no time material hereto, did Respondent report to the Board a change of address from 23 Seatrout Street, Ponte Vedra Beach. The Respondent has been disciplined by the Board for misconduct twice in the recent past. On November 15, 1984 final action was taken by the Board to suspend Respondent's license for one year, effective January 2, 1985. On November 7, 1985, final action was taken by the Board to suspend Respondent's license for ninety days, consecutive to the one year suspension effective January 2, 1985.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law it is, therefore, RECOMMENDED THAT a final order be issued requiring Respondent to pay an administrative fine of $1,000 and suspending Respondent's license for a period of five (5) years from the date of the Final Order in this case. Provided, however, that said suspension will be terminated early without further action by the Board, at any time that Respondent shall both pay said fine and provide written proof satisfactory to the Board's Executive Director of having paid restitution of $500 to Otis C. McCray, Jr. and $735.00 to Audrey L. Kelly. DONE and ORDERED this 6th day of August, 1986 in Tallahassee, Leon County, Florida. W. MATTHEW STEVENSON, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 6th day August, 1986. COPIES FURNISHED: Lagran Saunders, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Rex Alaniz 1612-5th Street, South Jacksonville, Florida 32250 Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation P. O. Box 2 Jacksonville, Florida 32201 Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Salvatore A. Carpino, Esquire General Counsel 130 North Monroe Street Tallahassee, Florida 321301 APPENDIX The following constitutes my specific rulings pursuant to Section 120.59(2), Florida Statutes, on all of the Proposed Findings of Fact submitted by the parties to this case. Rulings on Proposed Findings of Fact Submitted by the Petitioner Adopted in Finding of Fact 1. Adopted in Finding of Fact 3. Adopted in Findings of Fact 9 and 10. Adopted in Finding of Fact 10. Adopted in Finding of Fact 11. Adopted in Finding of Fact 11. Adopted in Finding of Fact 11. Adopted in Finding of Fact 12. Adopted in Finding of Fact 12. 10. Adopted in Finding of Fact 12. 11. Adopted in Finding of Fact 5. 12. Adopted in Finding of Fact 5. 13. Adopted in Finding of Fact 5. 14. Adopted in Finding of Fact 6. 15. Adopted in Finding of Fact 6. 16. Adopted in Finding of Fact 6. 17. Adopted in Finding of Fact 7. 18. Adopted in Finding of Fact 7. 19. Adopted in Finding of Fact 7. 20. Adopted in Finding of Fact 7. 21. Adopted in Finding of Fact 8. 22. Adopted in Finding of Fact 8. 23. Adopted in Finding of Fact 8. 24. Adopted in Finding of Fact 8. 25. Adopted in Finding of Fact 8. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Adopted in Finding of Fact 13. Rulings on Proposed Findings of Fact Submitted by the Respondent (None submitted) ================================================================ =
The Issue At issue in this proceeding is whether Respondent committed the offense set forth in the Administrative Complaint and, if so, what penalty should be imposed.
Findings Of Fact Preliminary matters At all times material hereto, Respondent, Carlos Morejon, was licensed by Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board (Department), as a certified building contractor and as a registered residential contractor, having been issued license numbers CB C056745 and RR 0066530, respectively.3 In early 1993, following the landfall of Hurricane Andrew, Respondent and Sergio Casiano, a family friend, resolved to "start a company" to engage in contracting. At the time, Casiano was not certified or registered to engage in contracting, a circumstance known to Respondent; however, he apparently had years of experience in the construction trade. Conversely, Respondent, although certified and registered, was lacking in experience. According to Respondent, both he and Casiano would bid or contract jobs, and Casiano (variously described by Respondent as his field manager, superintendent, supervisor, or foreman) would actually oversee the construction, subject to Respondent's supervision "as much as my abilities" allowed.4 The Moreno job Pertinent to this case, Henry and Ester Moreno own, and have owned since approximately 1986, a single-family residence located at 8361 Southwest 47th Street, Miami, Dade County, Florida. As sited, the home is located in unincorporated Dade County. In early October 1993, the Morenos were driving in their neighborhood when they observed a house being re-roofed with a clay roof tile of a color and style they wanted installed on their home. The Morenos stopped and inquired of the owner regarding the contractor, and the owner advised them he would have the contractor contact them. That evening, Casiano telephoned the Morenos and arranged to meet with them at their home. At the meeting, the Morenos explained that they wanted to replace their existing shingles with clay roof tiles, and discussed price with Casiano; however, no agreement was reached. Before he left, Casiano gave them his business card. The card identified Casiano as the "manager" of a business described as follows: C.M. STATE BUILDING CONTRACTOR ROOFING CONTRACTOR CC# 19424 / CBC # 056745 Between Respondent and Casiano, "C.M." was understood to stand for Carlos Morejon. In August 1994, the Morenos finally resolved to have their home re-roofed, and they telephoned Casiano at the telephone number displayed on his business card. Casiano met with the Morenos on or about August 26, 1994, at which time they entered into a written agreement to remove and replace their existing roofing material. The agreement named Carlos Morejon as the contractor and Henry and Ester Moreno as the owners. Type of construction was noted as residential; project location was noted as 8361 S.W. 47th Street, Miami, Florida; and the owners' telephone number was noted as (305) 226-0503. Contract price was $6,200. The agreement was signed by Mr. and Mrs. Moreno, as owners, and Sergio Casiano, as project supervisor.5 Upon execution of the agreement, and consistent with its terms, the Morenos gave Casiano a check for fifty percent of the contract price ($3,100). The check, at Casiano's direction, was made payable to his order. Under the terms of the agreement, the balance of the contract price was to be paid as the work progressed. On August 30, 1994, with information provided by Casiano regarding the Moreno project, Respondent completed and signed a permit application, and submitted it to the Metropolitan Dade County Building and Zoning Department. The application identified the job address as 8361 S.W. 47th Street; the improvement as re-roofing, with a value of $6,000; and the owners' name and address as "Henry Moreno & Esther," 8361 S.W. 47th Street, Miami, Florida, with a telephone number of 226-0503. The application was also signed by Esther Moreno, as owner. The application was approved and the permit (number 94148351) was issued on August 31, 1994.6 Consistent with the terms of the agreement, the old roof material was removed, and the roof prepared to accept the new tile; however, cement roof tile was delivered instead of clay tile as requested by the Morenos. When advised of the error, Casiano removed the cement tiles from the job site, and on January 20, 1995, ordered clay tile from Metro Roof Tile, Inc. (Metro Roof), a local manufacturer of roof tiles. The clay tile was promptly delivered and installed. Up to that date, the Morenos had paid Casiano $5,650 of the contract price,7 with the balance of $550 due on final inspection. Casiano neglected to pay Metro Roof for the clay tile installed on the Moreno property, and on February 24, 1995, Metro Roof served the Morenos with a Notice to Owner stating that it had furnished materials for improvement of the property upon the order of Casiano. Subsequently, on April 5, 1995, Metro Roof filed a claim of lien against the property for the value of the clay tiles ($1,061.42), and served a copy of the claim of lien on the Morenos. Notwithstanding the pending claim of lien, as well as the lack of a final inspection, the Morenos met with Casiano on September 11, 1995, and inexplicably tendered to him the final payment ($550) that was due under the contract. Subsequently, the last inspection of the roof noted ten to fifteen loose tiles, and the project failed inspection. On November 22, 1995, Metro Roof, having failed to receive satisfaction of its lien, filed a civil action to foreclose its lien. The Morenos were duly served with a copy of the civil action, and on December 20, 1996, a "Final Judgment for Construction Lien Foreclosure" was rendered. The amount awarded was $1,234.42, and represented principal ($1,061.42), filing fee ($129.00), and service of process fee ($44.00). The Morenos satisfied the judgment by payment of the full amount awarded. The costs of investigation and prosecution At hearing, Petitioner offered proof, without objection, that its costs of investigation and prosecution, excluding costs associated with any attorney's time, totaled $701.96, as of April 23, 1998. (Petitioner's Exhibit 10). Previous disciplinary action On March 28, 1995, Petitioner issued a Uniform Disciplinary Citation against Respondent imposing an administrative fine of $500 for failure to provide proof, in response to a random audit, of having completed all required continuing education requirements before renewing his license. (Petitioner's Exhibit 11).
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of the violation alleged in Count I of the Administrative Complaint, and imposing, as a penalty for such violation, an administrative fine in the sum of $1,500; assessing costs of investigation and prosecution in the sum of $701.96; ordering the payment of $1,234.32 to Henry and Esther Moreno as restitution; and requiring Respondent to furnish the Construction Industry Licensing Board with proof that the Moreno roof work has successfully passed a final inspection. It is further RECOMMENDED that the Final Order dismiss Count II of the Administrative Complaint. DONE AND ENTERED this 10th day of August, 1998, in Tallahassee, Leon County, Florida. WILLIAM J. KENDRICK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 10th day of August, 1998.
Findings Of Fact The Respondent's name is Troy Griffin. The Respondent is now and was at all times relevant to the pending Administrative Complaint, a registered residential contractor in the State of Florida having been issued license number RR 0030688. The Respondent is not now and at no time material to the pending Administrative Complaint was the Respondent a certified or registered roofing contractor in the State of Florida. At all times material to the pending Administrative Complaint, the Respondent's license #RR 0030688 qualified Griffin Remodeling & Repairs, Jacksonville, Florida. In June 1978 the Respondent d/b/a Griffin Remodeling and Repairs contracted to repair the residence of June Moody, Jacksonville, Florida. The contracting work included work upon the Moody's built-up roof, which Respondent re-roofed pursuant to contract. Respondent built up the roof with more than one layer of felt in 1978. These layers were discovered by the city's inspector in 1982. Respondent returned in 1978 and patched the roof he installed. These patches were seen by the city's inspector in 1982. The owner, Moody, did not complain of leaks in 1982. There was no evidence of leaks in 1982. A roof poorly installed without sufficient tar and felt will leak within the time that has passed between 1978 and 1982. See inspector's testimony in response to Hearing Officer's question. Moody's home was a single family, one story residence. No evidence was received regarding whether the City of Jacksonville requires examinations of roofing contractors prior to their certification.
Recommendation Having found that the Respondent did not commit the alleged violations, it is recommended that the Administrative Complaint be dismissed and no action be taken. DONE and ORDERED this 23rd day of August, 1985, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings The Oakland Buildina 2009 Apalachee Parkway Tallahassee, Florida 32301 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of August, 1985. COPIES FURNISHED: W. Douglas Beason, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Troy Griffin 7443 Laura Street Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Direetor Department of Professional -I Regulation. Construction Industry Licensing Board P. O. Box 2 Jacksonville, Florida 32202
Findings Of Fact Respondent has been licensed as a registered roofing contractor at all times relevant to this proceeding. His license number is RC0042041. On August 30, 1982, Respondent contracted with the Julien P. Benjamin Equipment Company of Jacksonville, Florida, for the rental of an asphalt kettle. Respondent executed this contract in the name of his roofing and remodeling business. When Respondent failed to return the kettle or make rental payments, the equipment company filed a complaint with the State Attorney. Respondent subsequently entered a plea of guilty to the charge of Grand Theft, second degree, and was placed on 18 months probation, by order of the Duval County Circuit Court dated May 16, 1983. Respondent returned the kettle and paid the rental fees in March 1983.
Recommendation Based on the foregoing, it is RECOMMENDED: That Petitioner enter a Final Order suspending Respondent's roofing contractor's license for a period of one year. DONE AND ENTERED this 24th day of August 1984 in Tallahassee, Florida. R. T. CARPENTER Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 24th day of August 1984. COPIES FURNISHED: Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Rex Alaniz 23 Seatrout Street Ponte Verde Beach, Florida 32082 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred M. Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact During times material, Respondent was a certified roofing contractor, having been issued license number CC C014700 and was the sole qualifier for Gulfstream Contractors, Incorporated (Gulfstream). Gulfstream entered into a contract with Dr. Paul J. Schwartz, a chiropractor, to repair the roof to Schwartz' office building located at 1565 South Missouri Avenue, Clearwater, Florida. The contract between Gulfstream and Schwartz was entered into on July 22, 1985, and for a fee of $1,375.00, Gulfstream contracted to repair Schwartz' roof by tearing off the old gravel roof, install new decking and lead boots, to galvanize the roof and to remove all debris brought about as a result of the contracting activities. Gulfstream guaranteed the roof to be free of defects for a period of ten (10) years. (Petitioner's Exhibit 1.) Gulfstream commenced the repairs to Schwartz' roof without obtaining a construction permit and failed to call for progress inspections as was required by the City of Clearwater. Within one month following Respondent's completion of Schwartz' roof, Schwartz encountered leaks to the interior of his office building resulting in stained carpet, interior walls, and furniture in several of his examining rooms. Schwartz made repeated calls to Gulfstream in an effort to get Gulfstream to honor its ten-year guarantee on the roof. Respondent initially attempted to correct (repair) the roof, although he failed to return to the project after two or three visits during the first two months following completion of the project during July 1985. Thomas Chiplinsky is an inspector for the City of Clearwater whose area of responsibility includes the inspection of roofing projects. As part of his duties, Inspector Chiplinsky inspected Schwartz' roof following a complaint received by the City of Clearwater and found that the roof was installed in July 1985 by Gulfstream and no permit was obtained or inspections called for or made by Respondent. Inspector Chiplinsky observed soft spots in the roof and noted that Respondent failed to install counter flashing. Respondent acknowledges his responsibility as qualifier for Gulfstream. Respondent admits that he neither obtained a permit to perform the roof repairs, nor did he call for inspections as required by the City of Clearwater. Within months after Respondent completed the Schwartz project, the entity, Gulfstream Contractors, was disbanded and therefore no one responded to Schwartz' request that his roof be repaired.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that: Petitioner enter a Final Order imposing a $500 fine against Respondent, payable to Petitioner within 30 days of the entry of its Final Order. Respondent's license number CC C014700 be suspended for a period of one (1) year within the further condition that Respondent be allowed a period of 20 days following the entry of the Final Order to revisit the Schwartz project and make the necessary repairs to correct the roof repairs and abide by the terms of his guarantee. In the event that Respondent makes the necessary repairs within 30 days of entry of the Final Order, it is further RECOMMENDED that the period of suspension be suspended. RECOMMENDED this 16th day of March, 1989, in Tallahassee, Leon County, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 16th day of March, 1989. COPIES FURNISHED: David Bryant 500 North Tampa Tampa, Florida 33602 Richard Domingo 4032 41st Avenue North St. Petersburg, Florida 33710 Kenneth E. Easley, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Construction Industry Licensing Board 111 East Coastline Drive Jacksonville, Florida 3220
Findings Of Fact At all times material hereto Respondent has been a registered roofing contractor in the State of Florida, having been issued license number RC- 0042963. At no time material hereto did Respondent's license qualify "Energy Plus Roofing" with Petitioner. Notice of the final hearing herein was provided to Respondent at his last known address of record in Bradenton, Florida, as shown on his Election of Rights form. The notice was not returned by the post office as "undeliverable" or for any other reason. In April, 1988 Respondent entered into a contract to perform certain roofing work for John Beede at a contract price of $1,610. Respondent executed this contract on behalf of Energy Plus Roofing, and provided a ten year warranty on workmanship and materials. Beede paid the full contract price to Respondent for work performed, but Respondent failed to correct leaks in Beede's Florida room. In fact, after the job Beede had additional leaks in his Florida room. Respondent failed to respond to several calls from Beede for further corrective work under the ten year warranty. Finally, Beede had to have a "roof over" constructed to correct the leaks in his Florida room at an additional cost of $4,000. Respondent did not obtain any permit from Manatee County for the work he performed for Beede, although Manatee County requires contractors to obtain permits for such jobs in excess of $200. Additionally, Respondent did not register "Energy Plus Roofing" with Manatee County, although Manatee County does require such registration. In March, 1986 Respondent entered into a contract with Marie Allen for roof repair on her mobile home in Ruskin, Hillsborough County, Florida. Allen did not have any leaks in her roof at the time, but she was simply seeking preventive maintenance. Respondent contracted with Allen on behalf of Energy Plus Roofing to pressure clean her roof and "apply energy plus roof system to (her) existing roof" for a contract price of $1,000. Respondent provided a ten year warranty on workmanship and materials. After Respondent's crew pressure cleaned her roof, Allen began experiencing leaks, and she presently continues to have four leaks which she did not have before work was performed by Respondent. She has tried repeatedly to contact Respondent under the warranty, but has been unsuccessful. Respondent is not registered in Hillsbourough County, and he did not obtain any permits for the Allen job. Hillsborough County requires contractors to be registered and to obtain permits for jobs such as he performed on Allen's roof. The only name on Respondent's license is his own individual name, Emanuel Fred Mosley.
Recommendation Based upon the foregoing, it is recommended that Petitioner enter a Final Order suspending Respondent's registration for a period of one (1) year and imposing an administrative fine of $1,000 upon Respondent. DONE AND ENTERED this 4th day of May, 1987 in Tallahassee, Florida. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 4th day of May, 1987. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-0442 Rulings on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact 1. Adopted in Finding of Fact 2. 3-8 Adopted in Finding of Fact 4. 9 Adopted in Finding of Fact 5. 10-14 Adopted in Finding of Fact 6. 15-16 Adopted in Finding of Fact 7. COPIES FURNISHED: W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32399-0750 Emanuel Mosley 5707 5th Street East Bradenton, FL 33507 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32201 Van Poole, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32399-0750 Joseph A. Sole General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32399-0750
Findings Of Fact At all times material hereto, Respondent has been a registered roofing contractor in Miami, Florida, having been issued license no. RC 0047352. Respondent is the qualifying agent for All Central Roofing, Inc. In May 1986 All Central Roofing, Inc., entered into a contract with Richard Crisonino to perform certain roofing work on Crisonino's residence in Miami, Florida. The contract price was $3,374. All Central Roofing, Inc., thereafter began the roofing work on Crisonino's residence without obtaining a permit for that work from the local building department and without posting a permit on the job site. All Central Roofing, Inc., failed to obtain the required inspections by the local building department. After completing part of the work involved and after receiving substantial payment under the contract, All Central Roofing Company, Inc., ceased work on the Crisonino residence and failed or refused to complete the work, thereby abandoning the job. By her own admissions at the final hearing in this cause, Respondent does not possess a working knowledge of roofing or roofing contracting. She lacks even a basic fundamental understanding of roofing construction to the extent that it is impossible that she is fulfilling any of her responsibilities as a qualifying agent for All Central Roofing, Inc. Further, Respondent does not even know the number of employees working for All Central Roofing, Inc. Respondent has been disciplined by the Dade County Construction Trades Qualifying Board, and Respondent's personal and business certificates have been revoked by that Board.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is, RECOMMENDED that a Final Order be entered finding Respondent guilty of the allegations contained in the Administrative Complaint filed against her and revoking Respondent's registered roofing contractor license. DONE and RECOMMENDED this 14th day of December, 1987, at Tallahassee, Florida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of December, 1987. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 G. Vincent Soto, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Harry E. Geissinger, Esquire 415 West 51st Place, Suite 201 Hialeah, Florida 33012 Tom Gallagher, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
