The Issue This is a license discipline proceeding in which the Petitioner seeks to take disciplinary action against the Respondent on the basis of alleged violations of Chapter 489, Florida Statutes, (1992 Supp.). Specifically, the Respondent has been charged in a four-count Administrative Complaint with violations of paragraphs (k), (m), (n) and (p) of Section 489.129(1), Florida Statutes (1992 Supp.).
Findings Of Fact Respondent is, and has been at all times material hereto, a licensed Certified General Contractor, having been issued license number CG C007303, by the State of Florida. At all times material hereto, the Respondent was licensed to contract as an individual. On September 18, 1992, the Respondent, doing business as an individual, contracted with Charles and Elba Williams (hereinafter referred to as "Customers") to reroof their dwelling and shed at 15205 SW 78 Place, Miami, Florida, for the price of Fifteen Thousand, One Hundred Seventeen dollars ($15,117.00). On October 1, 1992, the aforementioned contract was amended to provide for the payment of half of the second draw before the second stage of the project was completed, and to provide for the payment of an additional Three Hundred and Fifty One dollars ($351.00) in materials. On November 5, 1992, the aforementioned contract was amended to provide the Customers with a credit on the contract of One Thousand, Six Hundred Thirty Six dollars and Sixty Four cents ($1,636.64) for their purchase of roof shingles. The revised contract price was Sixteen Thousand and Fifty Eight dollars ($16,058.00). The Customers paid the Respondent Twelve Thousand, Two Hundred Seventy Seven dollars and Ninety cents ($12,277.90) toward the contract. After receiving a credit on the balance due on the contract, the Customers owed Two Thousand, One Hundred Forty Two dollars and Thirty Two cents ($2,142.32) to the Respondent. On September 23, 1992, the Respondent obtained roofing permit number 92-110050 for the Customers' project from the Dade County Building and Zoning Department. The Respondent worked on the Customers' roof from September 23, 1992, through November 15, 1992, when the installation of the shingles was completed. On November 19, 1992, the Respondent failed a final inspection performed on the Customers' roof by the Dade County Building and Zoning Department because the Respondent failed to supply Dade County with product approval information and manufacturer installation specifications for the ridge vent he had installed. On November 24, 1992, the Respondent again failed a final inspection performed on the Customers' roof by the Dade County Building and Zoning Department for the same reason as on November 19, 1992. The Respondent never obtained a passing final inspection on the Customers' roof from the Dade County Building and Zoning Department. On November 24, 1992, the Customers sent the Respondent a Certified letter, Return Receipt requested, informing the Respondent that the roof could not pass final inspection until Dade County was provided with the product approval information and manufacturer installation specifications for the ridge vent he had installed. On December 4, 1992, the Respondent was issued a Notice of Violation from the Dade County Building and Zoning Department for failure to provide product approval information and manufacturer installation specifications for the ridge vent that had been installed on the Customers' roof. On December 4, 1992, the Respondent was issued a Notice of Violation from the Dade County Building and Zoning Department for failure to remove construction debris from the Customers' property. The Respondent did not comply with either Dade County Notice of Violation and did not supply the Dade County Building and Zoning Department with the product approval information and manufacturer installation specifications for the ridge vent that had been installed on the Customers' roof. The Customers were left with a roof that did not comply with Dade County Code. On March 26, 1993, the Customers paid a Forty Five dollar ($45.00) renewal fee to the Dade County Building and Zoning Department and had the roofing permit renewed and reissued in their own names. On March 4, 1993, the Customers paid another contractor, Mark Mitchell, Two Hundred dollars ($200.00) to remove the ridge vent and close the hole in the roof left by the removal of the ridge vent. On March 27, 1993, after the ridge vent had been removed, the Customers paid a Special Investigator, Ken Nash, Fifty dollars ($50.00) to perform a final inspection of the roof. On March 31, 1993, Ken Nash performed a final inspection of the roof and the roof passed inspection. The Customers paid Steve Wooten Thirty dollars ($30.00) to remove construction debris left on their property by the Respondent and to bring their property in compliance with the Notice of Violation issued on December 4, 1992.
Recommendation On the basis of all of the foregoing, it is RECOMMENDED that the Construction Industry Licensing Board issue a Final Order in this case to the following effect: Dismissing the charges alleged in Counts I, II, and IV of the Administrative Complaint; Concluding that the Respondent is guilty of the violation charged in Count III of the Administrative Complaint; and Imposing a penalty consisting of a fine in the amount of Two Hundred Fifty dollars ($250.00) for the violation charged in Count III of the Administrative Complaint. DONE AND ENTERED this 3rd day of May, 1995 in Tallahassee, Leon County, Florida. MICHAEL M. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of May, 1995. COPIES FURNISHED: Diane Snell Perera, Esquire Department of Business and Professional Regulation 7300 North Kendall Drive, Suite 780 Miami, Florida 33156 Mr. Al C. Hufeld Post Office Box 681064 Orlando, Florida 32868-1064 Richard Hickok, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda Goodgame, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are made: At all times material to this proceeding, Respondent Joseph W. Miklavic was licensed as a certified building contractor in the state of Florida, holding license number CB C006615, qualifying Security Home d/b/a Security Homes of Clearwater (Security). Since March, 1989 the Respondent's license has been on active status qualifying, Individual. At all times material to this proceeding, Respondent was a salaried employee of Security. Ronald MacLaren was president of Security and also sole owner and president of Yankee Construction Inc. d/b/a Olympic Homes of Citrus County (Olympic). In accordance with a management agreement between Security and Olympic, the Respondent was assigned by Ronald MacLaren to oversee the operation of Olympic. Olympic was licensed to engage in construction having been qualified by Wilmon Ray Stevenson through license number RB A035005 which was in effect from June, 1987 until October, 1988 when Stevenson filed a change of status application with the Construction Industry Licensing Board (Board) requesting license number RB A035005 be changed to inactive status qualifying, Individual. While this application was not acted upon until February, 1989, the Board considered license number RB A035005 in effect as qualifying Olympic only until October, 1988. Effective September 26, 1988, the name of Yankee Construction, Inc. was changed to Rivercoast Homes, Inc. (Rivercoast) which apparently ceased doing business under the fictitious name of Olympic Homes of Citrus County. On September 19, 1988 Wilmon Ray Stevenson advised the Citrus County Building Department that he was no longer the "qualifier for Olympic Homes". Around this same time, the Respondent, Ronald MacLaren and the management of Olympic became aware that Stevenson would no longer be the qualifying agent for Olympic. There was no evidence that Rivercoast Homes, Inc. a/k/a Yankee Construction Inc. ever advised the Board of the name change or the termination of Stevenson as its only qualifying agent affiliation in accordance with Section 489.119(2)(3), Florida Statutes. Nor was there any evidence that Rivercoast was ever qualified by another qualifying agent pursuant to Section 489.119, Florida Statutes. In accordance with the agreement between Security and Olympic, referred to in Finding of Fact 4, the Respondent continued to oversee the Rivercoast operations until sometime around December 1988 when all of MacLaren's operations in Florida, including Security, closed down. Under Security's agreement with both Olympic and Rivercoast, Respondent's duties included working with management and subcontractors to develop construction schedules and to advise Ron MacLaren of the financial aspect of the company so that MacLaren could make funds available to pay subcontractors, etc. Respondent did not have any control over the finances of either Olympic or Rivercoast such as receiving, depositing or disbursing funds. Either in late September or early October of 1988, Respondent approached Larry Vitt, Citrus County Building Department, as to whether the Respondent could pull permits under his license for Olympic or Rivercoast. Vitt advised Respondent that unless he qualified the company he could not pull permits for that company under his license. Respondent advised MacLaren that Rivercoast would have to have a qualifying contractor in order to engage in contracting. MacLaren did not get Rivercoast qualified to engage in contracting at anytime. Respondent did not qualify Rivercoast under his contractor's license at anytime. Sometime around the last of September or the first part of October of 1988, Respondent became aware that Rivercoast a/k/a Yankee Construction, Inc. was no longer qualified under Section 489.119, Florida Statutes, and therefore, not authorized under law to engage in contracting. On August 16, 1988 Ernest and Marjorie Ellison met with Ken Smith and Gloria Stevenson of Olympic to discuss Olympic building the Ellisons a home. The Ellisons picked out a floor plan at this time and gave Olympic a $100.00 deposit to hold the price until a contract could be executed. On October 1, 1988 the Ellisons met again with Ken Smith and was introduced to the Respondent who gave them a brief run down on the status of the company and advised them that the company was in "good shape". At this meeting, Ken Smith advised the Ellisons of certain things that were required of them before construction began, including a survey. On October 31, 1988 the Ellisons signed a contract with Rivercoast to construct their home. In his capacity as a representative of Security, under the agreement between Security and Rivercoast, the Respondent signed this contract on the line designated Contractor/Representative. There is insufficient evidence to show that Respondent intended to sign the contract as contractor of record as the term contractor is defined in Section 489.105(3), Florida Statutes (Supp. 1988), and thereby impose upon himself the responsibility for the entire project. The contract price was $44,634.00. On November 1, 1977 the Ellisons delivered to Rivercoast a check for $4,363.40 which along with the $100.00 deposit paid in August represented a total down payment of $4,463.40. Respondent did not personally receive any funds from the Ellisons for Rivercoast or receive any funds for himself from the Ellisons under this contract. No permit was ever pulled or any work performed by Rivercoast under the aforementioned contract. Ernest Ellison met with Respondent on November 21, 1988 and requested that the contract be cancelled. Under the authority granted Respondent through the agreement between Security and Rivercoast, the Respondent and Ernest Ellison signed the contract as being cancelled on November 21, 1988. Although the Ellisons were offered an opportunity by the Respondent to transfer their deposit of $4,463.40 to Security and enter into a contract with Security to build their house, they declined and contracted with another contractor. On the date the contract was cancelled, Respondent advised Ernest Ellison that the down payment of $4,463.40 would be reimbursed. Although Respondent attempted to obtain a refund for the Ellisons from MacLaren and was advised by MacLaren that a refund was forthcoming, no refund of the Ellison's down payment was ever made by Rivercoast, Ronald MacLaren, the Respondent or anyone else. Respondent was aware during the negotiation and at the time the Ellison's contract was executed, that Rivercoast was not authorized by law to engage in contracting. However, there is insufficient evidence to show that Respondent ever advised the Ellisons that he would be the contractor responsible for building their home under the contract with Rivercoast or that he would be the contractor to pull the necessary permits for construction of their home. There is no evidence that Respondent had any financial interest or owned any stock or held any office in Rivercoast a/k/a Yankee Construction, Inc. Around October 1, 1988, after Stevenson had withdrawn as qualifying agent for Olympic, Rivercoast was no longer authorized to engage in the practice of contracting since it had not been qualified by another qualifying agent in accordance with Section 489.119, Florida Statutes.
Recommendation Having considered the foregoing Findings of Fact and Conclusions of Law, the evidence of record, the demeanor of the witnesses and the disciplinary guidelines set out in Chapter 21E- 17, Florida Administrative Code, it is RECOMMENDED: That the Board enter a final order finding Respondent guilty of violating Section 489.129(1)(e), Florida Statutes, and for such violation it is recommended that the Board assess the Respondent with an administrative fine of $1,000.00. It is further recommended that Counts I, II, IV and V be dismissed DONE and ORDERED this 27th day of November, 1990, in Tallahassee, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of November, 1990. APPENDIX CASE NO. 90-2046 The following constitute my specific rulings pursuant to Section 120.59(2), Florida Statutes, on all of the proposed findings of fact submitted by the parties in this case. Rulings of Proposed Findings of Fact Submitted by the Petitioner Not necessary. Adopted in Finding of Fact 1. Adopted in Finding of Fact 7 but modified. Adopted in Findings of Fact 4, 8, and 10. Adopted in Findings of Fact 9 and 14 but modified. Adopted in Finding of Fact 15. Adopted in Findings of Fact 16 and 17 but modified. Adopted in Findings of Fact 17 and 18. Rulings of Proposed Findings of Fact Submitted by Respondent 1. - 2. Not material or relevant. Adopted in Findings of Fact 1, 7 and 20. Adopted in Finding of Fact 4. Adopted in Findings of Fact 4 and 8. Not material or relevant. Adopted in Finding of Fact 19. - 10. Adopted in Finding of Fact 15. Restatement of testimony not a Finding of Fact but see Finding of Fact 13. Adopted in Finding of Fact 15. Not material or relevant. Adopted in Finding of Fact 15. - 16. Not material or relevant. Restatement of testimony not a Finding of Fact but see Findings of Fact 13, 14 and 15. Adopted in Finding of Fact 19 but modified. Not material or relevant. Adopted in Finding of Fact 4. Restatement of testimony not a Finding of Fact but see Finding of Fact 4. Adopted in Finding of Fact 9. Adopted in Finding of Fact 4 but modified to show license effective until October, 1988 rather than February, 1989. Restatement of testimony not a Finding of Fact but see Findings of Fact 1, 7 and 20. - 26. Not material or relevant. Adopted in Finding of Fact 4 but modified to show from June, 1987 until October, 1988. - 29. Adopted in Findings of Fact 5 and 13. Restatement of testimony not a Finding of Fact but see Finding of Fact 4. - 32. Adopted in Findings of Fact 4, 8 and 9 but modified. Not material or relevant. - 36. Adopted in Findings of Fact 4, 8, and 9 but modified. Adopted in Finding of Fact 10. Not material or relevant. - 40. Adopted in Findings of Fact 8, and 17, respectively. Rejected as there is no substantial competent evidence in the record to show any other contract than the one Respondent signed on October 31, 1988. Not material or relevant. Not supported by substantial competent evidence in the record. Not material or relevant. Adopted in Finding of Fact 18. Restatement of testimony not a Finding of Fact but see Finding of Fact 9. - 50. Not necessary to the conclusion reached since this matter was covered in the Preliminary Statement wherein the motion was denied. COPIES FURNISHED: G. W. Harrell, Senior Attorney Department of Professional Regulation 1940 N. Monroe Street, Suite 60 Tallahassee, FL 32399-0750 Geoffrey Vining, P.A. 2212 South Florida Avenue Suite 300 Lakeland, FL 33803 Daniel O'Brien, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32202 Kenneth D. Easley, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792
Findings Of Fact Leroy Alvin Colts was qualifier for Berkley Home Service, which held License #RC0029635. Colts held such license from 1977 - 81. In December 28, 1978, Leroy Alvin Colts' local certificate of competency was revoked by the Pinellas County authorities. This action was reviewed by the Florida Construction Industry Licensing Board prior to these charges being filed. On January 4, 1979, Leroy Alvin Colts was adjudged guilty of violating Section 812.021 (Grand Theft) and Section 812.014 (Grand Larceny) and sentenced to 45 years in the State Penitentiary. These offenses arose directly from Colts' activities as a licensed contractor. The court's judgment was affirmed by the appellate court. Notice of this proceeding was provided Colts in the manner prescribed by law, and inquiry of Counsel for the Petitioner Board and representatives of the St. Petersburg Police Department showed that Colts was free on bond and available to attend the hearing.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, the Hearing Officer recommended that the Florida Construction Industry Licensing Board revoke Leroy Alvin Colts' license. DONE and ORDERED this 21st day of September, 1979, in Tallahassee, Leon County, Florida. STEPHEN F. DEAN, Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 COPIES FURNISHED: Michael E. Egan, Esquire 247 South Adams Street Post Office Box 1386 Tallahassee, Florida 32302 Joseph F. McDermott, Esquire 544 First Avenue, North St. Petersburg, Florida 33701 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner,
Findings Of Fact Petitioner is the state agency charged, in conjunction with the Construction Industry Licensing Board, with the responsibility for prosecuting Administrative Complaints pursuant to chapters 455 and 489, and the rules promulgated thereunder. In September, 1983, license number CR C012950 was issued to Respondent, David A. Taylor, as the qualifying agent for Energywise Homes, Inc., 3305 S.W. 1st Court, Deerfield Beach, FL 33441. License number CR C01295p remained in effect until June 30, 1987. License number CR C012950 was delinquent and invalid from July, 1987, through May 10, 1988. In July, 1987, license number CR C012950 was placed on a delinquent status for non-renewal and considered invalid. On April 19, 1988, Respondent applied for renewal and reinstatement of license number CR C012950. Respondent's application for renewal and reinstatement was approved May 11, 1989. At that time, license number CR C012950 was changed from a qualifying business to an individual license. In April, 1988, Respondent applied to the City of Sebastian, Florida Construction Board (the "City") for an occupational license in order to obtain building permits for jobs he had contracted in that jurisdiction. License number CR C012950 was delinquent and invalid at the time Respondent applied to the City for an occupational license and permits. Respondent presented an altered license to Ms. Kathryn Nappi, the person responsible for issuing occupational licenses for the City in April, 1988, for the purpose of obtaining building permits from the City. The typeface on the license presented by Respondent to Ms. Nappi does not match either that used on the bottom portion of the same license or the copy of the licenses admitted as Respondent's Exhibit 1. Further, the date used on the altered license is not a date normally used by the Construction Industry Licensing Board. Finally, the license presented by Respondent to Ms. Nappi indicated the license was held by Respondent individually rather than as qualifying agent for Energywise Homes, Inc. The testimony of the witnesses for Petitioner was consistent and credible. The procedures followed by Ms. Nappi and her supervisor, Mr. Bruce Cooper, Director of Community Development and Building Official for the City of Sebastian, were customary procedures followed in the ordinary course of their business. Neither witness had any discernible motive for fabricating the events to which they testified. Respondent presented the altered license to Ms. Nappi sometime in April, 1988, for the purpose of obtaining building permits for the five homes to be constructed in the City. Ms. Nappi noticed that the type on the top of the license submitted by Respondent did not match the bottom portion. She brought the discrepancy to the attention of Mr. Cooper. Mr. Cooper confirmed with the Department of Professional Regulation that the license submitted to Ms. Nappi by Respondent had been altered. Mr. Cooper set up a meeting between himself, Respondent, and two detectives to ascertain Respondent's position concerning the altered license. Mr. Cooper did not believe Respondent's position and placed the matter on the agenda for the May 3, 1988, meeting of the Sebastian Construction Board (the "Board") 3/ Respondent and the owner of the five homes for which permits were being sought appeared at the May 3, 1988, meeting of the Board. The Board voted to approve the building permits subject to the issuance of a valid license by the Department of Professional Regulation. The owner requested issuance of the permits because delay was causing his investment to dwindle. The Board also considered the fact that the properties were becoming an eyesore in the City. The Board voted to approve the permits, subject to Respondent obtaining a valid license, and leave the issue of the altered license to the Department of Professional Regulation. Respondent's testimony that he did not present an altered license for the purpose of obtaining building permits from the City, and that he had never previously seen the altered license, is rejected as not credible. Such testimony is inconsistent with statements by Respondent to Mr. Cooper and at the May 3, 1988, meeting of the Board, which were admitted in evidence as exceptions to hearsay under Section 90.8C3(18). Respondent's testimony is also inconsistent with the greater weight of evidence. Financial pressures caused by previous delays in obtaining permits provided a motive for Respondent to present an altered license to obtain building permits for the five homes to be constructed in the City. Previous attempts by others to obtain building permits for five homes to be constructed in the City had been unsuccessful. Respondent made several further attempts to obtain building permits for the five homes to be constructed in the City. The delays in obtaining the permits had caused the investment of the owner of the homes to dwindle. Furthermore, the homes were becoming an eyesore for the City. Respondent committed an act of fraud, deceit, and misconduct in April, 1988, when Respondent intentionally presented an altered license to Ms. Nappi to obtain building permits for the five homes to be constructed in the City. No evidence has been presented to support a finding that Respondent altered the license presented to Ms. Nappi. However, Respondent knew or should have known that the license submitted by him had been altered, and Respondent submitted the altered license for the purpose of obtaining the needed building permits. Even without the requisite intent for fraud, deceit, and misconduct, Respondent is not exonerated. Inadvertently presenting an altered license to Ms. Nappi in April, 1988, at a time when Respondent knew his license was delinquent and invalid constitutes gross negligence and incompetence in the practice of contracting.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Respondent be found guilty of fraud, deceit, gross negligence, incompetency, or misconduct in the practice of contracting in violation of Section 489.129(1)(m). Florida Administrative Code Rule 21E-17.001 provides in relevant part: "The following guidelines Shall be used in disciplinary cases, absent aggravating or mitigating circumstances and subject to the other provisions of this Chapter. (emphasis added) * * * (19) 489.129(1)(m): Gross negligence, incompetence, and/or misconduct, fraud or deceit. (a) Causing no monetary harm to licensee's customer, and no physical harm to any person. First violation, $250 to $750 fine; repeat violation, $1,000 to $1,500 fine and 3 to 9 month suspension. Florida Administrative Code Rule 21E-17.002, describes aggravating and mitigating circumstances which may be considered in determining the penalty to be imposed in a particular proceeding. Petitioner produced no evidence of any aggravating circumstances other than the alleged violations of Sections 489.113 and 489.115. There was no evidence of monetary or other damage to the licensee's customer, actual job site violations, repetitive offenses, the number of complaints filed against Respondent, or actual damage to the licensee's customer. See Fla. Admin. Code Rule 21E-17.002(1),(2),(s),(6), and (8). Considering the absence of any aggravating factors, the length of time Respondent has practiced contracting without any complaint, the de minimis danger to the public, and the fact that the Board approved the permits sought by Respondent because of the beneficial effect the permits would have on the owner and the City, it is recommended that Respondent be fined $250. DONE AND ORDERED in Tallahassee, Leon County, Florida, this 26th day of February, 1990. DANIEL MANRY Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 26th day of February, 1990.
The Issue The issue for determination is whether Respondent committed the offenses set forth in the Administrative Complaint and, if so, what action should be taken.
Findings Of Fact At all times material hereto, Mr. Borek was licensed by the Department as a certified general contractor, having been issued license number CG C 58817. He was licensed on November 18, 1996. At all times material hereto, Mr. Borek was the qualifying agent of Atlantic Coast General Contractors, Inc. (ACGC), a Florida corporation, and has been its president. ACGC was issued a certificate of authority as a contractor qualified business on June 2, 1977, having been issued license number QB 07357. ACGC's license expired on September 1, 2001 and became null and void on September 1, 2003. The State of Florida, Department of State, administratively dissolved ACGC, as a corporation, on October 1, 2004, for its failure to file its annual report, as required by law; and, as a result, ACGC's authority to transact business, as a corporation, in the State of Florida was revoked on the same date. At all times material hereto, Tracey Meredith (Ms. T. Meredith) resided in and owned a home located at 7690 Northwest 16th Court, Pembroke Pines, Florida. Ms. T. Meredith wanted her mother, Jane Meredith1 (Ms. J. Meredith), to live with her so Ms. T. Meredith decided to have an addition built to her home, consisting of a bedroom, bathroom, and closet. Ms. T. Meredith obtained a proposal from ACGC and five other contractors for the addition. Each contractor was aware of the purpose of the addition. Ms. T. Meredith decided to contract with ACGC, which was not the lowest or the highest bidder, but was somewhat in the middle. On June 28, 2002, a Proposal/Contract (Contract) was executed with ACGC for the addition at a cost of $32,925.00. Even though the Contract showed Ms. T. Meredith as the contracting party, it was signed by Ms. J. Meredith because she (Ms. J. Meredith) was actually paying for the addition and signing the checks. Both Mses. T. Meredith and J. Meredith were in agreement with the Contract. The Contract provided, among other things, that the addition was 15 x 21; and that the payments would be as follows: 20% at acceptance of the Contract, 20% at permit issuance, 10% at slab, 20% at wall and roof framing, 10% at roof completion, 10% at finished walls and flooring, and 10% at final completion. No dispute exists that the cost of the Contract was reasonable. No dispute exists that the Contract failed to contain a provision explaining the consumer's rights under the Florida Homeowners' Construction Recovery Fund, formerly known as the Construction Industries Recovery Fund. No dispute exists that the Contract did not provide a date for completion of the addition. Regarding a completion date for the addition, Ms. T. Meredith testified that all the other proposals provided that the addition would be completed within six to eight weeks and that, at the beginning, Mr. Borek orally communicated to her that the addition would be completed by ACGC within six to eight weeks. To the contrary, Mr. Borek testified that, at the beginning, no completion date was given to her, either orally or in writing. None of the other proposals were submitted into evidence, only the Contract with Mr. Borek, which did not provide a completion date. It would not be reasonable for Ms. T. Meredith to accept Mr. Borek's proposal without it’s being within the time period of completion of the other proposals. The undersigned finds Ms. T. Meredith's testimony more credible and makes a finding of fact that, at the time of the signing of the Contract, Mr. Borek made an oral representation that the addition would be completed by ACGC within six to eight weeks. An expert in the field of general contracting, John Yanoviak (Mr. Yanoviak), testified on behalf of the Department. The undersigned finds his testimony credible, except as specifically indicated. A reasonable amount of time to complete the addition was a maximum of three months. Mr. Borek, as the contractor, was responsible for keeping the project timely and for quality control. On June 30, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,585.00. This amount was 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. Paying this amount was in accordance with the Contract. Mr. Borek filed an application for a building permit with the City of Pembroke Pines (CPP) on or about July 3, 2002. The building permit was issued by CPP on or about October 25, 2002. Work on the addition was commenced before the issuance of the building permit. Ms. T. Meredith was aware of the date that the building permit was issued. Prior to the issuance of the building permit, Ms. T. Meredith complained to Mr. Borek regarding the addition’s not being completed. No evidence was presented to show that Ms. T. Meredith indicated to Mr. Borek that, by his failure to complete the addition within a six-to- eight-week period, he was not abiding by the Contract. No evidence was presented to show that she indicated her dissatisfaction to the degree of possibly terminating the Contract with ACGC. On November 12, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,585.00. This amount was paid after Mr. Borek obtained the building permit and was 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. Paying this amount was in accordance with the Contract. On December 11, 2002, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $6,885.00. This amount was $300.00 more than 20 percent of the contracted cost for the addition. No dispute exists that this check was written and presented to Mr. Borek. An inference is drawn and a finding is made that this check was written in advancing of the addition. According to the records of the CPP's building department2 (Records), a CPP form for a revision to the addition was submitted on January 6, 2003, providing for an electrical change to the addition. Further, the Records indicate that, on March 20, 2003, an application for an electrical permit was submitted and that, on March 24, 2003, the permit was approved. Also, a revision to the plans of the addition was submitted to the CPP by the architect to the addition, Hernando Acosta, according to the Records. The Records indicate that the revision to the plans was dated January 30, 2003 by Mr. Acosta, that the revision was submitted on February 7, 2003, and that the revision was approved on February 11, 2003 by the CPP. In addition, in February 2003, Ms. T. Meredith received written communication from the CPP regarding a problem with the addition. Ms. T. Meredith received a copy of a letter from the CPP to Mr. Borek, dated February 18, 2003. The letter indicated, among other things, that the CPP had issued a "stop work status" on the addition due to Mr. Borek’s having issued a check, payable to the CPP, in the amount of $135.80, which was dishonored. Another revision, according to the Records, was submitted on March 27, 2003, regarding the trusses. The Records indicate that the revision was approved on April 17, 2003. Ms. T. Meredith became more dissatisfied with the progress toward completion on the addition by Mr. Borek to the point that she filed a complaint with the Department on May 21, 2003. In May 2003, Ms. T. Meredith received written communication from the CPP regarding a problem with the addition. By letter dated May 22, 2003, she received notification from the CPP, as information only, that a code violation had not been corrected within the allowable ten-day period, together with a copy of CPP's letter to Mr. Borek, dated May 22, 2003, of his failure to correct the code violation. The letter to Mr. Borek indicated, among other things, that Mr. Borek had until June 11, 2003 to correct the violation, identifying the inspection date and the violation. By a letter dated May 28, 2003, Ms. T. Meredith advised Mr. Borek, among other things, that he had seven days to continue with the work on the addition in accordance with the Contract or else the Contract would be considered by her to be "null and void"; that, if he did not do so, she would be "forced" to hire another contractor, with Mr. Borek being held financially responsible for completion of the addition; and that the Contract was to be completed within six to eight weeks. On June 12, 2003, Mr. Borek contacted the investigator for the Department regarding the complaint filed by Ms. T. Meredith. Among other things, Mr. Borek informed the investigator that he (Mr. Borek) was willing to complete the addition in 30 days. By his representation, Mr. Borek indicated that he would complete the addition on or about July 12, 2003. By a letter dated June 18, 2003, Mr. Borek notified the investigator, among other things, that he was working "diligently" to complete the addition. Mr. Borek failed to complete the addition within the 30-day period, as he had represented to the Department's investigator. The Records indicate that an application for a building permit, involving the roof to the addition, was submitted on June 25, 2003. The permit was issued, according to the Records, on July 30, 2003. Further, the Records indicate that a revision, regarding the size of a window and the elimination of a door, was submitted on July 8, 2003, and approved on July 9, 2003. In July 2003, Ms. T. Meredith received another written communication from the CPP regarding a problem with the addition. By letter dated July 9, 2003, she received notification from the CPP, as information only, that a code violation had not been corrected within the allowable ten-day period, together with a copy of CPP's letter to Mr. Borek, dated July 9, 2003, of his failure to correct the code violation. The letter to Mr. Borek indicated, among other things, that Mr. Borek had until July 28, 2003, to correct the violation, identifying the inspection date and the violation. In addition, in July 2003, Ms. T. Meredith received written communication from the CPP regarding another problem with the addition. She received a copy of a letter from the CPP to Mr. Borek, dated July 18, 2003, which indicated, among other things, that the CPP had issued a "stop work status" on the addition due to Mr. Borek having issued a check, payable to the CPP, in amount of $76.23, which was dishonored. Even though Mr. Borek failed to complete the addition within the 30-day period that he had represented to the Department's investigator and even though Ms. T. Meredith had received notification of the problems at the jobsite from the CPP, on September 10, 2003, Ms. J. Meredith wrote a check, payable to ACGC, in the amount of $4,000.00. No dispute exists that this check was written and presented to Mr. Borek. An inference is drawn and a finding is made that this check was written in furtherance of the addition. ACGC had been paid a total of $24,055.00 of the Contract cost of $32,925.00, which was approximately 73 percent of the Contract cost. The balance of the Contract cost was $8,870.00. Mr. Borek testified that, at the time of the writing of the check for $4,000.00, he and Ms. T. Meredith agreed that he would have until on or about November 15, 2003 to complete the project. Ms. T. Meredith testified that no such agreement was made. At the time of the check for $4,000, ACGC was almost 60 days beyond the completion date represented to the Department's investigator. No testimony was presented as to why the $4,000.00 was paid to ACGC in light of such a considerable delay in completing the job by ACGC and in light of the complaint being filed with the Department. Due to the lack of an explanation for the payment of the $4,000.00 to ACGC in furtherance of the project, Mr. Borek's testimony presents a reasonable explanation. Therefore, Mr. Borek's testimony is found to be credible. Hence, a finding is made that, on or about September 10, 2003, Mr. Borek and Ms. T. Meredith orally agreed that ACGC would have until on or about November 15, 2003, to complete the addition. Ms. T. Meredith continued to be dissatisfied with the progress on the addition by ACGC. Sometime after September 10, 2003, an incident occurred which caused her to reach the conclusion that she could not allow ACGC to continue working on the project. One day when she left for work, one of ACGC's workers was painting the exterior walls. When she returned from work later that same day, the same worker for ACGC was painting the exterior walls. Ms. T. Meredith immediately directed the worker to leave and to take all of his equipment with him; the worker did so. Ms. T. Meredith contacted Mr. Borek and informed him that she would not allow him to continue with the project. Mr. Borek repeatedly requested Ms. T. Meredith to allow him to continue with the project, but she refused. By letter dated October 9, 2003, Ms. T. Meredith terminated the Contract with ACGC. She mailed the letter on the same date and faxed it on October 14, 2003. Her mother was in agreement with terminating the Contract. Ms. T. Meredith indicated, among other things, in her letter to ACGC that its failure to complete the addition as of the date of the letter, when the oral agreement was completion within six to eight weeks, left her no choice but to terminate the Contract. Ms. T. Meredith included in the letter, among other things, what remained to be completed on the project and a cost of $539.55 for damaged items at her home caused by ACGC, with an itemized list. At the time of the termination, the following work remained to be completed: purchase and installation of plumbing fixtures; sewer hookup; molding; tile work in the bathroom; installation of storm panels and flooring; some painting; installation of an air conditioner; some electrical connections; and installation of an electrical panel, electric wall plates, and an electric light fixture. Ms. T. Meredith obtained a homeowner's permit and hired someone, Adam Friedman, to assist her in completing the addition. On December 15, 2003, the CPP issued a certificate of occupancy to her. As to expenditures by Mses. T. and J. Meredith in order to complete the addition, the undersigned finds the testimony of Mr. Yanoviak credible. Mses. T. and J. Meredith expended $19,170.52 to complete the addition. The expenditures for completion were reasonable and necessary. Not included in the expenditures for completion are the following: $3,941.31 for items not included in the Contract--a fence, pavers, wood floor, upgraded bathroom fixtures or accessories, closet woodwork and various Home Depot items (totaling $238.21); $250.00 for mill work associated with chair rails; and $2,400.00 for an exterior concrete slab. Included in the expenditures for completion is the following: $1,360.00 for a split-system air conditioning unit which was not installed by ACGC. Further, included in the cost of expenditures is an adjustment in favor of Ms. T. Meredith in the amount of $1,000.00 for the elimination of a window on the west elevation of the addition, which was orally agreed to by Ms. T. Meredith and Mr. Borek after the signing of the Contract and which would have been subtracted from the cost of the Contract. After Ms. T. Meredith terminated the Contract, she filed a claim under the Construction Industries Recovery Fund. The claim was dated October 10, 2003, one day after she terminated the Contract. Ms. T. Meredith set forth in the claim that she was requesting $12,000.00, which she indicated was the amount to pay another contractor to complete the project. The undersigned places very little weight upon the amount requested because the claim is prior to completing the project and fails to reflect the actual costs involved in completing the project, which were realized only after completion. Damage to items at Ms. T. Meredith's home occurred, during the work being performed by ACGC, for which ACGC was responsible. The following items were affected: damaged a window magnet that was part of the home's security system at $80.00; destroyed, broken, or thrown away one large planter pot, one archway, and two large stepping stones--all at an estimate of $440.34; and broken tiles in the front of the house at $13.57. The damages totaled $533.91. At the time of the hearing, Mr. Borek had not made any payments to Ms. T. Meredith or Ms. J. Meredith for their expenditures to complete the addition or for the damages. At the time of the termination, in accordance with the oral agreement of completion by on or about November 15, 2003, ACGC had a little over 30 days to complete the addition. In light of the finding that an oral agreement had been reached to allow ACGC until on or about November 15, 2003, to complete the addition and in light of the only incident since that agreement, presented by the evidence, was the situation involving ACGC's painter, the undersigned finds that the painting situation was not substantial and that, therefore, the termination on October 9, 2003, prior to the new agreed- upon termination date, was unreasonable. Ms. T. Meredith testified that, sometime during the middle of the year 2003, for a period of "exactly" 60 days, ACGC failed to perform any work at the project. Mr. Borek denies her assertion. Ms. T. Meredith testified that she kept records on everything. When she testified as to an exact 60- day period in the middle of 2003 during which no work was being done at the project, Ms. T. Meredith did not point to any of her records to verify the assertion or provide certain beginning and ending dates. Taking into consideration the standard of proof and the burden of proof, the evidence failed to show clearly and convincingly that no work was done at the jobsite by ACGC for a period of 60 days in the middle of the year 2003. Nothing was done by Ms. T. Meredith, the architect, or CPP to delay the completion of the project. Mr. Borek admits that he had other jobs in progress when he was working on the addition. He further admits that when changes had to be made to the project, whether by the CPP or the architect or Ms. T. Meredith or himself, he had to re- arrange his schedule to accommodate the other jobs, which included re-deploying his workers and subcontractors, which in turn caused delays. Further, Mr. Borek admits that the turnaround time for any changes given to the architect for the plans to the addition was reasonable and that the turnaround time for the CPP to review the changes to the plans submitted by the architect was reasonable. Consequently, no unreasonable or inordinate delays were caused by the architect or the CPP when changes were made to the plans of the addition. Mr. Borek performed some work for Ms. T. Meredith at no cost that was not required by the Contract. The extra work at no cost included the following: the removal of trees; pouring of an exterior concrete slab; and plastering of drywall. The slow progress in completing the Contract was significant and material and resulted in the Contract’s not being performed in a reasonable time. The delays in completion of the addition were significant and were the fault of Mr. Borek. In addition to re-deploying workers for other jobs on which ACGC was working, ACGC failed to properly perform work, which resulted in failed inspections by the CPP, which resulted in numerous delays, and failed to timely obtain an electrical permit. As to the failure to timely obtain an electrical permit, the electrical permit was obtained almost five months subsequent to the issuance of the building permit by the CPP. The electrical permit was applied for on March 20, 2003 and approved on March 24, 2003. CPP's turnaround time in approving the permit was short and inconsequential. As to the failure to properly perform work, the Records indicate construction defects, which were under Mr. Borek's, the contractor's, control and which resulted in failed inspections. Furthermore, the Records indicate prior construction faults, identified in inspections, not being timely corrected, which was under Mr. Borek's control and which resulted in delays until the faults were corrected. Mr. Yanoviak testified that failure to perform the Contract within a reasonable time constituted misconduct. The undersigned finds his testimony credible. A finding of fact is made that the failure to perform the Contract within a reasonable time constituted misconduct. Additionally, Mr. Yanoviak testified that the failure to perform the Contract within a reasonable time constituted a material breach of the Contract. The undersigned finds his testimony credible, and a finding of fact is made that the failure to perform the Contract within a reasonable time constituted a material breach of the Contract. Further, Mr. Yanoviak testified that, such material breach, justified terminating the Contract. The undersigned finds his testimony credible only as to a general application and, therefore, a finding of fact is made that, generally, the failure to perform a construction contract within a reasonable time would justify terminating the construction contract but does not justify terminating the Contract under the circumstances presented in the instant case. Both Mr. Borek and Ms. T. Meredith orally agreed to a new date for completion of the addition, i.e., on or about November 15, 2003. To disregard the new date of completion would be manifestly unjust. Furthermore, at the time of the termination of the Contract by Ms. T. Meredith, i.e., on October 9, 2003, the termination was unreasonable and not for just cause. Hence, a finding of fact is made that termination of the Contract by Ms. T. Meredith, prior to the new completion date, was not justified. Mr. Yanoviak also testified that failure to perform the Contract within a reasonable time constituted abandonment of the project. The undersigned finds his testimony credible only as to general application and, therefore, a finding of fact is made that, generally, the failure to perform a construction contract within a reasonable time would constitute abandonment of a project. However, as found above, a new date for completion of the project was orally agreed upon and the new date had not expired at the time of the termination of the Contract by Ms. T. Meredith. Hence, a finding of fact is made that, under the circumstances of the instant case, abandonment did not exist. The Department presented evidence of costs for the investigation and prosecution of this matter, excluding costs associated with attorney time. As of July 5, 2005, the costs for the investigation and prosecution totaled $880.18. As to prior disciplinary action, on September 9, 2004, the Department filed a Final Order in Department of Business and Professional Regulation vs. Bret Jayson Borek, Case No. 2003-069533, License No. CG Co58817 before the Construction Industry Licensing Board. In that case, an administrative complaint was filed against Mr. Borek for violating Section 489.129(1)(i), Florida Statutes (2001), by failing to comply in a material respect with a provision of Chapter 489, Florida Statutes, through the failure to obtain a certificate of authority for ACGC; and for violating Section 489.129(1)(q), Florida Statutes (2001), by failing to satisfy a civil judgment, related to the practice of construction, within a reasonable time. Mr. Borek waived his rights to an informal hearing, and no material fact was disputed. Among other things, the Final Order imposed an administrative fine of $1,000.00, required restitution of $15,218.94 to a roofing and sheet metal company and required payment of $506.92 for investigative costs.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order: Finding that Bret Jayson Borek committed the violations set forth in Counts I, II, and III; Dismissing Count IV; and Imposing the following penalties: As to Count I, an administrative fine in the amount of $1,000.00 and revocation of the license of Bret Jayson Borek. As to Count II, an administrative fine in the amount of $500.00. As to Count III, an administrative fine in the amount of $5,000.00 and revocation of the license of Bret Jayson Borek. S DONE AND ENTERED this 9th day of January, 2006, in Tallahassee, Leon County, Florida. _______________________________ ERROL H. POWELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 9th day of January, 2006.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following facts were found: At all times material to these proceedings, the Respondent, Victor S. Davis, held a registered general contractor's license, numbered RG 0013635 issued by the State of Florida, Department of Professional Regulation, Construction Industry Licensing Board in April, 1973. At all times material to these proceedings, Respondent's general contractor's license, number RG 0013635, was in a delinquent status and had been in a delinquent status since July 1, 1977. Respondent failed to renew his license after June 30, 1975 but in May, 1976 made application to reinstate license number RG 0013635 which was approved and reinstated on an active status by Petitioner in May, 1976 and issued to Respondent, Victor S. Davis, qualifying Conch Construction Corp., of Key West, Florida. There was no evidence that the reinstated license was issued for Monroe County, Florida or that Respondent ever held a certificate of competency for Monroe County, Florida. At all times material to these proceedings, Respondent was an officer (Secretary) of Classic Marketing and Development, Inc. (Classic). On July 28, 1983, the Respondent, as Secretary of Classic, entered into a contract with William Dees to construct a shell home on the Dees' property located at Lot 14, Block 7, Breezeswept Estates, Ramrod Key, Florida for a contract price of $27,000.00. On September 13, 1983, William Dees applied for and obtained building permit No. 10902-A as owner/builder for the construction of the Dees's home. Construction of the Dees home began on or about September 13, 1983. Gregory H. O'Berry, President of Classic had knowledge of, and approved of, Respondent entering into contracts for construction of homes in Monroe County, Florida, including the contract with Dees. O'Berry was aware that Respondent did not hold a certificate of competency in Monroe County, Florida and that Respondent's registered general contractor's license did not cover contracting in Monroe County, Florida. O'Berry understood that Phillip A. Braeunig, a properly licensed general contractor in Monroe County, Florida, was acting as the general contractor for Classic- in the construction of homes by Classic, including the construction of the Dees home. Braeunig did not act as general contractor on the construction of the Dees' home. Respondent supervised the contraction of the Dees' home, until Respondent abandoned the construction of the Dees' home, and in performing these supervisory duties fulfilled the responsibilities of a general contractor. No other officer or authorized agent of Classic had any responsibility for the supervision of, or acted in any manner as a general contractor, in the construction of the Dees' home. Braeunig prepared and submitted to Respondent an application to qualify Classic with Petitioner using Braeunig's license but this application was never filed with Petitioner during- anytime material to these proceedings. Classic was never qualified by anyone, including Respondent or Braeunig, at any time material to these proceedings. Braeunig~acted as general contractor for Classic on the Conti home, which was in the beginning stages of Classic and prior to the Dees' job. Braeunig was brought into Classic for the purpose of acting as general contractor because of the Respondent's invalid license.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the Board enter a final order Dismissing Count I of the Amended Administrative Complaint filed against the Respondent. It is further RECOMMENDED that the Board enter a final order finding Respondent guilty of the violation charged in Count II of the Amended Administrative Complaint and for such violation it is RECOMMENDED that the Board suspend the Respondent's registered general contractor's license for a period of two (2) years and assess the Respondent with an administrative fine of $500.00, stay the suspension and place Respondent on probation for a period of two (2) years, provided the Respondent pays the $500.00 fine within ninety (90) days. Respondent's failure to pay the $500.00 fine within the time specified will result in his registered general contractor's license being suspended for a period of two (2) years with the requirement that when the fine is paid and the suspension lifted, the Respondent must appear before the Board for reinstatement of his license. Respectfully submitted and entered this 3rd of December, 1985, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 3rd day of December, 1985. APPENDIX Department of Professional Regulation, Construction Industry Licensing Board v. Victor S. Davis, Division of Administrative Hearings Case No. 85-1963 Ruling on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact No. 1 except for the statement that "Respondent's license was issued for Okaloosa County only" which is rejected as not being based upon competent substantial evidence. Hearsay alone is not sufficient to support a finding of fact. Adopted in Finding of Fact No. 1 except for statement that "said license has been delinquent since July, 1981" which is rejected as being contrary to the evidence in Petitioner's Exhibit No. 1 which shows delinquent status as of July 1, 1977. Adopted in Finding of Fact No. 3. Rejected as a conclusion of law rather than a proposed finding of fact. Considered as background information and not as a finding of faet. Adopted in Finding of Fact No. 4. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact Nos. 4 and 5. Adopted in Finding of Fact Nos. 5 and 7. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of feet No. 10 Adopted in Finding of Fact No. 10 Rejected as a conclusion of law rather than a proposed finding of fact. Respondent did not submit Proposed Findings of Fact. COPIES FURNISHED: James Linnan, Executive Director Department of Professional Regulation Construction Industry Licensing Board P. O. Box 2 Jacksonville, FL 32202 Nancy M. Snurkowski, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Victor S. Davis 2169 North Hercules Avenue Clearwater, FL 33575 and 6290 Sandcrest Circle Orlando, FL 32819
Findings Of Fact The Respondent, Marlene E. Lutman, is a vice president of American Custom Builders, Inc. and was a vice president in 1977. Respondent holds licenses Number CR C012570 end Number CR CA12570 issued by the Petitioner Board. On September 11, 1978, Respondent submitted a certification change of status application to the Florida Construction Industry Licensing Board. This application, completed by Respondent under oath on September 7, 1978, was filed for the purpose of changing the contractor's licenses held by Respondent to add the name of American Custom Builders, Inc. to said licenses. On July 6, 1979, an Administrative Complaint was filed against Respondent, doing business as American Custom Builders, Inc., seeking to permanently revoke her licenses and her right to practice under said licenses and to impose an administrative fine in the amount of $500.00. Respondent Lutman requested an administrative hearing, which was scheduled for September 6, 1979, continued on Motion of Respondent, and held November 29, 1979. On the application completed by Respondent, Question 12(b) asked: Are there now any unpaid past-due bills or claims for labor, materials, or services, as a result of the construction operations of any person named in (i) below or any organization in which such person was a member of the personnel? Question 12(c) of the application asked: Are there now any liens, suits, or judgments of record or pending as a result of the construction operations of any person named in "(i) below" or any organization in which any such person was a member of the personnel? Respondent, as a vice president of American Custom Builders, Inc., was designated in "(i) below." She answered "no" on the application to both of the above stated questions. Respondent completed the application while she was in Florida. Prior to completing the application, Respondent spoke by telephone with John D. Cannell, an attorney in Ohio, in reference to Questions 12(b) and 12(c), supra. Cannell told Respondent that there were no unpaid bills outstanding. He said that there had been liens filed involving American Custom Builders, Inc., but that these liens had been cancelled. Cannell based his statements to Respondent upon oral assurances from personnel at the bank involved in financing the construction project associated with the liens that all liens had been paid. It was later learned that on September 7, 1978, the date Cannell told Respondent the liens had been cancelled, the liens had not been cancelled and were of record in the Recorder's Office of Geauga County, Ohio. Liens had been filed on January 6, 1978, January 23, 1978, and January 3l, 1978, by various subcontractors involved in the construction of a house owned by Winford and Sally Ferrentina. The liens were based on claims against American Custom Builders, Inc. as general contractor and the Ferrentinas as owners for unpaid labor and materials and were not satisfied of record until September 20, 1978, on which date the January 6, 1978 lien was satisfied, and March 22, 1979, on which date the other two (2) liens were satisfied. The Hearing Officer finds that Respondent Lutman did not intend to make a material false statement but negligently relied on oral representations that there were no past-due bills and no liens of record pending as a result of her construction operations. Both parties submitted proposed findings of fact, memoranda of law and proposed recommended orders, and the Petitioner Board submitted a reply memorandum. These instruments were considered in the writing of this order. To the extent the proposed findings of fact have not been adopted in, or are inconsistent with, factual findings in this order they have been specifically rejected as being irrelevant or not having been supported by the evidence.
Recommendation Based upon the foregoing Findings and Conclusions of Law, the Hearing Officer recommends that the Respondent, Marlene Lutman, be reprimanded. DONE and ORDERED this 1st day of February, 1980, in Tallahassee, Leon County, Florida. COPIES FURNISHED: Jeffery B. Morris, Esquire 2400 Independent Square One Independent Drive Jacksonville, Florida 32202 Jeffrey R. Garvin, Esquire 2532 East First Street Post Office Box 2040 Fort Myers, Florida 33902 DELPHENE C. STRICKLAND Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. DOAH CASE NO. 79-1546 Marlene Lutman, CR C012570, CR CA 12570 Respondent, /
The Issue The issues are whether Respondent committed the several violations of Sections 489.129(1)(h)2.,(h)3.,(j),(k), and (n), Florida Statutes (1997), for the reasons stated in the respective Administrative Complaints and, if so, what, if any, penalties should be imposed. (All chapter and section references are to Florida Statutes (1997) unless otherwise stated.)
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a certified general contractor pursuant to license number CG C059414. At all relevant times, Respondent was the qualifying agent for Fred T. Garrett Construction, Inc. ("FTG"). As the qualifying agent, Respondent was responsible for all of FTG's contracting activities in accordance with Section 489.1195, Florida Statutes. Respondent failed to obtain a certificate of authority for Fred T. Garrett Construction, Inc., as required by Section 489.119(2), Florida Statutes. The St. Cyr Case On or about August 21, 1998, Respondent entered into a contract with Louis L. St. Cyr to construct an addition to the residence located at 201 South Bel Air Drive, Plantation, Florida. The contract price was $50,000. Although Mr. St. Cyr paid $2,500 to Respondent, Respondent failed to commence work and canceled the project, thereby abandoning it without just cause and without proper notification to Mr. St. Cyr. The contract did not permit Respondent to keep the $2,500 paid by Mr. St. Cyr, and Respondent failed to refund the payment within 30 days after abandonment. Out of the $2,500 he received from Mr. St. Cyr, however, Respondent paid $1,600.00 to the architect before abandoning the project. Thus, the net amount that Respondent owes to Mr. St. Cyr is $900. Petitioner incurred a total of $1,092.28 in investigative costs relating to the St. Cyr case. The Forney Case On May 22, 1998, Respondent, who was doing business as FTG, entered into a contract with Mr. Warren Forney for the construction of a two-bedroom, one-bath addition to the residence located at 1698 Northeast 33rd Street, Oakland Park, Florida. The contract price was $32,500. The contract with Mr. Forney did not contain a written statement explaining the customer’s rights under the Construction Industries Recovery Fund, as required by Section 489.1425(1), Florida Statutes. On July 7, 1998, Respondent obtained permit number 98-050297 from the Oakland Park Building Department. Construction commenced on or about July 7, 1998, and continued sporadically until October 29, 1998, when Mr. Forney dismissed Respondent for failure to timely complete the project. The Oakland Park Building Department issued notices of violation against the project on August 3, September 11, and October 14, 1998, for various building code violations. Mr. Forney was forced to obtain a homeowner’s permit and subsequently hired a subcontractor to complete the work. Mr. Forney paid Respondent approximately $29,250 before relieving Respondent of his duties. To complete the project, Mr. Forney paid a total of $48,746.52, which was $15,396.52 over and above the original contract price. Petitioner incurred a total of $2,190.78 in investigative costs relating to the Forney case. The Kong Case In or around January 1998, a contractor named Lakeview Concepts hired Respondent to perform demolition work for the Kong dry cleaning store project on the property located at 5171 South University Drive, Davie, Florida. On or about June 17, 1998, permit 98-00002349 was issued to Respondent to perform alterations on commercial property located at 5171 South University Drive, Davie, Florida. Respondent, however, did not yet have a contract with the owner for this work. The next month, on or about July 30, 1998, Respondent, who was doing business as FTG, entered into a contract with Shek Kong to complete the dry cleaning store project at 5171 South University Drive, Davie, Florida, for the contract price of $22,300. Shek Kong made payments to Respondent totaling $16,000. Respondent’s work was of poor quality, however, and on or about November 6, 1998, he ceased work, though the project had not been completed. On or about November 14, 1998, Douglas Frankow, license number CB C052960, gave Mr. Kong an estimate of $20,562 to complete the project. Thereafter, on or about June 30, 1999, Mr. Kong contracted with George Settergren, another licensed contractor, to complete the project for a contract price of $27,956. On December 9, 1999, in Case No. 98-020065 08, the Circuit Court, Seventeenth Judicial Circuit, Broward County, Florida, rendered a Final Judgment against Respondent and in favor of Mr. Kong. This judgment awarded Mr. Kong the total amount of $28,693.30, plus 10 percent interest per annum. Petitioner incurred a total of $2,502.78 in investigative costs relating to the Kong case.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Florida Construction Industry Licensing Board enter a Final Order finding Respondent guilty of violating Sections 489.129(1)(h)2., (h)3., (j), (k), and (n), Florida Statutes, imposing administrative fines in the aggregate amount of $3,700, assessing investigative costs in the aggregate amount of $5,785.84, placing Respondent's license on probation for a period of four years from the date the Final Order is entered by the Board, and awarding payment of restitution to each customer as follows: (1) to Warren Forney, the amount of $15,396.52; (2) to Shek Kong, satisfaction of the unpaid civil judgment in the amount $28,693.30, plus 10 percent interest accrued thereon; and (3) to Louis L. St. Cyr, the amount of $900. DONE AND ENTERED this 15th day of February, 2002, in Tallahassee, Leon County, Florida. _________________________________ JOHN G. VAN LANINGHAM Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 15th day of February, 2002.
Findings Of Fact Respondent Henry Huggins is presently licensed by the Construction Industry Licensing Board as a certified general contractor under license number CO C003466. He first received his license in November of 1972 and has since been continuously licensed. His license was however suspended for a period of one year beginning on May 16, 1980. That suspension was by an Order of the Florida Construction Industry Licensing Board. In October of 1981 Mr. Huggins renewed his license on inactive status but changed it to active status in December 1981. His license continued to be active and he is the qualifying agent for Florida Petroleum Services, Inc., in Winter Park Florida. In the fall of 1980 Mr. Albert Dupre agreed to do some home renovation work for Dr. Charles Gill at Dr. Gill's residence located at 2193 Turkey Run, Winter Park, Florida. Mr. Dupre completed the work and shortly thereafter in the spring of 1981 he and Dr. Gill entered into another oral contract whereby Mr. Dupre would construct an upstairs addition to Dr. Gill's home. The addition included the installation of a bathroom and another bedroom. In exchange for these services Dr. Gill "traded off" dental work for Mr. Dupre's wife and agreed to pay an additional $12,000 or $13,000. At Mr. Dupre's request the construction permit for the upstairs addition was obtained by the Respondent Henry L. Huggins. At all times material Albert Dupre has held no contracting licenses authorizing him to individually perform the work called for by his agreement with Dr. Gill. During the time in question, that is April 1981, Respondent did not himself have an active contractor's license due to his suspension by the Construction Industry Licensing Board. He was authorized by the qualifying agent for Roberts Insurance Contractors to obtain building permits under the qualifying agent's license in order to undertake building projects for Roberts. Roberts Insurance Contractors was not a party to the agreement between Dr. Gill and Mr. Dupre for the up stairs addition to Dr. Gill's home. On April 7, 1981 Respondent obtained building permit number 7487 from the City of Winter Park, Florida, which authorized the construction of a bedroom and bathroom addition on the property of Dr. Charles Gill in Winter Park, Florida. Respondent obtained that permit on behalf of Mr. Dupre because of their friendship and their previous business associations dating back to the mid- 1970's Respondent did not supervise or otherwise participate in the construction of Dr. Gill's addition until the work was complete and Dr. Gill made a complaint to several regulatory bodies about Mr. Dupre's work. This complaint centered around the earlier air conditioning project; but once notified that there were difficulties concerning the project, Respondent, along with Mr. Dupre, completed all unfinished items and corrected all defects. As a result of Respondent's willingness to remedy those defects Dr. Gill has requested that all charges against Mr. Huggins here be dropped.
Recommendation Based on the foregoing Findings of Fact and Conclusions Law, it is RECOMMENDED: That the Construction Industry Licensing Board enter a Final Order suspending the license of Henry L. Huggins as a certified general contractor for a period of two (2) years from the date of the Board's Final Order. DONE and RECOMMENDED this 17th day of February, 1984, in Tallahassee, Florida. MICHAEL PEARCE DODSON Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9673 Filed with the Clerk of the Division of Administrative Hearings this 17th day of February, 1984.
