Findings Of Fact Based upon Section 120.65(11), Florida Statutes, and Ms. Curry's failure to dispute the allegations of paragraph 4 of the Administrative Complaint (quoted above), that count will be treated as admitted.
Recommendation It is recommended that a final order be entered by the Education Practices Commission revoking the teaching certificate of Sherry Curry. RECOMMENDED this 3rd day of April, 1990, at Tallahassee, Florida. WILLIAM R. DORSEY, JR., Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of April, 1990. COPIES FURNISHED: Karen B. Wilde, Executive Director Education Practices Commission 301 Florida Education Center 325 West Gaines Street Tallahassee, Florida 32399-0400 Martin Schaap, Administrator Education Practices Commission 352 Florida Education Center 325 West Gaines Street Tallahassee, Florida 32399-0400 Lane Burnett, Esquire 331 Union Street Jacksonville, Florida 32202 Sherry Curry 4260 Northwest 170 Street Carol City, Florida 33055 Sydney H. McKenzie, General Counsel Department of Education The Capitol, PL-08 Tallahassee, Florida 32399-0400
Findings Of Fact On November 22, 1989, T. L. James & Company, Inc. was convicted of conspiracy to suppress and eliminate competition. This is a public entity crime. T. L. James executed a Public Entity Crimes Affidavit on July 24, 1994. On the affidavit T. L. James disclosed the conviction. Pursuant to Section 287.133, Florida Statutes, the Department of management Services (DMS) shall investigate public entity crimes to determine if the convicted company should be placed on the convicted vendors' list. After receiving the affidavit from T. L. James, DMS conducted an investigation and discovered mitigating factors as defined and listed in Section 287.133, Florida Statutes. These factors are: payment of fines and damages totalling $600,000, cooperation with the officials criminally investigating and prosecuting the case, cooperation with DMS' investigation, instituting safeguards in the bid estimation process to prevent further irregularities, and providing full and accurate notice. All other facts stipulated to by the parties pursuant to the Joint Stipulation previously filed in this case are hereby adopted and incorporated by reference.
Findings Of Fact On October 14, 1988, shortly before 9:00 a.m., Sheriff Deputy William Emral of the Monroe County Sheriff's Office was notified by radio that the Sheriff's Office dispatcher had received an anonymous telephone call advising that two white males were loading what appeared to be narcotics into a white four-door Cadillac, with Florida license plate number 367-ZGX. The caller indicated that the Cadillac was headed northbound on the highway from Lower Matecumbe Key. Deputy Emral then took up a stationary position at mile marker 84 and began watching the northbound traffic. At about 9:05 a.m., he observed the Cadillac described by the anonymous caller. Deputy Emral began to follow the subject Cadillac northbound. He followed the Cadillac for approximately one mile and then activated his emergency lights and pulled the Cadillac over. From the time Deputy Emral first saw the subject Cadillac until the time he pulled the Cadillac over, he did not observe anything about the car or the driver that would have caused him to stop the Cadillac. Had it not been for the information provided by the anonymous caller, Deputy Emral would not have stopped the subject Cadillac. The Respondent, Mark Alfred Herre, was driving the Cadillac at the time Deputy Emral pulled it over. Mr. Herre did not flee and obeyed the directions given to him by Deputy Emral. He produced his driver's license which showed his name as Mark Alfred Herre. The car was rented and, when requested, he produced the rental contract showing that it had been rented by another individual. Deputy Emral reported this information to his base and to his superior, Captain Wilkinson, who later arrived at the scene. Deputy Emral observed two bags, one green and one gray. These were soft sided bags and appeared to be stuffed between the rear and front seats of the rented car, on both the driver and passenger sides. They were relative large, approximately three feet by four feet in size. The rental contract produced by Mr. Herre indicated that the vehicle was rented by a Maryland resident named Robert E. Lee. Mr. Herre could produce no authorization from Mr. Lee that he was entitled to use the vehicle nor could he produce the name of someone who could confirm he was authorized to be driving the subject vehicle. At about this time, Captain Wilkinson arrived at the scene as backup. At this point, Mr. Herre was not suspected of a crime and continued to answer questions from the Deputy. He stated that the bags in the car contained diving gear. Deputy Emral is a certified diver and the story seemed suspicious and inconsistent with the Deputy's previous diving experiences. Mr. Herre did not ask any questions or make other inquiries as to why he was stopped. Deputy Emral did explain that an anonymous tip was received and discussed this information with the Petitioner. At this point, Deputy Emral and Captain Wilkinson conferred and because of the information received by the anonymous tip to the Sheriff's Office and the inability of the Petitioner to prove he had authorization to be driving the rented vehicle, they decided that the vehicle should be taken into custody. In preparation for taking a vehicle into custody, an inventory of the vehicle is made as a standard procedure. Mr. Herre was not placed under arrest at this time. Mr. Herre was asked for, but declined to give, permission for the Deputy to search the vehicle. The vehicle was then searched and it was determined that the two bags in the passenger compartment contained bales of marijuana. Captain Wilkinson then took charge of the vehicle and drove it to the Sheriff's Office. Captain Wilkinson stated that even if no contraband were in the vehicle, he would probably have driven it to the substation to await confirmation that Mr. Herre was actually authorized to be in possession of the rented car and the same was not actually stolen. At the Sheriff's Office, the Cadillac was thoroughly searched and the car and its contents were photographed. Three bales of marijuana were recovered from the back seat and ten bales of marijuana were recovered from the trunk. Samples tested positive for marijuana. For purposes of this case, the parties have stipulated that the marijuana found in the subject Cadillac weighed a total of 300 pounds. On November 17, 1988, the Department issued a Notice Of Assessment And Jeopardy Findings to the Petitioner, Mr. Herre. The assessment was based on an estimated retail price for marijuana of $700.00 per pound times the stipulated 300 pounds, which comes to a total estimated retail value of $210,000.00. The tax, surcharge, and penalty assessed against Mr. Herre were as follows: 50% Tax $105,000.00 25% Surcharge 52,500.00 Additional penalty of 50% 78,750.00 Total Amount of assessment $236,250.00 Daily interest on the amount due is $51.78. The Notice of Assessment And Jeopardy Findings described above was properly and correctly prepared and notice of it was properly given to the Petitioner, Mr. Herre. On December 28, 1988, Mr. Herre was sentenced in Case No. 33-88-00446- CF-A to a period of five (5) years probation and to pay $5,000.00 in costs. The sentence in the aforementioned case was as a result of criminal charges arising from Petitioner's arrest for the conduct alleged in the Notice Of Assessment And Jeopardy Findings dated November 17, 1988.
Recommendation For all of the foregoing reasons, it is recommended that the Department of Revenue issue a Final Order in this case concluding that the Petitioner, Mark Alfred Herre, is liable for taxes, surcharges, penalties, and interest pursuant to Section 212.0505, Florida Statutes (1988 Supp.), and assessing the amount of such liability at $236,250.00, plus interest at the rate of $51.78 per day since November 7, 1988. RECOMMENDED in Tallahassee, Leon County, Florida, this 18th day of March 1991. COPIES FURNISHED: Stephen J. Bronis, Esquire 1395 Coral Way Third Floor Miami, Florida 33145 MICHAEL M. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 18th day of March 1991. Mark T. Aliff, Esquire Assistant Attorney General Department of Legal Affairs The Capitol - Tax Section Tallahassee, Florida 32399-1050 J. Thomas Herndon Executive Director Department of Revenue 104 Carlton Building Tallahassee, Florida 32399-0100 Vicki Weber General Counsel Department of Revenue 204 Carlton Building Tallahassee, Florida 32399-0100
The Issue The issues in this case are: a) whether White Construction Company, Inc. timely filed its requests for hearing with the Department of Transportation in response to notices of intent to suspend White's certificate of qualification because of alleged delinquencies on State Project Nos. 97770-3305 and 97770-3306 and; (b) if not, whether the doctrine of equitable tolling, waiver, estoppel or other legal or equitable principles apply under the facts of this case such that White is entitled to a formal hearing on the merits of the department's determination of delinquency.
Findings Of Fact White Construction Company, Inc. (White) is a contractor prequalified to bid on Department of Transportation (Department) construction projects in excess of $250,000. It was incorporated in 1951 and maintains a home office in Chiefland, Florida. White was the successful bidder on three projects that are included within the Department's Seminole Expressway Project in Seminole County which is being funded and supervised by the Department's Turnpike Office. The projects are three contiguous segments and are identified as State Project Nos. 97770-3304, 97770-3305 and 97770-3306. The Seminole Expressway Project consists of twelve separate projects. HNTB Corporation is the Department's Resident Engineer for Project Nos. 97770-3304 and 97770-3306 and maintains an office at 2927 US 17-92 in Sanford. ICF Kaiser Engineers is the Resident Engineer for Project No. 97770-3305 and maintains an office in a trailer at the job site. The Resident Engineers are the main liaison between White and the Department on the Project. The Department's Turnpike Office maintains a local office at 112 Beider Avenue in Casselberry. The Resident Engineers are supervised from that location by Mr. Gary Geddes, the Department's Program Manager, in conjunction with Mr. Ray Daniel, an Area Engineer who is employed by Post, Buckley, Schuh and Jernigan, which is under contract with the Department. The Resident Engineers, though employed by private consultants, serve as the Department's representatives and are delegated the title of Engineer of the Project for the Department. On July 30, 1993, the Department issued notices of intent to suspend White's certificate of qualification because of alleged delinquencies in White's performance on State Project Nos. 97770-3305 and 97770-3306. The Department's notices of intent to suspend were received by White at its Chiefland offices on August 3, 1993. Each notice contained the following language: Pursuant to Florida Administrative Code Rule 14-23 and in accordance with this determination, we intend to suspend your Certificate of Qualification and those of your affiliates. This suspension will become conclusive final agency action unless you request an Administrative Hearing within ten (10) days of receipt of this notice. Your request for a hearing shall be in writing and shall be filed with the Clerk of Agency Proceedings, Mail Station 58, Haydon Burns Building, 605 Suwanee Street, Tallahassee, Florida 32399-0450 within ten days of receipt of this notice. A copy of the request for hearing shall also be provided to the State Construction Engineer, Mail Station 31, Haydon Burns Building, 605 Suwanee Street, Tallahassee, Florida 32399-0450. The request for hearing shall include: The name and address of the party making the request; A statement that the party is requesting a formal or informal proceeding; and All specific facts and circumstances which the Contractor believes legally excuses the unsatisfactory progress on the project. A request for hearing is filed when it is delivered to and received by the Clerk of Agency Proceedings. If a hearing is timely requested after the receipt of the notice of the intent, the hearing shall be held within 30 days after receipt by the Hearing Officer of the request for hearing in accordance with 337.16 of the Florida Statutes. In addition to a request for an Administrative Hearing and in accordance with Article 8-8.2 of the Special Provisions of this project, you are hereby given opportunity to request an extension of allowable contract time in an amount of cause progress on this contract to be acceptable or to submit other information to show that progress of work is not delinquent. (Petitioner's Exhibit #7, emphasis added) White forwarded the two Notices of Intent to its attorneys, Cummings, Lawrence and Vezina, P.A. On August 11, White's attorneys sent to Mr. Burney Keen of White Construction, via Federal Express Priority Morning Delivery, a package containing originals and copies of requests for formal hearing and for contract time extensions for both projects, with written instructions to have the requests executed and delivered to the Clerk of Agency Proceedings and James Lairscey, via Federal Express, and to hand deliver copies to the Project Engineers no later than August 13. The package from White's attorneys did not arrive at White's offices until late in the afternoon on August 12, when Mr. Keen was no longer in the office. Mr. Keen did not receive the package from White's counsel until the morning of August 13. Notwithstanding the Priority Delivery designation, Federal Express delivery to White's Chiefland office occurred between 3:00 p.m. and 5:00 p.m. Mr. Keen instructed his secretary, Patti Cook, to have the documents executed by an officer of White, and to have them hand-delivered to the Department's Resident Engineers and delivered to the Department's Tallahassee offices by Federal Express, in accordance with counsel's instructions. On Friday afternoon, August 13, 1993, White hand-delivered its request for hearing, along with its requests for contract time extension, to the Department's two Resident Engineers. On that same day, White sent out a package containing copies of these documents by Federal Express addressed to Mr. J. Lairscey, 605 Suwanee Street, MS 58, Tallahassee, Florida 32399. Mr. Keen and Ms. Cook both believed that J. Lairscey was the Clerk of Agency Proceedings. This is not surprising since at his deposition, J. Lairscey, who is the State Construction Engineer for the Department, did not know who the Clerk of Agency Proceedings was either. Standard operating procedure for the Project established by the Department at the preconstruction conference required that all correspondence from White be sent to the Department's Resident Engineers. Mr. Keen believed it to be of utmost importance to timely hand-deliver the requests for formal hearing to the Department's Resident Engineers. Although White had filed notices or requests with the Department Clerk in the past, this was Mr. Keen's first experience with the delinquency filing procedures. The package arrived at the Department's offices in Tallahassee on Saturday, August 14, 1993, and was delivered to Mr. Lairscey's office, MS 31, and not MS 58 (which is the Clerk of Agency Proceedings' Mail Station and office) on the morning of August 16, 1994. The package delivered to ICF Kaiser contained an original letter from White addressed to Michael Landry, which requested an extension of time on Project No. 97770-3305 and referred to an enclosed request for hearing. The package also contained an original letter addressed to: Clerk of Agency Proceedings, 605 Suwanee Street, MS 58, Tallahassee, Florida 32399. The letter to the Clerk requested a formal hearing in response to the Department's July 30th Notice of Intent and referred to three large appendices which were enclosed. Upon its receipt on August 13, 1993, a secretary and the office engineer at ICF Kaiser's office recognized that they received misdirected originals of important legal documents. The office engineer and secretary telephoned Ray Daniel, the Department's Area Engineer, at the Department's office in Casselberry and told him that they had received from White what looked like an original legal document, which they did not think they were supposed to have. They questioned whether the documents should be redirected to the Department. Mr. Daniel instructed them not to send the documents to him. Mr. Daniel knew that requests for hearing should be sent to the Clerk of Agency Proceedings in Tallahassee, but was not sure that a mistake was made and took no action regarding the request for hearing. The documents were filed away at ICF Kaiser until August 27, 1993, when Michael Landry followed up an inquiry from Ray Daniel and had the originals forwarded to the Turnpike's Casselberry office. The package delivered to HNTB Corporation also on August 13 contained an original letter from White addressed to Ralph Burrington which requested an extension of time on Project No. 97770-3306 and referred to an enclosed request for hearing. Like its counterpart, this package also contained an original letter addressed to: Clerk of Agency Proceedings, 605 Suwanee Street, MS 58, Tallahassee, Florida 32399. The letter to the Clerk requested a formal hearing in response to the Department's July 30th Notice of Intent and referred to three large appendices which were enclosed. The Resident Engineer at HNTB, Mr. Ralph Burrington, did not note that the documents were originals and filed them away. Mr. Burrington's normal procedure is to forward such documentation by facsimile to the Department's Casselberry office, but in this instance he feels he made a mistake. The package delivered to the Department's Tallahassee offices on Saturday, August 14, 1993, contained one signed photocopy of the requests for formal hearing for Project No. 97770-3305 addressed to the Clerk of Agency Proceedings, unsigned copies of the requests for formal hearing in Project Nos. 97770-3305 and 97770-3306 addressed to the Clerk of Agency Proceedings, as well as copies of the request for time extension for Project Nos. 97770-3305 and 97770-3306 and appendices. The documents were received by J. Lairscey on Monday, August 16, 1993, and were filed away until they were inspected on August 27, 1993, as a result of an inquiry by Ava Parker, a Department attorney. Sometime before August 27, 1993, Ava Parker, as a result of an inquiry from Gary Geddes, the Department's Program Manager, began to investigate whether White had filed its requests for hearing. Ms. Parker first checked with the Clerk of Agency Proceedings and was informed that nothing had been filed at that location. Ms. Parker then contacted Charles Peterson, the Department's Area Construction Engineer, to discern whether White had filed a request for hearing. Mr. Peterson searched his files and the Department's central files; he questioned various people in the Department's Tallahassee office and telephoned Ray Daniel in the Department's Casselberry office. Ray Daniel told Mr. Peterson that he had no knowledge concerning White's requests for hearing and no idea where they were. Mr. Daniel in fact knew at that time that White had delivered its requests for hearings to both Resident Engineers on August 13, based upon previous conversations with the Department's Resident Engineers and office staff. Mr. Peterson later discovered from Jimmy Lairscey that Mr. Lairscey had received the requests for hearing but they had been filed away. On Friday, August 27, 1993, Joe Lawrence, counsel for White, telephoned Ava Parker to discuss consolidation of the hearings and discovery. Ms. Parker advised White's counsel that no requests for hearing had been filed with the Clerk in response to the two Notices of Intent. Ms. Parker knew prior to her conversation with counsel for White that the requests had not been filed with the Clerk of Agency Proceedings, yet made no attempt to contact White or its counsel to notify them that the Clerk had not received the request. On Monday, August 30, 1993, copies of the requests for hearing were delivered to the Department's Tallahassee offices from counsel for White, via Federal Express addressed to Ava Parker and Clerk of Agency Proceedings, Florida Department of Transportation, 605 Suwanee Street, MS 58, Haydon Burns Building, Tallahassee, FL 32399-0450. The documents were received by Ms. Parker who delivered the requests for hearing to the Clerk and they were stamped in by the Clerk of Agency Proceedings on that same date. The Clerk of Agency Proceedings' function is to docket and maintain a record of documents and to send a copy of any requests for hearing in contractor suspension cases to the legal section and to Jimmy Lairscey. The Department's standard procedure after receipt of requests for hearing and contract time extension is to have the documents reviewed by Jimmy Lairscey and the Project Resident Engineer to determine whether the time extension should be granted. The legal section then determines whether to send the matter to the Division of Administrative Hearings. The Department's purpose in soliciting a request for contract time extension in conjunction with its Notice of Intent to Suspend is to afford the contractor the opportunity to cure the delinquency. The Department, prior to taking action on the request for hearing, reviews the time extension request to determine whether it may obviate the need for further delinquency proceedings. The Department's Resident Engineers are primarily responsible for evaluating and making recommendations concerning time extension requests. It is generally after the Department makes a determination concerning the appropriateness of the request for contract time that it proceeds to act upon the request for hearing. The Department did not deny White's request for contract time extension until August 30, 1993, the same date that White's requests for hearing were docketed in by the Clerk. The Department's review, analysis and decision can take up to five months. The delay in docketing the requests for hearing did not, therefore, delay the process. There was no prejudice to the Department by White's delivery of its requests for hearing to the Department's Resident Engineers on August 13, 1993, rather than to the Clerk of Agency Proceedings. There was no harm to the Department by Jimmy Lairscey's receipt of White's requests for hearing on Monday August 16, 1993, rather than the Clerk receiving it on Friday, August 13, 1993. The Department was aware, prior to and on August 13, 1993, that White disputed the Department's determination of delinquency on State Project Nos. 97770-3305 and 97770-3306. The Department expected White to file requests for formal hearing challenging the Department's determination of delinquency on State Project No. 97770-3305 and 97770-3306. White had verbally notified the Department prior to August 13 that it was challenging the delinquency notices. No evidence established any prejudice or harm to the Department from the Clerk's receipt of White's requests for hearing on August 30, 1993 rather than August 13, 1993. White will be severely prejudiced if not afforded a hearing, and therefore automatically declared delinquent, because it will be precluded from bidding and acquiring much needed additional work. White's work is primarily for the Department, in all phases of highway construction. At the time of hearing White had Department contracts of approximately $100 million, which contracts carry over a several year period, and it employed approximately 500 people. No culpability or blame can be ascribed to either party in the series of gaffes surrounding the filing of White's requests for hearing. Mr. Keen, a novice to the process, thought he was doing the right thing by assuring timely filing with the Resident Engineers, who had always received other correspondence related to the Project. Mr. Daniel, who was immediately informed that the original documents were filed in the wrong place, did nothing to correct the error, but neither did he deliberately frustrate the process (as argued by White) since the message he received about some original legal documents was ambiguous. Mr. Lairscey had no idea that his packet was intended for the Agency Clerk; moreover, he had no idea who the agency clerk was. Under these circumstances, and in the absence of any more than mere inconvenience to the Department, it is patently unfair to deny White its hearing on the merits.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED that the Department enter its final order granting a formal hearing to White Construction Co., Inc. on the substantive issue of whether it should lose its qualification to bid. DONE AND ENTERED this 29th day of August, 1994, in Tallahassee, Leon County, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of August, 1994. APPENDIX The following constitutes specific rulings on the findings of fact proposed by the parties. Petitioner's Proposed Findings Adopted in paragraph 1. - 4. Adopted in substance in paragraph 2; otherwise rejected as unnecessary and immaterial. Adopted in part in paragraph 10; otherwise rejected as unnecessary. Adopted in substance in paragraph 4. Adopted in paragraph 30. Adopted in paragraph 4. Except as to the conclusion that the notice was not filed with the clerk on August 13, rejected as contrary to the greater weight of evidence, considering the testimony of Keen in its entirety. Adopted in substance in paragraphs 5, 8, 9, 10 and 12. Rejected as argument and conjective unsupported by the weight of evidence. Adopted in substance in paragraph 5. Adopted in part in paragraphs 6-9, otherwise rejected as immaterial. Adopted in part in paragraph 9; otherwise rejected as statement of testimony or unnecessary. Adopted in substance in paragraph 13. 16.-18. Adopted in paragraphs 14 and 19; otherwise rejected as unnecessary. Adopted in paragraph 21. Adopted in substance in paragraph 22. Adopted in substance in paragraph 16; otherwise rejected as unnecessary. Adopted in substance in paragraph 18. Adopted in substance in paragraph 20. Adopted in part in paragraphs 23-26; otherwise rejected as unnecessary. Adopted in substance in paragraphs 27 and 29. Rejected as contrary to the weight of evidence. 27.-28. Adopted in part in paragraph 36; otherwise rejected as argument or unnecessary. White clearly proved it will be severely prejudiced, even if it is not "put out of business". 29. Rejected as contrary to the weight of evidence (as to prejudice to the agency). 30.-31. Rejected as unnecessary. 32. Rejected as contrary to the weight of evidence; more commonly, the agency rules on the extension request first. Respondent's Proposed Findings Adopted in paragraph 1. Adopted in paragraph 2. Adopted in paragraph 3. Adopted in paragraph 4. Adopted in paragraph 5. Adopted in paragraph 6. Adopted in paragraph 7. Adopted in paragraph 8. Adopted in paragraph 9. Adopted in paragraph 10. Adopted in paragraph 11. Adopted in paragraph 12. Adopted in paragraph 13. Adopted in paragraph 14. Adopted in paragraph 15. Adopted in paragraph 16. Adopted in substance in paragraph 17. Rejected as unnecessary. 19. Adopted in paragraph 18. 20. Adopted in paragraph 19. 21.-22. Adopted in substance in paragraph 20. 23. Adopted in paragraph 21. 24. Adopted in paragraph 22. 25. Adopted in paragraph 23. 26. Adopted in paragraph 24. 27. Adopted in substance in paragraph 25. 28. Adopted in paragraph 26. 29. Adopted in paragraph 27. 30. Adopted in paragraph 28. Rejected as unnecessary. Adopted in paragraph 29. Adopted in part in paragraph 30; otherwise rejected as contrary to the weight of evidence (as to being a "paper shuffler"). 34.-38. Adopted in paragraph 31. 39.-40. Adopted in paragraph 32. 41.-42. Adopted in paragraph 33. Adopted in paragraph 34. Adopted in paragraph 35. Adopted in paragraph 36, except that the implication that the company will absolutely go out of business is rejected as unsupported by the evidence. Rejected as unnecessary. COPIES FURNISHED: Paul Sexton, Esquire Department of Transportation Haydon Burns Building, MS 58 605 Suwanee Street Tallahassee, Florida 32399-0458 Joseph W. Lawrence, II, Esquire Cummings, Lawrence and Vezina, P.A. 1600 S.E. 17th Street, Suite 304 Fort Lauderdale, Florida 33316 Ben G. Watts, Secretary Attn: Eleanor F. Turner, M.S. 58 Department of Transportation Haydon Burns Building 605 Suwanee Street Tallahassee, Florida 32399-0450 Thornton J. Williams, General Counsel Department of Transportation 562 Haydon Burns Building 605 Suwanee Street Tallahassee, Florida 32399-0450
The Issue Whether Respondent committed an unlawful employment practice in violation of Sections 760.10(1), Florida Statutes.
Findings Of Fact The Respondent, Beard Equipment Company, Inc., sells and maintains heavy equipment in Panama City, Florida. The Petitioner, Robert G. Harrison began employment with the Respondent in Panama City, Florida, in September, 1988. The Petitioner was employed as a janitor. Petitioner's duties included running numerous and varied errands which required driving of a motor vehicle. In April of 1989, Petitioner was hospitalized in order to adjust his medication for what he indicated was a bipolar disorder. However, at the hearing, Petitioner produced no expert testimony to establish that he was mentally handicapped or had bipolar disorder. At that time, Respondent became aware that Petitioner had a medical problem. Later, Petitioner was hospitalized in order to adjust his medication on two more occasions in 1989, and twice in 1992. On each occasion the Respondent accommodated Petitioner by making arrangements to hire temporary employees or readjust other employees' duties so that they could perform Petitioner's duties while he was hospitalized. In early 1992, the Respondent's liability insurance company conducted a random audit of employee driving records. The Respondent was notified by its insurance company that no coverage would be provided for any accident where the employee/driver had a DUI conviction. This random audit prompted Respondent to conduct a complete company- wide internal audit of driving records of all employees. The driving record audit resulted in some transfers for those employees for whom driving was an essential part of their job duties, but whose driving records would prohibit them from being covered under Respondent's liability policy. Employees who could not fulfill the duties of a non-driving position were terminated. Respondent could not afford to allow employees to drive who could not be insured by Respondent's liability carrier. The in-house driving record audit revealed that Petitioner had a DUI conviction on his record. Respondent had no other non-driving positions for which the Petitioner was qualified. Respondent was therefore forced to discharge the Petitioner since he could no longer fulfill the duties of his employment. Petitioner was discharged in November of 1992. When Petitioner was terminated, Petitioner was advised by Mark Veal, his supervisor, that the driving record audit had revealed that Petitioner had a DUI conviction, and because he would not be covered under the company insurance policy, they had no alternative but to discharge him. Within a day or so, Petitioner's wife called and requested his discharge letter in writing. Veal prepared the letter, indicating that due to Petitioner's medical history, his operating a motor vehicle would be too much of a liability. Although the real reason for Petitioner's discharge and the reason given him at the time was the DUI conviction, Veal tried to write the discharge letter in such a way as to minimize any embarrassment for the Petitioner due to his DUI conviction. Therefore, the termination letter does not support the conclusion that Respondent discriminated against Petitioner based on a mental handicap. In fact, there was no substantial evidence that Respondent terminated Petitioner based on a mental handicap. The evidence clearly showed Respondent was terminated for his driving record and his lack of qualifications to fill any other non-driving position. Moreover, Petitioner failed to establish that his position was filled by a person not in a protected class or that Respondent is an employer employing more than 15 employees. Given these facts, Petitioner has not established a prima facie case that Respondent committed an unlawful employment practice.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is accordingly, RECOMMENDED that the Florida Commission on Human Relations enter a Final Order finding that Petitioner did not prove by a preponderance of the evidence that he was discriminated against because of his alleged handicap in violation of the Florida Human Rights Act and that the petition be dismissed. DONE AND ORDERED this 22nd day of December, 1994, in Tallahassee, Florida. DIANE CLEAVINGER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of December, 1994.
The Issue An Administrative Complaint dated February 8, 1999, alleges that Respondent committed violations of Section 493.6118, Florida Statutes, when he performed armed security officer services without a proper license and when he failed to cooperate with an official investigation and gave false information regarding his identity and address. The issues in this proceeding are whether the alleged violations occurred and, if so, what penalty is appropriate.
Findings Of Fact Respondent, Vance H. Britto, was licensed by the Florida Department of State as a security officer some time prior to 1993. His license expired and he was deemed ineligible for re- licensure because of an unpaid disciplinary fine. On August 27, 1998, at approximately 11:30 p.m., Richard Yates, an investigator with the Florida Department of State, conducted a pro-active investigation at Windhover Apartments in Orlando, Orange County, Florida. Investigator Yates was accompanied by his colleague, Ed Sundberg. The investigators approached an individual wearing a security officer's uniform and badge and carrying a 38-caliber revolver. They identified themselves and asked the individual for his name and security officer's license. The individual gave his name as David Wilson but said that his license was at his employer's office being laminated. Although he was in a white Ford sedan with security markings, the individual denied having his driver's license or social security card with him. He gave his address as 2203 Page Street in Orlando. He gave his supervisor's name as Ricky Heath and his employer as Security Enforcement Services, Inc. After a brief exchange with the investigators, the individual sped away in his vehicle. Investigator Yates made a note of the license plate and made further notes on an inspection checklist. When he returned to his office and described the individual and the encounter to his supervisor, and with the aid of a file photograph, Investigator Yates was able to identify the individual as Vance Britto, a former licensee. In 1998 and to the present time, Mr. Britto has not been licensed with either a "Class G" or "Class D" license. No one knew Mr. Britto at the Page Street address he gave the investigators and when they checked his address in the computer file they learned that he had not lived there in over two years.
Recommendation Based on the foregoing, it is RECOMMENDED: that the agency enter its formal order finding Respondent guilty of violating Sections 493.6118(1)(g) and (o), Florida Statutes, and assessing an administrative fine of $1,000. DONE AND ENTERED this 8th day of November, 1999, in Tallahassee, Leon County, Florida. MARY CLARK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 8th day of November, 1999. COPIES FURNISHED: Douglas D. Sunshine, Esquire Department of State Division of Licensing The Capitol, Mail Station 4 Tallahassee, Florida 32399-0250 Vance H. Britto 6525 Pompeii Drive Orlando, Florida 32822 Honorable Katherine Harris Secretary of State Department of State The Capitol, Plaza Level 02 Tallahassee, Florida 32399-0250 Deborah K. Kearney, General Counsel Department of State The Capitol, Lower Level 10 Tallahassee, Florida 32399-0250
The Issue Whether Respondent Employer is guilty of an unlawful employment practice against Petitioner Employee.
Findings Of Fact On or about November 17, 2006, Petitioner filed an Employment Complaint of Discrimination (formerly known as a "Charge of Discrimination") on the basis of disability/handicap and national origin with the Florida Commission on Human Relations. On June 15, 2007, the Commission entered a Determination: No Cause. On or about July 2, 2007, Petitioner filed a Petition for Relief with the Commission. On or about July 5, 2007, this case was referred by the Commission to the Division of Administrative Hearings. On July 18, 2007, a telephonic conference was held to schedule a final disputed-fact hearing date. The hearing date agreed upon was October 1, 2007, and a Notice of Hearing and Order of Pre-hearing Instructions issued on July 18, 2007. Neither party complied with the Order of Pre-hearing Instructions. At the time noticed for October 1, 2007, Respondent appeared for hearing. In the Joint Response to Initial Order, filed July 16, 2007, and in a subsequent Motion filed September 26, 2007, Respondent referred to itself as "Wal-Mart Stores, East L.P. (incorrectly referred-to in the caption as Wal-Mart Stores)," but made no motion to correct the style of this cause. Respondent acknowledged in its pleadings, and its counsel acknowledged orally at hearing, that it was the appropriate Respondent in this cause, regardless of the case's style. After waiting 30 minutes, Petitioner still had not appeared for hearing. The undersigned made diligent inquiry to ensure that Respondent had done nothing to discourage Petitioner from appearing, and closed the hearing.
Recommendation Based on the foregoing Findings of Facts and Conclusions of Law, it is RECOMMENDED that the Florida Commission on Human Relations enter a final order dismissing the Employment Complaint of Discrimination and a Petition for Relief. DONE AND ENTERED this 3rd day of October, 2007, in Tallahassee, Leon County, Florida. S ___ ELLA JANE P. DAVIS Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 3rd day of October, 2007. COPIES FURNISHED: Cecil Howard, General Counsel Florida Commission on Human Relations 2009 Apalachee Parkway, Suite 100 Tallahassee, Florida 32301 Denise Crawford, Agency Clerk Florida Commission on Human Relations 2009 Apalachee Parkway, Suite 100 Tallahassee, Florida 32301 Amy Harrison, Esquire Lindsay A. Connor, Esquire Ford & Harrison 225 Water Street, Suite 710 Jacksonville, Florida 32202 Catrina Soriano 1826 Nekoma Court Tallahassee, Florida 32304
Findings Of Fact On August 6, 1980, the Respondent Gerald B. Natelson, was charged in the United States District Court, Eastern District of Missouri, with violating Sections 841(a)(1) and 846, Title 21, USC, by knowingly and willingly, combining, conspiring, confederating and agreeing with others to distribute and possess with intent to distribute, marijuana, methaqualone and hashish, Schedule I and II controlled substances. The Respondent Natelson pled guilty to violating Sections 841(a)(1) and 846, Title 21, USC, as charged in Count I of the Indictment, by knowingly conspiring with others to distribute and to possess with intent to distribute marijuana. The amount or quantity of marijuana which was involved in the conspiracy set forth in Count I, is not identified in the Indictment, the Judgment and Probation/Commitment Order entered December 22, 1980, or Judge Aronovitz's Order Granting Motion to Vacate, Set Aside or Correct Sentence, and Granting Petition for Writ of Habeas Corpus in Natelson v. United States, Case No. 82-542 SMA, entered May 10, 1982. The Indictment, at paragraphs 12, 14 and 22, sets forth the Respondent's involvement in the conspiracy, which consisted of meeting in Hollywood and Fort Lauderdale, Florida, on April 1 and 4, 1979, and Phoenix, Arizona, on June 1, 1979, with specifically named co-conspirators. Jose Fanelo, president of Universal Casualty Insurance Company and formerly regional director for the Department of Insurance, and Les Lloyd, regional investigator for the Department of Insurance, established that the Respondent had been a fit and trustworthy insurance agent. Additionally, the Respondent submitted various documents, identified as Respondent's Exhibits 2- 13, which support the opinions expressed by Fanelo and Lloyd that the Respondent is a fit and trustworthy insurance agent.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Department of Insurance enter a Final Order dismissing its Administrative Complaint against the Respondent Gerald B. Natelson. DONE and ORDERED this 20th day of May, 1983, in Tallahassee, Florida. SHARYN L. SMITH Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of May, 1983.
