The Issue The issue presented is whether Respondent committed the offenses alleged in the administrative complaint, and, if so, what penalty should be imposed.
Findings Of Fact At all times material hereto, Respondent, John Arena, was a certified residential contractor, the qualifying agent for Classic Industries, Inc. and held license number CR C021139 from the Florida Construction Industry Licensing Board. The President and sole owner of Classic was Anthony Manganelli. Mr. Manganelli was also the manager of Classic and the principal from whom Mr. Arena received his information about the contracts entered into by Classic. On or about July 30, 1988, someone contacted Ms. Solange Gaston of Hollywood, Florida, by telephone, and asked her if her roof needed repair. The solicitor represented himself as an associate of Classic and offered to come out and inspect her roof. Ms. Gaston, believing her roof was in disrepair, agreed to have the inspection completed and entered into a contract with Mr. Carlo Mangano, representing himself as an agent of Classic, to do the repair. With Ms. Gaston's agreement, the tile on her roof was replaced with shingle roofing and certain other repairs were attempted. A letter to Petitioner from the Chief Permit Processor of the City of Hollywood, Florida indicates that no roofing permit was issued for Ms. Gaston's address. The roof was leaking prior to the repair and continues to leak. Ms. Gaston paid the complete contract price of $3,500 to Classic, but has been unable to locate Mr. Mangano or to have her roof repair completed. In her attempts to achieve satisfaction, Ms. Gaston contacted Classic and asked to speak with someone in charge. She was under the impression that she was speaking with Mr. Arena; however, she never spoke to Mr. Arena. In fact, Mr. Arena was not aware of the contract with Ms. Gaston until the instant complaint was filed against him. Mr. Arena does not know Mr. Mangano. When Mr. Arena became aware of the problem, he attempted to contact Mr. Manganelli, but was told that Mr. Manganelli had moved. Ultimately, Mr. Arena located Mr. Manganelli at a new address. According to Mr. Arena, Mr. Manganelli produced a copy of what appeared to be a contract with Ms. Gaston which has the signature of Carlo Mangano on it, but it is marked indicating that Ms. Gaston's credit was turned down. Mr. Manganelli told Mr. Arena that Classic had not undertaken the job due to the refusal of credit. With that representation, Mr. Arena was under the impression that the work had not been done, as was the custom of dealing for Classic when credit was denied. The two papers purporting to be contracts, one which Ms. Gaston acknowledged as being the one which she signed and the other being the one which Mr. Arena obtained from Mr. Manganelli as the actual contract between Ms. Gaston and Classic through Mr. Mangano, appear to be altered. Although both documents contain the same information, including the date, parties, addresses, work to be completed and price quoted, the portion of the copy indicating the price is written in Arabic numerals on Mr. Arena's copy and by words on Ms. Gaston's copy. Mr. Arena's copy also has the indication that credit was turned down on it, although the cancelled checks paid to Classic by Ms. Gaston were received into evidence. It was Mr. Arena's arrangement with Mr. Manganelli that Mr. Arena was to be informed of every contract into which Classic entered. In this way, Mr. Arena knew which sites he was to supervise. Since he was not advised about the roofing job for Ms. Gaston, he made no attempt to supervise it and after he became aware that the credit for the job had been disallowed, he was under the reasonable impression that the job was not done by Classic. Further, he did not know Mr. Mangano, nor did he believe that Mr. Mangano had the authority to bind Classic. Mr. Arena believes that Mr. Mangano may have obtained a blank contract form of Classic and misrepresented himself to Ms. Gaston as an agent for Classic. Petitioner asserted, however, that Mr. Arena, nevertheless, was responsible for the job and that Classic did perform the job. Neither Mr. Manganelli nor Mr. Mangano were present or testified at the hearing. Given Mr. Arena's demeanor at the hearing and the conflicting and altered state of the alleged contract forms, Mr. Arena's testimony is deemed credible, and the proof failed to demonstrate clearly that Classic actually attempted to repair Ms. Gaston's roof or that Mr. Arena was responsible for the attempted repair.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is: RECOMMENDED that the Florida Construction Industry Licensing Board issue a Final Order dismissing the administrative complaint filed in this case against Respondent, John Arena. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 20th day of June, 1990. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of June, 1990. COPIES FURNISHED: Robert G. Harris Department of Professional Regulation 1940 North Monroe Street Suite 341 Tallahassee, Florida 32399-0792 John D. Arena 5961 Southwest 13th Street Plantation, Florida 33317 Fred Seely Executive Director Department of Professional Regulation Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 Kenneth D. Easley General Counsel Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792 =================================================================
Findings Of Fact On February 27, 1974, Pelle J. Lindquist contracted with Patrick G. Yeager to build a house on Concord Road in Ormond Beach, Florida. This contract was admitted in evidence as petitioner's Exhibit No. 1. The contract called for work to begin on March 1, 1974, and to be completed within 90 days. Work did not begin on March 1, 1974, but did begin in the latter half of March, 1974. Frequent rain in March, 1974, caused the roof to warp, so that it had to be replaced. After considerable delay in undertaking the repair, actually replacing the roof took only about a week. Replacing the roof added significantly to respondent's costs in performing under the contract. Eleven months after construction began, Mr. Yeager moved in. Because the kitchen and both bathrooms lacked wallpaper, and because the gravel yard was partly unfinished, respondent Lindquist paid Mr. Yeager $300.00, in exchange for which Mr. Yeager released Mr. Lindquist from all liability in connection with the house. The release was admitted in evidence as respondent's Exhibit No. 1. In the course of construction, Haven Vaughn, a sub- contracting carpenter, filed a notice of intent to lien on behalf of himself and his partner, Cal Fisher. As long as Mr. Lindquist was allowed draws on the construction loan, Messrs. Vaughn and Fisher were paid regularly. For reasons which were not developed in the evidence, the lender withheld part of the loan proceeds from respondent. When the draws stopped, the carpenters were not paid, and they stopped work on the Yeager house. The lender ultimately paid the carpenters in full. At the time Mr. Yeager contracted with Mr. Lindquist for the house, Mr. Lindquist entered into a separate agreement with Mr. Cameron, a real estate broker who introduced Mr. Lindquist to Mr. Yeager. Under the latter agreement, Mr. Lindquist was to pay Cameron Realty Company a brokerage fee upon "obtaining last draw from lending firm." The brokerage fee has not been paid and is currently the subject of civil litigation. On February 15, 1974, Mr. and Mrs. Horace N. Smith, Jr., contracted with respondent for the construction of a house on another lot on Concord Road in Ormond Beach, Florida. This contract was admitted in evidence as petitioner's Exhibit No. 2. The contract called for completion of the Smith house on or about June 15, 1974. After the contract was signed, the Smiths returned to New Jersey, entrusting oversight of the project to Mr. Cameron, a real estate broker who introduced Mr. Lindquist to the Smiths. As construction progressed, Mr. Cameron kept Mrs. Smith advised, and she mailed installment payments on the strength of Mr. Cameron's representations. In this fashion, Mr. Lindquist was paid 75 percent of the total contract price of $27,600.00. For reasons which were not developed in the evidence, the Smiths stopped payments under the contract, presumably at Mr. Cameron's suggestion. When the payments stopped, work on the house also stopped, and, during the ensuing hiatus in construction, vandals broke a glass door, scrawled obscenities on the walls, scraped the walls, damaged the outside doors, and ruined the wooden trim. Work had fallen far behind schedule when, in April of 1975, a lawyer retained by Mr. and Mrs. Smith wrote Mr. Lindquist to the effect that the Smiths would take over the project unless it was finished within a week. When the week had passed, the Smiths began dealing directly with the sub-contractors, the house was eventually completed at a total cost to the Smiths of $29,100.00, or $1,500.00 more than the Smiths had agreed to pay Mr. Lindquist for the job. As completed, the house lacked an electric garage door opener and a sprinkler system which Mrs. Smith guessed would cost $1,000.00, but no competent evidence as to the cost or value of either the door opener or the sprinkler system was adduced. Vandalism added significantly to the cost of the Smith house. Mr. Lindquist replaced a glass door broken by vandals. On account of the vandalism, the Smiths paid the carpenters an additional $300.00 for their labor. The front doors, the trim, and all bays had to be replaced; the cost of replacement materials was not established. At the time Mr. and Mrs. Smith contracted with Mr. Lindquist for the house, Mr. Lindquist entered into a separate agreement with Mr. Cameron. Under the latter agreement, Mr. Lindquist was to pay Cameron Realty Company a brokerage fee. The brokerage fee has not been paid and is currently the subject of civil litigation. Certified general contractors' licenses are renewable annually in June, pursuant to Section 468.108, Florida Statutes (1975). Mr. Lindquist had such a license for 1974-75. In June of 1975, he desired to renew his license, but in a fashion which would authorize him to contract on behalf of a corporation, rather than as an individual. He telephoned the Jacksonville office of the Florida Construction Industry Licensing Board and explained his situation. That office mailed him forms which he filled out and mailed back in June of 1975. In March of 1976, some nine months later, the completed forms were mailed back to respondent, but no license was issued. On March 22, 1976, Mr. Clyde Pirtle, an investigator employed in the Jacksonville office of the Florida construction Industry Licensing Board, filled out and mailed to respondent a Notice of Violation," notifying respondent that he had failed to renew his certificate during June of 1975. The same "Notice of Violation" advised respondent of his putative failure to notify the Florida Construction Industry Licensing Board of his new address, although his application papers for the 1975-76 license had been returned to the new address. On the Monday after the Friday on which respondent received the "Notice of Violation," he telephoned Mr. Pirtle's office and was told that Mr. Pirtle would contact him. On or about June 3, 1976, Mr. Pirtle did contact respondent and meet with him. At this meeting, respondent showed Mr. Pirtle the papers he had mailed to the Board in June of 1975, and which were returned to him unprocessed in March of 1976. Mr. Pirtle told respondent that the papers had been returned because the application forms were for a registered, and not for a certified, contractor's license, and furnished respondent another set of forms. Respondent filled out the new set of forms and mailed them to the Board in June of 1976. A month and a half before the hearing in this cause, respondent received 1976-1977 certified general contractor's license No. CGC007702, which is currently in force. No contractor's license for 1975-76 was ever issued to respondent. On May 3, 1976, respondent applied for and was issued a building permit to erect a new residence at 1623 Anniston Avenue in the City of Holly Hill. At that time, respondent had no current contractor's license and presented to the authorities a license which had expired.
Recommendation Upon consideration of the foregoing, it is RECOMMENDED that disciplinary action against Respondent, if any, be limited to a reprimand. DONE and ENTERED this 6th day of April, 1977, in Tallahassee, Florida. ROBERT T. BENTON Hearing Officer Division of Administrative Hearings Room 530 Carlton Building Tallahassee, Florida 32304 COPIES FURNISHED: Mr. Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. Thomas L. West, Esquire Post Office Box 1857 1030 Volusia Avenue Daytona Beach, Florida 32015 J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
The Issue The issues are whether Respondent committed the several violations of Sections 489.129(1)(h)2.,(h)3.,(j),(k), and (n), Florida Statutes (1997), for the reasons stated in the respective Administrative Complaints and, if so, what, if any, penalties should be imposed. (All chapter and section references are to Florida Statutes (1997) unless otherwise stated.)
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a certified general contractor pursuant to license number CG C059414. At all relevant times, Respondent was the qualifying agent for Fred T. Garrett Construction, Inc. ("FTG"). As the qualifying agent, Respondent was responsible for all of FTG's contracting activities in accordance with Section 489.1195, Florida Statutes. Respondent failed to obtain a certificate of authority for Fred T. Garrett Construction, Inc., as required by Section 489.119(2), Florida Statutes. The St. Cyr Case On or about August 21, 1998, Respondent entered into a contract with Louis L. St. Cyr to construct an addition to the residence located at 201 South Bel Air Drive, Plantation, Florida. The contract price was $50,000. Although Mr. St. Cyr paid $2,500 to Respondent, Respondent failed to commence work and canceled the project, thereby abandoning it without just cause and without proper notification to Mr. St. Cyr. The contract did not permit Respondent to keep the $2,500 paid by Mr. St. Cyr, and Respondent failed to refund the payment within 30 days after abandonment. Out of the $2,500 he received from Mr. St. Cyr, however, Respondent paid $1,600.00 to the architect before abandoning the project. Thus, the net amount that Respondent owes to Mr. St. Cyr is $900. Petitioner incurred a total of $1,092.28 in investigative costs relating to the St. Cyr case. The Forney Case On May 22, 1998, Respondent, who was doing business as FTG, entered into a contract with Mr. Warren Forney for the construction of a two-bedroom, one-bath addition to the residence located at 1698 Northeast 33rd Street, Oakland Park, Florida. The contract price was $32,500. The contract with Mr. Forney did not contain a written statement explaining the customer’s rights under the Construction Industries Recovery Fund, as required by Section 489.1425(1), Florida Statutes. On July 7, 1998, Respondent obtained permit number 98-050297 from the Oakland Park Building Department. Construction commenced on or about July 7, 1998, and continued sporadically until October 29, 1998, when Mr. Forney dismissed Respondent for failure to timely complete the project. The Oakland Park Building Department issued notices of violation against the project on August 3, September 11, and October 14, 1998, for various building code violations. Mr. Forney was forced to obtain a homeowner’s permit and subsequently hired a subcontractor to complete the work. Mr. Forney paid Respondent approximately $29,250 before relieving Respondent of his duties. To complete the project, Mr. Forney paid a total of $48,746.52, which was $15,396.52 over and above the original contract price. Petitioner incurred a total of $2,190.78 in investigative costs relating to the Forney case. The Kong Case In or around January 1998, a contractor named Lakeview Concepts hired Respondent to perform demolition work for the Kong dry cleaning store project on the property located at 5171 South University Drive, Davie, Florida. On or about June 17, 1998, permit 98-00002349 was issued to Respondent to perform alterations on commercial property located at 5171 South University Drive, Davie, Florida. Respondent, however, did not yet have a contract with the owner for this work. The next month, on or about July 30, 1998, Respondent, who was doing business as FTG, entered into a contract with Shek Kong to complete the dry cleaning store project at 5171 South University Drive, Davie, Florida, for the contract price of $22,300. Shek Kong made payments to Respondent totaling $16,000. Respondent’s work was of poor quality, however, and on or about November 6, 1998, he ceased work, though the project had not been completed. On or about November 14, 1998, Douglas Frankow, license number CB C052960, gave Mr. Kong an estimate of $20,562 to complete the project. Thereafter, on or about June 30, 1999, Mr. Kong contracted with George Settergren, another licensed contractor, to complete the project for a contract price of $27,956. On December 9, 1999, in Case No. 98-020065 08, the Circuit Court, Seventeenth Judicial Circuit, Broward County, Florida, rendered a Final Judgment against Respondent and in favor of Mr. Kong. This judgment awarded Mr. Kong the total amount of $28,693.30, plus 10 percent interest per annum. Petitioner incurred a total of $2,502.78 in investigative costs relating to the Kong case.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Florida Construction Industry Licensing Board enter a Final Order finding Respondent guilty of violating Sections 489.129(1)(h)2., (h)3., (j), (k), and (n), Florida Statutes, imposing administrative fines in the aggregate amount of $3,700, assessing investigative costs in the aggregate amount of $5,785.84, placing Respondent's license on probation for a period of four years from the date the Final Order is entered by the Board, and awarding payment of restitution to each customer as follows: (1) to Warren Forney, the amount of $15,396.52; (2) to Shek Kong, satisfaction of the unpaid civil judgment in the amount $28,693.30, plus 10 percent interest accrued thereon; and (3) to Louis L. St. Cyr, the amount of $900. DONE AND ENTERED this 15th day of February, 2002, in Tallahassee, Leon County, Florida. _________________________________ JOHN G. VAN LANINGHAM Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 15th day of February, 2002.
Findings Of Fact At all times material to this action, Respondent was and presently is a registered plumbing contractor having been issued License No. RF0038438. On August 18, 1981, the Collier County Contractor's Licensing Board revoked Respondent's competency card to practice plumbing in Collier County. The revocation was based upon Respondent's violation of Sections 4.1.10 and 4.1.17, Collier County Ordinance No. 78-02. Respondent failed to appear at the public hearing held before the Collier County Contractor's Licensing Board on August 18, 1981.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That Respondent's license as a registered plumbing contractor be revoked. DONE and ENTERED this 9th day of August, 1983, in Tallahassee, Florida. MARVIN E. CHAVIS Hearing Officer Division of Administrative Hearings 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 4th day of August, 1983. COPIES FURNISHED: Xavier J. Fernandez, Esquire Nuckolls, Johnson & Fernandez Post Office Box 729 Fort Myers, Florida 33902 Danny E. Fox Route 1, Box 54 Pleasant Shade, TN 37145 Mr. James Linnan Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue Whether Jose Ramone Garcia obtained a building permit for the purpose of aiding an uncertified or unregistered person to evade the provisions of Part 2, Chapter 468, Florida Statutes.
Findings Of Fact Jose Ramone Garcia holds a license as a general contractor issued by the Florida Construction Industry Licensing Board and is licensed as doing business as Gabros Construction. Jose Ramone Garcia, on or about April 26, 1974, obtained a building permit No. 74-1006 issued by Collier County Building Department to build a home at 378 Seabee Avenue, Vanderbilt Beach, Florida. The home at 378 Seabee Avenue, Vanderbilt Beach, Florida, was built by Roger Dulaney, an unlicensed person, who had contracted verbally to build said home with Mr. William E. Young, the owner of the real property. Jose Ramone Garcia obtained the building permit No. 74-1006 with money given to him by Roger Dulaney, but Jose Ramone Garcia did not receive any compensation for his assistance to Roger Dulaney. Jose Ramone Garcia did not contract with William E. Young to build the home at 378 Seabee Avenue, Vanderbilt Beach, Florida. Jose Ramone Garcia did not contract with any of the subcontractors or materialmen for services or goods used in the construction of the home at 378 Seabee Avenue, Vanderbilt Beach, Florida. Jose Ramone Garcia was frequently at the construction site at 378 Seabee Avenue and did oversee the construction which Dulaney directed. Garcia did insure that all construction work done was in accordance with the specifications and plans and the building code of Collier County. All work on the home at 378 Seabee Avenue was inspected and approved by the building authorities of Collier County. With several minor adjustments, the construction was acceptable to the owners. The major problem involved with the house constructed at 378 Seabee Avenue involved the contract price of the home arrived at between Dulaney and Young. Garcia did not negotiate the contract of the construction of the house at 378 Seabee Avenue and had no knowledge of the contract price. The dispute between Dulaney and Young resulted in court action between these parties which resulted in a judgment by the court in the favor of Dulaney. Jose Ramone Garcia has been unable to obtain a building permit as a contractor in Collier County since the filing of the Administrative Complaint in January, 1976. Garcia currently resides in Collier County.
Recommendation Because the licensing privilege of Garcia has already been effectively suspended for 14 months, which is a substantial period of suspension, the Hearing Officer does not feel that a further suspension would be of any benefit. The Hearing Officer would recommend that a civil penalty of $500 be assessed against Garcia based upon the foregoing findings of fact and conclusions of law. DONE and ORDERED this 29th day of March, 1977, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire Jacobs, Sinoff, Edwards, Alford & Burgess Post Office Drawer I Fernandina Beach, Florida 32034 Jose Ramone Garcia 9341 S. W. 38th Street Miami, Florida J. K. Linnan Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
