The Issue The issues are whether Respondent committed the several violations of Sections 489.129(1)(h)2.,(h)3.,(j),(k), and (n), Florida Statutes (1997), for the reasons stated in the respective Administrative Complaints and, if so, what, if any, penalties should be imposed. (All chapter and section references are to Florida Statutes (1997) unless otherwise stated.)
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a certified general contractor pursuant to license number CG C059414. At all relevant times, Respondent was the qualifying agent for Fred T. Garrett Construction, Inc. ("FTG"). As the qualifying agent, Respondent was responsible for all of FTG's contracting activities in accordance with Section 489.1195, Florida Statutes. Respondent failed to obtain a certificate of authority for Fred T. Garrett Construction, Inc., as required by Section 489.119(2), Florida Statutes. The St. Cyr Case On or about August 21, 1998, Respondent entered into a contract with Louis L. St. Cyr to construct an addition to the residence located at 201 South Bel Air Drive, Plantation, Florida. The contract price was $50,000. Although Mr. St. Cyr paid $2,500 to Respondent, Respondent failed to commence work and canceled the project, thereby abandoning it without just cause and without proper notification to Mr. St. Cyr. The contract did not permit Respondent to keep the $2,500 paid by Mr. St. Cyr, and Respondent failed to refund the payment within 30 days after abandonment. Out of the $2,500 he received from Mr. St. Cyr, however, Respondent paid $1,600.00 to the architect before abandoning the project. Thus, the net amount that Respondent owes to Mr. St. Cyr is $900. Petitioner incurred a total of $1,092.28 in investigative costs relating to the St. Cyr case. The Forney Case On May 22, 1998, Respondent, who was doing business as FTG, entered into a contract with Mr. Warren Forney for the construction of a two-bedroom, one-bath addition to the residence located at 1698 Northeast 33rd Street, Oakland Park, Florida. The contract price was $32,500. The contract with Mr. Forney did not contain a written statement explaining the customer’s rights under the Construction Industries Recovery Fund, as required by Section 489.1425(1), Florida Statutes. On July 7, 1998, Respondent obtained permit number 98-050297 from the Oakland Park Building Department. Construction commenced on or about July 7, 1998, and continued sporadically until October 29, 1998, when Mr. Forney dismissed Respondent for failure to timely complete the project. The Oakland Park Building Department issued notices of violation against the project on August 3, September 11, and October 14, 1998, for various building code violations. Mr. Forney was forced to obtain a homeowner’s permit and subsequently hired a subcontractor to complete the work. Mr. Forney paid Respondent approximately $29,250 before relieving Respondent of his duties. To complete the project, Mr. Forney paid a total of $48,746.52, which was $15,396.52 over and above the original contract price. Petitioner incurred a total of $2,190.78 in investigative costs relating to the Forney case. The Kong Case In or around January 1998, a contractor named Lakeview Concepts hired Respondent to perform demolition work for the Kong dry cleaning store project on the property located at 5171 South University Drive, Davie, Florida. On or about June 17, 1998, permit 98-00002349 was issued to Respondent to perform alterations on commercial property located at 5171 South University Drive, Davie, Florida. Respondent, however, did not yet have a contract with the owner for this work. The next month, on or about July 30, 1998, Respondent, who was doing business as FTG, entered into a contract with Shek Kong to complete the dry cleaning store project at 5171 South University Drive, Davie, Florida, for the contract price of $22,300. Shek Kong made payments to Respondent totaling $16,000. Respondent’s work was of poor quality, however, and on or about November 6, 1998, he ceased work, though the project had not been completed. On or about November 14, 1998, Douglas Frankow, license number CB C052960, gave Mr. Kong an estimate of $20,562 to complete the project. Thereafter, on or about June 30, 1999, Mr. Kong contracted with George Settergren, another licensed contractor, to complete the project for a contract price of $27,956. On December 9, 1999, in Case No. 98-020065 08, the Circuit Court, Seventeenth Judicial Circuit, Broward County, Florida, rendered a Final Judgment against Respondent and in favor of Mr. Kong. This judgment awarded Mr. Kong the total amount of $28,693.30, plus 10 percent interest per annum. Petitioner incurred a total of $2,502.78 in investigative costs relating to the Kong case.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Florida Construction Industry Licensing Board enter a Final Order finding Respondent guilty of violating Sections 489.129(1)(h)2., (h)3., (j), (k), and (n), Florida Statutes, imposing administrative fines in the aggregate amount of $3,700, assessing investigative costs in the aggregate amount of $5,785.84, placing Respondent's license on probation for a period of four years from the date the Final Order is entered by the Board, and awarding payment of restitution to each customer as follows: (1) to Warren Forney, the amount of $15,396.52; (2) to Shek Kong, satisfaction of the unpaid civil judgment in the amount $28,693.30, plus 10 percent interest accrued thereon; and (3) to Louis L. St. Cyr, the amount of $900. DONE AND ENTERED this 15th day of February, 2002, in Tallahassee, Leon County, Florida. _________________________________ JOHN G. VAN LANINGHAM Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 15th day of February, 2002.
The Issue Whether Respondent committed the violations alleged in the Amended Administrative Complaint issued against him and, if so, what disciplinary action should be taken.
Findings Of Fact Based on the evidence adduced at hearing, and the record as a whole, the following findings of fact are made to supplement and clarify the facts to which the parties stipulated at the outset of the final hearing (Parties' Stipulations)2: The contract referenced in the Parties' Stipulations (Building Contract) was signed by Mr. Stasinos (on behalf of ICC) and Mr. Skiera (on behalf of himself and his wife) on June 29, 2000. The home that ICC agreed to build for the Skieras (Skiera Residence) was described in the Building Contract as a "[c]ustom two-story residence with detached garage and riding cor[r]al for a total of 5,370 square feet." It was to be constructed on a tract of land owned by the Skieras in Boynton, Beach, Florida. The Building Contract provided for the following allowances: $20,000.00 for "electrical"; $17,000.00 for "plumbing"; $15,000 for "HVAC"; a "door hardware allowance" of "$50.00 per [interior] door"; $6,000.00 for a "stacked stone veneer" exterior; an "entry door hardware allowance" of "$100.00 per door"; $15,000.00 for "kitchen cabinetry and vanity"; $8,000.00 for "counter tops and vanity tops"; $9,000.00 for "landscaping," including "trees, shrubs, sod, automatic time clock, [and an] operated irrigation system with rain sensor"; and $7,000 for "driveways, walkways, [and] flatwork." There was no written statement in the Building Contract explaining a consumer's rights under the Construction Industries Recovery Fund, as then required by Section 489.1425, Florida Statutes. The Building Contract contained a "[p]ayment [d]raw [s]chedule," which provided as follows: Upon execution of contract: 10%- $36,608.00 Thereafter, progress payments based on schedule of values. This "schedule of values" (referred to in the "[p]ayment [d]raw [s]chedule") contained the following "scheduled values" (excluding change orders): 1. Permits $21,600.00 2. Clearing/Grading/Fill $10,800.00 3. Foot'gs. Undgr Plumb, Soil Treatmt $23,000.00 4. Foundation/Slab poured $32,760.00 5. Exterior Walls/Tie Beam $26,600.00 6. Roof Trusses $26,600.00 7. Roof Sheathing/Felt $19,400.00 8. Interior Framing Complete $14,000.00 9. Windows/Exterior Door Frames Set $14,400.00 10. 2nd Plumbing/Tub Set $7,200.00 11. Wiring Rough-In $14,400.00 12. HVAC Ducts Installed $7,200.00 13. Roof Shingles/Tiles Installed $14,400.00 14. Insulation (wall & ceiling) $4,200.00 15. Exterior Trim/Soffits $11,800.00 16. Drywall Hung $14,400.00 17. Drywall Finish $10,800.00 18. Interior Trim/Interior Doors Installed $13,400.00 19. Interior Paint $8,800.00 20. Siding/Stucco $14,400.00 21. Exterior Paint Complete $8,800.00 22. Exterior Doors & Garage Door Install $6,200.00 23. Cabinets/Countertops Installed $10,000.00 24. Plumbing Finish $3,600.00 25. Electrical Finish $5,600.00 26. HVAC-Compressor/A.H. Installed $10,920.00 27. Driveway/Walks Installed $3,600.00 28. Landscaping/Irrigation $7,200.00 There were six separate change orders. They were dated August 20, 2000 (Change Order No. 001), August 29, 2000 (Change Order No. 002), September 26, 2000 (Change Order No. 003), October 15, 2000 (Change Order No. 004), October 15, 2000 (Change Order No. 005), and November 10, 2000 (Change Order No. 006). As of December 21, 2000, ICC had been paid in full for all six change orders, as well as for items 1 through 8 on the "schedule of values." As of February 27, 2001, ICC had received additional monies from the Skieras: payment in full for items 9 through 12 and 15 on the "schedule of values" and partial (50 percent) payment for items 13 and 20 on the "schedule of values." As of April 10, 2001, ICC had been paid a total of $287,966.20 (all from the proceeds of a mortgage loan the Skieras had obtained from Admiralty Bank) for work done on the Skiera Residence. On May 1, 2001, the Skieras paid ICC an additional $16,800.00 for drywall work, bringing the total amount of payments that ICC had received from (or on behalf of) the Skieras, as of that date, to $304,766.20. The Skieras made no further payments to ICC. The "eight valid claims of lien" referenced in the Parties' Stipulations were filed by eight different subcontractors, all of whom had been hired by ICC to work on the Skiera Residence: Boca Concrete Pumping, Inc.; Gulf Stream Lumber Company; L & W Supply Corp., d/b/a Seacoast Supply; Waste Management of Palm Beach; B.T. Glass & Mirror, Inc.; Boca Raton Decorating Center Company; American Stairs; and Broten Garage Door Sales Inc.3 Boca Concrete Pumping was the "very first" subcontractor to work on the construction of the Skiera Residence. It did the "slab work, the foundation" (referenced in item 4 of "schedule of values"). Its lien was recorded on December 6, 2000. The lien was in the amount of $1,001.25, and it indicated, on its face, that it was for unpaid "concrete pumping" that had been furnished between September 8, 2000, and September 22, 2000. A satisfaction of this lien, dated March 8, 2001, was filed March 24, 2001. Gulf Stream Lumber's original lien was recorded February 15, 2001. It was in the amount of $67,872.59, and it indicated, on its face, that it was for unpaid "building material" that had been furnished between August 15, 2000, and January 24, 2001. An amended claim of lien was recorded May 3, 2001, in the amount of $36,530.59 for unpaid "building material" that, according to the lien, had been furnished between August 25, 2000, and March 27, 2001. A satisfaction of the original lien and amended claim of lien, dated November 30, 2001, was filed December 5, 2001. The liens were satisfied, pursuant to the terms of a Settlement Stipulation, upon the Skieras' payment of $39,579.28 to Gulf Stream Lumber. L & W Supply's lien was recorded April 30, 2001. It was in the amount of $4,536.98, and it indicated, on its face, that it was for unpaid "building materials [and] related items" that had been furnished between December 16, 2000, and January 30, 2001. A satisfaction of this lien, dated October 11, 2001, was filed November 7, 2001. The lien was satisfied by the payment of $10.00 "and other good and valuable consideration" (which was the payment of an additional $2,850.00 by check dated October 11, 2001). Waste Management of Palm Beach's lien was recorded May 31, 2001. It was in the amount of $1,665.89, and it indicated, on its face, that it was for unpaid "[w]aste [r]emoval [s]ervices" that had been furnished between August 30, 2000, and April 5, 2001. A satisfaction of this lien, dated October 19, 2001, was filed November 13, 2001. B.T. Glass & Mirror's lien was recorded June 29, 2001. It was in the amount of $3,560.00, and it indicated, on its face, that it was for an unpaid "glass/mirror package" that had been furnished between May 3, 2001, and May 31, 2001. A satisfaction of this lien, dated October 19, 2001, was filed November 13, 2001. The lien was satisfied by the payment of $1,600.00 (by check dated November 10, 2001), plus an agreement to provide "$2,000.00 in gazebo or arbor products from the Hitching Post," the Skieras' family business. Boca Raton Decorating Center's lien was recorded May 19, 2001. It was in the amount of $1,218.79, and it indicated, on its face, that it was for unpaid "paint, sealers [and] sundries" that had been furnished between May 1, 2001, to May 2, 2001. A satisfaction of this lien, dated October 11, 2001, was filed November 7, 2001. American Stairs' lien was recorded August 16, 2001. It was in the amount of $4,188.00, and it indicated, on its face, that it was for unpaid "[s]tairs and [r]ailings" that had been furnished between June 8, 2001, and June 15, 2001. A satisfaction of this lien was executed on October 15, 2001. Broten Garage Door Sales' lien was recorded September 5, 2001. It was in the amount of $3,214.00, and it indicated, on its face, that it was for the unpaid "sale and installation of garage doors and openers," which took place between June 25, 2001, and July 17, 2001. A satisfaction of this lien, dated January 31, 2002, was filed on February 5, 2002. At a meeting "in the early part of August [2001]" attended by Respondent, Mr. Stasinos, the Skieras, and the president of the bank from which the Skieras had borrowed the money to pay for the construction of their residence, Respondent announced that, on behalf of ICC, "he was filing [for] bankruptcy."4 ICC stopped working on the Skiera Residence after this meeting. At the time, the Skiera Residence was approximately 70 to 80 percent completed (and the Skieras had paid ICC a total of $304,766.20, or approximately 80 percent of the total contract price (including change orders) of $378,286.205). In addition to paying $57,316.62 to satisfy the "eight valid claims of lien" referenced in the Parties' Stipulations, the Skieras paid approximately an additional $57,000.00 to other subcontractors who provided goods and/or services "needed to complete the house." The $10,000.00 check referred to in the Parties' Stipulation 14 (that the Skieras received from Andover Construction, Inc.) did not "represent any kind of final settlement" between the Skieras and ICC. The October 4, 2001, Certificate of Occupancy for the Skiera Residence referred to in the Parties' Stipulations indicated, on its face, that ICC was the contractor, notwithstanding that ICC had abandoned the project "in the early part of August [2001]." Respondent has been a Florida-licensed general contractor since July 29, 1987. In his capacity as ICC's licensed qualifier, he has previously (by Final Order filed in DBPR Case Nos. 2001-03283 and 2001-03284 on December 23, 2003) been found guilty of, and disciplined for, violating (in connection with two residential construction projects undertaken by ICC for A. Richard Nernberg) the same subsections of Section 489.129(1), Florida Statutes (Subsections (1)(g), (i), and (m)) that he is accused of violating in the instant case. In these prior disciplinary proceedings, Respondent's license was suspended for two years, and he was fined $6,000.00 and required to pay $958.30 in investigative costs. Administrative complaints were also filed against Respondent in DBPR Case Nos. 94-15958 and 97-17352. Both of these cases were resolved by settlement stipulations in which Respondent "neither admit[ted] [nor] denie[d] the allegations of fact contained in the [a]dministrative [c]omplaint[s]."
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Board issue a Final Order: finding Respondent guilty of violating Section 489.1425(1), Florida Statutes, as alleged in Count I of the Amended Administrative Complaint, and fining him $1,000.00 for this violation; (2) finding Respondent guilty of the violation of Section 489.129(1)(g)1., Florida Statutes, relating to Boca Concrete Pumping's December 6, 2000, $1,001.25 lien, alleged in Count II of the Amended Administrative Complaint, and taking the following disciplinary action against him for this violation: suspending his license for four years (with such suspension to run consecutively with his current suspension); (b) fining him $5,000.00; (c) requiring him to pay restitution in the amount of $1,001.25 to the Skieras; and (c) ordering him to reimburse the Department for all reasonable investigative and prosecutorial costs (excluding costs related to attorney time) incurred by the Department; and (3) dismissing all other charges in the Amended Administrative Complaint. DONE AND ENTERED this 8th day of May, 2007, in Tallahassee, Leon County, Florida. S STUART M. LERNER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 8th day of May, 2007.
The Issue Whether Respondent's registration as a general contractor should be suspended or revoked, or the respondent otherwise disciplined, for alleged violations of Sections 468.112 (2)(a), (2)(g), and (2)(h), Florida Statutes, as set forth in the Administrative Complaint.
Findings Of Fact Petitioner Phillip H. Bare, Ocala, Florida, is registered with Respondent as a general contractor under the provisions of Chapter 468, Florida Statutes, and was so registered throughout the year of 1977. He operates under the name of American General Corporation of Florida, but that firm has not been qualified to engage in the contracting business in Florida, pursuant to Section 468.107, Florida Statutes. (Petitioner's Exhibits 1, 2, Stipulation, Testimony of Cherry) On August 15, 1977, Respondent, as president of American General Corporation of Florida, entered into a Home Improvement Installment Contract and Note with Joe Wheeler and wife, who reside at Route 2, Box 63, Live Oak, Florida. The contract provided that for a price of $4,250 Respondent would make the following property improvements on the Wheeler residence: Build 12 X 20 Room Addition and finish with paneling, ceiling tile, & all trim. Build 6 X 14 porch with top. Replace all Rotten sills. Replace all Rotten siding. Paint house with latex paint. Repair floor joist. The Wheelers made a down payment of $350 leaving an unpaid balance of $3,900. The promissory note provided for a total financed cost of $6,629.28 payable in monthly payments over a period of seven years. On August 29, 1977, the parties entered into another such contract for additional work to the residence for the price of $1,600 as follows: Install ceiling tile in (2) bed rooms and bathroom complete with trim. Install paneling in (2) bed rooms complete. Install paneling and tile board in bath. Remove old shingles and install new 235lb asphalt shingles. Install 54" kitchen sink complete and hook to water. The Wheelers paid $100 as a down payment on the work and financed the remainder with a total deferred price of $2,100 payable in 48 consecutive monthly installments. (Petitioner's Exhibits 5, 6, Testimony of E. Wheeler, J. Wheeler) Respondent subcontracted the work on the Wheeler residence to one John Compton. Respondent did not secure a Suwannee County Building Permit for the work, nor was he licensed in that county to act in the capacity of a contractor. (Testimony of Respondent, Wilson) On September 12, 1977, Mr. Wheeler signed a Customer's Completion Certificate" wherein he acknowledged that the contract work had been satisfactorily completed. Although Respondent testified that he explained the contents of the document to Wheeler at the time it was executed, Wheeler denied the same and testified that he had not read its contents prior to signing it. (Testimony of Respondent, J. Wheeler, Respondent's Exhibit 1) Prior to completion of the work, the Wheelers noted that certain deficiencies in the work existed, including a floor that "shaked" in the new addition, looseness of wall paneling, failure to replace rotten siding and lower sills, and failure to install ceiling tile in one bedroom. They spoke to workmen on the job who said that they would return and finish the work. However, nothing further was done in spite of the fact that Respondent told Mrs. Wheeler in a telephone conversation that he would be back to complete the job. As a result, Mrs. Wheeler made a complaint to Derl W. Wilson, the building official for Suwannee County. (Testimony of E. Wheeler, J. Wheeler, Wilson) Pursuant to Mrs. Wheeler's complaint, Wilson inspected the premises at some time during the month of September, 1977, and observed that the accomplished work was of a substandard nature involving various violations of the Southern Standard Building Code which had been adopted by Suwannee County in 1975. These violations, which Respondent acknowledged at the hearing to have been committed, included the following: concrete foundation blocks improperly aligned and unsupported by required concrete pad; improper spacing of floor joists at 24 inch rather required 16 inch intervals; use of one-ply instead of two-ply flooring material; failure to extend vent stack for plumbing system in kitchen to a height of 6 inches above the roof line; failure to provide a shutoff valve for cold water line under kitchen sink; failure to cover and protect splices in wiring of ceiling light fixture; failure to install ridge board for support of roof rafters; improperly installing two inch by four inch wood braces in attic; failure to connect sewer line to septic tank. Additionally, Wilson observed various instances of poor workmanship in installation of an electric wall receptacle and connection of the roof of the new addition to the existing building. Further, he noted that due to the improper spacing of floor joists, the substandard plywood flooring was not firm and constituted a safety hazard. (Testimony of Wilson, Petitioner's Composite Exhibit 3) After his inspection, Wilson wrote a letter to Respondent, dated October 18, 1977, pointing out the deficiencies in construction and advising that a complaint would be filed against him unless a building permit was obtained within ten days and the necessary corrections of deficiencies were made. Although Wilson testified that he did not hear from Respondent as a result of the letter, Respondent made several telephone calls to Wilson's office and was informed that he was on vacation. (Testimony of Wilson, Respondent, Respondent's Exhibit 7) On June 14, 1978, Respondent entered a plea of guilty in the County Court of Suwannee County, Florida to a charge of improper construction arising out of the Wheeler contract, and the Court withheld adjudication of guilt in the matter. (Petitioner's Exhibit 9) Respondent was previously convicted in the County Court of Putnam County, Florida, on August 13, 1974 of engaging in the business or acting in capacity of a contractor without being duly registered in the county pursuant to Section 468.105(2), Florida Statutes. On June 16, 1975, Respondent pleaded nolo contendere in the County Court of Alachua County, Florida to a charge arising out of his activities as a home improvement contractor. The Court withheld adjudication of guilt and placed the Respondent on probation for a period of six months and required that he "make necessary repairs to home of victim to satisfaction of Consumer Protection Section of State Attorney's Office, Eighth Judicial Circuit." (Petitioner's Exhibits 7-9) Petitioner has been a building contractor for twelve years. He testified that his subcontractor for the Wheeler job had been competent in the past and he relied on this fact in not closely inspecting the work under the Wheeler contracts. For this reason, he was unaware that the building code violations had occurred until after he had sold the Wheeler contracts and mortgages to a third party who was contacted by the Wheelers regarding the deficiencies. Respondent denied that he abandoned the work because he thought it had been completed until subsequent notification of the Wheeler complaint. He has since made attempts through Counsel to resolve the complaint by having the work performed by a contractor licensed in Suwannee County or by means of a monetary settlement. He further testified that he had inquired of Petitioner's office as to the necessity for obtaining a Suwannee County license prior to commencing the Wheeler contracts and was informed that his registration was valid for work in that county. He acknowledged that he made a "mistake" in not obtaining a building permit and in failing to supervise his subcontractor properly, but stated that the licensing rules in the various counties were "confusing." As to his prior difficulties in Putnam and Alachua Counties, Respondent testified that the Alachua matter involved a complaint raised four or five years after construction regarding quality of workmanship and that he had taken care of the matter. As to the Putnam County case, he testified that he was unaware that a building permit was necessary at the time he did the work for which he was subsequently prosecuted. It is found that Respondent's exculpatory testimony regarding his failure to obtain a building permit or county licensing, and lack of knowledge of code violations with respect to the work performed at the Wheeler residence is not credible. (Testimony of Respondent, Respondent's Exhibits 2-6)
Recommendation That Respondent's registration as a general contractor be suspended for a period of one year and that an administrative penalty in the amount of $500 be imposed, for violation of Section 468.112(2)(a), Florida Statutes. DONE and ENTERED this 23rd day of March, 1979, in Tallahassee, Florida. THOMAS C. OLDHAM Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of March, 1979. COPIES FURNISHED: Barry Sinoff, Esquire 2400 Independent Square Jacksonville, Florida 32202 C. Valentine Bates, Esquire 726 NW 8th Avenue - Suite B Gainesville, Florida J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621
The Issue Did Respondent commit the violations alleged in the Administrative Complaint dated April 11, 2000, and if so, what discipline is appropriate?
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant findings of fact are made: The Department is the agency of the State of Florida charged with the responsibility of regulating the practice of contracting pursuant to Section 20.165, Florida Statutes, and Chapters 455 and 489, Florida Statutes. Respondent is, and has been at all times material hereto, a certified residential contractor in the State of Florida, having been issued license number CR CO13253 by the Florida Construction Industry Licensing Board. At all times material hereto, Respondent was licensed with the Construction Industry Licensing Board as an individual. On or about November 20, 1993, Respondent entered into a written contractual agreement (contract) with Kevin Watkins (Watkins) to construct a single family residence at 126 Meadow Lark Boulevard, Lot 65, Indian Lake Estates, Florida. The contract price was $333,944.00. Between December 7, 1993, and February 1, 1996, Watkins and Respondent executed 102 addenda to the contract which increased the contract price by approximately $241,874.43, for a total amount of approximately $575.818.43. On or about December 9, 1993, Respondent obtained permit number 93-120l850 from the Polk County Building Department and commenced work on the project. The contract provided that the "project shall be substantially completed on or about 195 days from the date all building permits are issued." However, due to the 100-plus addenda to the contract, it was estimated that an additional 190 days would be needed to complete the project. Additionally, construction ceased on the home for approximately 60 days so that Watkins could explore the possibility of a construction loan. However, due to the extent of completion, the lending institutions decided not to make any construction loans. On or about May 27, 1996, Watkins moved to Florida with the expectations that his home would be completed within a short period of time. (Watkins' recollection was that the home was to be completed in a couple of weeks. Respondent's recollection was that the home was to be completed in a couple of months.) In any event, Respondent did not complete the Watkins home within a couple of weeks or a couple of months. After Watkins moved to Florida, Respondent paid for Watkins to live in a Best Western motel for a few weeks. Subsequently, Respondent moved Watkins into a rental home for which Respondent paid the rent through September 1996. Beginning October 1996 through July 1999, Watkins paid $600.00 per month for a total of $20,400.00 as rent on the rental home. In early 1998, Respondent and Watkins went through the home, identified those items which had not been completed and Respondent made a handwritten list of those items. Respondent failed to complete the items identified on the list. In fact, shortly thereafter, Respondent ceased working on the project and was unresponsive to attempts to contact him. At the time Respondent ceased working on Watkins' home, the home was approximately 75 percent complete. While this estimation of completion may not be totally accurate, it is the best that could be derived based on the evidence presented, including Respondent's testimony to which I gave some credence. Watkins paid Respondent $561,617.91, which represents approximately 97.534 percent of the total contract price plus addenda to the contract. Seventy-five percent of the contract price plus addenda to the contract equals $431,863.82 for an overpayment of $129,754.09. To date, Respondent has not returned any of the money he received from Watkins above the amount completed under the contract. From early 1998, until August 1998, when Watkins had Respondent removed as general contractor on the building permit, Respondent failed to perform any work on the home for a period in excess of 90 days. Respondent contracted with Jack Eggleston to install cabinets in Watkins home. Eggleston performed under the contract but Respondent failed to pay Eggleston in full, requiring Watkins to pay Eggleston $1,200.00. After Watkins' home was partially complete, Respondent advised Watkins that he had the home insured when in fact he did not have the home covered with insurance. While Respondent was building Watkins' home, Respondent and Watkins entered into a joint venture called Contractors of Central Florida to build modular homes sometime after January 1, 1995. Respondent contends that some of the checks Watkins claims as payment under the contract for his home, were in fact reimbursement to Respondent for funds he had advanced for the joint venture. There is insufficient evidence to establish facts to show that any of the checks Watkins claims as payment under the contract for his home were in fact reimbursement for funds advanced by Respondent for the joint venture. Up until the time of the final hearing, the Department had incurred costs for the investigation and prosecution of this matter, excluding costs associated with an attorney's time, in the amount of $1,451.28.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, and after careful review of the guidelines set forth in Rule 61G4-17.001(8) and (11), Florida Administrative Code, and the circumstances for purpose of mitigation or aggravation of penalty set forth in Rule 61G4-17.002, Florida Administrative Code, it is recommended that the Department: Enter a final order finding Respondent guilty of violating Section 489.129(1)(h)2., Florida Statutes, and imposing a penalty therefor an administrative fine in the amount of $1,000.00; Enter a final order finding Respondent guilty of violating Section 489.129(1)(k), Florida Statutes, and imposing a penalty therefor an administrative fine in the amount of $1000.00; Assessing costs of investigation and prosecution, excluding costs associated with an attorney's time, in the amount of $1,451.28, plus any such further costs which have or may accrue through the taking of final agency action and; Requiring Respondent to pay restitution to Kevin Watkins in the amount of $129,754.09 which represents the amounts accepted by Respondent for work not performed. DONE AND ENTERED this 23rd of October, 2000, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6947 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 23rd day of October, 2000. COPIES FURNISHED: Robert A. Crabill, Esquire Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32388-2202 Ronald J. Powell Post Office Box 7043 Indian Lake Estates, Florida 33855 Rodney Hurst, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Barbara D. Auger, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: Respondent James W. Geary presently holds certified general contractor's license number CG C005775. Respondent Geary apparently entered into a contract with Phillip Smith to add a screened porch to the Smith residence. Neither the contract nor the testimony of Mr. Smith were made available to the undersigned Hearing Officer. Respondent had difficulty obtaining a roofer and completion of the project was therefore delayed. During the interim, the interior of the Smith's living room suffered water damage. After receiving a complaint from the Smiths, Mr. Robert Jahn, Chief Building Official for the City of Tamarac, personally inspected the Smith project. He found that the water damage was caused by the uncompleted work of respondent and certain violations of the Southern Florida Building Code. Jahn did not know how long the project had not been worked on, but Smith told him he had tried for about one month to get respondent to return to correct the situation. Respondent testified that when he sent a man to the Smith residence to install the roof columns, Smith chased the man off the job. Upon the delivery of certain supplies for his projects, respondent Geary, d/b/a First Triangle Corporation, wrote two checks in the total amount of $391.41 payable to Rinker Materials. (Exhibit 1) These checks were offered for payment by Rinker, and were returned due to insufficient funds. The former credit manager of Rinker Materials did not know whether anyone from Rinker had contacted respondent about the checks. Respondent testified that no one from Rinker had informed him that the checks were dishonored. However, respondent did receive notice from his bank that the checks had been returned. He was changing banks about the same time and felt that the bank had made mistakes in the past. He felt that the checks were good when issued and he therefore did not put much reliance upon the notices received from the bank. Respondent testified that he is ready, willing and able to honor the checks written to Rinker Materials. Respondent Geary apparently entered into a contract with Richard Decker for the addition of a five by eleven foot bathroom to the Decker's residence. Neither the contract, the plans or specifications nor the testimony of Mr. Decker were offered into evidence at the Hearing. Respondent felt there were no deviations between the finished product and the job specifications, and that, even if there had been, there was no way he could put a five foot vanity into the project without violating the applicable building code. The field investigator for petitioner's District No. 10 found deviations from the plans with regard to the size of the vanity, the bathroom door and the illumination. He found that the Deckers had not indicated their approval of such deviations by placing their initials on the plans or specification. The South Florida Building Code (302.2(b)) provides that when the cost of a job is over $5,000.00, the permit applicant must present plans signed and sealed by a registered architect or engineer. A larger permit fee is also required for jobs costing over $5,000.00. On or about April 9, 1976, respondent Geary applied to the City of Tamarac for two building permits. (Exhibit 2). While blueprints were submitted, no plans signed and sealed by a registered architect Or engineer were submitted. From the square footages contained on the right hand column of the application, Chief Building Official Jahn determined that the value of the two projects were $7,300.00 and $6,620.00. The contract prices for these projects were approximately $8,000.00 and $10,000.00. There was no conclusive testimony as to who supplied the footage information on these applications, It was respondent's opinion that the actual costs of these projects did not exceed $5,000.00. Respondent apparently entered into a contract with Daniel Salzman for some project, and then entered into a second contract for the construction and installation of a fence and a trellis. For this second project, respondent received a deposit of $825.00. The first job was never completed by respondent and respondent never began work on the fence and trellis project. Respondent admitted that some $500.00 was due Mr. Salzman as a refund for the second project. He testified that he instructed Mr. Salzman to have the work on the first project completed by someone else and then to send respondent the bill for the same. Respondent has not heard from Salzman regarding this matter. By letter dated November 20, 1976, Chief Building Official Jahn notified respondent that "No further building permits [would] be issued to First Triangle Builders with you as their qualifier because of numerous complaints and unfinished projects." As indicated in the Introduction, petitioner filed an administrative complaint against respondent seeking to revoke his license for violations of certain ordinances and Florida Statutes S468.112(2). The cause was referred to the Division of Administrative Hearings for the appointment of a Hearing Officer, and the undersigned was designated to conduct the hearing.
Recommendation Based upon the findings of fact and conclusions of law recited above, as well as the seriousness of the offenses of which respondent has been found guilty, It Is recommended that respondent's certified general contractor's license number CG C005775 be revoked. Respectfully submitted and entered this 18th day of July, 1977, in Tallahassee, Florida. DIANE D. TREMOR Hearing Officer Division of Administrative Hearings Room 530 Carlton Building Tallahassee, Florida 32304 (488-9675) Area Code 904 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. James W. Geary 4370 Northwest 32nd Court Lauderdale Lakes, Florida Wallace Norman Construction Industry Licensing Board 305 South Andrews Avenue Ft. Lauderdale, Florida 33301 J. K. Linnan, Executive Director Construction Industry Licensing Board Post Office Box 8621 JacksonvIlle, Florida 32211
Findings Of Fact At all times material hereto, Respondent has been a registered residential contractor having been issued license number RR 0040275. In approximately 1980, Respondent entered into a contract to erect a screen room for a Mr. Lewis. Under the terms of the contract, Respondent was to obtain the necessary building permit. After the contract had been signed, Respondent's grandfather died, and Respondent therefore went to New Jersey. He left the permit application with his qualifying agent to sign and process through the building department. When Respondent returned from New Jersey approximately 30 to 35 days later, he went to the Lewis job site and found the project almost completed. Respondent did not check to ascertain if the permit had been obtained, but rather completed the screen room himself. Lewis subsequently contacted Respondent to say that he had received a notice of violation from the building department for erecting a screen room without a permit. Respondent contacted the building department and advised that it was not Lewis's fault, but rather that it was Respondent's responsibility to pull the permit. Respondent was charged with unlawfully erecting a screen room without a permit; he appeared in court and pled guilty; and he paid a $250 fine pursuant to the adjudication of guilt entered on April 20, 1981, in the County Court in and for Dade County, Florida, in Case No. 81-50438. On June 24, 1981, Respondent submitted to the Construction Industry Licensing Board a Contractor's Registration application. On that application, Respondent answered in the negative the following question: "Has any person named in (i) below ever been convicted of any offense in this state or elsewhere other than traffic violations?" At the time Respondent gave that answer, he believed it to be true. He understood the question to call for information on criminal acts and did not comprehend the "screen room" charge to have been criminal conduct. Since Respondent answered that question in the negative, his application for registration was processed in accordance with normal procedures. Had Respondent answered that question in the affirmative, his application would not have gone through normal processing but rather would have been presented to the Construction Industry Licensing Board for the Board's determination of whether to approve the application based upon a consideration of the facts. On November 22, 1982, Respondent contracted with Naomi Blanton to construct an addition to Blanton's home located in the City of Miami, in Dade County, Florida, for a contract price of $11,250. When Respondent had first met with Blanton several months earlier, he had told her he could guarantee completion of the project within 45 days. No contract was entered into at that time, however, since Blanton had not obtained the financing she needed in order to construct an addition. When the contract was signed on November 22, Respondent told Blanton he would start the job when he finished the Chamber of Commerce building he was con structing but that he was starting a 12-unit duplex project around Christmas and would not be able to guarantee any 45-day completion deadline. Accordingly, when the contract was signed, no completion date was included in the terms of that written contract, since Respondent did not know when he could guarantee completion. The Blanton contract written by Respondent specifically provided that Respondent would obtain the building permit. On December 22 and 23, 1982, two of Respondent's employees arrived at the Blanton job site, dug a trench, knocked down the utility room, and moved Mrs. Blanton's washing machine. No further work was done until January 1983. Since Respondent knew that he was required to obtain the building permit before commencing any construction work, Respondent submitted his plans and permit application to the City of Miami Building Department. After the plans had been there about a week, he was advised that his plans would not be accepted unless they were drawn by an architect, although that is not required by the South Florida Building Code. After attempting several more times to obtain approval from the City of Miami Building Department, Respondent hired an architect to redraw the plans and secure the building permit. By this time, Respondent found himself unable to concentrate on operating his business efficiently, since he was preoccupied with spending time with his father who was dying of cancer. Also by this time, Blanton had commenced telephone calls to Respondent on an almost daily basis as late as 11:00 p.m. at his office, at his home, at his mother's home, and at his father's home. Respondent offered to return Blanton's deposit, but she refused to cancel the contract and threatened Respondent that she would sue him if he did not comply with that contract. Respondent commenced working on the Blanton job, although no permit had yet been obtained. The contract on the Blanton job called for payments at certain stages of the construction. By January 27, 1983, Respondent had completed a sufficient amount of the work under the contract so that Blanton had paid him a total of $8,270 in accordance with the draw schedule contained in the contract. Respondent ceased working on January 27, 1983, and advised Blanton and her attorney that he would do no further work until he could obtain the building permit, which he had still not been able to obtain. Although he told them his work stoppage was due to his continued inability to obtain the permit, he also stopped work due to his father's illness and his continued inability to get along with Mrs. Blanton. A delay occurred with the plans being redrawn by the architect Respondent hired to obtain the Blanton building permit, since the architect needed information from Blanton and she was out of town. After Blanton returned, the architect made unsuccessful attempts to obtain the building permit. Respondent and his architect were finally able to speak to one of the top personnel in the City of Miami Building Department about the problems they were experiencing in obtaining a building permit, and, at about the same time, Blanton contacted that same individual to complain that Respondent had no permit. On May 4, 1983, the building department finally accepted the second permit application together with the plans drawn by the architect, and the building permit was issued on May 4, 1983. No work was performed on the Blanton job between January 27, 1983, when Blanton paid Respondent the draw to which he was entitled by that date, and May 4, 1983, when the building permit was finally issued by the City of Miami. Respondent immediately resumed work and quickly completed the next stage of construction called for under the Blanton contract. Upon completing that next stage, he requested his next draw payment; however, Blanton decided not to pay Respondent for the work completed and had her attorney advise Respondent not to return to the job site. Blanton then had a friend of her son come to Miami from Wisconsin to complete the addition to her home. At all times material hereto, Respondent held a certificate of competency issued by Metropolitan Dade County.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of violating Section 489.129(1)(d), Florida Statutes, by willfully and deliberately violating Section 301(a) of the South Florida Building Code; imposing an administrative fine against Respondent in the amount of $2,000 to be paid by a date certain; and dismissing the remaining charges contained in the Administrative Complaint, as amended, against Respondent. DONE and RECOMMENDED this 13th day of April, 1984, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of April, 1984. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Joseph F. Scioli, Jr. 246 North Krome Avenue Florida City, Florida 33034 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
Findings Of Fact The Respondent is a certified general contractor holding license number CG C016888. The Petitioner is an agency of the State of Florida charged with enforcing the provisions of Chapter 489, Florida Statutes, regulating the licensure and practice status and standards of building contractors in the State of Florida and enforcing the disciplinary provisions of that chapter. On December 14, 1981, Respondent contracted with Mr. and Mrs. Frank J. Sullivan to build the Sullivans a home in Sarasota County, Florida. Those parties entered into a contract whereby the Respondent was to be paid the actual cost of construction including all labor and materials plus a commission in the amount of 8 percent of the actual cost of construction, provided however, that the total contract price would not exceed $49,000, including actual costs and commission. In January, 1982, Respondent commenced work constructing the home. The Respondent worked on the home for several months and then abruptly ceased and abandoned construction without explanation on May 14, 1982. At this time the house was approximately 70 percent complete. At the time the Respondent ceased work on the project he had already been paid $47,362.29 or approximately 97 percent of the total contract price agreed to by the parties. The Sullivans thereafter had to pay $10,633.53 to subcontractors and materialmen who had been hired by the Respondent to supply labor and/or materials to the house, at the Respondent's direction, prior to his ceasing construction and leaving the job. Additionally, the Nokomis Septic Tank Company, Inc., the subcontractor who installed the septic tank, was owed $1,180.07 by the Respondent for the installation of the septic tank, which amount was to have been paid out of the total $49,000 contract price. The Respondent failed to pay Nokomis Septic Tank Company, which then filed a mechanic's lien on the property. In order to remove this cloud on their title to the property and avoid foreclosure of the lien, the Sullivans were forced to pay the $1,180.07 amount of the lien. In addition to more than $10,000 paid to subcontractors who had already performed labor or supplied materials to the job before the Respondent left it, the Sullivans had to obtain a loan from their bank in order to finish the project. The contracted for items which the Respondent had left undone (approximately 30 percent of the construction) required them to expend $18,662.04 to complete the dwelling in a manner consistent with the contractual specifications. The items which remained to be constructed or installed are listed on Petitioner's Exhibit 7 in evidence. The remaining amount of contract price which the Respondent was due upon completion of the job would have been $1,737.71. With this in mind, as well as the fact that the Sullivans had to pay in excess of $10,000 to defray already outstanding bills to subcontractors for labor and materials already furnished and then had to obtain a loan in order to pay $18,662.04 in order to complete the house, and it being established without contradiction that the Respondent was unable to make his payroll at the point of leaving the job, the Respondent obviously used substantial amounts of the funds he received from the Sullivans for purposes other than furthering the construction project for which he contracted with the Sullivans. Concerning Count II, on December 22, 1981, Frederick Berbert doing business as Venice Enclosures of Venice, Florida, contracted with Mr. Emory K. Allstaedt of Grove City, Florida, Charlotte County, to build an addition to Mr. Allstaedt's mobile home. The contract specified a price of $4,952 for which Berbert was required to construct a 12-foot by 20-foot enclosure or porch. Mr. Allstaedt never did and never intended to contract with the Respondent, Mr. Martin, rather, his contract was only with Frederick Berbert. Mr. Berbert was a registered aluminum specialty contractor in Sarasota County. He was not registered or licensed to practice contracting in Charlotte County where Mr. Allstaedt lived and where the porch was to be constructed. On December 28, 1981, the Respondent obtained building permit number 72030 from the Charlotte County Building and Zoning Department to construct a "Florida room" for Mr. Allstaedt's mobile home, the same room to be constructed by Mr. Berbert. Under Charlotte County Ordinances in evidence as Petitioner's Exhibits 13 and 13A, only a properly licensed "A", "B" or "C" contractor or a registered aluminum contractor can perform this type of job. The Respondent was appropriately licensed for this type of work in Charlotte County, but Mr. Berbert was not and thus could not obtain the permit in his own right. The Respondent's only connection with this job was obtaining the permit in his own name as contractor of record and in performing some minor work in replacing some damaged sheets of paneling shortly after the construction of the room addition and after the performance of the contract by Berbert. Though the Respondent listed himself as contractor in order to be able to obtain a building permit for the job, he never qualified as the contractor of record nor "qualified" Mr. Berbert's firm with the Construction Industry Licensing Board. Both Mr. Berbert and the Respondent were aware that Mr. Berbert could not legally perform contracting in Charlotte County at the time the Respondent obtained the building permit on Berbert's behalf.
Recommendation Having considered the foregoing Findings of Fact and Conclusions of Law, the evidence of record and the candor and demeanor of the witnesses, it is, therefore RECOMMENDED: That the contractor's license of Jack A. Martin be suspended for a period of ten (10) years, provided however, that if he makes full restitution to the Sullivans of all monies they expended for labor, materials and permits to enable them to complete the work he had contracted to perform, within one year from a final order herein, that that suspension be reduced to three (3) years after which his license should be reinstated. DONE and ENTERED this 27th day of April, 1984, in Tallahassee, Florida. P. MICHAEL RUFF Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of April, 1984. COPIES FURNISHED: Charles P. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Jack A. Martin 305 Park Lane Drive Venice, Florida James Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred M. Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue An administrative complaint dated June 7, 1989, alleges that Respondent violated Chapter 489, F.S., governing the construction industry, by completing a contracting job without having obtained a local building permit. The issue in this proceeding is whether the violation occurred, and if so, what discipline is appropriate. An ancillary issue is what effect, if any, Respondent's discharge in bankruptcy dated January 9, 1989, would have on any penalty in this case.
Findings Of Fact At all times material, and between July 1985 and July 1989, Robert Lambert was licensed by the Florida Construction Industry Licensing Board as a Registered Aluminum Specialty Contractor, with license number RX-0048976. Robert Lambert was the sole qualifying agent for The Screenbuilders Aluminum Trim, 1410 Elk Court, Apopka, Florida, a partnership business in which Lambert was a partner. In June 1987, the Screenbuilders entered into a written contract with Cecil Floyd to construct a carport and screened-in porch and new roof over Mr. Floyd's home at 741 Baron Road, Orlando, Orange County, Florida. The entire job was completed without Lambert's having obtained a building permit from the Orange County Building Department. Section 103 of the Standard Building Code of 1985, as adopted in the Orange County Building Code, requires that a building permit be obtained prior to altering, repairing, improving, converting, constructing, or demolishing any building or structure in the jurisdiction. (Petitioner's exhibits #2 and #3) Respondent and his agents knew that they needed a permit from the Orange County Building Department. For other jobs they had routinely obtained permits. After the work commenced, Lambert attempted to obtain a permit for the job. The building department would not accept the paperwork he offered and Cecil Floyd refused to pay for another plat as he had already paid out the entire contracted for monies for the job. To date, no permit for the Floyd job has been obtained. Robert Lambert's licensure file reveals several prior disciplinary actions, including revocation on January 11, 1990. As of the date of hearing, no final order on that action had been issued. On January 9, 1989, George L. Proctor, Bankruptcy Judge for the U.S. Bankruptcy Court, Middle District of Florida, entered a "Discharge of Debtor", providing as follows: DISCHARGE OF DEBTOR It appears that the person named above filed a petition commencing a case under title 11, United States Code on August 29, 1988 , that an order for relief was entered under chapter 7, and that no complaint objecting to the discharge of the debtor was filed within the time fixed by the court [or that a complaint objecting to discharge of the debtor was filed and, after due notice and hearing, was not sustained]. IT IS ORDERED THAT: The above-named debtor is released from all dischargeable debts. Any judgement heretofore or hereafter obtained in any court other than this court is null and void as a determination of the personal liability of the debtor with respect to any of the following: debts dischargeable under 11 U.S.C. Section 523; unless heretofore or hereafter determined by order of this court to be nondischargeable, debts alleged to be excepted from the discharge under clauses (2), (4) and (6) of 11 U.S.C. Section 523 (a); debts determined by this court to be discharged. All creditors whose debts are discharged by this order and all creditors whose are declared null and void by paragraph 2 above are enjoined from instituting or continuing any action or employing any process or engaging in any act to collect such debts as personal liabilities of the above-named debtor. Respondent Exhibit #1
Recommendation Based on the foregoing, it is hereby, RECOMMENDED That Respondent, Robert Lambert, be found guilty of violation of Section 489.129(1)(d), F.S. and fined $1,000.00. DONE AND RECOMMENDED this 22nd day of March, 1990, in Tallahassee, Leon County, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of March, 1990. COPIES FURNISHED: Jack L. McRay, Esquire Dept. of Professional Regulation 1940 N. Monroe St., Suite 60 Tallahassee, FL 32399-0792 Robert Lambert 1410 Elk Court Apopka, FL 32712-3026 Kenneth D. Easley, General Counsel Dept. of Professional Regulation 1940 N. Monroe St., Suite 60 Tallahassee, FL 32399-0792 Fred Seely, Executive Director Construction Industry Licensing Board P.O. Box 2 Jacksonville, FL 32202
Findings Of Fact Notice in this case was given as required on May 2, 1977. Paul Slivyak holds registered residential contractor's license RR 0000896 issued by the Florida Construction Industry Licensing Board. Slivyak is the qualifying licensee for Allcraft Construction Company, Inc., a Florida corporation solely owned by Paul Slivyak. Gussie Hailey identified a contract between Allcraft Construction Company, Inc., to her husband, Willie Hailey, for repairs to the interior of their residence caused by fire. See Exhibit 1. She also identified a cancelled check payable to Allcraft Construction Company signed by her in the amount of $1,700 as the initial payment to Allcraft Construction Company, Inc., under the terms of the contract. The only work performed by Allcraft Construction Company, Inc., on the Hailey residence pursuant to the contract was the removal of a portion of the burned interior of the Hailey hone. Gussie Hailey identified a photograph of the material removed from the hone as it was left in her back yard by the workmen. The total work performed by Allcraft Construction Company, Inc., on the contract was performed by two young men who worked one half day. The photograph and check identified by Mrs. Hailey were received as composite Exhibit 2. After the failure of Allcraft Construction Company, Inc. to complete the work called for under the contract, the Haileys had to additionally pay approximately $4,000 to complete the job in addition to the $1,700 paid to Allcraft Construction Company, Inc. Marjorie Kneski, the wife of Mr. Joseph Kneski, identified a contract between Allcraft Construction Company, Inc., and she and her husband for the construction of an addition to their home. See Exhibit 3. She also identified a cancelled check payable to Allcraft Construction Company in the amount of $700, initial payment to Allcraft Construction Company pursuant to the contract for the construction work to be performed. After waiting two or three weeks for Allcraft Construction Company to begin work, the Kneskis became concerned and contacted the Better Business Bureau. The Better Business Bureau contacted the Florida Construction Industry Licensing Board investigator in the area. The Better Business Bureau also informed Mr. Kneski that the business reputation of Allcraft Construction Company, Inc. , was of such a nature that care should be exercised in dealing with the company. Mr. Kneski contacted Allcraft Construction Company, Inc., and advised them that he wanted his money back in that they had not started work under the contract. The Kneskis never received any of their money back from Allcraft Construction Company. The investigator for the Florida Construction Industry Licensing Board contacted Slivyak regarding the Kneski's complaint. Slivyak told the investigator that he had used the money received from the Kneskis to pay a portion of his income taxes and no longer had the money. Kneski also identified a letter received by him from Jack A. Nants, Attorney at Law, representing Allcraft Construction Company, Inc. This letter (Exhibit 5) recognizes and ratifies the contract entered into in behalf of Allcraft Construction Company, Inc., by Doug Fioto, but indicates the intention of Allcraft Construction Company, Inc. , to retain the initial $700 received from the Kneskis as liquidated damage if Allcraft Construction Company, Inc., was not allowed to perform under the contract. The contract does not contain a liquidated damage provision.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, the Hearing Officer recommends that the Florida Construction Industry Licensing Board revoke the registered residential contractor's license of Paul Slivyak, No. RR 0000896. DONE and ORDERED this 19th day of July, 1977, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. Paul Slivyak 502 South Lake Formosa Drive Orlando, Florida 32803 Mr. J. K. Linnan Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
