Elawyers Elawyers
Ohio| Change
Find Similar Cases by Filters
You can browse Case Laws by Courts, or by your need.
Find 49 similar cases
CONSTRUCTION INDUSTRY LICENSING BOARD vs. FRED H. MOORE, 88-001999 (1988)
Division of Administrative Hearings, Florida Number: 88-001999 Latest Update: Jul. 11, 1988

Findings Of Fact At all times pertinent to the allegations contained in the Administrative Complaint filed herein, Petitioner was licensed as a general contractor in Florida, holding license number CG CO20660, under which license he had qualified Custom Retail Contractors, Inc., and the Petitioner, Construction Industry Licensing Board, (Board), was the state agency charged with regulating the practice of contracting. On February 12, 1986, the Board entered a Final Order in its case number 0058164 in which it suspended Respondent's license to practice contracting for five years. This action was based on a finding that Respondent had violated several sections of the Standard Building Code in a contract to build several commercial buildings in Largo, Florida, and also had exhibited gross negligence or incompetency in several aspects of the job. Respondent was first made aware of the action of the Board in late March or early April, 1986 when his attorney, Mr. Gordon, told him he had received a copy of the Final Order. At that point, Respondent did not know there had been a hearing on his case, though he knew an action had been filed. Correspondence extracted from the files of DPR relating to Respondent, indicates that between March 11, 1986 and June 25, 1986, several phone calls and letters were exchanged between DPR legal personnel and Respondent's counsel regarding whether Respondent had been given notice that the initial Administrative Complaint against him had been filed. The complaint had been served by an investigator with DPR on Mr. Gordon who declined to accept service since he was counsel for Respondent's corporation and not Respondent, individually. The evidence further indicates that subsequent pleadings in that case were misdirected and misaddressed due to faulty addresses used by the Department which included erroneous street addresses and erroneous ZIP codes. The upshot of all this was that Respondent failed to submit an Election of Rights regarding the initial Administrative Complaint, and, after numerous attempts at communication by DPR, which included the posting of a notice of the Board hearing in the Clearwater, Florida newspaper, the Board ultimately held Respondent in default and entered the Final Order suspending his license as described above. In the Spring of 1986, however, while the communication and correspondence between DPR and Mr. Gordon was going on, Respondent was led to believe, he contends, that the Final Order was not dispositive of his status, that the status of his license was still undecided, and that he could continue to practice his profession. His reliance on advice of counsel was misplaced and works to his detriment here as it does not excuse his improprieties. Consistent with that understanding, on May 1, 1986, Respondent entered into a contract with Mr. Clarence P. Foster, owner of Clarence's, a lounge, restaurant and package store located in Clearwater, Florida, to remodel a patio outside the facility. Work was to include pouring a concrete slab in the drive- thru, constructing a block wall around the patio, installing lattice panels on top of the block wall, and placing planter boxes on two of the walls. The total contract price was $4,730.00 and on May 15, 1986, the manager of Clarence's issued a check in the amount of $1,730.00 payable to Tom Morgan, Respondent's associate. At the time of Respondent's negotiations with Mr. Foster, Mr. Foster indicated he was utilizing a contractor for the complete remodeling of his facility who did not want to do the patio work, and Respondent agreed to do it. After their contract was signed, Respondent dealt with Mr. Foster's manager who showed him the plans for the entire remodeling which, according to Respondent, included the patio. They were stamped by the contractor and had a permit number on them. Respondent contends he asked if that indicated permit included the entire project and claims he was told it did. Respondent also claims he advised Foster's manager that there was some problem with his contractor's license but was assured that the master permit already issued would cover any work done by him under the terms of the individual contract. After receiving the down payment from the manager, Respondent purchased the required materials, paying cash therefore, and started work. Respondent relates that at the very beginning, a violation was written by building inspectors for the failure of the electrical contractor to procure a permit for his portion of the work. When this was done, the contractor immediately got the required permit after the fact and continued with his work. This concerned the Respondent, however, and he requested the manager to bring the existing permit for the remodeling around to the area where Respondent was working where he posted it and covered it with cellophane. When the inspector subsequently came by to check Respondent's work, he asked where the permit for that portion of the construction was and Respondent pointed to the master permit. The inspector then indicated that that permit was only for exterior siding and when Respondent protested that decision, called his office and verified that fact. Upon being advised of this development, Respondent then took the plans he had been furnished and a copy of the permit to the building office and asked the clerk on duty what he had to do. According to Respondent, he was advised that he needed to get more plans prepared with a certificate that the work already done had been done to code. Respondent relates that in response to these instructions, he procured an architect to come and look at the job as it then stood. The architect reportedly thereafter drew up plans and certified the quality of the work already accomplished by Respondent and Respondent allegedly took this information to the building department where, on June 25, 1986, he applied for a building permit to do the work. At that time, according to Respondent, he advised the clerk he had a problem with his license and that all he wanted was a supplemental permit to finish the job. Approximately two weeks later, when passing the County building, Respondent stopped in at the building department office to check on the status of his permit. It was at this point that he first discussed the matter with Mr. Palmer, the plans examiner, who told him that his license had been suspended and that he could not receive a permit to do the work requested. Respondent returned to Mr. Foster and explained the situation to him. Mr. Foster turned the matter over to his manager who arranged for someone else to get the permit and complete the job. Respondent contends he was not trying to trick anyone or to contract without a license. He claims that at the time he entered into the agreement with Mr. Foster, he was unsure of the status of his license and he thought he had made that clear to everyone, including Mr. Foster and the people at the building office. Respondent contends that in his dealings with Foster he was attempting to deal as a subcontractor and not as a general contractor. The fact is, however, that the contract he entered into was a separate contract with Mr. Foster and failed to indicate any reference to subcontractor status. The agreement called for Respondent to be paid directly by Foster and not by the general contractor and his claim is, therefore, not believed. Respondent's protestations in this regard are without merit. Further, his story regarding the permit status is equally as unbelievable. As a qualified contractor, Respondent knew, or should have checked on, the limits of the permit issued and whether it would cover the work he was to do. Reliance on the representations of the non-contractor manager of Mr. Foster's facility as to the status of the permit was unreasonable and constituted gross negligence. Consequently, he was thereafter operating in violation of the local law which required a permit for this work. As a result of the ongoing negotiations between Respondent's counsel and counsel for the Board, on July 10, 1986, after the contract between Mr. Foster and Respondent had been entered into, Respondent and the Board entered into a Settlement Stipulation which called for amendment of the Final Order entered in the prior case and which provided for the payment of a fine of $1,000.00 within 30 days with the further stipulation that when the fine was paid, the previously imposed five year suspension would be set aside. In the event the fine was not paid, however, then the Respondent's license was to be relinquished to the Board. The Amended Final Order was sent by certified mail to the Respondent but was unclaimed because the address used by the Department was, again, incorrect. It must also be noted, however, that at the time the Board agreed to the settlement stipulation, it had available to it the report of investigation relating to the current Administrative Complaint. The Board either failed to consider it or chose to ignore it when it agreed upon a settlement to the former Administrative Complaint. It is also noted that the Board was aware of the difficulties involving service of process as early as August, 1986. At that time, Respondent received a certified letter from the Board Attorney indicating that final action on his license would be taken by the Board at its September, 1986 meeting in Ft. Lauderdale. Respondent attended that meeting where, after discussion, counsel for the Board convinced the Board to reopen the case due to the questions involving proper service of its former actions. A year later, in July, 1987, Respondent was advised that the reopened case would again be considered at the Board's meeting in Tampa, and at the 1987 meeting of the Board, it entered its Amended Final Order. Though regrettable, these factors are not controlling and do not affect this current action.

Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is, therefore, RECOMMENDED that the Respondent's license as a general contractor in Florida be suspended for two years. RECOMMENDED this 11th day of July, 1988, at Tallahassee, Florida. ARNOLD H. POLLOCK, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of July, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 88-1999 The following constitutes my specific rulings pursuant to Section 120.59(2), Florida Statutes, on all of the Proposed Findings of Fact submitted by the parties to this case. For the Petitioner: 1 - 2. Accepted and incorporated herein. 3. Accepted and incorporated herein. 4 - 5. Accepted and incorporated herein. Accepted and incorporated herein. Accepted and incorporated herein. Accepted and incorporated herein. Accepted. 10 - 13. Accepted and incorporated herein. Accepted that Palmer refused to issue the permit because Respondent's license had been suspended. Accepted and incorporated herein. Rejected that Respondent willfully violated local building code. Evidence shows more of gross negligence than willfulness. Accepted. For the Respondent: No submittal. COPIES FURNISHED: Belinda Miller, Esquire, Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0758 Fred H. Moore 12687 - 97th Street, North Largo, Florida 34643 Fred Seely, Executive Director DPR, Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201

Florida Laws (3) 120.57489.127489.129
# 1
CONSTRUCTION INDUSTRY LICENSING BOARD vs. WELTON SMITH, 86-002641 (1986)
Division of Administrative Hearings, Florida Number: 86-002641 Latest Update: Sep. 02, 1987

The Issue Whether the Respondent's license as a registered general contractor should be disciplined?

Findings Of Fact The Respondent is a registered general contractor in the State of Florida. His license is number RG 0001015. At all times material to this case, the Respondent has held license number RG 0001015. The Respondent has been in the construction business for 51 to 52 years. During the Fall of 1985, Mr. Edward J. Ashley discussed a construction project at Mr. and Mrs. Ashley's residence with the Respondent. The Ashley's residence is located at 2353 Hampshire Way, Tallahassee, Florida. The Ashleys and the Respondent, on behalf of Big Bend Builders Corp., Inc., agreed on the construction work to be performed and the price to be paid for the work. The agreement was memorialized on October 7, 1985, (hereinafter referred to as the "Proposal"), by the Respondent and presented to the Ashleys. Pursuant to the agreement between the Ashleys and the Respondent, Big Bend Builders Corp., Inc., was to construct a room addition to be used as a porch in the back of the existing residence, extend a master bedroom and bathroom, replace the tile in the bathroom, remove a partition between the kitchen and the living room and replace the existing roof with fiberglass shingles with a 20-year warranty. The Ashleys agreed to pay the Respondent's corporation $28,300.00 in consideration of the work to be performed. The Proposal presented to the Ashleys by the Respondent was never signed by the Ashleys but they did agree verbally to the work to be performed. The Ashleys and the Respondent agreed verbally that the construction price would be paid in two installments. One installment was to be made when half the construction was completed and the other half was to be paid when the construction was completed. The Ashleys made the first payment on December 5, 1985. The payment was for $14,000.00. Although the project was not completed, the Ashley's made a partial payment of $6,000.00 on January 10, 1986. The second payment was made earlier than agreed upon at the request of the Respondent. The Respondent told the Ashleys that the payment was needed so that the project, which was already late, could be completed. The Ashleys and the Respondent agreed verbally that the construction would be completed by December 15, 1985. Construction began at the Ashleys on November 14, 1985. On November 22, 1985, the concrete slab for the addition to the Ashley's home was poured in the morning. That afternoon a hurricane struck and rain associated with the hurricane washed away the top layer of concrete. The loss of the top layer of concrete caused the slab to be rough and uneven. It was especially unsightly in the area where the new room was being added as a porch. The Ashleys planned to leave this area uncovered. When they complained to the Respondent he told them not to worry, that he would take care of it. It was not repaired, however. The slab was also uneven in the bathroom and approximately 1 and 1/2 inches higher than the existing slab in the master bedroom. These problems were also not corrected. The area where the new slab joined the existing slab in the master bedroom was ground down but a bump still remains. The trusses of the addition to the residence were higher than the existing trusses. Although some of the problems associated with this problem were corrected, there remains a bump on the roof of the addition. The wall between the bathroom and the master bedroom did not match the existing wall. This problem was not corrected and is still visible. The Respondent filed an application for a building permit with the City of Tallahassee on November 12, 1985. The permit was issued on November 13, 1985. The Respondent was required to arrange slab, framing, and insulation inspections and a final inspection of the construction at the Ashley's residence. The Respondent had the slab inspection completed on November 19, 1985. The framing inspection was conducted on December 11, 1985, by Mr. Rackley. The construction did not pass this inspection because there was no "header" over one door and the ceiling joists were not adequately attached. It was the Respondent's responsibility to correct the problems found as a result of the framing inspection before proceeding with construction. The fact that the construction failed the framing inspection was noted on the copy of the building permit which is displayed at the construction site. Ms. Ashley was the only person present during the inspection other than the inspector. On December 17, 1985, Mr. Rackley saw the Respondent at a party and mentioned the door header and the failure of the residence to pass the framing inspection. The ceiling joists were not mentioned. At the time the framing inspection was completed, the construction was 40 to 50 percent complete. By letter dated February 12, 1986, Mr. Rackley asked the Respondent why the Respondent had not requested a re-inspection. The Respondent proceeded with construction without passing a framing inspection. Therefore, in the February 12, 1986 letter from Mr. Rackley the Respondent was directed to uncover the areas which had failed the inspection so that they could be re-inspected. The Respondent did not respond to Mr. Rackley's letter of February 12, 1986. Therefore, on February 24, 1986, the Respondent was contacted by Mr. Rackley by telephone. The Respondent agreed to open the areas necessary to complete the framing inspection. On February 26, 1986, the framing inspection was completed. An opening had to be cut in the existing roof for the inspection to be completed. The Respondent did not fail to arrange a re-inspection of the property in order to hide anything or cover-up improper work. The construction passed the insulation inspection. No final inspection of the construction has ever been requested or completed. As a part of the Respondent's agreement with the Ashleys, the Respondent was to remove the roof on the existing structure and cover it and the new roof with fiberglass shingles with a 20-year life. The shingles used by the Respondent were Temko shingles. Manufacturers of roofing materials generally recommend how to apply their products in writing. Therefore, Temko included instructions for the application of the shingles used by the Respondent. The instructions were written on the paper used to wrap the bundles of shingles. In order for the manufacturer's guarantee of the Temko shingles to be effective, the shingles must be installed according to the manufacturer's instructions. The Southern Building Code, which applies in Leon County, also requires that manufacturer's instructions be complied with. The following pertinent instruction, among others, was included with the shingles used on the Ashley's residence: LOW SLOPE APPLICATION: On pitches of 2" per foot to 4" per foot, provide a double underlayment of asphalt saturated felt by applying a 19" wide felt strip along the eaves and over this apply a full 36" wide sheet. Continue with full 36" wide sheets, lapping each 19" over the preceding course. If winter temperatures average 25 F or less, thoroughly cement the felt to each other with Temko plastic cement from eaves and rakes to a point a [sic] least 24" inside the inside wall line of the building. This instruction is consistent with roofing industry standards. The roof of the Ashley's residence pitches at 2" to 2 1/2" per foot. Therefore, the Respondent should have applied two layers of felt to the roof as specified in the "Low Slope Application" instruction. The Respondent's crew, however, only applied one layer of felt to the Ashley's roof. The instructions for the shingles also specified that each shingle be attached with four nails placed in a particular pattern. The Respondent's crew did not follow these instructions. Along the edges of the roof, the felt should have been cemented to the roof. It was not, however. Shingles placed in the valleys on the roof were not attached in any manner to the roof. The manner in which the roof was installed was incompetent. After the roof was placed on the Ashley's residence, water leaked in at several locations. The Respondent did not return the Ashley's telephone call. One of the Respondent's work crew when informed about the leaks told Mr. Ashley that the roof was not leaking; that it was blowing in from outside. Some of the problems with the roof were corrected by the Respondent. They were corrected, however, only after a building inspector was called in by the Ashleys. Even then, the leaks did not stop. The Ashleys subsequently paid another contractor $560.00 to correct problems with the roof. Throughout the period of time that the Respondent's crew worked at the Ashley's residence, whenever a problem arose, the Ashleys would be told not to worry about the problem; that it would be taken care of. Many of the problems, however, were not taken care of by the Respondent. Throughout the period of time that work was being performed at the Ashley's residence, there were numerous times when no one would perform any work at the Ashley's. Weeks would often go by without the Ashley's seeing the Respondent and without the Respondent's presence at the Ashley's. During the period that work was being performed at the Ashley's residence, there was a great deal of rain and the temperature dropped below 40 degrees. These weather conditions slowed progress on completing the job. These weather condition were not unique, however, and the Respondent admitted that he knew it rains and gets cold often during the period of time involved in this proceeding. One weather problem that the Respondent could not have reasonably foreseen was the hurricane which struck Tallahassee on November 22, 1985. As a result of damage to property caused by the hurricane, roofing and other materials were more difficult to obtain. Rain associated with the hurricane washed away the top layer of the concrete from the slab that was poured the day the hurricane struck. The Respondent checked with the weather service that morning. Based upon the projected weather, the hurricane was headed away from Tallahassee and rain was not expected until that afternoon. The concrete was poured in the morning and would have been dry before the afternoon. The weather forecast was incorrect, however, and the rain struck earlier than expected. After work had commenced on the Ashley's residence, the agreement was modified. The Respondent indicated that he could not do the tile work in the bathroom. Therefore, the agreed upon price for the project was reduced by $2,000.00. The Ashleys also had the Respondent perform other work not originally agreed upon; 2 skylights and a door were added and additional brick work was performed. These changes caused some delay in completion of the project. The evidence did not prove, however, that all of the delay was attributable to the changes in the work to be performed. Much of the delay was caused by the fact that the Respondent's crew simply did not show up to work at the Ashley's residence. The delays in completing construction at the Ashley's residence were on the whole not reasonable. Although days were lost because of weather conditions, including the hurricane, and changes in the work to be performed, the days that no work was performed were not reasonable or caused by these factors. The Respondent failed to properly supervise the work performed at the Ashley's residence. Although the Respondent indicated that he relied upon the men who worked for him, he was ultimately responsible for the proper completion of the project. The project was not completed and some of the work performed was not performed in a satisfactory manner. The Respondent was not allowed to complete the project. The Ashleys eventually got so fed up with the Respondent's failure to correct problems and to complete the project that they would not allow the Respondents onto the property. Sometime after 1981, the Respondent received forms from the Petitioner which could be used to register his contracting license in the name of Big Bend Builders Corp., Inc. He asked his former attorney to complete the forms for him. The forms were completed and placed in the Petitioner's mail. The Respondent's license has not been registered in the name of Big Bend Builders Corp., Inc. The Respondent believed that his license was being switched to the corporate name. He knew or should have known that the change had not been completed because he did not receive a copy of a license with the corporate name. The Respondent's license had previously been held in a corporate name. The heading of the Proposal indicates that it is a proposal of "Big Bend Builders Corp., Inc." The Proposal was signed by the Respondent and was also signed "Big Bend Builders Corp., Inc. by Welton Smith." Mr. Ashley understood that the agreement he was entering into was with Big Bend Builders Corp., Inc. The two payments made by the Ashleys were made by checks. The checks were made out to Big Bend Builders Corp., Inc. The building permit on the Ashley's residence was applied for and issued in the name of Big Bend Builders Corp., Inc. Big Bend Builders Corp., Inc., was not qualified with the Petitioner.

Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Respondent be found guilty of violating Sections 489.129(1)(d), (g), (j) and (m) and 489.119, Florida Statutes (1985). It is further RECOMMENDED: That the Respondent be required to pay an administrative fine of $2,000.00. DONE and ENTERED this 2nd day of September, 1987, in Tallahassee, Florida. LARRY J. SARTIN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of September, 1987. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-2641 The parties have submitted proposed findings of fact. It has been generally noted below which proposed findings of fact have been generally accepted and the paragraph number(s) in the Recommended Order where they have been accepted, if any. Those proposed findings of fact which have been rejected and the reason for their rejection have also been noted. Petitioner's Proposed Findings of Fact Proposed Finding Paragraph Number in Recommended Order of Fact Number of Acceptance or Reason for Rejection 1 1 and 2. 2 56. 3 4. 4 5. 5-6 6. 7 7. 8 18. 9-10 18 and 61. 11-12 10. 13 39 and 41. 13 The first sentence is hereby accepted. The second sentence is not supported by the weight of the evidence. This state- ment was made to the Ashleys but in regard to the problems they had with their roof. 14 43. 15-16 44. 17 21. 18 21, 23 and 25. The building inspector informed the Respondent of the failed framing inspection on December 17, 1985, and not December 7, 1985. 19 28. 20 26. 21 33 and 34. 22 Hereby accepted. 23 37 and 38. 24-25 Hereby accepted. 26 38. 27 37. 28-29 39. 30 38-39 and 42. 31-35 Cummulative. 36-37 57. Respondent's Proposed Findings of Fact 1 Hereby accepted. 2 2. 3 28 and 29. There was no "final inspection" performed on the project. There was a final framing inspection, however, that indicated that the work that originally failed the inspection had been performed correctly. 4-7 These proposed findings of fact are not supported by the weight of the evidence. 47-48 and 50. The last sentence is not supported by the weight of the evidence. Not supported by the weight of the evidence. 10-11 Hereby accepted. 12 62. The last sentence is not supported by the weight of the evidence. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Van Poole, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Joseph Sole, Esquire General Counsel Department of Professional Regulation Tallahassee, Florida 32399-0750 W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Elwin Thrasher, Jr., Esquire 908 North Gadsden Street Tallahassee, Florida 32303

Florida Laws (3) 120.57489.119489.129
# 2
CONSTRUCTION INDUSTRY LICENSING BOARD vs. FRANK DANIELE, 79-001941 (1979)
Division of Administrative Hearings, Florida Number: 79-001941 Latest Update: Jul. 23, 1980

The Issue The issue posed for decision herein is whether or not the Respondent has engaged in conduct which warrants the Board to take disciplinary action as set forth in its Administrative Complaint.

Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, arguments of the parties and the entire record compiled herein, the following relevant facts are found. The pertinent complaint allegations are that: Respondent willfully and deliberately disregarded and violated the building codes or laws of this state or its cities, counties or municipalities. Acted as a contractor under a name different from his registered certification. Abandoned a construction project. Materially failed to comply with the provisions of Chapter 468, Florida statutes. 1/ Frank Daniele, Respondent, is a registered General Contractor who holds license No. RG 0009465, which is currently active. On October 24, 1977, Respondent entered into a contract with Mr. and Mrs. Howard Heil to construct a residence for the sum of $75,000.09 in Lee County, Florida. (Petitioner's Exhibit 2.) On December 27, 1977, Respondent, through the entity of D & D Construction Company, applied for and obtained a building permit to construct the Heils' residence. Respondent has qualified D & D Construction Company with the local Lee County Board. The events which are the subject of this complaint occurred in Lee County. (Testimony of John Viking, Petitioner's investigator assigned to investigate the complaint filed by the Heils.) On November 11, 1977, Mrs.. Theresa Heil paid Respondent a fee of $5,000.00 to commence construction of their residence. The Heils paid Respondent two additional payments in the amount of $10,500.00 each on January 30, and March 13, 1978. When Respondent and the Heils entered into the agreement for the construction of their residence the Heils advised Respondent that they wanted parts of two models which the Respondent had plans for, the Amhurst and the Victoria. Respondent attempted to comply with the Heils' request and, in so doing, prepared a set of drawing plans which were submitted to the Heils at their permanent residence in Dumont, New Jersey. According to the plans and specifications submitted to the Heils, the total square footage of the living area was approximately 3,172 plus an additional 520 square feet for the unheated area. (Petitioner's Exhibit 5) The Heils visited the construction site after Respondent had completed the framing chase of the construction. The Heils inspected the Respondent's progress to that point and were pleased with the construction. However, they wanted the entrance area (foyer) enlarged. Respondent explained the difficulty he would encounter in removing various partitions and wall plates after they had been erected. Respondent reluctantly agreed to go along with the Heils' desire to enlarge their home on an "at-cost" basis. The Heils disagreed and Respondent counter-offered to do the enlargement if the Heils would defray one-half of his cost for the enlargement. According to Respondent's undisputed testimony, the Heils requested an enlargement which would bring the total square footage of the house to approximately 5,400 square feet. The parties were unable to independently resolve their differences and the Heils engaged the services of James Humphrey, a local attorney in Fort Myers. Attorney Humphrey was called upon to act as trustee for the disbursement of the remaining monies due Respondent for the completion of the Heils' residence. During approximately July of 1979, Respondent and Attorney Humphrey disagreed with the progress of construction and the disbursement of funds. All work ceased on the project by Respondent after Attorney Humphrey had disbursed approximately $17,500.00. Respondent does not dispute the amount of money paid him by the Heils and their trustee, Attorney James Humphrey. He credibly testified that he endeavored to construct the residence for the Heils within the limits of the funds disbursed him; however, Attorney Humphrey was "very slow in disbursing funds as construction was completed". He (Respondent) also emphasized the fact that he was operating with limited funds and further weakened his financial wherewithal by attempting to enlarge the Heils' residence over and above that which he originally agreed to in an effort to satisfy the Heils. After reviewing the entire testimony and the documents compiled herein relating to the Heils' complaint, the undersigned is of the opinion that the Respondent's version of the events surrounding the Heils' complaint is more credible than the version attested to by Mrs. Heil. For example, Mrs. Heil testified on direct examination that there were no change orders in the project; however, Respondent's undisputed testimony is that the Heils requested and he reluctantly agreed to enlarge the foyer of their residence after the framing phase of the construction was complete. Respondent also testified that the total square footage of the Heils' residence as agreed upon in the contract was approximately 3,483 square feet, 2/ whereas subsequent to the modifications and changes requested by the Heils, the total square footage of the residence was increased to approximately 5,400 square feet. (Testimony of Heil and Petitioner's Exhibit 5.) Finally, Mrs. Heil made much of the fact that she had to pay an additional $1,500.00 for the purchase of a central vacuum system, whereas a review of the contract entered into between the parties revealed that that was one of the items to be purchased "by owners at contractor's cost, if desired". (Petitioner's Exhibit 2, paragraph 23.) Respondent made known to the Heils his inability to complete their residence, as enlarged, without an adjustment in the contract price. When the Heils refused, Respondent had just cause for refusing to complete their residence with the modifications without an adjustment in his contract price. For all these reasons, it is concluded that the Respondent is not guilty of abandonment of a construction project as set forth and defined in Section 468.112(2)(h), Florida Statutes. 3/ I shall so recommend. Maxine Allred, an employee of the Lee County Code Enforcement Licensing Complaint section, appeared and testified at the hearing. Based on Ms. Allred's review of the pertinent inspection documents respecting the Heils' residence, Respondent's work was satisfactory and at each inspection stage the work passed inspection. During 1977 through December 30, 1978, Respondent held a local Lee County registration with D & D Construction Company listed as the qualifying entity. There is no record that the Respondent was suspended by the Lee County Board of Construction as alleged. To the contrary, the Lee County Board advised the Heils by letter dated May 20, 1978, that Respondent's work was satisfactory and in compliance with Code specifications. (Testimony of Ms. Maxine Allred.) Although Ms. Allred testified that in order for Respondent to renew his license, in view of the hiatus between the date that his license expired, i.e., December 30, 1979, and the present time, it would be necessary for Respondent to take a "block exam" and prove his proficiency before the Board, there was nothing in that testimony which would tend to indicate that this requirement was occasioned by anything other than the mere lapse of time since the expiration date of his license. In this regard, Respondent testified that he had in fact passed the required block exam; however, he had not applied for licensure inasmuch as he was merely completing on-going Projects which were commenced during a period in which he was licensed by the local Lee County Board. Finally, Respondent closed by asserting that he would have completed the Heils' house even with the enlargements had payments been timely made as construction progressed. The soaring costs of construction both in terms of labor and materials forced Respondent to halt activity on this project for nonpayment.

Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED: The Administrative Complaint filed herein be DISMISSED IN ITS ENTIRETY. ENTERED this 30th day of April, 1980, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of April, 1980.

Florida Laws (1) 120.57
# 3
ROBERT E. ROSSER vs CONSTRUCTION INDUSTRY LICENSING BOARD, 94-005214 (1994)
Division of Administrative Hearings, Florida Filed:Miami, Florida Sep. 20, 1994 Number: 94-005214 Latest Update: May 17, 1995

The Issue The central issue in this case is Petitioner's challenge to part III of the licensure examination as set forth in his letter dated September 8, 1994.

Findings Of Fact Petitioner, Robert E. Rosser, is a candidate for licensure as a general contractor. Petitioner has taken the examination to become a licensed general contractor consecutively over the last four years. As a result of the twelve attempts at the examination, Petitioner has passed parts I and II on two separate test dates. In his attempts to pass the examination Petitioner has enrolled in and studied for the examination with two approved construction schools. Petitioner scored a 68 on part III of the general contractor's examination for the June 16, 1994 test date. Petitioner timely challenged questions related to part III (Project Management) of the general contractor's examination given on June 16, 1994. Petitioner attended a review session and claimed that as to question 2 his scratch sheet from the examination demonstrates he had used formulas properly and that he had inadvertently marked the incorrect response on the answer grid sheet. The minimum score required to pass part III of the examination was 70. For each of the challenged questions in part III (2, 4, 7, 9, 11, 17, 18, and 20) Respondent presented competent evidence to support the correct answer as scored by the Department. The Petitioner did not present credible evidence to dispute the accuracy of the answers which had been deemed correct by the Department. Based upon those answers, the Petitioner's score sheet was tabulated correctly. The questions challenged were clearly and unambiguously worded and contained sufficient factual information to reach a correct answer. The examination was open book and applicants were allowed to use reference materials. All current techniques were considered before the correct answer was chosen. All knowledge needed to reach a correct answer was within a candidate's expected range of expertise. The Department's scoring of part III was not arbitrary, capricious, or devoid of logic. For each of the challenged questions, the correct answer was scored at a higher percentage than the answers marked by Petitioner. In fact, for question 4, for example, 79 percent of the examinees scored the correct answer while only 3 percent marked the same answer as Petitioner.

Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That Department of Business and Professional Regulation, Bureau of Testing enter a final order dismissing Petitioner's challenge to the general contractor's examination. DONE AND RECOMMENDED this 23rd day of January, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of January, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NO. 94-5214 Rulings on the Petitioner's proposed findings of fact: Petitioner did not number the paragraphs denoted as "STATEMENT OF FACTS AND FINDINGS". The lettered paragraphs are addressed as listed; but where no letter identified the paragraph, the rulings are as to the paragraphs in the order of presentation. Paragraph [A] is accepted. Paragraph [B] is accepted to the extent it identifies Petitioner as a candidate otherwise rejected as not supported by the weight of the credible evidence. Petitioner's citation to Rule 21E-16.005 is an error. It is accepted that the minimum passing grade for the challenged part is 70 percent out of 100 percent. Paragraph [C] is accepted in substance; however, Petitioner's citation to Rule 21E-16.003 is an error. The next paragraph is rejected as contrary to the weight of the credible evidence. The next paragraph is accepted as a correct statement of procedural review. The next paragraph is rejected regarding question 4 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected regarding question 7 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected regarding question 9 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected regarding question 11 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected as not a statement of fact. Petitioner's scratch sheets have been received as Petitioner's exhibit 1. The next paragraph is rejected regarding question 17 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected as not a statement of fact. Petitioner's scratch sheets have been received as Petitioner's exhibit 1. The next paragraph is rejected regarding question 18 is rejected as not a statement of fact or contrary to the weight of the credible evidence. The next paragraph is rejected regarding question 20 is rejected as not a statement of fact or contrary to the weight of the credible evidence. Paragraph [D] is accepted as statement of procedural information but is not supported by the evidence. Paragraph [E] is accepted as statement of procedural information but is not supported by the evidence. The next paragraph is merely an address for the Department and is not a statement of fact. Paragraph [F] is accepted as statement of procedural information but is irrelevant. Paragraph [G] is accepted as statement of procedural information but is irrelevant. The next paragraph is merely an address for the Division and is not a statement of fact. Paragraph [H] is accepted as statement of procedural information but is irrelevant. Paragraph [I] is accepted as statement of procedural information but is irrelevant. Paragraph [J] is accepted as statement of procedural information but is irrelevant. Paragraph [K] is rejected as contrary to the record in this case since an order of prehearing instruction was not entered in this case and interrogatories were not served. Paragraph [L] is rejected as irrelevant, not a statement of fact, and contrary to the record. Moreover, Petitioner's scratch sheets have been received as Petitioner's exhibit 1. Paragraph [M] is rejected as argument or contrary to the weight of credible evidence. Paragraph [N] is rejected as irrelevant or contrary to the weight of credible evidence. Paragraph [O] is rejected as contrary to the weight of credible evidence. Paragraph [P] is rejected as contrary to the weight of credible evidence. Rulings on the proposed findings of fact submitted by the Respondent: Paragraphs 4 through 11 are accepted. Paragraph 1 is accepted as statement of procedural information. Paragraph 2 is accepted as to the substance but is not a statement of relevant fact. Paragraph 3 is accepted as to the substance but is not a statement of relevant fact. COPIES FURNISHED: Robert E. Rosser P.O. Box 560541 Miami, Florida 33256-0541 William M. Woodyard Assistant General Counsel Department of Business and Professional Regulation 1940 North Monroe Street, Suite 60 Tallahassee, Florida 32399-0750 Jack McRay General Counsel Department of Business and Professional Regulation 1940 North Monroe Street, Suite 60 Tallahassee, Florida 32399-0792 Richard Hickok Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-6310

# 4
CONSTRUCTION INDUSTRY LICENSING BOARD vs. LEE W. HOLLIDAY, 87-005604 (1987)
Division of Administrative Hearings, Florida Number: 87-005604 Latest Update: Mar. 07, 1988

Findings Of Fact The parties stipulated at conclusion of hearing to the matters set forth in the following findings of fact. Stipulated Facts The Respondent was the subject of a previous administrative complaint filed by the Petitioner. The previous administrative complaint issued by Petitioner was number 76024. The Respondent did not seek a formal administrative hearing to contest the charges of the previous administrative complaint which consisted of the same fact allegations and statutory violation as set forth in the charges in the instant complaint. The Respondent and the Petitioner reached an accommodation in regard to the charges set forth in the previous administrative complaint. Petitioner entered a final order in that previous case pursuant to stipulation and settlement which imposed sanctions upon the Respondent. Such final order was signed on November 19, 1987, by J. R. Crockett, Chairman of the Construction Industry Licensing Board and was filed with the Board Clerk on November 24, 1987. The administrative complaint in Division of Administrative Hearings case number 87-5604 and Petitioner's case number 82716, the instant case, is included in the settlement of Petitioner's case number 76024. As a result of the previous administrative adjudication of the same cause of action as set forth in the present proceeding, further factual findings in this case are not warranted.

Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that, in view of the parties's stipulation at hearing, a final order be entered 1) finding this administrative complaint, as set forth in Division of Administrative Hearings case number 87-5604 and Petitioner's case number 82716, should have been included in the previous disposition of Petitioner's case number 76024 and 2) dismissing further proceedings in this cause. DONE AND RECOMMENDED this 7th day of March, 1988, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 7th day of March, 1988. COPIES FURNISHED: Lee Sims, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Michael B. Holden, Esquire Litigation Building, Suite 204 633 South Andrews Avenue Ft. Lauderdale, Florida 33301 William O'Neil General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201

Florida Laws (1) 120.57
# 5
CONSTRUCTION INDUSTRY LICENSING BOARD vs. ROLAND C. RAY, 82-002395 (1982)
Division of Administrative Hearings, Florida Number: 82-002395 Latest Update: Apr. 27, 1983

Findings Of Fact The Respondent is a registered general contractor, having been issued license number RG 0012013. On October 3, 1980, the Respondent, d/b/a Five Ray Enterprises, Inc., entered into a contract with David and Laytha Danley to construct a residence near Brooksville, Florida, for the sum of $61,621.00. This contract was a construction management type of agreement in which the Respondent was to be paid a fee for his services. The Respondent commenced construction, and completed between 85 percent and 95 percent of the project before discontinuing an active role in the work during June of 1981. The Respondent's base of operations was in Winter Park, nearly 100 miles from the construction site, and he was having some personal problems. Therefore, the Respondent agreed with Al Nickola to have Nickola supervise the completion of construction, which involved some painting, grading, finish electrical work and the installation of appliances. The Respondent knew that Al Nickola was unlicensed as a contractor when he entered into the agreement with Nickola to complete the construction. Before he discontinued his work on the project, the Respondent received all the inspections except for the Certificate of Occupancy. His agreement with Nickola was to complete the work which was left and to obtain the Certificate of Occupancy. The Respondent did not properly qualify Five Ray Enterprises, Inc., under which name he contracted to build the residence for the Danleys. On September 9, 1981, the Citrus County Hoard of Examiners revoked the Respondent's license for abandonment of the Danley construction project. However, the minutes of the Board meeting at which this action took place, do not reflect whether or not a full examination was made of all the facts. They simply indicate that the Respondent did not appear at the meeting as requested.

Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Respondent, Roland C. Ray, be found guilty of one violation of Section 489.129(1)(g), Florida Statutes, and one violation of Section 489.119(2) and (3), Florida Statutes, and that he be assessed an administrative fine of $250 on each charge for a total fine of $500. It is further RECOMMENDED that the Respondent be found guilty of violating Section 489.129(1)(i), Florida Statutes, and that his license be suspended until such time as the Respondent has obtained reinstatement of his Citrus County license. And it is further RECOMMENDED that the Respondent be found not guilty of violating Section 489.129(1)(k), Florida Statutes. THIS RECOMMENDED ORDER entered on this 11th day of February, 1983, in Tallahassee, Florida. WILLIAM B. THOMAS, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 11th day of February, 1983. COPIES FURNISHED: John O. Williams, Esquire 547 North Monroe Street Suite 204 Tallahassee, Florida 32301 Roland C. Ray 305 North Pennsylvania Avenue Winter Park, Florida 32789 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 ================================================================= AGENCY FINAL ORDER ================================================================= STATE OF FLORIDA DEPARTMENT OF PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD DEPARTMENT OF PROFESSIONAL REGULATION, Petitioner, DPR Case No. 0018288 DOAH Case No. 82-2395 ROLAND C. RAY RG 0012013 Post Office Box 5877 Orlando, Florida 32855 Respondent. /

Florida Laws (3) 120.57489.119489.129
# 9

Can't find what you're looking for?

Post a free question on our public forum.
Ask a Question
Search for lawyers by practice areas.
Find a Lawyer