Findings Of Fact Respondent is a certified pool contractor, holding license number CP CO27486. Respondent obtained his certificate in October, 1983. His only prior discipline consists of a letter of guidance in late 1989 or early 1990. At all material times, Respondent was qualifying agent for Gold Medallion Pcol, Inc. On March 27, 1986, Respondent and Mr. and Mrs. Don Burson entered into a contract for the construction cf a swimming pool at the Bursons' residence. The Bursons had purchased the residence while it was still under construction in May or June, 1985. The lot was low and had required fill. Clearly visible behind the lot is a large marshy wetland. The contract called for the Bursons to pay $16,315 for the construction of a 20' by 40' concrete lap pool with depths of 3' at either end and 6' in the center. Paragraph 4 of the contract provides: The Owner is responsible for increased costs incurred by the Contractor due to underground conditions which may be encountered during construction, such as but not limited to, muck, inadequate soil-bearing capacity, and excessive ground water. The Contractor, upon encountering such conditions, shall notify the Owner of their existence and give him an approximate cost estimate to rectify the problem. The Owner shall have five (5) days from the receipt of the approximate cost estimate to instruct the Contractor not to proceed with the pool. . . . If the Contractor determines that additional testing is required prior to furnishing approximate costs estimates to determine the exact nature or extent of the underground condition encountered, the Owner shall be responsible for the cost of all testing and/or engineering required by the Contractor. Paragraph 8.D states that the Owner warrants that there [is] no . . . mock . . . in that portion of the owner's property which the contractor will construct the pool [and] decking . . .. The owner is responsible for the removal, repair or replacement of any underground conditions . . . encountered during construction unless he elects to terminate the contract and pay damages to the contractor as set forth in the clause on underground conditions. Paragraph 11.A provides: Contractor warrants to the original owner for the lifetime of the original purchaser, the swimming pool structure, the shell, will not leak due to cracking. . . . This Limited Structural Warranty does not cover damage to the pool shell caused by fluctuations of the water table, construction in the vicinity of the pool site, or natural phenomenon. . . . The contractor's responsibility under this Limited Structural Warranty shall be to repair the shell so that it holds water without cost to the original owner. . . . The method of repair shall be at the discretion of the contractor. THE CONTRACTOR MAKES NO OTHER EXPRESS OR IMPLIED WARRANTIES INCLUDING THE WARRANTY OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE IN REGARDS TO THE POOL STRUCTURE, THE SHELL. Paragraph 11.B.2, which further describes the limited warranty, states: It is anticipated the concrete deck and deck coatings may crack due to settling of deck or weather. Cracks one-quarter inch or less with no substantial deviation in elevation are not covered. . . . The plot plan, which is part of the contract, shows the pool located on the east side of the house. The pool is oriented in a north-south direction. The southern end of the pool runs toward the back of the lot, which is on a steep slope. The southern end of the pool adjoins the widest section of decking, which Respondent constructed at the time of the construction of the pool. The plot plan also shows that excavated dirt was to be placed just south of the decking on the south end of the pool. Shortly after pulling a building permit from the Seminole County Building Department on March 27, 1986, Respondent began construction of the pool. The actual construction was performed by Mid-Florida Pool Company, which is a major pool construction company in Central Florida. Construction was completed on April 23, 1986, and the Bursons paid the amount required under the contract. Prior to commencement of construction of the pool, this area of the Bursons' lot had been filled with about 2 1/2 to 3 feet of dirt. In order to construct the pool, Respondent or his subcontractors added another 2 1/2 to 3 feet of fill, at least to the southern end of site of the pool and decking. It is at this point that the land begins to slope most steeply toward the marsh in the back. Neither Respondent nor any of his subcontractors conducted any soil tests prior to commencing construction or compressed or compacted the soil beneath the pool prior to installing the shell. This omission constitutes a departure from sound contracting practices under the facts cf this case. Respondent constructed several pilasters under the southern end of the deck, but these structural supports were designed to support the deck, not the pool. In general, the depth of the excavation had to exceed the depth of the pool by one foot in order to accommodate the shell. Thus, the extreme southern end of the shell required a hole only about four feet deep. An excavation of this depth did not exceed the combined depth of the old and new fill. There is no indication that Respondent or his subcontractors encountered muck during the excavation or construction of the pool. Likewise, there is no indication that Respondent or any of subcontractors was aware that mucky, unstable soils underlaid the location of the pool, especially the southern end. The pool was completed to the initial satisfaction of the Bursons. However, within 90 days of completion, the southern half of the shell developed five or six major cracks as a result of the settlement of the southern end of the pool. This portion of the pool settled because the underlying muck had been compressed by the weight of the shell and water. Gradually, the water loss from the settlement cracks, which were mostly below the waterline, became significant. At Respondent's suggestion, the Bursons agreed to wait through the winter before commencing repairs in order to allow the cracking to stabilize. In the spring of 1987, the Bursons drained the pool at Respondent's direction. Respondent then scored the cracks with a screwdriver and applied a filling compound in order to seal any leaks. As directed by Respondent, the Bursons then refilled the pool, but before more than two feet of water had been added, the filling compound fell out of the cracks. When the Bursons informed Respondent of the failure of the repair, he responded that he had performed under the contract and had no further obligation. The Bursons exercised their right to arbitrate, as provided in the contract. The arbitrators conducted a limited investigation. Expressly noting that they were not soil engineers and thus could not determine why the soil under the pool failed to support the shell, the arbitrators determined that the contractor was not responsible for any damage to the pool, "which was built to industry standards." The Bursons next contacted various pool contractors about repair options. Most of the contractors suggested a V-cut about 2 1/2 inches deep followed by the injection of hydraulic cement. When the Bursbns informed Respondent that this type of repair appeared necessary, he refused to undertake such work. By this time, one of the contractors documented that five of the cracks, which ranged from 1/16" to 1/4" wide, were pulling water out of the pool at a rate of 1-3" daily. This contractor charged the Bursons $125 for his services. After contacting the Seminole County Building Department, the Bursons learned that the pool had never passed a final inspection. When they had an inspector visit the site on September 13, 1991, he failed the job due to, among ether things, "massive deck cracks." At the insistence of Seminole County officials, the Bursons obtained expert opinions as to the cause of the cracks in preparation for the local hearing on the Bursons' charges against Respondent. In July, 1990, the American Testing Laboratories, Inc. conducted tests and opined that the south end of the pool had settled due to muck at a level of five feet below the bottom of the shell. Additional testing found muck at depths of 3-7 feet at two points just east of the south end of the pool. These tests cost the Bursons $498. When the Seminole County officials insisted upon further testing, the Bursons hired Jammal & Associates, Inc., which performed soil borings on August 23, 1990. The boring sites were just east of a point about midway along the southern half of the pool and a point just south of the southern end of the pool. The latter boring site revealed muck after penetrating about six feet of fill. At the request of Respondent, a Jammal employee returned to the site on November 13, 1990, to determine the potential cause of the cracking of the pool shell and deck. Jammal concluded that the cracking is the result of consolidation of the highly compressible peat layer found in the [southern] boring. Based upon the [cracking] observed, we suspect the southern 1/3 or so of the pool and deck area are underlain by the buried peat layer. The remainder of the pool and deck are most likely underlain by sandy soils. Because of the nature of the buried organic soils, the pool and deck will probably continue to settle at a diminishing rate for several years. Addition of new loads such as placement of additional fill around the pool and deck area, or a significant drop in the groundwater table could cause additional and accelerated settlement of the pool and deck. Jammal offered three repair options. The first was to patch the cracks. Jammal assumed that, although continued cracking could be expected, it would occur at a lesser rate because most of the settlement of the buried muck had already taken place. The second option was to remove the pool and then remove the underlying muck. The third option was to install inside the shell a fiberglass liner. The last option had been first suggested by Respondent. If not rigidly attached to the shell, the liner probably would not reflect further cracking of the shell. The Bursons paid Jammal the sum of $300 for its services. Ultimately, the Bursons decided to install a fiberglass liner and entered into a contract on November 19, 1990, with Fibre Tech for the work. The total cost of the project was $5415. This cost excludes the cost of replacing a pool vacuum for which Respondent does not appear responsible. The liner was later installed, and the Bursons paid the contract price. In the meantime, at a meeting on October 16, 1990, the Seminole County Swimming Pool Contractor's Board revoked Respondent's County certificate of competency until he repaired the pool or made restitution to the owners. This action was based upon a violation of Seminole County Code Section 40.151 and 40.34(2) and (9). Section 40.151 provides that "[a]11 completed pools shall be absolutely watertight." Section 40.34(a) allows the Board to revoke a certificate of competency if the contractor: (2) Continue[s] performance of building work in a negligent, incompetent or unworkmanlike manner. (9) Violate[s] any provision of this Chapter. The determination of the Seminole County Swimming Pool Board became final when Respondent failed to take a timely appeal of the order.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that the Construction Industry Licensing Board enter a final order imposing an administrative fine of $2500 and suspending Respondent's license until he makes restitution to the Bursons in the amount of $6338. ENTERED this 29th day of October, 1991, in Tallahassee, Florida. ROBERT E. MEALE Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of October, 1991. COPIES FURNISHED: Jack McCray, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Daniel O'Brien Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32202 Craig M. Dickinson, Senior Attorney Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Merwin C. Carter, pro se 611 Ensenada Avenue Orlando, FL 32825
Findings Of Fact Respondent is the holder of currently active General Contractor's license No. RG-0023888. On January 18, 1977, Norwood W. Hope (hereinafter "Developer") entered into a contract with Respondent for the construction of a commercial swimming pool. Respondent was to have been paid the amount of $43,346.40 under the contract for construction of the pool. The contract amount was to be paid pursuant to a five-stage draw schedule as follows: 1. Framing and steel draw paid $10,836.60 2. Gunite draw paid 10,836.60 3. Mancite draw 7,224.40 4. Equipment set draw 7,224.40 5. Final approval draw 7,224.40 Respondent made application for an Alachua County building permit for the swimming pool project on February 23, 1977. The permit application was approved on February 25, 1977, and a building permit was issued. Thereafter, the project received Alachua County approval on a temporary power pole inspection on June 1, 1977. An interim inspection of the property was made by Alachua County officials on November 7, 1977, with no deficiencies noted. A final inspection on the electrical work on the project was made, with satisfactory results, on November 8, 1977. The Alachua County Building Code, by incorporation of the 1973 Southern Standard Building Code, 1974 Revision, provides, in part, as follows: 108.2--INSPECTIONS REQUIRED The Building Official shall inspect or cause to be inspected at various intervals all construction or work for which a permit is required, and a final inspection shall be made of every building or structure upon completion, prior to the issuance of the Certificate of Occupancy, as required in Section 109. * * * (c) The Building Official upon notifica- tion from the permit holder or his agent shall make the following inspections of buildings and such other inspections as may be necessary, and shall either approve that portion of the construction as completed or shall notify the permit bolder or his agent wherein the same fails to comply with the law: * * * Final Inspection: To be made after the building is completed and ready for occupancy. (Emphasis added). The contract entered into on January 18, 1977 between the Developer and Respondent called for Respondent to construct the swimming pool according to the plans and specifications admitted into evidence as Petitioner's Exhibit No. 1. Associated construction, including construction of concrete pool decking, a pumphouse and a fence surrounding the swimming pool site were either completed by the Developer or by other sub contractors. By invoice dated October 12, 1977, Respondent requested a final draw on the project in the amount of 87,000, which, if paid, would have left only $224.40 unpaid under the contract. This draw request indicated that a balance due for extra time and materials would be billed ". . . upon acceptance of total pool." (Respondent's Exhibit No. 4). On October 25, 1977, the Developer paid $6,000 of the $7,000 requested to be paid by Respondent's invoice of October 12, 1977. The Developer contested Respondent's expressed intention to bill for additional time and material, asserting that the Developer had not approved any additional sums for extras. In remitting the $6,000 payment to Respondent, the Developer indicated that "[t]his leaves a balance on our account of $1,224.40, which will be paid upon checking out the pool." (Respondent's Exhibit No. 2). (Emphasis added.) An invoice for back charges on the swimming pool project in the amount of $274 was forwarded to the Developer by Respondent by invoice dated November 8, 1977. In addition, on November 8, 1977, Respondent also invoiced the Developer for a final draw on the project in the amount of $1,224.40. At some time after notification from the Developer's representatives that tile targets in the racing lanes of the pool were improperly located, Respondent returned to the job site after November 9, 1977 to relocate the targets. Respondent performed this work as a result of a written request from the Developer dated November 9, 1977. Respondent completed primary construction of the pool prior to submission of the final draw request of October 12, 1977. At that time, back- filling around the exterior of the pool structure preparatory to the pouring of the concrete pool decking had not been completed. Although by October 12, 1977, Respondent had removed much of the excess dirt and debris from around the edges of the pool. There were still areas of exposed piping which would, in due course, be covered with back-fill and tamped by the decking subcontractor. Respondent did not attempt to back-fill or tamp any areas around the pool's piping system. At some time subsequent to October 12, 1977, which date is not clearly reflected in this record, a separate sub- contractor completed back-filling work around the pool, and poured the concrete decking. Neither the Developer nor his subcontractor advised Respondent that the back-filling had been accomplished and that the deck was to be poured. Prior to October 12, 1977, Respondent "pressure tested" the pool's piping system, and determined that the pool would hold water at a level above its scum gutters. The results of this testing indicated that, at least as of October 12, 1977, there was no leakage from the pool. Standard practice in the pool construction industry dictates that a minimum of three pressure tests be made of a pool's piping system during the course of construction. The first of these tests should occur immediately after installation of the pipes, and a second test should be performed immediately before final back-filling to cover the pipe system. A final pressure test should be conducted after tamping of the fill and prior to the pouring of concrete for the pool deck. The obvious purpose of this system of pressure testing is to discover any water leaks before concrete pool decking is poured to avoid having to cut out sections of the concrete in order to locate leaks. Because the Developer and his subcontractor failed to notify Respondent of further work being done on the pool. Respondent was unable to perform a pressure test either after back-filling was completed, after the back- fill had been tamped and before the concrete deck was poured. By letter dated January 17, 1978, Respondent was furnished by the Developer with a "punch list" indicating several areas of deficiency that needed to be corrected in the pool. In that letter the Developer requested that Respondent complete the necessary work within seven days. The Developer forwarded a second letter to Respondent dated February 23, 1978 advising Respondent that the punch list items had not been corrected, and urging Respondent to complete the work described in the punch list as soon as possible. From receipt of the punch list in January of 1978 through the middle of March, 1978 Respondent had workers on the job intermittently making the corrections indicated in the punch list. Respondent satisfactorily corrected fifteen of the eighteen items listed as defective n the punch list. Some of the items were repaired by other subcontractors. Respondent had difficulty obtaining some items of equipment, which he was required to back-order. When the back-ordered equipment was slow in arriving, the Developer opted to obtain these items from a source other than Respondent. Respondent replaced a defective pump associated with the pool construction at some time subsequent to January 18, 1977. The last work performed by Respondent on the pool project occurred some time between March 10 and March 16, 1978. At no time thereafter was Respondent ever advised by the Developer that any work performed under the contract was either unsatisfactory or incomplete. The pool received a final State of Florida, Department of Health and Rehabilitative Services inspection on July 13, 1978, at which time all necessary permits for operation of the pool under applicable regulations were issued. Respondent at no time requested that Alachua County officials come to the job site to conduct the necessary final inspection of the project, nor did he advise the Developer of the necessity to do so. At some time during 1979, subsequent to the completion of the swimming pool project, the Developer discovered that the pool was losing water at a rate of approximately 2,100 gallons per day. During this period, the water level inside the pool would drop to a level equal to the piping running around the exterior of the pool shell and under the pool decking. When the Developer was unable to ascertain the cause of the leak, an outside subcontractor was hired to check the pool. This sub- contractor performed pressure tests on the pool's piping system in an attempt to determine whether the leakage was occurring through the pipes. These tests apparently showed no leakage through the piping system. The Developer then caused the concrete decking around the edge of the pool to be removed in order to more closely inspect the interior piping. At this point it was discovered that there existed flaws and breaks in the neoprene piping surrounding the exterior shell of the pool. After repairs to the damaged piping, the pool decking was repoured and there has been no subsequent leakage problem in the pool. The Developer incurred expenses in the amount of $2,288 in removing the decking around the pool and repairing the neoprene piping. Because of the fact that several subcontractors in addition to Respondent worked in the pool area during construction of the pool project, it is impossible on the basis of this record to determine the cause of the damage to the neoprene piping. Respondent's testimony is uncontroverted that pressure testing performed prior to the conclusion of primary work on the pool in October of 1977 showed no leakage through the pool's piping system. Further, at the conclusion of the primary work in October, 1977, much of the pool's piping system was left exposed and could have been damaged either by the Developer's own workers or by employees of other subcontractors in the course of back- filling and tamping fill material preparatory to pouring concrete decking. The Developer's failure to advise Respondent of the schedule for back-filling, tamping and pouring of concrete deprived Respondent of an opportunity to properly pressure test the piping system at appropriate stages of construction. Respondent has submitted proposed findings of fact for consideration by the Hearing Officer. To the extent that those proposed findings of fact are not incorporated in this Recommended Order, they have been rejected as being either irrelevant to the subject matter of this proceeding or as not having been supported by the evidence.
Findings Of Fact When the third vinyl liner Brenda Hanna had installed in her swimming pool also ripped, she decided concrete would serve better. A friend referred her to respondent Richard Cobb. Mrs. Hanna and Mr. Cobb entered into a written agreement on March 10, 1977, by which Mr. Cobb undertook, among other things, to cement the pool walls and bottom, in exchange for eighteen hundred eighty dollars ($1,880,00). Plumbing was not covered by this agreement. Approximately one month later two workmen began on the project. Work progressed sporadically. Mr. Cobb himself helped remove the vinyl wall, remove aluminum plates, widen the existing excavation and replace the aluminum plates with the intention of using them as part of the forms for pouring the concrete swimming pool walls. Mr. Cobb also put some steel bars in place, After several telephone calls, on October 17, 1977, Mrs. Hanna wrote respondent saying he had 15 days in which to resume work and 45 days thereafter to finish. On or about November 1, 1977, respondent appeared at the job site. The last day he worked on the project Mrs. Hanna told Mr. Cobb she would call him when she had gotten the plumbing finished. Mrs. Hanna never told Mr. Cobb not to finish the work he began for her. On or about March 10, 1977, Mrs. Hanna wrote a check in favor of DLC, a contracting company, in the amount of five hundred dollars ($500.00), which she intended as partial payment under the contract she entered into on March 10, 1977. Two weeks after work began, Mr. Cobb asked Mrs. Hanna for more money, saying that DLC had charged him five hundred dollars ($500.00) for getting the job for him. Mrs. Hanna gave him one hundred dollars ($100.00) at that time, After Mrs. Hanna investigated, she again discussed what had happened to the first five hundred dollars ($500.00) with Mr. Cobb who conceded that some bills were paid with the money. On another occasion, Mrs. Hanna advanced one hundred fifteen dollars ($115.00) which Mr. Cobb used to buy steel. Before beginning work Mr. Cobb, who held individual swimming pool servicing contractor's license No. RP 2997 from March 17, 1977, till June 30, 1977, secured building permit No. 77-338 to repair Mrs. Hanna's swimming pool. John F. Viking, an investigator in petitioner's employ since February 15, 1971, issued a notice of violation to Mr. Cobb in 1971 or 1972, when he was told that Mr. Cobb had been contracting without a license. In 1973, on the basis of similar information, he filed a complaint with the state attorney's office which he understood resulted in Mr. Cobb's conviction and probation. Lester A. Davis, a long time employee of the City of Gainesville and presently its acting building official, visited Mrs. Hanna's residence after Mr. Cobb had begun work and asked Mr. Cobb to show him engineering plans. In Mr. Davis' opinion, the plans Mr. Cobb showed him were not being followed. Mr. Davis told Mr. Cobb that he could finish the job only if he associated a contractor licensed to build swimming pools. Mr. Davis inspected and discovered that the bottom drain had been installed. No other plumbing was required to be done before cementing the pool walls and bottom.
Recommendation Upon consideration of the foregoing, it is RECOMMENDED: That petitioner suspend respondent's license for one year. DONE and ENTERED this 28th day of November, 1978, in Tallahassee, Florida. ROBERT T. BENTON, II Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Michael Egan, Esquire Post Office Box 1386 Tallahassee, Florida 32302 Richard Cobb, Esquire 1238 Southest 18th Terrace Gainesville, Florida 32601 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. CASE NO.: 78-1553 RICHARD COBB, RP 0029977, 1238 S. E. 18th Terrace, Gainesville, Florida 32601, Respondent. /
Findings Of Fact The Respondent Wilbur A. Sellars is licensed as a residential pool contractor by the Construction Industry Licensing Board through license number RP 0045541. Mr. Sellars was first licensed in 1975. At all times material to this case Respondent has owned and operated in Tallahassee, Florida, a pool contracting company called Pro Pools Service and Supply or Pro Pools, Inc. Cabana Construction In November 1977 Respondent entered into a contract with Dr. Frank S. Bilek to construct for him a 20' by 40' vinyl lined pool and a 20' by 40' cabana building. The contract price for the pool was $11,166.10. The price for the cabana was $14,517.30. The pool and building were constructed as provided in the contract. The cabana sits on an 800 square foot slab with footings and consists of three separate rooms. One room is a small bathroom containing a lavatory, water closet, and shower. Another room is fully enclosed by finished walls and sliding glass doors. The third room is open on two sides, one of which faces the swimming pool. The walls are typical stud construction with plywood siding on the exterior and half-inch drywall on the interior. The roof is supported by 2/12 2x4 prefabricated trusses with shingles on top. The ceiling inside the cabana is the same as would be found in a residential home and the floor is a cement slab covered by carpet. There is one overhead ceiling fan in the open room and another in the fully enclosed room. For all practical purposes the construction techniques and materials used in the cabana are the same as would be used in a residential dwelling, although they may not meet the code standards which would be applicable to a dwelling in the Killearn residential area where Dr. Bilek's home is located in Tallahassee, Florida. The cabana is equipped with plumbing for the bathroom and also for a wet bar in the kitchen area of the cabana. No pool accessories were located in the cabana at the time Petitioner's witness inspected the facility, however as with any other structure of its size, pool equipment such as vacuuming hoses, wands, etc., could be placed inside it. The original design for the cabana included large solar panels located on the roof. The purpose of these panels was to provide heating for the swimming pool water. After the panels were installed they malfunctioned and have since been removed from the cabana roof. Typically in home swimming pool installations such panels are placed on house roofs or are independently supported by a special structure located near the swimming pool. The swimming pool water recirculation pump and filter for Dr. Bilek's pool were not located inside the cabana in issue, but were located nearby out in the open. The cabana was not designed for the purpose of housing this equipment. It appears from the furnishings found in the cabana, its orientation with respect to the pool, and from its equipment that the cabana along with the pool coordinate to create a unified entertainment complex. Neither is essential to the other, however. The cabana could host a cocktail party without there being a drop of water in the pool and the pool can function perfectly without the cabana. Criminal Convictions On May 18, 1979 Respondent sent a work crew to Cairo, Georgia, for the construction of a residential swimming pool for Mr. and Mrs. Vanlandingham. The crew was using a dump truck to haul excavated dirt from the pool site to a dumping site several miles from the Vanlandinghams' residence. An inexperienced driver was operating the truck. Upon arrival at the dumping site he engaged the bed lift to dump the dirt but forgot to release the safety chains. As a result the chassis of the truck broke. Members of the crew called Mr. Sellars to give him the bad news. He instructed them to burn the truck, which they did. Respondent then submitted an insurance claim for the loss of his truck due to an accidental fire. As a result of this false claim he was convicted of insurance fraud as defined in Section 817.234(1)(a), Florida Statutes. He entered a guilty plea and judgment was entered on June 7, 1982. On the same date Respondent also pled guilty and was convicted on another count of insurance fraud arising from his filing a false claim for the alleged theft of three mobile radios from trucks operated and owned by Pro Pools Service and Supply. The radios had in fact not been stolen. Since his conviction Mr. Sellars has obtained insurance coverage for the business of Pro Pools including automobile liability, physical damage, general property and general liability insurance.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Construction Industry Licensing Board enter a Final Order finding the Respondent Wilbur A. Sellars guilty of Counts One, Two, Three and Four in the Amended Administrative Complaint and impose discipline in the form of an administrative fine of $200 and suspending Respondent's license as a residential pool contractor for a period of three months. DONE and RECOMMENDED this 23rd day of December, 1983, in Tallahassee, Florida. MICHAEL P. DODSON Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of December, 1983.
Findings Of Fact On December 30, 1975, Collier County adopted Ordinance No. 75-57 which required, among other things, swimming pool contractors to be licensed by the county or state after establishing their competency. Prior to this time swimming pool contractors did not need certificates of competency to construct swimming pools. Anthony Schmidt had been engaged in the manufacture and installation of swimming pools for several years before opening a swimming pool business in Collier County. On April 22, 1976 Schmidt entered into a contract (Exhibit 1) to construct a swimming pool for John Dottore in Naples, Florida. Shortly thereafter Schmidt was issued a violation by an investigator of the FCILB for starting a different pool without a license. Schmidt contacted friends to ascertain who he could get to "pull" the permit needed to construct Dottore's pool, and was subsequently introduced to George C. Moyant, Respondent, a resident of Hollywood, Florida. He was introduced to Moyant at Moyant's house at a meeting arranged by mutual friends. The alleged purpose of this meeting was special tutoring of Schmidt by Moyant to prepare Schmidt for the pool contractor's exam and no other subject was discussed at this meeting. No final arrangements for such tutoring were made. Respondent holds Pool Contractor's License # CP C009205 and General Contractor's License #CG C001828 issued by the FCILB. He is president of Allstate Construction College, Inc. and prepares applicants for the various examinations required for registration with the FCILB. Subsequent to the meeting at Moyant's house Schmidt contacted Moyant regarding Moyant pulling a permit for Schmidt to construct Dottore's pool, and on a subsequent visit by Moyant to Naples Moyant, in company with Schmidt, submitted an Application for Building Permit (Exhibit 4) prepared and signed by Schmidt, showing the contractor to be George C. Moyant, License #CP C009205. At the same time Collier County Permit (Exhibit 5) was issued to Moyant as contractor for the construction of a swimming pool for Dottore. Immediately thereafter, at the Collier County Courthouse parking lot Schmidt gave Moyant a check dated May 4, 1976 in the amount of $500. Moyant's testimony that the payment was an advance for tuition is not credible. Moyant admits that Schmidt called him around the first of May for help in getting a permit for the swimming pool for Dottore and that he, Moyant, was "very reluctant" but assented to come to Naples to help Schmidt out and in fact, pulled the permit. Moyant recognized that his actions were in violation of the laws unless "one does things correctly." He advised Schmidt that his brother or the mutual friend, both of whom have general contractor's licenses would act as his, Moyant's, agent "if any problems come up". Before Schmidt completed the pool an investigator for the FCILB became aware of the circumstances surrounding the issuance of the permit and the investigation and administrative complaint followed.
Findings Of Fact At all times material to the pending Administrative Complaint, Respondent was a registered pool contractor licensed by the State of Florida, having been issued license number RP 0029202. (Petitioner's First Request for Admissions, Item 2: Pet. Exh. C) On or about December 5, 1984, Respondent, d/b/a Miller Pools, contracted with Terry Kilpatrick to construct a pool at the Kilpatrick residence. (Pet. Exh. B; T. 9-10) The contract provided for a contract price of $10,963 for the construction of the pool and $1600 for the installation of fencing. (Pet. Exh. B; T. 10) Under the provisions of the contract and pursuant to the agreement of the parties, Respondent was responsible for all aspects of the pool construction and Kilpatrick was responsible for the installation of the fencing. (Pet. Exh. B; T. 10-11) As part of the contract, Respondent gave Kilpatrick a one-year warranty on the construction of the pool. (T. 19-20) The Kilpatrick residence was located in Putnam County, Florida, within the jurisdiction of the Putnam County Building and Zoning Department. (Pet. Exh. B; T. 37) In December 1984, the 1982 Standard Swimming Pool Code was in effect in Putnam County, having been adopted by county ordinance. (Pet. Exh. E, F; T. 40- 42) The Standard Swimming Pool Code in effect in Putnam County in December 1984 required that a building permit be obtained before the commencement of construction of a swimming pool at a residence in the county. (Pet. Exh. E; T. 42) Respondent obtained the necessary building permit for the Kilpatrick pool job. (Pet. Exh. D; T. 42) The Standard Swimming Pool Code in effect in Putnam County in December 1984 also required that certain inspections be done during the course of the construction of a swimming pool. (Pet. Exh. E; T. 43) Among the required inspections was an electrical inspection and a final inspection. (Pet. Exh. E; T. 44-45) It was the responsibility of Respondent as contractor to request the Putnam County Building and Zoning Department to conduct the necessary inspections of the pool. (Pet. Exh. E; T. 44) The purpose of requiring the various pool inspections, including the electrical and the final, was to make certain that the pool had been constructed and was operating correctly and safely. (T. 45) Respondent was aware that certain inspections were required by local law. On three occasions, December 19, 1984, January 7, 1985 and January 10, 1985, inspections were performed on the Kilpatrick pool at Respondent's request. (Pet. Exh. D; T. 23, 43) Respondent did not make arrangements for the electrical or final inspections to be performed on the Kilpatrick pool. (Pet. Exh. D; T. 23, 43-44) During the construction of the Kilpatrick pool, Respondent was at the job site infrequently. (T. 12-16, 18, 19, 22) Almost immediately after the pool construction was completed, Kilpatrick began to experience problems with the pool, problems which included pitting of the marcite finish, leaks in the tiled area of the pool, and chipping of the brick and coping. (T. 24-35) The problems experienced by Kilpatrick were problems related to the construction of the pool and were covered by the one-year warranty on the pool given to Kilpatrick by Respondent. (T. 19-20) Respondent failed to take any action to correct the problems until after Kilpatrick had contacted the Putnam County Building and Zoning Department and the Department of Professional Regulation to complain about the problems with the pool. (T. 25-28, 35-36, 46-50) As of the date of the hearing in this case, Kilpatrick continued to experience problems with the pool leaking around the tile. (T. 31-31, 34) By Final Order, dated March 17, 1986, in Department of Professional Regulation Case No. 0059028, the Construction Industry Licensing Board imposed an administrative fine of $1000 and suspended Respondent's registered pool contractor's license for five years as a result of Respondent's default in a disciplinary case in which Respondent had been charged with failure to supervise a swimming pool construction project and/or performing said construction in a grossly negligent and/or incompetent manner. (Pet. Exh. C)
Recommendation Having found the Respondent guilty of violating Subsections 489.129(1)(d) and (m), Florida Statutes, it is recommended that Respondent be fined $1000, and that his license be suspended for an additional year after the suspension imposed by the Construction Industry Licensing Board in its Final Order, dated March 17, 1986, in Department of Professional Regulation Case No. 0059028. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 12th day of January, 1987. COPIES FURNISHED: David R. Terry, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Jimmy G. Miller 706 Southeast 35 Avenue Ocala, Florida 32671 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Wings S. Benton, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
Findings Of Fact Brian E. Michaels, the Codes Administrator for Putnam County testified that he regulates the building codes in Putnam County and is in charge with the effective administration thereof. He testified that the pertinent regulations and codes relative to the construction of swimming pools in Putnam County are Ordinances 73-6 and 75-4. (See Petitioner's Exhibits number 2, and number 3, received in evidence). Michaels testified that after seeing an advertisement in the Palatka Daily News on august 6, 1975, his office advised Respondent's office on two occasions to apprise him of certain local laws regulating contractors and the business of contracting. When Respondent failed to respond to approximately three phone calls to its office, Michaels advised Respondent by certified letter dated August 28, 1975, that swimming pool contractors desiring to operate in Putnam County must be locally certified even if they hold state registration. He advised Respondent that if he in fact was state certified that he could send a copy of his certificate for Putnam County official files and to discuss with their office procedures for obtaining a certification in Putnam County. He further advised that the county had adopted the standard swimming pool code, 1974 edition, which requires a plot plan as well as a plan approved before a pool permit could be issued. (See Petitioner's Composite Exhibit number 5). Michaels explained the procedures for complying with the County's certification process which included the filing of an application; taking an exam and receiving a score of at least 70 percent; posting of a $5,000.00 bond; payment of a $50.00 fee which should be included with the application which should also have included a recent photo and the issuance of an occupational license. Additionally, he advised that it was necessary to comply with registration and requirements of the Florida Construction Industry Licensing Board under Chapter 468; Florida Statutes, within 90 days. Michaels testified that Respondent received his certified letter dated August 28, 1975, the following day. (See Petitioner's Composite Exhibit number 5). Section 1020 of Ordinance No. 75-6 of the zone ordinances of Putnam County states in pertinent part that building and related permits issued by the chief building official are required in advance of the construction, erection, demolition, moving, destruction, or alteration of any building or structure with a completed evaluation of $1,000.00. (See Petitioner's Exhibit number 6). On May 27, 1975, the Putnam County Board of County Commissioners enacted Putnam County Ordinance no. 75-4, which ordinance adopted by reference the Southern Standard Swimming Pool Code, 1974 edition, which provided for the adoption of a fee schedule and charges for the issuance of permits to "defray the costs of inspections". (See Petitioner's Exhibit number 7). Jerrell Sparks of Crescent City, testified that he contacted Respondent regarding the construction of a swimming pool during the fall of 1975 following his visit to a building show. On October 21, 1975, Sparks entered into a contract with Terry Michaels, a partner of Respondent, Steve Klapach, d/b/a Starfish Pools for a total price of $5,150.00. At the execution of the contract, Sparks paid Respondent $200.00 and agreed to pay an additional $1,300.00 on November 5, 1975. (See Petitioner's Exhibit number 8, received and made a part herein). Sparks testified that Respondent made the financial arrangements with a mortgage broker in Jacksonville and that Respondent was paid $4,650.00. The construction completed by Respondent consisted of the excavation for the pool and delivery of the pool shell. He testified that he obtained a homeowner's permit but that Respondent did not obtain a permit for the installation of the swimming pool. Tom McConnell of Palatka, testified that he contacted the Respondent regarding a $2,000.00 pool kit which he had seen advertised. He testified that Respondent's partner, Tony Michaels, visited his home on October 14, 1975, at which time he executed a contract for the installation of a pool for a total price of $5,714.00. When the contract was executed, McConnell secured it by an advance payment of $500.00 and he thereafter was never able to contact Respondent. (See Petitioner's Exhibit number 9, received in evidence and made a part hereof). Kenneth L. Rue of Ormond Beach contacted the Respondent based on an ad which appeared in the Sunday supplement of the Daytona Beach News Paper. On August 21, 1975, Rue entered into a contract with Respondent's partner, Tony Michaels and a Mr. Charles Van Dent for the construction of a pool for the total price of $5,200.00. He paid Respondent $500.00 when the contract was executed and paid an additional $4,200.00 when the pool was delivered. He testified that Respondent removed shrubbery and palm trees where the pool was to be positioned and thereafter the excavation and the necessary site preparation was readied. Thereafter the pool was positioned and the plumbing and electrical-fixtures were connected. He testified that the pool did not comply with the specifications as called for in the contract which by its term called for a kidney shaped pool with dimensions of 27' X 13' and a depth of a minimum of 3 and a maximum of 5 feet. He testified that the actual dimensions of the pool installed was 25' x 11' and the depth ranged from 26" to 47". He testified that after the pool was installed it began leaking around the "circulation area" and that when he contacted the Respondent, the pool was removed and Respondent agreed to install any size pool that he desired. The pool called for in the contract was a fiberglass pool however Respondent opted for the installation of a vinyl liner pool. On November 11, 1975, Respondent sent two employees out to make forms for the construction of the pool but since that time, he has had no further contact with Respondent despite repeated attempts. He paid Respondent approximately $4,700.00 of the $5,200.00 contract price and paid another contractor an additional $2,300.00 to complete construction of the swimming pool. (See Petitioner's Composite Exhibit number 10) Brian Michaels was recalled and testified that Respondent never was issued building permits for the McConnell or Sparks projects. The Board introduced into evidence documents showing that Respondent, Steve A. Klapach, RP22049 was registered with the Florida Construction Industry Licensing Board as an active swimming pool contractor during 1975 in the period September, 1975 to December, 1975. (See Petitioner's Exhibit number 1).
Findings Of Fact The Warwick Condominium Association, Inc., operates a swimming pool at its condominium located at 5100 DuPont Boulevard, Fort Lauderdale, Florida. The swimming pool is licensed as a commercial swimming pool, and it has satisfactorily passed the inspections conducted by Respondent over the past two years. The Warwick pool has a perimeter gutter system which meets Respondent's regulations. The Condominium Association plans to renovate the pool. The renovation plans, which must be approved by Respondent, involve changing the pool from the approved gutter system to a recessed automatic surface skimmer system. The pool dimensions are approximately 25' x 46', and the pool surface water area is approximately 1,035 square feet. Respondent's rules prohibit the use of recessed automatic surface skimmers for pools larger than 800 square feet and for pools wider than 20'. Therefore, Petitioner's proposed modifications to the pool do not meet existing rule requirements for commercial pools. The pool renovation plans were not approved by Respondent since the plans do not meet the standards set by the Department's rules. Petitioner submitted its proposed plans to the independent Public Swimming and Bathing Facilities Advisory Review Board, and that Board recommended to the Department that Petitioner's request for a variance from the Department's rules be granted. The Department denied Petitioner's request for a variance. There is no evidence that the Department considered the Advisory Review Board's recommendation to approve a variance, and there is no evidence as to what standards the Department has used in approving variances, if any variances have been approved. The location of the Warwick pool is unique and causes the Warwick to experience extraordinary problems in maintaining the cleanliness of the pool. The Warwick pool is located adjacent to the Intracoastal Waterway and a bascule bridge crossing the Waterway. The pool receives an extraordinary amount of highway soot and dirt due to its location next to the elevated highway and bridge. Additionally, grease and oils from boats idling next to the swimming pool waiting for the bridge to open are deposited on the surface of the Warwick swimming pool. Swimming pools at nearby condominiums are not located directly on the Waterway. They are located either on the roofs of those condominium buildings or on the other side of those buildings away from the Waterway. Accordingly, the location of the Warwick pool is unusual. A prevailing southeast wind blows across the Waterway and across the Warwick pool. It then hits the wall of the condominium building and reverses its direction. It creates a great deal of turbulence on the surface water of the pool, pushing the water and the debris on the surface of the water to the south wall of the pool which is located at the pool's deep end. The dirt, debris, grease, and oil deposited by the vehicular and boat traffic accumulate at, and adhere to, the south wall of the pool at the deep end. Cleaning the tile at the south end of the pool requires constant effort. The accumulation of grease and oil at the deep end of the swimming pool is unusual. The perimeter gutter at the deep end of the Warwick pool is slightly higher than the gutters around the other three sides of the pool. Accordingly, the surface water does not overflow the gutter at the deep end except when there are a number of bathers in the pool, thereby altering the water level and creating additional turbulence. At such times and during heavy rains, the gutters flood, and the debris and grease are carried back into the pool where they come in contact with bathers. There is no guarantee that attempting to lower the level of the south gutter will make the perimeter gutter system ideally level. The condominium manager and one of the condominium owners, each of whom have substantial expertise and experience in constructing and operating swimming pools, have determined that the unique problems of the Warwick pool can be resolved by the installation of recessed automatic surface skimmers at the south end of the pool. All witnesses in this proceeding agree that proper skimmer location is determined by the prevailing wind. The amount of surface water removed is the same for both the perimeter gutter system and the recessed automatic surface skimmer system. The accessibility to debris is greater with a gutter system than with the skimmer system since the skimmer system collects debris and retains it in baskets which are then manually emptied. There are greater losses of water with the gutter system than with the skimmer system. Department employees visited the Warwick pool on one occasion for approximately 45 minutes. They placed the gutter system into operation and found that it was working. They testified that the Warwick's system is operational and therefore should simply be improved. The Warwick's witnesses agreed that the system is operational but have shown that the system does not operate properly based upon their extended familiarity with that particular swimming pool. The opinion of the experts with extended experience with the Warwick pool has been given more weight than those who visited the pool on one occasion for less than-one hour, particularly since the Department's witnesses admitted that the conditions at the Warwick during their site visit were not the normal conditions. Although the Department's witnesses clearly have a preference for gutter systems over recessed skimmer systems, no evidence was offered to show that the skimmer system (allowed by the Department in smaller swimming pools) would pose a threat to the health or safety of the bathing public should a variance be granted.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED THAT: A Final Order be entered approving Petitioner's request for a variance. DONE and RECOMMENDED this 9th day of February, 1989, at Tallahassee, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings, The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this day 9th day of February, 1989. APPENDIX TO RECOMMENDED ORDER D0AH CASE NO. 88-3045 Petitioner's proposed findings of fact numbered 1 4, 5, 7-14, 16, and 17 have been adopted either verbatim or in substance in this Recommended Order. Petitioner's proposed finding of fact numbered 2 has been rejected as being irrelevant to the issues under consideration in this cause. Petitioner's proposed finding of fact numbered 6 has been rejected as being subordinate to the issues under consideration herein. Petitioner's proposed findings of fact numbered 3 and 15 have been rejected as not constituting findings of fact but rather as constituting argument of counsel or conclusions of law. Respondent's proposed findings of fact numbered 1-3 and 9 have been adopted either verbatim or in substance in this Recommended Order. Respondent's proposed findings of fact numbered 4- 6, 10, and 11 have been rejected as not being supported by the weight of the evidence in this cause. Respondent's proposed findings of fact numbered 7 and 8 have been rejected as being contrary to the evidence presented herein. Respondent's proposed finding of fact numbered 12 has been rejected as being irrelevant to the issues under consideration herein. COPIES FURNISHED: Gregory L. Coler, Secretary Department of Health and Rehabilitative Services 1323 Winewood Boulevard Tallahassee, Florida 32399-0700 Sam Power, HRS Clerk Department of Health and Rehabilitative Services 1323 Winewood Boulevard Tallahassee, Florida 32399-0700 Lois J. Minetti, Manager Warwick Condominium Association, Inc. 5100 DuPont Boulevard Fort Lauderdale, Florida 33308 Martha F. Barrera, Esquire Department of Health and Rehabilitative Services 2421 Southwest Sixth Avenue Fort Lauderdale, Florida 33315
Findings Of Fact At all times pertinent to this proceeding, Respondent, Alfred C. Wicht, has been registered as a pool contractor, license numbers RP 0026439 and RP A026439. At all times material herein, Respondent was the qualifier for Heritage Pools, Inc. On or about August 1, 1978, Heritage Pools, Inc. entered into a contract with Pacesetter Homes, Inc. to install a swimming pool at 3530 North 30th Terrace, Hollywood, Florida, for the sum of $5,350.00. Heritage Pools, Inc. commenced construction and completed the pool through the gunite and tile stage and received draw payments totaling approximately $4,295.00. About April or May, 1979, the pool popped out of the ground through no fault of the Respondent. The Respondent made some effort at repairing the pool and placing it back in the ground from the date it popped out through October, 1979. Respondent conceded that he delayed completing his repairs on the pool by virtue of the expense it was causing to his company and his belief that Pacesetter Homes, Inc. should have provided financial assistance. On or about December 5, 1979, Pacesetter Homes, Inc. learned that the pool could not be repaired and hired Electra Pools, Inc. to take out the pool initially installed by Respondent, and install a new pool in its place.
Recommendation From the foregoing, it is RECOMMENDED: That Petitioner enter its Final Order dismissing the charges contained in the Administrative Complaint. DONE and ENTERED this 27th day of May, 1983, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of May, 1983. COPIES FURNISHED: Michael Cohen, Esquire Suite 101, Kristin Bldg. 2715 E. Oakland Park Blvd. Ft. Lauderdale, Florida 33306 Alfred C. Wicht 6701 Cypress Rd., #108 Plantation, Florida 33317 James Linnan, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
