The Issue The issue presented for decision herein is whether or not the Respondent, Department of Environmental Regulation (DER), should issue a permit to Respondent, Robert Peterson, to construct a 0.007 MGD wastewater treatment facility with effluent disposal to Dual Class V injection wells in Key Largo, Monroe County, Florida.
Findings Of Fact On January 17, 1986, Robert Peterson, doing business as Peterson's Condominiums, submitted an application to the Florida Department of Environmental Regulation (DER) to construct a 0.007 MGD wastewater treatment plant with effluent disposal to Dual Class V injection wells into G-III groundwater. The proposed site is located at Mile Marker 95.6, U.S. Highway 1, Key Largo, Florida. The sewage treatment plant is to serve a ten unit condominium with provisions for four future units. The designed population to be served is 62. (Permit Application) The Plant is designed to treat the sewage so that after treatment and disinfection, the effluent will, on average contain no more than 20 parts per million biological oxygen demand (BOD-5 day) and 20 parts per million of total suspended solids (TSS). There will be 90 percent removal of these pollutants after treatment. The effluent will be disinfected in a chlorine contact chamber, with chlorine tablets used as the disinfectant. Sludge will be removed by a licensed scavenger truck to Monroe County approved disposal sites. Noise from the plant will be controlled by a blower filter, silencers, and a weather proof hood. (Permit Application). No control is contemplated for odor or aerosol drift other than proper plant operation. No lighting will be provided at the plant. Emergency power `from a rental portable generator will be used if there is an extended power failure. Along with the sewage treatment application, Respondent Peterson also submitted two permit applications for injection of the treated effluent into 2 Class V injection wells. The total volume of treated effluent that would enter into both wells combined is 6500 gallons per day. The 6 inch diameter wells would be 65 feet deep with casing and grout down to a depth of 30 feet. Upon receipt of the permit applications, DER reviewed the application and requested an additional application including groundwater samples measuring total dissolved solids. Peterson submitted two samples, both indicating total dissolved solids significantly greater than 10,000 milligrams per liter. (DER's Exhibits 2, 3 and 4). The samples (TDS) were taken approximately 1 and 6 miles from the proposed site. Based on DER's staff review of hundreds of groundwater quality analyses from the Keys, DER's staff determined that the samples submitted were consistent with other groundwater TDS levels throughout the Keys. (Testimony of Barrone and Me1e). Use of the samples by DER was reasonable and proper. Groundwater in which the TDS is greater than 10,000 milligrams per liter (parts per millions) is classified as G-III groundwater. Such water is considered non-potable. (Testimony of Barrone and Mele; Florida Administrative Code, Rule 17-3.403(1)). After review of the application, DER issued an "intent to issue" Peterson the permits requested on March 5, 1986. (DER's Exhibit 7). The "intent to issue" as drafted by DER established certain conditions to monitor water quality and to test treated effluent before it is discharged to Class V wells. As an example, flow, pH, and chlorine residuals are to be sampled daily; BOD and total suspended solids are to be sampled monthly and fecal coliform is to be sampled once per quarter. Test results are to be submitted to DER on a monthly basis and the analysis program is conditioned to demonstrate substantial compliance with water quality standards as set forth in pertinent sections of the Florida Administrative Code. Provided the monthly reports reveal violation of DER's standards, the permittee will be required to rectify the problems. (DER's Exhibit 7, testimony of Barrone and Mele). Additionally, DER has conditioned its intent to issue on a trial or experimental basis and this project will again be subjected to review in one year. (DER's Exhibit 7, condition 12). Should the permittee fails to bring the facility into full compliance within the one year period, an operational permit will not be issued. DER imposed this condition on the subject wastewater treatment plant, based on the fact that it is a new model and DER does not have extensive experience with the monitoring of this type plant. (Testimony of Barrone and Mele). Evidence introduced reveals that the plant manufacturer, Smith and Loveless, is the largest manufacturer of factory built water and wastewater pump stations and treatment plants. The manufacturer pioneered prefabricated treatment plants with over 30 years experience. Evidence reveals that there are at least three plants in operation in Florida without any operational problems. Upon "issuing the intent to issue", DER directed the permit applicant (Peterson) to publish notice in the Key West Citizen (Peterson's Exhibit 1). Notice of this proposed agency action was published in the Key West Citizen on March 17, 1986, giving any substantially affected party 14 days from that date to file a petition for administrative proceedings with DER's Office of General Counsel. (Petitioner's Exhibit 2). On March 26, 1986, DER received a letter from Petitioner McInerny, Popp and other local citizens (C.C. Waggle) protesting the proposed project. The Objectors indicated that they had heard that the proposed agency action was advertised in the Key West Citizen but that the Key West Citizen was not available in their area. 1/ Based on these protest letters, DER afforded Objectors, including Petitioners, a new point of entry into these proceedings. Petitioners Ohi, Popp and McInery timely petitioned for an administrative hearing challenging the proposed agency action. The challenges by Petitioners, based on DER's second point of entry, were timely filed. When the proposed facility becomes operational, it will not cause foul odors or create a nuisance due to aerosol drift based on the design features. (Testimony of Barrone, Mele and Sikorski. The extended aeration facility, as proposed, is the most reliable type of sewage treatment plant for this type operation. (Testimony of Mele). The expected pollutants produced from domestic sewage are BOD, dissolved solids and to a lesser extent heavy metals, nitrates, phosphorus and bacteria. (Testimony of Mele). After treatment, the effluent from this facility is not expected to be either toxic or carcinogenic. (Testimony of Mele). The Class V wells into which the treated effluent would be placed are approximately 500 feet from the nearest shoreline, the Atlantic Ocean. This is the closest distance to any Outstanding Florida Water. As such, the treated effluent will be diluted prior to its discharge into the Atlantic Ocean. (Permit Application, Testimony of Mele). Respondent Peterson has provided Respondent DER reasonable assurances that the proposed facility, upon operation, will not violate the Department's rules relating to air, noise and water quality standards.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That Respondent, Department of Environmental Regulation enter a Final Order issuing Respondent, Robert Peterson, doing business as Peterson's Condominiums, a permit to construct a 0.007 MGD wastewater treatment plant with effluent disposal to Dual Class V injection wells with the conditions as set forth in the DER's "intent to issue" dated March 5, 1986. RECOMMENDED this 1st day of December 1986 in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 1st day of December 1986.
Findings Of Fact The Petitioner is a special tax district created by special act of the Florida Legislature. Chapter 71-822, Laws of Florida. The district covers approximately seventy-two square miles in northern Palm Beach County and southern Martin County, Florida. Petitioner's purpose is to provide water, sewer, drainage and solid waste services within the district. In conformity with its powers, the Petitioner operates an advanced waste water treatment plant on property which it owns in northern Palm Beach County. Petitioner has secured appropriate permits from DER in order to construct and operate the treatment plant. The treatment plant is among the most advanced in southeastern Florida. It has a four million gallon daily capacity, which could be increased to an eight million gallon capacity. In treating waste water the plant utilizes filtration, disinfection, retention in a holding pond, and discharge into a remote off-site area. The present discharge system is to pump effluent from the retaining pond through a canal or drainage system to a recharge or discharge lake which is located approximately three miles north and west of the treatment plant. This is known as the western discharge system, and was installed at a cost of approximately one million dollars. Due to the large amounts of pumping activity, it is an expensive system to utilize. Through its instant application, the Petitioner is seeking a permit allowing it to discharge effluent on-site. Effluent would flow into percolation ponds that have already been constructed. Effluent would settle in the ponds, and eventually would percolate through the soil. This system would he less expensive to operate than the western discharge system. Petitioner is interested in experimenting with the amount of waste water treatment that can be obtained through action of vegetation in the percolation ponds upon the effluent. Such a natural system, if it operated effectively, could save the Petitioner additional money in treating waste water by reducing the need for chemical treatment. Petitioner's waste water treatment presently results in a discharge of effluent which within some parameters meets even drinking water standards. The Petitioner's system very effectively treats bio-chemical oxygen demand ("bod"), suspended solids, nitrogen, and phosphorus in the effluent. Reports have been submitted by the Petitioner to DER which indicate that the system does not meet DER's standards for advanced waste water treatment. Samples upon which these reports were based were taken at a point in the system before the effluent was subjected to the action of the retention pond and the subsequent bumping into the western discharge system. Samples taken beyond the retention pond indicate that DER's standards are met for "bed", suspended solids, total nitrogen, and total phosphorus. The Intervenor owns property adjacent to the Petitioner's waste water treatment plant. The Intervenor operates a well field and drinking water treatment plant on the property, and provides drinking water to residents of the Town of Jupiter and surrounding communities from the well field. The Intervenor acquired its treatment plant, and surrounding well fields from a private utility company. The Petitioner was aware of the well field when it purchased the property upon which it presently operates its waste water treatment plant. While the Petitioner's plant adequately treats waste water in terms of "bod", suspended solids, total nitrogen, and total phosphorus it does not treat the waste water for heavy metals, pesticides, or viruses. These are common elements found in waste water effluent in the south Florida area. The Petitioner's proposal is to discharge its effluent into on-site ponds. The effluent would then percolate into the ground. The retention ponds are located at a distance from 1200 to 1600 feet from the nearest of the Intervenor's wells. Water which percolates from these ponds would flow directly toward the wells, and would eventually find its way into the wells. The flow from the retention ponds to the wells would be increased due to the draw-down effect that the wells have on the surrounding water table. As water is drawn from the wells, the adjoining water table becomes depressed in the area of the wells, and water from the surrounding area flows more rapidly into the area of the wells. Heavy metals will not be filtered out as a result of retention or percolation. Heavy metals in the effluent would eventually find their way into the Intervenor's well fields. Estimates as to the amount of time that it would take for water from the percolation ponds to reach the wells varied from four months to six years. The longer estimate appears the more reasonable; however, the evidence is conclusive that eventually waters from the percolation ponds would reach the wells, and that heavy metals in the water would not be filtered out. The Petitioner proposes to obviate any problems with heavy metals reaching the well fields by operating testing wells between the percolation ponds and the well fields. If any heavy metals were detected in the ground water, Petitioner would again use the western discharge system rather than the percolation ponds. While this would prevent increased contamination of the wells, contamination that had already reached the test wells would reach the Intervenor's wells. It was suggested that the percolation ponds could be drawn down in order to reverse the flow of ground water back into the percolation ponds, thence to be pumped through the western discharge system. In order to accomplish this, however, the percolation ponds would have to be more than forty feet deep, which they are not. The effect of heavy metals intruding into the Intervenor's water supply could be to increase the cost of treatment, or to render the wells unfit for use. Uncontaminated drinking water supplies are rare in the northern Palm Beach County area, and the expense of finding a new water supply is difficult to calculate.
The Issue The issue in this case is whether the Petitioner has the actual experience required for certification as a Class B domestic wastewater treatment plant operator.
Findings Of Fact By application filed September 16, 1991, James H. Redden applied for certification as a Class B domestic wastewater treatment plant operator. At the time of the application, Mr. Redden was employed as a laboratory technician at a Class B Collier County regional wastewater treatment facility. From August 15, 1978, to July 31, 1989, Mr. Redden was employed at the Colgate-Palmolive Company facility at Jeffersonville, Indiana. The Colgate-Palmolive treatment facility is an Indiana Class D industrial wastewater treatment plant. Mr. Redden is certified by the State of Indiana as a Class D industrial wastewater treatment plant operator. During his employment at the Jeffersonville facility, Mr. Redden held positions as an associate chemist, senior chemist/plant microbiologist, and wastewater treatment plant supervisor. His duties included daily operations and supervision of personnel, scheduling and performance of maintenance activities, budgeting, ordering, materials balance, sludge management, laboratory analysis, quality assurance and quality control programs, and compliance with various state and federal reporting requirements. Mr. Redden has no experience either in the operation of a drinking water or domestic wastewater treatment plant, or at a DER-permitted industrial wastewater treatment plant.
Recommendation Based on the foregoing, it is hereby: RECOMMENDED that the Department of Environmental Regulation enter a Final Order denying the application of James H. Redden for certification as a Class B wastewater treatment plant operator. DONE and RECOMMENDED this 9th day of April, 1992, in Tallahassee, Florida. WILLIAM F. QUATTLEBAUM Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 9th day of April, 1992. APPENDIX The following constitute rulings on proposed findings of facts submitted by the parties. Petitioner: The Petitioner did not file a proposed recommended order. Respondent: The Respondent's proposed findings of fact are accepted as modified and incorporated in the Recommended Order except as follows: 2-4. Rejected, unnecessary. COPIES FURNISHED: Carol Browner, Secretary Dept. of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32399-2400 Daniel H. Thompson, General Counsel Dept. of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32399-2400 James H. Redden 1362 Chesapeake, Avenue Naples, Florida 33962 Francine M. Ffolkes, Esq. Assistant General Counsel 2600 Blair Stone Road Tallahassee, Florida 32399
Findings Of Fact During 1990, Respondent/Applicant, City of Lynn Haven, filed several applications with the Respondent, Department of Environmental Regulation, seeking the issuance of several permits to build a wastewater collection system and a two million gallon per day advanced wastewater treatment (AWT) plant. The proposed facility is intended to replace the wastewater treatment facility currently being used by the City of Lynn Haven. After a review of the applications the Department proposed several Intents to Issue covering the different aspects of the proposed projects. The Intents to Issue included: A) a variance and dredge and fill permit, pursuant to Sections 403.201, 403.918, 403.919, Florida Statutes, and Rule 17-312, Florida Administrative Code, authorizing a subaqueous crossing of North Bay (Class II waters) and installation of a force main (permit #031716641), B) a collection system permit, pursuant to Chapter 403, Florida Statutes, and Rules 17-4, 17-600 and 17-604, Florida Administrative Code, for the installation of approximately 11 miles of pipe from North Bay to the proposed treatment plant, C) a dredge and fill permit #031785181, pursuant to Sections 403.918, 403.919, Florida Statutes, and Rules 17-4, 17-312, Florida Administrative Code, authorizing 10 incidental wetland crossings associated with the collection system, and, D) a construction permit #DC03-178814, pursuant to Chapter 403, Florida Statutes, and Rules 17-4, 17-302, 17-600 and 17-611, Florida Administrative Code, authorizing the construction of a 2.0 mgd wastewater treatment plant. Sand Hill Community Improvement Association challenged the Department's Intents to Issue. The Sand Hill Community Improvement Association (Sand Hill) is an association composed of 74 formal members plus numerous supporters. Both members and supporters are residents who live near the site of the proposed Lynn Haven sewage treatment plant. They are sufficiently close to the plant site that construction of the proposed project could impact their property. The members are very concerned about any threat of pollution to the aquifer from the proposed plant since all of the members are dependent on private wells for their drinking water. Additionally, members of the association use the proposed site, as well as the associated wetlands, Burnt Mill Creek and the nearby lakes, for a variety of recreational purposes, including hunting, fishing, hiking, bird-watching, boating and swimming. Given these facts, the Association has standing to challenge the Department's Intents to Issue involved in this case. The City of Lynn Haven is located on a peninsular section of the south shore of North Bay and, except for its connection to the land, is surrounded by environmentally sensitive Class II or Class I waters. Lynn Haven's existing wastewater treatment plant was poorly designed, has not worked properly, and is old and outdated. The plant is permitted to treat up to 950,000 gallons per day. However, the existing plant is currently exceeding its originally permitted treatment limits and is treating in excess of 1,200,000 gallons per day. The sewage only receives secondary treatment, Secondary treatment is the minimum state standard for wastewater treatment. The secondarily treated wastewater is pumped several miles to a spray irrigation site located in the eastern portion of the City. The sprayfield site has never worked properly due to a high groundwater table and a confining layer of soil, both of which prevent the effluent from percolating into the ground. Because the sewage effluent cannot percolate into the ground, the existing operation frequently results in direct runoff into a ditch which empties into North Bay, a Class II waterbody. Such discharge of wastewater effluent into Class II waters is prohibited by Department regulations. 1/ At this time, the existing wastewater treatment facility is in violation of both DER and EPA standards and is under enforcement action by both agencies. The existing facility is currently operating without a permit and the Department has advised Lynn Haven that the existing facility as it now operates can not be permitted. In fact, all the parties agree that the City is in serious need of a wastewater treatment facility which works and does not pollute the environment. However, the parties disagree over the method by which proper wastewater treatment could be accomplished by Lynn Haven. Since 1972, the City, through various consultants and with the aid of DER, has reviewed approximately 40 alternatives for wastewater disposal. After this review, the City of Lynn Haven selected the alternative which is the subject of this administrative hearing. The alternative selected by the City of Lynn Haven consists of the construction of a proposed advanced wastewater treatment (AWT) plant and distribution system. The new plant will be on a 640 acre parcel of property located approximately 12 miles north of Lynn Haven. The location of the new plant will necessitate the rerouting of the wastewater from the old plant to the new plant by construction of a new transmission line approximately 12 miles north of the City across North Bay and parallel along State Road 77. 2/ The treatment process proposed for use in the new AWT plant is known as the AO2 process. The process is patented. The AO2 treatment process primarily consists of biological treatment with settling and filtration. The treatment process also includes a chemical backup treatment to further reduce phosphorus if necessary. The evidence demonstrated that this type of facility has been permitted by the Department in at least five other wastewater facilities throughout the state. The treatment facility will have a two million gallon per day, lined holding pond on site for the purposes of holding improperly treated wastewater for recirculation through the proposed facility. Any excess sludge generated by this treatment process would be routed to lined, vacuum-assisted, sludge drying beds. The sludge would then be transported offsite to a permitted landfill for disposal. The evidence demonstrated that this treatment process would not produce any objectionable odors. Once the wastewater is treated, it will be disinfected by chlorination to eliminate pathogens. The chlorination process is expected to meet state standards. After chlorination, a dechlorination process would occur to remove any chlorine residuals which would have a harmful affect on the environment. The treated wastewater would then be re-aerated and discharged through the distribution system indirectly into a wetland located on the 640 acre parcel of property. The quality of the treated wastewater is expected to meet the advanced wastewater treatment (AWT) standards. These standards are five milligrams per liter total suspended solids (T.S.S.), five milligrams per liter BOD, three milligrams per liter nitrogen (N), one milligram per liter phophorus (P). Ph will be in the range of six to eight units on an average annual basis and can be adjusted up or down if necessary to meet the ph levels of the ecology into which the wastewater ultimately flows. This effluent quality is approximately five times cleaner than secondarily treated effluent. Additionally, as a condition of the draft permit, the proposed facility would be operated by a state-licensed operator and would be routinely monitored to insure that the treated wastewater effluent meets advanced wastewater treatment standards. Given these facts, the evidence demonstrated that the applicant has supplied reasonable assurances that the plant will perform as represented and that the effluent will meet the state standards for advanced wastewater treatment. As indicated earlier, the site for the proposed AWT plant contains approximately 640 acres and is located approximately 12 miles north of Lynn Haven in an area known locally as the Sand Hills. The City specifically purchased this parcel of property for the construction of the proposed wastewater treatment plant. The plant itself would be located in the northeast corner of the property. The 640 acre site was previously used for silviculture. The entire area is currently planted in pines except for a low area that is dominated by a pristine, woody wetland system of titi. The titi wetland is approximately 212 acres in size and generally runs through the center of the property from the northeast to the southwest. The wetland is low in acidity, with an estimated ph between 4 and 5. The site consists of hilly, mineralized soils. The soils within the forested wetland are organic in nature. Based on the evidence at the hearing, there does not appear to be any significant confining layers of soil which would prevent the treated wastewater from percolating in the soils and draining towards the wetland and ultimately into Burnt Mill Creek, a Class III waterbody. Once the effluent leaves the plant, it would go through a distribution system. The proposed distribution system will consist of six, 500 foot long, 12 inch diameter perforated pipes. Each 500 foot section of pipe has 100 one and one-half inch orifices which will discharge the treated effluent onto an eight foot wide concrete pad. This concrete pad will dissipate the effluent's energy, prevent erosion at the orifice site and insure that the effluent sheetflows onto and eventually into the sandy soils of the plant site and ultimately into the receiving wetland. The distribution pipes are located around the east, north and western portions of the receiving wetland and are variously set back from the receiving wetland approximately 80 to 200 feet. The distribution system is designed with valves to allow for routing of flow to different branches of the system if it is determined through long term monitoring that there is a need to allow for any of the receiving wetland to dry out. None of the distribution branches are located in any jurisdictional wetlands of the State of Florida. The receiving wetland will receive a hydraulic loading rate of approximately 1.8 inches per week once the new advanced wastewater treatment plant is operating at capacity. Both the surface waters and groundwaters on the 640 acre parcel flow from northeast to southwest across the property. The evidence clearly demonstrated that any treated wastewater discharged on the site would move down hill by surface or groundwater flows towards the wetlands in the central portion of the property and eventually discharge into Burnt Mill Creek located at the southwest corner of the parcel. The evidence demonstrated that it would be highly unlikely for the surface or groundwater to move in any other direction and would be unlikely for the surface or groundwater to move towards any residents located to the north or east of this parcel. Evidence of the topography and its relatively sharp gradient clearly demonstrated that the treated wastewater discharged in the northeast corner of this site would not result in any significant still water ponding and would exit the site at the southwest corner of the property in approximately 14 hours. The evidence did demonstrate that, depending on the wetness of the weather, there may likely be certain times of the year when a flowing type of ponding would occur. However, this wet weather ponding was not shown to be of a duration which would impact to a significant degree on the flora and fauna of the area or increase the number of disease bearing mosquitoes in the area. As indicated earlier the treated effluent from the proposed AWT plant will flow into Burnt Mill Creek. Burnt Mill Creek will ultimately carry the treated wastewater approximately 11 miles down stream to North Bay. The City can directly discharge up to two million gallons per day of AWT water into Burnt Mill Creek without violating state water quality standards. Therefore, the volume of wastewater discharged into Burnt Mill Creek should not have significant impacts on surface and ground water quality. Moreover, Chapter 17-611, Florida Administrative Code, authorizes the discharge of up to 2 inches per week to receiving wetlands provided wastewater is treated to AWT standards. The evidence demonstrated that this rule was developed as an experimental effort to determine if wetlands could be appropriate areas for wastewater effluent to be either discharged or treated. These state limits were intended to be very conservative limits and were designed to insure that the impacts to receiving wetlands would be minimal. The evidence and testimony demonstrated that the receiving wetland system involved in this case should not be adversely impacted beyond those limits set forth in Section 17-611.500, Florida Administrative Code, for flora, fauna, macroinvertebrates, fish or vegetation and will meet all standards set forth in Chapter 17-611, Florida Administrative Code. However, it should be noted that the wetland/wastewater program is highly experimental and very little is known about the actual impacts of wetland/wastewater systems since facilities similar to the one proposed by Lynn Haven have not yet been placed in service. The evidence did show that there would be some long term impacts to flora and fauna in the wetland area primarily due to ponding, changed ph and the introduction of nutrients and pollution in the form of the effluent. However, the regulation does allow for some change within a receiving wetland and the evidence did not demonstrate that these changes would be significant or detrimental. Petitioners' own witness concluded that other deep wetland treatment systems are doing a very good job in meeting state water quality standards. Although Petitioners' expert noted potentially adverse impacts to flora and fauna from other wastewater treatment systems, these other systems were slow moving, impoundment-type systems that are not similar to the wastewater/wetlands system proposed by the City of Lynn Haven. The Lynn Haven system is designed for percolation and sheetflow, not ponding. Though there should be some expected changes, no evidence was provided that the receiving wetlands for the Lynn Haven facility would be affected to the extent there would be violations of any standard as set forth in Chapter 17-611, Florida Administrative Code. In essence, the legislature has determined that such experimentation with wetland areas is appropriate, albeit, even with the conservative limits of DER's rule, may prove to be a mistake. This facility is designed to fit within that rule and in fact is probably the best technology available for use in a wetland/wastewater situation. Finally, in order to avoid any potential impacts on the area which may over time become significant an approved monitoring program for surface water quality and affects on flora and fauna, as well as a groundwater monitoring program are required as conditions of the permit. The groundwater monitoring program has been designed to monitor any potential long term impacts to groundwater. With these protections there should not be any significant adverse impacts to surface or groundwater quality and the applicant is entitled to a construction permit for the AWT plant and distribution system. Lynn Haven's sewage would reach the proposed AWT plant through a transmission line. The transmission line would run from Lynn Haven's existing wastewater treatment plant across North Bay and through the unincorporated area of South Port. The Southport area is not sewered and utilizes individual septic tanks for its sewage. The transmission line would be constructed entirely in state road right-of-way. The line would terminate at the 640 acre site described above. A new, variable speed pumping station would be constructed adjacent to the old wastewater treatment plant. From this pump station, a 24 inch line would be constructed on City right-of-way up to the south shore of North Bay. At this point, the transmission line would be reduced in size to 20 inches and would be embedded approximately three feet below the Bay bottom. An additional variable speed pumping station would be located approximately half way along the 12 mile route of the transmission line to insure adequate pressure to pump wastewater to the new wastewater treatment plant. The pumps are to be employed to insure that the wastewater is continuously pumped uphill to the new site so that waste does not set, become septic, and create odor problems. The pumps are equipped to provide for chemical control of odor if necessary. Also, as a condition of the permit, the pumping stations are required to have backup power supplies should power be lost to the stations. The pumping stations and backup power supplies are to be tested monthly and the pumps are required to be continuously monitored by radio telemetry to insure they are operating properly. Additionally, the City of Lynn Haven will be required, as a condition of the permit, to visually inspect the entire length of the wastewater transmission line three times per day. The portion of the transmission line which would cross North Bay is approximately 3000 feet in length and would be constructed of high density polyethylene pipe (HDPE) with a wall thickness of one and one-half inches. HDPE pipe is used to transport materials such as hazardous wastes where leakage is not permissible. This type of pipe is virtually inert in that it is highly resistant to corrosion and other chemical reactions. It is also impact resistant and has a very high tensile strength. The pipe comes in 40 foot segments and is heat welded (fused) together. This type of joint significantly reduces the chance of any leakage. In fact, leakage around pipe joints is more likely to occur with other types of pipe and pipe connections. HDPE pipe is currently carrying wastewater across Watson Bayou in Bay County, Florida. 3/ There have been no reported problems with leaks or breaks occurring in the pipe crossing Watson Bayou. Given these facts, the probability of the proposed HDPE pipe leaking or breaking is extremely low, albeit not impossible, and such pipe appears to be the best material available for constructing a wastewater treatment transmission line across protected waters of the State. As a condition of the construction permit, the portion of the transmission line crossing North Bay will be required to have isolation valves at each end so that the pipe may be completely isolated in the event that it needs repair. The underwater portion of the line would be visually inspected by a diver twice per year and the line would be pressure tested before being placed into service. Additionally, pressure tests would be performed once a year. The construction permit also requires Lynn Haven to periodically inject dye into the proposed transmission line to check for any small leaks that may not otherwise be detected. Finally, the HDPE pipe would also be equipped so that television cameras could be inserted into the pipe to routinely inspect the interior of the pipe. In the event the HDPE portion of the transmission line would need to be repaired, the line could be immediately, temporarily repaired by a dresser coupling. A permanent repair could then be made in less than 24 hours once the material and equipment were staged at the site. The City intends to locally stockpile all necessary parts and equipment to effect any required repair to prevent any delay beyond four days. Permanent repairs would be accomplished by floating the line to the surface. The area needing repair would be cut out and a new section would be put in place by heat fusion. The line would then be pressure tested to insure the absence of leaks and placed back into service. During this process, the line would be taken out of service by the isolation valves and flow would be diverted to the eight million gallon holding ponds at the City of Lynn Haven's existing facility. These holding ponds can hold four days worth of wastewater from the City of Lynn Haven. Lynn Haven is required, as a condition of the construction permit, to have this reserve capacity as well as have a contractor on standby to make any repairs in the event such repairs are necessary. All of the technical specifications for the transmission system and the operating conditions imposed on it are designed to insure that the system does not fail or develop any leaks which could impact receiving waters, including North Bay. Given the permit conditions, the required inspections for leaks, the sound engineering design and quick repair methods proposed, the evidence demonstrated that the probability of any leak occurring in the portion of the transmission line crossing North Bay is extremely low and that if such a leak does occur any potential harm to the environment will likely be limited and quickly eliminated. The evidence demonstrated that the design of the transmission line and permit conditions provide reasonable assurances that the transmission line will meet or exceed the Department standards set forth in Chapter 17-604, Florida Administrative Code. Therefore, the applicant has provided reasonable assurances that the transmission line/collection system will not violate Department standards or rules and the applicant is entitled to a permit (permit #CS03-178910) for the proposed collection system. In addition to requiring a construction permit/collection system permit for the wastewater transmission line, the line will also require dredge and fill permits and a variance for crossing waters of the state. There are ten incidental crossings of state waters and one major crossing o f North Bay. Of the ten incidental crossings, two are over small creeks (Scurlock and Little Burnt Mill) These two incidental creek crossings will be accomplished by placing the transmission line (ductile iron pipe) on top of pilings placed in the water. Best management practices such as turbidity curtains and other erosion control practices are proposed and required by the permit to minimize construction impacts on water quality. The only impacts to wetland resources would be from the placement of the pilings. The evidence demonstrated that any impact would be minimal and not significant. The evidence did not demonstrate that the aerial crossings would have any long term water quality or environmental impacts. The remaining eight incidental crossings of waters of the state consist of small, seasonally wet ditches which would be traversed by trenching and burying the transmission line. Again, turbidity controls such as curtains and hay bales would be employed to protect water quality. The evidence did not demonstrate that any significant long term or short term impacts to resources of the state would occur. The evidence did demonstrate that the applicant has provided reasonable assurances that water quality standards would not be violated in regards to these 10 incidental water crossings. Likewise, the evidence demonstrated that the construction of these 10 incidental water crossings would not be contrary to the public interest. Therefore, the applicant is entitled to issuance of a dredge and fill permit (permit #031785181) for these 10 water crossing. However, a much harder question arises in relation to the dredge and fill permit and the variance required for the 3,000 foot segment of the wastewater transmission line which crosses North Bay. Pursuant to Rule 17- 312.080(7), Florida Administrative Code, permits for dredging and filling activity directly in Class II waters which are approved for shellfish harvesting by the Department of Natural Resources (DNR) shall not be issued. The reason for the rule is that any pollution caused by dredging and filling and, as in this case, the permanent placement of a sewage pipe in food producing waters could potentially have catastrophic effects on more than just the environment but on local employment in the shellfish industry and the quality of food available to the State. Put simply, the Department has determined by enacting its Rule that the public interest in food producing waters far outweighs any other consideration or criteria under Sections 403.918 and 403.919, Florida Statutes, in determining whether dredging and filling should take place in Class II, shellfish waters. In other words, it is not in the best interest of the public to allow dredging and filling so that a pipe carrying raw sewage can be placed in shellfishing waters. However, irrespective of this determination, the Department believes that, pursuant to Section 403.201(1)(c), Florida Statutes, it may grant a variance from its rules to relieve a hardship. As indicated earlier, North Bay is a Class II waterbody, conditionally approved for shellfishing. North Bay, therefore, falls within the Rule's prohibition against dredging and filling in Class II waters and the City is required to demonstrate the presence of a hardship in order to vary the Rule prohibition and obtain a dredge and fill permit for the North Bay crossing. On issues involving variances, the Department employs a two step analysis. The first part of the analysis is whether a hardship is present and the second is whether, if the variance were granted, would it result in permanent closure of Class II shellfish waters. The Department correctly recognizes that the question of whether a hardship exists is a question of fact and is determined on a case-by-case basis. Surprisingly, in a kind of "what we don't know can't hurt" posture the Department reviews a request for a variance standing alone based on the application as it is presented and does not require analyses of other possible alternatives to the granting of a variance. However, the existence of any alternatives, costs of any alternatives, timeliness of any alternatives, problems with any alternatives, whether an alternative represents a short term or long term solution to a given problem and the implementability of any of the alternatives are all factors utilized by the Department in determining whether or not to grant a variance. The Department's policy of non- review makes no sense, either factually or statutorily, when the Department is faced with varying a prohibition it created in its own rules. Similarly, the Department's policy of not requiring other alternatives to be examined before granting a variance goes against the fact that an applicant has the burden to establish entitlement to a permit and, in the case of a hardship variance, that a hardship exists because reasonable alternatives to granting a variance are not available. 4/ Likewise, the second part of the Department's hardship analysis relating to the permanent closure of shellfishing waters makes no sense given the fact that a non-permanent closure of shellfishing waters may have the same or just as serious effect on employment in the shellfishing industry, the loss of income due to an inability to earn a living in that industry and health risks posed by contaminated seafood. Temporary loss of income or a livelihood can, for all practical purposes, have consequences to the persons directly affected by a temporary closure of shellfishing waters similar in nature those caused by the permanent closure of shellfishing waters. The same can be said for health risks posed by a contaminated food supply. Rule 17-312.080(7), Florida Administrative Code, does not contain any exceptions for the temporary closure of shellfish waters. Nor is the rule limited to instances of permanent closure. Permanent closure is simpy not required in order to support a hardship under Section 403.201, Florida Statutes. Moreover, neither step in the Department's two-step analysis is included in any Rule promulgated by the Department. 5/ Without such a Rule, it is incumbent upon the Department or the applicant to demonstrate the underpinnings for this non-rule policy. No such evidence was presented at the hearing. In fact, the evidence presented at the hearing affirmatively demonstrated that the Department's non-rule policy violated both its own rules and the statute under which it is trying to proceed. As indicated, the issue of hardship is a question of fact and involves a weighing of all the facts and cicumstances involved in this project. In this case, there are shellfishing areas located close to the proposed location of the transmission line. North Bay is sometimes closed to shellfish harvesting by the Department of Natural Resources. These closures generally occur during wet weather conditions and are due to stormwater runoff and the failure of septic tanks in Southport. 6/ Additionally the current Lynn Haven system also contributes to the closure of North Bay. No competent, substantial evidence was provided that issuance of the permit and variance would result in the permanent closure of shellfish waters. The location of the proposed transmission line would be several hundred feet west of the Bailey Bridge embedded in the Bay floor. 7/ The proposed alignment of the transmission line through North Bay is in an area which is relatively biologically unproductive. The proposed placement of the transmission line avoids the few grassbeds that exist in the nearshore shallow areas except for approximately 200 square feet of grass. During construction of the line, these grasses would be removed immediately before the line is placed in a trench and then would be promptly replanted in the same area. The evidence demonstrated that the affected areas of grass should be able to reestablish itself. The evidence further demonstrated that there would not be any long term adverse impacts to these aquatic resources and there should not be any significant long term impacts on the balance of any aquatic life which may exist on the bay bottom. Water quality during construction will be protected by use of turbidity controls to control sediments. Therefore, any short term impacts on aquatic resources are likely to be insignificant. Concerns about long term adverse impacts to Class II waters are greatly reduced by the type of pipe and conditions in the permit which require that the transmission line be routinely inspected and tested to insure that there is no leakage and that in the unlikely event the line should need to be repaired, the line could be easily isolated and quickly repaired. The evidence showed that, to completely avoid Class II waters, the line could be moved several miles to the west or east of the line's proposed location or be placed over or under the Bay. If the line was moved west to the extent that it was in Class III waters, it would be over 40 miles long and would more than double the cost of the project. If the line was moved several miles to the east, it would go through the Deer Point Lake Watershed. The watershed is a Class I water supply for Bay County. Clearly, moving the line either west or east is not practical nor realistically feasible. Tunneling under North Bay would be very risky and is not technically feasible. The length of the tunnel would require steel pipe to be used. If tunneling could be done at all steel pipe would not provide the level of protection afforded by the HDPE pipe proposed by Lynn Haven. Placing the transmission line on pilings for an aerial route over North Bay is uneconomical and would create a potential hazard to navigation. Moreover, an aerial crossing would not solve any pollution problems should the transmission line leak or break and would also still involve a variance request since it would be necessary to dredge and fill in Class II waters for the placement of pilings or supports. Put simply, the evidence, showed that there was no realistic way to avoid Class II waters in North Bay given the location of the proposed wastewater treatment facility. A location which the City knew would require a hardship variance from the rule prohibition of dredging and filling in Class II, shellfishing waters. A hardship which the City created by site selection and which it hoped to overcome by strenuous permit conditions and futuristic speculative benefits to unsewered areas of the County. The existing treatment facility is operating in violation of both EPA and DER requirements, has been issued a notice of violation, is nonpermitted and is destined to be operating under a consent order. The system is hydraulically overloaded, handling approximately 1.2 million gallons per day while its rated capacity is 950,000 gallons per day. Refurbishing Lynn Haven's existing wastewater treatment facility would not be viable since the plant has outlived its useful life, is of a very poor design and probably could not be made to function within Departmental standards and water quality standards. The existing sprayfield does not function and results in overland flow of effluent which discharges to Class II waters. The high water table and presence of a semiconfining layer on the Lynn Haven peninsula virtually guarantee such discharges. Further, the plant only provides secondary treatment. Put simply, Lynn Haven needs another method of handling its sewage. The only remaining alternative to a Bay crossing is to tie into the existing Bay County system and any AWT wastewater treatment plant Bay County may build in the future. 8/ The existing Bay County system provides at most only secondary treatment. The Cherry Street facility, which is part of that system, functions essentially as a lift station rather than a treatment facility. The Military Point Lagoon portion of the system is nonpermitted and is operating under a consent order and has been the subject of enforcement action. The Department has an extensive agreement with Bay County requiring a significant and long term series of actions to deal with their wastewater treatment system. The modifications or improvements to the Bay County system to provide advanced treatment are not imminent and the final system conditions cannot now be determined as they will depend in large measure upon data and analysis remaining to be collected. Currently, the existing Bay County system processes a significant amount of industrial discharge and has a problem with phenols most likely due to industrial waste from two discreet industrial facilities in the County. 9/ However, all of Bay County's wastewater system problems are reasonably solvable and will be corrected in the near future, if they have not already been corrected. Additionally, the amount of sewage Lynn Haven would be sending into the current Bay County system probably would not significantly impact that system and its problems or the County's ability to solve those problems. The County is willing to accept Lynn Haven's sewage into its system and future AWT system. The connection into Bay County's system is a viable alternative currently in existence. Moreover, as indicated, Bay County has a long range plan to build an advanced wastewater treatment plant. As yet the plan remains "just a twinkle in the County's eye" and has not progressed to the design stage. However, this plan, of necessity, will eventually become reality in the next 5 to 10 years. The estimated cost to a Lynn Haven user for the Bay County conceptual system will be $25.00 per month in lieu of $15.00 for the proposed Lynn Haven system. These estimates are at best speculative. However, this cost estimate is not excessive given the fact that a Lynn Haven user lives in an environmentally sensitive area and a Bay County hook-up would eliminate the need to run a sewer pipe through food producing, Class II waters. 10/ Based on these facts, the evidence demonstrated that it was feasible for Lynn Haven to hook into Bay County's wastewater system without creating any more environmental impacts than that system is already experiencing and must solve and which, to a significant degree, have already been solved by Bay County. Given the existence of this alternative to crossing food producing waters and the fact that any future benefits are just as likely to be provided just as quickly by the County through AWT facilities, the applicant has failed to demonstrate the necessity for crossing North Bay and failed to demonstrate entitlement to a hardship variance for that crossing. Therefore, the applicant is not entitled to either a dredge and fill permit or variance for the proposed North Bay crossing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is, recommended that the Florida Department of Environmental Regulation enter a final order issuing permit applications CS03178910, DC03178814, and 031785181, and denying the variance and permit number 031716641. RECOMMENDED this 27th day of November, 1991, in Tallahassee, Florida. DIANE CLEAVINGER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of November, 1991.
Findings Of Fact The Respondent, Albert R. Stewart applied to take the examination given on August 3, 1979, to receive a Class "C" waste-water treatment plant operator license. At the examination site of Clearwater, Florida, on the scheduled examination date, the examinees were instructed to print their names on the examination answer sheet and to sign their names on the cover of the examination booklet. At the request of Mr. Stewart, Mr. Alan Ferguson appeared and took the examination in Clearwater, Florida, on August 3, 1979, in the place of and on behalf of Mr. Stewart. Mr. Ferguson signed the examination cover (DER Exhibit 2) and answer sheet (DER Exhibit 3) with the name of "Albert Stewart". The signature on the examination booklet does not resemble any of the signatures of Albert R. Stewart on his application for this examination or for any previous exams. The signature does resemble that of Mr. Ferguson in his prior correspondence with the Department of Environmental Regulation. (Mr. Ferguson presently holds a Class "C" permit). The testimony of Mr. Stewart that he actually took the examination administered on August 3, 1979, is not credible. To allow Mr. Ferguson to be admitted to the examination, Mr. Stewart provided him with his social security card and his driver's license. He also gave Mr. Ferguson twenty dollars ($20.00) for his expenses incurred in traveling to and from Clearwater. At the time of the examination, Mr. Stewart who is presently employed as a supervisor for the Waste-Water Treatment Plant for the City of Inverness, was the supervisor of Mr. Ferguson. Mr. Stewart by his agreement with Mr. Ferguson to take the examination in his place, has falsely represented to DER that he took the August 3, 1979 examination. This false representation occurred in the process of his application for a waste-water treatment plant operator license.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That a final order be entered by the State of Florida, Department of Environmental Regulation immediately revoking the Class "C" waste-water treatment plant operator's license granted to Respondent, Albert R. Stewart. DONE and ENTERED this 25th day of July, 1980, in Tallahassee, Florida. MICHAEL PEARCE DODSON Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of July, 1980. COPIES FURNISHED: Alfred W. Clark, Esquire Assistant General Counsel Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32301 Mr. Albert Roscoe Stewart Post Office Box 306 Crystal River, Florida 32629 =================================================================
Findings Of Fact Petitioner, Department of Health and Rehabilitative Services, is the state agency charged with regulating waste water treatment facilities and any sanitary nuisance which may emanate as a result of such operations pursuant to Chapters 381 and 386, Florida Statutes. Respondent, Larry G. Delucenay d/b/a Madhatter Utilities, Inc., owns and operates the Foxwood Waste Water Treatment Plant which is permitted and certified by the Department of Environmental Regulation. Respondent, in operating the Foxwood system, discharges its treated effluent water by means of two percolation ponds and a drip field located adjacent to the Cypress Cove Subdivision in Pasco County, Florida. Respondent owns and controls percolation ponds which are located adjacent to the Cypress Cove Subdivision and pumps human waste from a sewage treatment plant to percolation ponds in the Cypress Cove Subdivision. Respondent's percolation ponds are located approximately 50 ft. west of several residences and the ponds are accessible to the public. The ponds are elevated from 3 ft. to 5 ft. above the adjacent residential lots in the subdivision. However, there is a sand berm approximately 8 ft. high with a 12 yd. base which serves as a barrier between the percolation ponds and the Cypress Cove residences. On August 5, 1991, environmental health specialist Burke observed liquid flowing through the sand berm. He also observed erosion patterns in the sand on the berm which indicated liquid was flowing through it. Mr. Burke, while in the company of two other employees of Petitioner, observed liquid flowing from the percolation ponds onto Lake Floyd Drive to the south of the ponds. An improperly designed nearby lake exacerbated the flooding into Lake Floyd Drive. Respondent's waste water treatment system is designed according to the manufacturer's specifications. Pasco County allowed a number of developments to be built in the area without an adequate drainage system which adversely impacts Respondent's system to the point whereby untreated drainage outfall is draining into the southeast areas in Cypress Cove. Specifically, Respondent's pond #4 is designed to handle a water level up to 67.33 ft. During the investigation of the case, the water level in that pond was approximately 3 1/2 ft. higher than the designed capacity and was therefore causing overflow into the southeast areas of the development. (Respondent's Exhibits A, B and C.) Noteworthy also was the fact that a developer failed to complete a connection which has impacted Respondent's percolation pond and has forced the water to rise approximately 9 ft. higher than the designed capacity which has resulted in an overflow approximately 3 ft. to 4 ft. into the neighboring subdivision. As a result of the overflow, waste water spills over the percolation ponds and prevents the water from draining through the berms as designed. Petitioner's consulting engineer, Robert William Griffiths, credibly testified that a number of agencies having oversight responsibility such as Pasco County, the Southwest Florida Water Management District and the Department of Environmental Regulation, mandated that the drainage system be completed prior to the entire build-up of Cypress Cove. Despite the mandate, the drainage system was not completed and the County allowed the development to continue. Respondent is properly treating and chlorinating sewage in its plant which complies with Petitioner's requirements for the treatment of sewage in systems designed such as Respondent's. Respondent properly treats sewage flowing through its ponds and its berms are properly maintained. As early as October 1989, Respondent consulted and retained an engineer, Gerald E. Towson, who was commissioned to investigate the specifics of designing a waste water treatment plant based on concerns raised by the Department of Environmental Regulation (DER). As a result of that charge, Towson investigated the area and observed flooding and the stormwater runoff in the Cypress Cove neighborhood and attempted to find a solution to alleviate the problem. Consultant Towson also investigated Respondent's treatment plant to determine if the system was functioning as designed. Based on his observation and inspection of the treatment facility, the facility was operating as it was designed and properly filters and treats the effluent. However, based on Respondent's inability to control the stormwater runoff in the neighborhood created by the excess buildup, Towson concluded that there was no workable solution to the problem. As a result of Towson's inability to find a workable solution to handle the concerns raised by DER, Respondent suggested that Towson locate another wastewater treatment site which he found in a surrounding area. Respondent negotiated a lease arrangement with the landowner and initiated the permit process with DER. After the completion of numerous documents and engineering studies required by the Department of Environmental Regulation, Respondent was able to get the leased site permitted by DER as a slow drip irrigation system during March 1991. However, while construction of the system was scheduled to start during March 1991, as a result of vigorous protests from area neighbors, construction was delayed. Respondent thereafter investigated several sites but was unable to fine a suitable area near Cypress Cove. Towson completed a lengthy and cumbersome process in getting Respondent's construction application processed by DER. Initially the application was filed and following a DER review, a Notice of Intent to Issue was given. Hillsborough County thereafter reviewed the project and following their review, Hillsborough County issued its Notice of Intent to Grant and public notice was given. Based on Respondent's inability to comply with the neighbor's concerns regarding setback problems, DER withdrew its permit during May of 1991. Thereafter, Petitioner became involved in connecting with the Pasco County Public System. That connection was ultimately made and the County gave its approval following a delay based on a review occasioned by an employee who had been on vacation. Upon getting the approval, Petitioner ordered the equipment from a supplier which included installation of a magnetic meter and the necessary hookups into the Pasco County System. A "phased in" connection has been completed and the stormwater runoff problem has been abated. When the problems raised by DER and ultimately Petitioner was first brought to Respondent's attention, Pasco County did not have the capacity to handle the hookups required by Respondent's system. Respondent, has been involved in the installation of waste water treatment plants since 1967. Respondent is qualified as a Class "A" Licensee Waste Water Operator. He has been accepted as an expert in numerous administrative hearings. Respondent purchased the Foxwood System during 1982. Respondent utilized a 13 acre tract near Lake Floyd Drive. The system was licensed and designed with a flow capacity of 300,000 plus gallons per day. During the time when the Administrative Complaint was issued, the flow capacity was 220,000 gallons per day. The storm water system which was to have been completed by developers in the area was not connected to the public system and the County granted numerous other permits to daycare centers and several parking lots were constructed for other newly constructed commercial buildings in the area. As a result of the excess runoff created by the development in the area, Respondent's system was impacted and the water level was raised in the percolation ponds to the point whereby an overflow resulted. Petitioner adduced no evidence which showed that any physical or emotional harm resulted from the runoff. At all times while the concerns were being raised by Petitioner and other oversite agencies, the effluents in Respondent's systems were properly treated. Respondent vigorously attempted to abate the runoff created by the excess buildup in the area despite the fact that the problem was raised by Pasco County and over which Respondent had no control. Throughout the process of attempting to find alternate solutions and ultimately getting permitting approval to start construction of an alternative waste water treatment system, Respondent operated in good faith. When no alternate site became available, Respondent initially made application to connect with Pasco County System and that connection has now been made.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that: Petitioner enter a Final Order dismissing the Administrative Complaint herein in its entirety. DONE and ENTERED this 29 day of April, 1992, in Tallahassee, Leon County, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29 day of April, 1992. COPIES FURNISHED: THOMAS W CAUFMAN ESQ HRS DISTRICT V LEGAL OFFICE 11351 ULMERTON RD - STE 407 LARGO FL 34648 RANDALL C GRANTHAM ESQ COTTERILL GONZALEZ & GRANTHAM 1519 N MABRY - STE 100 LUTZ FL 33549 RICHARD S POWER AGENCY CLERK DEPT OF HEALTH AND REHABILITATIVE SERVICES 1323 WINEWOOD BLVD TALLAHASSEE FL 32399 0700 JOHN SLYE ESQ/GENERAL COUNSEL DEPT OF HEALTH AND REHABILITATIVE SERVICES 1323 WINEWOOD BLVD TALLAHASSEE FL 32399 0700
The Issue Whether, under the facts and circumstances of this case, Respondent's license to practice engineering in the State of Florida, should be revoked, suspended, or otherwise disciplined.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: At all times material to this proceeding, Respondent, L. Thomas Hubbard d/b/a The Hubbard Association, was licensed to practice professional engineering in the State of Florida, having been issued license number PE 006634 on August 17, 1962. Certificate of authorization number EB0003297 was issued to the firm, The Hubbard Association, Inc., on September 25, 1981. In March 1986, Respondent prepared a set of plans for the proposed City of Macclenny Wastewater Treatment Works Improvement Program, Sewage Treatment Facility ("Macclenny project"), and one volume of "Contract Documents and Specifications" ("specifications"), which were submitted to the State of Florida Department of Environmental Regulation, Bureau of Wastewater Management and Grants (Bureau) on or about April 24, 1986. All wastewater treatment plans designs must go to the DER for approval prior to construction, and if a public entity wants grant funding for its wastewater treatment facility, the project must be reviewed and approved by the Bureau (now called Bureau of Local Government and Waste Water Financial Assistance) which administers State grant programs for wastewater treatment facilities. The Bureau reviews grant project plans and specifications to ensure that they: (a) comply with administrative requirements of the grants programs; (b) comply with minimum Federal and/or State technical standards for wastewater facilities; (c) are suitable for bidding; and (d) present a constructible project. The plans for the Macclenny project depict an existing treatment facility, a new clarifier to improve the removal of solids (an expansion of about 130,000 gallons per day in treatment capacity), and a new effluent pumping station to pump to an overland flow field (field) through a force main pipeline to spray risers. The risers would spray the water laterally across the field. Water would collect in a central collection ditch, and run through a final chlorine contact chamber prior to discharge in Turkey Creek. A new agricultural building for equipment storage, and a new holding pond, which is an off-line pond for storage of inadequately treated water, are also depicted. The field in the Macclenny project is roughly 24 acres and is located in a large area between the chlorine contact chamber and the holding pond. The field in this system has 5 cells. A cell is an area of land that can be independently controlled to allow loading/resting cycles in the treatment process. Each cell in a given field should be as near equal in size as possible to provide for equal treatment of the wastewater during the loading/resting cycles. Loading/resting cycles allows a cell within the field to "rest" (no effluent being pumped on to that cell) so maintenance mowing or harvesting can be accomplished and to "load" the other cells to revitalize the bacteria that renews the treatment process. "Load" means to apply the effluent or treated wastewater from the existing facility to the field. Generally, forty percent of the field would be loaded with wastewater at any one time. On December 9, 1985, the Bureau had a predesign conference with Respondent in Macclenny to discuss design items. No plans or specifications for the Macclenny project had been submitted at that time, nor were they submitted at this conference. On February 18, 1986, an in-progress design review was held at Macclenny, with the Bureau staff available to answer Respondent's questions. On March 5, 1986, another in-progress design review meeting was held in Macclenny, with the Bureau staff present, at which time the plans were "fifty percent" (50%) complete. The unsigned and unsealed plans were given to the Bureau for a preliminary review. On March 25, 1986, the Bureau issued a few preliminary comments on the 50% completed plans and specifications. The purpose of the 50% complete review is to help the design engineer complete his plans and specifications. On March 31, 1986, Respondent transmitted to the Bureau a set of plans for the proposed Macclenny project. Respondent's transmittal letter, which the Bureau received with the plans on April 11, 1986, stated that "completed plans" were being transmitted. On April 21, 1986, Respondent transmitted to the bureau an additional set of the same plans for the Macclenny project, which Respondent again referred to as "completed plans" on his transmittal letter form which were received by Bureau on April 24, 1986. This transmittal also included specifications, a design data check list, design calculations, cost estimate, and plan of operation. The plans in this submittal are referred to as "the plans." It was Respondent's understanding that signing and sealing a set of engineering drawings signified a legal obligation that if someone takes the plans and builds a project it will work. Respondent's signature and seal are on the first sheet of the set of plans which was in the April 1986 submittal but not on the specifications. The plans were prepared, signed, sealed and submitted to the Bureau for review by Respondent. Respondent did not place any conditional language or qualification on the plans or write a letter advising the Bureau that the plans were not complete. It was Respondent's understanding that the Bureau would not review a set of plans unless they were signed and sealed, notwithstanding the completeness of the plans. Respondent did not consider the plans as completed, notwithstanding that he had signed, sealed and submitted them to Petitioner as "completed". It was Respondent's understanding that the plans were being submitted for review only, not complete for construction. An engineer may get answers from the Bureau without submitting plans that are signed and sealed as completed, such as the predesign conference or 50% review that occurred in this case. The Bureau considers plans that are signed, sealed and submitted as "completed" for review to be 100% complete and ready to bid. The Bureau considered the plans and specifications which Respondent submitted on April 24, 1986 as being final, complete plans and specifications for final review by the Bureau. The Bureau reviewed the plans assuming them to be complete and followed normal procedures for reviewing a complete set of plans and specifications. On June 19, 1989, the Bureau issued 52 written comments based on its review of the plans and specifications it had received in the April 24, 1986 submittal from Respondent. The plans and specifications were submitted to the Department of General Services (DGS) by the Bureau for a review and opinion because the Bureau was concerned about the structural design. DGS responded to this request through Jim Berkstresser, P.E. on June 25, 1986. By cover letter dated July 18, 1989, Respondent filed written responses to the Bureau's 52 comments. The Bureau did not approve Respondent's plans and specifications for the Macclenny project submitted on April 24, 1986. On September 5, 1986, Respondent resubmitted plans in response to the Bureau's 52 comments. These plans had the same configuration as the April submittal regarding the overland flow treatment. On September 29, 1986, Respondent met with David Wolfe to discuss the field configuration for the proposed overland flow system and other outstanding issues related to the revised contract documents. The principal concerns were non- uniform flow and significant erosion potential. Respondent's plans did not follow accepted design criteria. At this meeting field configurations were discussed, as well as guidelines to be followed in design of the overland flow field, and a general field layout were developed. Respondent submitted another set of plans which the Bureau received on October 30, 1986, and that set was approved and stamped accepted by DER-BWMG on December 22, 1986. All sheets in the approved set are dated August 20, 1986, with the exception of the cover sheet on which Respondent failed to date his seal and signature, and sheets G-6 and G-7 which are dated October 24, 1986. Respondent signed and sealed the cover sheet and sheet G-7 of the approved set of plans, but did not seal any other sheets in the approved set of plans. A signature and seal on a set of plans indicates that the plans were prepared by, or under the direct supervision of the person signing and sealing them, and that the plans are complete and depict a project that will perform its intended function. A signature and seal on a set of plans means the engineer assures that the design is his design and that the plans and specifications are ready to be bid for construction. The design should contain criteria and information significant to ensure the project will work. Sheet flow is the primary treatment mode in an overland flow system. Sheet flow is where a thin layer of water is induced to flow in a very controlled atmosphere across a length of land that is functioning very similarly to a trickling filter. The acceptable range of slope of an overland flow system is 2% to 8% with the best results obtained in the lower range because of a longer "residence time". "Residence time" is the amount time the wastewater is on the field for treatment. The slopes must be even and uniform to maintain a constant velocity so as to minimize the potential for erosion and to maintain a constant depth of water throughout the filed so as to maximize the treatment. Cross slopes should be minimized and topographic lines should be as close to parallel as possible on the field. The plans for the Macclenny project shows: (a) slopes ranging from less than 2% up to 6%; (b) multiple compound slopes across the field and; (c) topographic lines that are not parallel. The specifications for the field do not set out the acceptable tolerances on the slopes or the acceptable level of compaction of the field for the contractor who is to construct the field and; therefore, lacks control over the final product. Contours in an overland flow field are important, and while it is desirable for them to be on 1-foot intervals, contours at intervals of 2 feet are acceptable provided the plans and specifications address what happens between the contours. Respondent's plans and specifications show contours at intervals of 2 feet but do not address what happens between the contours. The plans of the facilities that were approved prior to the submittal of any plans by Respondent called for a 2- 3 week loading/resting cycle. The standard practice is to have all cells within an overland flow field to be of equal size so that the area to be loaded at any given period of time is the same size. The cells in the overland flow field in the Macclenny project as depicted by the plans are not of equal size, and if operated on a 2-3 week loading/resting cycle would not provide a consistent amount of treatment and thereby result in varying levels of treatment of the effluent. It is standard practice to provide performance specifications for seeding the field with the primary grass cover and for overseeding when necessary to prevent wind and water erosion. There were no performance specifications in the plans and specifications on the Macclenny project submitted by the Respondent. Agricultural equipment is an integral part of the overland flow field system and has a direct bearing on whether the system will function over the long run. Specifications for agricultural equipment are necessary to determine if the system will work properly. There were no specifications for agricultural equipment submitted by the Respondent in the plans. It is standard practice to furnish spray nozzle specifications, such as nozzle size, degree of fanning, characteristics under varying pressures and how much water will be discharged by the nozzle, in a set of plans and specifications for an overland flow field. Respondent's specifications for the Macclenny project did not contain the necessary specifications for the spray nozzles. Compacting is a standard practice, and it is standard practice to show compaction requirements on plans or specifications. The usual practice is to investigate the soil and specify compaction, usually based on a foundation report by a geo-technical engineer, showing the safe beading capacity of the soil in what condition, with recommendations for compaction. The Respondent's specifications do not call for compaction of the soil under the clarifier slab. However, the Respondent's specifications do call for compaction in the holding pond and situations where an area is over-excavated and backfilled. Should the area under the clarifier slab be over- excavated and backfilled, then compaction is covered in the specifications but compaction would not be covered unless this occurs. Therefore, since the weight of the slab is carried by the soil beneath it, specifications for compaction should have been included in Respondent's specifications for any situation. Changes in temperature causes concrete to expand or contract which may result in cracking. Placement of a concrete slab may result in the slab bending which may result in cracking. Therefore, reinforcing a concrete slab is required to maintain the slab's integrity. The thickness of a concrete slab will determine the distribution of the reinforcing so that cracking is minimized. The clarifier slab in the Macclenny project is depicted as being 12 inches thick and shows number 6 bar reinforcing on 6 inch centers in the top of the slab but no reinforcing in the bottom of the slab. Failure to require reinforcing in the bottom of the slab could result in the slab cracking due to significant changes in temperature and soft spots in the soil beneath the slab. Failure to place reinforcing in the bottom as well as in the top of the slab is not in accordance with standards of the code of the American Concrete Institute (ACI), revised in 1983, and is a structural weakness. The chlorine contact chamber as detailed on sheets 5-6 and 5-7 is like a rectangular concrete box beneath the earth where the earth is within a few inches of the top of the walls. The walls are vertically reinforced with number 4 bars on 12 inch centers placed in the center of the 8 inch thick wall. When the tank is empty the reinforcing bars will be approximately 160 per cent overstressed from the active pressure of the earth. Additional reinforcing is needed in the walls to meet ACI standards. There are deficiencies in the vertical wall reinforcing of the chlorine contact chamber as detailed on sheets 5-6 and 5-7 of the Plans. On sheets 5-3, 5-4 and 5-7 of the plans, reinforcement through the construction joints is incorrectly detailed to assure that cracking of the concrete will not occur. Construction joints occur between different pours of concrete, such as where the walls meet the top of the bottom slab. The concrete bottom of the holding pond as detailed in sheet 5-8 of the Plans is large enough to require expansion joints to prevent cracking as the slab expands and contracts due to changes in the weather, yet no expansion joints are shown for the slab as detailed on sheet 5-8 of the plans. Neither the collection ditches nor the spray riser bases as detailed on the plans show any reinforcing to maintain the integrity of the concrete. While this is not a major structural weakness, it indicates a failure to comply with standard structural engineering practices. Although the plans call for relocation of an existing drainage ditch, the Respondent failed to consult DER regarding the permitting of such drainage ditch. A detention time of 30 minutes is required to properly disinfect wastewater and is-basic knowledge for all civil engineers, yet the plans called for only a fifteen minute detention time. It is standard engineering practice to provide flood level elevations on the site plans. Respondent failed to provide flood level elevations for the Macclenny facility site plans. The plans failed to: (a) provide elevations for high water alarm and pump off settings; (b) provide specifications for flume liner on sheet M-4; (c) show how to close an existing outlet on the chlorine contact chamber; (d) show where an effluent pump station was to be located; (e) show pressure relief valve locations and; (f) indicate quantities for purpose of contract bidding. The specifications list equipment and work items, such as pumping equipment, grit storage tank, case-out assembly, telescoping valve, air diffusers, portable pump, hose and couplings, that are inapplicable to the Macclenny project. There are inconsistencies in the plans and specifications, such as: (a) the plans showing one clarifier while the specifications call for two clarifiers, (b) the plans showing a 150 pound chlorine cylinder as opposed to a 1-ton chlorine cylinder in the specifications and; (c) the plans showing the clarifier with a 38-foot diameter while the specifications calls for a clarifier with a 40-foot diameter. Respondent was negligent in submitting incomplete plans to the Bureau as "completed plans" and in failing to utilize due care and failing to have due regard for acceptable standards of engineering principles, with regard to the content of those plans which he submitted as "completed plans".
Recommendation Having considered the foregoing Findings of Fact and Conclusions of Law, the evidence of record, the candor and demeanor of the witnesses and the circumstances surrounding this case, it is, therefore, RECOMMENDED that the Board enter a Final Order finding Respondent, L. Thomas Hubbard guilty of violating Section 471.033(1)(g), Florida Statutes, and for such violation impose an administrative fine of $1,000.00 and suspend from the practice of engineering for a period of thirty (30) days, stay the suspension and place the Respondent on probation for a period of one year under terms and conditions the Board deems appropriate. DONE AND ENTERED this 20th day of June, 1990, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearing this 20th day of June, 1990. APPENDIX TO THE RECOMMENDED ORDER IN CASE NO. 89-0096 The following constitutes my specific rulings pursuant to Section 120.59(2), Florida Statutes, on the Proposed Findings of Fact submitted by the Petitioner in this case. Specific Rulings on Proposed Findings of Fact Submitted by the Petitioner Adopted in Findings of Fact 1. Rejected as not being necessary to the conclusions reached in this Recommended Order. 3.-12. Adopted in Findings of Fact 2, 3, 4, 5, 6, 7, 8, 9, 10, and 11, respectively, but modified. 13. Rejected as being immaterial or irrelevant or unnecessary or subordinate. 14.-19. Adopted in Findings of Fact 12, 13, 14, 15, 16, and 17, respectively, but modified. Rejected as being immaterial or irrelevant or subordinate or unnecessary. Adopted in Findings of Fact 17 and 18 but modified. 22.-33. Adopted in Findings of Fact 19, 20, 21, 22, 23, 24, 24, 25, 26, 27 and 27, respectively, but modified. 34. Adopted in Findings of Fact 17 and 18, but modified. 35-37. Rejected as being immaterial or irrelevant or unnecessary or subordinate. 38. Adopted in Findings of Fact 28 and 29, but modified. 39.-40. Rejected as being immaterial or irrelevant or unnecessary or subordinate, but see Findings of Fact 37 and 38. 41.-5O. Adopted in Findings of Fact 28, 32, 29 (28-31), 29, 29, 32, 30, 32 and 32, respectively, but modified. 51. Rejected as being immaterial or irrelevant or unnecessary or subordinate. 52.-53. Adopted in Findings of Fact (28-33) and 32, respectively, but modified. 54.-55. Rejected as being immaterial or irrelevant or unnecessary or subordinate. Adapted in Finding of Fact 55. Rejected as being immaterial or irrelevant or unnecessary or subordinate. 58.-62. Adopted generally in Findings of Fact 28-33. 63.-66. Adopted generally in Findings of Fact 34-36. 67.-72. Adopted generally in Finding of Fact 37. 73.-74. Adopted generally in Finding of Fact 38. 75.-76. Adopted generally in Finding of Fact 39. 77.-79. Adopted generally or covered in Findings of Fact 13-15 and 28-39. 80.-82 Adopted generally or covered in Findings of Fact 40- 41. 83.-90. Adopted generally or covered in Findings of Fact 42 and 43. 91.-96. Adopted generally or covered in Findings of Fact 44 and 45. 97.-104. Adopted generally or covered in Finding of Fact 46. 105.-107. Adopted generally or covered in Finding of Fact 47. 108.-109. Adopted in Finding of Fact 48. 110.-115. Adopted generally or covered in Finding of Fact 55. 116.-117. Adopted in Finding of Fact 49 and 50. 18. Rejected as being immaterial or irrelevant or unnecessary or subordinate. 119. Adopted in Finding of Fact 51. 120.-124. Adopted in Finding of Fact 52. 125. Rejected as immaterial or irrelevant or unnecessary or subordinate. 126.-127. Adopted in Finding of Fact 52. Adopted in Finding of Fact 53. Adopted in Finding of Fact 54. Adopted in Finding of Fact 53. Adopted in Finding of Fact 55. Specific Rulings on Proposed Findings of Fact Submitted by the Respondent Adopted in Findings of Fact 13-15. Adopted in Finding of Fact 19 except last sentence that is rejected as being immaterial or irrelevant. Rejected as being a restatement of Administrative Complaint and not a Finding of Fact but see Findings of Fact 15 and 19. Rejected as being a restatement of John Sowerby's testimony and not a Finding of Fact, but see Findings of Fact 15, 17 and 18. Adopted in Finding of Fact 15. 6. Restatement of David Wolfe's testimony COPIES FURNISHED: Rex Smith Executive Director Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792 Kenneth Easley, Esquire General Counsel Department of Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, FL 32399-0750 Wings S. Benton, Esquire 1020 D. Lafayette Street, Suite 205 Post Office Box 5676 Tallahassee, Florida 32314-5676 L. Thomas Hubbard, pro se THA Building 3110 Spring Glen Road Jacksonville, Florida 32207
The Issue Whether respondent should admit petitioner to the examination for Class B Wastewater Treatment Plant Operator certification or deny admission for failure to comply with Rule 17-602.300(3), Florida Administrative Code?
Findings Of Fact At the time and place set for final hearing, neither petitioner nor respondent presented any evidence on which findings of fact could be based.
Recommendation It is, accordingly recommended that respondent deny petitioner's application for certification as a Class B Wastewater Treatment Plant Operator, without prejudice to the filing of a subsequent application. RECOMMENDED this 13th day of March, 1991, in Tallahassee, Florida. ROBERT T. BENTON, II Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of March, 1991. COPIES FURNISHED: Charles H. Colvin 2140 Bay Road Neptune Beach, FL 32233 William H. Congdon, Esquire Twin Towers Office Building 2600 Blair Stone Road Tallahassee, FL 32399-2400 Carol Browner, Secretary Department of Environmental Regulation Twin Towers Office Building 2600 Blair Stone Road Tallahassee, FL 32399-2400 Daniel H. Thompson, General Counsel Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, FL 32399-2400
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: Several years prior to1978, petitioner General Development Corporation (GDC) applied to the DER for a dredge and fill permit to remove a plug of land between the Ocean Breeze Waterway and the North Fork of the St. Lucie River. During the course of negotiations for this permit, it was discovered that the North Port St. Lucie Sewage Treatment Plant, owned and operated by General Development Utilities, Inc., a wholly-owned subsidiary of the petitioner, was operating without a permit from the DER and discharging effluent into a ditch which flowed into the Ocean Breeze Waterway. In March of 1978, a temporary operating permit was issued for the sewage treatment plant. In July of 1978, petitioner received from the DER Permit No. 253.123- 1031 to dredge an area approximately 800 feet in length, 90 feet in width and 6 feet in depth in order to connect the Ocean Breeze/Sagamore Waterways to the dead end oxbow of the North Fork of the St. Lucie River. The permit application was given special consideration pursuant to Rule 17-4.28(7), Florida Administrative Code. The purpose for obtaining the permit was to create direct navigable access to the North Fork of the St. Lucie River from thee Ocean Breeze Waterway. The Ocean Breeze Waterway was and is currently connected to the North Fork of the St. Lucie River by a narrow, shallow, meandering creek and lake system. However, there is not a large enough opening to allow the type of navigable access desired by the petitioner for the benefit of 118 lots plotted along the Ocean Breeze and Sagamore Waterways. Among the seven particular or special conditions attached to the dredge and fill permit issued to petitioner was that the earthen plug not be removed until such time as a permanent operational permit was issued for the sewage treatment plant owned and operated by General Development Utilities, Inc. More specifically, petitioner agreed to the following special conditions to the issuance of the dredge and fill permit: "(7) The applicant is aware that the GDC Utilities' sewage plant is providing an unknown quantity of discharge into Ocean Breeze Waterway and that this discharge may be a source of pollution to the receiving body of water unless affirmative steps are taken by the Utilities. The sewage treatment plant is currently operating under a Temporary Operating Permit (TP56-4601). In no case shall the plug at Cove Waterway be removed before an Operation Permit for the STP has been issued by the Department of Environmental Regulation." At time of issuance of the dredge and fill permit, DER personnel considered the quoted special condition number 7 to an integral part of the permit in terms of water quality assurances. General Development Utilities, Inc. has not been able to obtain a permanent operational permit from the DER for its sewage treatment plant which discharges into a ditch that flows into the Ocean Breeze Waterway. Therefore, particular condition number 7 has not been satisfied and petitioner has been unable to proceed with the dredging or removing of the plug under the permit. As a result of the delays in removal of the plug, petitioner has had to repurchase some 41 of the 118 plotted lots. The sewage treatment plant was and is still operating under a temporary permit. General Development Utilities, Inc. has requested a permanent operational permit for the sewage treatment plant and DER has issued a letter of intent to deny such a permit. As a result, General Development Utilities has petitioned DER for site specific alternative criteria pursuant to Rule 17-3.031, Florida Administrative Code. This matter is the subject of a separate proceeding currently being held in abeyance pending a determination of alternative criteria. General Development Utilities, Inc. v. Department of Environmental Regulation, DOAH Case No. 81-177. In September of 1980, petitioner sent a letter to DER requesting that special condition number seven be removed from its dredge and fill Permit No. 253.123-1031. It was intended that this request be considered as a minor modification to the dredge and fill permit. In response, DER's Chief of the Bureau of Permitting, Suzanne P. Walker, informed petitioner by letter dated October 15, 1980, that it was the staff's initial reaction, after a review of the original dredge and fill permit file, that the requirement that the sewage treatment plant obtain a permanent operational permit prior to dredging remain as a condition of the dredge and fill permit. Petitioner was informed that if it wished to pursue the matter further, the project must be reevaluated as a major modification to the dredge and fill permit. A major modification to a permit requires a new permit application and fee and is treated and processed as an initial application for a permit, with the applicant being required to provide reasonable assurances that the water quality standards will not be violated. Upon request for a minor modification, DER simply reviews the file and determines whether the request is obviously environmentally insignificant. After receipt of the letter from Mrs. Walker, petitioner supplied DER with additional water quality data. Based upon this additional data, discussions with DER staff who had been involved with the initial dredge and fill permit and the sewage treatment plant permit, and two days of sampling data collected by DER, DER determined that particular condition number seven was an integral part of the affirmative reasonable water quality assurance provided and should remain a condition of the permit. This determination was communicated to petitioner by letter dated January 7, 1981. The sewage treatment plant discharges treated effluent into a drainage ditch known as C-108. Effluent from the plant first goes into holding or retention ponds. Under its current flow, it takes about forty days for the effluent to be discharged from the plant to C-108 and the Ocean Breeze Waterway. C-108 flows into the Ocean Breeze Waterway, an artificial waterway which is presently connected to the North Fork of the St. Lucie River by a narrow, shallow meandering creek and lake system. The sewage treatment plant currently operates at 300,000 gallons per day but has an authorized capacity to operate at two million gallons per day. It currently contributes approximately two percent of the total daily flow to C-108. The Ocean Breeze Waterway and C-108, independent of the sewage treatment plant, drain approximately 4,000 square acres and produce about 35 percent of the water that will flow into the North Fork. The North Fork is tidal, with four one foot tides per day. The tidal action comprises almost 63 percent of the moving water. At a two million gallons per day discharge, the wastewater plant would be contributing about 12 percent of the water that would be going into the North Fork from the Ocean Breeze Waterway system. In comparison with two adjacent drainage systems, the Ocean Breeze system contributes only about three percent of the fresh water which flows into the North Fork. The dissolved oxygen levels of C-108 are chacteristically below the state standard of five milligrams per liter, primarily due to the seepage of ground water into the canal. Due to man-made alterations and to natural phenomena, the North Fork's dissolved oxygen levels also characteristically fall below state standards. The dissolved oxygen level of the Ocean Breeze Waterway is characteristically above state standards. Higher levels of dissolved oxygen coming from the sewage treatment plant improves the dissolved oxygen levels of the existing system. High levels of nitrogen, phosphate and chlorophyll have been found near the point of discharge. The quality of water in the North Fork is better than in the Ocean Breeze Waterway. It was the opinion of petitioner's experts that no change in dissolved oxygen levels would occur in the Ocean Breeze Waterway or the North Fork if the plug of land between these water bodies were removed. Petitioner's witnesses also opined that the Ocean Breeze/C-108 system was not a source of nutrient enrichment to the North Fork, and that the present creek system provided no water quality benefits in the form of nutrient uptake for the North Fork. It was estimated that, if the plug of land were removed pursuant to the permit, a pollutant placed at the upper end of the Ocean Breeze Waterway would be diluted by 98 percent in 26 hours in lieu of the present 39 hours due to increased flushing. These opinions were based upon analyses by petitioner's witnesses of various samplings and data regarding dissolved oxygen, nutrients and phytoplankton. The respondent's witnesses felt that the poor water quality in the Ocean Breeze Waterway was attributable in large part to the sewage treatment plant discharge and, if the plug of land were removed, the water quality problems would be moved to the North Fork and the St. Lucie River. It was felt that the present creek and lake system -- the narrow circuitous connection presently existing between the canal and the river -- reduces the nutrients which otherwise would flow into the river. These conclusions were based upon DER's own survey, a review of the dredge and fill permit file and a review of the additional data supplied by the petitioner General Development Corporation. No data regarding the water quality of the effluent from the sewage treatment plant was submitted by the petitioner at the time of DER's review of the original application for the dredge and fill permit.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the request of General Development Corporation to modify Permit Number 253.123-1031 by removing particular condition number seven be DENIED. Respectfully submitted and entered this 14th day of October, 1981, in Tallahassee, Florida. DIANE D. TREMOR, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of October, 1981. COPIES FURNISHED: Valerie Fravel Corporate Counsel General Development Corp. 1111 South Bayshore Drive Miami Florida 33131 Alfred J. Malefatto Assistant General Counsel Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32301 Honorable Victoria Tschinkel Secretary, Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32301
