Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
The Issue Whether Respondent should be disciplined for failure to comply with provisions of Florida law?
Findings Of Fact Respondent, George F. Garrard, is licensed as a registered roofing contractor holding State of Florida license number RC 0045805. On May 14, 1986, Respondent entered into a contract with Ronald Skinner to reroof a house located at 2226 Eudine Drive, in Jacksonville, Florida. The contract provided that Respondent would: "Tear off the entire roof to sheeting. Haul off all debris. Install 5 ply-build-up roof. New metal edging." In exchange for the work, the contract called for Respondent to receive $1100.00, $600.00 to be paid in advance for materials and $500.00 to be paid upon completion of the job. 2. Mr. Skinner paid Respondent the $600.00 advance for materials and work on the roof began the following day. While the work on the roof was in progress, Mr. Skinner conducted periodic inspections and noticed that the felt had buckled up. Mr. Skinner asked Respondent how he was going to fix the felt and Respondent said that he could fix the felt by cutting out the buckled parts and patching the felt. Mr. Skinner responded that he had a patched roof before and did not want another; he wanted a new roof. Respondent promised he would fix the problem. Prior to the work being completed, Respondent made a telephone call to Mr. Skinner and asked for payment of the remaining balance on the contract in order to purchase the materials needed to finish the job. Mr. Skinner agreed to meet John T. Garrard (Respondent's son) at the house and pay the balance. Respondent authorized Mr. Skinner to pay John T. Garrard. When Mr. Skinner arrived at the house, John T. Garrard and another person were unloading rocks from a pick-up truck and placing the rocks in a pile on the carport roof. Mr. Skinner paid John T. Garrard $500.00 and John T. Garrard wrote "Paid in Full" on the face of the contract and signed his name. A few minutes after Mr. Skinner left the house, John T. Garrard and the other person also left the house. Two or three days later, Mr. Skinner returned to the house. He noticed that no further work had been done. The rocks which had been unloaded from the pickup truck were still in a pile on top of the carport. Mr. Skinner was afraid the weight of the rocks would damage the carport so he spread the rocks on the roof. There were not enough rocks to cover the whole roof. Also, the rocks were loose because no tar had been spread on the roof to hold the rocks in place. Mr. Skinner contacted Respondent or someone in his household several times, and Respondent assured him he would finish the job. No further work was done on the roof by Respondent. Mr. Skinner last contacted Respondent by letter dated January 26, 1987, wherein he asked that Respondent finish the job since he had been paid in full. On the date of the hearing, the roofing job had not been completed. The rocks were still insufficient to cover the entire roof, no tar had been spread to hold the rocks in place, and the felt was still buckled in various places. Respondent never obtained a building permit for the reroofing job.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner enter a final order finding Respondent guilty of violating Sections 489.129(1)(d) and (k), Florida Statutes, and imposing a fine of $2,000 on Respondent. DONE and ENTERED this 30th day of March, 1988, in Tallahassee, Florida. JOSE A. DIEZ-ARGUELLES Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of March, 1988. COPIES FURNISHED: David L. Swanson, Esquire Department of Professional Regulation 120 North Monroe Street Tallahassee, Florida 32399-0750 George F. Garrard 4622 Tabernacle Place, East Jacksonville, Florida 32207 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue Whether the Respondent aided and abetted an unlicensed contractor by obtaining a permit for a roofing job performed by the unlicensed contractor; Whether the work on the job failed to fully comply with the local building codes; Whether the Respondent gave a guarantee on the job and thereafter failed to reasonably honor the guarantee; and Whether Respondent failed to properly supervise the job site activity.
Findings Of Fact At all times material to this action, Respondent was licensed by the Construction Industry Licensing Board as a registered roofing contractor, holding License No. RC0030450. Carol Kilgore is the daughter of Beula Relihan, who owns a rental home located at 207 East Selma in Tampa, Florida. Mrs. Relihan is 86 years old, and for several years Mrs. Kilgore has been managing the property. In early 1987, Mrs. Kilgore was involved in obtaining estimates to replace the roof at the rental home. After obtaining estimates from contractors listed in the yellow pages, which Mrs. Kilgore felt to be high, Mrs. Kilgore responded to an advertisement for roofing work located in the Money Saver. She called the number listed in the advertiser, talked to Leroy Rison, and asked him to come to the house and give her an estimate. On or about February 26, 1987, Leroy Rison and his nephew, Gary Terrell, visited Mrs. Kilgore after looking at the job site, and wrote out an estimate for replacing the roof of $1,650.00. Mr. Terrell wrote the proposal which reflected the work to be done, the price, and the proposed beginning and finishing date. However, before any contract was entered into, Mrs. Kilgore discovered that neither Rison or Terrell were licensed contractors. She explained that she wanted only a licensed contractor who could pull the permit to perform the work. Although Mr. Terrell and Mr. Rison are willing to work for a homeowner if the homeowner will obtain the permit, Mrs. Kilgore insisted that she wanted a licensed contractor. Therefore, Mr. Rison recommended the Respondent, and later called the Respondent to advise him of the job. The next day, February 27, 1987, Respondent met Mrs. Kilgore and wrote a contract proposal on a form with a printed heading "MacDill Roofing", to which in handwriting was added "& Services." Respondent operates under the name of, and is the qualifying agent for, MacDill Services. The contract prepared by the Respondent merely copied the proposal submitted by Terrell and Rison, including the same price and the same misspelled words. The contract was accepted and signed by Ms. Kilgore's mother. Mrs. Kilgore paid Respondent $650.00, with the balance to be paid upon successful completion of the contract. Work was scheduled to begin the following day, Saturday, February 28, 1987 and be completed by Monday, March 2, 1987. The following Saturday work began. Respondent obtained the permit for the job, and apparently purchased the materials and had them delivered. Leroy Rison worked on the job and hired the laborers. Gary Terrell also worked on the job. One of the men Rison hired, Earl, worked for a roofing company during the week but did not have a license. Mr. Rison could not remember the name of any of the other men who worked on the job. Leroy Rison was not an employee of MacDill Roofing or MacDill Services, but he had worked for Respondent on other occasions. Although Respondent contends that he went by the job site on three or four occasions, staying at the job site between 1 and 2 hours on each occasion, his testimony is not credible. Charles Doty, who was the tenant in the rental home, had received a leg injury which forced him to stay home during this entire period of time. The only time Mr. Doty was gone was for an hour and half on Saturday to attend a therapy session. Mr. Doty never saw Respondent on the job site, although he had heard Respondent's name mentioned by Mr. Rison. Mrs. Kilgore also visited the job site on several occasions and she never saw the Respondent at the job site. Respondent simply did not supervise the job site activities. On March 3, 1987, the roof was scheduled for final inspection by the building department. Mrs. Kilgore went to the house to wait for the building inspector. After several hours, she left to get a soft drink. She was gone only five minutes, but when she returned, she discovered that the building inspector had come and gone, and a "green tag", indicating that the house had passed inspection, had been left on the porch. Mrs. Kilgore was very upset because she felt that the roofing work had not been done properly. She went to the building supervisor at City Hall and asked him if he could send the inspector back to the house so that she could point out the problems. The building supervisor agreed to send the inspector back to the house. The building department inspector was Terry Scott. On March 3, 1987, Mr. Scott had approximately 20 or 25 inspections to do. When he first went to the house he just looked around quickly and left a green tag. He admitted that a thorough inspection was only done if a homeowner complained. When Mr. Scott returned to the house on March 3, 1987, he still did not do a thorough inspection. However, he did issue a "red tag" which listed certain deficiencies that would have to be corrected before the roof could pass inspection. The red tag required that the contractor "replace bad wood where needed and install drip-edge where needed." Normally, when a red tag is issued, the contractor corrects the deficiency and calls for another inspection. That did not occur in this case. On April 9, 1987, Inspector Scott met Mr. Park at the job-site to discuss problems with the roof. On that day, a more thorough inspection was performed. Another red tag was issued and the following deficiencies were noted: "Bad wood not replaced--Wall flashing not properly installed. Flashing around chimney not proper--Felt under drip-edge." Respondent did not correct these deficiencies and never called for another inspection. The permit expired without the roof being approved by final inspection. Although not all the deficiencies noted in the inspection constitute code violations, the Tampa Building Code does require that rotten wood be replaced and the contract specified that the rotten decking would be replaced. Nevertheless, after Respondent completed the job, rotten wood remained in place. The replacement of the rotten wood was noted in both red tags. Respondent never attempted to correct this deficiency. On the day the property initially passed inspection, March 3, 1987, Respondent called Mrs. Kilgore and requested the remaining $1,000 owed on the contract price. Mrs. Kilgore refused to pay the Respondent since she was dissatisfied with the work and the first red tag had issued. At some point, apparently after the red tag issued in April, Respondent decided that he was not going to get any more money from Mrs. Kilgore. Other than asking for the money on March 3, 1987, Respondent has not attempted to collect the remainder of the money from Ms. Kilgore; however, he has also not attempted to correct the code violations and other deficiencies. Since Respondent did not collect the remainder of the money owed, Respondent did not pay Leroy Rison, and Mr. Rison did not pay the laborers who performed the work. As the contractor on this job, Respondent had full responsibility for ensuring that the work was done properly and that the roof passed final inspection. Respondent failed to supervise the work on the job, and the re- roofing was not done in a workmanlike manner. In essence, Respondent abdicated his responsibilities as the contractor on the job, and allowed the work to be performed by unsupervised unlicensed persons. The roofing material used was supposed to be fiberglass shingle guaranteed for 20 years. There was no evidence presented that something other than the material specified was used or that the shingles were not installed in accordance with the manufacturer's specifications. The roof did not leak after the work was completed. No evidence relating to a guarantee, other than the guarantee related to the shingles, was presented. Respondent has previously been disciplined by the Construction Industry Licensing Board. On September 10, 1986, a 61 paragraph Administrative Complaint was filed against Respondent which alleged, among other things, willful violation of local law; failure to qualify a firm through which he was operating; gross negligence, incompetence, misconduct, fraud, or deceit in the practice of contracting; failure to discharge supervisory duties as a qualifying agent; and aiding and abetting an unlicensed person to evade the provisions of Chapter 489. On March 26, 1987, Respondent signed a stipulated settlement with the Department of Professional Regulation admitting to all the allegations set forth in the Administrative Complaint. The stipulated disposition was that Respondent's licensure would be suspended for two years and indefinitely thereafter until an administrative fine in the amount of $3,000 was paid. The stipulation was adopted by Final Order of the Construction Industry Licensing Board rendered June 9, 1987.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered revocation of Respondent's license as a registered roofing contractor. DONE and ORDERED this 25th day of October, 1988, in Tallahassee, Florida. DIANE A. GRUBBS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 25th day of October, 1988. APPENDIX The following constitutes rulings on the Petitioner's Proposed Findings of Fact. 1.-4. Accepted, generally except the date of February 26, 1987 appears to be the appropriate date, rather than February 7, 1987, in that the estimate from Larry Rison was obtained one day before the contract was entered into with Respondent. Accepted, generally. Accepted as true, but unnecessary and irrelevant, since Rison and Terrell did not enter into a contract for the job. 7.-14. Accepted. 15. Accepted as true; however, the last two sentences were considered unnecessary. 16.-19. Accepted, generally. First sentence accepted, sentences two and three rejected as irrelevant to the issues in this case. Rejected as redundant and for the reasons set forth under Proposed Finding of Fact No. 6. First sentence rejected as not supported by the evidence, second sentence accepted, except as to Respondent's intent. Third and fourth sentences accepted in general. COPIES FURNISHED: Belinda H. Miller, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Francis A. Park 6109 South MacDill Avenue Tampa, Florida 33611 Lawrence A. Gonzalez Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Bruce D. Lamb, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201
The Issue The central issue in this case is whether Respondent is guilty of the violations alleged in the amended administrative complaints.
Findings Of Fact Based upon the testimony of the witnesses and the documentary evidence received at the hearing, I make the following findings of fact: At all times material to the allegations, Respondent, Ruth Ogen, was a licensed roofing contractor, license no. CC CO27471. A. R. Ogen Construction, Inc. was qualified by the Department as a roofing contractor. Respondent is the sole qualifier and licensee associated with the company, A. R. Ogen Construction, Inc. Respondent is married to Avraham Ogen who presents himself as the president of A. R. Ogen Construction, Inc. On or about November 9, 1986, A. R. Ogen Construction, Inc. doing business as Ogen Roofing & Waterproofing entered into a contract with Ardee Yuran to replace the entire roof of a commercial structure located at 14951 N.E. 6th Avenue, North Miami Beach (6th Avenue). The contract provided, among other things, that the top row of tiles around the parapet wall would be removed and reinstalled upon completion of the roof. In negotiating the contract described in paragraph 4, Mrs. Yuran was mindful of the work Avraham Ogen had performed at her residence. Mr. Ogen had supervised the reroofing of Mrs. Yuran's residence which had been satisfactorily performed. The residential job had required the removal of the tiles along the parapet wall and Mrs. Yuran expected the same process would be utilized in completing the commercial roof. The purpose intended to be accomplished by removing the tiles was to allow the roofers to extend the roofing materials up the sides of the parapet and over the crest. The roofing material is then sealed to the wall and the tiles replaced. This procedure results in a waterproof barrier so that when rain accumulates on the flat roof (and the water level rises) it cannot seep through the sealed perimeter. During the time Mr. Ogen was negotiating and performing the roof work for the 6th Avenue building, he was also retained to paint the structure (which was to be completed after the roof was finished). There came a time when Mrs. Yuran and Mr. Ogen disagreed regarding aspects of the roof work and the painting that was to be done. Eventually, the parties reached an impasse where neither was willing to concede: Mr. Ogen was not willing to perform the work as specified by Mrs. Yuran, Mrs. Yuran was not willing to pay Mr. Ogen any more on the contracts. At this point, Ruth Ogen, Respondent, had not been involved in the daily work progress made at the site. To make matters worse, a leak developed at the 6th Avenue property which resulted in a waterfall pouring down through the overhang of the building. As a result of the disagreement, both parties retained lawyers and, understandably, the issues escalated. Mrs. Yuran retained three individuals to review the work performed by Mr. Ogen. On March 4, 1987, Walter H. Scott, Scott Roofing & Repair, Inc., determined that water accumulating on the 6th Avenue roof was draining behind flashing which had not been properly sealed to the perimeter walls instead of running through the outlets. Mr. Scott recommended that the flashing be resealed along the wall. Had the tiles been removed and the work been performed as stated in the contract, the leak would have been avoided. A second licensed roofing contractor, Gary Carruth, Falcon Roofing Co., inspected the property on June 23, 1987, and recommended reflashing the walls along the perimeter of the 6th Avenue building. Mr. Carruth observed that the tiles had not been removed along the wall and that the roofing materials had not been properly sealed along the perimeter. James Rodgers, a consulting engineer performed a third inspection of the roof at 6th Avenue on June 25, 1987. According to Mr. Rodgers, several items of the contract work completed by Mr. Ogen were inadequately performed. Mr. Rodgers found that the pitch pans were not installed properly around the air conditioning units and that the flashing along the parapet wall was not properly completed nor performed as described in the contract. Respondent also retained a licensed roofer to review the work at 6th Avenue. Bill Mathews, Bill Mathews Roofing, completed a roof inspection report on November 21, 1988. According to Mr. Mathews, the flashing along the parapet wall required repair because it had been improperly sealed. Mr. Mathews noted that the top row of tile should have been removed so that flashing could have been taken up and over the parapet wall. Mr. Mathews also noted that the flat roof had buckles or "fish mouths" which should have been corrected as the roof was being installed. Mr. Mathews recommended that the flashing be resealed and that the buckles be cut and sealed with membrane and roofing cement. Finally, Mr. Mathews determined that the pitch pans under the air conditioning units should be filled with an asphalt cold process to prevent further cracking and potential leaks. A final inspection report was completed by Robert B. Hilson, Bob Hilson & Company, Inc., on August 18, 1988. Mr. Hilson is a consultant for the Department and made the inspection at the request of its attorney. Mr. Hilson's findings and recommendations mirrored those suggested by Mr. Mathews. The work performed by Mr. Ogen on the 6th Avenue property did not meet the terms of the contract and did not meet performance standards acceptable in the roofing industry. Mr. Ogen failed to properly seal all flashing materials along the parapet wall, failed to correct the buckles or "fish mouths," and failed to meet the contractual obligations (removing the tiles and extending the flashing over the crest). Because of the substandard work, Mrs. Yuran incurred additional expenses and inconvenience. Respondent did not view the 6th Avenue structure either before or during the time that her husband supervised the work performed. Respondent's role with the company was as secretary, bookkeeper, and office manager. Mr. Ogen supervised or performed all work at the 6th Avenue job. Respondent did not supervise Mr. Ogen or the workers under his supervision. "Ogen Roofing & Waterproofing" has not been qualified by the Department as a roofing contractor. On or about April 28, 1987, A. R. Ogen Construction, Inc. was requested to perform a roofing inspection at 1180 N.E. 204 Terrace. The subject property was under contract for sale and was ultimately purchased by Rose Zenar. According to the inspection report filed by Mr. Ogen, the roof and roof covering were in satisfactory condition with no evidence of leaks. Mr. Ogen signed the inspection report as president of A. R. Ogen Construction, Inc., state license no. CC CO27471. During the first rain after she had moved into the house, Mrs. Zenar observed water leaking through the ceiling into the kitchen. She immediately called Mr. Ogen who came out, observed the problem, but did not repair the leak. Mr. Ogen did not return Mrs. Zenar's subsequent calls. Ultimately, she contacted James Rodgers to perform a second roof inspection. As a result of Mr. Rodgers' inspection, Mrs. Zenar discovered that the leak was of long duration as it had completely rotted and decayed the roof rafters and sheathing in the area of the leak. Mr. Rodgers took pictures of the area which clearly showed the discolored wood. Evidence of the discoloration was visible from the attic entrance located in the garage adjacent to the kitchen. Mr. Ogen's failure to discover the rotted roof was due to an inadequate inspection of the crawl space between the ceiling and the roof rafters. It is the normal practice of qualified roof inspectors to examine the crawl space between the ceiling and roof supports. Respondent did not perform the roof inspection at Mrs. Zenar's home, did not supervise the inspection performed by Mr. Ogen, and did not have a checklist of items to be reviewed by him in making the inspection. The erroneous inspection performed by Mr. Ogen resulted in expenses and inconvenience to Mrs. Zenar.
Recommendation Based on the foregoing, it is RECOMMENDED: That the Department of Professional Regulation, Construction Industry Licensing Board, enter a final order finding the Respondent guilty of the violations set forth above and, based upon the penalties recommended by rule, impose an administrative fine against the Respondent in the amount of $3000.00 DONE and RECOMMENDED this 20th day of April, 1989, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of April , 1989. APPENDIX RULINGS ON PETITIONER'S PROPOSED FINDINGS OF FACT: Paragraphs 1 through 7 are accepted. With the correction to reflect Mrs. Yuran not Mr. Yuran, paragraph 8 is accepted. Paragraphs 9 through 12 are accepted. Paragraph 13 is accepted. Paragraph 14 is accepted with the correction that the witness' name was Gary Carruth. With the deletion of the last paragraph of paragraph 15 which is rejected as argument or comment, the first five paragraphs of paragraph 15 are accepted. Petitioner is warned not to subparagraph statements of fact or to restate testimony, but to simply set forth the fact deduced from such testimony. Paragraph 16 is rejected as irrelevant or immaterial. Paragraph 17 is accepted to the extent that it finds the reroofing work performed on the 6th Avenue building was a poor quality which was not done under the supervision of a qualified, licensed roofing contractor. Further, it was gross negligence not to properly supervise the job. No conclusion is reached as to whether Respondent is able to supervise a job. Paragraph 18 is accepted. Paragraph 19 is rejected as a recitation of testimony. Paragraphs 20 through 24 are accepted. Paragraphs 25 through 31 are accepted. Paragraph 32 is accepted. Paragraph 33--none submitted. With regard to paragraph 34, the first sentence is accepted. The remainder is rejected as conclusion of law, argument, or comment. Paragraph 35 is rejected as irrelevant. Paragraphs 36-38 are accepted. Paragraph 39 is rejected as comment, irrelevant, or recitation. The first two sentences of paragraph 40 are accepted, the remainder is rejected as comment, conclusion of law, or argument. Paragraph 41 is rejected as irrelevant, conclusion of law, or argument. RULINGS ON RESPONDENT'S PROPOSED FINDINGS OF FACT: Paragraph 1 is accepted. Paragraph 2 is accepted but is irrelevant. Paragraph 3 is accepted. Paragraph 4 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 5 is accepted. Paragraph 6 is rejected as irrelevant to the issue of whether a competent inspection was performed. Paragraph 7 is rejected as irrelevant or unsupported by the record. Paragraph 8 is accepted. Paragraph 9 is accepted. Paragraph 10 is rejected as contrary to the weight of the credible evidence presented. Paragraph 11 is rejected as argument, speculation, or unsupported by the record. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument, irrelevant, or unsupported by the weight of credible evidence. Paragraph 14 is rejected as argument, irrelevant, or comment. Paragraph 15 is accepted but is irrelevant. Paragraph 16 is rejected as argument. Paragraph 17 is accepted but is irrelevant. Paragraph 18 is rejected as irrelevant, argument, or unsupported by this record. Paragraph 19 is rejected as irrelevant. The following are rulings on case no. 88-1776 as submitted by Respondent: Paragraph 1 is accepted. Paragraph 2 is rejected as unsupported by the record. Paragraph 3 is rejected as irrelevant. Paragraph 4 is accepted but is irrelevant, immaterial. Paragraph 5 is rejected as unsupported by the record. Paragraph 6 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 7 is rejected as unsupported by the weight of credible evidence. Paragraph 8 is rejected as irrelevant, immaterial, or unnecessary. Paragraph 9 is accepted but is irrelevant. Paragraph 10 is rejected as irrelevant, immaterial or unnecessary. Paragraph 11 is rejected as irrelevant, immaterial or unnecessary. Paragraph 12 is rejected as irrelevant. Paragraph 13 is rejected as argument or unsupported by the weight of the credible evidence. Paragraph 14 is rejected as contrary to the weight of the credible evidence. Paragraph 15 is accepted but is irrelevant. COPIES FURNISHED: Fred Seely Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Bruce D. Lamb General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Elizabeth R. Alsobrook Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
Findings Of Fact Respondent has been a registered roofing contractor at all times material hereto. His license number is RC-0035594. On or about April 26, 1985 Respondent, doing business as Pinellas Roofing Service, contracted with Bausch and Lomb to reroof their plant in Manatee County, at a contract price of $31,150. Respondent admits that at no time material hereto was he licensed to engage in contracting in Manatee County. Pinellas Roofing thereafter began, and partially performed, this job for which it was paid a total of $28,035. Petitioner alleges, and Respondent denies, that Respondent diverted funds received from this job for other purposes, and was thereafter unable to fulfill the terms of the contract with Bausch and Lomb. Petitioner did not present competent substantial evidence in support of this charge. Respondent never completed this job and took no steps to inform Bausch and Lomb that he would not complete the contract or make other arrangements for its completion. He left several thousand dollars worth of material on the roof, exposed, when he walked off this job, and this resulted in these materials being substantially destroyed. During the job, he did not take precautions to assure that the roof did not leak during heavy rainstorms. In fact, on at least three occasions, leaks caused damage to the interior of the plant and Respondent could not be reached. Therefore, Bausch and Lomb had to have another roofing contractor make emergency repairs on June 25, July 15 and September 3, 1985, at a total additional cost of $4,150. Since Respondent did not complete the contract, and left the roof unfinished, Bausch and Lomb contracted on September 17, 1985 with Bernard J. Lozon, Inc., to complete the job, and make certain additional repairs, at a cost of $24,000. In the opinion of Bernard J. Lozon, who was accepted as an expert in roofing contracting, the actual work that was done by Pinellas Roofing was satisfactory. However, Respondent's actions in walking off the job and leaving the roof unattended without completing the job is an unacceptable practice in roofing contracting, and constitutes incompetence and misconduct. Respondent failed to properly supervise this job. He relied upon his son to hire the necessary crews, pay them, handle financial aspects of the job, and assure its completion. His testimony indicates he fails to understand his own responsibility for supervising and completing the work for which he contracted, and which was performed under his license. At no time material hereto did Respondent qualify Pinellas Roofing Service with Petitioner. Respondent failed to apply for and obtain a Manatee County building permit for the roofing job in question, and also failed to request the county building department to perform inspections of the work performed. The Board of County Commissioners of Manatee County has adopted and follows the 1979 edition of the Standard for Installation of Roof Coverings, Southern Building Code, as amended in 1981. This Code requires all contractors performing work in Manatee County to be registered in Manatee County, and to obtain permits for all roof replacements and repairs in excess of $200, as well as obtain inspections of all such work to insure compliance with the Code. Respondent failed to comply with these requirements of the local building code. When Respondent submitted his proposal on April 16, 1985 for the Bausch and Lomb job, he specifically acknowledged, in writing, that "all work (is) to be done according to owner specifications sheet." (Emphasis supplied). At hearing, Respondent contended that when he submitted his proposal he never saw the project specification sheet which was thereafter attached to his contract with Bausch and Lomb and made a part thereof. Rather, he testified that his proposal referred to certain specifications that appeared on project drawings which he reviewed prior to submitting his proposal. After considering the demeanor of the witnesses and all of the evidence presented, and particularly the fact that Respondent referred to the "specifications sheet" and not "drawings" in his proposal, it is specifically found that Respondent had knowledge of, and did in fact submit his proposal based upon the "specifications sheet" which ultimately became a part of his contract. As such, he was bound thereby in the performance of work under this contract. In pertinent part, the "specifications sheet" requires that the contractor obtain all necessary permits from Manatee County, that notice be given to the owner in advance of work that will produce excessive amounts of dust or tar fumes so proper precautions could be taken, that roofing materials be stored in a manner that protects them from damage or adverse weather conditions during construction, and that the contractor provide a two year written guarantee at the conclusion of the job. Respondent failed to comply with these requirements of the specifications.
Recommendation Based upon the foregoing, it is recommended that Petitioner enter a Final Order suspending Respondent's registration for a period of ninety (90) days and imposing an administrative fine in the amount of $1,500. DONE AND ENTERED this 22nd day of April, 1987 in Tallahassee, Florida. DONALD D. CONN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of April, 1987. APPENDIX TO RECOMMENDED ORDER, CASE NO. 86-3698 Rulings on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact 1. Adopted in Finding of Fact 8. 3,4 Adopted in Finding of Fact 2. 5,6 Adopted in Finding of Fact 3, but otherwise rejected as irrelevant and unnecessary. 7,8 Adopted in Finding of Fact 9. Adopted in Finding of Fact 6. Adopted in Findings of Fact 5, 6. Rulings on Respondent's Proposed Findings of Fact: Adopted in part in Findings of Fact 3, 5. Rejected as not based upon competent substantial evidence. Adopted in part in Finding of Fact 3. Adopted in part in Findings of Fact 2, 3. 5-7 Addressed in Findings of Fact 2, 3 and 5. 8,9 Rejected as irrelevant and unnecessary. 10. Adopted in part in Finding of Fact 5. 11,12 Adopted in part in Finding of Fact 6. Rejected as not based upon competent substantial evidence. Adopted in Findings of Fact 5, 6. Adopted in Finding of Fact 6. COPIES FURNISHED: W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750 Michael Schlesinger, Esquire 655 Ulmerton Road Building 11-A Large, Fl 33541 Fred Seely Construction Industry Licensing Board Post Office Box 2 Jacksonville, Fl 32201 Van Poole Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750 Joseph A. Sole, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Fl 32399-0750
Findings Of Fact At all times relevant hereto, Respondent was licensed as a roofing contractor by the Construction Industry Licensing Board, having been issued license number CC CO24406. Respondent contracted with Michael Cirulnick on or about June 21, 1986, to replace his flat tar and gravel roof. The contract was for $900 and provided a five year guarantee against leaks. The City of Sunrise required a permit for this job, having adopted by local ordinance sections 301 et seg. of the South Florida Building Code. Prior to contracting with Respondent, Cirulnick had obtained a bid from Code Three Roofing Company. He did not sign a contract with Code Three and did not know that Code Three had applied for a permit. Cirulnick did not tell Respondent that he already had a permit on the job. Respondent performed the job without obtaining a building permit or inspections. Approximately two weeks after the job was finished, at the first hard rain, the roof began to leak in new areas. After the job, leaks developed twenty-four feet from the valley of the adjoining sloped roof to the right and twelve feet to the left, corresponding to the kitchen sliding door and the dining room sliding door. Cirulnick called Respondent for 6 to 8 weeks before finally reaching him in response to the leaks, at which time Respondent promised to repair them. Respondent claimed that he was contacted approximately two weeks after the job was completed. He blamed the new leaks on the sloped shingle roof and refused to repair them under his guarantee. Cirulnick contacted the City of Sunrise after repeated unfulfilled promises from Respondent that he would attend to the problem. When Cirulnick learned that no permit or inspections had been obtained, he contacted the Department of Professional Regulation. In 1987, in response to Cirulnick's complaints, Respondent sent Walter Harris, who told Cirulnick he was with "American Roofing". He told Cirulnick that the problem was with the way the flat roof was tied into the sloped roof, and called the job "terrible." He made repairs to the tie-in where the flat tar and gravel roof connected to the sloped shingle roof, which repairs stopped the leaks over the living and dining room sliding doors, but not the leak by the kitchen doorway beneath the area where the valley of the sloped roof ties in with the flat roof. Respondent obtained a permit and final inspection based upon his affidavit filed with the City of Sunrise in December of 1987, 1-1/2 years after he completed the Cirulnick job. Eugene Gardner, Building Official for the City of Sunrise, had inspected the Cirulnick roof when the shingle roof had been installed. This was shortly before Cirulnick purchased the property. When Gardner was there, there was no black roof cement in the valley of the sloped shingle roof. Cirulnick examined the roof both before and after Respondent worked on the roof. The black substance over the shingles was put there by Respondent. The leaks which developed after Respondent finished the job related directly to the areas where the flat roof joins or ties into the sloped shingle roof. Leaks developed in both the kitchen and dining eating areas, by the sliding glass doors. These are situated where the flat and sloped roofs meet. The leaks continued from June of 1986 until Walter Harris was sent out to do repairs, approximately February of 1987. His repairs stopped these leaks but not the leak in the kitchen doorway, situated under the area where the valley in the sloped roof joins the corner of the flat roof. That leak still exists. Petitioner called Robert Hilson as its expert. Respondent called Kirk Keuter. Both experts examined the roof in May of 1988. Keuter found the work to be within professional standards and blamed the leaks on the shingle roof valley. He was unable to explain the cause of the leaks. He testified that "As near as I can ascertain" the base sheet of the flat roof was properly tucked under the existing old material on the sloped shingle roof. He admitted that the leaks complained of by Cirulnick were coming from the valley which tied into the flat roof, but claimed that the leaks were above the tie-in. Although Walter Harris admitted making repairs well after the original job was done, Keuter claimed that had repairs been made after a couple of months from the original work, he would have been able to detect them. Yet, Keuter failed to see the repairs made by Walter Harris in approximately February of 1987. The testimony of Hilson was persuasive. In comparison with Keuter's eight years of experience, Hilson has been in the roofing business for 25 years and has been the chairman of various technical and roofing code committees. He was able to determine that the shingle roof had been applied over the original shingle roof, a fact which came out at the hearing during the testimony of the Sunrise Building Official, Eugene Gardner. He was also able to explain why the roof leaked after Respondent replaced the flat roof. The flat roof was not properly tied into the sloped roof, allowing water to run under the roofing material where the two roofs joined. Additionally, the black cement Respondent had placed above the shingles in the valley of the sloped roof in the corner where the flat roof joined the sloped roof was trapping water, causing water pockets to form, from which leaks developed. This explanation is consistent with the history of the leaks. They developed only after the flat roof was replaced. The leaks coming from the tie- in stopped when Walter Harris made his repairs. The leaks originating from the valley came from the black cement which was improperly applied above the shingles in the valley. Wayne Roper was called by Respondent to testify that he saw areas of leak damage in the kitchen and back porch. He hesitantly remembered damage in the dining area as well. However, this testimony had little meaning since the entire shingle roof had been replaced shortly before Cirulnick purchased the property. There was no evidence as to the cause of or age of the interior damage described by Roper. Respondent failed to respond to the complaints of the homeowner until the Department of Professional Regulation and the City of Sunrise got involved. Cirulnick had been calling Respondent for over a month and a half. When (and if) Respondent did look at the job, he blamed the new leaks on the shingle roof and refused to repair any of them under his guarantee. Although he sent Walter Harris out to make repairs in approximately February of 1987, he did not repair the leaks associated with the water pocketing in the valley of the sloped roof where he had placed the black roof cement. Despite Respondent's contractual guarantee, the leaks in the kitchen emanating from the area where the valley ties into the flat roof, were not repaired. Respondent entered into a contract with Rolden W. Jones in April of 1986 to repair several leaks at his house and recover the breezeway between the house and garage for $750. The Jones house was located in Delray Beach. In Delray Beach, any roofing contractor must hold an occupational license. Respondent did not hold an occupational license in Delray Beach under his own name or "American Roofing". A permit was required for this job under the applicable building code and ordinances then in effect. Respondent did not obtain a permit or call for inspections for the Jones job. Respondent told Jones that Respondent held a "tri- county license" and was authorized to work and pull permits in the City of Delray Beach. Respondent operated under the name "American Roofing", which appears prominently on his contract with Jones. Respondent never placed "American Roofing" on his license or otherwise qualified said company. Before Respondent commenced work on the residence, and pursuant to the agreement between Jones and Respondent, Jones took off the existing tar paper but did not remove the nearby tile. Respondent began the job by tearing off the garage roof tile by the breezeway and putting down new tar paper. He did not repair the leak at the northeast corner of the house or by the front door. The leaks persisted with the rain since they had not been repaired. In response to Jones' calls Respondent did come out one time to place some compound on the roof to help stop the leaks, but thereafter failed to return to finish the job. Jones paid Respondent $500 the day Respondent commenced working. Jones never paid Respondent the additional $250 called for by their contract since Respondent failed to return to complete the job and failed to return Jones' phone calls or to claim the registered letter Jones sent to him. Respondent admitted that he did not finish the job, stating: "Because it was not real high priority, undoubtedly, I didn't give it priority." E. J. Brodbeck & Sons, Inc., finished the work on Jones' roof for a cost of $1077.65. Michael Brodbeck, who performed the work, found that the only area which had been worked on was the breezeway. He found the job incomplete. On September 25, 1986, Andrew Jackson, an unlicensed contractor doing business as Jackson Renovation Enterprises, entered into a contract with a company known as Madco. The contract was for $7,000 to install a new roof system on the roof of a commercial building owned by the company. Respondent knew that Jackson was not a licensed roofing contractor. Jackson had previously made an arrangement with Respondent whereby Jackson would pay the cost of permits and 10% of the contract price to Respondent in return for having his company qualified by Respondent and having Respondent pull the necessary permits. Respondent's only duty was to pull the permit. Pursuant to this arrangement Jackson contacted Respondent and, in Respondent's words, told him "I got a $7,000 contract and let's go ahead and do it." Respondent obtained the building permit. He listed the owner as "Jackson" and the job as "roof repairs & coating" for $6,500. On one occasion Respondent went to the job site. While he was there, he took a photograph of Jackson installing Madco's new roofing system. Respondent did not supervise or in any way participate in installing Madco's roofing system. The president of Madco, Samuel Weiss, dealt only with Andrew Jackson. Until a few months prior to the final hearing he had no knowledge of Respondent, never having met with or heard of him. After the roof was installed by Andrew Jackson it consistently leaked, in one instance causing a fire and major damage. In accordance with the understanding between Respondent and Jackson, Jackson paid Respondent the cost of the permit fee plus 10% i.e., $700.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered revoking Respondent's roofing contractor's license number CC C024406. DONE and RECOMMENDED this 25th day of January, 1989, at Tallahassee, F1orida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of January, 1989. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 87-4392, 87-4393, 87-4398 Petitioner's proposed findings of fact numbered 2- 19, 23-30, and 37-43 have been adopted either verbatim or in substance in this Recommended Order. Petitioner's proposed finding of fact numbered 44 has been rejected as being subordinate. Petitioner's proposed findings of fact numbered 1, 20-22, 31-36, and 45-47 have been rejected as not constituting findings of fact. Respondent's first, second, ninth, eleventh, twelfth, fifteenth, and sixteenth unnumbered paragraphs have been rejected as being contrary to the weight of the credible evidence in this cause. Respondent's third and fourth unnumbered paragraphs have been rejected as being subordinate. Respondent's fifth, sixth, seventh, thirteenth and seventeenth unnumbered paragraphs have been rejected as not being supported by the weight of the credible evidence in this cause. Respondent's eighth, tenth, fourteenth, and eighteenth unnumbered paragraphs have been rejected as not constituting findings of fact. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Michael J. Cohen, Esquire 517 Southwest First Avenue Fort Lauderdale, Florida 33301 George W. Harrell, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Office of the General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 John C. Moppert, Esquire 7491 West Oakland Park Boulevard Suite 207 Lauderhill, Florida 33319
Findings Of Fact Respondent is Richard McDougal, holder, at all times pertinent to these proceedings, of registered roofing contractor license no. RC 0050466. Petitioner is the Department of Professional Regulation, Construction Industry Licensing Board, the state agency charged with the regulation of contractors in the State of Florida. Respondent was the qualifying agent for D & R Roofing Co., at all times pertinent to these proceedings. On July 31, 1989, Arla Jackson signed and accepted Respondent's written proposal to re-roof a house belonging to Jackson, located in Washington County, Florida. Prior to engaging Respondent to re-roof the house, Jackson had only a minimal amount of leakage in a couple of corners inside the house. Under the terms of the written proposal provided by Respondent to Jackson, Respondent agreed to remove the old roof covering from the structure; install a new three ply fiberglass felt covering; install new eave metal around the roof perimeter; extend the roof a short distance at one end; and top coat a utility building on the premises. Further, Respondent agreed to haul away debris resulting from the job. Completion of the roofing project by Respondent and receipt of payment from Jackson in the amount of $3,000 occurred on August 9, 1989. $2,900 of this amount was payment to Respondent for replacing the old roof while the remainder satisfied charges by Respondent for additional work required to extend the roof. Shortly after Respondent's completion of the roof replacement, Jackson began to telephone Respondent, requesting that he come and repair holes in the roof that were leaking water as the result of rain. Respondent came to Jackson's house on at least three occasions to attempt to stop leaks in the roof. He eventually determined that he had stopped the leaks and told Jackson that, as far as he was concerned, there was no roof leakage problem. Jackson's flat roof continued to leak. Eventually, Gus Lee, an unlicensed roofing assistant to H.M. Strickland, a local licensed contractor, agreed to repair her roof and eliminate the leakage problem. Strickland's signature appears with Lee's on written documentation bearing the date of October 1, 1989, and promising a "fine roof with no leaks; and I will stand behind it." Jackson accepted the Strickland offer. Jackson paid approximately $1,925.00 to Lee for work in connection with replacing the roof and painting the interior ceiling of the house. She paid an additional $653.79 for building supplies in connection with the project. Overall, Jackson paid approximately $2,578.79 for labor and materials to re-roof her house and repair the interior ceiling damage resulting from the leakage. This amount was in addition to the amount previously paid to Respondent. On October 20, 1989, Lee, the unlicensed assistant to Strickland and the person who actually undertook the task of re-roofing Jackson's house, removed the previous roofing material placed on Jackson's house by Respondent. Lee observed no fiber glass felt covering material on Jackson's roof at the time he re-roofed the house. Lee's testimony at hearing was credible, candid and direct. Although unlicensed as a contractor, Lee's attested experience supports his testimony regarding what he observed and establishes that Respondent failed to comply with his agreement to Jackson to provide fiber glass felt during the initial roofing of the house and instead used a less expensive material. Lee's testimony, coupled with that of Jackson and Lee's son, also establishs that significant damage had occurred to the interior ceiling of Jackson's house as the result of leakage after completion of work by Respondent. After Lee completed the re-roofing of Jackson's home, inclusive of use of a six ply felt covering on the roof accompanied by pea gravel and sealant, the roof's leakage stopped.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that a Final Order be entered imposing an administrative fine of $1500 upon Respondent's license as a registered roofing contractor. DONE AND ENTERED this 25th day of November, 1991, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Fl 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of November, 1991. APPENDIX TO RECOMMENDED ORDER The following constitutes my specific rulings, in accordance with Section 120.59, Florida Statutes, on findings of fact submitted by the parties. Petitioner's Proposed Findings. 1.-4. Adopted, though not verbatim. 5.-8. Subordinate to Hearing Officer's Conclusions. 9.-11. Adopted in substance, though not verbatim. Respondent's Proposed Findings. None submitted. COPIES FURNISHED: Robert B. Jurand, Esq. Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, FL 32399-0792 Richard McDougal Box 10277 Panama City, FL 32404 Daniel O'Brien, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, FL 32201 General Counsel Department of Professional Regulation The Northwood Centre, Suite 60 1940 N. Monroe St. Tallahassee, FL 32399-0750
The Issue Whether Mr. Masiero is guilty of gross negligence in reroofing work he performed, and misconduct by failing to honor a guarantee given in connection with that work?
Findings Of Fact Mark Masiero was the qualifying agent for All Florida Roofing Company. Mr. Masiero entered into a contract, on behalf of All Florida Roofing Company, with Cristobal Sotolongo of Miramar, Florida, on January 19, 1987 According to the contract Mr. Masiero would [r)emove the roof at the address above down to wood sheathing or smooth, workable surface and haul all debris away (Department Exhibit 1) and install a hot tar roof on a flat deck. The company further gave a guarantee which read: The company guararitees its workmanship for ten years. It will replace faulty materia1 or faulty workmanship within the period of the guarantee free of charge (Department Exhibit 1). Mr. Sotolongo paid $700 at the time the contract was executed. The total price was to be $2,500. Mr. Sotolongo thereafter paid All Florida Roofing Company an additional $1,600. Mr. Sotolongo received a job invoice from All Florida Roofing Company signed by Mark Masiero on March 14, 1987, showing payment in full for the roofing work. Two hundred dollars had been deducted from the contract price for damage done to a patio screen and popcorn ceiling at the Sotolongo residence during the roofing work. After the work was completed, Mr. Sotolongo had a leak in his bedroom. Mr. Masiero returned and put some tar on the roof, but it still leaked. As a result of the leak Mr. Sotolongo lost the ceiling in the bedroom. He called Mr. Masiero repeatedly in an attempt to have the leak repaired and ultimately retained a lawyer, Steven M. Rosen, who wrote to All Florida Roofing Company on Mr. Sotolongovs behalf to complain about the failure to honor the guarantee and perform remedial work. After he received no reply to his lawyer's letter from Mr. Masiero or All Florida Roofing Company, Mr. Sotolongo received estimates for roof repairs from a number of roofers, including Professional Roofing, Inc. of Hollywood, Florida, Pioneer Roofing Company, Inc. of Hollywood, Florida, Universal Roofing, Inc. of Hollywood, Florida, and Gory Roofing, Inc. of Hollywood, Florida. A roof inspection was also provided by Gory Roofing. The reroofing was done by Gory Roofing, Inc. at a cost of $1,500. The problem with the roofing work done by All Florida Roofing Company and Mr. Masiero was that the work did not conform to the contract, in that the old roof had not been removed down to the wood sheathing or to a smooth workable surface. The old roof had been a tar and gravel roof. Lengths of 2 x 4 lumber had been placed around the perimeter of that roof and 1 1/2" to 2" of concrete had been poured on that old roof; the old tar and gravel roof had been placed over the concrete. Mr. Masiero and All Florida Roofing Company had not removed the underlying concrete roof or an older tar and gravel roof below it. This caused the leaking. The repair work done by Gory Roofing, Inc. included removal of the old roofing system, and application of a new roof. After that work, there have been no leaks from the roof.
Recommendation It is recommended that Mr. Masiero be found guilty of violations of Section 489.129(1)(j) and (m), and that he be fined $2,250. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 23rd day of March, 1990. WILLIAM R. DORSEY, JR. Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 23rd day of March, 1990. COPIES FURNISHED: Robert G. Harris Department of Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792 Mark Masiero 6631 Southwest 26th Court Miramar, Florida 33023 Kenneth D. Easley, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792 Fred Seely, Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32202
Findings Of Fact Joseph Barrass is a registered roofing contractor holding State of Florida license number RC0026890. Respondent was so licensed at all times relevant to this proceeding. Respondent began doing business as a registered roofing contractor through his corporation, J. B. Roofing and Repairs, Inc., about six years ago. This corporation was dissolved and he continued as a roofing contractor through a corporation known as Roofing Services, Inc. He next did business through a third corporation, C. B. Roofing, Inc. Most recently he has done business as C. B. Roofing, a sole proprietorship. Respondent failed to register any of these entities with Petitioner, and is still licensed under his original fictitious name, J. B. Roofing and Repairs. Respondent contracted with Green Glades Construction Co. in early 1979, to install roofs on some 28 new houses. A dispute arose between the parties regarding several unfinished and leaking roofs. Respondent contends he refused to complete the roofs at issue due to nonpayment in accordance with the oral contract. He also argues that he was unable to repair the leaks while the roofs were wet, as demanded by Green Glades. The dispute was settled through civil proceedings. Another matter which culminated in civil action concerned the installation and repair of a patio roof pursuant to an oral contract between Respondent and Marvin Berkowitz, at the latter's Coral Springs residence. Berkowitz complained that Respondent failed to correct a leak in this roof as required by their agreement. Respondent claims the leak was the result of an improperly installed ceiling fan and the flat roof design demanded by Berkowitz. Respondent completed the job and received final payment on October 9, 1979. However, the roof leaked and Berkowitz thereafter contacted Respondent on numerous occasions requesting repairs. It was not until Berkowitz retained counsel and threatened legal action that Respondent made any effort to repair the leak. He returned on February 14, 1980, and did limited repair work. The roof continued to leak and Berkowitz sought damages through civil action. The evidence is conflicting as to whether or not the ceiling fan had been removed when Respondent returned in February, 1980. Berkowitz testified that it had been removed, and Respondent testified that it had not. The evidence is also in conflict with respect to the caveats and/or assurances Respondent gave Berkowitz regarding this installation. The recollections of both witnesses were self-serving and their testimony was generally lacking in credibility. The City of Coral Springs' building code requires a contractor to obtain a permit prior to roof installation. Respondent knew he was required to obtain such a permit for the Berkowitz project, but failed to do so.
Recommendation From the foregoing, it is RECOMMENDED: That Respondent be found guilty of violating Sections 489.119, 489.129(1)(g) and 489.129(1)(j), F.S., in failing to register his business entities and contracting without requisite qualification. It is further RECOMMENDED: That Respondent be found guilty of violating Subsection 489.129(1)(d), F.S., for wilful disregard of the Coral Springs building code pertaining to building permits. It is further RECOMMENDED: That all other charges against Respondent be dismissed. It is further RECOMMENDED: That Petitioner suspend Respondent's roofing contractor's license for a period of six months. DONE AND ENTERED this 17th day of February, 1982, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 17th day of February, 1982.
The Issue Whether Respondent committed the offenses set forth in the administrative complaint and, if so, the penalty which should be imposed.
Findings Of Fact At all times material to this case, the Respondent, Harry Bradshaw, was licensed as a registered roofing contractor in the State of Florida, holding license number RC 0033812. On August 26, 1986, Respondent's license as a registered roofing contractor was suspended by Petitioner. Respondent's license remained suspended at all times material to this case. On December 16, 1987, Respondent contracted with the Moose Lodge located in Hialeah, Florida, to reroof the Moose Lodge building. The proposal submitted by Respondent contained representations that Respondent was licensed as a registered roofing contractor and that he was insured. Respondent knew that his license as a registered roofing contractor was under suspension. Respondent had no insurance. The contract between Respondent and the Moose Lodge provided that Respondent would perform the work and supply the materials for the sum of $6,200.00. The sum of $3,200.00 was paid to Respondent in advance of his beginning the job. Respondent used the sums advanced to purchase materials and supplies. The remaining $3,000.00 was to have been paid upon Respondent's completion of the job. During the negotiations that resulted in the contract between Respondent and the Moose Lodge, Respondent represented that the job should be completed in time for the functions scheduled for New Year's Eve. While Respondent had purchased the materials needed for the job and had done a substantial amount of work on a portion of the roof, he was unable to complete the work by the New Year. Respondent was ordered to stop work on the job on January 26, 1988. Respondent did not abandon the job. Although he was slow in performing the work, a part of Respondent's delay in performance was caused by rain. There was no evidence as to what would have been a reasonable period of time for Respondent to have completed the job. On January 26, 1988, the administrator for the Moose Lodge complained to the Building Inspection Department for the City of Hialeah, Florida, because the administrator was not pleased with the progress that Respondent was making toward completion of the job. The administrator was told by a representative of the Building Inspection Department on January 26, 1988, that Respondent had no license and that the required permit had not been pulled. The administrator was told to prohibit Respondent from working on the roof. Immediately thereafter, the administrator instructed Respondent to do no further work on the roof. The members of the Noose Lodge completed the job started by Respondent for less than $3,000.00, the balance of the amount that would have been owed Respondent if he had finished the job. Respondent knew that a permit was required for this work. Respondent also knew that only a licensed roofing contractor could pull the required permit. Respondent proceeded with the job when he was unable to persuade a licensed roofing contractor to pull the permit for him. Petitioner filed an administrative complaint against Respondent alleging that at the time he contracted with the Moose Lodge, Respondent's license was suspended, thus violating the provisions of Section 489.129(1)(j), Florida Statutes, and the provisions of Section 489.127(1)(e), Florida Statutes. The administrative complaint also alleged that Respondent failed to perform in a reasonably timely manner and/or abandoned the job in violation of Section 489.129(1)(m), Florida Statutes, and Section 489.129(1)(k), Florida Statutes. Respondent denied the allegations of the administrative complaint and timely requested a formal hearing. This proceeding followed. Respondent was previously disciplined by the Construction Industry Licensing Board, and his license remained under suspension at the time of the final hearing.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered finding Respondent guilty of having violated Section 489.127(1)(e), Florida Statutes, and Section 489.129(1)(j), Florida Statutes. It is further recommended that the final order revoke Harry Bradshaw's license in the State of Florida as a registered roofing contractor. DONE and ENTERED this 31st day of October, 1989, in Tallahassee, Florida. CLAUDE B. ARRINGTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 31st day of October, 1989. COPIES FURNISHED: Harry Bradshaw 5590 East Seventh Avenue Hialeah, Florida 33013 David M. Gaspari, Esquire Adams, Coogler, Watson & Merkel, P.A Suite 1600 NCNB Tower 1555 Palm Beach Lakes Boulevard West Palm Beach, Florida 33402-2069 Kenneth E. Easley, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seely, Executive Director Department of Professional Regulation Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201
