Findings Of Fact At all times material hereto, Respondent was the holder of general contractor's license number CG C007235, and certified residential contractor's license number CR C006769. On or about January 6, 1976, Respondent entered into a Building Agreement with Walter and Ellen Scott (hereinafter "owners") for construction of a residence to be located at 10244 Deerwood Club Road in Jacksonville, Duval County, Florida. Among the provisions contained in this agreement was the following: [Respondent] will construct house for actual Construction Costs plus $10,000 profit. Addendum to contract Number 19 contains construction estimate sheet and allowance sheet which is guaranteed by [Respondent] not to exceed $85,000, plus $10,000 profit. All construction costs above $85,000 will be absorbed by contractor resulting from faulty workmanship or incorrect overall estimate. Additional costs resulting from exceeding allowances or phases not covered by estimate, (Wallpaper, Light fixtures, etc.), will be paid by purchaser. [Respondent] will be compensated at $2,500.00 out of each of the last four construction draws. Purchaser will be refunded in difference of construction under $85,000.00. Purchaser has the right to examine cost of construction at any stage to determine how close cost [sic] are running to estimate. (Emphasis added.) In addition, the Building Agreement contains a listing of allowances for various items such as carpet, flooring, wallpaper, doors, fireplaces, appliances, plumbing fixtures, wiring and windows. These provisions of the contract deal with standard items to be included in the construction, absent some request and agreement between the parties to specific changes. With respect to changes, the agreement provides specifically that: Should the Purchaser at any time during the progress of said residence require any alterations to or deviations from, additions to, or omissions, in said Agreement, which are acceptable to the Contractor, they shall have the right and power to make such change or changes when practicable, and the same shall in no way make void the Agreement; but the differences shall be added to, or deducted from the amount of the Agreement as the case may be, by a fair and reasonable evaluation . . . (emphasis added.) Finally, the Building Agreement also provides that Respondent was to use his best effort to deliver the completed residence on or about 180 days from the start of construction, which, by terms of the agreement, is defined as the date on which footings are poured or the day rough plumbing was begun. Although Respondent obtained a building permit for construction of the residence, from the City of Jacksonville, Florida, dated February 5, 1976, there is nothing in the record of this proceeding on which a firm determination can be made as to when construction actually started. Although the actual starting date for construction is unclear, it is obvious from the record that Respondent and the owners began to experience problems from the outset. The owners received a notice of lien soon after the slab for the residence was poured. In addition, there appears to have been some miscalculation with respect to the size of the slab for the structure to which some additions had to be made. Respondent apparently failed to pay for the initial treatment for subterranean termites at the time of the pouring of the slab, and the termite bond on the residence was cancelled. In addition, the slab appears to have been poured in such a fashion as to require adjustments in the construction of the driveway to avoid rainwater runoff entering the residence. One of the more difficult problems in the initial stages of construction involved leaks in the roof of the structure. When it appeared that efforts to repair the leaks had not been entirely successful, the owners requested that Respondent delay work on the interior in order that repairs on the roof might be accomplished before proceeding in order to avoid interior damage. After an extended delay occasioned by an unusual period of dry weather which prevented a determination as to whether the roof would continue to leak, work on the interior was recommenced, only to discover that the roof had not been sufficiently repaired. As a result of continuing problems with the roof, work which had been completed in the interior of the structure was damaged by rainwater. In fact, as of the date of final hearing in this cause, it appears that final repairs to the roof had still not been accomplished. It appears from the record that construction delays attributable to roof leaks in the residence set the tone for the remainder of the business dealings between Respondent and the owners. From this point forward, the relationship between Respondent and the owners became virtually adversary in tone. This state of affairs was complicated by an extensive series of changes or substitutions in the original plans and specifications by the owners. As indicated above, the original Building Agreement contained provisions concerning allowances for various portions of the work, and optional items which could be added at additional charge to the owner. Unfortunately, the record is unclear as to exact dollar amounts attributable to extras selected by the owners, as well as to amounts actually received by Respondent in the course of construction draws on the original contract. However, it is clear that extras selected by the owners totalled between $20,000 and $25,000. These items, which were not contained in the original contract, included ceramic tile flooring; double oven; wooden window frames; extensive extra bricking work, including brick more expensive than that described in the original contract; a larger driveway; burglar alarms; simulated marble vanities, tubs and sinks instead of cast iron fixtures as originally contemplated; crown moldings and interior door moldings throughout the interior of the residence; more expensive plumbing fixtures; extensive parquet flooring; larger closet areas; and extensive changes in the location of plumbing fixtures and electrical outlets. In addition, what appears from the evidence to have been a handmade stairway was substituted at an additional cost of approximately $5,000. The construction of the staircase not only included additional expense, but for some reason not entirely apparent from the record, caused additional delay in construction of other areas in the residence. Respondent apparently did not maintain a separate checking account for construction draws on this project, instead comingling disbursements on the construction loan with other funds in his general checking account. Additionally, no documentation was submitted by either Petitioner or Respondent to establish dates on which draw requests were either submitted by Respondent to the owners or the financial institution financing construction, or the dates on which any such draw requests were funded, either in whole or in part. As a result, it is virtually impossible from the record in this proceeding to determine the basis for disbursements from the construction loan account, or the disposition of those sums once disbursed. Although there was some general testimony about the filing of liens by various subcontractors, no documentation of these liens was submitted into evidence. What is, however, apparent from the record is that in early 1977, almost one year after initial disbursement of construction funds to Respondent, almost the entire $95,000 constituting the construction account was depleted. At that time the residence was approximately 90 percent complete. Thereafter, by Agreement dated February 18, 1977, Respondent and owners agreed that an additional $25,000 would be necessary to complete construction of the residence. Respondent acknowledged that he was in default under the terms of the original Building Agreement, and agreed to reimburse owners for the additional $25,000 needed to complete construction of the residence, subject to certain adjustments. Respondent agreed to complete construction of the residence within 40 days, and further agreed that the financial institution holding the mortgage on the residence was authorized to disburse the additional $25,000 directly to subcontractors, materialmen and laborers for work performed for services rendered on the property. Respondent executed a note in the amount of $25,000, secured by certain property belonging to him as evidence of his obligation to complete construction. However, shortly after execution of the February, 1977, Agreement, Respondent and owners had a dispute over payment of certain laborers. As a result, Respondent was advised by owners not to return to the job site. After this notification, evidence in the record establishes that Respondent contacted the financial institution which held the mortgage on the property and advised them that he would not be completing construction of the residence. It is clear from the record that the owners had more than ample cause for dissatisfaction with both the quality of workmanship and the timeliness with which work was performed by Respondent. Those matters are not, however, at issue in this proceeding. It is also abundantly clear that both Respondent and owners conducted their dealings with one another in a most informal fashion. With the exception of the original Building Agreement, and the February, 1977, agreement, most of the dealings between Respondent and the owners were verbal. Additionally, the absence of detailed documentary evidence makes resolution of many of the factual disputes in this proceeding difficult at best. However, the record clearly establishes that Petitioner failed to request that official notice be taken of any of the provisions of the building codes or other laws of the City of Jacksonville, and that none of these codes or laws were offered into evidence in this proceeding. As a result, a motion to dismiss that portion of the Administrative Complaint alleging violation of applicable building codes was granted by the Hearing Officer at the close of Petitioner's case. Further, although the owner testified as to his belief that certain building materials were "floating" between the project which is the subject of this proceeding and other projects being constructed by Respondent, there is no direct evidence to establish that Respondent, in fact, diverted any funds or property improperly. Finally, as to the question of abandonment, it appears from the record that the owner dismissed the Respondent prior to the expiration of the 40-day period contemplated in the February, 1977, Agreement, and that Respondent advised both the owner and the financial institution financing construction of the project that he would not complete construction of the residence as contemplated in the various agreements between the parties.
Findings Of Fact At the final hearing the following factual allegations contained in the Administrative Complaint were either stipulated to by the parties or not disputed by the Petitioner: The Respondent John W. Rohrback is a certified general contractor having been issued license numbers CC C002372, CG CA 02372, PM 0015083 and RF 0036563. The last known address of the Respondent Rohrback is 10282 N.W. 31st Street, Coral Springs, Florida 33065. The Respondent Rohrback, while doing business as Statewide Insulation and Solar Systems, Inc., failed to initially obtain building permits which are required by ordinance on the following job sites: Mrs. Blanche Nelson, 454 N.E. 4th Street, Boca Raton. Mrs. Dorothy Menzel, 784 N.E. 71st, Lot 27, Block C, Boca Harbor. Work started May 17, 1980. Permit taken out on May 19, 1980. Mrs. Meinhard, 1230 S.W. 7th Street, Lot 6, Block 29, Boca Raton Square. Work started on May 7, 1980. Permit taken out on May 19, 1980. Ms. Mary Greenhauer, 986 S.W. 14th Street, Lot 20, Block 63, Boca Raton Square. Work started on May 3, 1980. Permit issued on May 19, 1980. Although the Respondent Rohrback eventually received the permits for these projects, he also initially failed to obtain a license to do contracting in the City of Boca Raton as required by ordinance. On or about August 11, 1980, the City of Boca Raton Contractor's Board suspended the Respondent Rohrback indefinitely from doing business in the city for: using alternate materials and methods without clearance; not obtaining building permit; not filing a proper permit; and not filing proper proof of a certificate of competency. At the time of the hearing before the local contractor's board, the Respondent Rohrback had settled and obtained releases with two of the listed individuals. He was told to settle the remaining two cases, obtain releases and appear before the local Board at a later date. The Respondent appeared on the designated date and discovered that the Board had met the previous day and suspended his license. The Respondent Rohrback contacted the Boca Raton city attorney and a representative of the Department to present the signed releases and cancelled checks he eventually obtained from the four listed individuals in order to obtain a reversal of the local Board's action suspending his license. At the time of hearing, the Respondent had been unsuccessful in obtaining a reversal of the Board's decision. Additionally, the Respondent Rohrback acted as qualifying agent for D.R.K. Company from July 1, 1979 through February 1981. During this period of time, D.R.K. utilized deceptive practices in order to obtain contracts from various individuals. By certified letter dated June 12, 1980, the Respondent informed D.R.K. and pertinent licensing boards that he was withdrawing as qualifying agent for D.R.K. and Statewide Insulation and Solar Systems, Inc., and revoking any presigned permits or letters of authorization that may have been signed by John W. Rohrback. However, the Respondent did not actually attempt to revoke his authorization until October 28, 1980, when a letter was sent to Milton Rubin, administrative assistant to the Florida Construction Industry Licensing Board, outlining the problems he had encountered with D.R.K. and Statewide. On or about February 19, 1981, the Lee County Board of County Commissioners suspended the Respondent Rohrback's privilege to pull building permits.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That a Final Order be entered dismissing the Administrative Complaint filed against the Respondent John W. Rohrback in Case No. 82-2616. DONE and ORDERED this 28th day of March, 1983, in Tallahassee, Florida. SHARYN L. SMITH, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 28th day of March, 1983. COPIES FURNISHED: Michael J. Cohen, Esquire Suite 101 Kristin Building 2715 East Oakland Park Blvd. Fort Lauderdale, Florida 33306 John W. Rohrback 10282 Northwest 31st Street Coral Springs, Florida 33065 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue Whether Petitioners' claim for monies from the Florida Homeowners' Construction Recovery Fund is subject to adjudication pursuant to Section 120.57(1), Florida Statutes, and, if so, how much should Petitioners be awarded.
Findings Of Fact Based on the evidence adduced at hearing, and the record as a whole, the following findings of fact are made: On or about October 1, 1997, Petitioners entered into a contract in which they agreed to pay Respondent Norman Levinsky's company, Broward Roofing, Inc., $3,700.00 to place a "new shingle roof" on Petitioners' residence and perform other related roofing work. The contract provided Petitioners with a ten-year "labor warranty" and a 30-year shingle warranty. After the contracted work was completed and Petitioners paid Broward Roofing, Inc., the $3,700.00 called for by the contract, the newly-installed roof started leaking. Broward Roofing, Inc., refused to make the necessary repairs. Petitioners paid other contractors to perform the repair work. On November 17, 1998, Petitioner filed an application seeking to recover from the Florida Construction Industries Recovery Fund (which has since been renamed the Florida Homeowners' Construction Recovery Fund) $1,025.00 that they had paid for repairs to the "new shingle roof" Broward Roofing, Inc., had recently installed, contending that they were deserving of such an award inasmuch as "[t]he roofer [Broward Roofing, Inc.] [had] refused to fix [their] new roof that was leaking and [had] totally ignored [their] 10 year warranty." Their application was filed on a Board-produced Construction Industries Recovery Fund Claim Form (Form), at the end of which was printed the following: In addition to your complete written statement, we are requesting documentation of your contractual relationship with the contractor and evidence supporting your claim. Certified copies of the following list of documents are required to assist us in determining your eligibility for recovery. I have attached the following: (these documents are required for proper processing of your claim. Failure to provide required documentation will delay processing and could result in your claim being denied due to incompleteness.) Court certified copy of the Civil Judgment, and/or Final Order of the Construction Industry Licensing Board directing restitution be paid. Copy of contract between you and the contractor. Copies of applicable bonds, sureties, guarantees, warranties, letters of credit and/or policies of insurance. Court certified copies of levy and execution documents. Proof of all efforts/inability to collect restitution judgment. No claims will be processed until 45 days after the date of entry of the Civil Judgment and/or Final Restitution Order. On the completed Form that Petitioners filed, only the spaces next to "Copy of contract between you and the contractor" and "Copies of applicable bonds, sureties, guarantees, warranties, letters of credit and/or policies of insurance" were checked. On May 4, 1999, the Broward County Central Examining Board of Construction Trades filed an Administrative Complaint against "Norman Levinsky d/b/a Broward Roofing, Inc.," which read as follows: Count I At all times material hereto RESPONDENT was a roofing contractor holding Broward County Certificate of Competency #95-7726-R- R. On or about September 16, 1997, RESPONDENT entered into a contract to re- roof Complainant's home located at 10551 N.W. 21st Court, Sunrise, Florida. RESPONDENT obtained a building permit. The work was completed on March 10, 1998 and the roof began to leak on June 1, 1998. RESPONDENT failed to properly supervise to ensure that the tie in with flat roof was properly completed. His failure to ensure such a proper tie in resulted in leaks. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(11) of the Broward County Code of Ordinances by failing to properly supervise a project commenced pursuant to a building permit. Count II Paragraphs 1 and 2 are included as if restated herein. Complainant paid RESPONDENT the total contract price of $3,700.00. RESPONDENT completed the work. RESPONDENT gave Complainant a 10 year labor warranty. RESPONDENT failed and refused to honor his warranty. Complainant had to pay additional amount of $1,025.00 for a new contractor to repair the work of RESPONDENT. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(5)c of the Broward County Code of Ordinances by committing mismanagement which causes financial harm to a customer because the customer had to pay more for the contracted job than the original contract price. Count III Above paragraphs are included as if restated herein. RESPONDENT failed to honor the warranty and complete the project in a workmanlike manner for a period in excess of 90 consecutive days. Wherefore, it is charged that the RESPONDENT violated Subsection 9-14(b)(8) of the Broward County Code of Ordinances by abandoning a construction project in which RESPONDENT was under contract as a contractor. It is determined that the above stated charges are grounds for disciplinary action pursuant to Chapter 9, Sections 9-14, 9-28 and 9-46, Broward County Code of Ordinances and Section 6.11, Broward County Charter. Broward County has the authority to certify and discipline local contractors pursuant to Section 489.131, Florida Statutes. Following a hearing on the Administrative Complaint held May 25, 1999, the Broward County Central Examining Board of Building Construction Trades, on June 16, 1999, issued an Order, which read as follows: A Disciplinary Proceeding was held on May 25, 1999, before the Broward County Central Examining Board of Building Construction Trades (the "Board"), in accordance with Section 9-14, Broward County Code of Ordinances (the "Code"). Service of the Administrative Complaint filed against the Respondent was made by certified mail. The Respondent being duly advised was not present at the hearing. The Board heard the sworn testimony of William Grubb and Marlene Grubb. Upon consideration, it is ORDERED: The allegations of fact as set forth in the Administrative Complaint are found to be true and adopted and incorporated herein by reference as findings of fact. The conclusions of law alleged and set forth in the Administrative Complaint are approved and adopted and incorporated herein. Upon these findings, it is therefore ORDERED: That Respondent's Certificate of Competency is hereby revoked. That the Respondent make restitution to the Complainants in the amount of $3,700.00. Prior to the RESPONDENT being allowed to reinstate his certificate of competency or being allowed to sit for any exam administered by a Broward County Central Examining Board, or receiving any license from a Broward County Central Examining Board, RESPONDENT must appear before the Board and prove that the restitution amount has been paid in full. The board's order may be appealed by Petition for Writ of Certiorari to the Seventeenth Judicial Circuit within thirty (30) days of the date of rendition of the order of the board as provided by the Florida Rules of Appellate Procedure. FURTHER, the Broward County Central Examining Board of Construction Trades makes RECOMMENDATION to the Florida Construction Industry Licensing Board to impose on the state registration, the following penalty: 1. Revoke state registration and require the RESPONDENT to make restitution to the Complainants in the amount of $3,700.00. In accordance with Florida Statutes, Chapter 489.131(7)(c) and (d), the disciplined contractor, the complainant, or the Department of Business and Professional Regulation may challenge the local jurisdiction enforcement body's recommended penalty for Board action to the State Construction Industry Licensing Board. A challenge shall be filed within sixty (60) days of the issuance of the recommended penalty to the State Construction Industry Licensing Board in Jacksonville, Florida. If challenged, there is a presumptive finding of probable cause and the case may proceed before the State Board without the need for a probable cause hearing. Failure of the disciplined contractor, the complainant, or the Department of Business and Professional Regulation to challenge the local jurisdiction's recommended penalty within the time period set forth in this subsection shall constitute a waiver of the right to a hearing before the State Construction Industry Licensing Board. A waiver of the right to a hearing before the State Board shall be deemed an admission of the violation, and the penalty recommended shall become a final order according to procedures developed by State Board rule without further State Board action. Pursuant to Section 120.569, Florida Statutes, the Parties are hereby notified that they may appeal the Final Order of the State Board by filing one copy of a Notice of Appeal with the Clerk of the Department of Business and Professional Regulation, Northwood Centre, 1940 North Monroe Street, Tallahassee, Florida 32399-0792, and by filing the filing fee and one copy of the Notice of Appeal with the District Court of Appeal within thirty (30) days of the effective date of said Order. On or sometime after September 1, 1999, Petitioners filed an affidavit prepared by Petitioner Marlene Grubb, which read as follows: I, Marlene A. Grubb, hereby certify that I have completed a reasonable search and inquiry in accordance with the instructions provided by the Construction Industry Licensing Board and have not found property or assets to satisfy my Board Order[1] in whole or part. Legal Names The Department of State revealed that the company Broward Roofing Inc. was administratively dissolved on 9/10/98. The C[IL]B verified the contractor[']s name and license number as: Norman Levinsky d/b/a Broward Roofing Inc. RC0047656. Real Property My search included property in the names: Norman Levinsky and Broward Roofing Inc. in Broward County, Florida. Norman Levinsky had no real property and Broward Roofing Inc. is delinquent on property taxes for over two years. Boats and Motor Vehicles There were no vehicles or boats in the motor vehicle data bank registered to Norman Levinsky or Broward Roofing Inc. Aircraft The FAA in Oklahoma City, Ms. Jeannie Vannest stated that there is no registration listed for Norman Levinsky or Broward Roofing Inc. On March 25, 2004, the Board rendered a Final Order Approving Recommended Order of Disciplinary Action by Local Enforcement Body, which approved the Broward County Central Examining Board of Building Construction Trades' June 16, 1999, Order and read as follows: THIS MATTER came before the Construction Industry Licensing Board (hereinafter referred to as the "Board") pursuant to Section 489.131(7), Florida Statutes, for a determination of whether to accept the proposed recommended penalty by the Broward County Central Examining Board of Building Construction Trades (a copy of which is attached and incorporated herein by reference). Neither the Petitioner, the Respondent nor the Complainant filed a challenge to the local enforcement body's recommended penalty to the Board. Upon consideration of the local enforcement body's Administrative Complaint, the minutes from the meetings on January 21, 1999, and May 25, 1999, and the Final Order of Disciplinary Action and its proposed recommended penalty to the Board in this matter and being otherwise fully advised in the premises it is hereby ORDERED AND ADJUDGED: The proposed recommended penalty is hereby approved and adopted in its entirety and incorporated herein by reference. In accordance with the recommended penalty, Respondent's state registration (RC 0047656) is hereby REVOKED. Respondent shall pay restitution in the amount of $3,700 to William and Marlene Grubb. Respondent will adhere to and abide by all of the terms and conditions of the recommended penalty. Failure to abide by the terms of this Order may result in further action by the Board. This Order shall be placed in and become a part of Respondent's official records. A change in the Respondent's licensure status, including the suspension, revocation, voluntary relinquishment, or delinquency of license, does not relieve the Respondent of his obligation to pay any fines, costs, interest or restitution imposed in this and previous orders. Pursuant to Section 120.68, Florida Statutes, the Parties are hereby notified that they may appeal this Final Order by filing a Notice of Appeal with the Clerk of the Department of Business and Professional Regulation, Northwood Centre, 1940 North Monroe Street, Tallahassee, Florida 32399- 0792, and by filing the filing fee and one copy of the Notice of Appeal with the District Court of Appeal within thirty (30) days of the effective date of this Order. This Order shall become effective upon filing with the Clerk of Department of Business and Professional Regulation. This was the "Final Order of the Construction Industry Licensing Board directing restitution be paid," that, according to the Form Petitioners used to submit their claim for monies from the Florida Construction Industries Recovery Fund, was "required for proper processing of [their] claim." On June 10, 2004, more than five and a half years after Petitioners had filed their claim application, the Board met to determine the merits of their claim pursuant to Section 120.57(2), Florida Statutes. Although given due notice of the Board meeting, neither Petitioners, nor Mr. Levinsky, made an appearance, either in person or through a representative, at the meeting. "[U]pon consideration of the documentation and testimony submitted," the Board determined that Petitioners' claim for $1,025.00 should be "approved." On July 29, 2004, the Board rendered (that is, filed with the agency clerk) a written order to this effect, which read as follows: THIS MATTER came before the Construction Industries Recovery Fund Committee and Construction Industry Licensing Board (the "Board") pursuant to sections 120.57(2) and 489.143, Florida Statutes (2003) as well as rule 61G4-21.004, Florida Administrative Code, on June 10, 2004, in Coral Gables, Florida, for consideration of a claim for restitution from the Construction Industries Recovery Fund (the "Recovery Fund"). William [a]nd Marlene Grubb ("Claimants") and Norman Levinsky ("Licensee") were duly notified of the proceedings. At the proceedings before the committee and the Board, Claimants were not present, and were not represented by counsel. Licensee was not present, and was not represented by counsel. Upon consideration of the documentation and testimony submitted, it is ORDERED: Claimants satisfied all requirements for payment from the Recovery Fund. The Recovery Fund Claim was filed on November 17, 1998. The application was timely filed. The contractor was paid $3,700.00. Claimants were awarded restitution from the Construction Industry Licensing Board on March 24, 2004, in the amount of $3,700.00, pursuant to a Final Order Approving Recommended Order of Disciplinary Action by Local Enforcement Body. The Board adopted and approved the Broward County Central Examining Board of Building Construction Trades recommendation, which found: Contractor held a current and active license at all times material to the transaction; The construction contract is dated September 18, 1997; The work was completed on March 10, 1998, and the roof began leaking June 1, 1998; Contractor failed to honor the warranty on the roof; As a result, Claimants paid an additional $1,025.00 for repair work; Contractor violated subsection 9- 14(b)(5)c of the Broward County Ordinances by committing mismanagement, which caused financial harm to a consumer because the consumer had to pay more for the contractual job than the original contract price. The contractor engaged in activity that appears [to] violate section 489.129(1)(g)2, Florida Statutes (2003). There is an asset search in the file that shows no assets are available from which claimant can satisfy the judgment. Pursuant to section 489.143, Florida Statutes (2003), the maximum amount that the Recovery Fund can pay on a single claim is $25,000.00. Thus, the claim for restitution from the Recovery Fund is APPROVED in the amount of $1,025.00. In accordance with rule 61G4-21.005, Florida Administrative Code, the Secretary of the Florida Department of Business and Professional Regulation is directed to pay the claim from the Recovery Fund after forty-five days from the date upon which the Final Order is filed with the Agency Clerk. Pursuant to section 489.143(6), Florida Statutes (2003), upon payment of the claim from the Recovery Fund, Licensee's licensure to practice contracting is AUTOMATICALLY SUSPENDED without any further administrative action. Pursuant to section 489.143(2), Florida Statutes (2003), upon receipt by Claimant under section 489.143(1), Florida Statutes (2003) of payment from the Recovery Fund, Claimant shall assign his or her additional right, title, and interest in the judgment or restitution order, to the extent of such payment, to the Board, and thereupon the Board shall be subrogated to the right, title, and interest of the Claimant; and any amount subsequently recovered on the award, judgment or restitution order by the Board, to the extent of the right, title, and interest of the Board therein, shall be for the purpose of reimbursing the Recovery Fund. This Order shall become effective upon filing with the Clerk of the Department of Business and Professional Regulation. DONE AND ORDERED this 21st day of June, 2004. Appended to the order was the following Notice of Right of Appeal: You are hereby notified that mediation is not available in this matter. Pursuant to Section 120.569, Florida Statutes, you may seek review of the above by filing a request for hearing with the Executive Director of the Board at 1940 North Monroe Street, Tallahassee, Florida 32399-2202 within twenty-one (21) days of the filing of this Order. Upon request, you will receive an informal hearing pursuant to section 120.57(2), Florida Statutes. In the alternative, you may request a formal hearing pursuant to Section 120.57(1), Florida Statutes, if there are material facts in dispute; if you request a formal hearing, the petition must contain the information required by Rule 28-106.201, Florida Administrative Code, including specification of the facts which are in dispute. If you request a hearing, you have the right to be represented by an attorney or other qualified representative to take testimony. On August 12, 2004, Petitioners filed a Request for Hearing, complaining that they "should be awarded at least $3,475.00" to be adequately compensated for all of the repairs they had to make to their roof as a result of Broward Roofing, Inc.'s failure to meet its responsibilities. On August 30, 2004, the Board referred the matter to DOAH "for the assignment of an Administrative Law Judge to conduct a formal hearing" pursuant to Section 120.57(1), Florida Statutes.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Board issue an order dismissing Petitioners' Request for Hearing challenging the Board's order, rendered July 29, 2004, disposing of their claim for monies from the Fund, but allowing them, if they so desire, to request that that order be vacated and re-rendered so that they will have the opportunity to file a timely appeal in accordance with Section 120.68, Florida Statutes. DONE AND ENTERED this 28th day of December, 2004, in Tallahassee, Leon County, Florida. S __ STUART M. LERNER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 28th day of December, 2004.
The Issue The issue presented is whether Respondent committed the offenses alleged in the administrative complaint, and, if so, what penalty should be imposed.
Findings Of Fact At all times material hereto, Respondent, John Arena, was a certified residential contractor, the qualifying agent for Classic Industries, Inc. and held license number CR C021139 from the Florida Construction Industry Licensing Board. The President and sole owner of Classic was Anthony Manganelli. Mr. Manganelli was also the manager of Classic and the principal from whom Mr. Arena received his information about the contracts entered into by Classic. On or about July 30, 1988, someone contacted Ms. Solange Gaston of Hollywood, Florida, by telephone, and asked her if her roof needed repair. The solicitor represented himself as an associate of Classic and offered to come out and inspect her roof. Ms. Gaston, believing her roof was in disrepair, agreed to have the inspection completed and entered into a contract with Mr. Carlo Mangano, representing himself as an agent of Classic, to do the repair. With Ms. Gaston's agreement, the tile on her roof was replaced with shingle roofing and certain other repairs were attempted. A letter to Petitioner from the Chief Permit Processor of the City of Hollywood, Florida indicates that no roofing permit was issued for Ms. Gaston's address. The roof was leaking prior to the repair and continues to leak. Ms. Gaston paid the complete contract price of $3,500 to Classic, but has been unable to locate Mr. Mangano or to have her roof repair completed. In her attempts to achieve satisfaction, Ms. Gaston contacted Classic and asked to speak with someone in charge. She was under the impression that she was speaking with Mr. Arena; however, she never spoke to Mr. Arena. In fact, Mr. Arena was not aware of the contract with Ms. Gaston until the instant complaint was filed against him. Mr. Arena does not know Mr. Mangano. When Mr. Arena became aware of the problem, he attempted to contact Mr. Manganelli, but was told that Mr. Manganelli had moved. Ultimately, Mr. Arena located Mr. Manganelli at a new address. According to Mr. Arena, Mr. Manganelli produced a copy of what appeared to be a contract with Ms. Gaston which has the signature of Carlo Mangano on it, but it is marked indicating that Ms. Gaston's credit was turned down. Mr. Manganelli told Mr. Arena that Classic had not undertaken the job due to the refusal of credit. With that representation, Mr. Arena was under the impression that the work had not been done, as was the custom of dealing for Classic when credit was denied. The two papers purporting to be contracts, one which Ms. Gaston acknowledged as being the one which she signed and the other being the one which Mr. Arena obtained from Mr. Manganelli as the actual contract between Ms. Gaston and Classic through Mr. Mangano, appear to be altered. Although both documents contain the same information, including the date, parties, addresses, work to be completed and price quoted, the portion of the copy indicating the price is written in Arabic numerals on Mr. Arena's copy and by words on Ms. Gaston's copy. Mr. Arena's copy also has the indication that credit was turned down on it, although the cancelled checks paid to Classic by Ms. Gaston were received into evidence. It was Mr. Arena's arrangement with Mr. Manganelli that Mr. Arena was to be informed of every contract into which Classic entered. In this way, Mr. Arena knew which sites he was to supervise. Since he was not advised about the roofing job for Ms. Gaston, he made no attempt to supervise it and after he became aware that the credit for the job had been disallowed, he was under the reasonable impression that the job was not done by Classic. Further, he did not know Mr. Mangano, nor did he believe that Mr. Mangano had the authority to bind Classic. Mr. Arena believes that Mr. Mangano may have obtained a blank contract form of Classic and misrepresented himself to Ms. Gaston as an agent for Classic. Petitioner asserted, however, that Mr. Arena, nevertheless, was responsible for the job and that Classic did perform the job. Neither Mr. Manganelli nor Mr. Mangano were present or testified at the hearing. Given Mr. Arena's demeanor at the hearing and the conflicting and altered state of the alleged contract forms, Mr. Arena's testimony is deemed credible, and the proof failed to demonstrate clearly that Classic actually attempted to repair Ms. Gaston's roof or that Mr. Arena was responsible for the attempted repair.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is: RECOMMENDED that the Florida Construction Industry Licensing Board issue a Final Order dismissing the administrative complaint filed in this case against Respondent, John Arena. DONE AND ENTERED in Tallahassee, Leon County, Florida, this 20th day of June, 1990. J. LAWRENCE JOHNSTON Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 20th day of June, 1990. COPIES FURNISHED: Robert G. Harris Department of Professional Regulation 1940 North Monroe Street Suite 341 Tallahassee, Florida 32399-0792 John D. Arena 5961 Southwest 13th Street Plantation, Florida 33317 Fred Seely Executive Director Department of Professional Regulation Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201 Kenneth D. Easley General Counsel Department of Professional Regulation 1940 North Monroe Street Suite 60 Tallahassee, Florida 32399-0792 =================================================================
The Issue Did Respondent commit the violations alleged in the Administrative Complaint dated April 11, 2000, and if so, what discipline is appropriate?
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant findings of fact are made: The Department is the agency of the State of Florida charged with the responsibility of regulating the practice of contracting pursuant to Section 20.165, Florida Statutes, and Chapters 455 and 489, Florida Statutes. Respondent is, and has been at all times material hereto, a certified residential contractor in the State of Florida, having been issued license number CR CO13253 by the Florida Construction Industry Licensing Board. At all times material hereto, Respondent was licensed with the Construction Industry Licensing Board as an individual. On or about November 20, 1993, Respondent entered into a written contractual agreement (contract) with Kevin Watkins (Watkins) to construct a single family residence at 126 Meadow Lark Boulevard, Lot 65, Indian Lake Estates, Florida. The contract price was $333,944.00. Between December 7, 1993, and February 1, 1996, Watkins and Respondent executed 102 addenda to the contract which increased the contract price by approximately $241,874.43, for a total amount of approximately $575.818.43. On or about December 9, 1993, Respondent obtained permit number 93-120l850 from the Polk County Building Department and commenced work on the project. The contract provided that the "project shall be substantially completed on or about 195 days from the date all building permits are issued." However, due to the 100-plus addenda to the contract, it was estimated that an additional 190 days would be needed to complete the project. Additionally, construction ceased on the home for approximately 60 days so that Watkins could explore the possibility of a construction loan. However, due to the extent of completion, the lending institutions decided not to make any construction loans. On or about May 27, 1996, Watkins moved to Florida with the expectations that his home would be completed within a short period of time. (Watkins' recollection was that the home was to be completed in a couple of weeks. Respondent's recollection was that the home was to be completed in a couple of months.) In any event, Respondent did not complete the Watkins home within a couple of weeks or a couple of months. After Watkins moved to Florida, Respondent paid for Watkins to live in a Best Western motel for a few weeks. Subsequently, Respondent moved Watkins into a rental home for which Respondent paid the rent through September 1996. Beginning October 1996 through July 1999, Watkins paid $600.00 per month for a total of $20,400.00 as rent on the rental home. In early 1998, Respondent and Watkins went through the home, identified those items which had not been completed and Respondent made a handwritten list of those items. Respondent failed to complete the items identified on the list. In fact, shortly thereafter, Respondent ceased working on the project and was unresponsive to attempts to contact him. At the time Respondent ceased working on Watkins' home, the home was approximately 75 percent complete. While this estimation of completion may not be totally accurate, it is the best that could be derived based on the evidence presented, including Respondent's testimony to which I gave some credence. Watkins paid Respondent $561,617.91, which represents approximately 97.534 percent of the total contract price plus addenda to the contract. Seventy-five percent of the contract price plus addenda to the contract equals $431,863.82 for an overpayment of $129,754.09. To date, Respondent has not returned any of the money he received from Watkins above the amount completed under the contract. From early 1998, until August 1998, when Watkins had Respondent removed as general contractor on the building permit, Respondent failed to perform any work on the home for a period in excess of 90 days. Respondent contracted with Jack Eggleston to install cabinets in Watkins home. Eggleston performed under the contract but Respondent failed to pay Eggleston in full, requiring Watkins to pay Eggleston $1,200.00. After Watkins' home was partially complete, Respondent advised Watkins that he had the home insured when in fact he did not have the home covered with insurance. While Respondent was building Watkins' home, Respondent and Watkins entered into a joint venture called Contractors of Central Florida to build modular homes sometime after January 1, 1995. Respondent contends that some of the checks Watkins claims as payment under the contract for his home, were in fact reimbursement to Respondent for funds he had advanced for the joint venture. There is insufficient evidence to establish facts to show that any of the checks Watkins claims as payment under the contract for his home were in fact reimbursement for funds advanced by Respondent for the joint venture. Up until the time of the final hearing, the Department had incurred costs for the investigation and prosecution of this matter, excluding costs associated with an attorney's time, in the amount of $1,451.28.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, and after careful review of the guidelines set forth in Rule 61G4-17.001(8) and (11), Florida Administrative Code, and the circumstances for purpose of mitigation or aggravation of penalty set forth in Rule 61G4-17.002, Florida Administrative Code, it is recommended that the Department: Enter a final order finding Respondent guilty of violating Section 489.129(1)(h)2., Florida Statutes, and imposing a penalty therefor an administrative fine in the amount of $1,000.00; Enter a final order finding Respondent guilty of violating Section 489.129(1)(k), Florida Statutes, and imposing a penalty therefor an administrative fine in the amount of $1000.00; Assessing costs of investigation and prosecution, excluding costs associated with an attorney's time, in the amount of $1,451.28, plus any such further costs which have or may accrue through the taking of final agency action and; Requiring Respondent to pay restitution to Kevin Watkins in the amount of $129,754.09 which represents the amounts accepted by Respondent for work not performed. DONE AND ENTERED this 23rd of October, 2000, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6947 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 23rd day of October, 2000. COPIES FURNISHED: Robert A. Crabill, Esquire Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32388-2202 Ronald J. Powell Post Office Box 7043 Indian Lake Estates, Florida 33855 Rodney Hurst, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Barbara D. Auger, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Harry L. Wilson is the holder of a registered roofing contractor's license from the Florida Construction Industry Licensing Board. The license, Number RC 0041328, was first issued in March of 1982. The license was issued in the name of Harry L. Wilson Roofing, 1943 Hardy Street, Jacksonville, Florida, with the Respondent as qualifier. The Respondent has been the qualifier of Harry L. Wilson Roofing at all times relevant to this proceeding. On December 6, 1984, the Respondent and Robbie L. Hicks, entered into a written contract (Petitioner'S Exhibit 2). Pursuant to this written contract (hereinafter referred to as the "Contract"), the Respondent agreed to perform the repair work specified in the Contract in a "professional manner" and Ms. Hicks agreed to pay the Respondent $2,395.00. The property to be repaired is rental property owned by Ms. Hicks. The property is located at 1508 Eaverson Street, Jacksonville, Florida. The Respondent commenced work sometime during the early part of 1983. Shortly after commencing work, however, the Respondent and Ms. Hicks began having disagreements as to the work to be performed and the quality of the Respondent's work. These disagreements continued after the Respondent completed the work in November of 1983. Ms. Hicks testified that the work that the Respondent completed was done in an unprofessional manner and that the Respondent had not completed all of the work that he had agreed to perform. In particular, Ms. Hicks testified that the Respondent had failed to paint the interior of the house beige as required by the Contract, had failed to remove saw dust and other debris from the house following completion of the work, had failed to finish cabinets installed in the house, had failed to repair screens and generally had not performed in the manner he had agreed to perform. Ms. Hicks paid the Respondent all but $410.00 of the contract price. The Respondent testified that all off the work called for pursuant to the Contract had been performed. According to the Respondent, he had performed some work not required by the Contract and had not performed other work requested by Ms. Hicks because the work was beyond the scope of the Contract. The Respondent also stated that the work which Ms. Hicks expected would have cost considerably more than the price agreed upon in the Contract. The Respondent did not perform all of the work specified in the Contract in a "professional manner" as required by the Contract. Based upon the testimony of Mr. Claude Bagwell, Deputy Chief, Building and Zoning, Inspection Division of the City of Jacksonville, it is clear that no permit was issued by the City of Jacksonville to perform the work required by the Contract. The only permits issued with regard to Ms. Hicks' rental property was a permit issued in 1961 and the original building permit issued in 1949. Additionally, due to the fact that no Florida registered roofing contractor's license in the name of "Harry L. Wilson Roofing" had been filed with the City of Jacksonville, no permit could be issued to Harry L. Wilson Roofing with regard to the Contract. The Respondent admitted that he had not obtained a permit to perform the work required by the Contract. The Respondent indicated that he had not obtained a permit because he was not aware that one was required in order to perform the work. He did indicate that he had obtained permits to perform other jobs. The Respondent could not, however, have obtained permits for other jobs because no license issued in the name of Harry L. Wilson Roofing had been filed with the City of Jacksonville. The Respondent did take the examination required in order to obtain a registered roofing contractor's license. The Petitioner suggested in its Proposed Findings that the "permit requirement was explained" when the Respondent took the exam. No evidence to support such a finding was presented at the hearing. The Respondent in entering into the Contract clearly used the name "Wilson Recycling". Nowhere on the Contract is the name "Harry L. Wilson Roofing" used. The Respondent ultimately admitted that no Florida license authorizing the use of the name "Wilson Recycling" had been obtained by him. The Respondent, however, when initially asked whether a Florida license in the name of "Wilson Recycling" had been obtained indicated that such a license had been issued. On further examination, however, the Respondent testified that an occupational license in the name of "Wilson Recycling' had been obtained by him and not a Florida license. The work to be performed pursuant to the Contract was beyond the scope off the Respondent's license. As pointed out by Mr. Bagwell the work to be performed pursuant to the Contract would require licensure as a registered residential contractor or more.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That count I of the Administrative Complaint filed against the Respondent be dismissed. It is further RECOMMENDED: That Respondent be found guilty of violating Section 489.129 (1)(g), Florida Statutes (1983), by contracting in a name other than the name as set forth on the Respondent's license. It is further RECOMMENDED: That Respondent be found guilty of violating Section 489.129(1)(j), Florida Statutes (1983), by failing in a material respect to comply with the provisions of Section 489.119(2) and(3), Florida Statutes (1983), in that the Respondent failed to qualify the business name "Wilson Recycling" with the Construction Industry Licensing Board. It is further RECOMMENDED: That Respondent be found guilty of violating Section 489.129(1)(j), Florida Statutes (1983), when he failed in a material respect to comply with the provisions of Section 489.117(2), Florida Statutes (1983), by contracting to perform and actually performing work beyond the scope of his Florida contracting license. It is further RECOMMENDED: That Petitioner suspend Respondent's roofing contractor's license for a period of three (3) months. DONE and ENTERED this17th day of December, 1984, in Tallahassee, Florida. LARRY J. SARTIN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 17th day of December, 1984. COPIES FURNISHED: H. Reynolds Sampson, Esquire Staff Attorney Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Harry L. Wilson 1943 Hardee Street Jacksonville, Florida 32209 Mr. Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue The issue in this case is whether Respondent violated Section 489.129(1), Florida Statutes (1997) (hereinafter, "Florida Statutes"), by committing mismanagement or misconduct in the practice of contracting, causing financial harm to a customer, abandoning a construction project, and failing to satisfy a judgment against him.
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a contractor pursuant to license number CB C019811. At all relevant times, Respondent was the qualifying agent for Gulf and Bay Sunrooms, Inc. ("Gulf"). As the qualifying agent, Respondent was responsible for all of Gulf's contracting activities in accordance with Section 489.1195, Florida Statutes. On August 23, 1995, Respondent and Gulf entered into a contract with Mr. H. Edward Dowling ("Dowling") to install a Four Seasons System 330 Sunroom in Dowling's residence at 3016 West 38th Street, Orlando, Florida. The contract price was $31,340. Dowling paid the first draw of $9,402 to Respondent and Gulf by check number 45016644. On October 27, 1995, Gulf deposited the check to its account. Respondent and Gulf never commenced work on the sunroom. Respondent and Gulf did not return the first draw to Dowling. Respondent and Gulf abandoned the project without just cause and without notice to Dowling. On June 19, 1997, the County Court of the Ninth Judicial Circuit entered a Default Final Judgment in Case No. CO97-3800. The default judgment was entered in the amount of $9,402 plus costs of $145. Neither Respondent nor Gulf have satisfied the judgment. Respondent has a discipline history in two other cases. In Petitioner's Case No. 96-7123, Respondent failed to pay a supplier for windows. In DOAH Case No. 96-5914, Respondent contracted to build a sunroom in a residence, accepted payment of $1,540.44 toward the contract price of $4,668.00, never commenced construction, and abandoned the project. In the first case, Respondent was found guilty of failing to satisfy a civil judgment, was fined, and was ordered to pay restitution. In the second case, Respondent was found guilty of abandonment, incompetency or misconduct, was fined, and was ordered to pay restitution, and his license was suspended until Respondent complied with the penalty imposed.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Board enter a Final Order finding Respondent guilty of violating Section 489.129(1), Florida Statutes, imposing administrative fines in the aggregate amount of $15,000.00, and revoking Respondent's license. DONE AND ENTERED this 10th day of August, 1998, in Tallahassee, Leon County, Florida. DANIEL MANRY Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 10th day of August, 1998. COPIES FURNISHED: Rodney Hurst, Executive Director Department of Business and Professional Regulation Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Paul F. Kirsch, Senior Attorney Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street, Suite 60 Tallahassee, Florida 32399-0792 William Leete Stone, IV, pro se 3386 Poinsettia Avenue Naples, Florida 34104
The Issue Whether Respondent, a certified general contractor, is guilty of pulling permits for construction projects not supervised by Respondent, and, if so, the appropriate disciplinary action which should be taken by the Board.
Findings Of Fact At all times material hereto, Respondent was the holder of Certified General Contractor's License No. CG C005204 issued by the Board. Although this license was active at the time the Administrative Complaint was filed, Respondent has placed it on an inactive status until June 30, 1981. (Stipulation, Testimony of Respondent) As to Amiguet Construction Project During 1976, Jose Amiguet entered into a contract with San Pedro Construction Inc. for the construction of an addition to his existing residence located at 1409 Granada Boulevard, Coral Gables, Florida. (Stipulation, Petitioner's Exhibit 1) Since San Pedro Construction Inc. was not properly licensed as a building contractor, it was not qualified to apply for and obtain a Coral Gables building permit to undertake this residential addition. Therefore, on January 12, 1977, pursuant to an agreement with Jose San Pedro, representative of San Pedro Construction Inc., the Respondent applied and obtained the required Coral Gables building permit under his on name. (Stipulation, Testimony of Respondent, Charles Kozak, Petitioner's Exhibit 1) The Respondent did not participate in, manage, or supervise, in any manner, the construction of the Amiguet residential addition by San Pedro Construction Inc. Jose Amiguet neither knew the Respondent, nor had any dealings with him during the construction work. (Stipulation, Testimony of Respondent) Final inspection of the Amiguet construction project has not been conducted by the Coral Gables building inspection department since the required documentation concerning sidewalk improvements and subcontractors used has not yet been submitted. The actual construction work has, however, been completed, to the satisfaction of Jose Amiguet. (Testimony of Charles Kozak, Respondent) Respondent made an effort to assist Jose Amiguet in obtaining the final inspection and clearance by the city building inspection department. However, since Respondent did not supervise the subcontractors' work, he cannot truthfully complete the required documents. He has, therefore, offered to (1) pay for the additional costs associated with obtaining the necessary final inspection, and (2) transfer to Jose Amiguet the right to receive, after final inspection, the refund of the contractor's performance bond in the amount of approximately $400-$500. (Testimony of Respondent) As to the Shaw Construction Project During July, 1977, and on February 8, 1978, James L. Shaw entered into separate contracts with San Pedro Construction Inc. for the construction of residential improvements at 836 Obispo Avenue, Coral Gables, Florida. The final contract was in the amount of $16,700.00. (Stipulation, Testimony of Respondent, James L. Shaw, Petitioner's Exhibit 4) Since San Pedro Construction Inc. was an unlicensed contractor, Respondent, on November 15, 1977, pursuant to an agreement with that company, applied for and obtained the required Coral Gables building permit. (Stipulation, Testimony of Respondent, James L. Shaw, Petitioner's Exhibit 4) The Respondent did not participate in, manage, or supervise in any manner the construction of the Shaw residential improvements by San Pedro Construction Inc. James Shaw neither knew Respondent, nor had any dealings with him during the construction work. (Stipulation, Testimony of Respondent) On or about April, 1978, the lending institution for the Shaw project, and James Shaw stopped making construction payments to San Pedro Construction Inc., due to its failure to proceed on and abandonment of the project. (Testimony of James Shaw, Charles Kozak) On June 20, 1978, James Shaw obtained an "owner-builder" permit from the City of Coral Gables and incurred the following costs in order to complete the construction project as originally planned: $12,000 for labor and materials, and $625.00 for architectural services. Inasmuch as approximately, $10,128.00 had earlier been paid to San Pedro Construction Inc. for the construction project, the total cost of the project to James Shaw was approximately $22,753.00-$6,053.00 in excess of the original contract price. (Testimony of James Shaw and Respondent) San Pedro Construction Inc. is no longer in business, and the whereabouts of its owner, Jose San Pedro, is unknown. (Testimony of Respondent) As with the Amiguet construction project, final inspection of the Shaw project cannot be conducted until missing documentation relative to sidewalk improvements and subcontractors involved is supplied. In an effort to assist James Shaw, the Respondent has offered to transfer to Shaw the right to receive, after final inspection, the refund of the contractor's performance bond in the amount of approximately $400-$500. (Testimony of Charles Kozak and Respondent) At all times material hereto, the Respondent was aware that it was unlawful, under both state law and the Code of Metropolitan Dade County, to aide an unlicensed contractor in evading the contractor licensing law, and to use one's license to pull permits for projects not supervised by the licensee. (Stipulation, Testimony of Respondent, Petitioner's Exhibit 1) The Metro Dade Construction Trades Board heard the complaint against the Respondent and found prima facie evidence and probable cause to refer the matter to the Florida Construction Industry Licensing Board (Stipulation) Notwithstanding the evidence presented, the Administrative Complaint and the Board's counsel at hearing limited the amount sought for restitution purposes to $5,300.00, provided both the performance bonds are refunded to the benefit of Jose Amiguet and James Shaw. (Administrative Complaint, statement of Board's Counsel) Respondent regrets having taken the actions complained of in the Board's Administrative Complaint, and now more fully understands the resulting burdens which have been placed on Jose Amiguet and James Shaw. (Testimony of Respondent)
Recommendation Guilty, as charged. Respondent's certified general contractor's license should be suspended until such time as full restitution is made to the persons damaged by his actions.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following facts were found: At all times material to these proceedings, the Respondent, Victor S. Davis, held a registered general contractor's license, numbered RG 0013635 issued by the State of Florida, Department of Professional Regulation, Construction Industry Licensing Board in April, 1973. At all times material to these proceedings, Respondent's general contractor's license, number RG 0013635, was in a delinquent status and had been in a delinquent status since July 1, 1977. Respondent failed to renew his license after June 30, 1975 but in May, 1976 made application to reinstate license number RG 0013635 which was approved and reinstated on an active status by Petitioner in May, 1976 and issued to Respondent, Victor S. Davis, qualifying Conch Construction Corp., of Key West, Florida. There was no evidence that the reinstated license was issued for Monroe County, Florida or that Respondent ever held a certificate of competency for Monroe County, Florida. At all times material to these proceedings, Respondent was an officer (Secretary) of Classic Marketing and Development, Inc. (Classic). On July 28, 1983, the Respondent, as Secretary of Classic, entered into a contract with William Dees to construct a shell home on the Dees' property located at Lot 14, Block 7, Breezeswept Estates, Ramrod Key, Florida for a contract price of $27,000.00. On September 13, 1983, William Dees applied for and obtained building permit No. 10902-A as owner/builder for the construction of the Dees's home. Construction of the Dees home began on or about September 13, 1983. Gregory H. O'Berry, President of Classic had knowledge of, and approved of, Respondent entering into contracts for construction of homes in Monroe County, Florida, including the contract with Dees. O'Berry was aware that Respondent did not hold a certificate of competency in Monroe County, Florida and that Respondent's registered general contractor's license did not cover contracting in Monroe County, Florida. O'Berry understood that Phillip A. Braeunig, a properly licensed general contractor in Monroe County, Florida, was acting as the general contractor for Classic- in the construction of homes by Classic, including the construction of the Dees home. Braeunig did not act as general contractor on the construction of the Dees' home. Respondent supervised the contraction of the Dees' home, until Respondent abandoned the construction of the Dees' home, and in performing these supervisory duties fulfilled the responsibilities of a general contractor. No other officer or authorized agent of Classic had any responsibility for the supervision of, or acted in any manner as a general contractor, in the construction of the Dees' home. Braeunig prepared and submitted to Respondent an application to qualify Classic with Petitioner using Braeunig's license but this application was never filed with Petitioner during- anytime material to these proceedings. Classic was never qualified by anyone, including Respondent or Braeunig, at any time material to these proceedings. Braeunig~acted as general contractor for Classic on the Conti home, which was in the beginning stages of Classic and prior to the Dees' job. Braeunig was brought into Classic for the purpose of acting as general contractor because of the Respondent's invalid license.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the Board enter a final order Dismissing Count I of the Amended Administrative Complaint filed against the Respondent. It is further RECOMMENDED that the Board enter a final order finding Respondent guilty of the violation charged in Count II of the Amended Administrative Complaint and for such violation it is RECOMMENDED that the Board suspend the Respondent's registered general contractor's license for a period of two (2) years and assess the Respondent with an administrative fine of $500.00, stay the suspension and place Respondent on probation for a period of two (2) years, provided the Respondent pays the $500.00 fine within ninety (90) days. Respondent's failure to pay the $500.00 fine within the time specified will result in his registered general contractor's license being suspended for a period of two (2) years with the requirement that when the fine is paid and the suspension lifted, the Respondent must appear before the Board for reinstatement of his license. Respectfully submitted and entered this 3rd of December, 1985, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, FL 32301 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 3rd day of December, 1985. APPENDIX Department of Professional Regulation, Construction Industry Licensing Board v. Victor S. Davis, Division of Administrative Hearings Case No. 85-1963 Ruling on Petitioner's Proposed Findings of Fact: Adopted in Finding of Fact No. 1 except for the statement that "Respondent's license was issued for Okaloosa County only" which is rejected as not being based upon competent substantial evidence. Hearsay alone is not sufficient to support a finding of fact. Adopted in Finding of Fact No. 1 except for statement that "said license has been delinquent since July, 1981" which is rejected as being contrary to the evidence in Petitioner's Exhibit No. 1 which shows delinquent status as of July 1, 1977. Adopted in Finding of Fact No. 3. Rejected as a conclusion of law rather than a proposed finding of fact. Considered as background information and not as a finding of faet. Adopted in Finding of Fact No. 4. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact Nos. 4 and 5. Adopted in Finding of Fact Nos. 5 and 7. Adopted in Finding of Fact No. 5. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 6. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of Fact No. 9. Adopted in Finding of feet No. 10 Adopted in Finding of Fact No. 10 Rejected as a conclusion of law rather than a proposed finding of fact. Respondent did not submit Proposed Findings of Fact. COPIES FURNISHED: James Linnan, Executive Director Department of Professional Regulation Construction Industry Licensing Board P. O. Box 2 Jacksonville, FL 32202 Nancy M. Snurkowski, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, FL 32301 Victor S. Davis 2169 North Hercules Avenue Clearwater, FL 33575 and 6290 Sandcrest Circle Orlando, FL 32819
