Findings Of Fact Jurisdiction findings Petitioner is the state agency charged with regulating licenses for roofing contractors in the State of Florida. At all times material to the allegations of these cases, Respondent held two licenses; he was a certified roofing contractor, license no. CC CO55580, and a registered roofing contractor, license no. RC 0060386. Respondent filed an application to qualify the company, D.S.S. & Sons, Inc., as a licensed roofing contractor; however, he failed to complete all documents necessary for licensure, and his application was closed for lack of response effective August 3, 1993. Respondent's address of record with the Department is 821 SW Dwyer Street, Port St. Lucie, Florida 34983. D.S.S. & Sons, Inc. is not now, nor has it ever been, licensed to perform roofing construction by the State of Florida. Facts common to all consumers On or about August 24, 1992, Hurricane Andrew struck Dade County, Florida, resulting in damage to hundreds of roofs. Roof repair or total replacement following the storm was not uncommon. Due to the large amount of damage, and the demand for roofing materials created by the volume of work to be performed, some contractors had difficulty obtaining roofing supplies. Additionally, some contractors had difficulty hiring qualified labor to perform the extensive roofing that was in great demand. The problems with obtaining materials and labor, however, were short term in that most roofing contractors made arrangements to bring in supplies and staff from other areas. In fact, by the time the work was to be performed in connection with these cases, the problems which had plagued the Dade County contractors were subsiding. Additionally, at all times material to these cases, the weather would not have been a factor to justify the delays complained of by these consumers. Rainy weather did not cause any prolonged work delays after the storm. Findings as to Helmly Charles Helmly resides at 11985 SW 98th Lane, Miami, Florida. His home was damaged by Hurricane Andrew and required roof replacement. Mr. Helmly contracted with Respondent to re-roof his home for the sum of $17,940.00. The contract was signed by Respondent's salesman, Felix Fowler, and identified D.S.S. & Sons, Inc. doing business as Darryl Saibic, Roofing Contractor as the licensed entity. Mr. Helmly paid an initial deposit of $5,382.00 in order for the Respondent to begin work on the project. The next payment, an additional $5,382.00, was to be due at the "dry in" stage of the job, with the final payment (the balance) due on completion. One of the contract provisions Mr. Helmly insisted upon was a completion deadline to be stated in the contract. He was expecting visitors and he was anxious to have the home re-roofed before their arrival. He insisted that a guaranteed completion date of March 7, 1993 be noted on the face of the contract. Mr. Helmly complied with all requirements of the payment schedule outlined by the contract. In fact, he remitted $10,764.00 even though the roof had not been at the "dry in" stage. Between January and February, 1993, the Respondent removed the old roof, installed a base sheet, and nailed a single ply roof membrane to the roof. After February, 1993, the Respondent failed to timely complete the Helmly roof. The value of the work performed by Respondent on the Helmly roof was no more than $3,588.00. The Respondent did not respond to numerous telephone calls and letters from Helmly, and threatened to place a lien on the Helmly property when Mr. Helmly attempted to cancel the contract in May, 1993. Mr. Helmly went to the Dade County Building Department and complained about roof leaks in June, 1993 (Respondent had still not done any further work). On or about June 4, 1993, Respondent sent a crew to the Helmly property to repair the roof. The repairs caused the roof to leak more. Respondent did not refund Mr. Helmly's money, did not complete the roof, and showed a gross indifference to the plight which resulted when he failed to timely complete the project. In July, 1993, desperate to have his roof completed, Mr. Helmly offered to purchase the tiles himself if Respondent would have a crew come install the new roof. Respondent agreed to have a crew install the tile within ten days of its arrival. On September 17, 1993, Mr. Helmly took delivery of the new tile, paid for it in full (a cost of $4,803.00) and notified the Respondent so that the installation could begin. Respondent never returned to complete the re-roofing. He failed to honor his verbal agreement to install the tiles. By letter dated October 1, 1993, Respondent offered to reimburse Helmly for the overage if he would hire another contractor to complete the job. On October 19, 1993, Mr. Helmly hired a new contractor who completed the installation of the new roof in early November, 1993. Approximately eight months after the deadline on Respondent's contract, Mr. Helmly had his new roof. Extra expenses totalling $2,936.21 were paid by Mr. Helmly as a result of the Respondent's abandonment of this job. Findings as to Gurdian On January 14, 1993, the Gurdians contracted with Respondent through his agent, Ed Comstock, to repair the roof on their home located at 13301 SW 110 Terrace, Miami, Florida. The contract was executed as D.S.S. and Sons, Inc. d/b/a Darryl S. Saibic, Roofing Contractor and called for a total payment of $7,725.00 for the work to be done. The Gurdians made a deposit of $2,300.00 on January 14, 1993 by check made payable to D.S.S. and Sons, Inc. and received a partial release of lien. On February 8, 1993, the Respondent pulled a permit for the Gurdian home but never called for inspections on this project. In February, 1993, all the tiles were removed from the roof and roofing paper was installed. On March 1, 1993, the Gurdians made a second payment of $2,300.00 by check made payable to D.S.S. and Sons, Inc. and received another partial release of lien. The Respondent did not timely complete the Gurdian roof. From June through November, 1993, Respondent sent the Gurdians unsigned notices claiming he would return to their job but did not do so. Numerous excuses were offered as to why the project was not completed; however, none of these had merit. The Gurdians waited until April, 1994 hoping the Respondent would return and complete the work. They drove to Respondent's office and left a message seeking assistance. Finally, Respondent recommended a company called CTI to complete the roof work for the Gurdians. When contacted, CTI told the Gurdians it would cost $7,600.00 to complete their job for which they, not Respondent, would be responsible. The Gurdians then attempted to notify the Respondent at his address of record by certified mail of their continuing problems but the letter was returned to them unopened. In June, 1994, the Gurdians hired another company to finish their roof which was finally complete and passed inspections on July 26, 1994. The Gurdians were required to pay a total of $13,475.00 to have their roof replaced because the Respondent failed to perform under the original contract. Due to the Respondent's abandonment and indifference in connection with this project, the Gurdians were damaged in an amount not less than $4,200.00. The value of the work performed by Respondent on the Gurdians' roof did not exceed $1,545.00. Respondent has not refunded any of the funds paid by the Gurdians. Findings of fact as to Vila Marta Vila resides at 11116 SW 133 Place, Miami, Florida 33186. Like the others discussed above, the Vila home was damaged and required a new roof. On January 13, 1993, Vila signed a contract with Ed Comstock acting on behalf of D.S.S. and Sons, Inc., doing business as Darryl S. Saibic, Roofing Contractor, to have her roof repaired for a total contract price of $7,200.00. A down payment of $2,160.00 made payable to the company was made at that time. On February 8, 1993, Respondent pulled a permit to re-roof the Vila home. On February 15, 1993, Vila paid an additional $2,160.00 to Respondent. At that time Respondent removed the tiles from the Vila roof and installed one layer of roofing paper over the roof decking. Despite representations from Respondent that new tiles would be delivered in approximately three to four weeks, the Respondent did not install a new roof on the Vila home. In February and March, 1993, the roof was patched three times to stop leaks but no substantive work was performed to install new tiles. Respondent did not return to the Vila home despite numerous requests from the homeowner for the work to be completed. In June, 1993, Respondent represented that the Vila job might be completed if the tiles were sent out COD. When Vila attempted to verify that information, she was told she had paid enough to not have that concern. However, no tiles were ever delivered to her home. In August, 1993, Vila, after Respondent failed to return telephone calls, wrote to Respondent and demanded a refund. She has not received one. Vila ended up paying $7,754.00 to another contractor to have her roof replaced. The value of the work performed by Respondent on the Vila project did not exceed $1,440.00 yet he has failed or otherwise refused to refund the difference between that amount and what she paid. Vila has suffered monetary damages in an amount not less than $4,800.00 as a result of Respondent's abandonment of this project. Findings of fact as to Bermudez Mr. and Mrs. Bermudez reside at 8335 SW 147th Place, Miami, Florida. On November 30, 1992, they signed a contract with Respondent in the amount of $6,400.00 to correct extensive leakage on both floors of the Bermudez home. Mrs. Bermudez gave a deposit in the amount of $1,860.00 and was told that the repairs would begin in two weeks and be completed in approximately five weeks. In December 1992, and January, 1993, the Respondent performed some minor patching but no significant work was undertaken to repair the Bermudez home. In January, 1993, Respondent pulled a permit to replace the Bermudez roof. Within a week of the permit, Respondent sent an unsigned form letter to the Bermudez advising them that there would be delays. In February and March, 1993, the Respondent's crew stripped the old tile off the Bermudez home and installed batten and roofing paper over the decking. Mrs. Bermudez made deposits totalling $3,720.00 to Respondent in connection with this contract. Despite numerous requests from Mrs. Bermudez, Respondent did not complete the roof. In July, 1993, Respondent sent a crew to the Bermudez home in connection with a leak but the repair did not resolve the problems and did not substantively finish the roof. As with the other cases, between July and November, 1993, Respondent sent numerous unsigned form letters to Mrs. Bermudez offering false or ridiculous excuses for why the project had not been completed. In January, 1994, Mrs. Bermudez filed a formal complaint against Respondent but he never completed the job nor refunded the deposits. Between March and July, 1994, Respondent represented he would complete the Bermudez job but did not do so. The Bermudez roof was not completed until December 13, 1994. As a result of Respondent's incompetence, inability, or refusal to complete the Bermudez roof, the family lived with a leaking roof for approximately two years and incurred unnecessary expenses. Respondent showed a gross indifference to the plight of the Bermudez family. Respondent could not have timely completed the projects described above during the period July, 1993 to July, 1994, as his workers compensation had expired. The numerous promises to perform the contracts as originally agreed were meaningless.
Recommendation Based on the foregoing, it is, hereby, RECOMMENDED: That the Department of Business and Professional Regulation, Construction Industry Licensing Board enter a final order revoking Respondent's licenses, requiring Respondent to make full restitution to the consumers in these cases before being entitled to seek new licensure, imposing an administrative fine in the amount of $10,000, and assessing costs of investigation and prosecution of these cases as set forth in the affidavits filed in this cause. DONE AND RECOMMENDED this 25th day of October, 1995, in Tallahassee, Leon County, Florida. JOYOUS D. PARRISH Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 25th day of October, 1995. APPENDIX TO RECOMMENDED ORDER, CASE NOS. 95-1079, 95-1080, 95-1081, 95-1082 Rulings on the proposed findings of fact submitted by the Petitioner: 1. Paragraphs 1 through 155 are accepted. Rulings on the proposed findings of fact submitted by the Respondent: 1. None submitted. COPIES FURNISHED: Elizabeth Masters Senior Attorney Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 230 Jacksonville, Florida 32211 Darryl Saibic 821 S.W. Dwyer Road Port St. Lucie, Florida 34983 Richard Hickok Executive Director Department of Business and Professional Regulation Construction Industry Licensing 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, the documentary evidence received and the entire record compiled herein, the following relevant facts are found. Jesse Bruce, Respondent herein, is a registered roofing contractor and has been issued license No. RC0022948. On September 2, 1981, Respondent entered into a contract to repair a roof at 3684 NW 29th Street, Lauderdale Lakes, Florida, for Ms. Beryl Babb for the sum of $485.00. Respondent admits that he commenced construction under the above-referenced contract without first having obtained a building permit. Respondent was paid in full under the contract by Ms. Babb on September 4, 1981. Pursuant to the terms of the construction contract, Respondent provided for a two-year warranty on the roof repairs. Within an approximate two-month period following the repairs by Respondent, Ms. Babb made repeated phone calls to Respondent's construction company to report complaints that she was having in that the roof and garage appeared to "leak more than it had leaked prior to the repairs." Ms. Babb made at least six telephone calls to Respondent's construction company to no avail. During November, 1981, Ms. Babb filed a civil complaint in small claims court and during January, 1982, Ms. Babb received a judgment against the Respondent for $300.00. 1/ Respondent ahs been a licensed and registered roofing contractor since October, 1974. Respondent acknowledged that he received complaints from Ms. Babb as was testified herein; however, he states that he was busy during the times in which the complaints were made, an further that he did not want to make repairs inasmuch as Ms. Babb had elected to file a civil complaint against him in small claims court. Finally, Respondent acknowledged that he was obliged to return tot he Babb residence to make the repairs inasmuch as the complaints from Ms. Babb came during the two-year period in which the warranty for the roof repairs was in effect.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Respondent be placed on probation for a period of six (6) months. 3/ RECOMMENDED this 3rd day of February, 1983, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 3rd day of February, 1983. COPIES FURNISHED: Michael J. Cohen, Esquire Suite 101, Kristin Building 2715 E. Oakland Park Blvd. Ft. Lauderdale, Florida 33306 Jesse Bruce 721 NW 20th Ave. Ft. Lauderdale, Florida 33311 Mr. James Linnan Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Mr. Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact The Respondent is a registered roofing contractor, having been issued license number RC 0020923. On may 27, 1982, the Respondent, doing business as T & T Roofing Company, contracted with Jessie Reid, 1021 Abeline Drive, Deltona, Florida, to replace an existing shingle roof for a total contract price of $2,406.20. At all times material hereto, the Respondent was registered with the Construction Industry Licensing Board as qualifying agency for A. L. Roofing Specialists. At no time has the Respondent qualified T & T Roofing Company. On August 26, 1982, when the Respondent completed work on Jessie Reid's roof, he was paid $2,406.20 which was the entire contract price for this job. The Respondent was to return to the job site to inspect the roof and correct minor remaining problems. However, when the Respondent would not return to the job, even after repeated calls, it was determined that there is a difference in shingle thickness at points on the roof, and the rain runs down over the gutters instead of into them. Further, the hip and ridge caps are of a different material than the major portion of the shingled roof; there are exposed nails; and the gutters are filled with roofing debris. The Respondent has not been responsive to communications and he has refused to make the necessary corrections to Jessie Reid's roof. The Respondent never obtained a permit for the reroofing work done for Jessie Reid at 1021 Abeline Drive, in Deltona. A permit is required to do reroofing work in Deltona, which is within the jurisdiction of Volusia County.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Registered Roofing Contractor's license number RC 0020923 held by the Respondent, John W. Thorn, be revoked. DONE AND ENTERED this 30th day of May 1984 in Tallahassee, Florida. WILLIAM B. THOMAS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of May 1984. COPIES FURNISHED: Edward C. Hill, Jr., Esquire 130 North Monroe Street Tallahassee, Florida 32301 Mr. John W. Thorn Post Office Box 1897 Deland, Florida 32720
The Issue The issues to be resolved in this case are those promoted by the second amended administrative complaint brought by the State of Florida, Department of Professional Regulation against the Respondent, David W. Crosby. Briefly, the basic allegations are that the Respondent granted to James Crosby, d/b/a U.S. Seamless Roof Systems, the unlimited opportunity to obtain building permits under the Respondent's contracting license. This arrangement, it is alleged, was in the face of a circumstance in which James Crosby was not registered, certified, or otherwise licensed by the Construction Industry Licensing Board, nor had the Respondent qualified U.S. Seamless Roof Systems with the Construction Industry Licensing Board. It is further alleged that between August 1982 and in or about 1985 James Crosby operated a roofing contracting business in St. Johns County, Florida, and in St. Augustine, Florida, and utilized the Respondent's authorization to obtain certain building permits and that James Crosby then performed roofing work authorized by those permits. By reason of this arrangement Respondent is said to have violated Sections 489.119 and 489.129(1)(e) (f) (g) (j) and (m), Florida Statutes. There are additional allegations of similar nature pertaining to work in Brooksville and Inverness, Florida.
Findings Of Fact Facts found based upon responses to requests for admissions propounded from Petitioner to the Respondent (see Petitioner's Exhibit 1 admitted into evidence) Respondent's name is David W. Crosby. Respondent is a certified roofing contractor in the State of Florida having been issued license number CC CO 15442. At all times material to the pending Administrative Complaint, Respondent was a certified roofing contractor in the State of Florida having been issued license number CC CO 15442. Respondent's license number CC CO 145442 is active for the period expiring June 30, 1987. In or about August 1982, Respondent issued an unlimited authorization, addressed "To whom It May Concern," which authorized all building departments to issue roofing permits to Respondent's brother, James Crosby. Said James Crosby was operating a roofing business in the period 1982 to 1985, in and about the St. Johns County and St. Augustine area. On or about January 13, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems obtained permit number 12102 from the City of St. Augustine. Said permit, number 12102, was obtained to repair a roof for Zorayda Castle of 83 King Street, St. Augustine, Florida. On or about February 3, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12122 from the City of St. Augustine. Said permit, number 12122, was obtained to reroof the residence of Zorayda Castle of 83 Ring Street, St. Augustine, Florida. On or about February 24, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12158 from the City of St. Augustine. Said permit, number 12158, was obtained to reroof the residence of Lillian Perpall of 67 Abbott Street, St. Augustine, Florida. On or about May 17, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, obtained permit number 12288 from the City of St. Augustine. Said permit, number 12288, was obtained to reroof the residence of Emily M. Alexander of 20 Cuna Street, St. Augustine, Florida. On or about May 2, 1983, said James Crosby, d/b/a U.S. Seamless Roofing Systems, contracted with Lawrence Golden to repair the roof at Golden's residence at 17 Bay View Drive, St. Augustine, Florida, for a contract price of $985. On or about March 28, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, used contractors license number CC CO 15442 to obtain permit number 3781-81 from St. Johns County Florida. Said permit, number 3781-81, was obtained to reroof the residence of Burton Chase of St. Johns County, Florida. On or about March 28, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, used contractors license number CC CO 15442 to obtain permit number 3780-81 from St. Johns County, Florida. Said permit, number 3780-81, was obtained to reroof the residence of Fred Jensen of St. Johns County, Florida. On or about May 7, 1984, said James Crosby, d/b/a U.S. Seamless Roofing Systems, contracted with Ceal Butler to repair Butler's roof on his residence at Rt. 3, Box 56W3, St. Augustine, Florida, for the contract price of $1,335. Said contract referenced in number 20 above, was executed on a printed form bearing contractors license number CC CO 15442. At no time relevant hereto did Respondent qualify the roofing business, American Roof and Waterproofing Company and/or American Roofing and Waterproofing Company. Facts found based upon testimony at final hearing and exhibits admitted at final hearing James Crosby is also known as James A. Crosby, Jr., and Jim Crosby. On May 17, 1982, James A. Crosby, Jr., who held registered roofing contracting license number RC 0029375, voluntarily relinquished that license in Department of Professional Regulation, Construction Industry Licensing Board v. James A. Crosby, Jr., DPR Case No. 006237. On June 30, 1987, the Construction Industry Licensing Board, in accordance with that voluntary relinquishment, entered a final order approving and accepting the relinquishment. See Petitioner's composite Exhibit 3. James Crosby, in those instances described in the fact finding related to roofing contracting activities, was unlicensed and therefore not authorized to practice contracting, to include roofing contracting. See Petitioner's Exhibit 4 admitted into evidence, a February 7, 1986, notice to cease and desist in the case of State of Florida, Department of Professional Regulation vs. James Crosby, DPR Case No. 62490, in which it is indicated that James Crosby does not hold the necessary license to do roofing work or other forms of contracting contemplated by Chapter 489, Florida Statutes. Petitioner's Exhibit 5 is a copy of the general authorization which Respondent directed "To Whom It May Concern" in August 1982 authorizing James Crosby ". . . to pull permits for all roof work done by U.S. Seamless Roof Systems, St. Augustine, Florida." A copy of Respondent's certified roofing contractors license was attached to this authorization. This authorization has never been withdrawn and still remains on file with the City of St. Augustine, Florida, Building Department. At all relevant times related to the second amended administrative complaint, the City of St. Augustine, Florida, by ordinance, had adopted the Southern Building Code, which required building permits to be issued by the City before James Crosby or the companies under whose name he was doing business could undertake the various projects that are contemplated by the second amended administrative complaint. In January 1983, James Crosby entered into a contract with Wallace Mussallem for the roof repair in a tourist attraction in downtown St. Augustine, Florida, known as Zorayda Castle. Price of the repairs was approximately $6500. Petitioner's composite Exhibit 6 admitted into evidence pertains to various building permit applications and for certificate of appropriateness which James Crosby filed related to the Mussallem job. Crosby was operating under the name U.S. Seamless Roofing Co. as depicted in the aforementioned composite exhibit. Crosby completed the job and was paid the full amount of the contract. Crosby warranted his repair work for a period of ten years. During the initial two years, the roof did not leak; however, in 1986 a number of leaks occurred in the roof. Mussallem was unable to locate James Crosby to fix the roof and Mussallem had another roofer effect repairs and spent $3000 to have one section of the roof repaired. As of the time of the hearing, when Mussallem gave his testimony, part of the roof was still leaking and needed to be fixed. Respondent was never involved in the transaction between Mussallem and James Crosby, beyond giving permission to James Crosby to pull building permits from the City of St. Augustine, Florida. On March 4, 1984, Mr. and Mrs. William Blanchard entered into a contract with James Crosby, d/b/a American Roof and Waterproofing Company. James Crosby's associate, Basil R. Boone, was the person who estimated the job; however, the contract was with James Crosby. A copy of that contract can be found as Petitioner's Exhibit 14 admitted into evidence. It calls for the repair of the roof on the Blanchards' residence in St. Augustine, Florida. On April 5, 1985, James Crosby applied for a building permit from the City of St. Augustine to do the roofing work at the Blanchard home, and on April 30, 1985, that building permit was issued. Petitioner's composite Exhibit 8 is a copy of the application for permit and the permit. The price of the contract was $1575. James Crosby was paid for the roofing work. In the course of this transaction, William Blanchard had no occasion to deal with the Respondent. On May 7, 1984, James Crosby, d/b/a U.S. Seamless Roof Systems contracted with Ceal Butler of St. Johns County, Florida, to do roof repair work on a mobile home belonging to Mr. Butler. See Petitioner's Exhibit 15 admitted into evidence. The contract price was $1335 and Crosby guaranteed the work for ten years. May l8, 1984, James Crosby, as referred to in the check written to the Butlers as "Jim Crosby," was paid the contract amount. The contract form that was utilized in the Butler case referred to the Florida certified contracting number which pertains to the Respondent. Notwithstanding this reference, Respondent did not involve himself with this project. The Butlers immediately began to experience problems with the roofing work done by James Crosby. There were leaks in the roof repair work. The Butlers made numerous requests to have James Crosby honor the warranty, but the repairs were not made. Eventually, another roofer other than James Crosby had to make the repairs on the roof. Lillian Perpall owned a home in St. Augustine, Florida, and contracted with James Crosby to do roofing repair work at her residence. A copy of the contract may be found as Petitioner's Exhibit 17 admitted into evidence. James Crosby was doing business in this instance as U.S. Seamless Roof Systems. The contract price was $4875 and the project carried a ten-year guarantee. On February 24, 1983, in furtherance of the conduct of the project, James Crosby applied for a building permit which was granted that same day. A copy of the application and building permit may be found as Petitioner's composite Exhibit James Crosby was paid the full amount of the contract price for concluding the roofing repair work. Within a year after the work had been done, there was a leak in the roof and James Crosby came and put another coat of material on the roof in response to the complaint of Ms. Perpall. In the last eight or ten months, the back porch area where roof repairs had been made began to leak. Ms. Perpall has tried to contact James Crosby about that problem and has been unable to. In particular, she tried to make contact at the telephone number listed on the contract document that was signed. On the evidence presented, it is found that the Respondent did not participate in the roofing repair work at the Perpall residence, On October 14, 1982, James Crosby, d/b/a U.S. Seamless Roof Systems contracted with Edward Carriere to perform room repair work on Carriere's residence in St. Augustine, Florida. The contract amount was $5100 and the contract included a ten-year guarantee. A copy of the contract may be found as Petitioner's Exhibit 18 admitted into evidence. This contract format bears Respondent's Florida certified contractor's number. In furtherance of this work, James Crosby applied for a building permit from the City of St. Augustine on September 28, 1982, and that permit was issued that same day. A copy of the application and permit may be found as Petitioner's composite Exhibit 11 admitted into evidence. A second building permit related to this work was issued on October 27, 1982, from the City of St. Augustine as acknowledged by James Crosby and is found as part of the Petitioner's composite Exhibit 11. From the beginning, following the work, Carriere has experienced problems with the repair work. These problems are leaks in the roof. They have caused damage in the kitchen and living room area of the Carriere home. James Crosby responded to complaints about the room leaking, but did not fix the problem. The roof leaked from 1983 to 1985. By 1985, Carriere was unable to locate James Crosby to fix the leaking roof. Being unsuccessful in locating James Crosby, Carriere hired another roofer to fix the problem in January 1986. This cost an additional amount of approximately $5800. Carriere never dealt with the Respondent in the roof repair project at his home. On May 2, 1983, Lawrence G. Golden contracted with a representative of U.S. Seamless Roof Systems, the company of James Crosby, to have roof repair work done at the Golden residence in St. Augustine, Florida. A copy of the contract entered into with the company be found as Petitioner's Exhibit 19 admitted into evidence. The contract amount was $985 and the work carried a ten-year guarantee. Lawrence Golden paid the man $985 called for by the contract. Mr. Golden had problems with the roof repair work with the advent of heavy rains, in that the roof leaked. After numerous attempts to contact the company, James Crosby came to examine the nature of the complaint. James Crosby did not fix the problems with the leaking roof or cause them to be fixed until Golden had made a complaint to the State of Florida, Department of Professional Regulation. James Crosby did not obtain a building permit for the roof repair work, nor was a building permit obtained by anyone other than James Crosby. Golden did not deal with the Respondent in the transaction involving the roof repair. On July 15, 1982, Wilbur Lane contracted with James Crosby d/b/a U.S. Seamless Roof Systems to perform roof repair work on Lane's residence in St. Johns County, Florida. The roof repair contract carried the certified roofing contractor license number associated with the Respondent. The amount of the contract price was $1300 and the work carried a ten-year guarantee. James Crosby completed the construction work and received the full payment. A copy of the contract may be found as Petitioner's Exhibit 20 admitted into evidence. Although James Crosby was paid the amount contemplated by the contract, the roof repair work was not successful. After the project was undertaken, Lane experienced leaks inside of his home and made numerous attempts to try to contact James Crosby to take care of the problem. Crosby did attempt to fix the leaks, but failed in the attempt. Eventually Mr. Lane was unable to contact Crosby to continue the effort at rectifying the problem and Mr. Lane had to complete his own repair work on the roof to stop the leaks. Lane never had occasion to deal with the Respondent in this project. 35, The Department of Professional Regulation investigator Augostino A. Lucente investigated the complaint that had been filed by Lawrence Golden and spoke with the Respondent. Respondent indicated that he did not know anything about Mr. Golden or his problem or the fact that roofing repair work had been undertaken by U.S. Seamless Roof Systems. Respondent did indicate to Lucente that James Crosby was using Respondent's certified roofing contractor's license to obtain building permits. Respondent stated that he was trying to do his brother a favor by setting up a company for him in the St. Augustine area. In actuality, James Crosby may not be the brother of Respondent and may in fact be Respondent's cousin. Respondent told Lucente that he had issued the authorization letter, Petitioner's Exhibit 5, and that he had intended to open up a business in the St. Augustine area and to put James Crosby in charge. After about six weeks, Respondent said that he determined that he did not want to do anything with the St. Augustine situation and left everything as it was. This decision came about in September 1982. Respondent also denied any knowledge of the Carriere contract. On October 22, 1986, Petitioner took action against the Respondent in DPR Case Nos. 59109 and 59115 by the entry of a final order disciplining the license which is at issue in this proceeding. A copy of that final order and the underlying administrative complaint may be found as Petitioner's Exhibit 2 admitted into evidence.
The Issue Whether Respondent should be disciplined for failure to comply with provisions of Florida law?
Findings Of Fact Respondent, George F. Garrard, is licensed as a registered roofing contractor holding State of Florida license number RC 0045805. On May 14, 1986, Respondent entered into a contract with Ronald Skinner to reroof a house located at 2226 Eudine Drive, in Jacksonville, Florida. The contract provided that Respondent would: "Tear off the entire roof to sheeting. Haul off all debris. Install 5 ply-build-up roof. New metal edging." In exchange for the work, the contract called for Respondent to receive $1100.00, $600.00 to be paid in advance for materials and $500.00 to be paid upon completion of the job. 2. Mr. Skinner paid Respondent the $600.00 advance for materials and work on the roof began the following day. While the work on the roof was in progress, Mr. Skinner conducted periodic inspections and noticed that the felt had buckled up. Mr. Skinner asked Respondent how he was going to fix the felt and Respondent said that he could fix the felt by cutting out the buckled parts and patching the felt. Mr. Skinner responded that he had a patched roof before and did not want another; he wanted a new roof. Respondent promised he would fix the problem. Prior to the work being completed, Respondent made a telephone call to Mr. Skinner and asked for payment of the remaining balance on the contract in order to purchase the materials needed to finish the job. Mr. Skinner agreed to meet John T. Garrard (Respondent's son) at the house and pay the balance. Respondent authorized Mr. Skinner to pay John T. Garrard. When Mr. Skinner arrived at the house, John T. Garrard and another person were unloading rocks from a pick-up truck and placing the rocks in a pile on the carport roof. Mr. Skinner paid John T. Garrard $500.00 and John T. Garrard wrote "Paid in Full" on the face of the contract and signed his name. A few minutes after Mr. Skinner left the house, John T. Garrard and the other person also left the house. Two or three days later, Mr. Skinner returned to the house. He noticed that no further work had been done. The rocks which had been unloaded from the pickup truck were still in a pile on top of the carport. Mr. Skinner was afraid the weight of the rocks would damage the carport so he spread the rocks on the roof. There were not enough rocks to cover the whole roof. Also, the rocks were loose because no tar had been spread on the roof to hold the rocks in place. Mr. Skinner contacted Respondent or someone in his household several times, and Respondent assured him he would finish the job. No further work was done on the roof by Respondent. Mr. Skinner last contacted Respondent by letter dated January 26, 1987, wherein he asked that Respondent finish the job since he had been paid in full. On the date of the hearing, the roofing job had not been completed. The rocks were still insufficient to cover the entire roof, no tar had been spread to hold the rocks in place, and the felt was still buckled in various places. Respondent never obtained a building permit for the reroofing job.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that Petitioner enter a final order finding Respondent guilty of violating Sections 489.129(1)(d) and (k), Florida Statutes, and imposing a fine of $2,000 on Respondent. DONE and ENTERED this 30th day of March, 1988, in Tallahassee, Florida. JOSE A. DIEZ-ARGUELLES Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 30th day of March, 1988. COPIES FURNISHED: David L. Swanson, Esquire Department of Professional Regulation 120 North Monroe Street Tallahassee, Florida 32399-0750 George F. Garrard 4622 Tabernacle Place, East Jacksonville, Florida 32207 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750
The Issue The issue is whether Respondent should have an administrative fine or other disciplinary action imposed for allegedly acting as a contractor without a license.
Findings Of Fact Based upon all of the evidence, the following findings of fact are determined: When the events herein occurred, Respondent, Edsel Mathews, operated a business under the name of Home Repair Roofing in Monticello, Florida. Records of Petitioner, Department of Business and Professional Regulation, Construction Industry Licensing Board (Board), establish that Respondent holds no licenses from that Board and thus he is not authorized to engage in any professions regulated by the Board. Gessie Lee Choice owns a residence at 1701 South Campbell Street, Perry, Florida. In 1995, her home was partially destroyed in a fire. Based on a recommendation by her lender, who was refinancing the repair work, Choice selected Respondent to repair her home. Relevant portions of the City Code of the City of Perry (City) were not made a part of this record. However, testimony established that under the licensing scheme for the City, an individual who has a specialty contractor license from the City may perform residential carpentry work if he works under the supervision of a licensed contractor. Alternatively, the same work may be performed by the license holder if the property owner obtains a building permit and signs an affidavit that he or she will be supervising the work. The license does not, however, authorize the holder to perform air-conditioning, electrical, or plumbing work even if the owner supervises the project. In addition, roofing work involving structural changes can only be performed under the auspices of a licensed roofing contractor. Respondent held a valid specialty contractor license from the City. On August 7, 1995, Choice obtained a building permit from the City and executed an affidavit stating that she would be supervising the work. Under these circumstances, Respondent was authorized to perform all work on the house except that relating to the plumbing, electrical, and air-conditioning systems. Also, he could not perform any structural work on her roof. The evidence is conflicting as to the representations Respondent made to Choice regarding his qualifications before the two parties executed a contract. The more persuasive evidence supports a finding that he represented he was a "subcontractor," but was not a licensed contractor within the Board's purview. While there is a conflict as to representations regarding his ability to perform plumbing and electrical work, it is found that Respondent simply agreed to procure for Choice a licensed plumber and electrician to do that type of work. Under the agreement executed by Choice, Respondent agreed to "furnish and perform the labor necessary for the completion" of a wide array of work. The items to be completed are listed on Petitioner's exhibit 3 and include removing asbestos from the outside of her house, enlarging three bedrooms and bath, removing an existing tin roof, installing new rafters, reroofing the home, building new cabinets and installing new plumbing and wiring for the kitchen, remodeling the existing bathrooms, building a utility room, installing new windows, insulating walls and ceilings, drywalling all ceilings, installing new carpet and vinyl, and placing vinyl siding on outside of home. Respondent established that even though the contract lists a number of items outside the scope of his authority, he intended to get licensed contractors to perform all work for which he held no authority under his city license. Choice agreed with this assertion. Despite Respondent's offer to obtain other contractors to perform the electrical and plumbing work, Choice selected her own licensed contractors to do that work. She also hired another individual to remove the asbestos from her home. Respondent performed a part of the remaining work, including the installation of a new roof. This latter work involved structural changes upon the house. Respondent made two draws totaling $13,200.00 from the escrowed funds. Also, in September 1995, Choice paid Respondent $446.00 in personal funds to purchase plywood to be placed on the floor and walls of the house. There is no allegation, however, that he failed to perform an equivalent amount of work before he was told by a Board inspector to stop working on the project. A short time after Respondent terminated work, a City building inspector, David Parker, inspected the roofing work performed by Respondent. Parker found that the truss system did not meet building code requirements. Because of numerous code violations, which are enumerated in Petitioner's Exhibit 9, the entire roof system had to be removed and reinstalled. Parker also noted that Respondent's work involved structural changes not authorized under his license. In mitigation, however, it is found that Respondent believed that he was authorized to do this work under his local license. Choice was forced to hire a licensed roofing contractor to reroof her home. That contractor described Respondent's workmanship as "not good." In order to correct the deficiencies and complete the remodeling project, Choice expended another $12,000.00 over and above her original contract price of $33,490.00. Except for this incident, there is no evidence of Respondent violating Board rules and statutes relating to contracting.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Construction Industry Licensing Board enter a Final Order finding Respondent guilty of violating Section 489.127(1)(f), Florida Statutes, and that a fine in the amount of $1,000.00 be imposed, to be paid within such time as the Board deems appropriate. A decision on Petitioner's request for the assessment of costs against Respondent under Section 455.227(3), Florida Statutes, is deferred to the Board. Finally, Counts I and II should be dismissed. DONE AND ENTERED this 4th day of November, 1997, in Tallahassee, Leon County, Florida. DONALD R. ALEXANDER Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (904) 488-9675 SUNCOM 278-9675 Fax Filing (904) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 4th day of November, 1997. COPIES FURNISHED: John O. Williams, Esquire Post Office Box 14267 Tallahassee, Florida 32317 Clifford L. Davis, Esquire Post Office Box 1057 Monticello, Florida 32345 Rodney Hurst, Executive Director Construction Industry Licensing Board 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Lynda L. Goodgame, Esquire Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Joseph Barrass is a registered roofing contractor holding State of Florida license number RC0026890. Respondent was so licensed at all times relevant to this proceeding. Respondent began doing business as a registered roofing contractor through his corporation, J. B. Roofing and Repairs, Inc., about six years ago. This corporation was dissolved and he continued as a roofing contractor through a corporation known as Roofing Services, Inc. He next did business through a third corporation, C. B. Roofing, Inc. Most recently he has done business as C. B. Roofing, a sole proprietorship. Respondent failed to register any of these entities with Petitioner, and is still licensed under his original fictitious name, J. B. Roofing and Repairs. Respondent contracted with Green Glades Construction Co. in early 1979, to install roofs on some 28 new houses. A dispute arose between the parties regarding several unfinished and leaking roofs. Respondent contends he refused to complete the roofs at issue due to nonpayment in accordance with the oral contract. He also argues that he was unable to repair the leaks while the roofs were wet, as demanded by Green Glades. The dispute was settled through civil proceedings. Another matter which culminated in civil action concerned the installation and repair of a patio roof pursuant to an oral contract between Respondent and Marvin Berkowitz, at the latter's Coral Springs residence. Berkowitz complained that Respondent failed to correct a leak in this roof as required by their agreement. Respondent claims the leak was the result of an improperly installed ceiling fan and the flat roof design demanded by Berkowitz. Respondent completed the job and received final payment on October 9, 1979. However, the roof leaked and Berkowitz thereafter contacted Respondent on numerous occasions requesting repairs. It was not until Berkowitz retained counsel and threatened legal action that Respondent made any effort to repair the leak. He returned on February 14, 1980, and did limited repair work. The roof continued to leak and Berkowitz sought damages through civil action. The evidence is conflicting as to whether or not the ceiling fan had been removed when Respondent returned in February, 1980. Berkowitz testified that it had been removed, and Respondent testified that it had not. The evidence is also in conflict with respect to the caveats and/or assurances Respondent gave Berkowitz regarding this installation. The recollections of both witnesses were self-serving and their testimony was generally lacking in credibility. The City of Coral Springs' building code requires a contractor to obtain a permit prior to roof installation. Respondent knew he was required to obtain such a permit for the Berkowitz project, but failed to do so.
Recommendation From the foregoing, it is RECOMMENDED: That Respondent be found guilty of violating Sections 489.119, 489.129(1)(g) and 489.129(1)(j), F.S., in failing to register his business entities and contracting without requisite qualification. It is further RECOMMENDED: That Respondent be found guilty of violating Subsection 489.129(1)(d), F.S., for wilful disregard of the Coral Springs building code pertaining to building permits. It is further RECOMMENDED: That all other charges against Respondent be dismissed. It is further RECOMMENDED: That Petitioner suspend Respondent's roofing contractor's license for a period of six months. DONE AND ENTERED this 17th day of February, 1982, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 17th day of February, 1982.
The Issue The issues in Case No. 07-4376PL are whether Respondent violated Subsections 489.129(1)(i), 489.119(2), 489.126(2)(a), and 489.129(1)(j), (m), and (o), Florida Statutes (2004),1 and, if so, what discipline should be imposed. The issues in Case No. 07-4377PL are whether Respondent violated Subsections 489.1425(1), and 489.129(1)(i) and (o), Florida Statutes, and, if so, what discipline should be imposed.
Findings Of Fact Petitioner is the state agency charged with regulating the practice of contracting pursuant to Section 20.165 and Chapters 455 and 489, Florida Statutes. Mr. Roach is, and was at all times material to this action, a certified roofing contractor in the State of Florida having been issued License No. CCC1326005. Mr. Roach's Certified Roofing Contractor License No. CCC1326005 is current and active. Mr. Roach's current addresses of record are Post Office Box 345, Orange Springs, Florida, and 22204 U.S. Highway 301, Hawthorne, Florida. At all times material to this action, Mr. Roach was a licensed qualifier for All Florida Roofing Contractors, Inc. (All Florida). There is evidence in the record sufficient to establish that Mr. Roach has been previously disciplined for a violation under Chapter 489, Florida Statutes. Notably, Mr. Roach has been previously disciplined for, among other things, violations of Subsections 489.129(1)(m) and (o), Florida Statutes. Case No. 07-4376PL Mr. Roach failed to obtain a Certificate of Authority for All Florida, as required by Subsection 489.119(2), Florida Statutes. On or about August 23, 2004, Mr. Pang contracted with Mr. Roach, to remove and replace the hurricane-damaged roof of his hotel property located at 1620 West Vine Street, Kissimmee, Florida. The contract price for the aforementioned project was $40,000.00. Mr. Pang made an initial payment of $2,250.00 on August 22, 2004, and another payment of $20,000.00 on August 23, 2004. As part of the contract, All Florida was required to pull the building permits for the project, and Mr. Roach failed to do this. Mr. Roach commenced work on the project on or about September 7, 2004. On or about late September 2004, he ceased work on the project, and the project remained unfinished. Mr. Pang paid All Florida an additional $10,000.00 on September 16, 2004. On October 1, 2004, the City of Kissimmee issued a Notice of Violation against Mr. Pang for failure to have a building permit for the work that had been performed by Mr. Roach on the roof. Mr. Roach scheduled repairs on the project, but did not return to the project. Mr. Roach did not have any inspections performed on the roof. Later, another contractor hired by Mr. Pang finished the roofing project at a cost of an additional $32,975.00. Case No. 07-4377PL On or about September 15, 2004, Ms. Perez contracted with Mr. Roach to repair roof damage to her residence at 1502 Golden Poppy Court, Orlando, Florida. The contract price for the aforementioned project was $7,268.32, of which Mr. Roach was paid $3,634.16 on September 18, 2004. The contract entered into between Ms. Perez and Mr. Roach failed to inform the homeowner of the Construction Industry Recovery Fund. On or about October 27, 2004, the Orange County Building Department issued Mr. Roach a permit for the aforementioned project (Permit No. T04018050). Mr. Roach did not have any inspections performed on the roof. On September 25, 2004, Ms. Perez paid $3,614.16 to All Florida, which was the remaining amount of the contract. Another contractor was hired by Ms Perez to correct deficient aspects of Mr. Roach's work on the roof at a cost of $900.00.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered whose outcome is the following: That in Case No. 07-4376PL Respondent violated Subsections 489.129(1)(i), (j), (m) and (o), Florida Statutes; Dismiss Count II of the Administrative Complaint in Case No. 07-4376PL; In Case No. 07-4376PL, imposing an administrative fine of $1,000.00 for the violation of Subsection 489.129(1)(i), Florida Statutes; imposing an administrative fine of $5,000.00 for the violation of Subsection 489.129(1)(j), Florida Statutes; imposing an administrative fine of $2,500 for the violation of Subsection 489.129(1)(o), Florida Statutes; no administrative fine is recommended for the violation of 489.129(1)(m), Florida Statutes, because the violation is included in the violations of Subsections 489.129(1)(j) and (o), Florida Statutes; That in Case No. 07-4377PL, Respondent violated Subsections 489.129(1)(i) and (o), Florida Statutes; In Case No. 07-4377PL, imposing an administrative fine of $1,000 for the violation of Subsection 489.129(1)(i), Florida Statutes; imposing an administrative fine of $2,500 for the violation of Subsection 489.129(1)(o), Florida Statutes; Requiring Respondent to make Restitution to Mr. and Mrs. Pang in the amount of $25,000; Requiring Respondent to make Restitution to Ms. Perez in the amount of $900; and Revoking Respondent's contractor license. DONE AND ENTERED this 31st day of March, 2008, in Tallahassee, Leon County, Florida. S SUSAN B. HARRELL Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 31st day of March, 2008.
Findings Of Fact Based on my observation of the witnesses and their demeanor while testifying, the documentary evidence and the positions of the parties, I hereby make the following: Thomas G. Walker (herein sometimes called "Licensee" or "Respondent") is a registered residential contractor and is issued license number RR 0009839. Thomas G. Walker was initially licensed by the Board in July of 1969 as an individual and during January, 1975, he changed his registration status as an individual to qualify Insulshield Roofing as the business entity through which he would conduct his business (Petitioner's Exhibit No. 1). An examination of the official records pertaining to the Licensee reveals that he does not now nor has he ever held a roofing license in the State of Florida. On February 16, 1979, the Licensee was apprehended contracting roofing without a State roofing contractor's license by the Board's representative and was issued a Notice of Violation (Petitioner's Exhibit No. 3). On July 26, 1977, the Licensee entered into an agreement with Jan Soderstrom, 501 Orlando Avenue, Indialantic, Florida, to remove the tile from the Florida Room of her residence and hot mop the herein-described roofing area, to replace tile as needed, to clean and coat the entire roof, and to install a cap over Ms. Soderstrom's chimney. He guaranteed the work for a period of five (5) years and charged a contracted price of $800.00. The Licensee was paid the contracted price of $800.00 by check dated August 4, 1977 (Petitioner's Exhibit No. 5). During early February, 1978, Ms. Soderstrom detected a leak in her roof and summoned the Licensee back to her residence to repair same. During February, 1978, Respondent returned to Ms. Soderstrom's residence to repair the leak in her roof. Upon his return, he removed several roof tiles and since February, 1978, to the present, he has not returned to this project. Clyde Pirtle, a field investigator for the Board, investigated the Licensee based on complaints that he received from Ms. Soderstrom and from a Mr. Capitz. On or about February 16, 1977, Mr. Pirtle discussed a Notice of Violation with the Licensee and explained to him the necessity to register as a Roofing Contractor, if he was in the business of acting as a Roofing Contractor. Mr. Charles D. Franklin, a building official of Indian Harbor Beach, Florida, is the custodian of the records in Indian Harbor, Florida. Based on an examination of the records by Mr. Franklin, the Respondent/Licensee is not registered as a Roofing Contractor locally.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby, RECOMMENDED: That the registered residential contractor's license, number 0009839, of the Licensee, Thomas G. Walker, d/b/a Insulshield Roofing, be suspended for a period of one (1) year. RECOMMENDED this 4th day of April, 1979, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 2400 Independent Square Jacksonville, Florida 32202 Thomas G. Walker d/b/a Insulshield Roofing 170 5th Street South Melbourne Beach, Florida 32951 J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
Findings Of Fact At all times material hereto, Respondent Robert F. Copenhaver was holder of a registered general contractor's license number RG 0013968 issued by the State of Florida. At all times material hereto, Respondent qualified Southwest Building and Development Corporation with the Construction Industry Licensing Board. See Petitioner's Exhibit #1. At all times material herein, neither Respondent nor Southwest Roofing and Waterproofing, Inc., were registered or certified as a roofing contractor with the Board. See Petitioner's Exhibit #1. At all times material herein, Respondent was the holder of a Class C building contractor's license and a specialty limited roof-coating and spraying license, both issued by Sarasota County. See Transcript of Proceedings, page Said license was limited to work done to cosmetically improve a roof. Any work done to repair leaks required a standard roofing license. Respondent and Don Cogswell incorporated Southwest Roofing and Waterproofing, Inc. (SRWI), under the laws of the State of Florida on January 10, 1980. See Petitioner's Exhibit #5. All work done by SRWI was done under the Sarasota special roofing contractor qualification. Respondent was president of the corporation until December 15, 1980, at which time he resigned and transferred all his stock to Cogswell. See Petitioner's Exhibit #6. On February 14, 1980, SRWI contracted with A. T. Esslinger to completely waterproof a roof at 816 Idlewild Way, Sarasota, Florida. See Petitioner's Exhibit #2. The only warranty referenced in the contract was a separate standard warranty to be delivered at the time of final payment. See Petitioner's Exhibit #3A. Respondent gave the Esslingers a letter (Petitioner's Exhibit #3B) in which SRWI guaranteed to stop the leaks in their roof. This letter referenced SRWI's standard warranty. To waterproof the roof, gravel was removed from the existing roof and a cement-like surface applied to the roof. On June 4, 1980, SRWI contracted with Earl Mowry to waterproof a roof at 5339 Gulf Drive, Holmes Beach, Bradenton, Florida, in accordance with specifications originally attached to the contract but not introduced at hearing. See Petitioner's Exhibit #4. To waterproof the roof, a concrete material was applied to the existing roof. On June 25, 1980, SRWI contracted with Maynard Howe to waterproof a roof over the family room in accordance with attached specifications at 2271 Mill Terrace, Sarasota, Florida. The only warranty given was the separate standard warranty to be delivered at the time of final payment. See Petitioner's Exhibits #7A and #7B. To waterproof the roof, a concrete material was applied to the existing roof. All of these contracts provided that SRWI would apply MARKEM Elastic Waterproofing material so that said roof areas were completely covered and free of all leaks. See Petitioner's Exhibits #9A, #9B and #9C for data concerning MARKEM. After the work was completed, each of the roofs in question leaked. When Respondent was contacted after he had left SRWI, he advised each of the persons that he had left the company and could not assist them. Respondent referred them back to SRWI, MARKEM or the company who became the MARKEM distributors in the area. None of the persons obtained relief from SRWI, the Respondent, MARKEM or MARKEM's new distributor. See Transcript of proceedings, pages 16, 25, 34. Howe sued SRWI and served Respondent with suit papers. In response, Respondent sent Howe a notarized document (Petitioner's Exhibit #6), which states that as of December 15, 1980, Respondent had resigned as president of SRWI and had transferred all of his stock to Don Cogswell. On October 14, 1980, SRWI contracted with Catherine Gilligan to waterproof her roof at 4819 Graywood Lane Meadows, Sarasota, Florida. See Petitioner's Exhibit #12. Gilligan paid SRWI $174 as partial payment on this contract. SRWI never did any work pursuant to the contract. Gilligan called SRWI, but to her knowledge never spoke to the Respondent concerning when SRWI was to start the job. Gilligan waited for one month, then called SRWI every day for three weeks. In the fourth week, SRWI's telephone was disconnected. This date reasonably coincides with the date Respondent resigned, December 15, 1980. No evidence was received of disciplinary action against SRWI or the Respondent by Sarasota County.
Recommendation Having found Respondent Robert W. Copenhaver guilty of violating Section 489.129(1)(j), Florida Statutes, it is recommended that the Construction Industry Licensing Board suspend the registration of Respondent as a general contractor for one year. DONE and RECOMMENDED this 21st day of December, 1982, in Tallahassee, Leon County, Florida. STEPHEN F. DEAN, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 21st day of December, 1982. COPIES FURNISHED: Stephanie A. Daniel, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Robert W. Copenhaver 2409 34th Street, West Bradenton, Florida 33505 Samuel R. Shorstein, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 K. Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 =================================================================
