The Issue Whether disciplinary action should be taken against Respondent, Michael Hill's, contracting license based on the violations as charged in the Administrative Complaint in this proceeding.
Findings Of Fact Based on the evidence and testimony of the witnesses presented and the entire record in this proceeding, the following Findings of Fact are made: Respondent is a certified contractor, having been issued License No. CR C057409 by the Florida Construction Industry Licensing Board. Respondent's license as a certified residential contractor is currently active. Respondent was not certified with the Construction Industry Licensing Board as doing business as "Michael Hill Homes, Inc." On or about April 11, 2005, Kenneth and Aldith Farquharson ("Farquharson") entered into a written contractual agreement with Respondent, d/b/a Michael Hill Homes, Inc., for the construction of a single-family residence at Lot 17, Hattaras Terrace, Palm Bay, Florida. The original contract price of the contract between Respondent and Farquharson was $240,900.00. The original contract price was subsequently increased, via change orders executed by Respondent and Farquharson, by $4,500.00, for a total contract price of $245,400.00, adding the value of the change order for the fill dirt needed for the lot. On June 19, 2005, Farquharson paid a total of $28,590.00 to Respondent. The scope of work under contract required appropriate permits from the City of Palm Bay Building Department before work could commence. Respondent failed to apply for the permits necessary to commence work under the contract. Respondent delivered some sand to the lot on or before October 2005. After delivering the sand, Respondent failed to continue any more of the contracted work. From November 2005 to December 2006, Respondent performed no work on the project under contract. From October 2005 to February 2006, Farquharson made multiple attempts to contact Respondent regarding the lack of work under the contract. Farquharson did not prevent Respondent from commencing and completing the work under contract or agree to delay the project for any reason. Farquharson did not terminate the contract with Respondent. Respondent did not refund any money to Farquharson. The amount of actual damages that Respondent caused Farquharson is calculated as follows: Amount paid: $28,590.00 Amount of work performed by Respondent (dirt fill): _ 4,500.00 $24,090.00 The Petitioner's total investigative cost for the case is $439.79.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered as follows: Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(i), Florida Statutes, as alleged in Count I of the Administrative Complaint, for violating Subsection 489.119(2), Florida Statutes, and imposing as a penalty an administrative fine in the amount of $500.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(i), Florida Statutes, as alleged in Count II of the Administrative Complaint, for violating Subsection 489.126(2)(a), Florida Statutes, and imposing as a penalty an administrative fine in the amount of $1,000.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(g), Florida Statutes, as alleged in Count III of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $2,500.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(j), Florida Statutes, as alleged in Count IV of the Administrative Complaint, and imposing as a penalty an administrative fine of $5,000.00; Finding Respondent guilty of having committed one violation of Subsection 489.129(1)(o), Florida Statutes, as alleged in Count V of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $1,000.00; Finding Respondent guilty of having committed one violation of Section 489.129(1)(m), Florida Statutes, as alleged in Count VI of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $2,500.00; Respondent be ordered to pay financial restitution in the amount of $24,090.00 to Kenneth and Aldith Farquharson; Assessing cumulative cost of investigation and prosecution in the total amount of $439.79, which excludes costs associated with any attorney's fees; and Permanently revoking Respondent's license as a result of the numerous violations and the financial harm sustained by Kenneth and Aldith Farquharson. DONE AND ENTERED this 12th day of October, 2007, in Tallahassee, Leon County, Florida. S JEFF B. CLARK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 12th day of October, 2007.
The Issue The Florida Construction Industry Licensing Board (Petitioner herein) seeks to revoke Carroll L. Mozingo's (Respondent herein) license to practice as a registered general contractor based on allegations which will be set forth hereinafter in detail that he diverted funds in violation of Chapter 468.112(2)(e), Florida Statutes. Based upon my observation of the witnesses and their demeanor while testifying and the entire record compiled herein, I make the following:
Findings Of Fact The Respondent is a registered general contractor, who holds current license no. RG0015876. On September 7, 1976, Respondent entered into a contract with Robert Johnson and his wife Sandra Johnson for a room addition and patio to their house located at 197 North Roscoe Blvd., Ponte Vedra Beach, Florida. The full amount of the contract plus agreed upon extras amounted to $9,640.00. (Petitioner's Composite Exhibit Number 2) Respondent applied for and obtained a building permit for the construction of the Johnson's addition on or about September 27, 1976, and construction commenced shortly thereafter. (Petitioner's Exhibit Number 1) Donald Jermaine, a St. Johns County field inspector, testified that he conducted inspections on the subject job and noted numerous violations of the St. Johns County Building Code. He coordinated the inspections for this project up until the time it was abandoned by Respondent during mid February, 1977. At the time of abandonment, the owner, Robert Johnson, had paid a total amount of $11,021.96 to Respondent and/or various suppliers. To complete the job as contracted by the parties (Johnson and Mozingo) Messr. Johnson had to pay Proctors Construction Company $2,800.00, an electrical contractor $369.00 and a plumbing contractor $520.00 for a total expenditure over and above the above referenced contract amount of $3,689.00. He testified that no additional work was done to his home. The Respondent testified that he expended $7,458.00 for materials on the Johnson project and was unable to complete it because his mortgage payments were delinquent and he was not receiving any additional monies from Messr. Johnson to fulfill his obligations. He testified that he was unable to work at night and therefore had to seek other employment with another contractor. The above explanation by the Respondent which led to his abandonment of the subject project does not excuse him from his contractual obligations to either fulfill the contract as agreed upon or to seek a renegotiation based on additional costs and/or unexpected circumstances. This was not done nor was any other explanation given as to where the additional monies in excess of $4,000.00 was spent. I therefore conclude that he engaged in a diversion of funds as alleged in the administrative complaint filed by the Petitioner on May 27, 1977. I shall so recommend.
Recommendation Based on the foregoing findings of fact and conclusions of law, I hereby recommend that the Respondent's general contractor's license be suspended for a period of two years. RECOMMENDED this 2nd day of December, 1977, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings 530 Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 C. H. Hoskinson, Chief Investigator Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211 Carroll L. Mozingo 1909 Ed Johnson Drive Jacksonville, Florida 32218 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1095 CARROLL L. MOZINGO dba CARROLL CONSTRUCTION COMPANY, RG 0015876, 1909 Ed Johnson Drive, Jacksonville, Florida 32218, Respondent. /
Findings Of Fact At all times relevant to this proceeding, the Respondent was licensed as a contractor by the Florida Construction Industry Licensing Board. His license for the 1979-1981 license period had not been renewed at the time that the hearing was conducted, and he was therefore delinquent. [This finding is determined from Petitioner's Exhibit 1.] During June, 1977, the Respondent entered Into a contract with Emily D. Wohanka and Ruby Sue Dennard. Ms. Wohanka and Ms. Dennard, who are sisters, agreed to purchase a lot in Satellite Beach, Florida, and the Respondent agreed to construct a single-family dwelling on the lot. The parties agreed to an addendum to the contract during July or August, 1977. The addendum included some specifics with respect to construction and provided: Home will be complete and ready for occupancy within a reasonable period of time--normally three to five months. [This finding is determined from Petitioner's Exhibits 8 and 9, and the testimony of Wohanka and Jordan.) The lot which Ms. Wohanka and Ms. Dennard purchased was not cleared until December, 1977. No progress on construction was made during January or February, 1980. The Respondent obtained a building permit from the City of Satellite Beach, Florida, on February 20, 1978. Construction work commenced in either March or April, 1978. By June, 1978, Ms. Wohanka became concerned that work was commencing too slowly. She told the Respondent that she needed to move in by the end of July. Respondent told her that it was probable that construction would not be completed until mid-August. By September, the project was still not completed. Ms. Wohanka tried to reach Respondent by telephone, but he would not return her calls. She tried to locate him at home, but no one would answer the door. She complained to the building official in the City of Satellite Beach, but the building official had similar problems reaching the Respondent. Ms. Wohanka also complained to N. M. Jordan, the real estate agent who had negotiated the contract. Ms. Jordan was able to locate the Respondent, and the Respondent told Ms. Jordan that he could not complete the project because he was losing money. In late September or early October, Ms. Wohanka and her sister located the Respondent at his home. The Respondent was just walking out of the front door when they arrived. The Respondent told them that he could not discuss the matter, that he had turned it over to Ms. Jordan, and that he was not a part of it anymore. [This finding is determined from Petitioner's Exhibits 2 and 3; and from the testimony of Wobanka, Hijort, and Jordan.] When Ms. Wohanka contacted the Respondent in late September or early October, no work had been done on the project for at least a month, and the house was not completed. Light fixtures, appliances, and air conditioning had not been installed. Cabinets and other fixtures were stored in a bathroom. Inside doors had not been installed. Flooring was not completed. No sidewalks or concrete driveway had been constructed. There had been no landscaping or sodding, and the sprinkler system had not been installed. The plumbing was not operational. Ms. Wohanka contracted with a new builder to complete the project. She was able to move into the residence on December 28, 1978, but work was not finally completed until late January, 1979. Additional expenses beyond those agreed to by the Respondent were incurred by Ms. Wohanka. The Respondent had drawn on a construction loan; but, there is no evidence in the record that the Respondent used these funds for any purposes other than the construction of the dwelling. [This finding is determined from the testimony of Wohanka.] During July, 1977, the Respondent entered into a contract with James and Eleanor A. Lawrence. The Lawrences agreed to purchase a lot in Satellite Beach, Florida, and the Respondent agreed to construct a duplex dwelling on the lot. The Respondent obtained a building permit from the City of Satellite Beach on February 22, 1978. Unknown problems developed, and the project was not being completed. The Satellite Beach building official had difficulty locating the Respondent, but he was ultimately assured by the Respondent that the project would be completed. The Respondent told the realtor who negotiated the contract, Ms. Jordan, that he could not complete the 3 reject because he was losing money. The Lawrences did not testify at the hearing, and specifics regarding their relationship with the Respondent are not known. It is not known whether the Respondent abandoned the project uncompleted without notifying the Lawrences, or whether some agreement was made between them regarding completion of the project. There is no evidenced that the Respondent diverted any funds from the project. [This finding is determined from the testimony of Hjort and Jordan.] No building codes from the City of Satellite Beach were received into evidence. There is no evidence in the record from which it could be concluded that the Respondent violated any provisions of the building codes in either the Wohanka or Lawrence transactions.
Findings Of Fact Respondent Henry Huggins is presently licensed by the Construction Industry Licensing Board as a certified general contractor under license number CO C003466. He first received his license in November of 1972 and has since been continuously licensed. His license was however suspended for a period of one year beginning on May 16, 1980. That suspension was by an Order of the Florida Construction Industry Licensing Board. In October of 1981 Mr. Huggins renewed his license on inactive status but changed it to active status in December 1981. His license continued to be active and he is the qualifying agent for Florida Petroleum Services, Inc., in Winter Park Florida. In the fall of 1980 Mr. Albert Dupre agreed to do some home renovation work for Dr. Charles Gill at Dr. Gill's residence located at 2193 Turkey Run, Winter Park, Florida. Mr. Dupre completed the work and shortly thereafter in the spring of 1981 he and Dr. Gill entered into another oral contract whereby Mr. Dupre would construct an upstairs addition to Dr. Gill's home. The addition included the installation of a bathroom and another bedroom. In exchange for these services Dr. Gill "traded off" dental work for Mr. Dupre's wife and agreed to pay an additional $12,000 or $13,000. At Mr. Dupre's request the construction permit for the upstairs addition was obtained by the Respondent Henry L. Huggins. At all times material Albert Dupre has held no contracting licenses authorizing him to individually perform the work called for by his agreement with Dr. Gill. During the time in question, that is April 1981, Respondent did not himself have an active contractor's license due to his suspension by the Construction Industry Licensing Board. He was authorized by the qualifying agent for Roberts Insurance Contractors to obtain building permits under the qualifying agent's license in order to undertake building projects for Roberts. Roberts Insurance Contractors was not a party to the agreement between Dr. Gill and Mr. Dupre for the up stairs addition to Dr. Gill's home. On April 7, 1981 Respondent obtained building permit number 7487 from the City of Winter Park, Florida, which authorized the construction of a bedroom and bathroom addition on the property of Dr. Charles Gill in Winter Park, Florida. Respondent obtained that permit on behalf of Mr. Dupre because of their friendship and their previous business associations dating back to the mid- 1970's Respondent did not supervise or otherwise participate in the construction of Dr. Gill's addition until the work was complete and Dr. Gill made a complaint to several regulatory bodies about Mr. Dupre's work. This complaint centered around the earlier air conditioning project; but once notified that there were difficulties concerning the project, Respondent, along with Mr. Dupre, completed all unfinished items and corrected all defects. As a result of Respondent's willingness to remedy those defects Dr. Gill has requested that all charges against Mr. Huggins here be dropped.
Recommendation Based on the foregoing Findings of Fact and Conclusions Law, it is RECOMMENDED: That the Construction Industry Licensing Board enter a Final Order suspending the license of Henry L. Huggins as a certified general contractor for a period of two (2) years from the date of the Board's Final Order. DONE and RECOMMENDED this 17th day of February, 1984, in Tallahassee, Florida. MICHAEL PEARCE DODSON Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9673 Filed with the Clerk of the Division of Administrative Hearings this 17th day of February, 1984.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: Respondent James W. Geary presently holds certified general contractor's license number CG C005775. Respondent Geary apparently entered into a contract with Phillip Smith to add a screened porch to the Smith residence. Neither the contract nor the testimony of Mr. Smith were made available to the undersigned Hearing Officer. Respondent had difficulty obtaining a roofer and completion of the project was therefore delayed. During the interim, the interior of the Smith's living room suffered water damage. After receiving a complaint from the Smiths, Mr. Robert Jahn, Chief Building Official for the City of Tamarac, personally inspected the Smith project. He found that the water damage was caused by the uncompleted work of respondent and certain violations of the Southern Florida Building Code. Jahn did not know how long the project had not been worked on, but Smith told him he had tried for about one month to get respondent to return to correct the situation. Respondent testified that when he sent a man to the Smith residence to install the roof columns, Smith chased the man off the job. Upon the delivery of certain supplies for his projects, respondent Geary, d/b/a First Triangle Corporation, wrote two checks in the total amount of $391.41 payable to Rinker Materials. (Exhibit 1) These checks were offered for payment by Rinker, and were returned due to insufficient funds. The former credit manager of Rinker Materials did not know whether anyone from Rinker had contacted respondent about the checks. Respondent testified that no one from Rinker had informed him that the checks were dishonored. However, respondent did receive notice from his bank that the checks had been returned. He was changing banks about the same time and felt that the bank had made mistakes in the past. He felt that the checks were good when issued and he therefore did not put much reliance upon the notices received from the bank. Respondent testified that he is ready, willing and able to honor the checks written to Rinker Materials. Respondent Geary apparently entered into a contract with Richard Decker for the addition of a five by eleven foot bathroom to the Decker's residence. Neither the contract, the plans or specifications nor the testimony of Mr. Decker were offered into evidence at the Hearing. Respondent felt there were no deviations between the finished product and the job specifications, and that, even if there had been, there was no way he could put a five foot vanity into the project without violating the applicable building code. The field investigator for petitioner's District No. 10 found deviations from the plans with regard to the size of the vanity, the bathroom door and the illumination. He found that the Deckers had not indicated their approval of such deviations by placing their initials on the plans or specification. The South Florida Building Code (302.2(b)) provides that when the cost of a job is over $5,000.00, the permit applicant must present plans signed and sealed by a registered architect or engineer. A larger permit fee is also required for jobs costing over $5,000.00. On or about April 9, 1976, respondent Geary applied to the City of Tamarac for two building permits. (Exhibit 2). While blueprints were submitted, no plans signed and sealed by a registered architect Or engineer were submitted. From the square footages contained on the right hand column of the application, Chief Building Official Jahn determined that the value of the two projects were $7,300.00 and $6,620.00. The contract prices for these projects were approximately $8,000.00 and $10,000.00. There was no conclusive testimony as to who supplied the footage information on these applications, It was respondent's opinion that the actual costs of these projects did not exceed $5,000.00. Respondent apparently entered into a contract with Daniel Salzman for some project, and then entered into a second contract for the construction and installation of a fence and a trellis. For this second project, respondent received a deposit of $825.00. The first job was never completed by respondent and respondent never began work on the fence and trellis project. Respondent admitted that some $500.00 was due Mr. Salzman as a refund for the second project. He testified that he instructed Mr. Salzman to have the work on the first project completed by someone else and then to send respondent the bill for the same. Respondent has not heard from Salzman regarding this matter. By letter dated November 20, 1976, Chief Building Official Jahn notified respondent that "No further building permits [would] be issued to First Triangle Builders with you as their qualifier because of numerous complaints and unfinished projects." As indicated in the Introduction, petitioner filed an administrative complaint against respondent seeking to revoke his license for violations of certain ordinances and Florida Statutes S468.112(2). The cause was referred to the Division of Administrative Hearings for the appointment of a Hearing Officer, and the undersigned was designated to conduct the hearing.
Recommendation Based upon the findings of fact and conclusions of law recited above, as well as the seriousness of the offenses of which respondent has been found guilty, It Is recommended that respondent's certified general contractor's license number CG C005775 be revoked. Respectfully submitted and entered this 18th day of July, 1977, in Tallahassee, Florida. DIANE D. TREMOR Hearing Officer Division of Administrative Hearings Room 530 Carlton Building Tallahassee, Florida 32304 (488-9675) Area Code 904 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. James W. Geary 4370 Northwest 32nd Court Lauderdale Lakes, Florida Wallace Norman Construction Industry Licensing Board 305 South Andrews Avenue Ft. Lauderdale, Florida 33301 J. K. Linnan, Executive Director Construction Industry Licensing Board Post Office Box 8621 JacksonvIlle, Florida 32211
Findings Of Fact At all times pertinent to the issues in this hearing, Respondent was a licensed building contractor, whose license is No. CBC014467. His certification as an individual by the Florida Construction Industry Licensing Board was initially dated August 16, 1979. In February, 1981, he requested his second license be registered qualifying Jeff Webb Homes, Inc.; and in September, 1982, the license was changed from Jeff Webb Homes, Inc., to Intervest Construction, Inc. On April 23, 1981, Anna Ray McClellan contracted with Regency Central, Inc., for the construction and purchase of a single family residence located at Lot 5, Devonwood Subdivision, Volusia County, Florida. David L. Martin is president of Regency Central, Inc., and neither he nor Regency Central, Inc., are or have ever been registered or certified by the Florida Construction Industry Licensing Board to engage in the business of contracting in the State of Florida. On June 5, 1981, Respondent applied for a residential construction permit for Lot 5, Devonwood Subdivision, listing Regency Central, Inc., as the owner of the property, and himself, with License No. CBC014467, as the contractor. Actual contracting for the construction at Lot 5, Devonwood Subdivision, was accomplished by Regency Central, Inc. Three separate addenda to the construction/purchase contract calling for modifications to the specifications of construction were signed, not by Respondent, but by David L. Martin for Regency Central, Inc. Major subcontracts on the construction including plumbing, electrical, and heating and air conditioning, were entered into between the subcontractors and Regency Central, Inc., and not Respondent. Subcontractors looked to Regency Central for payment, and not to Respondent. A claim of lien filed on ,September 9, 1981, for central air conditioning and heating work on the property in question reflects the work was done under contract with Regency Central, Inc., David L. Martin, President. During construction of the house, Ms. McClellan visited the construction site several times a week at different hours of the day. She recalls seeing Respondent in the area only twice, the first time being the day the contract for purchase was signed, and the second being the day the slab was poured. Her dealings at the site were with the supervisor, Dan Haley, who indicated to her that he worked for Regency Central, Inc. Respondent was interviewed by Philip T. Hundemann, an investigator for the Florida Department of Professional Regulation, in late March, 1982, at Respondent's home. During the course of the interview, Respondent admitted that he met David L. Martin when Martin rented office space in a building that Respondent had constructed and owned. During the course of conversations, Martin suggested to Respondent that he, Martin, had ninety-nine lots available for building and that if Respondent would pull the construction permit for the Lot 5 project, he would get a contract from Martin to build on the other ninety- nine lots. Respondent admitted that he did not supervise the contract, that he did pull the permit, and that he was in violation of the law and had prostituted his license. His defense was, at that time, that he was hungry to get a big construction contract with Martin. Though after he pulled the permits his agreement was to work on the site for the rate of ten dollars per day with the supervisor, Mr. Haley, he was there only infrequently. Respondent now modifies the admissions made previously to Mr. Hundemann. He now states he was heavily involved with the construction project on a daily basis either in his office or on the construction site, not only as a contractor, but also as sales broker. While he admits what he did was in violation of the law and was foolish, he did not intend to break the law. Respondent's involvement with Ms. McClellan's project was not as contractor as indicated in the permit he pulled. He had very little contact with that project until Martin abandoned the project and left the area.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That Respondent's, Dominic D'Alexander's, license as a certified building contractor be suspended for one year, but that, upon the payment of a $500 administrative fine, the execution of the suspension be deferred for a period of three years, with provision for automatic recission. RECOMMENDED this 21st day of March, 1983, in Tallahassee, Florida. ARNOLD H. POLLOCK, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 21st day of March, 1983. COPIES FURNISHED: Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Dominic D'Alexander Post Office Box 4580 South Daytona, Florida 32021 Mr. James Linnan Executive Director Construction Industry Licensing Board Department of Professional Regulation Post Office Box 2 Jacksonville, Florida 32201 Mr. Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue The issue in this proceeding is whether Willie Daniels violated sections 489.129(1)(d) and (e) F.S., as alleged in the administrative complaint, by willful violation of a local building code and aiding and abetting an unlicensed person to evade any provision of Chapter 489. At the hearing the material facts were uncontroverted.
Findings Of Fact Willie F. Daniels is now, and was at all times relevant, licensed as a roofing contractor by the Florida Construction Industry Licensing Board. He holds license #RC 0027954 and does business as "Daniels Roofing', a sole proprietorship. He has been doing roofing in the Orlando, Florida area since 1954. Willie Daniels first met Thomas Dahlman when Dahlman came to his house trying to sell windows. Dahlman told him that he did all kinds of work, including windows, roofing and painting. Later Dahlman called him and said he had a roofing job that he wanted Daniels to do and that he would take him out to the house. The house belonged to Chris Correa and was located at 4421 Sebastian Way, in Orlando. Dahlman bought the materials for the job and Willie Daniels provided a day and a half labor on the roof. He was paid approximately $600.00 by Dahlman. Chris Correa was initially contacted by an agent for Thomas Dahlman who was trying to sell solar heating devices. When she told him she really needed a new roof, he said his boss could arrange that. Dahlman arranged for her loan to pay for the roof and arranged for the labor to be done by Willie Daniels. Chris Correa paid Thomas Dahlman $3,000 for the roof. About three days after the roof was completed, on February 18, 1986, she signed a contract for the roof work with Dahlman Enterprises, Inc. The contract is signed Thomas Dahlman and by Ms. Correa. Willie Daniels was not a party to the contract. The City of Orlando has adopted the Standard Building Code, including the following provision relating to permit applications: Section 105 - Application for Permit - When Required Any owner, authorized agent, or contractor who desires to construct, enlarge, alter, repair, move, demolish, or change the occupancy of a building or structure, ... or to cause any such work to be done, shall first make application to the Building Official and obtain the required permit therefor. * * * No permit was applied for or obtained for the roofing job on Chris Correa's house. Willie Daniels assumed Thomas Dahlman was a licensed contractor because Dahlman told him he was in the business of doing roofing, painting, installing windows and similar work. He did not ask Dahlman if he was licensed. Dalhman was, in fact, not a licensed contractor.
Findings Of Fact In late 1988, information was received by Department of Professional Regulation (DPR) investigators that a Georgia licensed contractor was building Shoney's restaurants in Florida with a permit pulled in the name of a deceased Florida licensed contractor, Donald Loftin. The contractor, Quality Construction Builders, Inc., owned by Fred Pringle, was not licensed in Florida. Prior to 1986, Pringle had worked for a restaurant management services who had built several Shoney's restaurants in Florida and Georgia. Pringle, in 1980, obtained a power of attorney from Donald Loftin, a licensed Florida contractor, to pull permits under Loftin's license. Loftin died in December 1981, but Pringle renewed Loftin's license once or twice after Loftin's death and pulled construction permits under this license. An extensive investigation was commenced with particular emphasis on construction projects commenced under permits pulled with Loftin's license. Some 25 witnesses were interrogated, including contractors who had pulled permits for Shoney's restaurants on which construction had been stopped, or threatened with stoppage by local officials, because of the initial permit being pulled on Loftin's license. One of these contractors contacted in this investigation was Samuel Whitener who had pulled a permit for a Shoney's restaurant under construction in Ellenton, Florida, on which a stop order had been issued because of the invalid permit. Other contractors who had pulled similar permits for a fee were questioned as were numerous subcontractors, the superintendent for Quality Construction Builders, Inc., and officials of Restaurant Management Services. When the restaurant at Ellenton was approximately 80 percent completed, the local construction authorities stopped work on the project because of the invalid permit which had been pulled using Loftin's license. After the stop order was issued, Restaurant Management Services (RMS), an arm of Shoney's restaurants, entered into a contract with Petitioner herein to complete the project for which Petitioner was paid $4000. When questioned by DPR investigators regarding this function, Petitioner acknowledged that he was paid $4000, that the subcontractors working on the restaurant continued on the job, that these subcontractors were paid by RMS, that he could not hire or fire the subcontractors, and the construction was supervised by Shoney's general contractor, Quality Construction Builders, who had built several other Shoney's restaurants in Florida. Petitioner further told, or led the investigators to conclude, that he had no responsibility for the ongoing construction and that he visited the site once or twice per week; and that the superintendent was primarily in charge of the construction. Other Florida contractors who had also pulled permits for Shoney's restaurants admitted that, although they had pulled the permits, they did not hire, fire, or pay subcontractors and that they performed little, if any, supervision of the construction. Based on this information, the investigator concluded that Petitioner and other contractors were aiding and abetting an unlicensed contractor to do contracting in this State, and submitted this investigative report recommending that Petitioner be charged with violation of Section 489.129(1)(e) and (f), Florida Statutes. The investigative file, which also included a copy of the Construction Management Services contract between Whitener and RMS, was forwarded to the Probable Cause Panel with recommendation that probable cause for a violation of the Construction Industry License Law be found. This contract contains six specific management services which Whitener would supply on the Ellenton project. The contract did not provide that Whitener would obtain the building permit, gave Whitener no control over the financial aspects of the construction, provided for RMS to pay all subcontractors, and did not provide for Whitener to be the qualifying contractor for RMS or Quality Construction. After reviewing the investigation file, including the management services contract, the Probable Cause Panel found probable cause that Whitener violated Section 489.129(1)(e) and (f), Florida Statutes.
Findings Of Fact At all times material to these proceedings, the Respondent, David R. Knight, held a registered general contractor's license numbered RG 007907 issued by the State of Florida, Department of Professional Regulation, Construction Industry Licensing Board initially in July, 1968. Respondent's license is presently in an inactive status for failure to renew but renewal can be accomplished by Respondent paying the required renewal fee only. On May 13, 1983, Respondent contracted with Joseph Cobb to remodel a house in Milton, Florida. The contract price was $23,800.00. The Respondent began the remodeling and when the project was approximately 50 percent completed, left the site. Joseph Cobb, on numerous occasions, offered to work with the Respondent in any way to finish the project, but the Respondent failed to return. Joseph Cobb paid Respondent $19,100.00 from May 14, 1983 through June 23, 1983. In addition, although the contract required Respondent to pay for all supplies and materials, Cobb paid $2,300.98 for supplies and material used in the remodeling. Respondent failed to pay Gary Rich Plumbing for the plumbing work done on the Cobb residence. Joseph Cobb was forced to pay Gary Rich $1,200.00 in order to avoid a lien being filed on his home. Respondent was not licensed to contract in Milton, Santa Rosa County, Florida, when he contracted with Joseph Cobb to perform remodeling. In June, 1982, Respondent contracted with Pearlie Rutledge to remodel a house at 608 North D Street, Pensacola, Florida, Escambia County. The contract price was $17,000.00. The Respondent began the construction without obtaining a building permit which is in violation of Section 106 Standard Building Code as adopted by the City of Pensacola Ordinance 81-83. Respondent deliberately and in a hurry left the site of construction when the building inspector appeared on the job. The Respondent was not licensed in Escambia County or the City of Pensacola to practice contracting. Pearlie Rutledge paid Respondent $5,000.00 which the Respondent failed to return when the remodeling was stopped by Charles Humphreys, Housing Inspector for the City of Pensacola. Pearlie Rutledge obtained a Final Judgement against the Respondent for $4,557.00 which has not been paid by the Respondent. Respondent's "81-82' and "82-83", Okaloosa County Occupational License was issued to David Knight doing business as "Your Way Construction." However, there was no evidence presented at the hearing that Respondent ever contracted in the name of "Your Way Construction." In fact there is evidence that during the year 1983 he contracted with Cobb as David Knight, General Contractor and not as David Knight, General Contractor, d/b/a Your Way Construction. (See Petitioner's Exhibit No. 1.)
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the Board enter a final order Dismissing Counts II, V and VI of the Administrative Complaint filed against the Respondent. It is further RECOMMENDED that the Board enter a final order finding Respondents guilty of the violation charged in Counts I, III and IV of the Administrative Complaint filed against the Respondent and for such violation it is RECOMMENDED that the Board revoke the Respondent's registered general contractor's license numbered RG 0007907, to practice contracting in the State of Florida Respectfully submitted and entered this 9th day of January, 1986, in Tallahassee, Leon County, Florida. WILLIAM R. CAVE Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 9th day of January, 1986. APPENDIX TO RECOMMENDED ORDER IN CASE NO. 84-3836 The following constitutes my specific rulings pursuant to Section 120.59(2), Florida Statutes, on all of the Proposed Findings of Fact submitted by the Petitioner to this case. Rulings on Proposed Findings of Fact Submitted by the Petitioner Adopted in Finding of Fact 1. Exhibit 1). 3. Adopted in Finding of Fact 3. 4. Adopted in Finding of Fact 4. 5. Adopted in Finding of Fact 5. 6. Adopted in Finding of Fact 6. 7. Adopted in Finding of Fact 7. 8. Adopted in Finding of Fact 8. 9. Adopted in Finding of Fact 9. 10. Adopted in Finding of Fact 10. 11. Adopted in Finding of Fact 11. 12. Adopted in Finding of Fact 12. Adopted in Finding of Fact 2 except for contract amount which should have been $23,800. (See Petitioner's Respondent Did Not Submit Any Proposed Findings of Fact COPIES FURNISHED: James Linnan, Executive Director Department of Professional Regulation Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32202 Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee Florida 32301 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Salvatore A. Carpino, General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. David R. Knight 1215 East Hayes Street Pensacola, Florida 32503
The Issue DOAH Case No. 89-3902, the Barona and Carrow Complaints Whether Respondent violated Florida Statutes Section 489.129(1)(d), by willfully or deliberately disregarding and violating the applicable building codes or laws of the state or of any municipalities or counties thereof. Whether Respondent violated Florida Statutes Section 489.129(1)(m), by being guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 90-1900, the Grantz, Victor, Beckett, Maffetonne, and Wolfe Complaints Whether Respondent violated Sections 489.129(1)(m), (j), and 489.105(4), and 489.119, Florida Statutes, by being guilty of gross negligence, incompetence, and/or misconduct. Whether Respondent violated Sections 489.129(1)(h), (m), (j), and 489.119, and 489.105(4), Florida Statutes, by being guilty of financial mismanagement or misconduct. Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilful or deliberate violation or disregard of applicable local building codes and laws. Whether Respondent violated Sections 489.129(1)(m), (j), 489.119, and 489.105(4), Florida Statutes, by failing to properly supervise contracting activities he was responsible for as qualifying agent, which supervisory deficiency also reflected gross negligence, incompetence, or misconduct Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Sections 489.129(1)(m), and (j), Florida Statutes, by giving a guarantee on a job to a consumer and thereafter failing to reasonably honor said guarantee in violation of Florida Statutes. DOAH Case No. 90-1901, the Klokow Complaint Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilfully or deliberately disregarding and violating the applicable building codes or laws of the state or any municipalities or counties thereof. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being guilty of fraud or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 90-1902, the Meister Complaint Whether the Respondent violated Section 489.129(1)(n), Florida Statutes, by failure to obtain a permit. DOAH Case No. 91-7493, the Antonelli Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 91-7951, the Insurance, Palomba, Romanello and Marin Complaints The Insurance Complaint Whether Respondent violated Section 489.129(1)(c), Florida Statutes, by violating Section 455.227(1)(a), Florida Statutes, by making misleading, deceptive, untrue, or fraudulent representations in the practice of his profession. Whether Respondent violated Section 489.129(1)(d), Florida Statutes, by wilfully or deliberately disregarding and violating the applicable building codes or laws of the state or any municipalities or counties thereof. Whether Respondent violated Section 489.129(1)(c), Florida Statutes, by violating Section 455.227(1)(b), Florida Statutes, by intentionally violating a Board rule. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Palomba Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Romanello Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. The Marin Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer. Whether Respondent violated Section 489.129(1)(k), Florida Statutes, by abandoning a construction project in which the contractor is engaged or under contract as a contractor. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by being found guilty of fraud or deceit or of gross negligence, incompetency, or misconduct in the practice of contracting. DOAH Case No. 92-0370, the Pappadoulis Complaint Whether Respondent violated Section 489.129(1)(h), Florida Statutes, by committing financial misconduct. Whether Respondent violated Section 489.129(1)(m), Florida Statutes, by committing gross negligence, incompetence and misconduct in the practice of contracting.
Findings Of Fact Pre-Hearing Admissions 3/ Admissions Applicable to All Cases Respondent is currently licensed as a contractor by the Florida Construction Industry Licensing Board. Respondent's current license number from the Florida Construction Industry Licensing Board is CG C040139. Respondent is licensed by the Florida Construction Industry Licensing Board as a certified general contractor. Respondent holds Florida Certified Roofing License No. CC-042792. Respondent is the qualifying agent for Tropical Home Industries, Inc. As qualifying agent for Tropical Home Industries, Inc., Respondent is responsible for all work performed. DOAH Case No. 89-3902 Respondent was licensed as set forth in items 1, 2, 3 and 4 above at the time of the job alleged in the Administrative Complaint. Exhibit "A", attached to the Request for Admissions 4/ is a true and correct copy of the contract between Sarah S. Carrow and the firm Respondent qualified at the time the contract was executed. As a qualifier for Tropical Home Industries, Inc., Respondent was responsible in his capacity as a certified general and roofing contractor for all work performed by Tropical Home Industries, Inc., pursuant to its contract with Sarah S. Carrow. Pursuant to the contract between Sarah S. Carrow and Tropical Home Industries, Inc., all work under said contract was to be completed in three (3) to six (6) weeks. Respondent, acting through Tropical Home Industries, Inc., failed to complete all work under the contract with Sarah S. Carrow within six (6) weeks after work was commenced. Respondent, acting through Tropical Home Industries, Inc., failed to obtain a final inspection of the work under the contract with Sarah S. Carrow prior to the building permit's expiration date. Broward County, Florida, has adopted the South Florida Building Code as its local ordinance governing residential construction. Respondent's failure to obtain a timely final inspection of the work performed pursuant to the contract between Tropical Home Industries, Inc., and Sarah S. Carrow is a violation of Section 305.2 of the South Florida Building Code. Section 1405.1 of the South Florida Building Code requires installation of either a window or vent fan in each bathroom. Section 3407.9(a) of the South Florida Building Code requires that flashing be installed on plumbing vent pipes which are installed through the roof. Any problems or deficiencies in the work performed by Tropical Home Industries, Inc., pursuant to its contract with Sarah S. Carrow were caused by employees and/or subcontractors of Tropical Home Industries, Inc. DOAH Case Nos. 89-3902, 90-1900, 90-1901, and 90-1902 DOAH Case No. 89-3902 The Baronas' house is located at 1251 Westchester Drive East, West Palm Beach, Florida 33417. Respondent contracted with the Baronas as the qualifying agent of Tropical Home Industries, Inc. The Baronas' house is located within Palm Beach County. Palm Beach County is the appropriate Building Department under which all inspections were to have been performed. DOAH Case No. 90-1901 On or about December 5, 1988, Respondent contracted with Mel Klokow, acting for Linda Klokow ("Klokow"), for the renovation of a screen porch with a roof to her home. Respondent contracted with Klokow as a qualifying agent of Tropical Home Industries, Inc. Permit No. 88-8085 was issued by the local building department. The work at the Klokow residence did not pass final inspection. DOAH Case No. 90-1902 In December of 1987, Respondent contracted to close in a screen porch for Janet Meister ("Meister"). Respondent contracted with Meister as the qualifying agent for Tropical Home Industries, Inc. Respondent failed to obtain a permit for the work performed at the Meister's. Respondent's failure to obtain a permit for the Meister job violated local building codes and Section 489.129(1)(n), Florida Statutes. DOAH Case No. 90-1900 The Grantz home is located at 10878 Granite Street, Boca Raton, Florida. The approximate amount of the contract price with the Grantz was $1,890.00. Respondent contracted for the Grantz job as a qualifying agent of Tropical Home Industries, Inc. Respondent began work at the Grantz residence on or about May 10, 1989. The work at the Grantz residence failed final inspection on July 12, 1989. Respondent wilfully violated applicable local building codes and laws on the Grantz project. Respondent wilfully disregarded local building codes and laws in connection with the Grantz project. Respondent deliberately violated applicable local building codes and laws in connection with the Grantz project. Respondent deliberately disregarded applicable local building codes and laws in connection with the Grantz project. On or about April 12, 1989, and April 17, 1989, Respondent contracted with Stephen Victor ("Victor") to install sliding glass doors at his home. The Victor residence is located at 9768 Majorca Place, Boca Raton, Florida. The contract price with Victor was $3,293.00. Respondent contracted with Victor as a qualifying agent of Tropical Home Industries, Inc. Victor paid a total deposit of $670.00 to Respondent. Respondent never began work at the Victor residence. On or about April 17, 1989, Respondent contracted with Vinton Beckett ("Beckett") to install windows at her home. The Beckett residence is located at 2501 N.W. 41st Avenue, Unit 302, Lauderhill, Florida. The contract price with Beckett was $1,684.00. Respondent contracted with Beckett as a qualifying agent of Tropical Home Industries, Inc. On or about October 29, 1988, Respondent contracted with Thomas and Sherry Maffetonne (the "Maffetonnes") to construct a patio enclosure at their home. The Maffetonne's residence is located at 22980 Old Inlet Bridge Drive, Boca Raton, Florida. The contract price for the work to be performed at the Maffetonnes was $4,350.00. Respondent contracted with the Maffetonnes as a qualifying agent for Tropical Home Industries, Inc. A five-year warranty on materials was given by Respondent for the work to be performed at the Maffetonne's. A one-year warranty on labor was given by Respondent for the work performed at the Maffetonne's. On or about June 6, 1989, Respondent contracted with Mr. and Mrs. Morton Wolfe (the "Wolfes") to install windows at their home. The Wolfe's residence is located at 7267 Huntington Lane, #204, Delray Beach, Florida. Respondent contracted with the Wolfes as the qualifying agent of Tropical Home Industries, Inc. Respondent failed to obtain a timely permit or call for required inspections at the Wolfe residence. DOAH Case No. 91-7951 On June 21, 1990, Tropical's general liability insurance coverage (policy number 891006GL327), produced by Steven Adams and Associates, Inc., (hereinafter "Adams and Associates") and afforded by Guardian P & C Insurance Company, expired. On July 17, 1990, Tropical issued a check to Adams and Associates in the amount of $2,475.00 to obtain general liability and workers' compensation insurance. Upon receipt of the check, Adams and Associates issued a Certificate of Insurance to the Davie (Florida) Building Department indicating that Tropical had general liability (policy number GL 235810) and workers' compensation insurance in force through July 17, 1991. After said Certificate of Insurance was issued, Tropical stopped payment on the check issued to Adams and Associates. Tropical failed to issue an additional check or remit payment of any kind, resulting in both the general liability and workers' compensation insurance being canceled, effective July17, 1990. In September of 1990, a Certificate of Insurance was submitted to the Davie Building Department indicating that Tropical had general liability insurance in effect from September21, 1990, until September 21, 1991. Said certificate had been altered in that the issue, effective, and expiration dates had been updated to reflect that the policy coverage was current and in force. The policy listed on the certificate (number 891006GL327, produced by Adams and Associates with coverage being afforded by Guardian P & C Insurance Company) expired on June21,1990, and was never renewed or kept in force after that date. The Davie Building Department had no other certificates or records indicating that Tropical had insurance coverage. Between July 17, 1990, and April 8, 1991, Tropical obtained five (5) building permits from the Davie Building Department. At no time during the aforementioned period did Tropical have general liability insurance, thereby violating Section 302.1(b) of the South Florida Building Code which requires that building permit applicants be qualified in accordance with PartI of Chapter 489, Florida Statutes. Licensees are required to maintain public liability insurance at all times as provided by rules promulgated pursuant to Part I of Chapter 489, Florida Statutes. Construction Industry Licensing Board records indicate that Tropical has general liability insurance coverage through Equity Insurance (hereinafter "Equity") of Hollywood, Florida. Effective June 8, 1988, Tropical's insurance with Equity was canceled. On February 20, 1991, Tropical entered into an agreement with Michael and Margaret Palomba (hereinafter "Palombas") to perform enclosure and remodeling work at the Palombas' residence located at 130 North East 5th Court, Ft. Lauderdale, Florida 33334. The approximate contract price was $11,978.00. On March 13, 1991, Tropical received a $2,994.50 deposit from the Palombas. On March 25, 1991, Tropical obtained a permit for the project from the Broward County Building Department. Subsequent to receiving the permit, Tropical removed an interior closet from the area that was to be remodeled. Subsequent to receiving the permit, Tropical removed interior plaster from the area that was to be remodeled. Subsequent to receiving the permit, Tropical removed exterior doors from the area that was to be remodeled. Tropical then stopped work stating that rotten wood had been discovered, and requested an additional $2,800.00 to continue with and complete the project. Tropical refused to perform any additional work without the Palombas agreeing to the added cost. Tropical failed to continue with the project pursuant to the original agreement. Tropical refused to continue with the project pursuant to the original agreement. Tropical failed to return any monies to the Palombas. In May 1991, the Palombas hired a second contractor, Dan Sturgeon, to complete the project for $13,830.00. On or about July 11, 1990, Tropical entered into an agreement with Don Romanello (hereinafter "Romanello") to construct a screen room on an existing slab at Romanello's residence located in Boca Raton, Florida. The contract price was $9,500.00. Tropical received $4,800.00 in payments from Romanello, but failed to obtain a permit or perform any work pursuant to the agreement. Tropical has failed to return any portion of Romanello's payments. Tropical refused to communicate with Romanello. Based on the preceding, Tropical committed misconduct in the practice of contracting. On or about June 23, 1990, Tropical entered into an agreement with Marcelina Marin (hereinafter "Marin") to construct a screen room at Marin's residence located in Broward County, Florida, for $4,021.00. Tropical received a $2,000.00 deposit from Marin at the time the agreement was entered into. Tropical failed to perform any work under the terms of the agreement. Tropical has failed to return Marin's deposit. Tropical has refused to return Marin's deposit. Based on the preceding, Tropical committed misconduct in the practice of contracting. DOAH Case No. 91-7493 On July 2, 1988, Respondent contracted with Anthony Antonelli ("Antonelli") to construct an aluminum roof over the patio and gutters of his residence at 9303 Laurel Green Drive, Boynton Beach, Florida. The price of the contract was $2,016.00. Antonelli paid a deposit of $500.00 to Tropical Home Industries. Respondent informed Antonelli that he would not be able to perform the work at the contracted price. Respondent never performed any work at the Antonelli's home. Respondent canceled the contract with Antonelli. Respondent failed to return the deposit paid by Antonelli to Tropical Home Industries. Testimony at Final Hearing Facts Applicable to All Cases Respondent is, and has been at all times hereto, a certified general and roofing contractor in the State of Florida, having been issued license number CG C040139 and CC 2042792. For all contracts and jobs referenced in all of the administrative complaints in these consolidated cases, Respondent acted through the contracting business with which he was associated and for which he was responsible in his capacity as a licensed contractor. DOAH Case No. 89-3902, The Barona and Carrow Complaints Respondent contracted with Rhonda Barona to build an addition to her home at 1251 Westchester Dr. East., West Palm Beach, Florida, for approximately $5,124. The work performed at the Barona residence took an unreasonable amount of time to complete. The permit issued to perform the work at the Barona residence was canceled and Respondent failed to obtain a final inspection. Respondent contracted with Sarah Carrow to build an addition at her home located at 1421 N. 70th Avenue, Hollywood, Florida, for approximately $14,460.60. Respondent allowed the permit to expire and failed to obtain required inspections at the Carrow residence. Respondent failed to fully comply with applicable local codes by failing to install a window or vent fan in the bathroom. DOAH Case No. 90-1900, The Grantz, Victor, Beckett, Maffetonne and Wolfe Complaints On or about March 31, 1989, Respondent contracted with John and Lori Grantz to install windows at 10878 Granite Street, Boca Raton, Florida, for the amount of $1,890.00. Work at the Grantz residence began on or about May 10, 1989. At the time work began, no permit had been obtained. A late permit was obtained on June 15, 1989, in violation of local codes. The work performed by Respondent at the Grantz residence failed final inspection on July 12, 1989, because the structure was not constructed as for the intended use. The windows which were installed were designed as a temporary structure, removable in cases of severe weather and not as a permanent enclosure. On or about April 12, 1989, and April 17, 1989, Respondent contracted with Stephen Victor ("Victor") to install sliding glass doors and windows at 9768 Majorca Place, Boca Raton, Florida, for the total amount of $3,293.00. Victor paid Tropical a total deposit of $670.00, but work never began. On or about April 17, 1989, Respondent contracted with Vinton Beckett ("Beckett") to install windows at 2501 N.W. 41st St., Unit 808, Lauderhill, Florida, in the amount of $1,684. A five-year warranty on materials and a one-year warranty on labor were provided to Beckett by Tropical. Respondent failed to obtain a timely permit or call for required inspections in violation of local law. Respondent failed to correct defects and deficiencies in the work performed at the Beckett residence in a reasonable amount of time. On or about October 29, 1988, Respondent contracted with Thomas and Sharee Maffetonne to construct a patio enclosure at 22980 Old Inlet Bridge Drive, Boca Raton, Florida, for the amount of $4,350.00. A five-year warranty on materials and a one-year warranty on labor were given. Respondent failed to correct defects and deficiencies in the work on the Maffetonne residence in a reasonable amount of time. On or about June 6, 1989, Respondent contracted with Morton Wolfe to install windows at 7267 Huntington Lane, #204, Delray Beach, Florida, for the amount of $1,668.13. Respondent failed to obtain a timely permit or call for required inspections at the Wolfe residence in violation of local codes. DOAH Case No. 90-1901 The Klokow Complaint On or about December 5, 1989, Respondent contracted with Mel Klokow, acting for Linda Klokow, for the construction of a screen porch with a roof to her home at 5292 N.E. 10th Terr., Ft. Lauderdale, Florida, for the sum of $4,473.00. Permit number 88-8085 was issued by the local building department. The work performed at the Klokow residence initially failed to pass the final inspection, and the Respondent failed to return to correct the code violations in a reasonable amount of time. DOAH Case Number 90-1902 The Meister Complaint In December of 1987, Respondent contracted to close in a screen porch for Janet Meister. Respondent failed to obtain a permit for the work performed, which is a violation of local building codes. DOAH Case Number 91-7493 The Antonelli Complaint On July 2, 1988, Respondent contracted with Anthony Antonelli ("Antonelli") to construct an aluminum roof over the patio and gutters at his residence at 9303 Laurel Green Drive, Boynton Beach, Florida. The price of the contract for the work to be performed at the Antonelli residence was $2,016.00. Antonelli remitted a deposit of $500 to the Respondent. Respondent informed Antonelli that he would not be able to perform said job for the contracted price and no work ever began. Respondent canceled the contract with Antonelli and failed to return the deposit to Antonelli. DOAH Case Number 91-7951 The Insurance, Palomba, Romanello and Marin Complaints On June 21, 1990, Tropical's general liability insurance coverage, policy number (891006GL327), produced by Stephen Adams & Associates, Inc., ("Adams & Associates") and afforded by Guardian Property & Casualty Company, expired. On July 17, 1990, Tropical issued a check to Adams & Associates in the amount of $2,475.00 to obtain and/or renew general liability and workers' compensation insurance. Upon receipt of the check, Adams & Associates issued a certificate of insurance to the Davie Building Department in Davie, Florida, indicating that Tropical had general liability (policy number 235810) and workers compensation insurance in force through July 17, 1991. After said certificate of insurance was issued, Tropical stopped payment on the check issued to Adams & Associates. Tropical failed to issue an additional check or remit payment of any kind resulting in the general liability and workers compensation insurance being canceled, effective July 17, 1990. In about September 1990, a certificate of insurance was submitted to the Davie Building Department indicating that Tropical had general liability insurance in effect from September 21, 1990, until September 21, 1991. Said certificate had been altered in that the issue, effective and expiration dates had been updated to reflect that the policy coverage was current and in force. The policy listed on the certificate (number 891006GL327), produced by Adams & Associates and afforded by Guardian Property & Casualty Company, expired on June 21, 1990, and was never renewed or kept in force after that date. The Davie Building Department has no other certificates or records indicating that Tropical has insurance coverage. Between July 17, 1990, and April 8, 1991, Tropical obtained five (5) building permits from the Davie Building Department. At no time during the aforementioned period did Tropical have general liability insurance thereby violating Section 302.1(b) of the South Florida Building Code which requires that building permit applicants be qualified in accordance with Part I of Chapter 489, Florida Statutes. Licensees are required to maintain public liability insurance at all times as provided by rules promulgated pursuant to Part I of Chapter 489, Florida Statutes. Construction Industry Licensing Board ("CILB") records indicate that Tropical has general liability insurance coverage through Equity Insurance Company ("Equity") of Hollywood, Florida. Effective June 8, 1988, Tropical's insurance with Equity was canceled. On February 20, 1991, Tropical entered into an agreement with Michael and Margaret Palomba (the "Palombas") to perform enclosure and remodeling work at the Palomba's residence located at 130 N.E. 5th Ct., Ft. Lauderdale, Florida 33334. The approximate contract price was $11,978.00. On March 13, 1991, Tropical received a $2,994.50 deposit from the Palombas. On March 25, 1991, Tropical obtained a permit for the project from the Broward County Building Department. Subsequent to receiving the permit, Tropical removed an interior closet and exterior doors from the area that was to be remodeled. Tropical then stopped work stating that rotten wood had been discovered, and requested an additional $2,800.00 to continue with and complete the project. Tropical refused to perform any additional work without the Palombas agreeing to the added cost. Tropical failed or refused to continue with the project pursuant to the original agreement and failed to return any monies to the Palombas. In May, 1991, the Palombas hired a second contractor, Dan Sturgeon, to complete the project for $13,000.00. 156. Based on the foregoing, Tropical committed misconduct in the practice of contracting. On or about July 11, 1990, Tropical entered into an agreement with Don and Norma Romanello (the "Romanellos") to construct a screened room on an existing slab at the Romanello's residence located in Boca Raton, Florida. The contract price was $9,500. Tropical received a $4,800.00 payment from the Romanellos but failed to perform any work pursuant to the agreement. Tropical has failed or refused to return any portion of the Romanellos payments and has refused to communicate with the Romanellos. Based on the preceding, Tropical committed misconduct in the practice of contracting. On or about June 23, 1990, Tropical entered into an agreement with Marcelina Marin to construct a screened room at Marin's residence located in Broward County, Florida for $4,021.00 Tropical received a $2,000.00 deposit at the time the agreement was entered into. Tropical failed to perform any work under the terms of the agreement, and has failed or refused to return Marin's deposit. Based on the preceding, Tropical committed misconduct in the practice of contracting. DOAH Case Number 92-0370 The Pappadoulis Complaint On or about February 11, 1990, the Respondent contracted with John Pappadoulis ("Pappadoulis") to remodel a Florida room for the agreed upon amount of $11,448.00 at his residence located at 983 Southwest 31st Street, Fort Lauderdale, Florida. Respondent received a deposit of $648.00, but never obtained a permit nor began work. The Respondent failed or refused to return Pappadoulis' deposit. John Pappadoulis has since passed away. Aggravating and Mitigating Circumstances Monetary Damages Several of the customers in these cases suffered monetary damages. The Baronas had to hire an attorney to deal with the Respondent. The Baronas also incurred additional costs in the work they performed to complete the contract. John and Lori Grantz also suffered monetary damages due to their dealings with the Respondent. The work at the Grantz residence was never completed by the Respondent. The Respondent filed a lien on the Grantz property and also filed a lawsuit to receive the full amount of the contract price. The Grantz had to hire an attorney to obtain legal advice and to defend the lawsuit. The Grantz prevailed in that lawsuit and a judgment was entered requiring the Respondent to refund the $500.00 cash deposit. The Grantz also spent at least $150.00 on attorney fees. The deposit money was never returned and none of their costs were ever reimbursed by the Respondent. Steven Victor also sustained monetary damages in his dealings with the Respondent. Victor paid the Respondent $670.00 as a deposit. No work was ever performed. After requesting the return of his deposit money and failing to receive it, Victor filed a civil action against the Respondent. Judgment was entered in favor of Victor, but the judgment was never paid. The Maffetonnes also sustained monetary damages in their dealings with the Respondent. The Respondent agreed to refund a portion of the contract money to the Maffetonnes due to a problem with the carpet he installed incorrectly, but failed to ever refund any money. The Maffetonnes therefore paid for goods which were defective, and never received a compensatory credit. Klokow also sustained monetary damages in his dealings with the Respondent Because of continuing roof problems, Klokow had to hire an independent roofing expert to inspect the roof and prepare a report. Mr. and Mrs. Palomba also sustained monetary damage due to their dealings with the Respondent. When the Respondent abandoned the Palomba job, the Palombas were forced to hire a second contractor at a higher contract price. The Respondent's actions also caused monetary damages to Antonelli, Pappadoulis, Marin, and Romanello. In each case, the homeowner paid a deposit to the Respondent, and the Respondent failed to ever perform work or return any of the deposit money. The Antonellis paid $500.00, Pappadoulis paid $648.00, Marin paid $2,000.00, and Romanello paid $4,800.00. Actual Job-Site Violations of Building Codes or Conditions Exhibiting Gross Negligence, Incompetence, or Misconduct by the Licensee Several of the jobs involved in these cases had actual job site violations of building codes or conditions which exhibited gross negligence, incompetence, or misconduct by the Respondent which had not been resolved as of the date of the formal hearing. At the Barona residence, the framing inspection failed twice before finally being passed a third time; the lath inspection failed three times before finally passing on the fourth time; and the final inspection failed and was never satisfactorily completed by the Respondent. At the Carrow residence, the Respondent failed to install a window or vent fan in the bathroom of the room addition which he installed. In addition to the building code violation, the work performed was incompetent as the structure installed leaked for many months. Further, the original permit expired prior to a final inspection ever being obtained. At the Grantz residence, the Respondent exhibited incompetence and misconduct by installing windows that he knew or should have known were unsuitable for the purposes specified by the customer. Severity of the Offense The large number of violations established in these cases indicates that the Respondent is a serious threat to the public. These violations establish that the Respondent had a pattern of failing to conduct any meaningful supervision of work in progress. And perhaps most serious of all is his frequent act of soliciting deposits for projects he apparently had no intention of even beginning, much less finishing. This latter practice borders on constituting some form of larceny. Danger to the Public The Respondent is a danger to the public in two ways. First, he is a financial threat to the public, most significantly by his practice of taking deposits for jobs he apparently did not intend to perform. Second, he is a threat to public safety, because the work he performs is often done in a haphazard, careless manner. The Number of Repetitions of Offenses As is obvious from the findings of fact and conclusions of law in this Recommended Order, the Respondent is guilty of numerous repeated offenses which occurred over a period of approximately three years. The Respondent's numerous offenses are indicative of an attitude of contempt or disregard for the requirements of the applicable rules and statutes. Number of Complaints Against Respondent The charges in these cases are based on fifteen separate customer complaints to the Department of Professional Regulation regarding the Respondent. Further, the Palm Beach County Construction Industry Licensing Board received four complaints from homeowners regarding the Respondent 5/ and the Broward County Consumer Affairs Department received twenty-nine complaints regarding the Respondent. 6/ Such a large number of complaints indicates that the Respondent's shortcomings were not isolated events, but represent a recurring problem. The Length of Time the Licensee Has Practiced The Respondent was first licensed as a state general contractor in 1987. He obtained his roofing contractor license shortly thereafter. The Respondent's licenses were placed under emergency suspension in August of 1991. Damage to the Customers The damages, monetary and otherwise, suffered by the Respondent's customers has already been addressed. In addition, all of the Respondent's customers mentioned in the findings of fact suffered a great deal of aggravation, stress, and frustration in dealing with the Respondent. Penalty and Deterrent Effect In these cases, the proof submitted demonstrates that no penalties short of revocation of the Respondent's licenses and imposition of the maximum amount of fines will act as a deterrent to the Respondent and others and as appropriate punishment for the many violations established by the record in these cases. Efforts at Rehabilitation There is no persuasive evidence in the record of these cases that the Respondent has become, or is likely to become, rehabilitated. To the contrary, the greater weight of the evidence is to the effect that the Respondent is unwilling or unable to conform his conduct to the requirements of the statutes and rules governing the practice of contracting.
Recommendation Based upon the foregoing findings of fact and conclusions of law, IT IS RECOMMENDED: That the Respondent be found guilty of all of the violations charged in each Administrative Complaint and Amended Administrative Complaint as noted in the conclusions of law, and that the Respondent be disciplined as follows: The Respondent be required to pay an administrative fine in the amount of $5,000.00 for each of the twenty-nine counts of violations charged and proved, for a grand total of $145,000.00 in administrative fines; The Respondent's license numbers CG C040139 and CC C042792 be revoked; and The Respondent be required to pay restitution to the following Complainants in the following amounts: Steven Victor - $670.00; John Grantz - $650.00; Don Romanello - $4,800.00; Marcelina Marin - $2,000.00; Anthony Antonelli - $500.00; John Pappadoulis' next of kin - $648.00. All restitution shall earn 12% interest per annum from the date the Complainants paid their deposit to Respondent. DONE AND ENTERED at Tallahassee, Leon County, Florida, this 21st day of October, 1992. MICHAEL M. PARRISH, Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 904/488-9675 Filed with the Clerk of the Division of Administrative Hearings this 21st day of October, 1992.
