The Issue Whether a consumptive use permit for the quantities of water as applied for should be granted.
Findings Of Fact Application No. 7500112 requested water from three (3) wells for the purpose of industrial use. This application is for a new use. The center of withdrawals will be located at Latitude 27 degrees 38' 58" North, Longitude 81 degrees 48' 21" West, in Hardee County, Florida. The application is for the use of not more than 470 million gallons of water per year and not more than 2,592,000 gallons of water during any single day to be withdrawn from the Florida Aquifer. Application received as Exhibit 1. Notice was published in a newspaper of general circulation, to-wit: The Herald Advocate, published weekly in Wauchula, Florida, on August 7 and 14, 1975, pursuant to Section 373.146, Florida Statutes. Notices of said public hearing were duly sent by certified mail as required by law. The affidavit of publication was received without objection and entered into evidence as Exhibit 2. Letters of objection were received from the following: Mr. Joseph F. Smith, Route 1, Box 238, Wauchula, Florida 33273. Mr. Smith states that in his opinion such withdrawal of water will severely damage his property. He is developing a mobile home park on eight (8) acres and is fearful that the amount of water requested in this application will diminish his supply of water for his project. A letter from Mr. and Mrs. A. H. Van Dyck, written on August 16, 1975, Route 2, Box 657, Wauchula, Florida 33873. They are fearful that the large amount of water American Orange Corporation proposes to pump each day will affect their shallow well which provides water for their home. They would like to see some type of agreement whereby American Orange Corporation would be willing to pay for replacement of the well if the corporation should cause their well to go dry. Mr. Stanley H. Beck, Counselor at Law, wrote a letter in behalf of his client, Harold Beck, requesting information as to the applicable statutes and regulations which affect the matter of the consumptive use permit. A telegram was sent by Harold Beck of Suite 1021, Rivergate Plaza, Miami 33131, stating that he objected to the application of American Orange Corporation's withdrawal of water or the reason that it would reduce the property value. The witness for the permittee is Barbara Boatwright, hydrologist, who was duly sworn and agreement was reached on each point enumerated as required by Rule 16J-2.11, Rules of the Southwest Florida Water Management District and Chapter 373, Florida Statutes. The staff hydrologist recommended that the permit be granted with two (2) conditions. One was that each of the wells be metered and two, that the District receive monthly reports from each meter. The applicant has consented.
Findings Of Fact Petitioner, Department of Health and Rehabilitative Services, is the state agency charged with regulating waste water treatment facilities and any sanitary nuisance which may emanate as a result of such operations pursuant to Chapters 381 and 386, Florida Statutes. Respondent, Larry G. Delucenay d/b/a Madhatter Utilities, Inc., owns and operates the Foxwood Waste Water Treatment Plant which is permitted and certified by the Department of Environmental Regulation. Respondent, in operating the Foxwood system, discharges its treated effluent water by means of two percolation ponds and a drip field located adjacent to the Cypress Cove Subdivision in Pasco County, Florida. Respondent owns and controls percolation ponds which are located adjacent to the Cypress Cove Subdivision and pumps human waste from a sewage treatment plant to percolation ponds in the Cypress Cove Subdivision. Respondent's percolation ponds are located approximately 50 ft. west of several residences and the ponds are accessible to the public. The ponds are elevated from 3 ft. to 5 ft. above the adjacent residential lots in the subdivision. However, there is a sand berm approximately 8 ft. high with a 12 yd. base which serves as a barrier between the percolation ponds and the Cypress Cove residences. On August 5, 1991, environmental health specialist Burke observed liquid flowing through the sand berm. He also observed erosion patterns in the sand on the berm which indicated liquid was flowing through it. Mr. Burke, while in the company of two other employees of Petitioner, observed liquid flowing from the percolation ponds onto Lake Floyd Drive to the south of the ponds. An improperly designed nearby lake exacerbated the flooding into Lake Floyd Drive. Respondent's waste water treatment system is designed according to the manufacturer's specifications. Pasco County allowed a number of developments to be built in the area without an adequate drainage system which adversely impacts Respondent's system to the point whereby untreated drainage outfall is draining into the southeast areas in Cypress Cove. Specifically, Respondent's pond #4 is designed to handle a water level up to 67.33 ft. During the investigation of the case, the water level in that pond was approximately 3 1/2 ft. higher than the designed capacity and was therefore causing overflow into the southeast areas of the development. (Respondent's Exhibits A, B and C.) Noteworthy also was the fact that a developer failed to complete a connection which has impacted Respondent's percolation pond and has forced the water to rise approximately 9 ft. higher than the designed capacity which has resulted in an overflow approximately 3 ft. to 4 ft. into the neighboring subdivision. As a result of the overflow, waste water spills over the percolation ponds and prevents the water from draining through the berms as designed. Petitioner's consulting engineer, Robert William Griffiths, credibly testified that a number of agencies having oversight responsibility such as Pasco County, the Southwest Florida Water Management District and the Department of Environmental Regulation, mandated that the drainage system be completed prior to the entire build-up of Cypress Cove. Despite the mandate, the drainage system was not completed and the County allowed the development to continue. Respondent is properly treating and chlorinating sewage in its plant which complies with Petitioner's requirements for the treatment of sewage in systems designed such as Respondent's. Respondent properly treats sewage flowing through its ponds and its berms are properly maintained. As early as October 1989, Respondent consulted and retained an engineer, Gerald E. Towson, who was commissioned to investigate the specifics of designing a waste water treatment plant based on concerns raised by the Department of Environmental Regulation (DER). As a result of that charge, Towson investigated the area and observed flooding and the stormwater runoff in the Cypress Cove neighborhood and attempted to find a solution to alleviate the problem. Consultant Towson also investigated Respondent's treatment plant to determine if the system was functioning as designed. Based on his observation and inspection of the treatment facility, the facility was operating as it was designed and properly filters and treats the effluent. However, based on Respondent's inability to control the stormwater runoff in the neighborhood created by the excess buildup, Towson concluded that there was no workable solution to the problem. As a result of Towson's inability to find a workable solution to handle the concerns raised by DER, Respondent suggested that Towson locate another wastewater treatment site which he found in a surrounding area. Respondent negotiated a lease arrangement with the landowner and initiated the permit process with DER. After the completion of numerous documents and engineering studies required by the Department of Environmental Regulation, Respondent was able to get the leased site permitted by DER as a slow drip irrigation system during March 1991. However, while construction of the system was scheduled to start during March 1991, as a result of vigorous protests from area neighbors, construction was delayed. Respondent thereafter investigated several sites but was unable to fine a suitable area near Cypress Cove. Towson completed a lengthy and cumbersome process in getting Respondent's construction application processed by DER. Initially the application was filed and following a DER review, a Notice of Intent to Issue was given. Hillsborough County thereafter reviewed the project and following their review, Hillsborough County issued its Notice of Intent to Grant and public notice was given. Based on Respondent's inability to comply with the neighbor's concerns regarding setback problems, DER withdrew its permit during May of 1991. Thereafter, Petitioner became involved in connecting with the Pasco County Public System. That connection was ultimately made and the County gave its approval following a delay based on a review occasioned by an employee who had been on vacation. Upon getting the approval, Petitioner ordered the equipment from a supplier which included installation of a magnetic meter and the necessary hookups into the Pasco County System. A "phased in" connection has been completed and the stormwater runoff problem has been abated. When the problems raised by DER and ultimately Petitioner was first brought to Respondent's attention, Pasco County did not have the capacity to handle the hookups required by Respondent's system. Respondent, has been involved in the installation of waste water treatment plants since 1967. Respondent is qualified as a Class "A" Licensee Waste Water Operator. He has been accepted as an expert in numerous administrative hearings. Respondent purchased the Foxwood System during 1982. Respondent utilized a 13 acre tract near Lake Floyd Drive. The system was licensed and designed with a flow capacity of 300,000 plus gallons per day. During the time when the Administrative Complaint was issued, the flow capacity was 220,000 gallons per day. The storm water system which was to have been completed by developers in the area was not connected to the public system and the County granted numerous other permits to daycare centers and several parking lots were constructed for other newly constructed commercial buildings in the area. As a result of the excess runoff created by the development in the area, Respondent's system was impacted and the water level was raised in the percolation ponds to the point whereby an overflow resulted. Petitioner adduced no evidence which showed that any physical or emotional harm resulted from the runoff. At all times while the concerns were being raised by Petitioner and other oversite agencies, the effluents in Respondent's systems were properly treated. Respondent vigorously attempted to abate the runoff created by the excess buildup in the area despite the fact that the problem was raised by Pasco County and over which Respondent had no control. Throughout the process of attempting to find alternate solutions and ultimately getting permitting approval to start construction of an alternative waste water treatment system, Respondent operated in good faith. When no alternate site became available, Respondent initially made application to connect with Pasco County System and that connection has now been made.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that: Petitioner enter a Final Order dismissing the Administrative Complaint herein in its entirety. DONE and ENTERED this 29 day of April, 1992, in Tallahassee, Leon County, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904)488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29 day of April, 1992. COPIES FURNISHED: THOMAS W CAUFMAN ESQ HRS DISTRICT V LEGAL OFFICE 11351 ULMERTON RD - STE 407 LARGO FL 34648 RANDALL C GRANTHAM ESQ COTTERILL GONZALEZ & GRANTHAM 1519 N MABRY - STE 100 LUTZ FL 33549 RICHARD S POWER AGENCY CLERK DEPT OF HEALTH AND REHABILITATIVE SERVICES 1323 WINEWOOD BLVD TALLAHASSEE FL 32399 0700 JOHN SLYE ESQ/GENERAL COUNSEL DEPT OF HEALTH AND REHABILITATIVE SERVICES 1323 WINEWOOD BLVD TALLAHASSEE FL 32399 0700
Findings Of Fact The City has brought this action pursuant to Section 120.56, Florida Statutes, challenging Rules 17-50.015(2)(f) and 17-50.016(2)(f), Florida Administrative Code. Section 120.56(1), Florida Statutes, authorizes any person substantially affected by a rule to seek an administrative determination of the invalidity of the rule on the ground that the rule is an invalid exercise of delegated legislative authority. The Department has stipulated to the City's standing to maintain this action. 4. Rules 17-50.015(2)(f) and 17-50.016(2)(f) were adopted by the Department pursuant to Sections 403.061, 403.101, 403.1823, 403.1832, 403.1838 and 403.804, Florida Statutes. No disputed issues of material fact exist between the parties.
Findings Of Fact Respondent owns and operates a waste water treatment facility at Polynesian Village Mobile Home Park, owns the land at this village, leases these lots to mobile home owners, and provides them with waste water treatment. He was last issued an operating permit on January 18, 1983, by Petitioner. Respondent posted an Operational Bond (Exhibit 2) in the amount of $7,500 with Northwestern National Insurance Company as surety to faithfully operate the treatment facility and comply with all Rules and Regulations of the Petitioner. Englewood Water District, petitioner, was established by special act of the Florida Legislature in Chapter 59-931, Florida Statutes, and is given authority in Section 4 thereof to regulate use of sewers, fix rates, enjoin or otherwise prevent violations of the act or any regulation adopted by Petitioner pursuant to the act, and to promulgate regulations to carry out the provisions of the act. Pursuant to this authority, Petitioner promulgated Waste Water Treatment Facilities Design, Construction and Operation Regulations dated June 19, 1980, and revised April 28, 1983. During an inspection of Respondent's waste water treatment facility on October 17, 1983, leaching was observed at both the north and south drain fields with effluent from the system rising to the surface. Samples of this effluent when tested showed a fecal coliform count of 2800/100 ml. The basic level of disinfectant shall result in not more than 200 fecal coliform values per 100 ml of effluent sample (Rule 17-6.060(1)(b)3a, F.A.C.). Following this test, Notice of Violation (Exhibit 4) was served on Respondent. No action was taken by Respondent to correct this condition and on January 6, 1984, a Citation (Exhibit 5) was issued to Respondent scheduling a hearing for January 26, 1984. Following the issuance of that Citation frequent inspections of the facility were conducted by employees of Respondent to ascertain if steps were being taken by Respondent to correct the deficiencies. Additionally, inspections were made by inspectors from Sarasota County Pollution Control. Inspections were conducted January 9, 16, 17, 18, 20, 23, and 31; February 1, 8, 13, 14, 16, 21, 24, 25, 26, 27, 28, and 29; and March 2, 5, 8, and 9, 1984. These inspections revealed what appears to be a "blow-out" in the south drain field where effluent bubbles to the surface and flows onto the adjacent streets and propert (Exhibits 9 and 11). Effluent tested from this source had fecal coliform counts as high as 9440/100 ml. During one of these inspections effluent from the treatment plant was being discharged directly onto the road to a drainage ditch adjacent to the plant (Exhibit 8). The coliform count of a sample taken from this ditch was 13500/100 ml. Respondent was issued a second Citation on March 2, 1984, and this hearing was held on the violations alleged in that Citation, to wit: creating a public nuisance and leaching from drain field. Respondent contends that he is dealing with the Sarasota County Engineer to correct the problems and, after failing in his attempt to get the county to provide drainage from his property, he is now in the process of installing drain pipes. Respondent contends that the natural drainage of surface waters from his land to adjacent land was stopped by development on the adjacent land and the heavy rains this winter has saturated his land and inhibited percolation in the drain fields. Accordingly, the effluent from his plant could not be absorbed by the drain field. Respondent also contends that the drain field worked fine for several years before the drainage problem arose and believes it will again work well when the drainage situation is corrected.
Findings Of Fact Upon consideration of the oral and documentary evidence adduced at the hearing, the following relevant facts are found: Several years prior to1978, petitioner General Development Corporation (GDC) applied to the DER for a dredge and fill permit to remove a plug of land between the Ocean Breeze Waterway and the North Fork of the St. Lucie River. During the course of negotiations for this permit, it was discovered that the North Port St. Lucie Sewage Treatment Plant, owned and operated by General Development Utilities, Inc., a wholly-owned subsidiary of the petitioner, was operating without a permit from the DER and discharging effluent into a ditch which flowed into the Ocean Breeze Waterway. In March of 1978, a temporary operating permit was issued for the sewage treatment plant. In July of 1978, petitioner received from the DER Permit No. 253.123- 1031 to dredge an area approximately 800 feet in length, 90 feet in width and 6 feet in depth in order to connect the Ocean Breeze/Sagamore Waterways to the dead end oxbow of the North Fork of the St. Lucie River. The permit application was given special consideration pursuant to Rule 17-4.28(7), Florida Administrative Code. The purpose for obtaining the permit was to create direct navigable access to the North Fork of the St. Lucie River from thee Ocean Breeze Waterway. The Ocean Breeze Waterway was and is currently connected to the North Fork of the St. Lucie River by a narrow, shallow, meandering creek and lake system. However, there is not a large enough opening to allow the type of navigable access desired by the petitioner for the benefit of 118 lots plotted along the Ocean Breeze and Sagamore Waterways. Among the seven particular or special conditions attached to the dredge and fill permit issued to petitioner was that the earthen plug not be removed until such time as a permanent operational permit was issued for the sewage treatment plant owned and operated by General Development Utilities, Inc. More specifically, petitioner agreed to the following special conditions to the issuance of the dredge and fill permit: "(7) The applicant is aware that the GDC Utilities' sewage plant is providing an unknown quantity of discharge into Ocean Breeze Waterway and that this discharge may be a source of pollution to the receiving body of water unless affirmative steps are taken by the Utilities. The sewage treatment plant is currently operating under a Temporary Operating Permit (TP56-4601). In no case shall the plug at Cove Waterway be removed before an Operation Permit for the STP has been issued by the Department of Environmental Regulation." At time of issuance of the dredge and fill permit, DER personnel considered the quoted special condition number 7 to an integral part of the permit in terms of water quality assurances. General Development Utilities, Inc. has not been able to obtain a permanent operational permit from the DER for its sewage treatment plant which discharges into a ditch that flows into the Ocean Breeze Waterway. Therefore, particular condition number 7 has not been satisfied and petitioner has been unable to proceed with the dredging or removing of the plug under the permit. As a result of the delays in removal of the plug, petitioner has had to repurchase some 41 of the 118 plotted lots. The sewage treatment plant was and is still operating under a temporary permit. General Development Utilities, Inc. has requested a permanent operational permit for the sewage treatment plant and DER has issued a letter of intent to deny such a permit. As a result, General Development Utilities has petitioned DER for site specific alternative criteria pursuant to Rule 17-3.031, Florida Administrative Code. This matter is the subject of a separate proceeding currently being held in abeyance pending a determination of alternative criteria. General Development Utilities, Inc. v. Department of Environmental Regulation, DOAH Case No. 81-177. In September of 1980, petitioner sent a letter to DER requesting that special condition number seven be removed from its dredge and fill Permit No. 253.123-1031. It was intended that this request be considered as a minor modification to the dredge and fill permit. In response, DER's Chief of the Bureau of Permitting, Suzanne P. Walker, informed petitioner by letter dated October 15, 1980, that it was the staff's initial reaction, after a review of the original dredge and fill permit file, that the requirement that the sewage treatment plant obtain a permanent operational permit prior to dredging remain as a condition of the dredge and fill permit. Petitioner was informed that if it wished to pursue the matter further, the project must be reevaluated as a major modification to the dredge and fill permit. A major modification to a permit requires a new permit application and fee and is treated and processed as an initial application for a permit, with the applicant being required to provide reasonable assurances that the water quality standards will not be violated. Upon request for a minor modification, DER simply reviews the file and determines whether the request is obviously environmentally insignificant. After receipt of the letter from Mrs. Walker, petitioner supplied DER with additional water quality data. Based upon this additional data, discussions with DER staff who had been involved with the initial dredge and fill permit and the sewage treatment plant permit, and two days of sampling data collected by DER, DER determined that particular condition number seven was an integral part of the affirmative reasonable water quality assurance provided and should remain a condition of the permit. This determination was communicated to petitioner by letter dated January 7, 1981. The sewage treatment plant discharges treated effluent into a drainage ditch known as C-108. Effluent from the plant first goes into holding or retention ponds. Under its current flow, it takes about forty days for the effluent to be discharged from the plant to C-108 and the Ocean Breeze Waterway. C-108 flows into the Ocean Breeze Waterway, an artificial waterway which is presently connected to the North Fork of the St. Lucie River by a narrow, shallow meandering creek and lake system. The sewage treatment plant currently operates at 300,000 gallons per day but has an authorized capacity to operate at two million gallons per day. It currently contributes approximately two percent of the total daily flow to C-108. The Ocean Breeze Waterway and C-108, independent of the sewage treatment plant, drain approximately 4,000 square acres and produce about 35 percent of the water that will flow into the North Fork. The North Fork is tidal, with four one foot tides per day. The tidal action comprises almost 63 percent of the moving water. At a two million gallons per day discharge, the wastewater plant would be contributing about 12 percent of the water that would be going into the North Fork from the Ocean Breeze Waterway system. In comparison with two adjacent drainage systems, the Ocean Breeze system contributes only about three percent of the fresh water which flows into the North Fork. The dissolved oxygen levels of C-108 are chacteristically below the state standard of five milligrams per liter, primarily due to the seepage of ground water into the canal. Due to man-made alterations and to natural phenomena, the North Fork's dissolved oxygen levels also characteristically fall below state standards. The dissolved oxygen level of the Ocean Breeze Waterway is characteristically above state standards. Higher levels of dissolved oxygen coming from the sewage treatment plant improves the dissolved oxygen levels of the existing system. High levels of nitrogen, phosphate and chlorophyll have been found near the point of discharge. The quality of water in the North Fork is better than in the Ocean Breeze Waterway. It was the opinion of petitioner's experts that no change in dissolved oxygen levels would occur in the Ocean Breeze Waterway or the North Fork if the plug of land between these water bodies were removed. Petitioner's witnesses also opined that the Ocean Breeze/C-108 system was not a source of nutrient enrichment to the North Fork, and that the present creek system provided no water quality benefits in the form of nutrient uptake for the North Fork. It was estimated that, if the plug of land were removed pursuant to the permit, a pollutant placed at the upper end of the Ocean Breeze Waterway would be diluted by 98 percent in 26 hours in lieu of the present 39 hours due to increased flushing. These opinions were based upon analyses by petitioner's witnesses of various samplings and data regarding dissolved oxygen, nutrients and phytoplankton. The respondent's witnesses felt that the poor water quality in the Ocean Breeze Waterway was attributable in large part to the sewage treatment plant discharge and, if the plug of land were removed, the water quality problems would be moved to the North Fork and the St. Lucie River. It was felt that the present creek and lake system -- the narrow circuitous connection presently existing between the canal and the river -- reduces the nutrients which otherwise would flow into the river. These conclusions were based upon DER's own survey, a review of the dredge and fill permit file and a review of the additional data supplied by the petitioner General Development Corporation. No data regarding the water quality of the effluent from the sewage treatment plant was submitted by the petitioner at the time of DER's review of the original application for the dredge and fill permit.
Recommendation Based upon the findings of fact and conclusions of law recited herein, it is RECOMMENDED that the request of General Development Corporation to modify Permit Number 253.123-1031 by removing particular condition number seven be DENIED. Respectfully submitted and entered this 14th day of October, 1981, in Tallahassee, Florida. DIANE D. TREMOR, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 14th day of October, 1981. COPIES FURNISHED: Valerie Fravel Corporate Counsel General Development Corp. 1111 South Bayshore Drive Miami Florida 33131 Alfred J. Malefatto Assistant General Counsel Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32301 Honorable Victoria Tschinkel Secretary, Department of Environmental Regulation 2600 Blair Stone Road Tallahassee, Florida 32301
