Findings Of Fact Petitioner is the Department of Professional Regulation. Respondent is James J. Hastings, the holder, at all times pertinent to these proceedings, of general contractor license number CG C009847. He is also the qualifying agent for Hastings Construction Co., Inc. James and Susan Cesiro, owners of a residence in Palm Bay, Florida, entered into a contract on June 13, 1985, with Mike Boyer, proprietor of a business known as American Fiberglass Pools, to furnish and install a swimming pool. The total contract price was $8500. The owners gave Boyer a $1,500 check at the time the contract was executed. On July 9, 1985, Boyer's employee obtained a second check from the owners for an additional $1,500 allegedly to complete the $3,000 required down payment. Unfortunately, the employee persuaded the owners to make this check payable to the employee personally. The employee subsequently disappeared after cashing the check. This complication resulted in some delay in the initiation of construction activities. On August 12, 1985, the owners were informed by Boyer that a contractor had been retained to install the fiberglass pool. On August 28, 1985, Respondent obtained a building permit from the City of Palm Bay authorizing the pool construction. The permit identified Respondent's company, Hastings Construction Co., Inc., as the contractor. The owners issued a check in the amount of $2,500 on September 6, 1985. Delivery of the check was made to Boyer, but was made payable to Respondent. In view of their past experience with furnishing a check payable to a party other than Boyer or his company, the owners obtained a receipt for the check from Boyer. The owners gave another check in the amount of $500 to Boyer on September 9, 1985. This check was also made payable to Respondent. Again, a receipt was obtained from Boyer by the owners. On September 23, 1985, Respondent personally received another check from the owners in the amount of $2,500. In September, 1985, after receipt of funds from the owners, Respondent and Boyer proceeded with the pool installation. While Boyer was present at the site more than Respondent, the Respondent was present every day at periodic intervals. The owners had the impression that Respondent was new at the installation of this type of pool. Boyer seemed to be more in charge of the construction and Respondent appeared to defer to him on questions asked by the owners during the installation process. This impression was confirmed at hearing by Respondent's admission that this was his first experience with this kind of pool. He had never "lifted pools over houses" and viewed the entire job as a "learning experience." Because of the tutorial nature of the situation, Respondent said he didn't enter into a formal contract with the owners. In May 1986, cracks appeared in the bottom of a portion of the pool. Respondent took the position that the pool should be repaired by Boyer under terms of the owners agreement with that individual. Respondent never prepared or accepted an assignment of the contract made by Boyer with the owners. Respondent is not an officer or employee of Boyer's business. Respondent is not a qualifying agent for Boyer or American Fiberglass Pools and those names do not appear on his license. The owners were never apprised that Respondent was "their" contractor. Respondent's testimony that a letter was sent from him to the owners on August 30, 1985, informing them of this fact is not credited in view of the Respondent's candor and demeanor while testifying on this point, the fact that he had obtained the building permit on August 28, 1985, and the owners denial that such letter was ever received. Respondent's credibility on this point was further undermined at one point in the hearing when he stated he was given this job by Boyer. Mike Boyer is not, and has never been, licensed by the Florida Construction Industry Licensing Board in accordance with Chapter 489, Florida Statutes. Respondent was aware that Boyer was not a licensed contractor. Respondent was previously disciplined by the Florida Construction Industry Licensing Board in Petitioner's case numbers 430077 and 50057, on or about October 29, 1984 and February 4, 1985, respectively. Discipline in the form of a $250 fine was imposed in the former case for Respondent's failure to qualify a company through which he was doing business and for deceptive representations in the practice of contracting. The latter disciplinary action resulted in the imposition of a $250 fine upon Respondent or suspension of his license for 60 days due to aiding and abetting an unlicensed individual and failing to qualify a business with the Board.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that a final order be entered suspending Respondent's licensure to practice contracting for one year and assessing an administrative fine in the amount of $2000. DONE AND RECOMMENDED this 18th day of March, 1988, in Tallahassee, Leon County, Florida. DON W. DAVIS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 18th day of March, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-5328 The following constitutes my specific rulings on findings of fact submitted by the Petitioner. Included in finding number 2. Included in findings numbered 3 and 15. The last sentence is rejected as noncorroborative hearsay. Included in part in finding number 4. Included in part in finding number 5. Included in finding number 6. Included in findings numbered 7, 8, and 9. Included in finding number 10. Included in finding number 12. Included in finding number 13. Included in finding number 16. The Respondent submitted a document entitled Proposed Findings of Fact. The document consists of five unnumbered paragraphs in the nature of a closing argument as opposed to proposed findings of specific facts. This document of the Respondent has been reviewed by the Hearing Officer and numbers 1-5 applied to the paragraphs therein. Rulings on those paragraphs are as follows: Rejected as unnecessary. Rejected as unnecessary with the exception of the proffered August 30, 1985 letter. In this regard see finding number 14. Rejected as not supported by the evidence. Rejected as a conclusion of law not supported by the evidence. Rejected as unnecessary. COPIES FURNISHED: David L. Swanson, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Mr. James J. Hastings 836 19th Place Vero Beach, Florida 32962 William O'Neil Department of Professional Regulation General Counsel 130 North Monroe Street Tallahassee, Florida 32399-0750 Fred Seeley, Executive Director Construction Industry Licensing Post Office Box 2 Jacksonville, Florida 32201
The Issue Whether Respondent's license as a registered pool contractor should be suspended or revoked or the licensee otherwise disciplined, for alleged violations of Chapter 489, Florida Statutes, as set forth in the Amended Administrative Complaint. This proceeding arises out of Respondent's alleged failure to remedy defects in a swimming pool that she built in 1981 which resulted in disciplinary action by the Leon County Contractor's Licensing and Examination Board; for failing to remedy defects in another pool that she built in 1981 whereby she allegedly made fraudulent representations and failed to honor a warranty; and for constructing a pool in 1982 after her Certificate of Competency had been revoked by the Leon County Contractor's Licensing and Examination Board. Respondent appeared at the hearing without counsel, and was thereupon advised of her rights and the procedures applicable to an administrative proceeding. She indicated that she understood such rights and elected to represent herself. At the hearing, Petitioner presented the testimony of nine witnesses and submitted 22 exhibits in evidence. Respondent testified in her own behalf, but did not submit any documentary evidence. Petitioner's Proposed Recommended Order has been fully considered, and those portions thereof not adopted herein are considered to be either unnecessary, irrelevant, or unsupported in law or fact, and are specifically rejected.
Findings Of Fact Respondent Laura H. Eubanks is a state registered commercial pool contractor who operates Eubanks Company Big Bend Pool Builders, Tallahassee, Florida. She was originally licensed in 1975 and remained licensed at all pertinent times relative to this proceeding, but her license was in a delinquent status as of July 1, 1983. (Petitioner's Exhibit 1) On May 2, 1981, Respondent entered into an agreement with Thomas V. and Barbara J. Mulqueen, Jr., 6719 Johnston Loop, Tallahassee, Florida, for the sale and installation of a swimming pool at their residence for the amount of $6,725.63. On September 22, 1981, Mr. Mulqueen filed a complaint against Respondent with the Leon County Contractors Licensing and Examination Board. Mr. Olin Williams, Supervisor of Inspections for the Board, investigated the complaint and found that staples were protruding underneath the pool liner, that a water pipe leaked at the pump, apron or deck concrete cracks were caused by curing tension at inside corners, about 35 percent of the concrete deck was darker in color than the remainder of the deck, an improperly placed outlet for the pool drain permitted seepage under the pool liner, and that repairs to a neighbor's fence and the owner's driveway had not been completed. He classified those discrepancies as pertaining to workmanship. In addition, he determined that there had been a violation of the health code in that a septic tank had been broken by workmen and waste sewage had flowed into the pool excavation for a period of several days. The owner was seeking to have Respondent correct the problems and complete the job. Inspector Williams contacted the Respondent on October 12, 1981, and, although she told him that she would come to his office that day and bring the individual responsible for the job, she failed to do so. No final inspection of the work had been requested by Respondent. (Testimony of Williams, Petitioner's Exhibit 4) By letter dated November 12, 1981, Respondent was advised by the Leon County Contractors Licensing and Examination Board that a formal hearing had been scheduled on the complaint for December 3, 1981. A copy of the complaint and the Building Inspector's Report was enclosed, and she was advised of her right to be represented by counsel at the hearing. In fact, the hearing by the Board was held on December 4, 1981, at which the Mulqueens were present and presented their complaint, and Inspector Williams informed the Board of his investigation and subsequent actions. Respondent was not present at the hearing, although the certified mail receipt reflected the signature of "L. H. Eubanks." At the December 4th meeting, the Board voted to suspend Respondent's license with the provision that the Board would not consider reinstatement unless repairs to the Mulqueen pool were made within thirty days after December 9, 1981, and if not, then the Board would consider permanent revocation. (Petitioner's Exhibits 5-6) By letter of January 12, 1982, the Board advised Respondent of the suspension of her license as a result of a hearing held on December 3, 1981. (No explanation was provided by Petitioner as to the discrepancy in the minutes of the Board meeting which reflected a date of December 4, 1931, and the letters sent to Respondent which stated that the hearing had been held on December 3, 1981.) Respondent was advised in the letter that the Board would not consider any application for reinstatement of Respondent's license unless repairs were effected to the Mulqueen pool within thirty days from receipt of the letter. She was further advised that if they had not been so completed, the Board would consider permanent revocation of her license, but if they had been completed within the required time, the Board would consider a written application for reinstatement at its meeting scheduled for January 28, 1982. This letter was hand delivered to Respondent's place of business on January 18, 1982. On January 20, 1982, Respondent telephoned Inspector Williams and stated that she would seek legal counsel and be at the Board meeting on January 28. She indicated to him that she had had some personal problems due to the illness of her sisters, and also had been the subject of theft (although a memo of Williams reflecting the telephone call was dated January 20, 1981, it was apparent from his testimony that the call was made on January 20, 1982.) (Testimony of Williams, Petitioner's Exhibits 7, 18) The Licensing Board met on January 28, 1982, and determined that Respondent's license would be revoked on February 26, 1982, if the previously noted defects had not been corrected. By letter dated February 3, 1982, she was advised by the Board of this fact and that the Board would meet again on February 25 concerning the matter. On February 25, the Board revoked Respondent's license. She was not present at the meeting. She was advised of this action by Letter of the Board, dated March 4, 1982. (Petitioner's Exhibits 2, 8-10) By contract dated July 15, 1981, Respondent agreed to install a swimming pool for Mr. and Mrs. Rex Tyler at their residence in Tallahassee, Florida, for the sum of $23,784.91. The project included installation of aluminum fencing and a brick wall, together with various items of pool equipment. The agreement provided that the contractor would remedy any defects in workmanship without cost, provided written notice was provided within one year after connection of the filter. After the pool was built and paid for by the Tylers, it was found that several problems existed. A pool light continuously went on and off improperly, the motor of the pool sweep leaked, the bottom drain was not adequately secured and would be knocked off by operation of the pool sweep, step tiles were not complete, one tile popped loose, and water faucets leaked. The primary problem, however, was that the main drain would not circulate water on the bottom of the pool. The Respondent was notified of these problems by the owners and repaired some of them over the course of time, but was unable to fix the pool light or the main drain. In this regard, Respondent called upon Walter Swans, another licensed pool contractor, who determined that both the light and the drain were stopped up with "marble" finish. The Tylers were obliged to spend $312.74 to pay Swann's bill and for a plumber to repair the leaking faucets. (Testimony of McCausland, A. Tyler, Clemens, Swann, Petitioner's Exhibits 21-23) By agreement dated May 28, 1982, Respondent contracted with Charles and Brenda Short for the installation of a swimming pool at 3249 Baldwin Drive West, Tallahassee, Florida, for a price of $6,809.20. During the course of construction, Mr. Short inquired of Respondent as to the need for a building permit. She initially told him that she would get one, but later when Short asked her again about the matter, she told him that if he didn't want one it would be all right with her because otherwise it would hold up completion of the pool. Short told her that that was all right with him. He was not familiar with permit requirements. After the walls of the pool had been finished, heavy rains caused the sides of the pool to partially collapse. Inspector Williams was notified of the problem and he found that the work was being done without the required permit. He therefore posted a stop work order at the construction site. On September 1, 1982, Respondent entered a plea of nolo contendere to a charge of contracting without a license in violation of Section 489.127(1)(f), Florida Statutes, in the Leon County Court, Case No. 82MM2702. The Court withheld adjudication of guilt and imposition of sentence and placed the Respondent on probation for a period of six months. The Shorts had paid Respondent a total of $4,000 on the contract price at the time work was stopped on the pool project. They eventually settled the matter with Respondent by agreement. (Testimony of Brenda Short, Charles Short, Courtney, Williams, Petitioner's Exhibits 12, 19-20) In a civil proceeding filed by the Mulqueens against Respondent in the Leon County Circuit Court, Case No. 82-68 the parties entered into a joint stipulation of settlement under which Respondent agreed by promissory note to pay the Mulqueens the sum of $2400 with interest by 24 monthly payments of $100.00 commencing January 1, 1983. On January 27, 1983, the Leon County Contractors Licensing Examination Board reinstated Respondent's license, subject to a 12 month probationary period. By letter October 24, 1983, Mr. Mulqueen advised the County Building Inspector that Respondent had only made two payments on the settlement agreement as of March 1983. (Testimony of Courtney, Petitioner's Exhibits 13-16) Section 2C, Leon County Ordinance No. 74-22, provides that its Contractors Licensing and Examination Board has the duty to suspend or revoke "authorized contractor" certificates for violation of the ordinance, violation of the County Building and Zoning Codes, or violation of any other state, municipal, or county law upon due cause shown to the Board after a hearing. Section 1E provides that the Board must provide the certificate holder with written notice of its intent to consider the revocation or suspension of the certificate, and afford him a hearing before the Board, and that all decisions concerning suspension of revocation of certificates shall be in writing. (Petitioner's Exhibit 17) Respondent testified at the hearing that she had had continuing financial problems commencing a number of years ago when some of her employees were building pools "on the side" with her materials. During the time that problems arose in connection with the Mulqueen and Tyler pools, she was preoccupied with serious personal problems involving her sisters, one of whom died of cancer and the other having been in a mental hospital. She acknowledged that she should have corrected the customer complaints and regrets that she did not do so. Respondent further stated that although she attempted to pay her note to the Mulqueens, her financial situation was such that she was unable to continue meeting the payments. Although she received notice of the various hearings before the Leon County Contractors Licensing and Examination Board, she testified that she had not been thinking of the consequences and didn't even read the letters of notification which were sent to her. She also acknowledged entering into the contract with the Shorts because she was "desperate" for money to pay her various creditors. (Testimony of Eubanks)
Recommendation That the Construction Industry Licensing Board enter a final order suspending the registration of Respondent Laura H. Eubanks as a pool contractor for a period of three months. DONE and ORDERED this 29th day of December, 1983, in Tallahassee, Florida. THOMAS C. OLDHAM Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of December, 1983. COPIES FURNISHED: James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Stephanie A. Daniel, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Laura H. Eubanks 1421 North Monroe Street Tallahassee, Florida 32303 ================================================================= AGENCY FINAL ORDER ================================================================= STATE OF FLORIDA DEPARTMENT OF PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD DEPARTMENT OF PROFESSIONAL REGULATION, Petitioner, vs. CASE NOS. 21738, 20754, 25386 LAURA H. EUBANKS DOAH CASE NO. 83-2362 737 North Monroe Street Tallahassee, Florida 32303 Respondent. /
Findings Of Fact At all material times hereto, Respondent was the holder of a registered swimming pool contractors license number RP 0035739. Respondent's license was issued in the name of Malicki Pools, Terry W. Malicki. In January, 1981, Gary Wieland entered into a contract with Patrick Barr d/b/a Pool and Spa World. Barr was to construct a pool for Weiland in Port Charlotte for $7,856.00. Barr had become known to Wieland as a builder of swimming pools through a neighbor. Barr stated to Wieland that he was a pool contractor. Wieland made all payments due under the contract to Barr. Petitioner's evidence established that the Wieland swimming pool required a building permit. On March 3, 1981, Terry Malicki d/b/a Malicki Pools obtained permit number 66970 to construct a pool at Wieland's residence in Port Charlotte. Wieland's testimony established that Malicki constructed the pool at his residence. However, all of his dealings were with Barr. Barr was not licensed as a swimming pool contractor in Charlotte County or in Florida, and was convicted in the Charlotte County court of acting as a contractor without being licensed. Mr. Robert Guariglia entered into a contract with Barr to construct a swimming pool for $9,500.00. The pool was to be constructed at Lot 17, Block 402, Subdivision 23 or 913 Cherry Chase, Port Charlotte, Florida. Petitioner's evidence established that the Guariglia pool required a building permit. On June 10, 1981, Terry Malicki d/b/a Malicki Pools obtained permit number 68962 to construct a pool at Lot 17, Block 402, Subdivision 23 or 913 Cherry Chase, Port Charlotte, Florida. Guariglia paid the first installment of his contract by check to Barr in the amount of $3,325.00. However, because the pool was not level, Guariglia told Barr or Malicki who was supervising the work that he wanted the pool redone or removed. The pool was later removed and Guariglia had to pay $1,400 to have his property restored. As noted above, Barr was not licensed as a swimming pool contractor in Charlotte County or in Florida, and was convicted of acting as a contractor without being licensed. However, the swimming pool constructed at the identified Guariglia residence required a building permit. On September 3, 1981, the Charlotte County Building Board suspended the certificate of competency of the Respondent until such time as he corrected all matters which were then pending before that Board. On November 5, 1981, the Charlotte County Building Board reinstated Malicki's license.
Recommendation In consideration of the foregoing, it is RECOMMENDED: That Petitioner enter a Final Order suspending the swimming pool contractor's license issued to Respondent for one (1) year. DONE and ENTERED this 22nd day of April, 1983, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of April, 1983. COPIES FURNISHED: Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Terry W. Malicki c/o Malicki Pools 1788 S.W. Sicily Avenue Port Charlotte, Florida 33952 Stephen Schwartz, Esquire 680 Aaron Street, N.W. Port Charlotte, Florida 33952 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
The Issue The issue in this case is whether Respondent committed the acts alleged in the Administrative Complaint and if so, what penalty is appropriate.
Findings Of Fact Based upon the testimony of the witnesses and the evidence presented and the entire record in this proceeding, the following material and relevant facts are found. At no time material hereto was Respondent, Donald Clark, licensed by the State of Florida Construction Industry Licensing Board to engage in construction contracting. At no time material hereto was Cancun Development Company ever qualified or certified by any State of Florida agency as a certified contractor. With knowledge of that he was not licensed by the State of Florida to solicit, engage in, nor contract for construction work, Respondent entered into an oral agreement with homeowner Ms. Eichar to build a second-story addition to her home, located in Indian Rocks Beach, Florida, for a contract price of $30,000.00. Respondent, who was paid by Ms. Eichar a total of $25,000.00, subcontracted with Mr. Erwin, a licensed electrical contractor, to do the electrical work at the Eichar's residence for $2,364.00. Respondent, after notice, failed to attend the formal final hearing regarding this matter. The investigative and prosecution costs to the Department of Business and Professional Regulation, excluding cost associated with attorney time, were $550.00.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is recommended that a final order be entered by the Department as follows: Finding Respondent, Donald Clark, guilty of having violated Subsection 489.127(1)(f), Florida Statutes, as alleged in the Administrative Complaint herein filed and imposing as a penalty an administrative fine in the amount of $5,000.00. Assess costs of investigation and prosecution, excluding costs associated with an attorney's time, in the amount of $550.70. DONE AND ENTERED this 23rd day of July, 2002, in Tallahassee, Leon County, Florida. FRED L. BUCKINE Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 23rd day of July, 2002. COPIES FURNISHED: Donald Clark 813 East Bloomingdale Avenue Suite 252 Brandon, Florida 32720 Brian A. Higgins, Esquire Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-2202 Hardy L. Roberts, III, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-2202
The Issue The issue at the hearing was whether Respondent's pool contracting license should be disciplined for alleged violations of Chapter 489, Florida Statutes.
Findings Of Fact Respondent is a licensed pool contractor in Panama City, Bay County, Florida, holding license number RP 0053231. Respondent was registered as an individual with the Board. The address given on his pool contractor's license was 3414 Jenks Avenue, Panama City, Florida. National Pools of Panama City, Inc. was not registered or certified as a contractor with the Board. National Pool's address was 3416 Jenks Avenue, Panama City, Florida. No clear and convincing evidence was presented as to whether Respondent had any knowledge of National Pool's unregenerate and incertitude status. On February 16, 1988, Robert D. Hay entered into a contract with National Pools of Panama City, Inc., for the construction of a pool on his property located at 1000 Kimberly Lane, Lynn Haven, Florida. The price of the pool was $9,310.92. The contract established a schedule of payments for the construction of the pool. Each payment was made upon completion of a certain portion of the construction work. The contract also provided that National Pools would pay for all work and materials used in the construction of the pool. A building permit was obtained for the construction of the pool. No evidence was submitted on who actually pulled the construction permit. The contractor listed on the building permit was Respondent and the construction was supervised by Respondent. The pool was completed to Mr. Hay's satisfaction and he paid the last installment payment to National Pools. 1/ Mr. Hay received a release of lien from Vance White. Mr. White was the president of National Pools. However, Mr. Hay later learned That National Pools had not paid for some materials which had been used in the pool's construction. The supplied of the materials filed a lien In the amount of $1,718.49 on Mr. Hay's property. Mr. Hay attempted to get National Pools to pay the lien. However, the lien was never satisfied by National Pools. Eventually, Mr. Hay was forced to pay the lien plus attorney's fees and court costs or else have the lien foreclosed on his property. The amount Mr. Hay was forced to pay in order to clear the title to his property was $2,615.41. There was no substantial evidence submitted which demonstrated Respondent's relationship to National Pools. The fact that Respondent's name appeared on the building permit does not support a finding that Respondent is the primary contracting agent for National Pools. Likewise, the fact that Respondent's address on his license was next door to National Pools does not support a finding that Respondent is the primary contracting agent for National Pools. It is just as likely an inference that Respondent was not the qualifying agent for National Pools, but was its subcontractor and it is National Pools and its officers who are violating the provisions of Chapter 489, Florida Statutes.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Board enter a Final Order dismissing the Administrative Complaint against Respondent. DONE and ENTERED this 2nd day of August, 1990 in Tallahassee, Florida. DIANE CLEAVINGER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of August, 1990.
Findings Of Fact At all times material hereto, Respondent has been a certified pool contractor in the state of Florida, having been issued License No. CP C029646. At all tines material hereto, Respondent has been the qualifying agent for Pools by Andrews, Inc., and the owner of that company. On August 21, 1986, George Silvers, a building inspector for the Village of Tequesta, saw people working at a pool site with no identification on the truck parked nearby. When he stopped, he discovered a crew installing- plumbing pipes for a swimming pool. When he asked for identification, Roland R. Androy identified himself as an employee of Pools by Andrews, Inc. Although "piping a pool" does not itself require specialized licensure, Silvers asked Androy if he were a licensed contractor, and Androy said that he was not. By way of further identification, Androy produced a personal card which read "Andy's Elite Pools." Silvers "red flagged" the job stopping construction and filed a complaint with the Department of Professional Regulation. Androy was an employee of Pools by Andrews, Inc., for approximately one year in 1974. He returned to Florida and again became an employee of Pools by Andrews, Inc. in February, 1985. During the remainder of that calendar year Androy drew a regular weekly salary from that company, received holiday pay, and drove a company vehicle. Taxes were deducted from his salary check, and the company provided him with health insurance. Androy was a fast worker and frequently finished piping pools early in the day at which time he was given odd jobs to perform for the company such as building shelves in the warehouse. Androy decided that he could make the same amount of money and substantially shorten his work day if he were paid on a piecework basis rather than for an eight hour work day. That way he would also be able to 'moonlight' by using his free time performing maintenance and repair work for swimming pool owners. Respondent agreed to pay Androy on the basis of piecework rather than a 40-hour work week. Since January 1, 1986, Androy appears at Pools by Andrews, Inc., at 6:00 a.m. six days a week at which time he is given a list of pools to plumb that day. All materials and equipment necessary to perform the work are supplied by the Respondent. When Androy finishes, he goes home. Every Friday he gives Respondent a list of pools that he piped that week, and Respondent pays Androy by check. Because Androy wanted to be free to leave when he finishes that day's work, he no longer drives a company truck but rather drives his own truck so he does not have to return the truck before he can go home. Under the new salary arrangement, he is paid by the job and no longer receives a regular weekly salary or holiday pay or health insurance. Further, Respondent has ceased deducting withholding tax and social security taxes from Androy's paycheck. The card which Androy gave to Inspector Silver is a card that he used prior to moving to Florida. He had new cards printed with his Florida address and telephone number. He uses them when persons ask how they can get in touch with him. Respondent had no knowledge of Androy having or using such a card. As a certified pool contractor, Respondent is aware of the requirements for licensure, that is, installation of a swimming pool must be done by a licensed contractor. However, there is no requirement for licensure for that portion of the installation known as piping a pool. Rather, that work can be performed by anyone under the supervision of a licensed contractor. Further, no separate permit is required for that "plumbing" portion of pool installation. All permits for the job in question were obtained by Pools by Andrews, Inc., pursuant to Respondent's state licensure. No other permits were necessary for the job, including the work done for Respondent by Androy. Respondent (like Androy) believes that Androy is an employee of his and not an independent contractor or a subcontractor. There is no intent on Respondent's part to evade he state licensure requirements. Respondent has had no other disciplinary actions filed against him.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is, RECOMMENDED that a Final Order be entered finding Respondent not guilty and dismissing the Administrative Complaint filed against him in this cause. DONE and RECOMMENDED this 29th day of February, 1988, at Tallahassee, Florida. LINDA M. RIGOT, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of February, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-4395 Petitioner's proposed findings of fact numbered 1, 2, and 4-6 have been adopted either verbatim or in substance in this Recommended Order. Petitioner's proposed finding of tact numbered 2 has been rejected as not being supported by any evidence in this cause. Petitioner's proposed finding of fact numbered 7 has been rejected as being contrary to the evidence in this cause. Respondent's proposed findings of fact numbered 1, 2, 6, 8, 9, and 12 have been adopted either verbatim or in substance in this Recommended Order. Respondent's proposed findings of fact numbered 3, 7, and 10 have been rejected as being irrelevant to the issues under consideration herein. Respondent's proposed findings of fact numbered 4, 5, and 11 have been rejected as not constituting findings of fact but rather as constituting argument of counsel or conclusions of law. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 David L. Swanson, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Edward W. Andrews 8300 Resource Drive Riviera Beach, Florida 33404 William O'Neil, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 =================================================================
Findings Of Fact Atlas Pools, Inc., contracted with Mr. and Mrs. Jerry Thompson in May, 1978, to construct a swimming pool on the Thompson property for a completed price of $5,940. Work ceased in mid-July, 1978, by which time the Thompsons had paid Atlas Pools $5,643. The Thompsons hired another pool contractor to complete the project at additional cost in excess of $2,000. Atlas Pools contracted with Mr. and Mrs. Dennis Perry in June, 1978, to construct a swimming pool on the Perry property for a completed cost of $5,770. Work ceased in late July, 1978, after the Perrys had paid Atlas Pools $5,474.50. The Perrys completed the project through self-help and use of another pool contractor at a further cost of $1,566. Atlas Pools contracted with Mr. and Mrs. Thomas Wolters in June, 1978, to construct a swimming pool on the Wolters' property for a completed cost of $6,980. Work ceased in mid-July, 1978, after the Wolters had paid Atlas Pools $6,631. The Wolters completed the pool through self help at an additional cost in excess of $1,300. Atlas Pools contracted with Mr. and Mrs. Albert Sentman in June, 1978, to construct a spa on the Sentman property for a completed cost of $5,500. The Sentmans paid Atlas Pools a $550 deposit after which the spa was delivered but not installed. The Sentmans completed the project by other means at an additional cost of $6,137. Respondent abandoned each of the above projects without notice to the customer, who ultimately learned of the company's bankruptcy from a third party source. Each of the four projects described above was completed at a final cost to the purchaser in excess of $900 over the contract price. The company filed a Voluntary Petition of Bankruptcy with the U.S. District Court, Middle District of Florida, on August 1, 1978. Thereafter, on March 7, 1979, the Brevard County Contractors Licensing Board revoked the certificate held by Atlas Pools for a minimum period of one year, with the requirement that financial rehabilitation be demonstrated as a condition of reinstatement. At the time of bankruptcy, Respondent was president of Atlas Pools, Inc., and owned one-third of the stock. He was, at all times relevant to this proceeding, the company's only licensed pool contractor. He is currently employed in pool construction work by a licensed contractor. Proposed findings of fact were submitted by the parties. To the extent these proposed findings have not been adopted herein or are inconsistent with the above findings, they have been specifically rejected as irrelevant or not supported by the evidence.
Recommendation Based on the foregoing, it is RECOMMENDED: That Pool Contractor's License No. RP 0018040 issued to Crawford L. Grove, be suspended until Respondent demonstrates compliance with the financial responsibility standards established by Section 489.115, Florida Statutes (1979). DONE AND ENTERED this 29th day of October, 1980, in Tallahassee, Florida. R. T. CARPENTER Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 FILED with the Clerk of the Division of Administrative Hearings this 29th day of October, 1980.
The Issue The administrative complaint filed on September 17, 1987 alleges that in a residential pool contracting job Respondent Martin ". . . exhibited financial mismanagement, misconduct, or diversion, in violation of 489.129(1)(h), (m) . . . [and] failed to perform in a reasonably timely manner, and/or abandoned said job, in violation of 489.129(1)(m), (k)." The issue is whether Martin committed those violations, and if so, what disciplinary action is appropriate.
Findings Of Fact At all times relevant, Kenneth Martin was licensed in the State of Florida as a registered commercial pool contractor, holding license number RP 0021608. His license is currently in inactive status. Martin was President of Adair Pools, Inc., the corporation under which he conducted his pool construction business. In early July 1986, Adair Pools contracted to build a residential pool for Paul and Cynthia Pajak at 8304 Helena Drive in Orange County, Florida. The pool was to be kidney-shaped, approximately 14 feet by 30 feet, with a waterfall and a detached spa. The contract amount of $11,571.00 expressly excluded the deck, electrical work and screening, although the written contract included a sheet describing the specifications for the excluded work, recommended contractors, and estimated costs. This sheet and the pool contract itself clearly indicated that these items were not the responsibility of the pool company and were not included in the contract price. Work commenced in July, shortly after the contract was signed. Although the contract did not specify a completion date, Martin concedes that the pool should have taken no more than four to eight weeks to complete. The Pajaks had planned a Labor Day party and were told by Adair's employees there would be no problem getting their pool finished for the party. The pool was not finished by Labor Day. After the pool was dug, shot with concrete and tiled, someone determined that the spa was supposed to have been raised. In attempting to raise the spa and to change the water jets, the workers cracked the shell of the spa and had to replace it. Until the problems with the spa, the Pajaks felt that the construction progress was reasonable and smooth. At this point, sometime around Labor Day, the problems began. Adair delayed in paying Shotcrete Pools, the subcontractor for the concrete shell, because Adair felt it was Shotcrete's fault that the spa was cracked. Shotcrete notified the Pajaks that a lien would be placed on the property if they were not paid. The notice to owner is dated November 3, 1986. Eventually Adair paid Shotcrete and its other subcontractors for the Pajak work and no lien was filed. The evidence does not reflect a clear sequence of events, but between Labor Day and February or March 1987, little progress was made to finish the pool. Martin's supervisor left and Martin's brother took over. The Pajaks kept calling Martin and were always assured that the job would be completed. Martin admits that the company at this time was in serious financial trouble because it was not being paid for a large commercial job that it had undertaken. On December 10, 1986, Mrs. Pajak's brother-in-law, an attorney, sent Martin a demand letter, giving a 10-day deadline for completion of the work. Martin and his brother met with the attorney and assured him the job would be finished. In spite of the problems, the Pajaks continued working with Martin and paid the full contract price, less the $100.00 that was to be paid when the pool was filled. On March 5, 1987, Martin informed the Pajaks that they should have the deck poured so that Adair could finish the pool. The Pajaks were not satisfied that the pool was ready for the deck as there were leaks in the waterfall, debris was all over the yard and the spa tile work looked messy. In Martin's opinion those items were his company's responsibility, but were part of the finishing to be done after the deck was poured and the pool was lined with marblelite. On March 21, 1987, the Pajaks contracted with another pool company for $4450.00 to finish their pool. Martin denies that Adair abandoned the job, but admits that it took an inordinate amount of time. The Pajaks did not allow him to finish the cleanup, the interior coating and the pool start up because they contracted with someone else. Martin did not contest that the waterfall leaked or that extensive cleanup needed to be done, but disputed that this work should be done before the deck was poured. He contended that the leaks in the waterfall would have been fixed when the finish was done. Martin estimates that between 1974 and 1986, his company completed over fourteen hundred residential pools and approximately five hundred large commercial pools. Martin has been active on various local pool construction industry boards and has no record of prior disciplinary action against his license.
Recommendation Based upon the foregoing, it is, hereby, RECOMMENDED: That Kenneth Martin be found guilty of misconduct, in violation of Section 489.129(1)(m), Florida Statutes, not guilty of the other violations with which he is charged, and that he be required to pay an administrative fine of $500.00. DONE and RECOMMENDED this 2nd day of August, 1988, in Tallahassee, Florida. MARY CLARK Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of August, 1988. COPIES FURNISHED: David E. Bryant, Esquire 220 East Madison Street, Suite 530 Tampa, Florida 33602 Kenneth R. Martin 3225 North Glenn Drive Orlando, Florida 32806 Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 =================================================================
Findings Of Fact At all pertinent times, respondent Henry J. Tinkler was licensed by petitioner as a swimming pool contractor, holding license No. 0024949, under the name of "Henry J. Tinkler." At one time, Fred C. Charlton worked as a "salesman" of swimming pool construction contracts for a Ft. Lauderdale construction company. When the Ft. Lauderdale company failed, several contracts to build swimming pools remained unexecuted. So that his "sales" would not have been in valid, Mr. Charlton organized Aquapool in late 1978 or early 1979 to step in to the shoes of the Ft. Lauderdale contractor. He has been president of the corporation since its inception. He knew that he could not pull building permits himself; and Mr. Charlton did not involve himself in the actual construction of the pools. Respondent became vice-president of Aquapool and held this office until September of 1979. Respondent has built several pools pursuant to oral agreements with Charlton (acting for Aquapool), to build all pools Aquapool "sold" in Pinellas County. In these transactions, Charlton made a profit and Tinkler made a profit. Respondent never applied for any building permit under Aquapool's name. He always used his own name or the name "Hank's Custom Pools." Respondent never made application to qualify Aquapool as a registered pool contractor in Florida. Neither did respondent make application to qualify "Hank's Custom Pools" as a registered pool contractor. Not uncommonly, contractors do business under fictitious trade names like "Hank's Custom Pools." Eventually one Clay Andrews of Jacksonville made application to quality Aquapool as a swimming pool contractor in Florida until November 17, 1979. Harry George Pugh and Grace L. Pugh signed, on May 19, 1979, a contract with Aquapool for construction of a swimming pool at their Indian Rocks Beach home. Petitioner's Exhibit No. 2. On the building permit application form, Petitioner's Exhibit No. 3, the contractor is listed as "Hank's Custom Pools." The application is dated June 19, 1979. Mr. Pugh never met Mr. Tinkler. Guy Jean and Jane A. Narejo also contracted with Aquapool to build a swimming pool at their home in Largo, Florida. Petitioner's Exhibit No. 4. Mr. Pugh never met Mr. Tinkler. On June 14, 1979, "H. Tinkler" applied for a permit to build the pool. The permit issued the following day. Petitioner's Exhibit No. 5. Willard L. Marks and Helen J. Marks signed, on May 1, 1979, a contract with Aquapool for construction of a swimming pool at their home in Clearwater, Florida. Petitioner's Exhibit No. 6. Mr. Marks never met Mr. Tinkler. H. J. Tinkler applied for a permit to build the pool on June 7, 1979. Petitioner's Exhibit No. 7. Swimming pool contractors ordinarily subcontract electrical work. Sometimes as many as four or five subcontractors participate in the building of a swimming pool. Petitioner's proposed recommended order has been considered and proposed findings of fact have been adopted except where they have been deemed irrelevant or unsupported by the evidence.
Recommendation Upon consideration of the foregoing, it is RECOMMENDED: That petitioner suspend respondent's registration as a swimming pool contractor for sixty (60) days. DONE and ENTERED this 27th day of April, 1982, in Tallahassee, Florida. ROBERT T. BENTON, II Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 Telephone: (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of April, 1982. COPIES FURNISHED: Michael Egan, Esquire 217 South Adams Street Tallahassee, Florida 32301 Gerald Nelson, Esquire 4950 West Kennedy Tampa, Florida 33609 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32302 Samuel R. Shorstein, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 ================================================================= AGENCY FINAL ORDER ================================================================= STATE OF FLORIDA DEPARTMENT OF PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD DEPARTMENT OF PROFESSIONAL REGULATION/CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. CASE NO. 81-3043 HENRY J. TINKLER, RP 0024949 d/b/a Individual 5243 27th Avenue St. Petersburg, Florida 33710 Respondent. /
The Issue The Florida Construction Industry Licensing Board, Petitioner, seeks to revoke the registered contractor's license of Stephen J. Borovina, Respondent, based on allegations, which will be set forth in detail hereafter, that he engaged in conduct violative of Chapter 468, Florida Statutes. The issue presented is whether or not the Respondent aided or abetted and/or knowingly combined or conspired with Mr. Howard North, an uncertified or unregistered contractor, to evade the provisions of Chapter 468.112(2)(b), and (c), Florida Statutes, by allowing North to use his certificate of registration without having any active participation in the operations, management, or control of North's operations. Based on the testimony adduced during the hearing and the exhibits received into evidence, I make the following:
Findings Of Fact The Respondent is a certified general contractor who holds license no. CGC007016, which is current and active. On or about July 25, 1976, Mr. and Mrs. Julius Csobor entered into a contract with Mr. and Mrs. Howard North for the construction of a home in Martin County, Florida, for a total price of $35,990. Neither Mr. or Mrs. North are certified or registered contractors in the State of Florida. (Petitioner's Composite Exhibit #2). Respondent applied for and was issued a permit by the Martin County Building Department to construct a residence for the Csobors at the same address stipulated in the contract between the Csobors and the Norths, i.e., Northwest 16th Street, Palm Lake Park, Florida. (Petitioner's Composite Exhibit #1). Howard North, a licensed masonry contractor for approximately nine (9) years was contacted by the Csobors through a sales representative from a local real estate firm. It appears from the evidence that North had previously constructed a "spec" house which the local realtor had sold and thus put the Csobors in contact with Mr. North when they were shown the "spec" house built by North. Evidence reveals that North contacted Borovina who agreed to pull the permit "if he could get some work from the job and could supervise the project". Having reached an agreement on this point, North purchased the lot to build the home for the Csobors and he orally contracted with the Respondent to, among other things, pull the permit, supervise construction, layout the home and do trim and carpentry work. North paid Respondent approximately $200 to layout the home for the Csobors. By the time that North had poured the slab and erected the subfloor, the Csobors became dissatisfied with his (North's) work and demanded that he leave the project. According to North, Respondent checked the progress of construction periodically. Prior to this hearing, the Csobors had never dealt with Respondent in any manner whatsoever. According to Csobor, North held himself out as a reputable building contractor. A contractor is defined in relevant part as any person who, for compensation, undertakes to, or submits a bid to, or does himself or by others, construct, repair, etc. . . . real estate for others. . . Chapter 468.102(1), Florida Statutes. Applying this definition to the facts herein, it appears that the Respondent, at least in a literal sense, satisfied the requirements and obligations of a contractor, as defined in Chapter 468.102, Florida Statutes. Thus, he contracted with North to oversee and/or supervise the project for the Csobors which he fulfilled, according to the testimony of North. Said testimony was not refuted and thus I find that no effort was made by Respondent to evade any provision of Chapter 468, Florida Statutes. Accordingly, I shall recommend that the complaint filed herein be dismissed in its entirety.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is hereby recommended that the complaint filed herein be dismissed in its entirety. RECOMMENDED this 4th day of November, 1977, in Tallahassee, Florida. JAMES E. BRADWELL Hearing Officer Division of Administrative Hearings 530 Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: Barry S. Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Stephen J. Borovina 2347 Southeast Monroe Street Stuart, Florida 33494 J. Hoskinson, Jr. Chief Investigator Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211 ================================================================= AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1442 STEPHEN J. BOROVINA, CG C007016, 2347 S. E. Monroe Street, Stuart, Florida 33494, Respondent. / This cause came before the FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD at its regular meeting on February 10, 1978. Respondent was sent the Hearing Officer's findings and recommendations and was given at least 10 days to submit written exceptions to the recommended order. Respondent was notified of the meeting so that respondent or counsel might appear before the Board. Respondent did not appear The FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD on February 10, 1978, after reviewing a complete transcript of the Administrative Hearing, by motion duly made and seconded voted to revoke the certified general contractor's license of STEPHEN J. BOROVINA. It is therefore, ORDERED that the certification of respondent STEPHEN J. BOROVINA, Number CG C007016, be and is hereby revoked. Respondent is hereby notified that he has 30 days after the date of this final order to appeal pursuant to Chapter 120, Florida Statutes, and the Florida Appellate Rules. DATED this 13th day of February, 1978. FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD BY: JOHN HENRY JONES, President ================================================================= SECOND AGENCY FINAL ORDER ================================================================= BEFORE THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD STEPHEN J. BOROVINA, CG C007016, Respondent/Appellant, vs. DIVISION OF ADMINISTRATIVE HEARINGS, DOCKET NO. 77-1442 FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner/Appellee. / This cause came before the Florida Construction Industry Licensing Board at its regular meeting on August 3, 1979. The respondent was sent the Hearing Officer's findings and recommendations and was given at least 10 days to submit written exceptions to the recommended order. Respondent was notified of the meeting so that respondent or counsel might appear before the Board. Respondent did appear. The Florida Construction Industry Licensing Board, on August 3, 1979, after reviewing a complete transcript of the Administrative Hearing, by motion duly made and seconded, voted to revoke the certified general contractor's license of Stephen J. Borovina, No. CG C007016. On February 13, 1978, the certification of respondent, Stephen J. Borovina, No. CG C007016, was revoked by order of the Florida Construction Industry Licensing Board. On April 25, 1979, the District Court of Appeal of the State of Florida, Fourth District, in Case Number: 78-527, reversed the final order of the Florida Construction Industry Licensing Board. That Court remanded the above captioned case to the Board to further consider the matter and enter such order as it may be advised in conformity with Section 120.57(1)(b)(9), Florida Statutes (1977). In accordance with the decision of the Florida District Court of Appeal, Fourth District, the Board has reconsidered the above captioned matter and finds as follows: The Board rejects the recommended order as the agency's final order. The Board adopts the first paragraph of the hearing officer's finding of fact. The Board, however, rejects the findings of fact found in the second paragraph of the hearing officer's findings. The second paragraph states as follows: A contractor is defined in relevent(sic) part as any person who, for compensation, undertakes to, or submits a bid to, or does himself or by others, construct, repair, etc. real estate for others...Chapter 468.102(1), Florida Statutes. Applying this definition to the facts herein, it appears that the Respondent, at least in a literal sense, satisfied the requirements and obligations of a contractor, as defined in Chapter 468.102, Florida Statutes. Thus, he contracted with North to oversee and/or supervise the project for the Csobors which he fulfilled, according to the testimony of North. Said testimony was not refuted and thus I find that no effort was made by Respondent to evade any provision of Chapter 468, Florida Statutes. Accordingly, I shall recommend that the complaint filed herein be dismissed in its entirety. The findings of fact found in the above-quoted paragraph were not based upon competent substantial evidence. The competent substantial evidence supports a finding that the respondent, Stephen J. Borovina, did not supervise the project and that Borovina evaded the provisions of Chapter 468, Florida Statutes. The following evidence supports the Board's position: There was no written agreement entered into between Howard North and the respondent which indicated that the respondent was to supervise the construction of the Csobors' house (T- 14); It was conceded at the hearing that the only subcontractors or draftmen who worked on the Csobors' house were contracted solely by Howard North and they had no contract whatsoever with the respondent (T-19, 25); The respondent never advised or informed Mr. and Mrs. Csobor that he was the contractor on the job. (T-51); At all times during the act of construction of the house, Mr. and Mrs. Csobor were under the impression that Howard North was the contractor (T-44-51). It is, therefore, ORDERED: That the certification of respondent, Stephen J. Borovina, Number CG 0007016, be and is hereby revoked. Respondent is hereby notified that he has thirty (30) days after the date of the Final Order to appeal pursuant to Chapter 120, Florida Statutes, and the Florida Appellate Rules. Dated this 3rd day of August, 1979. FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD BY: JOHN HENRY JONES, President
