Findings Of Fact In 1975 and 1976 John Morris, d/b/a Morris Pool Service, maintained the swimming pool at the Sunland Center in Miami, Florida under a contract with HRS. The contract for the year commencing July 1, 1976 and expiring June 30, 1977 (Exhibit 1) provided generally for Morris to maintain the Sunland Center pool for which he would be paid $520 per month. This contract further provided that a representative of Morris Pool Service check each day except Saturday and Sunday with Ms. O'Donohue, the Director of Training, or her successor. Recreation personnel at Sunland Center hoped to open the pool on Memorial Day; however, an impeller for the pump needed replacement and the pool was inoperative for some six weeks in May and June awaiting this part. During this time petitioner did little or no maintenance and the pool's condition was bad enough for the Superintendent to become involved and request a report from the Programs and Services Director (Exhibit 4). When the impeller did arrive in mid-June, 1977, the pool was in such bad shape it was necessary to drain the pool, scrub, and acid-wash the walls and floor of the pool to remove the accumulated algae and scum. Even a colony of frogs had taken up residence in the pool during this period. As a result of additional delays the next hoped-for opening date of July 4 was also missed. The pool was finally ready for operation and was opened the week following July 4, 1977. Although opened the water in the pool was not properly maintained by cleaning and chlorinating. In the latter part of July the gas chlorinator became inoperative and the pool's condition deteriorated as no chlorine was being added to the water. Under the contract Petitioner was to provide materials necessary to keep the pool water in a balanced condition. This contract expired on June 30, 1977. Nevertheless, Petitioner purported to continue working under the expired contract, pending the issuance of a new contract for 1977-1978. While the gas chlorinator was inoperative Petitioner did not hand-feed chlorine to the pool to maintain the proper chlorine level and to keep algae from growing. By early August, 1977, the pool had become so bad the supervisory personnel at Sunland Center called the Dade County Health Department to inspect the pool. A report of that inspection showing the pool unfit for use was admitted into evidence as Exhibit 3. Following the Superintendent's inquiry to Ms. Titus about the condition of the pool in June, 1977, she contacted Petitioner, who told her the pool would he hack in operation as soon as the impeller was received. Ms. Titus was the successor to Ms. O'Donohue and she told Petitioner to keep her advised regarding the status of the pool. Although the contract (Exhibit 1) required Petitioner to report to Ms. Titus daily (except Saturday and Sunday) she did not see him again, nor did she receive any report that he came to her office. Petitioner contends that he attempted to report to Ms. Titus but was unable to find her in her office and after a few attempts stopped trying. Ms. Titus and her assistant were both equipped with beepers and could be contacted any time of day by their office if they were out of the office. Following the Health Department's inspection on August 9, 1977, the pool was closed for several days, then reopened around mid-August after the chlorinator was repaired. When the pool was reopened in August its condition was barely satisfactory. Shortly after Labor Day the pool was again closed and remained closed throughout the balance of 1977. By October, the Sunland Center officials decided they should notify Petitioner that his contract would not be renewed for the 1977-1978 year and a letter dated October 27, 1977 (Exhibit 2) was forwarded to him by registered mail. This letter was mailed to an old address for Petitioner, was returned to the sender and remailed to the proper address. As a result, the letter was not received by Petitioner until December 14 or 15, 1977. Petitioner submitted bills to Respondent for services for the period July 1, 1977 through December 15, 1977, the approximate date he received Exhibit 2. Following August 10, 1977 some of Respondent's employees in the maintenance department saw Petitioner in the cafeteria at Sunland Center and on the premises, but none of them reported seeing Petitioner do any work on the pool. Petitioner contends he worked on the pool on a daily basis, however, the condition of the pool casts serious doubts on this testimony.
Findings Of Fact At all pertinent times, respondent Henry J. Tinkler was licensed by petitioner as a swimming pool contractor, holding license No. 0024949, under the name of "Henry J. Tinkler." At one time, Fred C. Charlton worked as a "salesman" of swimming pool construction contracts for a Ft. Lauderdale construction company. When the Ft. Lauderdale company failed, several contracts to build swimming pools remained unexecuted. So that his "sales" would not have been in valid, Mr. Charlton organized Aquapool in late 1978 or early 1979 to step in to the shoes of the Ft. Lauderdale contractor. He has been president of the corporation since its inception. He knew that he could not pull building permits himself; and Mr. Charlton did not involve himself in the actual construction of the pools. Respondent became vice-president of Aquapool and held this office until September of 1979. Respondent has built several pools pursuant to oral agreements with Charlton (acting for Aquapool), to build all pools Aquapool "sold" in Pinellas County. In these transactions, Charlton made a profit and Tinkler made a profit. Respondent never applied for any building permit under Aquapool's name. He always used his own name or the name "Hank's Custom Pools." Respondent never made application to qualify Aquapool as a registered pool contractor in Florida. Neither did respondent make application to qualify "Hank's Custom Pools" as a registered pool contractor. Not uncommonly, contractors do business under fictitious trade names like "Hank's Custom Pools." Eventually one Clay Andrews of Jacksonville made application to quality Aquapool as a swimming pool contractor in Florida until November 17, 1979. Harry George Pugh and Grace L. Pugh signed, on May 19, 1979, a contract with Aquapool for construction of a swimming pool at their Indian Rocks Beach home. Petitioner's Exhibit No. 2. On the building permit application form, Petitioner's Exhibit No. 3, the contractor is listed as "Hank's Custom Pools." The application is dated June 19, 1979. Mr. Pugh never met Mr. Tinkler. Guy Jean and Jane A. Narejo also contracted with Aquapool to build a swimming pool at their home in Largo, Florida. Petitioner's Exhibit No. 4. Mr. Pugh never met Mr. Tinkler. On June 14, 1979, "H. Tinkler" applied for a permit to build the pool. The permit issued the following day. Petitioner's Exhibit No. 5. Willard L. Marks and Helen J. Marks signed, on May 1, 1979, a contract with Aquapool for construction of a swimming pool at their home in Clearwater, Florida. Petitioner's Exhibit No. 6. Mr. Marks never met Mr. Tinkler. H. J. Tinkler applied for a permit to build the pool on June 7, 1979. Petitioner's Exhibit No. 7. Swimming pool contractors ordinarily subcontract electrical work. Sometimes as many as four or five subcontractors participate in the building of a swimming pool. Petitioner's proposed recommended order has been considered and proposed findings of fact have been adopted except where they have been deemed irrelevant or unsupported by the evidence.
Recommendation Upon consideration of the foregoing, it is RECOMMENDED: That petitioner suspend respondent's registration as a swimming pool contractor for sixty (60) days. DONE and ENTERED this 27th day of April, 1982, in Tallahassee, Florida. ROBERT T. BENTON, II Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 Telephone: (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of April, 1982. COPIES FURNISHED: Michael Egan, Esquire 217 South Adams Street Tallahassee, Florida 32301 Gerald Nelson, Esquire 4950 West Kennedy Tampa, Florida 33609 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32302 Samuel R. Shorstein, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 ================================================================= AGENCY FINAL ORDER ================================================================= STATE OF FLORIDA DEPARTMENT OF PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD DEPARTMENT OF PROFESSIONAL REGULATION/CONSTRUCTION INDUSTRY LICENSING BOARD, Petitioner, vs. CASE NO. 81-3043 HENRY J. TINKLER, RP 0024949 d/b/a Individual 5243 27th Avenue St. Petersburg, Florida 33710 Respondent. /
Findings Of Fact On October 10, 1979, the Respondent entered into a written swimming pool contract with Mr. and Mrs. Stellato, wherein the Respondent agreed to construct a swimming pool for them on their property in accordance with the plans and specifications attached to the contract. Among other things this swimming pool contract provided for the payment of a total purchase price of $11,225.00 to be paid in the following manner: ten percent to be paid at the signing of the contract. fifty percent to be paid upon the installation of the tank. thirty-five percent to be paid upon completion of the base decking and screen enclosure. five percent, or the balance of the purchase price, to be paid when the filter system was put in operation. Further, this contract provided that if the purchasers of the swimming pool failed to pay the purchase price in accordance with the prescribed schedule, the contractor reserved the right to suspend all work on the swimming pool, and to suspend all warranty work due after completion of the pool. During the month of February, 1980, the Respondent, acting through his duly authorized representatives, did all acts necessary to cause the filter system of the subject swimming pool to become operable, and requested that the Stellatos pay the five percent balance due under the contract. The Stellatos failed to make this final payment, claiming that there was a problem with the pool decking. In response to this complaint the Respondent personally met with the Stellatos, and agreed to cover the problem area of the decking with Chattahoochee River Rock at no cost to the Stellatos. In exchange for this agreement the Stellatos agreed to pay the balance due under the contract. Thereupon, the Respondent installed Chattahoochee River Rock over a substantial portion of the decking at his own expense. During the installation of this Chattahoochee River Rock, Mrs. Stellato contacted the Respondent by phone and demanded that he also install, at his own expense, Chattahoochee River Rock over an existing concrete patio area that had not been built by the Respondent. The Respondent refused to incur this additional expense, because it was not in accordance with the agreement of the parties. Thereafter, the Stellatos again failed to pay the balance due under the contract. The subject swimming pool was inspected by an inspector for Palm Bay, and the City issued a certificate of occupancy in June of 1980. The pool was ready for a certificate of occupancy in February of 1980 except for the removal of one pile of dirt that still remained on the premises. All other aspects of the pool construction passed inspection in February of 1980 when the pool filter system was activated. Since February Of 1980, the Stellatos have had full use of the subject swimming pool. Except for alleging that some low spots remain in the pool decking, the Petitioner offered no substantial evidence of any other significant problem with the Respondent's construction. Notwithstanding the failure of the Stellatos to pay the balance of the contract price in a timely manner, the Respondent performed warranty work on the subject swimming pool after February of 1980. During the course of this warranty work the Respondent added chlorine chemicals to the pool because the Stellatos had failed to properly maintain it up to June of 1980. Another claim concerning a leaking pipe on the pool sweep did not manifest itself until April of 1981, after the expiration of the one year warranty period afforded by the Respondent to all customers. The Petitioner offered no evidence to show that the leak in this pipe was caused by the Respondent. Notwithstanding the expiration of the warranty period, and the lack of evidence to show that the leak was caused by the Respondent, he did send an employee to the job site and stopped the water leak, at no cost to the Stellatos. On several occasions when the Respondent or his employees attempted to satisfy the complaints of the Stellatos, they had to leave the job site because of the abusive language and conduct directed toward them by the Stellatos. In one instance Mr. Stellato ordered the Respondent's employees from the job site and prevented performance of any work under the contract.
Recommendation Based upon the foregoing findings of fact and conclusions of law, it is RECOMMENDED that the Administrative Complaint, as amended, against John W. Thornett be dismissed. THIS RECOMMENDED ORDER entered this 9 day of June, 1982, in Tallahassee, Florida. WILLIAM B. THOMAS Hearing Officer Division of Administrative Hearings Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 Filed with the Clerk of the Division of Administrative Hearings this 9th day of June, 1982.
Findings Of Fact Martin R. McAndrew is a licensed general contractor and licensed pool contractor holding general contractor's license number RG 0020560 and pool contractor's license number RP 0024861. Martin R. McAndrew was provided notice in accordance with the applicable rules and statutes of the formal hearing to consider the allegations of the administrative complaint filed against him by the Florida Construction Industry Licensing Board. Ray Dowell identified a notice of violation served on McAndrew by the Florida Construction Industry Licensing Board which was received into evidence as Exhibit 1. This notice of violation related to the construction undertaken by McAndrew for Lynn McMillan. Melvin C. Huebschman entered into a contract with McAndrew for the construction of a pool. The contract price for the pool was $5,000.00. Huebschman paid McAndrew $2,000 in two payments. The first payment was in the amount of $300.00 to cover the cost of transportation of the pool materials to Pensacola, Florida. The second payment in the amount of $1,700.00 was for the first phrase of construction on the pool. Subsequent to receiving payment McAndrew provided no materials or labor pursuant to the contract. Huebschman talked with McAndrew concerning completion of the work pursuant to the contract and McAndrew failed to perform under the contract throughout the spring and summer of 1977. In August, 1977, Huebschman wrote McAndrew advising him that it had been over ninety days since they entered into the contract and McAndrew had not performed any services pursuant to the contract. Huebschman gave McAndrew thirty days within which to commence work. McAndrew did not respond to this notice. McAndrew did not return any portion of the $2,000.00 paid to him by Huebschman. Lynn McMillan entered into a contract, identified as a portion of Exhibit 4, with McAndrew. This contract called for the construction of a pool for a contract price of $5,800.00. Pursuant to that contract, McMillan paid to McAndrew $4,350.00. Subsequent to payment of the third draw, McAndrew failed to complete the job. The last work performed by McAndrew on this construction project was on May 17, 1977. Prior to May 17, 1977, all materials for completing the pool were on the site and installed. Before abandoning the project, McAndrew removed from the building site all portions of the pool construction except the poured concrete and vinyl lining. McMillan subsequently entered into a contract with Surf Side Pools for the completion of the pool. The contract price was $1275.00, which included $800.00 for equipment and materials necessary to complete the pool. In addition, McMillan found it necessary to pay $230.00 to O'Brian Enterprises to remove stumps and spoil left on the construction project by McAndrew. McMillan also paid $200.00 to Warrick Electric Company to satisfy a claim by Warrick for materials and labor provided by Warrick to McAndrew. Finally, American Ready Mix Concrete filed a claim of lien in the amount of $436.80 against the property of Lynn McMillan for labor and materials provided under the contract with McAndrew which McAndrew did not pay. On May 27, 1977, McAndrew wrote a letter to McMillan advising that he would like the opportunity to finish the pool and was invited to do so. However, McAndrew did not return to the construction site or provide any further labor or materials pursuant to the contract. Sarah White Witt entered into a contract with McAndrew for the construction of a pool at a contract price of $4,500.00. Witt paid McAndrew $500.00; however McAndrew did not finish the pool construction. Subsequently, Witt was advised by the materialmen and labors of various liens against her property totalling $2,200.00. Daryl Jernigan, electrical and pool inspector for Escambia County, inspected the work done by McAndrew on the McMillan pool. He found that the pool had been filled with water but that the equipment necessary to recirculate and chlorinate the water had been removed from the pool, thereby permitting the water to stagnate. This inspection was conducted in June, 1977. Prior to that time, Jernigan had found it necessary to order work on a pool begun by McAndrew halted because McAndrew had failed to acquire a building permit prior to commencing construction.
Recommendation Based upon the foregoing findings of fact and conclusions of law, the Hearing Officer recommends that Florida Construction Industry Licensing Board revoke the licenses of Martin R. McAndrew as a general contractor and as a pool contractor, and further fined a sum of $500.00. DONE and ORDERED this 24th day of May, 1978, in Tallahassee, Florida. STEPHEN F. DEAN, Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 (904) 488-9675 COPIES FURNISHED: J. K. Linnan Executive Director Florida Construction Industry Licensing Board P. O. Box 8621 Jacksonville, Florida 32211 Michael E. Egan, Esquire Attorney at Law 217 South Adams Tallahassee, Florida Martin R. McAndrew 3313 N. 17th Avenue Pensacola, Florida 32502
The Issue Whether Respondent's license as a pool contractor should be disciplined and, if so, what penalty to recommend.
Findings Of Fact At all times relevant hereto John A. Bennett, Respondent, was licensed by the Florida Construction Industry Licensing Board as a residential pool contractor, having been issued license number RP 0033592. He is the qualifying contractor for Quality Pools and Products, Inc., 2912 Forest Wood Drive, Seffner, Florida 33584 (Exhibit 2). On or about January 25, 1988, Evelyn L. Dittmer and James W. Dittmer entered into a contract with Quality Aquatech Pools & Spas (Quality Pools), 1500 N. Parsons Avenue, Brandon, Florida, to replace the liner and repair the bottom of the pool (Exhibit 5). This contract was signed by the Dittmers and Andy Priess, presumably the foreman of Quality Pools. The Dittmers never met Respondent, but they "understood" he owned the pool company. Printed on the bottom of Exhibit 1 is Respondent's state registration number. Employees of Quality Pools arrived on the site and removed the old liner. At this time, the bottom of the pool was in bad shape, but the workers attempted to replace the liner without repairing the bottom of the pool. They were stopped from replacing the liner and departed as they had brought no equipment with which to repair the bottom. Workers returned for the next several days to attempt to repair the bottom of the pool. Due to excessive ground water entering the pool, this task was onerous. The initial contract provided that if it became necessary to establish well points to keep excess water out of the pool, an additional fee of $200 would be required. The Dittmers paid this fee, but well points were not established. An addendum to the contract was prepared for additional work needed to get the bottom of the pool back in shape (Exhibit 1) and was signed by John A. Bennett. This provided for an additional payment of $600, but was not accepted or signed by the Dittmers. The new liner was ultimately installed, but was torn in the process and the unnatural hole in the bottom of the pool was not repaired. Although the Dittmers had paid Quality Pools the full contract price of $2700, which included a $200 charge for installing well points, the work was never satisfactorily completed, and Quality Pools failed to perform the work for which they had contracted. The project was finally abandoned by Quality Pools, and two of the pumps used to dewater the pool were left on the site. At no time did anyone from Quality Pools obtain a permit from Sarasota County where this work was done, and Quality Pools was not licensed to work in Sarasota County (Exhibit 3). After it became evident Quality Pools would not complete the repairs for which they had contracted, the Dittmers hired another contractor to whom they paid an additional $2945 to restore the pool to an operating condition (Exhibit 7).
Recommendation It is recommended that the charges against John A. Bennett arising out of the contract between the Dittmers and Quality Aquatech Pools & Spas be dismissed. RECOMMENDED this 5th day of January, 1990, in Tallahassee, Florida. K. N. AYERS Hearing Officer Division of Administrative Hearings The Desoto Building 1230 Apalachee Parkway Tallahassee, FL (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 5th day of January, 1990. APPENDIX TO RECOMMENDED ORDER, CASE NO. 89-4839 Proposed findings submitted by Petitioner are accepted with the exception of findings 3, 4, 5, 6, 7, 8, 11, 13, 14, 15, 16 and 17 which are rejected for the reason that the evidence submitted does not show Respondent to be the owner or qualifying contractor of Quality Aquatech Pools and Spas with whom the Dittmers contracted. Findings of fact cannot be founded in uncorroborated hearsay evidence not admissible over objection in civil proceedings. COPIES FURNISHED: Andrea Bateman, Esquire Department of Professional Regulation Northwood Centre 1940 North Monroe Street Suite 60 Tallahassee, FL 32399-0792 Michael S. Edenfield, Esquire 206 E. Mason Street Brandon, FL 33511 John A. Bennett 1500 Parsons Avenue Brandon, FL 33511 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32201 Kenneth E. Easley General Counsel Department of Professional Regulation 1940 N. Monroe Street Suite 60 Tallahassee, FL 32399-0792 =================================================================
The Issue The issues posed for decision herein are whether or not the certified pool contractor's license issued to Respondents Licensee, Edward G. Batter, should be revoked or suspended or the Licensee's right to practice thereunder should be withdrawn based on conduct which will be set forth hereinafter in detail as set out in the Administrative Complaint filed herein on August 23, 1979.
Findings Of Fact Based upon my observation of the witnesses and their demeanor while testifying, the arguments of counsel and the entire record compiled herein, the following relevant facts are found. Edward G. Batter, d/b/a Tropicana Pools, Inc., (Respondent or Licensee) is a certified pool contractor who holds license No. CPC 012906. Respondent was first licensed on July 28, 1978, as qualifier of Tropicana Pools, Inc., which license was temporarily suspended in June, 1979, and remains in an invalid status to this date. By its Administrative Complaint, Petitioner's Executive Director took action to revoke or otherwise suspend the Respondent's rights to practice pursuant to his referenced license. As a licensed pool contractor, Respondent is subject to the Board's rules and regulations. (See Petitioner's Composite Exhibit 1.) A special meeting of the Board of Adjustment, Appeals and Examiners for general building contractors for Hillsborough County was held on Thursday, July 19, 1979, for the purpose of hearing certain allegations concerning the demise of Tropicana pools, Inc. Jerry Taylor, Petitioner's field investigator, presented the Hillsborough County Board with the results of an investigation of Respondent and presented several cases wherein funds were diverted after being collected for a specific contract to other projects or for other purposes and that projects for which funds had been collected had either been left unstarted or abandoned at the time Tropicana Pools, Inc., ceased doing business. At that meeting, the Respondent's construction activities were suspended by the Board until restitution or settlement was made and verified by affected parties. The temporary suspension by Hillsborough County became final during August of 1979. (Petitioner's Exhibits 2 and 3.) Howard Shaw, Director of Building and Zoning for the City of Tampa, appeared and testified to substantiate the disciplinary action taken against the Respondent by Hillsborough County during the summer of 1979. On June 7, 1979, Mr. and Mrs. James R. Stanton entered into a contract with Respondent to have a pool constructed for a price of $8,182.00. Respondent was paid a 10 percent deposit to commence construction of the Stantons' pool. Respondent absconded with the deposit and never notified the Stantons that their pool would not be built nor did Respondent return their deposit. (See Petitioner's Exhibits 4 and 5.) On April 19, 1979, Mr. and Mrs. Theodore Hillary entered into a contract for the construction of a swimming pool for a contract price of $8,130.00. Approximately $5,690.00 or approximately 70 percent of the contract sum was paid on June 18, 1979, and the work ceased on the Hillary project at a completion stage of approximately 40 percent. Respondent abandoned the Hillary project on approximately June 5, 1979. The Hillarys completed their pool at a price of approximately $5,000.00 over and above the contracted price. (Petitioner's Composite Exhibit 6.) On April 30, 1979, Mr. and Mrs. Leon Tope entered into a contract for the construction of a swimming pool at their residence for the contract price of $8,050.00. On June 18, 1979, the Topes had tendered to Respondent approximately 70 percent of the contract cost while the Respondent abandoned the construction of the Topes' pool after approximately 40 percent of the work was complete. Respondent abandoned the project on June 18, 1979, and the Topes completed the construction of their pool at a price of approximately $2,000.00 by engaging the services of other contractors in the area. (See Petitioner's Exhibits 7, 8, 9, 10, and the testimony of Jim Moran.) Jerry Taylor, Petitioner's field investigator, attended the probable cause hearing during August of 1979 in which the Hillsborough County Board of Examiners suspended the pool license of Respondent. Investigator Taylor briefed the Hillsborough County Board respecting the results of the investigation conducted by Petitioner.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED that the Respondent's pool contractor's license No. CPC 012906 be REVOKED. ENTERED this 10th day of March, 1980, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings 101 Collins Building Tallahassee, Florida 32301 (904) 488-9675
Findings Of Fact At all material times hereto, Respondent was the holder of a registered swimming pool contractors license number RP 0035739. Respondent's license was issued in the name of Malicki Pools, Terry W. Malicki. In January, 1981, Gary Wieland entered into a contract with Patrick Barr d/b/a Pool and Spa World. Barr was to construct a pool for Weiland in Port Charlotte for $7,856.00. Barr had become known to Wieland as a builder of swimming pools through a neighbor. Barr stated to Wieland that he was a pool contractor. Wieland made all payments due under the contract to Barr. Petitioner's evidence established that the Wieland swimming pool required a building permit. On March 3, 1981, Terry Malicki d/b/a Malicki Pools obtained permit number 66970 to construct a pool at Wieland's residence in Port Charlotte. Wieland's testimony established that Malicki constructed the pool at his residence. However, all of his dealings were with Barr. Barr was not licensed as a swimming pool contractor in Charlotte County or in Florida, and was convicted in the Charlotte County court of acting as a contractor without being licensed. Mr. Robert Guariglia entered into a contract with Barr to construct a swimming pool for $9,500.00. The pool was to be constructed at Lot 17, Block 402, Subdivision 23 or 913 Cherry Chase, Port Charlotte, Florida. Petitioner's evidence established that the Guariglia pool required a building permit. On June 10, 1981, Terry Malicki d/b/a Malicki Pools obtained permit number 68962 to construct a pool at Lot 17, Block 402, Subdivision 23 or 913 Cherry Chase, Port Charlotte, Florida. Guariglia paid the first installment of his contract by check to Barr in the amount of $3,325.00. However, because the pool was not level, Guariglia told Barr or Malicki who was supervising the work that he wanted the pool redone or removed. The pool was later removed and Guariglia had to pay $1,400 to have his property restored. As noted above, Barr was not licensed as a swimming pool contractor in Charlotte County or in Florida, and was convicted of acting as a contractor without being licensed. However, the swimming pool constructed at the identified Guariglia residence required a building permit. On September 3, 1981, the Charlotte County Building Board suspended the certificate of competency of the Respondent until such time as he corrected all matters which were then pending before that Board. On November 5, 1981, the Charlotte County Building Board reinstated Malicki's license.
Recommendation In consideration of the foregoing, it is RECOMMENDED: That Petitioner enter a Final Order suspending the swimming pool contractor's license issued to Respondent for one (1) year. DONE and ENTERED this 22nd day of April, 1983, in Tallahassee, Florida. R. T. CARPENTER, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 22nd day of April, 1983. COPIES FURNISHED: Charles F. Tunnicliff, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Terry W. Malicki c/o Malicki Pools 1788 S.W. Sicily Avenue Port Charlotte, Florida 33952 Stephen Schwartz, Esquire 680 Aaron Street, N.W. Port Charlotte, Florida 33952 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202 Fred Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301
Findings Of Fact Respondent is a certified pool contractor, holding license number CP CO27486. Respondent obtained his certificate in October, 1983. His only prior discipline consists of a letter of guidance in late 1989 or early 1990. At all material times, Respondent was qualifying agent for Gold Medallion Pcol, Inc. On March 27, 1986, Respondent and Mr. and Mrs. Don Burson entered into a contract for the construction cf a swimming pool at the Bursons' residence. The Bursons had purchased the residence while it was still under construction in May or June, 1985. The lot was low and had required fill. Clearly visible behind the lot is a large marshy wetland. The contract called for the Bursons to pay $16,315 for the construction of a 20' by 40' concrete lap pool with depths of 3' at either end and 6' in the center. Paragraph 4 of the contract provides: The Owner is responsible for increased costs incurred by the Contractor due to underground conditions which may be encountered during construction, such as but not limited to, muck, inadequate soil-bearing capacity, and excessive ground water. The Contractor, upon encountering such conditions, shall notify the Owner of their existence and give him an approximate cost estimate to rectify the problem. The Owner shall have five (5) days from the receipt of the approximate cost estimate to instruct the Contractor not to proceed with the pool. . . . If the Contractor determines that additional testing is required prior to furnishing approximate costs estimates to determine the exact nature or extent of the underground condition encountered, the Owner shall be responsible for the cost of all testing and/or engineering required by the Contractor. Paragraph 8.D states that the Owner warrants that there [is] no . . . mock . . . in that portion of the owner's property which the contractor will construct the pool [and] decking . . .. The owner is responsible for the removal, repair or replacement of any underground conditions . . . encountered during construction unless he elects to terminate the contract and pay damages to the contractor as set forth in the clause on underground conditions. Paragraph 11.A provides: Contractor warrants to the original owner for the lifetime of the original purchaser, the swimming pool structure, the shell, will not leak due to cracking. . . . This Limited Structural Warranty does not cover damage to the pool shell caused by fluctuations of the water table, construction in the vicinity of the pool site, or natural phenomenon. . . . The contractor's responsibility under this Limited Structural Warranty shall be to repair the shell so that it holds water without cost to the original owner. . . . The method of repair shall be at the discretion of the contractor. THE CONTRACTOR MAKES NO OTHER EXPRESS OR IMPLIED WARRANTIES INCLUDING THE WARRANTY OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE IN REGARDS TO THE POOL STRUCTURE, THE SHELL. Paragraph 11.B.2, which further describes the limited warranty, states: It is anticipated the concrete deck and deck coatings may crack due to settling of deck or weather. Cracks one-quarter inch or less with no substantial deviation in elevation are not covered. . . . The plot plan, which is part of the contract, shows the pool located on the east side of the house. The pool is oriented in a north-south direction. The southern end of the pool runs toward the back of the lot, which is on a steep slope. The southern end of the pool adjoins the widest section of decking, which Respondent constructed at the time of the construction of the pool. The plot plan also shows that excavated dirt was to be placed just south of the decking on the south end of the pool. Shortly after pulling a building permit from the Seminole County Building Department on March 27, 1986, Respondent began construction of the pool. The actual construction was performed by Mid-Florida Pool Company, which is a major pool construction company in Central Florida. Construction was completed on April 23, 1986, and the Bursons paid the amount required under the contract. Prior to commencement of construction of the pool, this area of the Bursons' lot had been filled with about 2 1/2 to 3 feet of dirt. In order to construct the pool, Respondent or his subcontractors added another 2 1/2 to 3 feet of fill, at least to the southern end of site of the pool and decking. It is at this point that the land begins to slope most steeply toward the marsh in the back. Neither Respondent nor any of his subcontractors conducted any soil tests prior to commencing construction or compressed or compacted the soil beneath the pool prior to installing the shell. This omission constitutes a departure from sound contracting practices under the facts cf this case. Respondent constructed several pilasters under the southern end of the deck, but these structural supports were designed to support the deck, not the pool. In general, the depth of the excavation had to exceed the depth of the pool by one foot in order to accommodate the shell. Thus, the extreme southern end of the shell required a hole only about four feet deep. An excavation of this depth did not exceed the combined depth of the old and new fill. There is no indication that Respondent or his subcontractors encountered muck during the excavation or construction of the pool. Likewise, there is no indication that Respondent or any of subcontractors was aware that mucky, unstable soils underlaid the location of the pool, especially the southern end. The pool was completed to the initial satisfaction of the Bursons. However, within 90 days of completion, the southern half of the shell developed five or six major cracks as a result of the settlement of the southern end of the pool. This portion of the pool settled because the underlying muck had been compressed by the weight of the shell and water. Gradually, the water loss from the settlement cracks, which were mostly below the waterline, became significant. At Respondent's suggestion, the Bursons agreed to wait through the winter before commencing repairs in order to allow the cracking to stabilize. In the spring of 1987, the Bursons drained the pool at Respondent's direction. Respondent then scored the cracks with a screwdriver and applied a filling compound in order to seal any leaks. As directed by Respondent, the Bursons then refilled the pool, but before more than two feet of water had been added, the filling compound fell out of the cracks. When the Bursons informed Respondent of the failure of the repair, he responded that he had performed under the contract and had no further obligation. The Bursons exercised their right to arbitrate, as provided in the contract. The arbitrators conducted a limited investigation. Expressly noting that they were not soil engineers and thus could not determine why the soil under the pool failed to support the shell, the arbitrators determined that the contractor was not responsible for any damage to the pool, "which was built to industry standards." The Bursons next contacted various pool contractors about repair options. Most of the contractors suggested a V-cut about 2 1/2 inches deep followed by the injection of hydraulic cement. When the Bursbns informed Respondent that this type of repair appeared necessary, he refused to undertake such work. By this time, one of the contractors documented that five of the cracks, which ranged from 1/16" to 1/4" wide, were pulling water out of the pool at a rate of 1-3" daily. This contractor charged the Bursons $125 for his services. After contacting the Seminole County Building Department, the Bursons learned that the pool had never passed a final inspection. When they had an inspector visit the site on September 13, 1991, he failed the job due to, among ether things, "massive deck cracks." At the insistence of Seminole County officials, the Bursons obtained expert opinions as to the cause of the cracks in preparation for the local hearing on the Bursons' charges against Respondent. In July, 1990, the American Testing Laboratories, Inc. conducted tests and opined that the south end of the pool had settled due to muck at a level of five feet below the bottom of the shell. Additional testing found muck at depths of 3-7 feet at two points just east of the south end of the pool. These tests cost the Bursons $498. When the Seminole County officials insisted upon further testing, the Bursons hired Jammal & Associates, Inc., which performed soil borings on August 23, 1990. The boring sites were just east of a point about midway along the southern half of the pool and a point just south of the southern end of the pool. The latter boring site revealed muck after penetrating about six feet of fill. At the request of Respondent, a Jammal employee returned to the site on November 13, 1990, to determine the potential cause of the cracking of the pool shell and deck. Jammal concluded that the cracking is the result of consolidation of the highly compressible peat layer found in the [southern] boring. Based upon the [cracking] observed, we suspect the southern 1/3 or so of the pool and deck area are underlain by the buried peat layer. The remainder of the pool and deck are most likely underlain by sandy soils. Because of the nature of the buried organic soils, the pool and deck will probably continue to settle at a diminishing rate for several years. Addition of new loads such as placement of additional fill around the pool and deck area, or a significant drop in the groundwater table could cause additional and accelerated settlement of the pool and deck. Jammal offered three repair options. The first was to patch the cracks. Jammal assumed that, although continued cracking could be expected, it would occur at a lesser rate because most of the settlement of the buried muck had already taken place. The second option was to remove the pool and then remove the underlying muck. The third option was to install inside the shell a fiberglass liner. The last option had been first suggested by Respondent. If not rigidly attached to the shell, the liner probably would not reflect further cracking of the shell. The Bursons paid Jammal the sum of $300 for its services. Ultimately, the Bursons decided to install a fiberglass liner and entered into a contract on November 19, 1990, with Fibre Tech for the work. The total cost of the project was $5415. This cost excludes the cost of replacing a pool vacuum for which Respondent does not appear responsible. The liner was later installed, and the Bursons paid the contract price. In the meantime, at a meeting on October 16, 1990, the Seminole County Swimming Pool Contractor's Board revoked Respondent's County certificate of competency until he repaired the pool or made restitution to the owners. This action was based upon a violation of Seminole County Code Section 40.151 and 40.34(2) and (9). Section 40.151 provides that "[a]11 completed pools shall be absolutely watertight." Section 40.34(a) allows the Board to revoke a certificate of competency if the contractor: (2) Continue[s] performance of building work in a negligent, incompetent or unworkmanlike manner. (9) Violate[s] any provision of this Chapter. The determination of the Seminole County Swimming Pool Board became final when Respondent failed to take a timely appeal of the order.
Recommendation Based on the foregoing, it is hereby RECOMMENDED that the Construction Industry Licensing Board enter a final order imposing an administrative fine of $2500 and suspending Respondent's license until he makes restitution to the Bursons in the amount of $6338. ENTERED this 29th day of October, 1991, in Tallahassee, Florida. ROBERT E. MEALE Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, FL 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 29th day of October, 1991. COPIES FURNISHED: Jack McCray, General Counsel Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Daniel O'Brien Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, FL 32202 Craig M. Dickinson, Senior Attorney Department of Professional Regulation 1940 North Monroe Street Tallahassee, FL 32399-0792 Merwin C. Carter, pro se 611 Ensenada Avenue Orlando, FL 32825
The Issue Whether or not the Respondent's activity and conduct in the performance and completion of several construction projects constitute unreasonable or dilatory practices and also whether Respondent's workmanship on such projects was of such an inferior quality that it would indicate proof and continued evidence of gross negligence or misconduct by Respondent in the practice of contracting within the meaning of Chapter 489.129(1)(m), Florida Statutes (1979). 2/ Based upon my observation of the witnesses and their demeanor while testifying, the arguments of counsel, the memoranda submitted, and the entire record compiled herein, I hereby make the following:
Findings Of Fact By its Administrative Complaint signed April 27, 1981, Petitioner, Florida Construction Industry Licensing Board, seeks to revoke Respondent's license to practice the profession of contracting and to impose a civil penalty based on conduct set forth hereinafter. Respondent, Charles H. Bromley, is a certified pool contractor holding License No. CP-007871 (Petitioner's Composite Exhibit No. 1). During times material to the allegations of the Administrative Complaint herein, Respondent was a qualifying agent, pursuant to Section 489.119, Florida Statutes, for both Wands Construction Company, Inc., and for Magic Wands Pools, Inc. Respondent's testimony established that he was part owner of Wands Construction Company, Inc., was an officer of that company and deemed himself responsible for its activities. Respondent testified that he owned no stock in the predecessor company, Magic Wands Pools, Inc., nor was he an officer of that corporation and was not directly responsible for contracts undertaken by that company. Respondent's position is that at least two of these construction projects (Derfler and Dubovick) were projects undertaken by Magic Wands Pools, Inc., and completed by Respondent, doing business as, Wands Construction Company, Inc., inasmuch as Magic Wands Pools closed its doors in late 1979. Wands Construction Company, Inc., entered into a contract with Mariner Village, Inc., to construct a pool at a condominium site being developed by that corporation. The contract was dated September 6, 1979, and called for completion of the pool within six weeks from the date of issuance of a permit. The permit for pool construction was issued on November 6, 1979. Respondent was unable to complete construction of the pool at Mariner Village, inasmuch as problems developed after the pool was filled which caused the pool walls and decking to crack and leak. Respondent attempted to correct the deficiencies in the pool until approximately August of 1980, at which time he was ordered off the job by Mariner Village, Inc. Robert Hamilton, the developer and president of Mariner Village, was the person with whom Respondent negotiated the contract to build the pool for Mariner Village. During the course of time in which Respondent was attempting to correct the problems at Mariner Village, its president, Robert Hamilton, sent approximately six mailgrams to Petitioner reciting his contention that Mariner Village considered Respondent's actions to be a breach of its contract; that the pool was not completed in a professional-like manner and that Respondent's overall performance, or lack thereof, constituted negligence. (Petitioner's Composite Exhibits 3 and 4.) When Respondent completed the construction phase of the pool, neither the city nor the county would issue a certificate of occupancy to allow the residents of Mariner Village to use the pool. While it was noted that the county initially issued Respondent a certificate of occupancy for its construction of this pool site, that certificate was immediately revoked due to surface cracks in the pool on the north, east and west ends of the pool once it was filled to capacity. Robert Hamilton, president of Mariner Village, testified that at this time (during the hearing) he thought that the issuance of a certificate of occupancy was imminent and that while the price called for in the contract between Respondent and Mariner Village was $20,450.00, it (Mariner Village) had expended or was obligated to expend sums totaling $70,000.00 to complete the pool. Mr. Hamilton ordered two engineering studies to examine and report on performance in the Respondent's construction of the pool. According to Hamilton, the reports revealed that the pool was erected on "good" pilings. Respondent and Leslie Derfler entered into a contract on June 9, 1978, to construct a pool at his residence. The contract price was paid in full and the pool was completed, however, during the spring of 1979, Mr. Derfler detected an opening around the tile grout near the leaf-skimmer. The matter was immediately called to Respondent's attention. Failing to get a prompt response to his complaint, Mr. Derfler contacted the Better Business Bureau after which Mr. Derfler was able to communicate with Respondent during March of 1980. Respondent dispatched a repairman to regrout the tiles in the area around the leaf-skimmer, however, the repairman failed to regrout the tiles which he replaced. As a result, the door of the skimmer became inoperative and separated from the skimmer. Repeated attempts by Mr. Derfler to contact Respondent were unavailing and Mr. Derfler called another company (Boca Pool-Trol Laboratories, Inc.) to finish the necessary work. In this regard, evidence reveals that Respondent reimbursed Mr. Derfler for the monies paid to the Boca Pool-Trol Laboratories, Inc. Respondent and Lindberg Development Company, through its assistant project manager, Taisto Pistkan, entered a contract on January 31, 1980, for the installation of a commercial swimming pool at Shore Heights Condominiums in Lantana, South Palm Beach, Florida. Respondent commenced construction on the pool during August, 1980, and the pool was not completed, such that it could be used, until June, 1981. Mr. Pistkan had to make repeated requests of Respondent to correct numerous problems, including leaks, falling plaster and tiles. When Respondent initially completed construction of the pool and it was filled, during September, 1980, leaks surfaced and approximately nine months later (June, 1981) Respondent completed construction of the pool and a certificate of occupancy was issued. In this regard, Respondent admitted during the hearing that it took an inordinate amount of time to make the necessary repairs to get the Lindberg pool certified. On August 10, 1979, Mr. and Mrs. Melvin Dubovick entered into a contract with Magic Wands Pools to construct a pool at their residence in Delray Beach, Florida. This contract called for the completion of the pool within six weeks from the date that the permit was issued. In October of 1979, an agent of Wands Construction, which agent had previously been an agent of Magic Wands Pools, informed Mr. Dubovick that he would have to enter into a new contract due to a reorganization of the pool company. As a result of that advice, the Dubovicks and Respondent entered into another contract with Wands Construction Company, Inc., on October 25, 1979. (Petitioner's Exhibits 10 and 11.) According to Mr. Dubovick, the second contract was signed to "straighten out the paper work." Mr. Dubovick was advised that all of the material terms of the new contract would remain unchanged and that the work would be completed within approximately eight weeks. However, the contract with Wands Construction Company does not contain a completion date. Excavation for the pool was made during the middle of October, 1979. Thereafter, no further work was done during that year and the wooden deck of the Dubovicks' home, which was adjacent to the hole dug for the pool, collapsed on New Years Eve, 1979. Thereafter, there were a number of problems with the construction of the pool, including the fact that a spa was not built as called for in the plans for the pool which necessitated that the Respondent remove a portion of poured gunite around the pool's deck; the filter was improperly installed and leaks surfaced when the pool was filled, causing Respondent to place numerous patches and filter outlets in the pool. Additionally, the slope of the pool decking was improper and caused a flooding condition around the Dubovicks' patio. The dimensions of the pool were not completed according to plans in that the length of the pool as completed is 30 feet, 3 inches, whereas the plans called for the pool to be 34 feet in length. The contract provides that the pool would have a 15,000 gallon capacity whereas Mr. Dubovick contends that he has never been able to measure more than a 10,000 gallon capacity while he filled the pool. The pool was completed in July of 1980. Kim Parker, a certified pool contractor, testified on behalf of Petitioner concerning two of the projects complained of in the Administrative Complaint. Consultant Parker is a licensed pool contractor and has been certified approximately two years. He is presently the general manager for Almar Pools. Mr. Parker has supervised pool construction in excess of two years. Mr. Parker visited the Mariner Village project on August 28, 1981, and noted hairline cracks in the plaster around the pool. Those cracks indicated to him that the plaster was either improperly applied or cured. He also noted a return fitting protruding into the pool, which he considered to he evidence of "shoddy" workmanship. Mr. Parker also noticed that the pumps in the pump room were not installed in a "professional" manner. During this time period, Mr. Parker also visited the Dubovicks' residence and he noted that an air leak existed at the filter pump, which caused a loud noise and that the pool was situated approximately three inches above the patio which created a drainage problem. In this regard, the Dubovicks testified that two doors were ruined due to water drainage problems around the pool area. Mr. Parker considered the workmanship around the Dubovick pool to be professional in its appearance although he did note that the pool was not constructed to the measurements provided for in the contract. Respondent's Defense Respondent, Charles Bromley, qualified Magic Wands Pools during 1978. He did so, according to him, based on "bad legal advice." Respondent encountered numerous problems completing pools that were under construction for Magic Wands Pools while he also was handling the day-to-day affairs of the successor corporation. Respondent has completed all except two out of forty-two pools that remained incomplete when he took over and Magic Wands Pools ceased operations in late 1979. Respondent contends that the former owner dumped "problem" pools on him which included the Mariner Village pool. William Sheldon, a professional engineer who has acted as a consultant in the design of numerous pools (in excess of 1,000) was called as a witness to testify on behalf of Respondent. Mr. Sheldon visited the Mariner Village pool and studied the design. He concluded that inadequate pilings were the source of the problems with the Mariner Village pool. That is, he considered the pilings failed to give adequate support and that this was of no fault or could not result in any liability on Respondent's part, inasmuch as the pool contractor was not responsible for the pilings erected to provide support for the pool. Mr. Sheldon noted that the pilings were driven to substantially less depth than other short piles in the area which led him to conclude that the developers used "soft" piles which had a low-blow content. He concluded that this caused cracks to radiate out of the east end of the pool creating leaks. Mr. Sheldon's examination of the elevations around the pool indicated that the gutters were level; that the problem was therefore one relating to the pool's substructure and not due to any construction deficiency. Also, Mr. Sheldon noted that, based on his calculations, without the usual allowance in calculations for an approximate ten percent (10 percent) deviation in a pool's volume capacity, his calculations indicated that the pool would hold approximately 11,872 gallons whereas the plans called for an approximate gallonage capacity of 10,500 to 11,000 gallons. Finally, Mr. Sheldon indicated that his review of the pool construction at Mariner Village only indicated that there existed one extrusion which he considered not to be critical in view of the overall construction and the pool's layout. Respondent testified that construction at Mariner Village progressed at a reasonable pace indicating that on May 8, 1980, the pool was marble coated, however, the equipment was not completed in the pool room and therefore work could not proceed as scheduled. According to Respondent, the earliest time that the equipment was in place, by other subcontractors, was approximately August 18, 1980, and work commenced rapidly thereafter by Respondent's employees. Respondent testified that an engineer inspected the gutters on July 16, 1980, at which time the gutters were properly erected and that within four days, i.e., on July 20, 1980, the gutters were "low" and the tiles had sunk. Respondent replaced the gutters without cost, however, he refused to do further work on the pool until the substructure was solidified. During this period, Respondent also testified that Mariner Village failed to timely honor draw payment requests which forced him to stop work until funds were received according to the schedule for draws. Finally, Respondent testified that the pilings and related substructures were obligations contracted for and hired independently by the general contractor. For this reason, the Respondent offers that he was not obligated for the failures surrounding the pool at Mariner Village. Respondent admits that the Dubovick project caused problems in that it was one that was left from the predecessor entity, Magic Wands Pools. He admits to delays in construction, however, he testified that he labored as faithfully as he could under the circumstances and further that all corrections and/or repairs were made that were called to his attention. As to the contention that the pool was constructed smaller than the 15,000 gallon volume capacity as reflected in the plans and specifications, Respondent indicates that the 15,000 gallon capacity was an error and further that the Dubovicks never indicated to him that there was any discrepancy or deviations from requirements in the plans and specifications as he was required to do according to the terms of the contract. Respondent indicates a willingness to negotiate with the Dubovicks respecting this omission. Finally, Respondent testified that he never met the Derflers, although he did dispatch a repairman out to remedy their problem. Respondent considered that the problem had been resolved and was unaware that it had not until the subject complaints were filed. Respondent has, however, refunded the Derflers' monies which were expended to hire an outside contractor. Throughout the time in which Respondent was attempting to complete or correct projects which had been started or initiated by Magic Wands Pools, he labored to do so with as much dispatch as possible under the circumstances. Respondent indicates that money was due and owing Magic Wands Pools by many customers who refused or was slow to pay. Respondent has been in the pool construction business in excess of twenty years and based on the experience gained and the nature of that business he (Respondent) refuses to guarantee a completion date for a pool due to weather and other uncertainties beyond his control. He again acknowledged that the repairs took a great deal of time to complete, however, he stressed that he labored to perform those repairs in as much dispatch as possible under the circumstances. Concluding, Respondent offered that part of his problem with the Dubovick pool had to do with his attempt to stay within the setback lines of the Dubovicks' property which prompted him to make minor deviations from the plans and specifications.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is hereby RECOMMENDED: That the Respondent, who holds certified pool contractors License No. CP- 007871, be placed on probation by Petitioner for a period of one year. RECOMMENDED this 26th day of January, 1982, in Tallahassee, Florida. JAMES E. BRADWELL, Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32301 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 26th day of January, 1982.
