The Issue The issue is whether respondent's license as a registered roofing contractor should be disciplined for the reasons set forth in the administrative complaint.
Findings Of Fact Based upon the entire record, the following findings of fact are determined: At all times relevant hereto, respondent, Raymond D. Simmons, was licensed as a registered roofing contractor having been issued license number RC 0055320 by petitioner, Department of Professional Regulation, Construction Industry Licensing Board (Board). He has been licensed as a roofing contractor since November 1987. The Board's official records reflect that on July 1, 1991, the license was placed on the delinquent status for non-renewal and is now considered "invalid." 1/ When the events herein occurred, respondent was the qualifying agent for Simmons and Sons Plumbing and Roofing, Route 1, Box 191 (County Road 225), Waldo, Florida. Except for this action, there is no evidence that respondent has ever been disciplined by the Board. On May 3, 1988, respondent submitted a proposal to Charles and Thea Ansman to repair the roof on their home located at 5132 N. W. 29th Street, Gainesville, Florida. With minor modifications, the proposal was accepted by the Ansmans on May 10, 1988. According to the agreement, respondent was to perform the following services: Tear off old shingles dry-in with 15 lb. felt and replace with Corning Owens 20 year fungus resistant shingles. Replace all plumbing stacks and ease drips. Will replace back porch with 3-ply build-up roof will coat it with roof coating 10 year warranty on workmanship 20 year manufactor [sic] on shingles and build-up roof. Will replace all wood that needs to be replaced. Although the agreement does not specifically refer to ridge vents, the parties also agreed that respondent would install a ridge vent on the home. On May 16, 1988, respondent made application for a building permit from the City of Gainesville to "reroof" the Ansman's home. The permit was issued on May 20, 1988, in the name of Simmons & Sons Plumbing and Roofing. Respondent commenced work on the project on May 16 and continued the work over a period of several days. During this period of time, respondent was frequently on the job site overseeing the work. Indeed, Thea Ansman said respondent was at her home approximately half of the time while the repairs were being made. Thus, while respondent undoubtedly supervised the job, for the reasons stated in findings of fact 6 and 7, he nonetheless failed to "properly" supervise the work. On May 20, 1988, Thea Ansman paid respondent in full for the work. Although the job was not finished, respondent told Mrs. Ansman he would return the next day to complete the work. When respondent failed to return, the Ansmans repeatedly telephoned him during the next few months, but respondent either refused to speak with the Ansmans or told them he would return within a few days. However, the work was never finished and respondent never returned to the job site. While inspecting the roof one day, Charles Ansman noted that the roof trusses, an intregal part of the load bearing capacity of the structure, were cut at their peaks. The depth of the cuts was between one and two inches and was apparently the result of a saw-blade not set at the proper height when the ridge vent was installed. Sometime in July or August 1988 Charles Ansman discussed the damage with respondent and requested that respondent repair the same. Respondent refused to do so on the ground he was not responsible for the damage. Ansman then filed a complaint with the City of Gainesville Building Department. On September 9, 1988, a city building inspector inspected the home and confirmed that virtually every truss was cut and that the integrity of the roof was in jeopardy. He also observed that the soffits were improperly installed in some cases, and in others, were missing altogether. A notice of violation was then issued by the city on October 3, 1988, charging respondent with violating the Standard Building Code in two respects. More specifically, it was charged that respondent's workmanship violated sections 1701.1.1 and 1708.2.1 of the 1985 Standard Building Code, as amended through 1987. These sections pertain to the quality and design of wood trusses and the design of trussed rafters, respectively. At a hearing before the city's Trade Qualifying Board, respondent admitted his workers had violated the cited sections and caused the damage to the trusses. However, respondent denied liability on the theory that the workers, and not he personally, had negligently damaged the house. Respondent was thereafter issued a letter of reprimand for his actions. In order to recover their damages, which included the replacement of all damaged trusses, the Ansmans filed suit against respondent in Alachua County small claims court. On April 18, 1989, they received a judgment in the amount of $1,050. The judgment was eventually satisfied but only after the Ansmans threatened to levy on respondent's real property located in Alachua County. In preparation for the suit, the Ansmans obtained an engineering report which corroborates the findings made by the city building inspector concerning the damage and negligence on the part of respondent's work crew. By allowing the work to be performed in that manner, respondent was incompetent and committed misconduct in his practice of contracting. However, there is no evidence that respondent was grossly negligent during his supervision of the job. Respondent did not appear at hearing. However, prior to hearing he spoke to the city building inspector and acknowledged that the roof trusses were damaged as the result of negligence on the part of his crew. He also admitted this during the final hearing on the small claims action. At the same time, he denied that his workers had ever touched the soffits. This assertion, however, is rejected as not being credible.
Recommendation Based upon the foregoing findings of facts and conclusions of law, it is, recommended that respondent be found guilty of violating Subsection 489.129(1)(m), Florida Statutes (1987), and that he pay a $1000 fine and his license be suspended for one year. RECOMMENDED this 16th day of December, 1991, in Tallahassee, Florida. DONALD R. ALEXANDER Hearing Officer Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 16th day of December, 1991.
The Issue Whether the Respondent's license as a registered general contractor should be disciplined?
Findings Of Fact The Respondent is a registered general contractor in the State of Florida. His license is number RG 0001015. At all times material to this case, the Respondent has held license number RG 0001015. The Respondent has been in the construction business for 51 to 52 years. During the Fall of 1985, Mr. Edward J. Ashley discussed a construction project at Mr. and Mrs. Ashley's residence with the Respondent. The Ashley's residence is located at 2353 Hampshire Way, Tallahassee, Florida. The Ashleys and the Respondent, on behalf of Big Bend Builders Corp., Inc., agreed on the construction work to be performed and the price to be paid for the work. The agreement was memorialized on October 7, 1985, (hereinafter referred to as the "Proposal"), by the Respondent and presented to the Ashleys. Pursuant to the agreement between the Ashleys and the Respondent, Big Bend Builders Corp., Inc., was to construct a room addition to be used as a porch in the back of the existing residence, extend a master bedroom and bathroom, replace the tile in the bathroom, remove a partition between the kitchen and the living room and replace the existing roof with fiberglass shingles with a 20-year warranty. The Ashleys agreed to pay the Respondent's corporation $28,300.00 in consideration of the work to be performed. The Proposal presented to the Ashleys by the Respondent was never signed by the Ashleys but they did agree verbally to the work to be performed. The Ashleys and the Respondent agreed verbally that the construction price would be paid in two installments. One installment was to be made when half the construction was completed and the other half was to be paid when the construction was completed. The Ashleys made the first payment on December 5, 1985. The payment was for $14,000.00. Although the project was not completed, the Ashley's made a partial payment of $6,000.00 on January 10, 1986. The second payment was made earlier than agreed upon at the request of the Respondent. The Respondent told the Ashleys that the payment was needed so that the project, which was already late, could be completed. The Ashleys and the Respondent agreed verbally that the construction would be completed by December 15, 1985. Construction began at the Ashleys on November 14, 1985. On November 22, 1985, the concrete slab for the addition to the Ashley's home was poured in the morning. That afternoon a hurricane struck and rain associated with the hurricane washed away the top layer of concrete. The loss of the top layer of concrete caused the slab to be rough and uneven. It was especially unsightly in the area where the new room was being added as a porch. The Ashleys planned to leave this area uncovered. When they complained to the Respondent he told them not to worry, that he would take care of it. It was not repaired, however. The slab was also uneven in the bathroom and approximately 1 and 1/2 inches higher than the existing slab in the master bedroom. These problems were also not corrected. The area where the new slab joined the existing slab in the master bedroom was ground down but a bump still remains. The trusses of the addition to the residence were higher than the existing trusses. Although some of the problems associated with this problem were corrected, there remains a bump on the roof of the addition. The wall between the bathroom and the master bedroom did not match the existing wall. This problem was not corrected and is still visible. The Respondent filed an application for a building permit with the City of Tallahassee on November 12, 1985. The permit was issued on November 13, 1985. The Respondent was required to arrange slab, framing, and insulation inspections and a final inspection of the construction at the Ashley's residence. The Respondent had the slab inspection completed on November 19, 1985. The framing inspection was conducted on December 11, 1985, by Mr. Rackley. The construction did not pass this inspection because there was no "header" over one door and the ceiling joists were not adequately attached. It was the Respondent's responsibility to correct the problems found as a result of the framing inspection before proceeding with construction. The fact that the construction failed the framing inspection was noted on the copy of the building permit which is displayed at the construction site. Ms. Ashley was the only person present during the inspection other than the inspector. On December 17, 1985, Mr. Rackley saw the Respondent at a party and mentioned the door header and the failure of the residence to pass the framing inspection. The ceiling joists were not mentioned. At the time the framing inspection was completed, the construction was 40 to 50 percent complete. By letter dated February 12, 1986, Mr. Rackley asked the Respondent why the Respondent had not requested a re-inspection. The Respondent proceeded with construction without passing a framing inspection. Therefore, in the February 12, 1986 letter from Mr. Rackley the Respondent was directed to uncover the areas which had failed the inspection so that they could be re-inspected. The Respondent did not respond to Mr. Rackley's letter of February 12, 1986. Therefore, on February 24, 1986, the Respondent was contacted by Mr. Rackley by telephone. The Respondent agreed to open the areas necessary to complete the framing inspection. On February 26, 1986, the framing inspection was completed. An opening had to be cut in the existing roof for the inspection to be completed. The Respondent did not fail to arrange a re-inspection of the property in order to hide anything or cover-up improper work. The construction passed the insulation inspection. No final inspection of the construction has ever been requested or completed. As a part of the Respondent's agreement with the Ashleys, the Respondent was to remove the roof on the existing structure and cover it and the new roof with fiberglass shingles with a 20-year life. The shingles used by the Respondent were Temko shingles. Manufacturers of roofing materials generally recommend how to apply their products in writing. Therefore, Temko included instructions for the application of the shingles used by the Respondent. The instructions were written on the paper used to wrap the bundles of shingles. In order for the manufacturer's guarantee of the Temko shingles to be effective, the shingles must be installed according to the manufacturer's instructions. The Southern Building Code, which applies in Leon County, also requires that manufacturer's instructions be complied with. The following pertinent instruction, among others, was included with the shingles used on the Ashley's residence: LOW SLOPE APPLICATION: On pitches of 2" per foot to 4" per foot, provide a double underlayment of asphalt saturated felt by applying a 19" wide felt strip along the eaves and over this apply a full 36" wide sheet. Continue with full 36" wide sheets, lapping each 19" over the preceding course. If winter temperatures average 25 F or less, thoroughly cement the felt to each other with Temko plastic cement from eaves and rakes to a point a [sic] least 24" inside the inside wall line of the building. This instruction is consistent with roofing industry standards. The roof of the Ashley's residence pitches at 2" to 2 1/2" per foot. Therefore, the Respondent should have applied two layers of felt to the roof as specified in the "Low Slope Application" instruction. The Respondent's crew, however, only applied one layer of felt to the Ashley's roof. The instructions for the shingles also specified that each shingle be attached with four nails placed in a particular pattern. The Respondent's crew did not follow these instructions. Along the edges of the roof, the felt should have been cemented to the roof. It was not, however. Shingles placed in the valleys on the roof were not attached in any manner to the roof. The manner in which the roof was installed was incompetent. After the roof was placed on the Ashley's residence, water leaked in at several locations. The Respondent did not return the Ashley's telephone call. One of the Respondent's work crew when informed about the leaks told Mr. Ashley that the roof was not leaking; that it was blowing in from outside. Some of the problems with the roof were corrected by the Respondent. They were corrected, however, only after a building inspector was called in by the Ashleys. Even then, the leaks did not stop. The Ashleys subsequently paid another contractor $560.00 to correct problems with the roof. Throughout the period of time that the Respondent's crew worked at the Ashley's residence, whenever a problem arose, the Ashleys would be told not to worry about the problem; that it would be taken care of. Many of the problems, however, were not taken care of by the Respondent. Throughout the period of time that work was being performed at the Ashley's residence, there were numerous times when no one would perform any work at the Ashley's. Weeks would often go by without the Ashley's seeing the Respondent and without the Respondent's presence at the Ashley's. During the period that work was being performed at the Ashley's residence, there was a great deal of rain and the temperature dropped below 40 degrees. These weather conditions slowed progress on completing the job. These weather condition were not unique, however, and the Respondent admitted that he knew it rains and gets cold often during the period of time involved in this proceeding. One weather problem that the Respondent could not have reasonably foreseen was the hurricane which struck Tallahassee on November 22, 1985. As a result of damage to property caused by the hurricane, roofing and other materials were more difficult to obtain. Rain associated with the hurricane washed away the top layer of the concrete from the slab that was poured the day the hurricane struck. The Respondent checked with the weather service that morning. Based upon the projected weather, the hurricane was headed away from Tallahassee and rain was not expected until that afternoon. The concrete was poured in the morning and would have been dry before the afternoon. The weather forecast was incorrect, however, and the rain struck earlier than expected. After work had commenced on the Ashley's residence, the agreement was modified. The Respondent indicated that he could not do the tile work in the bathroom. Therefore, the agreed upon price for the project was reduced by $2,000.00. The Ashleys also had the Respondent perform other work not originally agreed upon; 2 skylights and a door were added and additional brick work was performed. These changes caused some delay in completion of the project. The evidence did not prove, however, that all of the delay was attributable to the changes in the work to be performed. Much of the delay was caused by the fact that the Respondent's crew simply did not show up to work at the Ashley's residence. The delays in completing construction at the Ashley's residence were on the whole not reasonable. Although days were lost because of weather conditions, including the hurricane, and changes in the work to be performed, the days that no work was performed were not reasonable or caused by these factors. The Respondent failed to properly supervise the work performed at the Ashley's residence. Although the Respondent indicated that he relied upon the men who worked for him, he was ultimately responsible for the proper completion of the project. The project was not completed and some of the work performed was not performed in a satisfactory manner. The Respondent was not allowed to complete the project. The Ashleys eventually got so fed up with the Respondent's failure to correct problems and to complete the project that they would not allow the Respondents onto the property. Sometime after 1981, the Respondent received forms from the Petitioner which could be used to register his contracting license in the name of Big Bend Builders Corp., Inc. He asked his former attorney to complete the forms for him. The forms were completed and placed in the Petitioner's mail. The Respondent's license has not been registered in the name of Big Bend Builders Corp., Inc. The Respondent believed that his license was being switched to the corporate name. He knew or should have known that the change had not been completed because he did not receive a copy of a license with the corporate name. The Respondent's license had previously been held in a corporate name. The heading of the Proposal indicates that it is a proposal of "Big Bend Builders Corp., Inc." The Proposal was signed by the Respondent and was also signed "Big Bend Builders Corp., Inc. by Welton Smith." Mr. Ashley understood that the agreement he was entering into was with Big Bend Builders Corp., Inc. The two payments made by the Ashleys were made by checks. The checks were made out to Big Bend Builders Corp., Inc. The building permit on the Ashley's residence was applied for and issued in the name of Big Bend Builders Corp., Inc. Big Bend Builders Corp., Inc., was not qualified with the Petitioner.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED: That the Respondent be found guilty of violating Sections 489.129(1)(d), (g), (j) and (m) and 489.119, Florida Statutes (1985). It is further RECOMMENDED: That the Respondent be required to pay an administrative fine of $2,000.00. DONE and ENTERED this 2nd day of September, 1987, in Tallahassee, Florida. LARRY J. SARTIN Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 2nd day of September, 1987. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-2641 The parties have submitted proposed findings of fact. It has been generally noted below which proposed findings of fact have been generally accepted and the paragraph number(s) in the Recommended Order where they have been accepted, if any. Those proposed findings of fact which have been rejected and the reason for their rejection have also been noted. Petitioner's Proposed Findings of Fact Proposed Finding Paragraph Number in Recommended Order of Fact Number of Acceptance or Reason for Rejection 1 1 and 2. 2 56. 3 4. 4 5. 5-6 6. 7 7. 8 18. 9-10 18 and 61. 11-12 10. 13 39 and 41. 13 The first sentence is hereby accepted. The second sentence is not supported by the weight of the evidence. This state- ment was made to the Ashleys but in regard to the problems they had with their roof. 14 43. 15-16 44. 17 21. 18 21, 23 and 25. The building inspector informed the Respondent of the failed framing inspection on December 17, 1985, and not December 7, 1985. 19 28. 20 26. 21 33 and 34. 22 Hereby accepted. 23 37 and 38. 24-25 Hereby accepted. 26 38. 27 37. 28-29 39. 30 38-39 and 42. 31-35 Cummulative. 36-37 57. Respondent's Proposed Findings of Fact 1 Hereby accepted. 2 2. 3 28 and 29. There was no "final inspection" performed on the project. There was a final framing inspection, however, that indicated that the work that originally failed the inspection had been performed correctly. 4-7 These proposed findings of fact are not supported by the weight of the evidence. 47-48 and 50. The last sentence is not supported by the weight of the evidence. Not supported by the weight of the evidence. 10-11 Hereby accepted. 12 62. The last sentence is not supported by the weight of the evidence. COPIES FURNISHED: Fred Seely, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 Van Poole, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Joseph Sole, Esquire General Counsel Department of Professional Regulation Tallahassee, Florida 32399-0750 W. Douglas Beason, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Elwin Thrasher, Jr., Esquire 908 North Gadsden Street Tallahassee, Florida 32303
The Issue Whether respondent on several occasions aided an unlicensed contractor to engage in contracting by obtaining permits on respondent's license for contracting jobs performed by the unlicensed contractor; Whether respondent committed the statutory violations alleged; and If so, whether respondent's license should be suspended or revoked, or whether some other penalty should be imposed.
Findings Of Fact At all times material to the Administrative Complaint, respondent was a certified general contractor in Florida holding License No. CG C000572. Johnnie T. Thomas is the president of J. T. Thomas Construction Company. Mr. Thomas is not a licensed contractor in the State of Florida. Although respondent has used his license to qualify several corporations, the last being Julius Isaac & Association, Inc., respondent never qualified J. T. Thomas Construction Company. Indeed, J. T. Thomas Construction has never been qualified by any licensee. During the time period relevant to this action, J. T. Thomas Construction Company was the name used by Mr. Thomas to engage in the contracting business. On July 25, 1983, J. T. Thomas Construction Company contracted with Hazel N. Jones for the construction of a residence at 11729 Rock Hill Road, Thonotosassa, Florida, in Hillsborough County. Johnnie Thomas signed the contract on behalf of J. T. Thomas Construction Company as "President and Builder." Ms. Jones did not know that Mr. Thomas was unlicensed. James Montjoy drew the plans for the house and recommended Thomas as the builder. The total price for the house was $75,500. The house was started in September of 1983, and on January 30, 1984 final payment was made. After moving into the house, Ms. Jones discovered several problems. In June of 1984 an energy check found that the home was not properly insulated; however, this was apparently corrected in May of 1985. Ms. Jones had several other problems with the home and sent a "punch-list" to Mr. Thomas setting forth the items that needed to be corrected. Although Mr. Thomas admitted at the hearing that there were items that should have been corrected on the punch-list, he also admitted that he did not correct them because he disputed other claims of Ms. Jones. The building permit application for Ms. Jones' home was signed by the respondent. On the building permit application, the contractor was listed as Julius Isaac and Association, Inc. The building permit was issued on August 15, 1983. It listed Julius H. Isaac and Julius Isaac and Association, Inc. as the contractor. The building permit was signed by Julius H. Isaac as agent. Ms. Jones never met Mr. Isaac, never saw him and never knew that he was involved in any way in the construction of her home. In late 1984, Ms. Catherine Farragut, the owner of a building located at 1704 North Nebraska Avenue, Tampa, Florida, contracted with J. T. Thomas to have her building remodeled. Ms. Jones recommended Mr. Thomas to Ms. Farragut before Ms. Jones began to experience problems with Mr. Thomas. Ms. Farragut was not aware that Mr. Thomas was not a licensed contractor. The remodeling of the building was completed in early 1985. The permit for the interior remodeling of the offices at 1704 North Nebraska Avenue was issued on July 23, 1984 to Julius Isaac & Association. Ms. Farragut did see Isaac at the job site in the central parking area; however, Mr. Thomas never advised Ms. Farragut that respondent was involved with the project. On August 20, 1985 J. T. Thomas Construction Company contracted with Evelyn S. Williams to construct a residence at 3620 East North Bay Street, Tampa, Florida. The contract price for the home was 66,000 and payments by check were made to Johnnie Thomas in intervals. Construction on the home began in November 1985. Ms. Williams moved into the home in August of 1986. She discovered some problems with the house, and gave Mr. Thomas a list of the items that needed to be corrected. Mr. Thomas corrected all the items but one. Ms. Williams still has a problem with the roof getting moldy due to water retention. A permit was issued by the City of Tampa Building Department on November 20, 1985, for construction at 3620 East North Bay Street. The permit was issued to Julius Isaac and the contractor of record is stated as Julius Isaac d/b/a Julius Isaac & Associates. Ms. Williams never met Mr. Isaac or saw him; however, Ms. Williams did not go to the job site during construction since the mortgage company was supposed to periodically inspect the house during construction. Ms. Williams was not aware that Mr. Thomas was unlicensed. On August 28, 1986, J. T. Thomas Construction Company entered into a written contract with Ms. Verlie Nelson to construct a residence at 8105 Jad Drive for a price of $102,560. Ms. Nelson thought that Mr. Thomas was a licensed contractor. She never saw Mr. Isaac at the job site, however, she was rarely there because Sun Coast Federal Credit Union was paid to do the inspections. On October 16, 1986, respondent applied for a building permit for 8105 Jad Drive. John and Augusta Thomas were listed as the owners and Julius Isaac & Association, Inc., was listed as the general contractor for the project. On November 7, 1986, the permit was issued by the Hillsborough County Building Department. Julius H. Isaac was listed as the applicant and contractor. John and Augusta Thomas were listed as the owners of the property at 8105 Jad Drive. Mr. Thomas admitted that J. T. Thomas Construction Company built the homes for Ms. Jones, Ms. Nelson and Ms. Williams, and did the renovation on the building owned by Ms. Farragut. Mr. Thomas received the payments for the projects, hired and paid the subcontractors and supervised construction. He also managed the daily affairs of J. T. Thomas Construction Company. J. T. Thomas Construction Company was formed in 1971 under the name Thomas (J. T.) Construction Company. However, the company, as a corporate entity, was dissolved by proclamation in 1973. J. T. Thomas' brother Leslie was the secretary of the corporation and a licensed contractor. He obtained the building permits for the company until be became ill. Thereafter, respondent obtained the building permits for J. T. Thomas Construction Company. Respondent knew that Mr. Thomas was not licensed and could not get the permits himself. Respondent is not a salaried employee of J. T. Thomas Construction Company, and he received no compensation for his services although he was reimbursed for the actual cost of obtaining the permits. Other than obtaining the permits, respondent's only connection with Mr. Thomas' construction projects was to visit job sites before inspections or go to a site if Mr. Thomas asked for his help with a construction problem. However, there was no competent evidence establishing that respondent ever went to the particular job sites involved in this case. Respondent had no responsibilities in connection with the projects and had no authority to take any actions. In essence, respondent was simply "helping" a long time friend. Respondent has been licensed since 1968, and there was no evidence presented of any prior violations or any prior complaints.
Recommendation Based on the foregoing findings of fact and conclusions of law, it is RECOMMENDED that the Construction Industry Licensing Board enter a final order finding respondent guilty of the act set forth in Section 489.129(e), Florida Statutes, and imposing an administrative fine of $1,500. DONE AND ENTERED this 27th day of May, 1988, in Tallahassee, Florida. DIANE A. GRUBBS Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 27th day of May, 1988. APPENDIX TO RECOMMENDED ORDER, CASE NO. 87-5586 Rulings on petitioner's proposed findings of fact by paragraph: 1-8 Accepted generally. COPIES FURNISHED: David L. Swanson, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32399-0750 Julius H. Isaac 421 Ella Mae Avenue Tampa, Florida 33602 Fred Seely Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32201 William O'Neil Stephen F. Hanlon, Esquire General Counsel BARNETT, BOLT & KIRKWOOD Department of Professional Post Office Box 3287 Regulation 100 Twiggs Street 130 North Monroe Street Sixth Floor Tallahassee, Florida 32399-0750 Tampa, Florida 33602
Findings Of Fact At all times relevant hereto Jonas C. Merricks, Respondent, was licensed by the Construction Industry Licensing Board, Petitioner, as a residential building contractor. In May 1981 Respondent was approached by John Oden regarding a building permit to add a room to the residence of Ms. Betty J. Wilson. Respondent testified he went to see Ms. Wilson to discuss the permit before pulling the permit; however, Ms. Wilson testified she did not see Respondent until after the word started. Regardless of the correct version Respondent pulled the permit for the construction knowing that he was not going to do the work. On May 23, 1981 Ms. Wilson entered into a contract with John Oden to construct an additional room on her residence. This contract was modified on May 26, 1981 to enlarge the room two feet and it is this contract (Exhibit 3), upon which the work was done. The contract made no mention of Respondent or of J & J Building Company which is owned by Respondent. Under the terms of the contract Ms. Wilson was to pay Oden one-third when walls were up, one-third when the roof was on and the final one-third when the job was completed. During the course of the construction Respondent appeared on the site a few times and straightened out existing problems. Ms. Wilson made all of her payments to Oden in accordance with the contract. However, she made the final payment before the work was completed. Her attempts to get Oden to satisfactorily complete the job were unsuccessful and Ms. Wilson complained to the Bureau of Consumer Affairs who referred her complaint to the Construction Industry Licensing Board which investigated and filed the complaint here under consideration. No evidence was submitted that Respondent pulled permits for work done by J & J Building Company. Evidence was presented that J & J Building Company is not licensed by petitioner. Respondent testified that he pulled the permit as a favor to Ms. Wilson and not for Oden, and that he did not know Oden had contracted with Ms. Wilson to do this job. However, Respondent did know that Oden was going to build the addition for Ms. Wilson; and, in his affidavit, Exhibit 5, Respondent acknowledged he had "helped out" Oden several times, that he was paid by Oden for work Respondent did on the premises, that payment for this work was made out to J & J Building Company, and that he supervised the work when he was on the premises.
