Findings Of Fact At all times material hereto, Respondent has been a registered residential contractor having been issued license number RR 0040275. In approximately 1980, Respondent entered into a contract to erect a screen room for a Mr. Lewis. Under the terms of the contract, Respondent was to obtain the necessary building permit. After the contract had been signed, Respondent's grandfather died, and Respondent therefore went to New Jersey. He left the permit application with his qualifying agent to sign and process through the building department. When Respondent returned from New Jersey approximately 30 to 35 days later, he went to the Lewis job site and found the project almost completed. Respondent did not check to ascertain if the permit had been obtained, but rather completed the screen room himself. Lewis subsequently contacted Respondent to say that he had received a notice of violation from the building department for erecting a screen room without a permit. Respondent contacted the building department and advised that it was not Lewis's fault, but rather that it was Respondent's responsibility to pull the permit. Respondent was charged with unlawfully erecting a screen room without a permit; he appeared in court and pled guilty; and he paid a $250 fine pursuant to the adjudication of guilt entered on April 20, 1981, in the County Court in and for Dade County, Florida, in Case No. 81-50438. On June 24, 1981, Respondent submitted to the Construction Industry Licensing Board a Contractor's Registration application. On that application, Respondent answered in the negative the following question: "Has any person named in (i) below ever been convicted of any offense in this state or elsewhere other than traffic violations?" At the time Respondent gave that answer, he believed it to be true. He understood the question to call for information on criminal acts and did not comprehend the "screen room" charge to have been criminal conduct. Since Respondent answered that question in the negative, his application for registration was processed in accordance with normal procedures. Had Respondent answered that question in the affirmative, his application would not have gone through normal processing but rather would have been presented to the Construction Industry Licensing Board for the Board's determination of whether to approve the application based upon a consideration of the facts. On November 22, 1982, Respondent contracted with Naomi Blanton to construct an addition to Blanton's home located in the City of Miami, in Dade County, Florida, for a contract price of $11,250. When Respondent had first met with Blanton several months earlier, he had told her he could guarantee completion of the project within 45 days. No contract was entered into at that time, however, since Blanton had not obtained the financing she needed in order to construct an addition. When the contract was signed on November 22, Respondent told Blanton he would start the job when he finished the Chamber of Commerce building he was con structing but that he was starting a 12-unit duplex project around Christmas and would not be able to guarantee any 45-day completion deadline. Accordingly, when the contract was signed, no completion date was included in the terms of that written contract, since Respondent did not know when he could guarantee completion. The Blanton contract written by Respondent specifically provided that Respondent would obtain the building permit. On December 22 and 23, 1982, two of Respondent's employees arrived at the Blanton job site, dug a trench, knocked down the utility room, and moved Mrs. Blanton's washing machine. No further work was done until January 1983. Since Respondent knew that he was required to obtain the building permit before commencing any construction work, Respondent submitted his plans and permit application to the City of Miami Building Department. After the plans had been there about a week, he was advised that his plans would not be accepted unless they were drawn by an architect, although that is not required by the South Florida Building Code. After attempting several more times to obtain approval from the City of Miami Building Department, Respondent hired an architect to redraw the plans and secure the building permit. By this time, Respondent found himself unable to concentrate on operating his business efficiently, since he was preoccupied with spending time with his father who was dying of cancer. Also by this time, Blanton had commenced telephone calls to Respondent on an almost daily basis as late as 11:00 p.m. at his office, at his home, at his mother's home, and at his father's home. Respondent offered to return Blanton's deposit, but she refused to cancel the contract and threatened Respondent that she would sue him if he did not comply with that contract. Respondent commenced working on the Blanton job, although no permit had yet been obtained. The contract on the Blanton job called for payments at certain stages of the construction. By January 27, 1983, Respondent had completed a sufficient amount of the work under the contract so that Blanton had paid him a total of $8,270 in accordance with the draw schedule contained in the contract. Respondent ceased working on January 27, 1983, and advised Blanton and her attorney that he would do no further work until he could obtain the building permit, which he had still not been able to obtain. Although he told them his work stoppage was due to his continued inability to obtain the permit, he also stopped work due to his father's illness and his continued inability to get along with Mrs. Blanton. A delay occurred with the plans being redrawn by the architect Respondent hired to obtain the Blanton building permit, since the architect needed information from Blanton and she was out of town. After Blanton returned, the architect made unsuccessful attempts to obtain the building permit. Respondent and his architect were finally able to speak to one of the top personnel in the City of Miami Building Department about the problems they were experiencing in obtaining a building permit, and, at about the same time, Blanton contacted that same individual to complain that Respondent had no permit. On May 4, 1983, the building department finally accepted the second permit application together with the plans drawn by the architect, and the building permit was issued on May 4, 1983. No work was performed on the Blanton job between January 27, 1983, when Blanton paid Respondent the draw to which he was entitled by that date, and May 4, 1983, when the building permit was finally issued by the City of Miami. Respondent immediately resumed work and quickly completed the next stage of construction called for under the Blanton contract. Upon completing that next stage, he requested his next draw payment; however, Blanton decided not to pay Respondent for the work completed and had her attorney advise Respondent not to return to the job site. Blanton then had a friend of her son come to Miami from Wisconsin to complete the addition to her home. At all times material hereto, Respondent held a certificate of competency issued by Metropolitan Dade County.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered finding Respondent guilty of violating Section 489.129(1)(d), Florida Statutes, by willfully and deliberately violating Section 301(a) of the South Florida Building Code; imposing an administrative fine against Respondent in the amount of $2,000 to be paid by a date certain; and dismissing the remaining charges contained in the Administrative Complaint, as amended, against Respondent. DONE and RECOMMENDED this 13th day of April, 1984, in Tallahassee, Leon County, Florida. LINDA M. RIGOT Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399-1550 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 13th day of April, 1984. COPIES FURNISHED: Douglas A. Shropshire, Esquire Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Joseph F. Scioli, Jr. 246 North Krome Avenue Florida City, Florida 33034 Frederick Roche, Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 James Linnan, Executive Director Construction Industry Licensing Board Post Office Box 2 Jacksonville, Florida 32202
The Issue Whether the Respondent willfully violated local building codes and abandoned a job.
Findings Of Fact David Cobb is a registered general and registered roofing contractor with the Florida Construction Industry Licensing Board. The job in question was done in Gainesville, Florida. Gainesville has a local building code, having adopted the Southern Standard Building Code, but does not have a local competing board. Cobb entered into a contract with John Larramore for a room addition to Larramore's home. Larramore paid Cobb a total of $2,475.84 on the job which was priced as $4,080.24, an amount which included the price of floor covering which both parties acknowledged would be purchased by Larramore and deducted from the monies paid Cobb. Cobb began work on the project. Larramore was not happy with the craftsmanship on the job, which was overseen by Cobb's foreman. Eventually, Larramore contacted a friend who was a contractor. This friend indicated to Larramore that the job should be inspected by the building inspectors of Gainesville, and Larramore contacted the Building Department of Gainesville. Pending inspection by the Department, Larramore told Cobb to stop work until he was contacted again. The chief building official, Leslie Davis, inspected the Larramore job on May 4, 1979. He found several violations of the local building code. Davis was accompanied by the Board's investigator, Herman Cherry. Davis contacted Cobb and advised him to correct the code violations. Davis sent Cobb a letter on May 10, 1979, outlining the violations and giving Cobb 14 days to correct these violations. See Exhibit 5. Cobb tried to contact Larramore by telephone without success concerning correction and completion of the job. Eventually, Cobb wrote Larramore an undated letter, Exhibit 4, which was written after the inspection by Davis and Cherry on May 4, 1979. Larramore was uncertain of the date he received the letter but did acknowledge it was after the Davis/Cherry inspection. Larramore did not contact Cobb after he received Cobb's letter. Instead, he contracted with another contractor to complete the job. This contractor began work on May 17, 1979.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, the Hearing Officer recommends that the Florida Construction Industry Licensing Board take no action against David Cobb. DONE and ORDERED this 9th day of April, 1980, in Tallahassee, Leon County, Florida. STEPHEN F. DEAN, Hearing Officer Division of Administrative Hearings Room 101, Collins Building Tallahassee, Florida 32301 (904) 488-9675 COPIES FURNISHED: Michael E. Egan, Esquire 217 South Adams Street Mr. David Cobb Post Office Box 1306 16146 James Couzens Freeway Tallahassee, Florida 32301 Detroit, Michigan 48221
The Issue The issue in this case is whether Respondent violated Sections 489.119(2), 489.124(2), 489.129(1)(n) and (p), and 489.1425(1), Florida Statutes (1999) (hereinafter, "Florida Statutes"), respectively, by: engaging in contracting as a business organization without applying for a certificate of authority through a qualifying agent and under a fictitious name; failing to notify Petitioner of the mailing address and telephone number of the certificate holder or registrant; committing incompetency or misconduct in the practice of contracting; proceeding on a job without obtaining applicable building permits and inspections; and failing to provide a written statement explaining the consumer's rights under the Construction Industries Recovery Fund (the "Fund").
Findings Of Fact Petitioner is the state agency responsible for regulating the practice of contracting. Respondent is licensed as a contractor with license number CC C018992. At all relevant times, Respondent was registered or certified with Petitioner as the qualifying agent for Earl Benjamin and Company, Inc. ("EBCO"). As the qualifying agent, Respondent was responsible for all of EBCO's contracting activities in accordance with Section 489.1195. Respondent failed to obtain a certificate of authority from Petitioner. On April 4, 1998, EBCO entered into a contract with Mr. Joseph Chapman ("Chapman") to repair a leak in the roof of Chapman's residence at 1880 Jessica Road, Clearwater, Florida. On the advice of Mr. Dale Edwards, a representative of EBCO, Chapman entered into a second contract with EBCO to repair the entire roof for an additional cost. None of the contracts or other documentation provided by EBCO to Chapman contained a notice explaining the consumer's rights under the Fund. The contract prices for the first and second contracts were $4,500 and $7,500, respectively. After completing the work, Respondent sent another bill to Chapman for $1,750 for additional materials and repairs. Chapman paid, and Respondent accepted, $13,210 as payment in full of all amounts owed to Respondent. The checks signed by Chapman were made payable to "Earl Benjamin and Company and/or EBCO." After EBCO completed the work on the Chapman residence, the roof leaked in four places and continued to leak as of the date of hearing. Chapman contacted Respondent and other EBCO representatives repeatedly in attempt to stop the leaks. EBCO has been unable to stop the leaks in Chapman's home. The Pinellas County Building Department (the "Building Department") never performed a final inspection approving the work performed by Respondent. The Building Department issued building permit number 175919 to Respondent on April 23, 1998. On May 26, 1998, Chapman indicated to the Building Department that the roof leaked, and an inspector for the Building Department inspected the roof on the same date. The inspector found that the birdcage was not reassembled, some flashing was too short, and other eaves and rates were not constructed properly. The inspector issued a red tag for the violations. On June 16, 1998, the inspector inspected the roof again and issued a second red tag for some violations that remained uncorrected. On November 16, 1998, the inspector inspected the roof again and issued another red tag because the roof still leaked. On January 14, 1999, the inspector met with Chapman and representatives for EBCO to address the continuing problems with the roof. The inspector instructed Respondent to update his address and licensing information. On January 26, 1999, the inspector inspected the roof for the last time. The roof still leaked. On May 9, 1998, EBCO entered into a contract with Jack and Dawn Wilcox ("Wilcox") to repair the roof and install roof vents in the Wilcox residence at 247 144th Avenue, Madeira Beach, Florida. The contract price for the Wilcox job was $1,800. The Wilcoxes paid, and Respondent accepted, $1,800 as payment in full of all amounts owed to Respondent. The checks signed by the Wilcox's were made payable to "EBCO" or "EBCO Roofing." After EBCO completed the work on the Wilcox residence, the roof leaked around the vents installed by Respondent. The work performed by Respondent suffered from incompetent workmanship including ragged and non-uniform holes cut into the roof for the vents. Mr. Wilcox attempted to contact Respondent and other EBCO representatives repeatedly in an attempt to correct the leaks in the roof. No one from EBCO returned the messages from Mr. Wilcox. Mr. Wilcox attempted to physically locate Respondent at Respondent's business address, but Respondent's address was incorrect. The Wilcoxes incurred additional expenses of $1,500 to correct problems caused by Respondent. On October 24, 1998, Mr. Wilcox entered into a contract with Kurt Dombrowski Roofing Contractor ("Dombrowski") to repair the leaks in the roof and to re-install the vents in the roof. Dombrowski correctly performed the work, and Wilcox paid Dombrowski $1,500. The Wilcoxes have no further problems with the roof. Respondent never obtained a building permit for the work performed on the Wilcox roof. The Wilcox home was located within the jurisdiction of the City of Madeira Beach (the "City"). The City no longer has a building department. The Pinellas County Building Department assumed the responsibilities of the City. Respondent never obtained a building permit for the Wilcox job.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that the Board enter a Final Order finding Respondent guilty of violating Sections 489.119(2), 489.124(2), 489.129(1)(n) and (p), and 489.1425(1), imposing administrative fines in the aggregate amount of $3,200, requiring Respondent to pay restitution to Chapman and Wilcox in the respective amounts of $13,210 and $1,800, and requiring Respondent to pay costs of investigation and prosecution in the amount of $690.40. DONE AND ENTERED this 9th day of October, 2000, in Tallahassee, Leon County, Florida. DANIEL MANRY Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 SUNCOM 278-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 9th day of October, 2000. COPIES FURNISHED: Rodney L. Hurst, Executive Director Construction Industry Licensing Board Department of Business and Professional Regulation 7960 Arlington Expressway, Suite 300 Jacksonville, Florida 32211-7467 Barbara D. Auger, General Counsel Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Robert A. Crabill, Esquire Department of Business and Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-3060 Earl Henry Benjamin 9914 Connecticut Street Gibsonton, Florida 33534
The Issue The issue is whether Respondent's license as a registered building contractor should be disciplined for the acts alleged in the Administrative Complaint, as amended?
Findings Of Fact Respondent, Robert Tucker, is a registered building contractor holding State of Florida license number RB 0033063 (Ex. 7). Respondent was licensed as a building contractor by the State of Florida in September 1978, and has remained licensed at all times material hereto (Ex. 7). Since September 20, 1978, Respondent has held a local Building Contractor's License issued by the Leon County Contractor Licensing and Examination Board (Ex. 7). Respondent's license with the Department has been delinquent since July 1, 1985 (Ex. 7). In July 1983, Respondent made an oral agreement with Violet Gladieux to erect a carport for her at a cost of $1,350 (Ex. 3). Ms. Gladieux's residence is located at 2321 Belle Vue Way, within the city limits of Tallahassee. Jay Gladieux, Jr. became acquainted with Mr. Tucker from his position as an employee of Mr. Tucker on a prior construction project. Mr. Gladieux introduced his mother, Ms. Gladieux, to Mr. Tucker for the carport construction. It was orally agreed that Ms. Gladieux would pay Mr. Tucker for supplies as they were needed. Mr. Tucker began erection of the carport approximately one week after July 11, 1983, when he received the first payment of $300. On July 29, 1983, Mr. Tucker received final payment of $350 so that he could complete the carport (Ex. 3). Approximately two weeks after July 29, 1983, Respondent completed the carport. A permit for the erection of the carport was required by Section 7-63, Buildings and Construction Regulations (The Building Code) of the City of Tallahassee. The language of that ordinance has not changed since 1957 (Ex. 1). No building permit was ever obtained by Mr. Tucker for erection of the carport. Approximately two weeks after completion of the carport, it collapsed after a heavy rainfall (Ex. 4 and 5). Mr. Tucker returned to repair the damaged carport. He erected center studs and was to return later to complete the damage repair. Mr. Tucker has failed to return to complete the damage repair after requested to do so by Jay Gladieux. When an administrative complaint has been filed against a contractor, personal service of the complaint is attempted upon the contractor at his last address of record. If personal service cannot be effectuated at the contractor's last address of record, further attempts are made to locate the contractor. The building departments, both City and County, the telephone company, utility company and post office are contacted. The building departments are contacted to determine if the contractor has obtained any permits, for the permits would list the contractor's address. The telephone company is contacted for prior and new telephone listing(s) with address(es). The post office is contacted for forwarding address(es). The utility company is contacted for new utility service which would contain a new address (es). If the contractor cannot be located after using these avenues, a diligent search affidavit is executed by the investigator who is attempting to serve the contractor. In September 1978 and at all times pertaining to the construction of the carport, Respondent's address of record with the Department was 1515-21 Paul Russell Road and P.O. Box 20234, Tallahassee, Florida. Respondent had not notified the Department of Professional Regulation, Construction Industry Licensing Board of any change in his address (Ex. 7), other than by the new address revealed on the Election of Rights form he filed in response to the administrative complaint. The Department attempted to personally serve Mr. Tucker at his listed address and could not locate him there. On May 21, 1984, Robert E. Connell, an investigator for the Department of Professional Regulation, executed a diligent search affidavit concerning service of the Administrative Complaint upon Mr. Tucker in this proceeding (Ex. 8).
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is recommended that Respondent be found guilty of the charges in count one of the Administrative Complaint, as amended; that counts two and three be dismissed; and that he be fined $250.00. DONE AND ORDERED this 4th day of April 1986 in Tallahassee, Leon County, Florida. WILLIAM R. DORSEY,JR., Hearing Officer Division of Administrative Hearings The Oakland Building 2009 Apalachee Parkway Tallahassee, Florida 32399 (904) 488-9675 Filed with the Clerk of the Division of Administrative Hearings this 4th day of April 1986. COPIES FURNISHED: Mr. James Linnan Executive Director Construction Industry Licensing Board P.O. Box 2 Jacksonville, Florida 32202 Mr. Fred Roche Secretary Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Salvatore A. Carpino, Esquire General Counsel Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Errol H. Powell, Esq. Department of Professional Regulation 130 North Monroe Street Tallahassee, Florida 32301 Mr. Robert Tucker P.O. Box 10218 Tallahassee, Florida 32302
