Findings Of Fact On February 27, 1974, Pelle J. Lindquist contracted with Patrick G. Yeager to build a house on Concord Road in Ormond Beach, Florida. This contract was admitted in evidence as petitioner's Exhibit No. 1. The contract called for work to begin on March 1, 1974, and to be completed within 90 days. Work did not begin on March 1, 1974, but did begin in the latter half of March, 1974. Frequent rain in March, 1974, caused the roof to warp, so that it had to be replaced. After considerable delay in undertaking the repair, actually replacing the roof took only about a week. Replacing the roof added significantly to respondent's costs in performing under the contract. Eleven months after construction began, Mr. Yeager moved in. Because the kitchen and both bathrooms lacked wallpaper, and because the gravel yard was partly unfinished, respondent Lindquist paid Mr. Yeager $300.00, in exchange for which Mr. Yeager released Mr. Lindquist from all liability in connection with the house. The release was admitted in evidence as respondent's Exhibit No. 1. In the course of construction, Haven Vaughn, a sub- contracting carpenter, filed a notice of intent to lien on behalf of himself and his partner, Cal Fisher. As long as Mr. Lindquist was allowed draws on the construction loan, Messrs. Vaughn and Fisher were paid regularly. For reasons which were not developed in the evidence, the lender withheld part of the loan proceeds from respondent. When the draws stopped, the carpenters were not paid, and they stopped work on the Yeager house. The lender ultimately paid the carpenters in full. At the time Mr. Yeager contracted with Mr. Lindquist for the house, Mr. Lindquist entered into a separate agreement with Mr. Cameron, a real estate broker who introduced Mr. Lindquist to Mr. Yeager. Under the latter agreement, Mr. Lindquist was to pay Cameron Realty Company a brokerage fee upon "obtaining last draw from lending firm." The brokerage fee has not been paid and is currently the subject of civil litigation. On February 15, 1974, Mr. and Mrs. Horace N. Smith, Jr., contracted with respondent for the construction of a house on another lot on Concord Road in Ormond Beach, Florida. This contract was admitted in evidence as petitioner's Exhibit No. 2. The contract called for completion of the Smith house on or about June 15, 1974. After the contract was signed, the Smiths returned to New Jersey, entrusting oversight of the project to Mr. Cameron, a real estate broker who introduced Mr. Lindquist to the Smiths. As construction progressed, Mr. Cameron kept Mrs. Smith advised, and she mailed installment payments on the strength of Mr. Cameron's representations. In this fashion, Mr. Lindquist was paid 75 percent of the total contract price of $27,600.00. For reasons which were not developed in the evidence, the Smiths stopped payments under the contract, presumably at Mr. Cameron's suggestion. When the payments stopped, work on the house also stopped, and, during the ensuing hiatus in construction, vandals broke a glass door, scrawled obscenities on the walls, scraped the walls, damaged the outside doors, and ruined the wooden trim. Work had fallen far behind schedule when, in April of 1975, a lawyer retained by Mr. and Mrs. Smith wrote Mr. Lindquist to the effect that the Smiths would take over the project unless it was finished within a week. When the week had passed, the Smiths began dealing directly with the sub-contractors, the house was eventually completed at a total cost to the Smiths of $29,100.00, or $1,500.00 more than the Smiths had agreed to pay Mr. Lindquist for the job. As completed, the house lacked an electric garage door opener and a sprinkler system which Mrs. Smith guessed would cost $1,000.00, but no competent evidence as to the cost or value of either the door opener or the sprinkler system was adduced. Vandalism added significantly to the cost of the Smith house. Mr. Lindquist replaced a glass door broken by vandals. On account of the vandalism, the Smiths paid the carpenters an additional $300.00 for their labor. The front doors, the trim, and all bays had to be replaced; the cost of replacement materials was not established. At the time Mr. and Mrs. Smith contracted with Mr. Lindquist for the house, Mr. Lindquist entered into a separate agreement with Mr. Cameron. Under the latter agreement, Mr. Lindquist was to pay Cameron Realty Company a brokerage fee. The brokerage fee has not been paid and is currently the subject of civil litigation. Certified general contractors' licenses are renewable annually in June, pursuant to Section 468.108, Florida Statutes (1975). Mr. Lindquist had such a license for 1974-75. In June of 1975, he desired to renew his license, but in a fashion which would authorize him to contract on behalf of a corporation, rather than as an individual. He telephoned the Jacksonville office of the Florida Construction Industry Licensing Board and explained his situation. That office mailed him forms which he filled out and mailed back in June of 1975. In March of 1976, some nine months later, the completed forms were mailed back to respondent, but no license was issued. On March 22, 1976, Mr. Clyde Pirtle, an investigator employed in the Jacksonville office of the Florida construction Industry Licensing Board, filled out and mailed to respondent a Notice of Violation," notifying respondent that he had failed to renew his certificate during June of 1975. The same "Notice of Violation" advised respondent of his putative failure to notify the Florida Construction Industry Licensing Board of his new address, although his application papers for the 1975-76 license had been returned to the new address. On the Monday after the Friday on which respondent received the "Notice of Violation," he telephoned Mr. Pirtle's office and was told that Mr. Pirtle would contact him. On or about June 3, 1976, Mr. Pirtle did contact respondent and meet with him. At this meeting, respondent showed Mr. Pirtle the papers he had mailed to the Board in June of 1975, and which were returned to him unprocessed in March of 1976. Mr. Pirtle told respondent that the papers had been returned because the application forms were for a registered, and not for a certified, contractor's license, and furnished respondent another set of forms. Respondent filled out the new set of forms and mailed them to the Board in June of 1976. A month and a half before the hearing in this cause, respondent received 1976-1977 certified general contractor's license No. CGC007702, which is currently in force. No contractor's license for 1975-76 was ever issued to respondent. On May 3, 1976, respondent applied for and was issued a building permit to erect a new residence at 1623 Anniston Avenue in the City of Holly Hill. At that time, respondent had no current contractor's license and presented to the authorities a license which had expired.
Recommendation Upon consideration of the foregoing, it is RECOMMENDED that disciplinary action against Respondent, if any, be limited to a reprimand. DONE and ENTERED this 6th day of April, 1977, in Tallahassee, Florida. ROBERT T. BENTON Hearing Officer Division of Administrative Hearings Room 530 Carlton Building Tallahassee, Florida 32304 COPIES FURNISHED: Mr. Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. Thomas L. West, Esquire Post Office Box 1857 1030 Volusia Avenue Daytona Beach, Florida 32015 J. K. Linnan, Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
Findings Of Fact At all times material to these proceedings, the Respondent, ROBERT MENSCHING, was a certified residential building contractor in Florida, and held license number CR C020166. Mr. Mensching was the owner and qualifying agent for Robert Mensching Homes. On or about July 10, 1986, a written proposal was submitted by the Respondent to Mr. and Mrs. Mangiardi for the construction of a single family dwelling in Cape Coral, Florida. The construction price was $60,000.00, with an additional $500.00 for the purchase of the house plans. Mr. and Mrs. Mangiardi paid for the plans on the date of the proposal. Revisions to the proposal were submitted to the Mangiardis in September, 1986. The purchase price and the payment schedule remained the same. The proposal was accepted by the Mangiardis, and the down payment of $5,000.00 required by the contract to start construction, was given to the Respondent. Construction commenced in November 1986. By March 26, 1987, the Respondent had been paid $53,750.00 of the total construction contract price. This included the fourth draw on a five draw payment schedule. Only $6,250.00 remained to be paid by the purchasers for the last phase of construction. In April 1987, the Respondent informed Mr. Mangiardi that he would not complete the final phase of construction. The Respondent informed Mr. Mangiardi that he would pay him $5,000.00. An accounting was not given to the purchasers of the monies disbursed by the Respondent pursuant to the construction schedule. After the Respondent left the project, the Mangiardis were given notice of an outstanding lien in the amount of $963.80, which was owed to Kirkland Electric, Inc. Another Notice to Owner was filed by Wallcrafters, another subcontractor, for $5,272.50. The work completed by both subcontractors was performed during the Respondent's term as the prime contractor on the project. These two subcontractors were never paid by the Respondent out of the draws received by him for that purpose. The Respondent did not pay the $5,000.00 he told Mr. Mangiardi he would pay in April of 1987. The evidence is unclear as to whether this amount of money was a payment of liquidated damages for the breach, the balance of funds entrusted to the contractor which had not been disbursed in the preceding construction phases, or the amount of unpaid liens known to the contractor at the time of breach. The Respondent filed for bankruptcy after a judgment was entered against him in a civil action by the Mangiardis for breach of contract. A Notice of Aggravation was not submitted during the formal hearing regarding the actual damage to the licensee's customers as a circumstance to be considered in aggravation of the penalty to be assessed. A copy of the Florida Construction Industry Licensing Board's previous letter of reprimand was not presented at hearing so that the hearing officer and the Board could use the prior violation for aggravation purposes.
The Issue Whether disciplinary action should be taken against Respondent’s license to practice contracting, license number CGC 060878, based on violations of Subsection 489.129(1), Florida Statutes (2005)1, as charged in the three-count Administrative Complaint filed against Respondent in this proceeding. Whether Respondent violated Subsection 489.129(1)(g)2., Florida Statutes (Count I) by committing mismanagement or misconduct in the practice of contracting that causes financial harm to a customer; Subsection 489.129(1)(j), Florida Statutes (Count II) by abandoning a construction project in which the contractor is engaged or under contract as a contractor, and Subsection 489.129(1)(m), Florida Statutes (Count III) by committing incompetency or misconduct in the practice of contracting. And, if so, what discipline should be imposed, pursuant to Section 489.129, Florida Statutes, and Florida Administrative Code Rule 61G4-17.002.
Findings Of Fact Based on the evidence and testimony of the witnesses presented and the entire record in this proceeding, the following facts are determined: At all times material, Respondent was a certified general contractor, having been issued license number CGC 060878 by the Florida Construction Industry Licensing Board (CILB). At all times material, Respondent was the qualifier of Epic Building and Development Corporation, a Florida Corporation, with its principal place of business in the Fort Myers area. On February 22, 2005, Respondent entered into a contract with Edward Dueboay to rebuild a house owned by Dueboay and his wife, located at 22299 Laramorre Avenue, Port Charlotte, Florida, which had been distroyed some months earlier by Hurricane Charlie. The price of the contract was $150,000.00. On or about March 24, 2005, Dueboay gave Respondent a check in the amount of $3,500 payable to Contractors Marketing America, Inc. (CMA, Inc.), for the engineering plans. On May 6, 2005, Dueboay paid Respondent $5,000, as an advance on the contract. Respondent did not obtain the building permit from the Charlotte County Building Department until December 12, 2005, and work on the project did not start until January 2006. Because of the enormous damage caused by the hurricane, contractors in the area were flooded with jobs, and significant shortages in building materials also occurred. On January 13, 2006, Respondent billed Dueboay $11,000.00 for land clearing and filling, $750.00 for permit fees, and $3,200.00 for a temporary electric pole. The bill gave credit for the $5,000.00 Dueboay paid on May 6, 2005, and showed a balance due of $10,000.00. On January 20, 2006, Dueboay paid the above-mentioned invoice, by check to Respondent, in the amount of $10,000.00. Respondent paid $4,600.00 to the sub-contractor who performed the lot clearing and filling, but billed Dueboay $11,000.00. However, the contract provided for a $2,500.00 allowance for clearing and filling, and a $750.00 allowance for permit fees. Section 11.c of the contract also provided that Respondent shall provide and pay for all materials and utilities and all other facilities and services necessary for the proper completion of the work on the project in accordance with the contract documents. To pay for the remainder of the contract, Dueboay negotiated and obtained a loan in the total amount of $153,000.00 from Suncoast Schools Federal Credit Union (Credit Union). On March 21, 2006, Dueboay and the Credit Union signed the construction loan agreement. On March 21, 2006, Respondent was paid $18,235.00 by the Credit Union for the pre-cast walls used in the erection of the structure. On May 11, 2006, Respondent finished Phase I of the project. On May 15, 2006, Respondent received $11,350.00 as the first draw by the Credit Union. On June 20, 2006, Respondent finished Phase II of the project. On June 20, 2006, Respondent was paid $26,335.00 as the second draw by the Credit Union. From June 2006 to November 2006, Respondent performed no work on the house under the Dueboay contract. Because the roof was not completed, mold appeared on and in the house. On August 21, 2006, Dueboay paid $109.95 to America’s Best Cleaning and Restoration, Inc., for mold removal. On or before September 13, 2006, Dueboay hired an attorney to clarify billing charges related to lot filling, permit fees and the temporary electric pole, and to prompt Respondent to resume work abandoned since June 2006. Under the Credit Union Loan Agreement, after several extensions, the completion of the Dueboay home should have taken place on or before October 17, 2006. On October 18, 2006, the Loan Agreement extension expired, and Dueboay was required to pay mortgage and interest on the loan, even though construction of the house was not completed. On November 10, 2006, Dueboay’s attorney sent Respondent a third letter advising him that the project was stagnating; that after eighteen months since the signing of the contract, the roof of the house was not yet completed; and that, under the contract, Respondent was obligated to substantially complete all work in a reasonable time after construction had started. On or about December 1, 2006, the building permit expired and had to be renewed. At some point after November 10, 2006, Respondent resumed work and finished Phase III on March 8, 2007, with the exception that some doors were not installed, including the garage door. Respondent submitted a sworn Contractor’s Affidavit stating that all subcontractors had been paid, and that there are no liens against Dueboay’s property. However, Dueboay had to pay Charlotte County Utilities $224.93 on October 29, 2007, and $240.00 to Pest Bear, Inc., on May 7, 2008, to avoid two liens being recorded against his property. From March 8, 2007, until July 2007, Respondent performed no work under the contract. David Allgood, another general contractor, was hired by Respondent to complete some of Respondent’s projects in the Port Charlotte area, including the Dueboay house. However, Dueboay was not informed of this arrangement. There was no contract directly between Dueboay and Allgood. On September 4, 2007, relying on advice from his attorney, Dueboay changed the locks to the house, with the intent to keep Respondent and his employees off his property. Shortly thereafter, employees of general contractor David Allgood broke the front lock and entered the property in September 2007, without Dueboay’s permission. Dueboay, again, following advice from this attorney, called law enforcement to eject Allgood’s employees from his property. Allgood attempted to invoice Dueboay for installing some doors on the house that Respondent had previously paid for, and which Respondent should have installed. However, following advice from his attorney, Dueboay resisted Allgood’s request to pay him for the doors. Respondent was paid a total of $122,246.03 for the Dueboay project, before the contract was cancelled. Respondent did not complete work from Phases IV and V, with the following exceptions: he did some work on the driveway, painted the interior, did some cabinet work, exterior trim and soffit, siding, stucco, and some interior trim. Therefore, Respondent completed, at best, three out of seven operations from Phase IV (interior and exterior paint, interior trim and doors, and exterior trim and soffits) and worked on, but did not complete, stucco and some cabinets. From Phase V, Respondent only worked on the driveway and sidewalks, which had to subsequently be repaired. Dueboay hired Storybook Homes, Inc. (Storybook), to complete work abandoned by Respondent from Phases IV and V. Storybook was hired to complete work as follows: install cabinets and vanities, install ceramic tiles, repair stucco, install custom tub, all electrical and plumbing per code, complete exterior paint, install hardware, sinks and faucets in the baths and showers, complete floors, install all appliances, complete air conditioning and heat, and obtain the certificate of occupancy. The amount of $122,246.03 paid to Respondent at the time when Respondent abandoned the Dueboay project represents 81 percent of the total contract price of $150,000.00. Respondent completed, at best, 75 percent of the job by completing only three out of seven operations of Phase IV and working on some additional operations that needed to be redone, like the driveway, sidewalks and stucco. Due to Respondent’s failure to perform work on time, Dueboay incurred $5,116.42 in additional expenses, as follows: $109.95 on August 21, 2006 (mold removal), $360.00 on November 23, 2006 (legal fees), $175.00 on June 4, 2007 (legal fees), $375.00 on September 4, 2007 (legal fees), $224.93 on October 29, 2007 (to satisfy lien), $668.34 on November 3, 2007 (legal fees), $200.00 on April 4, 2008 (legal fees), $1,151.05 on May 7, 2008 (to correct work performed deficiently by Respondent), $390.00 on May 7, 2008 (to repair driveway), $240.00 on May 7, 2008 (to avoid lien), and $412.00 on May 12, 2008 (to install safe room door that Respondent failed to install). The total investigative costs of this case to Petitioner, excluding costs associated with any attorney’s time, for Petitioner’s case no. 2005-028129 was $276.18.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is recommended that the Board render a Final Order as follows: Finding Respondent guilty of having violated Subsection 489.129(1)(g)2., Florida Statutes, as alleged in Count I of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $1,500. Finding Respondent guilty of having violated Subsection 489.129(1)(j), Florida Statutes, as alleged in Count II of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $2,500. Finding Respondent guilty of having violated Subsection 489.129(1)(m), Florida Statutes, as alleged in Count III of the Administrative Complaint, and imposing as a penalty an administrative fine in the amount of $1,500. Respondent’s license to practice contracting (CGC 060878) be suspended for a period of three months, followed by a period of probation for two years, upon such conditions as the Board may impose, including the payment of costs and restitution. Requiring Respondent to pay financial restitution to the consumer, Edward Dueboay, in the amount of $5,116.42 for consumer harm suffered due to payment of additional expenses. Requiring Respondent to pay Petitioner’s costs of investigation and prosecution, excluding costs associated with an attorney’s time, in the amount of $276.18. DONE AND ENTERED this 21st day of July, 2009, in Tallahassee, Leon County, Florida. S DANIEL M. KILBRIDE Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 21st day of July, 2009.
The Issue The issues are whether Respondent, Sarasota Housing Authority (the Housing Authority), discriminated against Petitioner, Estella Smith (Ms. Smith), based on her disability in violation of the Florida Fair Housing Act (the Florida FHA), and, if so, the relief to which Petitioner is entitled.
Findings Of Fact Ms. Smith, a 52-year-old female, testified she participated in the Section 8 program for over ten years and never had any problems until she moved to Sarasota. Ms. Smith moved into the Sarasota rental unit in October 2009. The Housing Authority is a public housing authority that administers the Section 8 program, within Sarasota County, Florida, pursuant to 42 U.S.C. section 1437f. Under the Section 8 program, the Housing Authority uses funds, supplied by HUD, to pay a percentage of the monthly rent on a leased "unit" directly to the landlord. The Section 8 program tenant pays the balance of the monthly rent to the landlord. Ms. Smith executed a residential lease for a HUD- approved unit on September 5, 2009, to begin a one-year rental. Ms. Smith agreed to abide by all the terms and conditions of the residential lease, including the timely payment of rent and the number of occupants (one adult and one child) in the rental unit without the written consent of the landlord. On or about October 1, 2009, Ms. Smith moved from Tampa, Florida, to Sarasota, Florida, and resided at the rental unit, 3047 East Tamiami Circle, Apartment A, Sarasota, Florida. On September 8, 2009, Ms. Smith executed the Housing Authority's personal declaration/tenant information form. Under part three of this form labeled: "Family Members (including Head of Household) currently residing in unit," there were blank lines to be completed by Ms. Smith. The following information was requested: name; date of birth; social security number; disabled; Hispanic; race; and relationship. Ms. Smith (or someone at her direction) completed the form including information about herself and her sole dependant. Under the disabled heading on the line for Ms. Smith, the word "Pending" is written. Additionally, in part five of this form labeled: "Expenses," was a question, "Are you or your spouse age 62 or older and/or disabled?" Ms. Smith (or someone on her behalf) checked the box before "no" after this specific question. Ms. Smith testified she suffered a stroke sometime in 2009 and was physically affected by it. However, she was unable to reference the specific time frame except for prior to her "porting" back to Sarasota. Ms. Smith claimed to use both a walker and a wheelchair at various times since suffering the effects of the stroke. Further, she later testified that, when she was in her rental unit, the doorways were narrow but she could maneuver in it. During her initial interview with the Housing Authority in September 2009, Ms. Smith stated she was using a walker that day and never told anyone at the Housing Authority that she was disabled. Ms. Smith admitted she withheld the rent from the landlord. However, she claimed her refusal to pay the rent was based on the lack of heat in the rental unit and the suspension of her laundry room privileges. Ms. Smith further testified Bertha L. Pete (Ms. Pete) provided Ms. Smith with assistance in her daily living activities and started living in Ms. Smith's rental unit after Christmas or in late December 2009. A copy of Ms. Pete's Florida driver's license, which reflects Ms. Smith's rental unit address as Ms. Pete's residence as of January 27, 2010, was admitted into evidence. On February 10, 2010, Ms. Smith executed a request for a live-in aide with the Housing Authority. Ms. Smith named Ms. Pete to be her proposed live-in aide. The date stamp for the Housing Authority reflects that the request was received by the Housing Authority on February 17, 2010. Any proposed live- in aide has to meet the requirements imposed by the Housing Authority and HUD. Ms. Pete did not meet the requirements. Additionally, on February 17, 2010, Ms. Smith executed a verification of live-in aide form to be completed by her physician and returned to the Housing Authority. That completed form was never returned to the Housing Authority. Both parties produced an executed medical doctor's prescription with Ms. Smith's name as the patient. The hand-written notation on the prescription is "patient needs in home aid." This verbiage is not sufficient nor equivalent to the requirements listed on the verification form for a "live-in aide." The Housing Authority did not know that Ms. Smith needed a live-in aide when she completed her application in September 2009. Although Ms. Smith utilized a walker at the time of her initial interview with the Housing Authority, the Housing Authority did not know she was disabled at that time. It is not the Housing Authority's practice to inquire of someone's physical status, as that could be perceived as a discriminatory question. Sharla Frantz (Ms. Frantz), director of human resources for the Housing Authority, is the hearing officer for the Section 8 program. Ms. Frantz testified as to the process utilized in the Housing Authority's Section 8 program. Ms. Frantz testified that Ms. Smith made a request for assistance on January 27, 2010, regarding the lack of heat in her rental unit. The Housing Authority caused an inspection to be made that same day, and a deficiency was noted. The repair was completed, and the rental unit passed a follow-up inspection on February 28, 2010. However, at the time of her complaint, Ms. Smith did not discuss any other conditions or circumstances regarding the rental unit, nor was any request for a live-in aide made. On or about February 11, 2010, the Housing Authority was made aware of a possible unauthorized person living at Ms. Smith's rental unit, as well as her failure to timely pay rent. Several days later, the Housing Authority issued a letter to Ms. Smith detailing the reasons for her termination from the Section 8 program: an unauthorized person living in the rental unit and her failure to pay rent. Ms. Smith requested a hearing from the Housing Authority, which was held on March 2, 2010. As a result of the hearing, the Housing Authority issued a letter detailing the basis for Ms. Smith's termination from the Section 8 program: an unauthorized person living in the rental unit and her failure to pay rent. Ms. Smith was afforded time to prove that the rental amount was paid in full and that Ms. Pete did not live with her. Ms. Frantz testified that at the Housing Authority hearing, Ms. Smith wrote a check for the past due rental amount. However, Ms. Frantz never received proof that the payment was actually made to the landlord. Ms. Smith testified the landlord wanted the payment in cash; however, Ms. Smith did not feel comfortable paying the rent in cash, as it did not provide her with a receipt. The rent was never paid. After waiting several days, the Housing Authority issued another letter to Ms. Smith stating that Ms. Smith was terminated from the Section 8 program for two program violations. It further described that a lease agreement, brought in to the Housing Authority, did not substantiate her claim that an unauthorized person (Ms. Pete) was not living in Ms. Smith's rental unit.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a final order be entered by the Florida Commission on Human Relations dismissing the Petition for Relief filed by Estella Smith in its entirety. DONE AND ENTERED this 17th day of August, 2011, in Tallahassee, Leon County, Florida. S LYNNE A. QUIMBY-PENNOCK Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (850) 488-9675 Fax Filing (850) 921-6847 www.doah.state.fl.us Filed with the Clerk of the Division of Administrative Hearings this 17th day of August, 2011.
The Issue The issue in this case is whether Respondent, Jerry Green, acted as a yacht and ship broker as defined in Section 326.022(1), Florida Statutes, without being licensed by Petitioner, the Department of Business and Professional Regulation, Division of Florida Land Sales, Condominiums and Mobile Homes, as alleged in a Notice to Show Cause entered September 3, 1996.
Findings Of Fact Petitioner, the Department of Business and Professional Regulation, Division of Florida Land Sales, Condominiums and Mobile Homes (hereinafter referred to as the “Division”), is an agency of the State of Florida. The Division is charged with the responsibility for carrying out the provisions of Chapter 326, Florida Statutes, the Florida Yacht and Ship Brokers’ Act (hereinafter referred to as the “Act”). Respondent is Jerry Green. Mr. Green is not licensed by the Division pursuant to the Act as a yacht and ship broker. At all times relevant to this proceeding, Mr. Green was employed at Rick’s on the River (hereinafter referred to as “Rick’s”), in Tampa, Florida. Mr. Green was compensated for his employment at Rick’s by being provided room and board. During 1996 the Division received an anonymous complaint including a copy of an advertisement from a October 13, 1995 edition of a publication known as the “West Florida Boat Trader”. The advertisement indicated it was from Rick’s and included several photographs of boats purportedly for sale at Rick’s. Among other boats listed on the advertisement was the following: 1975 42’POST Full Tuna Tower, Twin Turbo Charge Detroit 671 Out of Town Owner DESPARATE to Sell, $84,500 A similar advertisement was placed in the November 3, 1995 edition of the “West Florida Boat Trader”. Although Mr. Green denied at hearing that he had placed the advertisement, he admitted in his Response to Notice to Show Cause that “between October of 1995 and May of 1996 he advertised a 1975 42’ Post named the ‘Dunn Deal’ . . . .” He also admitted in the Response “that he advertised the 42’ Post at the request of the owner, Richard Dame, who is a personal friend, for the purpose of testing whether there was a market for such a boat and to determine the approximate value of the boat.” It is, therefore, concluded that Mr. Green was responsible for the advertisement. On May 31, 1996, James Courchaine, an investigator for the Division, went to Rick’s. After arriving at Rick’s, Mr. Courchaine met Mr. Green. Mr. Green identified himself as the “dockmaster”. Mr. Courchaine asked about the 42-foot Post and Mr. Green told him that he knew all about the Post and could talk to Mr. Courchaine about it. Mr. Green told Mr. Courchaine the Post belonged to a friend and that he, Mr. Green, could sell it. Mr. Green also indicated the Post was in Key West and that he wasn’t sure if the owner would be bringing it back. Mr. Green also told Mr. Courchaine that the owner was originally asking $84,500.00 for the Post but, that since it had been on the market so long without any interest, he might take between $79,000.00 and $81,000.00 for it. Mr. Courchaine asked Mr. Green whether the amount Mr. Green quoted included Mr. Green’s commission. Mr. Green told Mr. Courchaine that “he would be taken care of.” Mr. Green wasn’t employed as the dock master at Rick’s. Mr. Green lived on the premises and looked after the property, including boats located there. In return, he received room and meals. At the time of the formal hearing Mr. Green testified that he was not employed and that his only source of funds is Social Security. He also testified, however, that he still lives at Rick’s. The evidence failed to prove that Mr. Green has any source of funds other than Social Security. The evidence failed to prove that Mr. Green offered to sell any vessel regulated under the Act except as described in this Recommended Order.
Recommendation Based on the foregoing Findings of Fact and Conclusions of Law, it is RECOMMENDED that a Final Order be entered by the Department of Business and Professional Regulation, Division of Florida Land Sales, Condominiums, and Mobile Homes ordering Jerry Green to cease and desists from acting as an unlicensed broker in violation of the Act and that he pay a civil penalty in the amount of $500.00 within thirty days of the date this matter becomes final.DONE and ORDERED this 28th day of April, 1997, in Tallahassee, Florida. LARRY J. SARTIN Administrative Law Judge Division of Administrative Hearings The DeSoto Building 1230 Apalachee Parkway Tallahassee, Florida 32399-3060 (904) 488-9675 SUNCOM 278-9675 Fax Filing (904) 921-6847 Filed with the Clerk of the Division of Administrative Hearings this 28th day of April, 1997. COPIES FURNISHED: Suzanne V. Estrella Senior Attorney Department of Business and Professional Regulation 1940 North Monroe Street Tallahassee, Florida 32399-1007 Paul T. Marks, Esquire Post Office Box 4048 Tampa, Florida 33677 Lynda L. Goodgame General Counsel Department of Business & Professional Regulation Northwood Centre 1940 North Monroe Street Tallahassee, Florida 32399-0792 Robert H. Elizey, Jr., Director Department of Business & Professional Regulation Florida Land Sales, Condominium & Mobil Homes 1940 North Monroe Street Tallahassee, Florida 32399-0792
Findings Of Fact Notice in this case was given as required on May 2, 1977. Paul Slivyak holds registered residential contractor's license RR 0000896 issued by the Florida Construction Industry Licensing Board. Slivyak is the qualifying licensee for Allcraft Construction Company, Inc., a Florida corporation solely owned by Paul Slivyak. Gussie Hailey identified a contract between Allcraft Construction Company, Inc., to her husband, Willie Hailey, for repairs to the interior of their residence caused by fire. See Exhibit 1. She also identified a cancelled check payable to Allcraft Construction Company signed by her in the amount of $1,700 as the initial payment to Allcraft Construction Company, Inc., under the terms of the contract. The only work performed by Allcraft Construction Company, Inc., on the Hailey residence pursuant to the contract was the removal of a portion of the burned interior of the Hailey hone. Gussie Hailey identified a photograph of the material removed from the hone as it was left in her back yard by the workmen. The total work performed by Allcraft Construction Company, Inc., on the contract was performed by two young men who worked one half day. The photograph and check identified by Mrs. Hailey were received as composite Exhibit 2. After the failure of Allcraft Construction Company, Inc. to complete the work called for under the contract, the Haileys had to additionally pay approximately $4,000 to complete the job in addition to the $1,700 paid to Allcraft Construction Company, Inc. Marjorie Kneski, the wife of Mr. Joseph Kneski, identified a contract between Allcraft Construction Company, Inc., and she and her husband for the construction of an addition to their home. See Exhibit 3. She also identified a cancelled check payable to Allcraft Construction Company in the amount of $700, initial payment to Allcraft Construction Company pursuant to the contract for the construction work to be performed. After waiting two or three weeks for Allcraft Construction Company to begin work, the Kneskis became concerned and contacted the Better Business Bureau. The Better Business Bureau contacted the Florida Construction Industry Licensing Board investigator in the area. The Better Business Bureau also informed Mr. Kneski that the business reputation of Allcraft Construction Company, Inc. , was of such a nature that care should be exercised in dealing with the company. Mr. Kneski contacted Allcraft Construction Company, Inc., and advised them that he wanted his money back in that they had not started work under the contract. The Kneskis never received any of their money back from Allcraft Construction Company. The investigator for the Florida Construction Industry Licensing Board contacted Slivyak regarding the Kneski's complaint. Slivyak told the investigator that he had used the money received from the Kneskis to pay a portion of his income taxes and no longer had the money. Kneski also identified a letter received by him from Jack A. Nants, Attorney at Law, representing Allcraft Construction Company, Inc. This letter (Exhibit 5) recognizes and ratifies the contract entered into in behalf of Allcraft Construction Company, Inc., by Doug Fioto, but indicates the intention of Allcraft Construction Company, Inc. , to retain the initial $700 received from the Kneskis as liquidated damage if Allcraft Construction Company, Inc., was not allowed to perform under the contract. The contract does not contain a liquidated damage provision.
Recommendation Based upon the foregoing Findings of Fact and Conclusions of Law, the Hearing Officer recommends that the Florida Construction Industry Licensing Board revoke the registered residential contractor's license of Paul Slivyak, No. RR 0000896. DONE and ORDERED this 19th day of July, 1977, in Tallahassee, Florida. STEPHEN F. DEAN Hearing Officer Division of Administrative Hearings Room 530, Carlton Building Tallahassee, Florida 32304 COPIES FURNISHED: Barry Sinoff, Esquire 1010 Blackstone Building Jacksonville, Florida 32202 Mr. Paul Slivyak 502 South Lake Formosa Drive Orlando, Florida 32803 Mr. J. K. Linnan Executive Director Florida Construction Industry Licensing Board Post Office Box 8621 Jacksonville, Florida 32211
